Tender ID

Karnataka

Cancelled

Works

Electrical

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

Mysore Urban Development Authority

MUDA Commissioner Office Mysuru | Karnataka

Amount: ₹13.4 LCloses: 4 Nov 2024Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published28 Oct 2024
Cancelled28 Oct 2024

Cancellation Details

Cancelled

CancelledCancelledReason: Cancelled

Published 28 Oct 2024

Tender Value

₹13.4 L

EMD Value

₹32,000

Closing Date

4 Nov 2024, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Mysore Urban Development Authority

Contact Person

MUDA office

Office Number

Work Description

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

Tender Information

Tender ID

MUDA/2024-25/EL/WORK_INDENT139

Reference Number

MUDA/2024-25/EL/WORK_INDENT139

Tender Type

Open

Product Category

Electrical

Form of Contract

Electronic Documents, First(One Cover)

Location

MUDA Commissioner Office Mysuru

Source Website

Subscribe to view

Documents Required

3 documents required · 3 mandatory

Technical Bid

RequiredAnnual Turnover Certificate in any two year of Rsla 16.00 khs along with UDIN no

RequiredElectrical Registration Certificate

RequiredWork Done certificate of similar work amounting to Rs.8.00 lakhs issued by not below the rank of executive Engineer

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

Bidders shall ensure upload of relevant document certifying his/her status as Scheduled Caste/ Scheduled Tribe/other reserved category as prescribed in the tender document.

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Department Registration Details

Total value of civl engineering works executed and payments received in the last five years (year-wise)

List of existing commitments and ongoing work

List of works for which tenders already submitted

Banker Details

GST 18% shall be paid to the tendered amount separately.

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for the delay as determined by the authority while granting the extension of time.

Photo copy of the work before commencement of the work, during the work and after completion of the work should be produce with the bill.

Contractors should be registered with KPWD Class IV and above CONTRCTOR

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund.

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work

All safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent

All precautions should be taken by the contractor so that there are no damages to such public/ private properties.

Regarding Appealing Aggrieved contractors may appeal to the prescribed (Appellant) authority within 15 days as per KTTP and appeal should be through e-proc only as per Govt.order No:pwd/572/CRM-2020(E) Bangalore DT.09-10-2020. The same will not be considered if appeal through Letters.

All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erection and labour charges, complete as directed by the Engineer-in-charge of the work.

The successful Tenderer shall deliver to the Employer a Security deposit in the form of NSC/DD/FDR in the name of The COMMISSIONER, MUDA, MYSORE given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract.

Estimate rates are excluding GST as per common SR 2023-24 and prevailing GST (18% of amount put to tender) amount is kept in form of Lumpsum in sanctioned estimate according to guidelines in common SR. therefore amount put to tender and ECV amount are excluding GST. KPP Portal format has no options to add GST separately at the stage of Draft Tender Schedule process for overall amount put to tender, tender has been invited through an option with INCLUSIVE.But the itemwise rates do not include GST. Hence GST will be paid separately for the quoted amount accordingly.

Within 20 days of receipt of the Letter of Acceptance, the successful Tenderer shall deliver to the Employer a Security deposit in any of the forms given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with Clause 25.5 of ITT and Clause 44 of the Conditions of Contract.

For the vehicles/machineries/ equipments for which RTO registration is statutory,for such vehicles/machineries / equipments the contractor should upload the Registration Certificate documents issued by RTO. For Machineries and other equipments for which RTO registration is not applicable, for such machineries and equipments,purchase invoice document

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-2 . and further orders there on.

Tenders from Joint ventures are not acceptable.

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹32,000

Important Dates

Last Activity

28 Oct 2024

Published

28 Oct 2024

Download Ends

4 Nov 2024

BOQ Preview

•

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

•

Item Description:Rabbit ACSR Conductor with 1.5% sag ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:LT 4 Pin Cross Arm with clamps, bolts, nuts and washers for RCC Pole - 9 Mtr Long, 145 Kg WL ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:LT 2 Pin Cross Arm with clamps, bolts, nuts for RCC Pole - 9 Mtr Long, 145 Kg WL ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:1.1 kV Pin Insulator with GI Pin ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:No. 8 Strain Insulator ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:Supplying and Fixing of mm dia class A GI pipe bracket upto 2 ms long bent at suitable angle and fixing to this bracket street light fitting of all capacities to GI or GI or rail or R...

•

Item Description:Fixing halogen/metal halide /SVL/IL/LED floodlight fitting over existing pole / wall ceiling including clamps, bolts, nuts and wiring using suitable capacity wires. ---- With all lead...

•

Item Description:1.1 kV Class HR (Heat Resistant) PVC Insulated & Sheathed Aluminium Single Core Lead wires as per IS-694: 2010PVC Wire - 6Sqmm Weight per 100 Mtr Coil: 2.4 Kg ---- With all lead and l...

•

Item Description:1.1 kV Class HR (Heat Resistant) PVC Insulated & Sheathed Aluminium Single Core Lead wires as per IS-694: 2010 PVC Wire - 10 Sqmm Weight per 100 Mtr Coil: 5.3 Kg ---- With all lead an...

•

Item Description:Supply and fixing of 3pole power contactor with NO/NC contacts on existing wood/panel board using necessary bolts, nuts, washers and wiring etc., complete with AC-3 Rating and as p...

•

Item Description:Supplying and fixing miniature circuit breakers on existing MCB distribution boards using necessary fixing materials and 'C' Type curve, indicator ON/OFF, energy cross-3 with Short ci...

•

Item Description:Supplying and fixing Microprocessor based Electronic timer (without contactor, Din Mounting using necessary bolts, nuts and washers etc) 3-120sec setting. ---- With all lead and lift ...

•

Item Description:Supplying & fixing of Porcelain fuse channel with cut out on existing wooden/panel using necessary nuts, bolts and washers. 32Amps ---- With all lead and lift and as per direction of...

•

Item Description:PVC Insulation Tapes 19 mm wide and in rolls of 10 Mtr ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:Street light metering box made of MS sheet steel with Clamp ---- With all lead and lift and as per direction of Engineer In charge of work

•

Supply of LED Streetlight luminary with pressure die cast aluminium housing body for optimal thermal dissipation. Lamp compartment comprising of anti glare clear diffuser with Injection moulded polyca...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw1.doc

Tender Document • 0.40 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Tender ID

Karnataka

Cancelled

Works

Electrical

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

Mysore Urban Development Authority

MUDA Commissioner Office Mysuru | Karnataka

Amount: ₹13.4 LCloses: 4 Nov 2024Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published28 Oct 2024
Cancelled28 Oct 2024

Cancellation Details

Cancelled

CancelledCancelledReason: Cancelled

Published 28 Oct 2024

Tender Value

₹13.4 L

EMD Value

₹32,000

Closing Date

4 Nov 2024, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Mysore Urban Development Authority

Contact Person

MUDA office

Office Number

Work Description

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

Tender Information

Tender ID

MUDA/2024-25/EL/WORK_INDENT139

Reference Number

MUDA/2024-25/EL/WORK_INDENT139

Tender Type

Open

Product Category

Electrical

Form of Contract

Electronic Documents, First(One Cover)

Location

MUDA Commissioner Office Mysuru

Source Website

Subscribe to view

Documents Required

3 documents required · 3 mandatory

Technical Bid

RequiredAnnual Turnover Certificate in any two year of Rsla 16.00 khs along with UDIN no

RequiredElectrical Registration Certificate

RequiredWork Done certificate of similar work amounting to Rs.8.00 lakhs issued by not below the rank of executive Engineer

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

Bidders shall ensure upload of relevant document certifying his/her status as Scheduled Caste/ Scheduled Tribe/other reserved category as prescribed in the tender document.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Department Registration Details

Total value of civl engineering works executed and payments received in the last five years (year-wise)

List of existing commitments and ongoing work

List of works for which tenders already submitted

Banker Details

GST 18% shall be paid to the tendered amount separately.

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for the delay as determined by the authority while granting the extension of time.

Photo copy of the work before commencement of the work, during the work and after completion of the work should be produce with the bill.

Contractors should be registered with KPWD Class IV and above CONTRCTOR

All precautions should be taken by the contractor so that there are no damages to such public/ private properties.

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-2 . and further orders there on.

Tenders from Joint ventures are not acceptable.

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹32,000

Important Dates

Last Activity

28 Oct 2024

Published

28 Oct 2024

Download Ends

4 Nov 2024

BOQ Preview

•

Installation of electric conductors and installation of new electric lights on both sides of Hytension Road from Basavanahalli to KHB, Vijayanagar 4th stage

•

Item Description:Rabbit ACSR Conductor with 1.5% sag ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:LT 4 Pin Cross Arm with clamps, bolts, nuts and washers for RCC Pole - 9 Mtr Long, 145 Kg WL ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:LT 2 Pin Cross Arm with clamps, bolts, nuts for RCC Pole - 9 Mtr Long, 145 Kg WL ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:1.1 kV Pin Insulator with GI Pin ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:No. 8 Strain Insulator ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:PVC Insulation Tapes 19 mm wide and in rolls of 10 Mtr ---- With all lead and lift and as per direction of Engineer In charge of work

•

Item Description:Street light metering box made of MS sheet steel with Clamp ---- With all lead and lift and as per direction of Engineer In charge of work

•

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw1.doc

Tender Document • 0.40 MB

Ready to Participate?

Download all tender documents and submit your bid