Increasing the Vertical Clearance of existing 66kV Overhead EHT line crossings at Railway km No. 03/800-900 Double circuit between Channasandra (CSDR) - Yelahanka (YNK) Railway station in Hoody Division, Bengaluru, in the jurisdiction of Transmission (Operations), Circle South, KPTCL

Bidder shall have adequate knowledge of Sub-stations and Transmission lines design procedures including quality control and shall have infrastructure and erection facilities and capacity to execute the works.

Notwithstanding the above, if it is found that the performance vis a vis works awarded to the Bidder by KPTCL is either behind schedule or not satisfactory, KPTCL will be at liberty to disqualify the Bidder and reject its Bid at techno-commercial evaluation/any stage of processing of the Bid

The Bidder should possess valid Super Grade Electrical Contractors License issued by the Government of Karnataka as on the date of Bid Submission

The Bidder must not have Black listed by ESCOMS/other electrical utilities/who are in the business of distribution of power

The bidder should have satisfactorily completed in the last five years at least one work of Construction of Stations Transmission Lines Erection of Towers/Maintenance or rectification work of EHV Transmission lines/ One Terminal Bay of 220KV class or above voltage class on Total Turn Key, Partial Turnkey basis for the last five financial years in KPTCL/PGCIL/NHPC/NTPC/ any Govt., or public sector under takings & produce experience and performance certificate duly signed by competent authorities not below the rank of the Executive Engineer Electrical, which shall be in satisfactory service for a period of One year prior to date of submission of the Bid. Scanned copy of the supporting original Documents shall be uploaded.

The bidder should provide detailed information on any litigation or arbitration arising out of contracts completed or under execution by it over the preceding five years. A consistent history of awards involving litigation against the Bidder may result in rejection of bid

Notwithstanding anything stated above, the KPTCL reserves the right to assess the bidders capability to perform the work, should the circumstances warrant such assessment in the overall interest of the KPTCL

For executing the above works the contractor should have the necessary skilled men with tools and tackles. List of technical staff &tools and tackles to be uploaded in Techno commercial sheets

Bidder shall note that KPTCL may not award the work to successful bidder, even if it is lowest quoted offer (L1), if in opinion of KPTCL based on its experience, the firm may not perform well in execution of work and may delay in execution because of its existing works on hand

A Bidder shall submit only one tender in the same tendering process

Bidder shall be financially sound. Bidder shall submit audited financial reports for last five financial years preceding the date of bid submission, duly certified by the registered charted Accountant.

Bidders shall submit audited financial reports for last five years preceding the date of bid submission duly certified by Registered Charted Accountant. Minimum Average Annual Turnover MAAT of the bidder for best three years out of last five financial years ending on March or December