Karnataka

Retender

Works

Bridges/Culverts

Repairs to Bridge at Yeriyur to Mugur Road at Ch 0.25KM in Yelandur Taluk.

Public Works Department

PWD Division Office Chamarajanagara | Karnataka

Amount: ₹6.0 LCloses: 6 Dec 2025Closed

Timeline

Published28 Nov 2025
Closed6 Dec 2025
Retendered28 Nov 2025

Cancellation Details

Retendered

RetenderedRetenderedReason: Retendered

Published 28 Nov 2025

Tender Value

₹6.0 L

EMD Value

₹7,500

Closing Date

6 Dec 2025, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

TECHNICAL ASSISTANT

Office Number

082226222027

Mobile Number

9448595770

Work Description

Repairs to Bridge at Yeriyur to Mugur Road at Ch 0.25KM in Yelandur Taluk.

Tender Information

Tender ID

PWD/2025-26/BR/WORK_INDENT29744

Reference Number

PWD/2025-26/BR/WORK_INDENT29744

Tender Type

Reserved

Product Category

Bridges/Culverts

Form of Contract

Two Tender Document System(Two Cover)

Location

PWD Division Office Chamarajanagara

Source Website

Subscribe to view

Documents Required

4 documents required · 0 mandatory · 4 optional

Technical Bid

OptionalAnnual Turnover Certificate

OptionalCompany Registration Certificate

OptionalReserved Category Certificate

OptionalSmall Scale Industries Certificate

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

The bidder is required to ensure browser compatibility of the computer well in advance to the last date and time for receipt of tenders. The departments shall not be responsible for non-accessibility of KPP Portal due to internet connectivity issues and technical glitches at bidders end..

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Bidder shall pay Contract Management Module processing fees.

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs

The Tender processing fee shall not be refundable.

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders.

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund.

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval.

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work.

The successful Tenderer shall deliver to the Employer a Security deposit in the form of NSC/DD/FDR in the name of the Executive Engineer, Public works Department, Chamarajanagara Division, Chamarajanagara given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract.

Contractor should carryout additional test required to test the suitability of materials.

All safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent.

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost.

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost.

The contractors assessed available tender capacity will be calculated as per the clause 3.2 of STD tender document Attached.

All the items in the tender include all lead, lifts, loading unloading, transportation, labour, hire charges of machinery curing for concrete works, cost and conveyance of all material and all other such incidental charges necessary for successful completion of works as per the detailed technical specification and direction of Engineer in charge of this work.

All precautions should be taken by the contractor so that there are no damages to such public/ private properties.

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utility shifting. To that extent the contractor should indemnify the client.

Contractor should follow strictly the prevailing rules of labour act.

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, Public works Department, Chamarajanagar Division, Chamarajanagara during office hours on all working days.

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extent should submit HSE document defining all the procedure including the policies before execution of the project.

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have been constructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost.

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-1

The employer reserves the rights to Cancel or Withdraw any or all the tenders without Giving any reasons & Any Time.

Estimate rates are Exclusive of 18% GST,Hence GST will be paid separately for the quoted rates accordingly.

Contractors should be registered as KPWD Class IV & above Civil Contractor

The contractor will get payments based on the Schedule B only , except that no payment will be made by the Public Works Department.

3.1a Achieved in at least One financial years (2020-21 to 2024-25) an average financial turnover (in all classes of civil engineering construction works only)of Rs.5.96 Lakhs

The Intended Completion Date for the whole of the Work is 12 months (including monsoon)

The contractors assessed available tender capacity will be calculated as Assessed available tender capacity (AxNx5.00-B ) Where, A -Maximum value of civil engineering works executed in any one year during the last five years (updated to 2025-26 price level) taking into account the completed as well as works in progress taking into account the completed as well as ongoing works. N-Number of years prescribed for completion of the works for which tenders are invited.B-value, at 2025-26 price level, of existing commitments and on-going works to be completed during the next 03 months.

Regarding Appealing aggrieved contractors may appeal to the prescribed (Appellant) authority within 15 days as per KTTP and appeal should be through KPP-PORTAL only

The defect liability period is 365 days

The rates are EXCLUSIVE of 18 percent GST in the Estimate and The Amount put to tender is EXCLUSIVE of 18 percent GST

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for delay as determined by the authority while granting the extension of time

Bidders shall ensure upload of relevant document certifying his/her status as Cat-2A reserved category as prescribed in the tender cument.

For Category-2A:As per GO.FD 506 EXP-12/2023, Bangalore, dated 20.08.2024 Security deposit for an amount equivalent to 5 percent of the Contract price shall be deducted from every running bill.However, in case of first and final bill the entire security deposit will be deducted from the final bill.

Technical Criteria

Past Experience

List of existing commitments and ongoing work

Work Done Certificate

For Reserved Contractors are upload the residential/Domicile certificate stayed a minimum of 10 years issued by a competent authority Tahsildar For CAT-1 contractors only

Satisfactory Performance Certificate

For Reserved Contractors participate in the tender are upload a caste certificate issued by a competent authority Tahsildar For CAT-1 contractors only

Satisfactory Performance Certificate

Capabilities of Vendor

KPWD Registration Certificate (Class IV and above)

PWD Registration Certificate (Class I/II/III/IV)

Financial Status

Reports on the financial standing of the tenderer,such as profit and loss statements and auditor reports for the last five years i.e.2020-2021 to 2024-25

Audited CA Certificate of Annual Turnover

List of works for which tenders already submitted

Work Done Certificate

3.2 To qualify for award of this contract, each Tenderer in his name should have in the last five years i.e..2020-21 to 2024-25 (a) achieved in at least financial years a Minimum one financial turn over (in all classes of civil engineering construction works only) of Rs.5.96 lakhs

Audited CA Certificate of Annual Turnover

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹7,500

Important Dates

Last Activity

28 Nov 2025

Published

28 Nov 2025

Bid Opening

8 Dec 2025

Download Ends

29 Nov 2025

Pre-Bid Meeting

29 Nov 2025

BOQ Preview

•

Repairs to Bridge at Yeriyur to Mugur Road at Ch 0.25KM in Yelandur Taluk.

•

Mechanical Means -

•

Earth work excavation for Foundation by mechanical means for all works & depth upto 3 m, as per drawing and technical specifications, including setting out, shoring, stru...

•

Providing and laying in position Cement Concrete for levelling course for all works in foundation. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates ...

•

Providing and laying in position Cement Concrete for all Sub structures of building, Irrigation works, Sub structure works of bridges, Drain works & other parallel works fro...

•

Steel Fabrication

•

Supplying, fitting and placing TMT FE 550 / 550D Steel Reinforcement including cost of all materials, machinery, labour, cleaning, straightening, cutting,...

•

Providing and laying in position Cement Concrete for all Sub structures of building, Irrigation works, Sub structure works of bridges, Drain works & other parallel works fro...

•

Providing and laying in position Cement Concrete for all Super structures of building , Road works, Water works, Irrigation works & super structure works of bridges upto 3.50 m height. The granite...

•

Back filling behind abutment, wing wall and return wall complete including compaction as per drawing and Technical Specification - Granular material. Ref to MoRT&H : IRC - 710.1...

•

Providing and laying boulders apron on river bed for protection against scour with stone boulders weighing not less than 40 kg each complete as per drawing and Technical specification. - Boulder Laid ...

•

Providing and laying in position Cement Concrete for levelling course for all works in foundation. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates ...

•

Providing and laying in position Cement Concrete for all Foundation works. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS Codes machine mixed with ...

•

Painting Two Coats on New Concrete Surfaces - Painting two coats after filling the surface with synthetic enamel paint in all shades on new plastered concrete surfaces. Ref to MoRT&H : IRC - 8...

•

Boundary pillar / Guard Stone - Reinforced cement concrete M15 grade boundary pillars of standard design as per IRC:25, fixed in position including finishing and lettering but excluding...

•

PIPE CULVERTS - Providing and Laying Reinforced Cement Concrete Pipe NP3 as per Design in Double Row - Providing and laying reinforced cement concrete pipe NP3 for culverts on first class beddin...

•

Construction of Embankment by excavating the available approved Gravel/ Murrum deposited at a place or borrow pits during or prior excavation with all lifts and lead, transporta...

•

Construction of Embankment with approved materials deposited at site from roadway cutting and excavation from drain and foundation of other structures graded with desired compaction. (R...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw-1 29744 Cat 2A.pdf

Tender Document • 0.68 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at [email protected].