Quatation/22/JJ/02/ELV

Providing Fully compherensive maintainance of ESSL make Access Control comprising of Controller- 1 No. , Readers - 6 Nos, Mangnetic door locks - 7 Nos, Time & Attendance Software - 01 No, Control software 01 no, work station - 01 No. , A3 printer 01 No. The nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements . Scope of work 1) Checking of general operation of main Controller 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts with authentic OEM spares free of cost 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of D link Make Data Network comprises of L2 Managed switches below 28 ports - 21 No, & L2 Managed switches above 28 ports - 19 No, nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements .scope of work. 1) Checking of general operation of main server room Racks 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within1 working hours. 6 ) Checking of all data,voice cables,fiber optic cables,connectors,switches Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments such as patch- Panels, patchcords,rack,networking switches,Cat-6 4 pair UTP cablers,12 pair Fiber optic cables,LIU (line interface unit )with authentic OEM spares free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of D link Make Data Network comprises of 48 port L2 Managed switches 19No, .Nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements . scope of work. 1) Checking of general operation of main server room Racks 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within1 working hours. 6 ) Checking of all data,voice cables,fiber optic cables,connectors,switches Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments such as patch- Panels, patchcords,rack,networking switches,Cat-6 4 pair UTP cablers,12 pair Fiber optic cables,LIU (line interface unit )with authentic OEM spares free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of D link Make Data Network comprises of L3 Managed Switch - 9 Nos, Patch Panels, racks, and other Passive infrastructure he nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements . scope of work. 1) Checking of general operation of main server room Racks 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within1 working hours. 6 ) Checking of all data,voice cables,fiber optic cables,connectors,switches Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments such as patch- Panels, patchcords,rack,networking switches,Cat-6 4 pair UTP cablers,12 pair Fiber optic cables,LIU (line interface unit )with authentic OEM spares free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of D link Make Passive infrastructure comprises of racks & other passive Network nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements . scope of work. 1) Checking of general operation of main server room Racks 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within1 working hours. 6 ) Checking of all data,voice cables,fiber optic cables,connectors,switches Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments such as patch- Panels, patchcords,rack,networking switches,Cat-6 4 pair UTP cablers,12 pair Fiber optic cables,LIU (line interface unit )with authentic OEM spares free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of D link Make Data Network comprises of, Patch Panels, & Accesories nature of work for which services are to be provided, includes identifying the nature of fault and take corrective measures with necessary material, tools, tackles and plant. Repair or replacement of the faulty equipments as an when required with replacement of defective wiring & accessories as per requirements . scope of work. 1) Checking of general operation of main server room Racks 2) Ensure the functioning of network structural backbone cabling 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within1 working hours. 6 ) Checking of all data,voice cables,fiber optic cables,connectors,switches Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments such as patch- Panels, patchcords,rack,networking switches,Cat-6 4 pair UTP cablers,12 pair Fiber optic cables,LIU (line interface unit )with authentic OEM spares free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion , Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of Audio Video Court Room Audio Systems( Make Sennheisser) - 42 Nos x .36 Months = 1512Nos Scope of work 1) Checking of general operation of all court room Audio equipmen 2) Checking the healthiness of the system weekly. 3) Attending all the breakdowns within 2 working hours. 4) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 5) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 6) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of Court Room Display System comprising of , 50 " Displays -250 Nos ( samsung / Phillips )= 250 Nos * 36Months = 9000 Nos Scope of work 1) Checking of general operation of all court room Audio equipments 2) Checking the healthiness of the system weekly. 3) Attending all the breakdowns within 2 working hours. 4) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 5) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 6) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of Accessories for Court Room Display Systems Hdmi Splitters( Make- Milestone ) -42 Nos, HDMi cables & display mounts Scope of work 1) Checking of general operation of all court room Audio equipments 2) Checking the healthiness of the system weekly. 3) Attending all the breakdowns within 2 working hours. 4) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 5) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 6) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables if anydismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of Accesories for Court Room display system comprising of , Hdmi Transmitters & Receivers ( Make- Milestone )- 168 Nos, x 36 Months= 6048Nos Scope of work 1) Checking of general operation of all court room Audio equipments 2) Checking the healthiness of the system weekly. 3) Attending all the breakdowns within 2 working hours. 4) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 5) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 6) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables if any

Providing Fully compherensive maintainance of Audio Video Court Room Audio Systems( Make Sennheisser) - 42 Nos, Video conference systems ( Make Polycom )- 8 Nos x 36months = 288 Nos Scope of work 1) Checking of general operation of all court room Audio equipments 2) Checking the healthiness of the system weekly. 3) Attending all the breakdowns within 2 working hours. 4) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 5) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 6) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion or any dismantling, Any Physical damages & Consumables The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches.

Providing Fully compherensive maintainance of CCTV comprises of 2 MP Motorised Varifocal Vandalroof Bullet Network, 36X Speed Dome type PTZ camera ( Make- Hanwha Vision ) - 4 Nos, with 1 no controller Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if anyExclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of CCTV comprises of 5 MP Motorised Varifocal Vandalroof Dome Network Camera ( Make- Hanwha Vision ) - 593 Nos x 36 months = 21348 nos Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of CCTV Command centre comprises of Main Management Server ( Make- Hanwha Vision ) -1 no, Domain Server ( Make- Hanwha Vision ) -1 No, San Storage ( make- Netgear ) -2 No , Work stations with Display ( Make - HP)- 10 nos Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of CCTV Recroding system in command centre comprises of VMS ( Make- Hanwha Vision ) - 2 Nos, & Recording servers ( Make- Hanwha Vision ) - 7 Nos x 36months= 252 Nos Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of CCTV comprises of 95 Nos 3.5 inch Sata harddiskd for storage & displays for command centre of video recording Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of CCTV comprises of , POE Swiches , Racks, Cat-6 cables, fiberoptic backbone ( Make Dlink ) and with all other passive network infrastructure Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if any

Providing Fully compherensive maintainance of comprises of all other passive network infrastructure for CCTV Scope of work 1) Checking of general operation of all survelliance equipments 2) Ensure the functioning of Control room infrastructure including all active & Passive Parts. 3) Checking the healthiness of the system weekly. 4) Cleaning all the Hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other including replacement of all spares parts with authentic OEM spares parts free of cost. 8) extracting video files/footage whenever required ( Media will be provided by user ) as directed by the Engineer in charge , Court officials 9) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 10) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if anySoftware Application) and documentation in this regard need to be submitted to Engineer incharge /Hospital electrical sub division PWD on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches.

Providing Fully compherensive maintainance of Telecom system comprising of Digital super Hybrid type EPABX system ( Matrix Make ) of 4 PRI + 8 Nos. Digital extensions + suitable upto 400 Nos Analogue Extensions, Expendable Up to 1000 with Ip Gateways, & Phones Scope of work 1) Checking of general operation of all telecom equipments 2) Ensure the functioning of operator room infrastructure including all telephones 3) Checking the healthiness of the system weekly. 4) Cleaning all the MDF quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. including replacement of all spares parts with authentic OEM spares. 10) The contractor need to have OEM support for these components (Hardware & Software Application) and documentation in this regard need to be submitted to engineer incharge /Hospital electrical sub division PWD on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion & Consumables if anySoftware Application) and documentation in this regard need to be submitted to Engineer incharge/ Hospital Electrical sub division PWD on annual basis. The contractor shall do all the updates / up gradation of the software applications, firmware and security patches.

Providing Fully compherensive maintainance of active network for IBMS system Scope of work 1) Checking of general operation of all BMS equipments 2) Ensure the functioning of Main BMS room infrastructure including Software & Active & Passive Network 3) Checking the healthiness of the system weekly. 4) Cleaning all the DDC Panels quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts including replacement of all spares parts with authentic OEM spares. free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. 10) The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third person

Providing Fully compherensive maintainance of Passive Network for IBMS system Scope of work 1) Checking of general operation of all BMS equipments 2) Ensure the functioning of Main BMS room infrastructure including Software & Active & Passive Network 3) Checking the healthiness of the system weekly. 4) Cleaning all the DDC Panels quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts including replacement of all spares parts with authentic OEM spares. free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. 10) The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion, Physical damage & Consumables if any

Providing Fully compherensive maintainance of IBMS system compring of 5579 hard & Soft points along with Hardware & Software including 26 DDC panels & 2 Controllers Scope of work 1) Checking of general operation of all BMS equipments 2) Ensure the functioning of Main BMS room infrastructure including Software & Active & Passive Network 3) Checking the healthiness of the system weekly. 4) Cleaning all the DDC Panels quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts including replacement of all spares parts with authentic OEM spares. free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. 10) The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion, Physical damage & Consumables if any

Providing Fully compherensive maintainance of softwares for IBMS system Scope of work 1) Checking of general operation of all BMS equipments 2) Ensure the functioning of Main BMS room infrastructure including Software & Active & Passive Network 3) Checking the healthiness of the system weekly. 4) Cleaning all the DDC Panels quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts including replacement of all spares parts with authentic OEM spares. free of cost. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. 10) The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion, Physical damage & Consumables if any

Providing Fully compherensive maintainance of Public Address System compring of 10 Dual channel power Amplifiers , 2 Nos Mixers, 906 ceiling mount & 80 Flush Mount Speakers, 2 nos Controllers & all other networkinfg accessories including mutizone call Station Scope of work 1) Checking of general operation of all BMS equipments 2) Ensure the functioning of Main control room infrastructure including Software 3) Checking the healthiness of the system weekly. 4) Cleaning all the hubs quarterly. 5) Attending all the breakdowns within 2 working hours. 6 ) Checking of all cables & connectors Monthly 7) Repairs / Replacement of all damaged- nonfunctioning equipments and any other parts including replacement of all spares parts with authentic OEM spares free of cost.. 8) incase of non availibility of parts a standby arrangement shall be provided by the contractor for the interim period 9) Unattended breakdown calls or rectification of fault within specified time limit will attract penalty of Rs. 1000/- per day. 10) The contractor shall do all the updates / up gradation of the software applications, firmware and security patches. Contractor shall keep stock of adequate quantity of the contractual quantity of material ready at site throughout the contract period so that there shall not be any delay for clearing complaint due to non-availability of material at site. All Sundry hardware such as screws, rawl plugs, insulation tape, pin type lugs etc. required for the erection will fall within the scope of work and no additional payment will be made against it. Exclusions in the contract is for any equipment burnt due to external conditions or due to damages caused by any third persons or due to force majure conditions or any dismantling , shifting or reinstalltion, Physical damage & Consumables if any

Providing skilled Operator having appropiate knowledge to operate all the above systems required.( For 1 shift = 1 Duty ,for 4 person x 312 days = 1248 jobs, for 3 years =3*1248=3744

Please Enable Macros to View BoQ information