Tender ID

Karnataka

AOC

Works

Roads

Annual Maintanance of Badanaguppe-Nanjadevanapura Road from Ch 0.00 to 9.40 Km in Chamarajanagar Talluk

Public Works Department

PWD Division Office Chamarajanagara | Chamarajanagara, Karnataka

Amount: ₹9.3 LCloses: 27 Jan 2026Closed

Timeline

Published17 Jan 2026
Closed27 Jan 2026
Awarded17 Jan 2026

Bids

1 Bid17 Jan 2026

#	Company	Amount	Status
1	YARA PROJECTS ₹5.9 LAWARDED	₹5.9 L	AWARDED

Tender Value

₹9.3 L

EMD Value

₹11,700

Closing Date

27 Jan 2026, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

TECHNICAL ASSISTANCE

Mobile Number

Work Description

Annual Maintanance of Badanaguppe-Nanjadevanapura Road from Ch 0.00 to 8.40 Km in Chamarajanagar Taluk

Tender Information

Tender ID

PWD/2025-26/RD/WORK_INDENT32218

Reference Number

PWD/2025-26/RD/WORK_INDENT32218

Tender Type

Reserved

Product Category

Roads

Form of Contract

Two Tender Document System(Two Cover)

Location

PWD Division Office Chamarajanagara

Source Website

Subscribe to view

Documents Required

7 documents required · 7 mandatory

Technical Bid

RequiredKPWD Registration Certificate-CLASS-IV & ABOVE

RequiredAnnual Turnover Certificate for last 5 years from 2020-21 to 2024-25

RequiredExisting commitments and on-going works details to be completed during the next 12 months

RequiredGST Certificate

RequiredFor Reserved Contractors participate in the tender are upload a caste certificate issued by a competent authority Tahsildar For SC contractors only

RequiredFor Reserved Contractors are upload the residential certificate stayed a minimum of 10 years issued by a competent authority Tahsildar For SC contractors only

RequiredAchieved in at least One financial years a average financial turnover in all classes of civil engineering construction works only of Rs. 9.30Lakhs

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

Bidders shall ensure upload of relevant document certifying his/her status as Scheduled Caste/ category as prescribed in the tender document.

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Department Registration Details

Total value of civl engineering works executed and payments received in the last five years (year-wise)

List of existing commitments and ongoing work

List of works for which tenders already submitted

Banker Details

Bidder shall pay Contract Management Module processing fees of 0.025% of the contact value (Min Rs.500/- & Max Rs.7500/-)soon after contract has been issued to bidder

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs

The Tender processing fee shall not be refundable

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval

The employer reserves the rights to Reject or accept any or all the tenders without assigning any reasons

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work.

Contractor should carryout additional test required to test the suitability of materials

The safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent.

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost

The contractors assessed available tender capacity will be calculated as per the clause 3.1 of STD tender document Attached

All the items in the tender include all lead, lifts, loading unloading, transportation, labour, hire charges of machinery curing forconcrete works, cost and conveyance of all material and all other such incidental charges necessary for successful completionof works as per the detailed technical specification and direction of Engineer in charge of this work

All precautions should be taken by the contractor so that there are no damages to such public/ private properties

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utilityshifting. To that extent the contractor should indemnify the client

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, Pulic works Department, Hunsur Division, Hunsur during office hours on all working days.

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extentshould submit HSE document defining all the procedure including the policies before execution of the project

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have beenconstructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost.

Contractor should follow strictly the prevailing rules of labour act.

The difference in cost deposited by the lowest successful tenderer (for unbalanced) along with the performance security willbe released to the contractor 30 days after the completion of defects liability period.

The successful Tenderer shall deliver to the Employer a Security deposit in the prescribed form in the favour of the Executive Engineer, PWD Division, Chamarajanagar Division, Chamarajanagara given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-1

18-Percent GST shall be paid to the tendered amount separately

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for delay as determined by the authority while granting the extension of time

The rates are EXCLUSIVE of 18 percent GST in the Estimate and The Amount put to tender is EXCLUSIVE of 18 percent GST

Regarding Appealing aggrieved contractors may appeal to the prescribed (Appellant) authority within 15 days as per KTTP and appeal should be through e-proc only as per Govt.order No:pwd/572/CRM-2020(E) Bangalore DT.09-10-2020. The same will not be considered if appeal through Letters

Contractors should be registered as KPWD Class IV & above Civil Contractor

The tenderer should maintain the ROAD UPTO AUGUST 30 2026 (30-08-2026)

For Reserved Contractors participate in the tender are upload a caste certificate issued by a competent authority Tahsildar For SC contractors only

For Reserved Contractors are upload the residential certificate stayed a minimum of 10 years issued by a competent authority Tahsildar For SC contractors only

Technical Criteria

Financial Status

Achieved in at least one financial years a average financial turnover (in all classes of civil engineering construction works only) of Rs. 9.30 Lakhs

Audited CA Certificate of Annual Turnover

To qualify for award of this contract, each Tenderer in its name should have in the last five years i.e., 2020-21, 2021-22, 2022-23, 2023-24 & 2024-25

Audited CA Certificate of Annual Turnover

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹11,700

Important Dates

Last Activity

17 Jan 2026

Published

17 Jan 2026

Bid Opening

28 Jan 2026

Download Ends

21 Jan 2026

BOQ Preview

•

Annual Maintanance of Badanaguppe-Nanjadevanapura Road from Ch 0.00 to 8.40 Km in Chamarajanagar Talluk

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

KW-1 Indent No 32218 SC MDR.doc

Tender Document • 0.21 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Company

YARA PROJECTS

₹5.9 LAWARDED