Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

NAME OF THE CONTRACTOR E.C.Rs. 4,74,535/-

Civil works for residential buildings/industrial buildings/ industrial shed/institutional buildings/warehouses”

Technical Evaluation of Bidders

S. No. Name of the Contractor & address, email, cell no. 1. One similar completed work value not less Rs. 3.80/- Lakh or 2.Two similar completed works each value not less than Rs. 2.85/- Lakh or 3. Three similar completed works each value not less than Rs. 1.90/- Lakh Turnover-average annual turnover not less than Rs. 1.42/- Lakh Solvency - not less than Rs. 1.90/- Establishment ( staff) Remarks

Name of similar works completed during last 7 years Value of work in lakhs Date of completion (dd-mm-yyyy) Years Amount in Rs. lakhs Profit/loss in Rs. Lakhs Amount In Lakhs date (dd-mm-YYYY) Bank type Total no. required spared for work Recommendations of inspection, if any

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

FINANCIAL INFORMATION

NAME OF THE CONTRACTOR

TURNOVER OF CONTRACTOR /BIDDER FOR LAST FIVE YEARS

Financial Analysis - Details to be furnished duly supported by figures in balance sheet/profit & loss account for the last five financial years duly certified by the Chartered Accountant,as submitted by the Applicant to the Income Tax Department(Copies to be scanned & uploaded).

S. No Financial Year Gross Annual Turnover on Construction Works/ Works Contract (Rs. In Lakhs) Profit/loss(Rs. In Lakhs) Remarks

Financial arrangements for carrying out the proposed work.

Solvency certificate from bankers of the bidder(attached sepearately in FORM-B)

Signature of the Bidder (s)

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

NAME OF THE CONTRACTOR

SOLVENCY CERTIFICATE DETAILS

S. No Type of solvency Name of Bank Solvency Amount in Lakhs Issue Date (dd-mm-yyyy)

Signature of the Bidder (s)

NOTE: This table is meant for data

1 The original bankers certificate should be on letter head of bank as per form-B of the tender document.

2 In case of partnership firm,certificate should include names of all partners as recorded with the bank

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

DETAILS OF ALL WORKS OF SIMILAR NATURE COMPLETED DURING THE LAST SEVEN YEARS AS ON THE BID SUBMISSION DATE

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location Owner of sponsoring organization Cost of work Rupees (in Lakhs) Date of commencement as per contract Stipulated date of completion Actual date of completion Litigation/arbitration case pending/ in progress with details * Name and address/telephone number of officer to whom reference may be made for the work Remarks

* Indicate gross amount claimed and amount awarded by the Arbitrator

Signature of the bidders(s)

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

Projects under Execution or Awarded

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location Owner of sponsoring organization Cost of work rupees in lakhs Date of commencement as per contract (dd-mm-yyyy) Stipulated date of completion (dd-mm-yyyy) Actual date of completion (dd-mm-yyyy) Percentage progress of work. Litigation/arbitration cased pending/ in progress with details * Name and address/telephone number of officer to whom reference may be made Remarks

(i)* Indicate gross amount claimed and amount awarded by the Arbitrator

(ii)Applicant may submit separate form for giving details of work(completed) for each year to fill up the details as above.Separate sheets if any shall be numbered in sequence.

(iii)The scanned copies of the work orders for each work be uploaded.BOQ shall be furnished at a later date on request.

(iv)Certified that the above list of works is complete and no work has been left-out and the information given is correct to my knowledge and belief.

(v)The hard copy of all similar works completed during last seven years as on the previous day of date of submission date shall also be submitted on or before due date.

Signature of the Bidder (s)

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

PERFORMANCE OF WORKS

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location AGREEMENT N0 Cost of work rupees in lakhs Final completion value in lakhs Date of commencement as per contract (dd-mm-yyyy) Stipulated date of completion (dd-mm-yyyy) Actual date of completion (dd-mm-yyyy) extension of time with or without levy of penality or to be decided Amount of compensation for delay levied amount of reduced rates Perfrmance -to indicate very good/good/fair/poor Remarks

1 quality finance tech prof resources Gen behaviour 10

* Indicate gross amount claimed and amount awarded by the Arbitrator

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

NAME OF THE CONTRACTOR

S. No. Description of the item Details Remarks

1 Contractors name with address

Contact person name

2 Legal status of the bidder (a)An Individual( b)Proprietary firm (c) A firm in partnership (d) A limited company or Corporation-Attach copy of Legal document

3 Names and Titles of directors & Officers with designation to be concerned with this work

4 Designation of Individual authorised to act for the organisation

5 Was the bidder ever required to suspend construction for a period of more than 6 months(If so,give the details)

6 Registration of contractors

Financial Limit

Date of Registration

Address of the issuing authority/to whom TDS is to be remitted

8 GST registration no

Address of Commercial tax office to whom GST deducted to be remitted

9 EPF registration No

10 ESI registration No

11 LIN registration no.

12 Has the bidder or any constituent partner ever abandoned the awarded work before its completion(If so,give the details)

13 Has the bidder or any constituent partner ever been debarred/blacklisted for tendering in any organisation(If so,give the details)

14 Has the bidder or any constituent partner ever been convicted by the court of law(If so,give the details)

15 Field of Civil Engineering Construction the bidder has specialisation and interest

16 Any other information considered necessary but not included above

Signature of the Bidder (s)

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

NAME OF THE CONTRACTOR

DETAILS OF TECHNICAL & ADMINISTRATIVE PERSONNEL TO BE EMPLOYED FOR THIS WORK

S. No. Designation Total Number Required Number available for this work Remarks

""Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur." NIT NO. AMD/CR/ESG/Civil/ET-17/2025-26, Date: 25.02.2026

DETAILS OF CONSTRUCTION PLANT AND EQUIPMENT LIKELY TO BE USED IN CARRYING OUT THE WORK

NAME OF THE CONTRACTOR

S. No. Name of equipment Nos. Capacity or type Age Condition Ownership status Current location Remarks

Presently owned Leased To be purchased Proposed to be hired

Signature of the bidder (s)

Select, Excess (+), Less (-) Less (-)

Tender Inviting Authority: Regional Director, AMD, Central Region , Nagpur

Name of Work: "Providing vitrified tiles and PVC Floor for Chemistry Laboratory at AMD, Central Region, Nagpur."

Contract No: AMD/CR/ESG/Civil/ET-17/2025-26 Date: 25.02.2026

Name of the Bidder/ Bidding Firm / Company :

Sl. No. Item Description Item Code / Make Quantity Units Estimated Rate Addition / Deduction Addition / Deduction Values Currency Convertion against each Item Quoted Currency in INR / Other Currency RATE inclusive of all taxes In Figures To be entered by the Bidder Rs. P Excise Duty VAT Freight Charges ( Unloading & Stacking) Any Other Taxes/Duties/Levies Other Taxes 2 IIIrd Party i.e DGS&D / RITES etc Inspection Charges @0.34%+Service Tax Less for Cenvat Credit,if any respect of Supplies Under full Excise Duty Category

Providing and laying Vitrified tiles in floor in different sizes (thickness to be specified by the manufacturer) with water absorption less than 0.08% and conforming to IS:15622, of approved brand & manufacturer, in all colours and shade, laid on 20 mm thick cement mortar 1:4 (1 cement: 4 coarse sand) jointing with grey cement slurry @3.3 kg/sqm including grouting the joints with white cement and matching pigments etc. The tiles must be cut with the zero chipping diamond cutter only . Laying of tiles will be done with the notch trowel, plier, wedge, clips of required thickness, leveling system and rubber mallet for placing the tiles gently and easily:Glazed vitrified floor tiles polished finish of size:Size of Tile 600 x 600 mm sq.m Excess(+) Full Conversion INR

Dismantling tile work in floors and roofs laid in cement mortar including stacking material within 50 metres lead :For thickness of tiles 10 mm to 25 mm sq.m Excess(+) Full Conversion INR

Disposal of building rubbish / malba / similar unserviceable, dismantled or waste materials by mechanical means, including loading, transporting, unloading to approved municipal dumping ground or as approved by Engineer-in-charge, beyond 50 m initial lead, for all leads including all lifts involved. Cu.m Excess(+) Full Conversion INR

Supplying, laying and fixing in position 2 mm thick PVC sheet of approved shade and make to be laid on flooring using rubber based adhesives of approved quality and manufacturer including cost of Materials, labour, wastage, taxes etc,. all complete as direction of officer in charge sq.m Excess(+) Full Conversion INR

Note-1: General Notes 1.For their own interest, contractors are advised to inspect the site with prior permission before quoting their rates. 3. All the samples of materials which are to be used shall be approved by the department in advance. 4. The contractor shall comply with the provision of the Payment of Wages act 5. Rates quoted shall be inclusive of all cost of materials, labour, carriage, taxes, GST, labourcess, water charges, elctricity charges, signorage charges, wastages etc.. 6. Rates quoted shall be excluding the amount of EPFO and ESIC contributions. EPFO and ESIC contributions are reimbursable on production of valid proof of payment made by the contractor as per CPWD norms.

Total in Figures

Quoted Rate in Figures Select

Please Enable Macros to View BoQ information