Karnataka

AOC

Works

Buildings

Renovation work of the chamarajanagara MP office in the district administration building

Public Works Department

PWD Division Office Chamarajanagara | Chamarajanagara, Karnataka

Amount: ₹12.0 LCloses: 27 Mar 2026Closed

Timeline

Published18 Mar 2026
Closed27 Mar 2026
Awarded—

Bids

1 Bid27 Mar 2026

#	Company	Amount	Status
1	VENKATESH N ₹8.2 Laccepted-aoc	₹8.2 L	accepted-aoc

Tender Value

₹12.0 L

EMD Value

₹15,000

Closing Date

27 Mar 2026, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

Technical Assistant

Mobile Number

Work Description

Renovation work of the chamarajanagara MP office in the district administration building

Tender Information

Tender ID

PWD/2025-26/BD/WORK_INDENT34089

Reference Number

PWD/2025-26/BD/WORK_INDENT34089

Tender Type

Reserved

Product Category

Buildings

Form of Contract

Two Tender Document System(Two Cover)

Location

PWD Division Office Chamarajanagara

Source Website

Subscribe to view

Documents Required

4 documents required · 4 mandatory

Technical Bid

RequiredAnnual Turnover Certificate & Profit Poss statement from LAST 5YEARS

RequiredKPWD Class-IV and above Registration Certificate

RequiredExisting commitments and on-going works to be completed during the next 03 months

RequiredSchedule Caste Certificate and 10years Domicial certificate certified by the compitent authority

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

The bidder is required to ensure browser compatibility of the computer well in advance to the last date and time for receipt of tenders. The departments shall not be responsible for non-accessibility of KPP Portal due to internet connectivity issues and technical glitches at bidders end..

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Bidder shall pay Contract Management Module processing fees.

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs

The Tender processing fee shall not be refundable.

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders.

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund.

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval.

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work.

The successful Tenderer shall deliver to the Employer a Security deposit in the form of NSC/DD/FDR in the name of the Executive Engineer, Public works Department, Chamarajanagara Division, Chamarajanagara given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract.

Contractor should carryout additional test required to test the suitability of materials.

All safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent.

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost.

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost.

The contractors assessed available tender capacity will be calculated as per the clause 3.2 of STD tender document Attached.

All the items in the tender include all lead, lifts, loading unloading, transportation, labour, hire charges of machinery curing for concrete works, cost and conveyance of all material and all other such incidental charges necessary for successful completion of works as per the detailed technical specification and direction of Engineer in charge of this work.

All precautions should be taken by the contractor so that there are no damages to such public/ private properties.

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utility shifting. To that extent the contractor should indemnify the client.

Contractor should follow strictly the prevailing rules of labour act.

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, Public works Department, Chamarajanagar Division, Chamarajanagara during office hours on all working days.

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extent should submit HSE document defining all the procedure including the policies before execution of the project.

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have been constructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost.

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-1

The employer reserves the rights to Cancel or Withdraw any or all the tenders without Giving any reasons & Any Time.

Estimate rates are Exclusive of 18% GST,Hence GST will be paid separately for the quoted rates accordingly.

Contractors should be registered as KPWD Class IV & above Civil Contractor

The contractor will get payments based on the Schedule B only , except that no payment will be made by the Public Works Department.

3.1a Achieved in at least one financial years (2020-21 to 2024-25) an average financial turnover (in all classes of civil engineering construction works only)

The Intended Completion Date for the whole of the Work is 12 months (including monsoon)

The contractors assessed available tender capacity will be calculated as Assessed available tender capacity (AxNx5.00-B ) Where, A -Maximum value of civil engineering works executed in any one year during the last five years (updated to 2025-26 price level) taking into account the completed as well as works in progress taking into account the completed as well as ongoing works. N-Number of years prescribed for completion of the works for which tenders are invited.B-value, at 2025-26 price level, of existing commitments and on-going works to be completed during the next 03 months.

Regarding Appealing aggrieved contractors may appeal to the prescribed (Appellant) authority within 15 days as per KTTP and appeal should be through KPP-PORTAL only

The defect liability period is 365 days

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for delay as determined by the authority while granting the extension of time

Contractor should participate Sehedule Caste contactor Only

Contractor should submitted Sehedule Caste certificate and 10Years domicile certificate from the compitent authority

Technical Criteria

Capabilities of Vendor

KPWD Class-IV and above Registration Certificate

Work Done Certificate

Financial Status

Reports on the financial standing of the tenderer,such as profit and loss statements and auditor reports for the last five years i.e.2020-2021 to 2024-25

Audited CA Certificate of Annual Turnover

List of existing commitments and ongoing work

Work Done Certificate

Bank3.2 To qualify for award of this contract, each Tenderer in his name should have in the last five years i.e..2020-21 to 2024-25 (a) achieved in at least one financial years a Minimum financial turn over (in all classes of civil engineering construction works only) of Rs.11.96 lakhs

Audited CA Certificate of Annual Turnover

Others

List of works for which List of works for which tenders already submitted

Work Done Certificate

Work Locations

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹15,000

Important Dates

Last Activity

27 Mar 2026

Published

18 Mar 2026

Bid Opening

30 Mar 2026

Download Ends

24 Mar 2026

BOQ Preview

•

Renovation work of the chamarajanagara MP office in the district administration building

•

Dismantling aluminium/ Gypsum partitions, doors, windows, fixed glazing and false ceiling including disposal of unserviceable material and stacking of serviceable material to the appropriate disposal ...

•

Dismantling tile work in floors and roofs laid in cement mortar includ- ing stacking material to the appropriate disposal area as per direction of Engineer-in-charge.For thickness of tiles 10 mm to ...

•

Providing and fixing false ceiling at all height including providing and fixing of frame work made of special sections, power pressed from M.S. sheets and galvanized with zinc coating of 120 g/m2 (bo...

•

Providing & fixing 30mm thick factory made rigid foam Prelam Panelled Door Shutters made from M.S. tube of 19x19mm, 19 gauge for stiles and 15x15mm for top & bottom rails, covered with heat moulded Pr...

•

Providing & fixing of 2-track x 2-panel sliding windows made out of multi chambered UPVC (Matching to RAL-9016) sections and with minimum TiO2(Titanium Dioxide) at 6PHR with TPE(Thermo Plastic...

•

Providing and fixing 10 mm thick acid and/or alkali resistant tiles of ap- proved make and colour using acid and/or alkali resisting mortar bedding for Bathrooms: Toilet: Chemically exposed areas and ...

•

Providing and fixing Sink cock with swivel spout & wall flange, wall mountable made of Stainless steel with all concealed fitting arrangements & all necessary accesories complete - class - ...

•

Providing and fixing wash basin with C.I. brackets, 15 mm C.P. brass pillar taps, 32 mm C.P. brass waste of standard pattern, including painting of fittings and brackets, cutting and making good the w...

•

Providing and fixing C.P. brass angle valve for basin mixer and geyser

•

points of approved quality conforming to IS:8931 ---- Including cost of all materials cost of labour cost of equipment...

•

Providing and fixing CP brass 15 mm nominal dia Single lever telephonic

•

wall mixer of quality & make as approved by Engineer in charge. ---- Including cost of all materials cost of labour cost of equi...

•

Providing and laying Ceramic glazed floor tiles of size 300x300 mm (thickness to be specified by the manufacturer) of 1st quality conforming to IS : 15622 of approved make in colours such as...

•

Providing PVC ringtite pipes conforming to IS 4985:2000 with latest amendments and conveying to worksite, rolling and lowering into trenches, laying true to line and level and perfect linking at joint...

•

Removing the old paint or polish from wood and / or wood based surface with paint remover of approved brand / manufacturer and making surface even including cost of materials, labour, complete as per ...

•

Providing and fixing 12 mm thick prelaminated particle board flat pressed three layer or graded wood particle board conforming to IS: 12823 Grade l Type ll, in panelling fixed in aluminum doo...

•

Providing and fixing Three seater Sofa with cushion of size 7(L)x2.5(W) X2.75(H) ft made of upholstery fabric with seats fitted with padding, springs, webbing and as per direction of engine...

•

Providing and fixing Single seater Sofa with cushion of size 3(L)x2.5(W) X2.75(H) ft made of upholstery fabric with seats fitted with padding, springs, webbing and as per direction of engin...

•

Providing & fixing of 2.5 track x 2-panel sliding windows made out of multi chambered UPVC(Matching to RAL-9016) sections and with minimum TiO2(Titanium Dioxide) at 6PHR with TPE(Thermo Plastic...

•

Providing & supplying Carpet/Mat of 800+ gsm with stain proof, flexible and super absorbent fibre of good quality as per direction of Engineer in charge. ---- Including cost of all materials cost of ...

•

Providing & fixing Roller blinds of reputed make 38mm round Aluminium channel with blackout fabric, telting with chain (Ball) system with all necessary fittings and fixtures as ...

•

Providing and supplying 16mm thick both side balancing lamination factory pressed BWP grade marine ply as per IS 710 of approved brand bo xes,shelves,racks,almirah,cupboard and drawer etc. in...

•

Providing and supplying 19mm thick both side balancing lamination factory pressed BWP grade marine ply as per IS 710 of approved brand bo xes,shelves,racks,almirah,cupboard and drawer etc. in...

•

Labour & installation charges for BWP ply:BWR ply:HDHMR: MDF & Particle board work of any thickness applicable for all types of work ---- Including cost of all materials cost of labour cost o...

•

Supplying .TR split Air conditioners suitable for operation on A/C supply single phase 50 Hz 230 V with hermetically sealed compressor with air cooled condenser, motor capacitor and start run capacito...

•

Supplying, erecting, testing & commissioning of OFF- LINE UPS system suitable for operation on 230V, 50Hz, A/C supply, with allaccessories complete and Excluding batteries and wiring complete.(3kVA OF...

•

Supplying and drawing Flexible Multicore Cable manufactured with electrolytic grade flexible copper with low conductor confirming to IS 8130-1984 and (Virgin) PVC insulation sheathed suitable for work...

•

Providing and Supplying of 3 Seater Dow sofa, Westren Hemlock with walnut stain, Warwick Kiamamanuka (Light Mustard) Brass Rod…. Including cost all meterials with all lead lift and labour chargeslte...

•

Providing and Supplying of 3 Single Seater Moutana Sofa, solid wood with dark Teak Stain, Sarom-Penza 706 (Mustard) with white Stricting….Including cost all meterials with all lead lift and labour c...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

KW-1 INDENT-34089 SC.pdf

Tender Document • 0.90 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Company

VENKATESH N

₹8.2 Laccepted-aoc