Tender for the work of Replacement of Twisted tower No 53 and 54 by Providing new 2 nos of 110kV D/C NBT KPTCL Design DCplus0 towers with Coyote ACSR Conductor in existing corridor of 66kV Puttenahalli - Kanasawadi (DG-II) S/C line near Hesaraghatta farm, Muthkur Village limits, in TLM Section Doddaballapura, TLM Subdivision KPTCL, Doddaballapura and TL& SS Division Doddaballapura coming under the jurisdiction of TR(M), BRAZ circle, KPTCL, Bengaluru on Total Turnkey, Two Part & Percentage Basis

Should have carried out erection of all connected equipments of (01) One Transformer Bay/ erection of One Transmission line tower / One Terminal Bay of 66KV class or higher voltage class on Total Turnkey or Partial Turnkey basis in any of the Receiving Sub-Stations in KPTCL ESCOMs Public Sector undertakings, which shall be in satisfactory service for a period of One year prior to date of submission of the Bid. Performance certificates issued by not less than the rank of or equivalent rank of Executive Engineers Elec., TL&SS of KPTCL ESCOMS PSUs to be uploaded OR Should have carried out erection of all connected equipments of 02 (Two) Transformer Bays / two Transmission line towers/ two Terminal Bays of 66KV class or higher voltage class on Labour Contract or as Sub-Contract to any Turnkey Contractor in any of the Receiving Sub-Stations in KPTCL ESCOMs Public Sector undertakings which shall be in satisfactory service for a period of One year prior to date of submission of the Bid. Performance certificates issued by not less than the rank of or equivalent rank of Executive Engineers Elec., TL&SS of KPTCL ESCOMS PSUs to be uploaded.

The bidder should provide detailed information on any litigation or arbitration arising out of contracts completed or under execution by it over the preceding five years. A consistent history of awards involving litigation against the Bidder may result in rejection of bid. Self declaration regarding the same is to be uploaded.

The bidder must not have Black listed by ESCOMS/KPTCL other electrical utilities/who are in the business of distribution of power. Self declaration regarding the same is to be uploaded.

Notwithstanding the above, if it is found that the performance vis - a - vis works awarded to the Bidder by KPTCL is either behind schedule or not satisfactory, KPTCL will be at liberty to disqualify the Bidder and reject its Bid at techno-commercial evaluation/any stage of processing of the Bid.

Valid Super Grade Electrical License issued by GOK as on the date of Bid Submission to be uploaded.

The bidder shall furnish a self-declaration to this effect there is no Disqualification for non-performance in any of the Government utilities in the past five years failing which the offer is liable to be rejected.

Labour Registration Certificate issued by labour department, GOK.

Any other document as mentioned in the Tender document.

Filled Techno Commercial sheets to be uploaded.

Bidders shall submit audited financial reports for last five years preceding the date of bid submission duly certified by Registered Chartered Accountant. Minimum Average Annual Turnover (MAAT) of the bidder for best three years out of last five financial years ending on March or December as the case may be, shall not be less than Rs .42,01,120

The bidder shall enclose audited annual turnover statement certified by registered Chartered Accountant for the preceding Five years issued to the company (i.e. for FY 2023-24, 2022-23, 2021-22, 2020-21, 2019-20)

PAN card issued by competent authority.

Goods & Service Tax Registration certificate issued by GOI.