Karnataka

Retender

Works

Roads

Annual Manitenance of Chinnayakanahally-Tubinakere road from ch-0.00 km to 1.10 km in Srirangapatna Taluk for the year 2023-24 (For ST)

Public Works Department

PWD Division Office Mandya | Karnataka

Amount: Refer DocsCloses: 10 Jun 2024Closed

Timeline

Published31 May 2024
Closed10 Jun 2024
Retendered31 May 2024

Cancellation Details

Retendered

RetenderedRetenderedReason: Retendered

Published 31 May 2024

Tender Value

Refer Docs

EMD Value

₹5,400

Closing Date

10 Jun 2024, 10:00 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

Preethu.S.D

Office Number

08232228605

Work Description

Annual Manitenance of Chinnayakanahally-Tubinakere road from ch-0.00 km to 1.10 km in Srirangapatna Taluk for the year 2023-24

Tender Information

Tender ID

PWD/2023-24/RD/WORK_INDENT7337/CALL-3

Reference Number

PWD/2023-24/RD/WORK_INDENT7337/CALL-3

Tender Type

Reserved

Product Category

Roads

Form of Contract

Electronic Documents, First(One Cover)

Location

PWD Division Office Mandya

Source Website

Subscribe to view

Documents Required

7 documents required · 7 mandatory

Technical Bid

RequiredContractor Registration Certificate

RequiredAnnual turnover and Profit and loss statement

RequiredOngoing work details

RequiredDetails of tenders already submitted

RequiredAssessed available tender capacity AxNx5.00 - B

RequiredST Caste Certificate

RequiredResidential certificate stayed a minimum of 10 years

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

Bidders shall ensure upload of relevant document certifying his/her status as Scheduled Caste/ Scheduled Tribe/other reserved category as prescribed in the tender document.

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs

The Tender processing fee shall not be refundable

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval

The employer reserves the rights to Reject or accept any or all the tenders without assigning any reasons

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work

The work has to be completed within 60 Days from the date of agreement

This Road/Building/Bridge is to be maintained in good condition as per Schedule-B upto 31-3-2024

All safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost

All precautions should be taken by the contractor so that there are no damages to such public/ private properties

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utility shifting. To that extent the contractor should indemnify the client

Contractor should follow strictly the prevailing rules of labour act

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, PWD Mandya Division, Mandya during office hours on all working days

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extent should submit HSE document defining all the procedure including the policies before execution of the project

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have been constructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost

Regarding Appealing Aggrieved contractors may appeal to the prescribed (Appellant) authority within 30 days as per KTTP and appeal should be through e-proc only as per Govt.order No:pwd/572/CRM-2020(E) Bangalore DT.09-10-2020. The same will not be considered if appeal through Letters

GST of 18% shall be paid to the tendered amount separately

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for the delay as determined by the authority while granting the extension of time

The contractor who participates in tenders for more than one work for which tenders are invited in this IFT, the tenderer must fulfill all the conditions and criteria cumulatively for the participated works

The tenderer shall furnish last five years financial turnover, profit and loss account statement i.e., from 2019-20, 2020-21, 2021-22, 2022-23 & 2023-24 from the authorized Auditor or C.A. (Achieved in at least one financial year a minimum financial turnover (in all classes of civil engineering construction works only) (usually not less than the estimated annual payments under this conctract))

Photo copy of the work before commencement of the work, during the work and after completion of the work should be produce with the bill

All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erection and labour charges, complete as directed by the Engineer-in-charge of the work

The contractor was to make his own arrangement to got the concrete core test results from the authorised department / company

The successful Tenderer shall deliver to the Employer a additional security for unbalanced tenders in the form of NSC/DD/FDR in the name of the Executive Engineer, PWD Mandya Division, Mandya additional security for unbalanced tenders in accordance with the Conditions of Contract

Assessed available tender capacity AxNx5.00 - B where A Maximum value of civil engineering works executed in any one year during the last five years (updated to 2024-25 price level) taking into account the completed as well as works in progress N Number of years prescribed for completion of the works for which Tenders are invited. B Value, at 2024-25 price level, of existing commitments and on-going works to be completed. The tenderer has to Assess

For ST contractors reservation category participate in the tender are upload a caste certificate issued by a competent authority / Tahsildar

For ST contractors reservation category participate in the tender, the contractors are upload the residential certificate stayed a minimum of 10 years issued by a competent authority / Tahsildar

Contractors should be registered as KPWD Class IV & above Civil Contractor

Assessed Tender Capacity shall be more than the Tendered Amount Rs.4.20 Lakhs

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹5,400

Important Dates

Last Activity

31 May 2024

Published

31 May 2024

Download Ends

7 Jun 2024

BOQ Preview

•

Annual Manitenance of Chinnayakanahally-Tubinakere road from ch-0.00 km to 1.10 km in Srirangapatna Taluk for the year 2023-24

•

Earth work excavation for Foundation by mechanical means for all works & depth upto 3 m, as per drawing and technical specifications, including setting out, shoring, strutting, barricading, caution li...

•

Providing and laying in position plain cement concrete for levelling course for all works in foundation. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS...

•

Providing and laying in position Reinforced cement concrete for all Sub structures of building, Irrigation works, Sub structure works ofbridges, Drain works & other parallel works from 0.50m to 3.50 m...

•

Additionalities for Head wall @8percent ---- All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erection and labour charges, complete as...

•

Solid Round Glass Fibre Reinforced Polymer (GFRP) Bars for Concrete einforcement. Supplying, fitting & placing GFRP (Glass fibre Reinforced Polymer) bars conforming to IRC 137:2022 for structures such...

•

Maintenance of Earthen Shoulder (filling with fresh soil) Making up loss of material/ irregularities on shoulder to the design level by adding fresh approved soil and ompacting it with appropriate equ...

•

Retro-Reflectorised Traffic Signs Providing and fixing of retro- reflectorised cautionary,

•

mandatory and informatory sign as per IRC:67:2022 made

•

of Class B Type IV retro reflective sheeting fixed ove...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw 1- 7337-Srp-2024-25-(st reserve).doc

Tender Document • 2.70 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at [email protected].