Tender ID

Karnataka

Cancelled

Works

Roads

Construction of C.C Drain/Retaining Wall at Anasosalu Village Limit on Sira-Nanjangudu (SH-84) Road in Mandya Taluk.

Public Works Department

PWD Division Office Mandya | Karnataka

Amount: Refer DocsCloses: 10 Jun 2024Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published31 May 2024
Cancelled31 May 2024

Cancellation Details

Cancelled

CancelledCancelledReason: Cancelled

Published 31 May 2024

Tender Value

Refer Docs

EMD Value

₹10,700

Closing Date

10 Jun 2024, 10:00 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

Shubha.T.S

Office Number

Work Description

Construction of C.C Drain/Retaining Wall at Anasosalu Village Limit on Sira-Nanjangudu (SH-84) Road in Mandya Taluk.

Tender Information

Tender ID

PWD/2023-24/RD/WORK_INDENT7365/CALL-2

Reference Number

PWD/2023-24/RD/WORK_INDENT7365/CALL-2

Tender Type

Open

Product Category

Roads

Form of Contract

Electronic Documents, First(One Cover)

Location

PWD Division Office Mandya

Source Website

Subscribe to view

Documents Required

5 documents required · 5 mandatory

Technical Bid

RequiredContractor Registration Certificate

RequiredAnnual turnover and Profit and loss statement

RequiredOngoing work details

RequiredDetails of tenders already submitted

RequiredAssessed available tender capacity AxNx2.50 - B

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs

Department Registration Details

The Tender processing fee shall not be refundable

List of existing commitments and ongoing work

List of works for which tenders already submitted

Banker Details

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter no PW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval

The employer reserves the rights to Reject or accept any or all the tenders without assigning any reasons

In the case of the death of the contractor after executing the agreement / commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work

The work has to be completed within 60 Days from the date of agreement

This Road/Building/Bridge is to be maintained in good condition as per Schedule-B upto 31-3-2025

All safety precautions, warning signs, night illumination, reflectors, deployment of security guards has to be ensured so that no untoward incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost

All precautions should be taken by the contractor so that there are no damages to such public/ private properties

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utility shifting. To that extent the contractor should indemnify the client

Contractor should follow strictly the prevailing rules of labour act

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, PWD Mandya Division, Mandya during office hours on all working days

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extent should submit HSE document defining all the procedure including the policies before execution of the project

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have been constructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost

Regarding Appealing Aggrieved contractors may appeal to the prescribed (Appellant) authority within 30 days as per KTTP and appeal should be through e-proc only as per Govt.order No:pwd/572/CRM-2020(E) Bangalore DT.09-10-2020. The same will not be considered if appeal through Letters

GST of 18% shall be paid to the tendered amount separately

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for the delay as determined by the authority while granting the extension of time

The contractor who participates in tenders for more than one work for which tenders are invited in this IFT, the tenderer must fulfill all the conditions and criteria cumulatively for the participated works

The tenderer shall furnish last five years financial turnover, profit and loss account statement i.e., from 2019-20, 2020-21, 2021-22, 2022-23 & 2023-24 from the authorized Auditor or C.A. (Achieved in at least one financial year a minimum financial turnover (in all classes of civil engineering construction works only) (usually not less than the estimated annual payments under this conctract))

Photo copy of the work before commencement of the work, during the work and after completion of the work should be produce with the bill

All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erection and labour charges, complete as directed by the Engineer-in-charge of the work

The successful Tenderer shall deliver to the Employer a Security deposit in the form of NSC/DD/FDR in the name of the Executive Engineer, PWD Mandya Division, Mandya given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract

Assessed available tender capacity AxNx2.50 - B where A Maximum value of civil engineering works executed in any one year during the last five years (updated to 2024-25 price level) taking into account the completed as well as works in progress N Number of years prescribed for completion of the works for which Tenders are invited. B Value, at 2024-25 price level, of existing commitments and on-going works to be completed. The tenderer has to Assess

Contractors should be registered as KPWD Class IV & above Civil Contractor

Assessed Tender Capacity shall be more than the Tendered Amount Rs.4.24 Lakhs

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹10,700

Important Dates

Last Activity

31 May 2024

Published

31 May 2024

Download Ends

7 Jun 2024

BOQ Preview

•

Construction of C.C Drain/Retaining Wall at Anasosalu Village Limit on Sira-Nanjangudu (SH-84) Road in Mandya Taluk.

•

Earth work excavation for Foundation by mechanical means for all works & depth upto 3 m, as per drawing and technical specifications, including setting out, shoring, strutting, barricading, caution li...

•

Providing and laying in position plain cement concrete for levelling course for all works in foundation. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS...

•

Farm Work For I.No.2.1.3, P.No.15 Vol.1, Common SR for the year 2023-24) ---- All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erectio...

•

Providing and laying in position Reinforced cement concrete for all Sub structures of building, Irrigation works, Sub structure works of bridges, Drain works & other parallel works from 0.50m to 3.50 ...

•

Farm Work For I.No.2.4.2, P.No.17 Vol.1, Common SR for the year 2023-24) ---- All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erectio...

•

Providing and laying in position Reinforced cement concrete for all Super structures of building , Road works, Water works, Irrigation works & super structure works of bridges upto 3.50 m height. The ...

•

Farrm Work For I.No.2.5.2, P.No.17, Vol.1, Common SR for the year 2023-24 ---- All items in the tender include cost of hire charges of machineries and equipments with all lead, lift, supply and erec...

•

upplying, fitting and placing TMT FE 550 / 550D Steel Reinforcement including cost of all materials, machinery, labour, cleaning, straightening, cutting, bending, hooking, laping/welding joints, tying...

•

Back filling behind abutment, wing wall and return wall complete including compaction as per drawing and Technical Specification A Granular Material (I.No.12.3A P.No.117, Vol.3, SR Roads & Bridges for...

•

Maintenance of Earth Shoulder (stripping excess soil)Stripping excess soil from the shoulder surface to achieve the approved level and compacting with plate compactor (I.No.10.3, P.No.91, Vol.3, SR Ro...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw-1 - general New-2024-25-7365-Mdy.doc

Tender Document • 2.69 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Tender ID

Karnataka

Cancelled

Works

Roads

Construction of C.C Drain/Retaining Wall at Anasosalu Village Limit on Sira-Nanjangudu (SH-84) Road in Mandya Taluk.

Public Works Department

PWD Division Office Mandya | Karnataka

Amount: Refer DocsCloses: 10 Jun 2024Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published31 May 2024
Cancelled31 May 2024