Tender ID

Karnataka

Retender

Works

Buildings

Providing, Sculpting, Supplying and Installing Mythological Sri. Shiva Statue Near Sri.Arakeshwara Temple at K R Nagara in K.R.Nagara Town, Mysore District

Public Works Department

PWD Special Division Office Hunasuru | Karnataka

Amount: ₹32.6 LCloses: 18 Aug 2025Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published30 Jul 2025
Closed18 Aug 2025
Retendered30 Jul 2025

Cancellation Details

Retendered

RetenderedRetenderedReason: Retendered

Published 30 Jul 2025

Tender Value

₹32.6 L

EMD Value

₹65,240

Closing Date

18 Aug 2025, 9:30 pmClosed

Tender Inviting Authority

Office Inviting Bids

Public Works Department

Contact Person

M P muturaj

Office Number

Work Description

Providing Sculpting Supplying and Installing Mythological Sri Shiva Statue Near Sri Arakeshwara Temple at K R Nagara in K R Nagara Town Mysore District

Tender Information

Tender ID

PWD/2025-26/BD/WORK_INDENT22260/CALL-2

Reference Number

PWD/2025-26/BD/WORK_INDENT22260/CALL-2

Tender Type

Open

Product Category

Buildings

Form of Contract

Electronic Documents, First(One Cover)

Location

PWD Special Division Office Hunasuru

Source Website

Subscribe to view

Documents Required

3 documents required · 3 mandatory

Technical Bid

RequiredAnnual Turnover Certificate with UDIN from CA of last 5 years

RequiredKPWD Registration Certificate

RequiredWork Done Certificate for Similar nature work of rs.16.31 lakhs duly attested by the Officer Not below the rank of E.E.

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by Government of Karnataka

The bidder is required to ensure browser compatibility of the computer well in advance to the last date and time for receipt of tenders. The departments shall not be responsible for non-accessibility of kppp portal due to internet connectivity issues and technical glitches at bidders end

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

Bidder shall pay Contract Management Module processing fees of 0.025% of the contact value (Min Rs.500/- & Max Rs.7500/-)soon after contract has been issued to bidder.

Conditional tenders will not be accepted

The tenderer shall bear all costs associated with the preparation and submission of his tender, and the employer will in no case be responsible and liable for those costs.

The Tender processing fee shall not be refundable

Royalty on construction materials and other taxes will be deducted as per prevailing Govt orders

List of existing commitments and ongoing works

List of works for which tenders already submitted

As per Karnataka state Government order LD/300/LET/2006 Bangalore dated 01.01.2007 and Government letter noPW/134/BMS/2007 dated 27.07.2007, a sum amounting to 1% of the bill amount will be deducted towards constructions labour welfare fund.

All scanned documents to be uploaded shall be in original and the Executive Engineer reserves the right to verify the documents before approval.

The employer reserves the rights to Reject or accept any or all the tenders without assigning any reasons.

The intending contractors are requested to note that they should abide by the detailed instructions and conditions contained in the Standard Tender documents KW-2

In the case of the death of the contractor after executing the agreement /commencement of the work, his legal heir, if is an eligible registered contractor and is willing can execute and compete the work at the accepted tender rates irrespective of the cost of the work

Contractor should carryout additional test required to test the suitability of materials

All safety precautions, warning signs, night illumination, reflectors,deployment of security guards has to be ensured so that no incident happens on account of negligence or any project activity. Contractor should indemnify the client to that extent.

Formation levels and other data furnished are bare minimum the contractor should make all efforts to validate and to get additional data if required at his own cost

Materials like steel, cement etc., required for the work shall be procured by the tenderer themselves and should got tested by the quality control authority before use on the work at their own cost.

The contractors assessed available tender capacity will be calculated as per the clause 3.5 of STD tender document Attached

All the items in the tender include all lead, lifts, loading unloading, transportation, labour, hire charges of machinery curing forconcrete works,cost and conveyance of all material and all other such incidental charges necessary for successful completionof works as per the detailed technical specification and direction of Engineer in charge of this work

All precautions should be taken by the contractor so that there are no damages to such public/ private properties

Contractor should take all precautionary measures to avoid any damage to the utilities during excavation as well as utility shifting. To that extent the contractor should indemnify the client

Further particulars, if any, required by the Contractor can be had from the office of the Executive Engineer, Public works Department, Hunsur Division,Hunsur during office hours on all working days.

GST shall not be paid in the extended period of contract for which the contractor alone is responsible for delay as determined by the authority while granting the extension of time

Contractor should adhere to HSE (Health Safety Environment) policy applicable for similar projects. Contractor to that extent should submit HSE document defining all the procedure including the policies before execution of the project

Contractor should take all precautions to ensure that no damage is caused to the existing structures which have been constructed by other agencies during project execution. If any damage is caused, it has to be rectified at his own risk and cost

The difference in cost deposited by the lowest successful tenderer (for unbalanced) along with the performance security willbe released to the contractor 30 days after the completion of defects liability period

All the uploaded documents in e-portal should be got verified at the Division office within 3 working days from the stipulated date of opening of Technical Bid by producing the original documents at the Division office, failing which the tender is liable for rejection. No separate communication will be made in this regard.

The returns submitted to the I.T. along with the Profit and Loss account statement submitted to the I.T. Department should be uploaded for the financial turnover criteria as per tender document attested by Chartered accountant

The success-full contractor should complete the whole work with in 120days from the date of handing over of site (includingrainy season)

The successful Tenderer shall deliver to the Employer a Security deposit in the prescribed form in the favour of the ExecutiveEngineer, PWD Division, Hunsur Division, Hunsur given below for an amount equivalent to 5% of the Contract price plus additional security for unbalanced tenders in accordance with the Conditions of Contract

Regarding Appealing aggrieved contractors may appeal to the prescribed (Appellant) authority within 15 days as per KTTPand appeal should be through e-proc only as per Govt.order No:pwd/572/CRM-2020(E) Bangalore DT.09-10-2020. The samewill not be considered if appeal through Letters

18-Percent GST shall be paid to the tendered amount separately

Contractors should be registered as KPWD Class 3 and above Civil Contractor

Fee & Financial Details

Tender Fee Amount

₹820

EMD Fee Amount

₹65,240

Important Dates

Last Activity

30 Jul 2025

Published

30 Jul 2025

Download Ends

12 Aug 2025

BOQ Preview

•

Providing, Sculpting, Supplying and Installing Mythological Sri. Shiva Statue Near Sri.Arakeshwara Temple at K R Nagara in K.R.Nagara Town, Mysore District

•

Providing, Sculpting and Supplying of 14ftX 9ftX 2ft pedestal size of White/Black

•

Granite stone including Artisans charges for sculpting of pedestal with detail carving and as per

•

the instructions of ...

•

Providing, Sculpting and Supplying of SHIVA 7.5ft x 5.25ft x 10ft size first

•

quality Monolithic White/ Black Granite stone including Artisans charges for sculpting the shiva idol

•

according to shilpa s...

•

Lifting, transportation and Installation of pedestal (peeta) and Shiva Idol

•

according to shilpa shasrta, at K R Nagara Arakeshwara temple premises as per the instructions

•

of the engineer-in-charge of ...

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

kw2 bid document.docx

Tender Document • 0.11 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Tender ID

Karnataka

Retender

Works

Buildings

Providing, Sculpting, Supplying and Installing Mythological Sri. Shiva Statue Near Sri.Arakeshwara Temple at K R Nagara in K.R.Nagara Town, Mysore District

Public Works Department

PWD Special Division Office Hunasuru | Karnataka

Amount: ₹32.6 LCloses: 18 Aug 2025Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published30 Jul 2025
Closed18 Aug 2025
Retendered30 Jul 2025