supply of CUFF ASSY INSULATION

Other Requirements;

Supply should be from latest batch of manufacture and subject to Acceptance at ARDC, HAL.

Supply should accompany OEM Certificate of Conforamce (COC) i.e. M/s Honeywell Aerospace Yeovil, UK

Delivery : Vendors to indicate shortest possible lead time of supply from the date of placement of Purchase order

Bidder’s country which shares a land border with India: All the participating bidders have to mandatorily submit the relevant certificate as per format attached as ANNEXURE-II A and Annexure-IIC (either Type-I or Type-II), at the time of submiting the Technical bid along with their offer. Refer Annexure-II, Commercial Terms and Conditionss

Biding Quantity: The offered price should be the exact quantity requested in the RFQ,

IMPORTANT NOTE: It is noticed that vendors are not uploading the relevant documents in the bid also not filling the compliances requested in RFQ. Due to this there is abnormal delay noticed in the procurement process in this regard following to be noted for complains:  Each place requested for compliances are to be filled completely in the technical compliance sheet. In case vendor has left blank it will be treated as vendor has not quoted for that item and that particular item will be technically rejected. Hence you have to fill all the places mandatorily.

Additional Information if Any:

Annexure-2

Aircraft Research and Design Centre HINDUSTAN AERONAUTICS LIMITED Marathahalli Post Bangalore - 560 037. INDIA

COMMERCIAL TERMS AND CONDITIONS - PART OF TECHNICAL BID

Tender Ref. No: D/IMM/COM3/5461/03/2380/1

Name of the Vendor/ Firm: (To be indicated by vendor / firm)

Quotation Ref. No.: (To be indicated by vendor / firm)

PLEASE INDICATE YOUR RESPONSE/ COMPLIANCE/ ACCEPTANCE TO THE FOLLOWING TERMS (MANDATORY) AND UPLOAD AS A PART OF TECHNICAL BID. IN CASE OF ANY PRICE INFORMATION PROIVIDED IN TECHNICAL BID, EVEN IN THE FORM OF PDF, THE TECHNICAL BID WOULD NOT BE CONSIDERED FOR EVALUATION AND TREATED AS INVALID.

COMMERCIAL TERMS & CONDITIONS

Delivery and Passing of Property & Risk:-

Delivery and Passing of Property shall be as per INCOTERMS 2020 in respect of F.C.A, International airport in the country of origin. Indian Vendors : The delivery terms should be F.O.R., HAL,ARDC Division Stores basis & price quoted should be on FOR HAL ARDC stores inclusive of all charges including transit insurance (The charges for Packing, Freight & Delivery to HAL,ARDC, Bangalore shall be borne and paid by Supplier. Supplier shall insure the goods-in-transit at their own cost). Note: If, for special reasons, bidder prices are Ex-Works or F.O.B. plant, bidder must prepay inland transportation’s. Port dues and shipment charges up to F.O.B. vessel at port of shipment and claim this amount of actual along with the price of the goods through bank. Bidder’s quotation should indicate clearly the extent of such charges The following amount will be added to basic Price for vendors quoting different Delivery Term: Delivery Term Factor (DT): For Inland =0.02*Q Ex workss (Inland), where as Q is quoted prices For Foreign Bidders: F*Q/100 - [FCA/FOB (Foreign)] Where F = Freight & Insurance (in % as provided by Divisional Finance or 2%, whichever is higher. Besides, in case of Ex works (Foreign) an additional 0.5% will be loaded.

Receipt & Despatch: The Vendor is responsible for obtaining a clear receipt from the Transport Authorities specifying the goods dispatched. He will not book any consignment on a said to contain’ basis. If he does so, he does it on his own responsibility. HAL will take no responsibility for short deliveries or wrong supply of goods when the same are booked on said to contain’ basis. HAL shall pay for only such stores as are actually received by them in accordance with the contract

Price :

Quotations submitted in foreign currency will be converted to Indian Rupees (for comparison purpose) by adopting the TT-selling rate prevailing on the date of technical bid opening as indicated in www.exim.net. For any reason, if the exchange rate is not available on the date of tender opening, the nearest past available exchange rate will be adopted.

Validity of quote:- Quote should be valid for 120 days from the closing date of the present RFQ.

Delivery period: Vendors to indicate shortest possible lead time of supply from the date of placement of Purchase order.

Extension of Time: If an extension is desired by the Vendor/Supplier, then Vendor/Supplier shall apply for extension of time to HAL at least 15 days prior to the date of delivery without prejudice to the rights of HAL, then HAL may grant extension of time for any cause which HAL may deem proper and the decision of HAL in this respect to be final and binding and cannot be questioned in any manner whatsoever.

Payment Terms:- For supply of items: 100% payment will be made within 30 days after delivery and acceptance of items at our Stores. All payments will be done by way of NEFT / RTGS/ SWIFT Electronic Payment remittance mode. For the purpose of making payments, vendor to provide the following; a) Original Ink signed Commercial Invoice, b) Airworthiness certificate/ Certificate of Conformance / Release Note etc., as applicable c) Acceptance test report (ATR) for system or its components, spares as applicable. d) Any other documents specifically mentioned in the Purchase Order. e) Foreign vendor is requested to furnish the bank details in SWIFT form to Swift code:SBININBB147, SBI HAL branch and forward us a copy of Swift transfer details for our reference.

In case, the vendor does not accept the above payment terms and proposes alternative terms then HAL will appropriately adjust the quoted prices to account for the effects of the differences in payment terms. Although the exact adjustment will differ on a case by case basis, the following adjustments will mandatorily be made for making all the bids strictly comparable independant of the actual payment terms quoted by bidders. i) In case of Letter of credit, the estimated bank charges for operating the LC will be added to the quoted price. ii) The effect of time value of money arrising out of differing payment terms will be computed using an appropriate discount rate and will be added to the quoted price.

TAXES (for Indian Bidders)

Special Instruction for Foreign Service Providers regarding PAN: The current procedure for obtaining PAN for Foreign suppliers/service providers is available at website: https://tin.tin.nsdl.com/pan (refer Form 49A -online application for new PAN) PAN is required to facilitate deduction of Tax at source(TDS) as per prevailing rates towards payment against services rendered as mentioned above against contract emanating against subject RFQ, failing which tax will be deducted at the highest of the rates as indicated above. Important: The appropriate loading of TDS at applicable rate will be done during commerical evaluation of offers, in case of vendors who insist for payment net of Indian taxes.

Warranties:- Vendor warrants as follows: i) All items delivered are free from defects in materials and workmanship. ii) All items delivered are in conformance to the specification and are fit for the intended purpose. iii) It shall be ensured that HAL shall have clear and undisputed title to the goods supplied under the contract.

Post-Warranty Service: Arrangements for after sales service and maintenance (authorized service centre) in India on site during warranty & post warranty period should be clearly indicated providing with name, address, phone, Mob no, email Id of the contact person, infrastructure along with spare parts inventory held by your Authorized Technical Service Center. The Vendor to indicate the validity period of authorization for the technical service center

Restrictions on procurment from bidders from a country which shares a land border with India:

“Bidder” (including the term ‘tenderer’, ‘consultant’ or ‘service provider’ in certain contexts) means any person or firm or company, including any member of a consortium or joint venture (that is an association of several persons, or firms or companies), every artificial juridical person not falling in any of the descriptions of bidders stated herein before, including any agency branch or office controlled by such person, participating in a procurement process.

Liquidated Damages:- In the event that any supply under the PO/contract is delivered later than agreed schedules in the PO/contract, liquidated damages will be payable / deducted from Invoice equal to 0.5% for every week of delay or part thereof on the delayed portion of the order subject to a maximum of 10% of the value of the delayed item. For non compliance of LD clause, Loading factor i.e. (10- L)*Q/100) shall be loaded on quoted basic amount during commercial evaluation. Where L: MAXIMUM RATE OF LD AGREED & Q: QUOTED PRICE

Inspection, Consequences of Rejection: The goods on receipt in HAL will be subject to inspection and tests, if necessary and HAL inspector’s decision as regards acceptance/rejection of goods shall be final and binding between the parties. (In case of Plant & Machinery, goods shall be finally inspected & accepted only after successful commissioning) If any stores are rejected, then HAL shall be at liberty to: a) Either: i) Allow the contractor to re-submit stores in replacement of those rejected within a time specified by HAL, the contractor bearing the cost of freight in such replacement without being entitled to any extra payment, (or) ii) Buy the quantity of stores rejected or other of a similar nature elsewhere at the risk and cost of the contractor without effecting the contractor's liability as regards the supply of any further consignments due under the contract, (or) (iii) Terminate the contract and recover from the contractor the loss HAL may thereby incur. The contractor shall not be entitled to any gain on the repurchase,

Any stores rejected by HAL’s Inspector must be removed by the contractor within 14 days from the date of receipt of intimation of rejection and at his own cost, failing which the contractor shall be liable to pay storage charges at 1% for each day of delay on the invoice value of the stores. If the stores are not removed within a month from the date of intimation of rejection, the stores will be liable, to be sold by HAL at the contractor’s risk and responsibility and the proceeds adjusted towards storage charges. c) In case any payment is made against delivery and it is found that the supplied item is rejected during inspection/commissioning, contractor will be required to choose any one of the following options to collect the rejected item for replacement: i) Refund the amount paid and collect the item for replacement. ii) Submit a Bank Guarantee for the amount already paid and collect the item for replacement. iii) Bring the replacement item to HAL and collect the rejected item

Requirements of ISO 14001:2015; Environmental Management System (EMS): I. Information about potential significant environmental impacts associated with transportation, delivery, use, end-of-life treatment and final disposal of its products and services may be provided II. It is desired that Environmental Friendly Materials, Systems and Processes are used with the lifecycle perspective to have minimal impact on the Environment while delivering the product/service

Requirements of ISO 45001:2018 Standard: The vendor/Supplier/ contractor shall ensure requirements with respect to ISO 45001:2018 standard guidelines clause A 8.1.4. This includes equipment’s, installations and materials are safe for use by workers as intended by ensuring: -equipment is delivered according to specification and tested to ensure it works as intended -installations are commissioned to ensure they function as designed -materials are delivered according to their specifications -any usage requirements, precautions or other protective measures are communicated and made available (E.g. Safety instructions, Hazard communication Symbols, SDS, Etc.)

Shelf life:- Where stores offered have a limited shelf-life, kindly indicate the life involved and confirm that in the event of an order from us, only newly manufactured stores with the maximum possible shelf-life at the time of dispatch will be offered for shipment. In respect of rubber items such as seals etc., having cure date, the item should not have been manufactured earlier than 6 months of dispatch.

Packing:- Each item / deliverable will have to be packed in such a manner as to avoid damage during transit, handling, etc., and damage /deterioration due to climatic conditions. Batch number and date of manufacture & identification details and handling instructions should be printed / written on labels of the deliverables.

Modification:- Modifications, updates, etc. done to the hardware, software or documentation related to the deliverables under the contract at any point of time during or after the validity of the contract shall be promptly intimated to HAL for ensuring that such changes are incorportaed in the products delivered under this contract as well.

Others

Language: All correspondence between the Parties, as well as all documentation, manuals, software listings and other writings, in connection with this Contract shall be in the English Language.

Bribes and Gifts: Any bribe, commission, gift or advantage given, promised or offered by or on behalf of the Vendor or his parties, agent or servant or any one on his or their behalf to any officer, servant, representative or agent of HAL or any person on his or their behalf in relation to the obtaining or to the execution of this or any other contract with HAL shall in addition to any criminal liability which the Vendor may incur, subject to the Vendor to the cancellation of this and all other contracts with HAL and also to payment of any loss or damage resulting from any such cancellation thereof. Any question or dispute as to the commission of any offence under the present clause shall be settled by HAL in such manner and on such evidence or information as they may think fit and sufficient and their decision shall be final and conclusive.

Appropriation: Whenever under this contract any sum of money is recoverable from any payable by the contractor, HAL shall be entitled to recover such sum by appropriating in part or whole by deducting any sum then due or which at any time thereafter may become due to the contractor in this or any other contract entered by HAL as a whole its Divisions and Branch Offices etc., held by him alone or in partnership with others. Should this sum be not sufficient to cover the full amount recoverable, the contractor shall pay to HAL on demand the remaining balance due.

Settlement of Disputes and Arbitration:- All disputes or differences whatsoever arising between the parties out of or relating to the construction, meaning and operation or effect of this Contract or the breach thereof shall be settled by Arbitration in accordance with the Rules of Arbitration of the Indian Council of Arbitration or International Centre for Alternative Dispute Resolution (ICA/ICADR) and the award made in pursuance thereof shall be binding on the parties. The provisions of the Arbitration and conciliation Act 1996 or any statutory modifications thereof shall apply to such legislation.

SHORT CLOSURE OF CONTRACT:- HAL reserves the right to short close this contract with three month prior notice to the vendor at any time during the tenure of the contract. The financial settlement entailed by such action shall be finalized based on the principle of equitable price adjustment and shall be based on discussions and mutual agreement.

Jurisdiction:-The competent Court at Bangalore, India shall only have Jurisdiction to deal with and decide any legal matter whatsoever arising on account of formulation or execution of this Contract.

Applicable Law:- The contract shall be governed by and interpreted in accordance with the laws of the Republic of India.

Non Assignment to third Party:Vendor shall not be entitled without HAL’s consent to assign or transfer to a third party all or part of the benefi ts or obligations under this contract.

Agent / Agency Commission:- The seller confirms and declares to the buyer that the seller is the original manufacturer or authorized distributor / stockiest of original manufacturer or Govt. Sponsored / Designated Export Agencies (applicable in case of countries where domestic laws do not permit direct export by OEMS) of the stores referred to in this offer / contract / Purchase order and has not engaged any individual or firm, whether Indian or Foreign whatsoever, to intercede, facilitate or in any way to recommend to Buyer or any of its functionaries, whether officially or unofficially, to the award of the contract / purchase order to the Seller; nor has any amount been paid, promised or intended to be paid to any such individual or firm in respect of any such intercession, facilitation or recommendation. The Seller agrees that if it is established at any time to the satisfaction of the Buyer that the present declaration is in any way incorrect or if at a later stage it is discovered by the Buyer that the Seller has engaged any such individual / firm, and paid or intended to pay any amount, gift, reward, fees, commission or consideration to such person, party, firm or institution, whether before or after the signing of this contract / purchase order, the Seller will be liable to refund that amount to the Buyer. The Seller will also be debarred from participating in any RFQ / Tender for new projects / program with Buyer for a minimum period of five years. The Buyer will also have a right to consider cancellation of the Contract / Purchase order either wholly or in part, without any entitlement or compensation to the Seller who shall in such event be liable to refund all payments made by the Buyer in terms of the Contract / Purchase order along with interest at the rate of 2% per annum above LIBOR (London Inter Bank Offer Rate) (for foreign vendors) and Base Rate of SBI (State Bank of India) plus 2% (for Indian vendors). The Buyer will also have the right to recover any such amount from any contracts /Purchase order concluded earlier with Buyer.

IMMUNITY TO GOVERNMENT OF INDIA:- It is understood and agreed that the Government of India is not a party to this agreement and has no liabilities, obligations or rights hereunder. It is expressly understood and agreed that HAL is an independent legal entity with power and authority to enter into contracts solely in its own behalf under the applicable Laws of India and General Principles of Contract Law. The vendor shall agree, acknowledge and understand that HAL is not an agent, representative or delegate of the Government of India. It is further understood and agreed that the Government of India is not and shall not be liable for any acts, omissions, commissions, breaches or other wrongs arising out of the contract. Accordingly, vendor expressly waives, releases and foregoes any and all actions or claims against the Government of India arising out of this contract, not to sue the Government of India as to any manner, claim, cause of action or thing whatsoever arising out of or under this agreement.

Fall Clause: i) The prices charged for the stores supplied under the contract by the Vendor shall in no event exceed the lowest price at which the Vendor sells the stores or offers to sell stores of essentially identical description or specification to any persons/organizations including the purchaser of any Department of the Government of India or any Department of the Indian State Governments or any Public undertaking of the Central or State Governments, as the case may be during the period till the performance of the supply order against the order/contract is completed. ii) If at any time during the said period, the Contractor reduces the sales prices, sells or offers to sell such stores to any person/organization as mentioned above at a price lower than the price chargeable under the present order/contract, the contractor shall notify HAL of such reduction/sale or offer of sale and the price payable under the present contract for the stores supplied after the date of coming into force of such reduction or sale or offer to sale shall stand correspondingly reduced.

EXIT CLAUSE Exit criteria: The contract/order may be terminated under the following circumstances: i. In the event of unsatisfactory performance by the Seller during the contract period, or any of the information provided by the Seller is found to be untrue, or Seller is found to have attempted to influence any person involved with the contract through unethical means, the contract shall be terminated with three month’s advance notice without any financial implication to Buyer. Notwithstanding the foregoing, in cases where it is found that a Seller has engaged in unethical practices, they shall be barred from participating in the future contracts with HAL for a period of three years. ii. If there is change in Buyer requirement, contract shall be terminated with three months' advance notice. The liability of Buyer in this case will be agreed mutually. In the event of termination of contract by either party, the Seller shall ensure the following: a) IPR’s are transferred to Buyer to enable Buyer to proceed on the work with other Seller. Seller also will render all assistance till the other Seller fully takes over the balance work. b) Transfer title and deliver all or any part thereof of the supplies, materials, work-inprogress, finished Products, Tooling, drawings and data produced or acquired by Seller specifically for the Product being terminated. c) Supply of products and its components / spares at least for a period of two years from the date of such termination. iii. The Seller is declared bankrupt or becomes insolvent. iv. The delivery of material is delayed due to causes of Force Majeure by more than six months). v. Based on the decision of the Arbitration Tribunal.

Termination for Default of Seller or for other reasons: HAL shall have the right to short close present Contract in part or in full by giving 1 month prior notice to the Supplier, in any of the following cases:- a) The work is delayed or cancelled for causes attributable to force majeure. b) The requirement is withdrawn by HAL’s Customer. c) The Supplier is declared bankrupt or becomes insolvent. d) It is noticed that the firm has utilized the services of any agent to get the resulting Order and paid any commission to such agent. e) As per decision of the Arbitration Tribunal f) In case any part of the Order is subcontracted by the Supplier without prior permission of HAL. g) If the performance of the Supplier is not found satisfactory during the execution of work. In any of the above stated case, no claim of damage etc., by the Supplier will be allowed.

Export License: Vendors should categorically confirm the availability of export license from their government for exporting the system. Vendor shall be required to obtain and maintain all Export/Import licences and permits etc., as the case may be, required for performing supplies against this tender. Obtaining export licence shall be entire responsibility of the vendor.

Right of Sale and Utilization-ExportLicense/Reexport Permission:

RISK PURCHASE: The Supplier will supply quality items as per approved sample and also the quantity intended by the concerned Division in full as per terms and conditions of respective orders. In case the Supplier fails to execute the order either in terms of quality or in quantity, HAL reserves the right to procure from elsewhere at the risk and cost of the Supplier and any extra expenditure incurred due to this purchase is payable by the Supplier.

Indemnity against Patent rights:- The successful bidder/Supplier shall defend, indemnify and hold HAL harmless from and against all actions, causes of action, liabilities, claims, suits, judgment, liens, awards, damages of any kind and nature whatsoever and expenses and costs of litigation to the extent such claims arise out of infringement of any IPR, patent, copyright, trademark or involve wrongful use of trade secret or confidential information or negligence attributable to the Supplier

Confidentiality:- For the purpose of this Tender / Contract / Agreement, the Bidder / Contractor / Supplier shall not store, copy or disclose HAL’s data and information whether in written, machine readable or other tangible form or disclosed orally, that is of value to HAL. Also, Bidder / Contractor / Supplier agrees to use HAL’s data only for the purpose under this Contract, restrict disclosure to any person or entity or third party and shall safeguard the provided data including from cyber security risks etc. Bidder / Contractor / Supplier should promptly return within 90 days HAL’s data in original media and should not keep HAL’s data, upon expiry of Tender / Contract / Agreement or early termination of Contract / Agreement and certify that HAL’s data has been deleted permanently. Non-adherence to this confidentiality clause by the Bidder / Contractor / Supplier shall be treated, as a material breach of this Tender / Contract / Agreement. The provisions of this clause shall survive and remain in force notwithstanding the termination or expiry of this Contract / Agreement.

INSOLVENCY: Supplier enters into liquidation, whether compulsory or voluntary (other than amalgamation or reconstruction with another party taking over all its rights as well as commitments) or becomes insolvent or suffers a receiver of the whole or part of its asset to be appointed, i) Shall forthwith notify the same to HAL and the HAL shall have the right without prejudice to his other rights or remedies to terminate the unexecuted part of this Contract. ii) In such an event, HAL shall become entitled forthwith to get the refund within 30 days of all the advance payments received by Supplier and expenditure incurred by as a part of its obligations under this contract it has not fulfilled. In such an event if applicable, Supplier is liable for return of any materials/items (including drawings, designs etc) to HAL, which are held at his end as a part of the obligations under this contract

PENALTY FOR USE OF UNDUE INFLUENCE :- Vendor undertakes that he has not given, offered or promised to give, directly or indirectly any gift, consideration, reward, commission, fees, brokerage or inducement to any person in service of HAL or otherwise in procuring the Contract or forbearing to do or for having done or forborne to do any act in relation to the obtaining or execution of the Contract or any other Contract with the Government for showing or forbearing to show favor or disfavor to any person in relation to the Contract with the Government. Any breach of the aforesaid undertaking by Vendor or any of its employees or anyone acting on its behalf (whether with or without the knowledge of Vendor) or the commission of any offence by Vendor or anyone employed by him or acting on its behalf, as defined in Chapter IX of the Indian Penal Code, 1860 or the prevention of Corruption Act, 1947 or any other Act enacted for the prevention of Corruption shall entitle HAL to cancel the Contract and all or any other contracts with the vendor and recover from the vendor the amount of any loss arising from such cancellation. A decision of HAL or its nominee to the effect that a breach of the undertaking has been committed shall be final and binding on Vendor. Giving or offering of any gift, bribe or inducement or any attempt to any such act on behalf of Vendor towards any officer/employee of HAL or to any other person in a position to influence the decision of HAL, directly or indirectly or any attempt to influence any officer/employee of HAL for showing any favor in relation to this or any other contract, shall render the Vendor to such liability/penalty as HAL may deem proper, including but not limited to termination of the Contract, imposition of penal damages, forfeiture of the Bank Guarantee and refund of the amounts paid by HAL

Conflict of Interest: Any bidder having a conflict of interest, which substantially affects fair competition, shall not be eligible to bid in this tender. Bids found to have a conflict of interest shall be rejected as nonresponsive. A bidder in this Tender Process shall be considered to have a conflict of interest if the bidder: a) directly or indirectly controls, is controlled by or is under common control with another Bidder; or b) receives or have received any direct or indirect subsidy/ financial stake from another bidder; or c) has the same legal representative as another bidder for purposes of this bid. A Principal can authorize only one representative, and the representative also should not represent or quote on behalf of more than one Principal. However, this shall not debar more than one Authorised distributor from quoting equipment manufactured by an Original Equipment Manufacturer (OEM), in procurements under Proprietary Article Certificate; or d) has a relationship with another bidder, directly or through common third parties, that puts it in a position to have access to information about or influence the bid of another Bidder or influence the decisions of the Procuring Entity regarding this Tender process; or participates in more than one bid in this tender process; or

e) Participation in any capacity by a Bidder (including the participation of a Bidder as sub-contractor in another bid or vice-versa) in more than one bid shall result in the disqualification of all bids in which he is a party. However, this does not limit the participation of a non-bidder firm as a sub-contractor in more than one bid; or f) would be providing goods, works, or non-consulting services resulting from or directly related to consulting services that it provided (or were provided by any affiliate that directly or indirectly controls,is controlled by, or is under common control with that firm), for the procurement planning (inter-alia preparation of feasibility/ cost estimates/ Detailed Project Report (DPR), design/ technical specifications, Terms of Reference (ToR)/ Activity Schedule/ schedule of requirements or the Tender Document etc.) of this Tender process; or g) has a close business or family relationship with a staff of the Procuring Organization who: i) are directly or indirectly involved in the preparation of the Tender document or specifications of the Tender Process, and/or the evaluation of bids; or ii) would be involved in the implementation or supervision of resulting Contract.

Non-conformities between Figures and Words: In case of non-conformities/errors are observed in responsive tenders between the quoted prices in figures and in words. This situation normally does not arise in case of e-Procurement. This should be taken care of in the manner indicated below: i) If, in the price structure quoted for the required goods, there is discrepancy between the unit price and total price (which is obtained by multiplying the unit price by the quantity), the unit price shall prevail and the total price corrected accordingly; ii) If there is an error in a total corresponding to the addition or subtraction of sub-totals, the sub-totals shall prevail and the total shall be corrected; and iii) If there is a discrepancy between words and figures, the amount in words shall prevail. Such a discrepancy in an offer should be conveyed to the bidder asking him to respond by a target date and if the bidder does not agree to HAL's observation, then the bid is liable to be rejected.

Any query related to tender (like due date extension, technical clarification, etc.) needs to be sent to HAL directly. The name and contact details of HAL personnel to whom queries related to tender to be sent are as below:- i) CHANDRAMOULI GB, CM (IMM) ii) HS Thyagarajamurthy, AGM (IMM) Aircraft Research & Design Centre, Aircraft Research & Design Centre, Hindustan Aeronautics Limited, Hindustan Aeronautics Limited, Marathahalli Post, Marathahalli Post, Bangalore - 560037 Bangalore - 560037 Ph: 080 - 2232 4341 Ph: 080 - 2232 4357 Fax: 080 - 2231 7132 Fax: 080 - 2231 7132 E-mail: [email protected] E-mail: [email protected]

ANNEXURE-3

Please fill the details in cells shaded with colour

AIRCRAFT RESEARCH & DESIGN CENTRE HINDUSTAN AERONAUTICS LIMITED Marathahalli Post Bangalore - 560 037. INDIA

PRICE BID - ANNEXURE-3

Tender Ref. No.: D/IMM/COM3/5461/03/2380/1

Name of the Vendor/Firm:

Quotation Ref. No.:

PLEASE FILL ALL THE DETAILS OF PRICES, ETC AND UPLOAD THE SAME EXCEL FILE AS A PART OF YOUR PRICE BID. BIDDERS HAS TO FILL PRICES CAREFULLY. ANY TYPOGRAPHICAL ERROR SHOULD NOT BE CONSIDERED AT LATER STAGE.

Part No.

Any other Information: