Construction Ganesh Kund front of Dashama temple in Shahibaug ward.

Name of work: - bægÍtu l Ntnectd Jtu z o b tk œNtbtk l t bk r œh ytd¤ lt rJM<thbtk dKu N fw k z

<i g th fhJtlt ftb ctc<.

TenderInvited onBehalf ofAMC,CentralZone.

Assistant Manager, Central Zone,

CentralZoneZonalOffice”,B–Wing,

Third Floor,Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

SignatureofBidder Page2of36

AhmedabadMunicipalCorporation

AHMEDABADMUNICIPALCORPORATION

NoticeinvitingTender

Competent authority on behalf of Municipal Commissioner of A.M.C. invites percentage rate sealed

tenders from interested contractors for the following work at different locations within the limit of

1 Nameofwork bægÍtul Ntnectd Jtuzobtk œNtbtklt bkrœh ytd¤ lt rJM<thbtk dKuN fwkz <igth fhJtlt ftb ctc<.

2 EstimatedTenderAmount Rs.9,98,900.00 (excluding of GST). GST will be paid extra by

AMC/Authority at prevailing rate to the contractor.

3 Tenderfee Rs.900

(Nonrefundable) (DemandDraftinfavourofMunicipalCommissioner,Ahmedabad)

4 TimeLimit 9Months

5 Download of Tender Tendersfromthewebsitewww.nprocure.comorshallbedown loaded

Documents mentionedAS PER TENDER NOTICE INVITED

6 Requiredregistration Register“E-2”classhavinginRoadWorksinPWDinGovt.R&B/

CPWD/AMCorequivalentregisterwithanyotherstateGovt.or institutions.

7 Earnest Money Deposit Rs.9,989.00 (Demand Draft / payorder / Bank Guarantee in favour of

(Bid security) MunicipalCommissioner,Ahmedabadistobesubmittedasprescribed

(1%ofEstimateputto tender) asbelow.DemandDraft/BankGuaranteeshallbefromapprovedlistof AMC

of banks and the issuing branch of bank guarantee shall be of

Ahmedabad city only and it should be valid for 120 days.

E.M.D.shallbesubmittedphysicallyalongwiththePhysical

Submissionwhenapplicable.

8 SubmissionofEMDand Tender Fee& EMD should Submitted physically along with tender

Tender Fees documents as described in the invitation of tender should be

submitted toAssistant Manager- Central Zone, 3rd Floor, B – Wing,

Sardar Patel Bhavan, Danapith, Ahmedabad-380001.

Bidsubmittedwithoutbidsecurity&tenderfeeshallbetreatedas

nonresponsiveandshallbesummarilyrejected.

9 Mode of sending the Thewholetendershallbesubmittedbytwomodes.

Tender Documents • Whole tender shall be submitted only onwww.nprocure.com

website as per Schedulementioned inNotice inviting

• TenderFee,EMD,technicalbidandotherrelevantPQDocuments as

per check list given in tender shall be submitted physically in

twocopies(Original&duplicate)insealedenvelopeasper

SchedulementionedinNoticeinvitingTender.

10 Last date of receiving AsperNoticeinvitingTender/Addendum/Corrigendum.

Tenders. Thetendersreceivedafterlatestscheduledateandtimewillnot be

entertained under any circumstances.

11 SubmissionofPrice Bid ThePricebidshallbesubmittedonlineonly.Thebiddershallfill

percentagerateonamountof BOQ onlineonlyuntilspecified.

PriceBidshallbesubmittedphysicallydulysigned&sealwithout

mentioningquoted rated,elseitshallbeconsideredasrejected.

12 OpeningofTechnicalbid AsperNoticeinvitingTender/Addendum/Corrigendum.

SignatureofBidder Page3of36

AhmedabadMunicipalCorporation

13 Tendervalidityperiod 120daysfromthelastdateofsubmissionofTender.

14 SecurityDeposit 5 % of Contract Valuetobe submitted in the formof (Demand Draft/

pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad.Bank Guarantee shall be from approved list of AMC of

banks asper attchedANNEXURE - 1financedept. latest circular.

and the issuing branch of bank guarantee shall be of Ahmedabad City

only.The validity of the Security Deposit shall be up to valid till

days beyond Date of completion of work.

The Security Deposit shall be payable in 10 days (for tenders upto

Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above) from

dateofreceiptofLOIfailingwhichinterest@4%perannumwillbe

15 DeductionsfromRunning

a. RetentionMoney 2%amountofeachRunningBillshallbedeductedasaRetention

Money.Suchretentionmoneyshallbereleasedinthefinalbillofthe

b. Labourwelfarecess LabourwelfarecessaspertheAct,1996(nonrefundable)shallbe

deductedfromeachrunningbill.

16 Defect&LiabilityPeriod Notapplicableinthiscase.Ifapplicablethanreferconditionof

contractattachedoverruleasperformB-1publishedbyGovernment.

17 CompansationforDelay 10%oftheactualbalanceworkafterTimelimitexpired.

• All the circulars which were published by Authorities of AMC time by time will be applicable

on said Tender and bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the

rights to reject any or all the tenders without assigning any reasons thereof.

• TheauthorizedsignatoryholdingPowerofAttorneyshallonlybetheDigitalSignatory.Incase

authorized signatory holding Power of Attorney and Digital Signatory are not the same, the

bid shall be considered non-responsive.

Seal and Signature of the Bidder Additional City Engineer

Date: AhmedabadMunicipalCorporation

SignatureofBidder Page4of36

AhmedabadMunicipalCorporation

(Oncontractor’sLetterHead/ certifiedwith StampandSignwithContact Detail)

TENDERDECLARATIONFORM

AdditionalCityEngineer Central

Ahmedabad Municipal Corporation,

Name of Work:- bægÍtul Ntnectd Jtuzobtk œNtbtklt bkrœh ytd¤ lt rJM<thbtk dKuN fwkz <igth fhJtlt ftb ctc<.

I/We the undersigned have carefully gone through and clearly understood the Tender

documentsofabovementionedprojectcomprisingofNoticeInvitingtenders,ArticlesofAgreement, Scope

of work, Definition of terms, notes Instructions/Information to Bidder, Condition of Contract,

specialconditionofcontract,Appendices,Specifications,BillofQuantities,furnishedbyAHMEDABAD

MUNICIPAL CORPORATION.

I/We do hereby offer to execute and complete the whole of the work within the time

specifiedallinaccordancewiththespecification,designs,drawingandinstructioninwritingreferred

tointhesaiddocumentandwithsuchmaterialsasmentionedfor,attherespectiverateswhichI/we have

quoted in the Price Bid or at such other rates as may be fixed under the provisions of these

In the event of this tender being accepted I/Weagree to enter into an agreementand when

required,executethecontract,accordingtoyourform1ofagreementasorindefaultwhereofI/we bound

myself/ourselves to forfeit the "Earnest Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided

by AMC from the date of receipt of letter of acceptance, you will forfeit the earnest money paid by

me/us and take necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for

the sum as mentioned in NIT, the full value of which is to be absolutely forfeited to the Employer If

I/We fail to commence the work specified. Otherwise the Employer shall retain the said sum, as on

account of such Security Deposit as provided for in the aforesaid documents.

I/We agree not to employ sub-contractors other than those that may be approved in

accordance with conditions in the aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any

tender, which are received. I / We also understand & agree that Municipal Commissioner Reserves

therighttoallotnumberoftenderstosuccessfulbiddersathissolediscretionincaseifI/Weam/are lowest in

more than one tender.

I/We am/are bound to execute the job if the work order is issued within 120 days from the

date of opening of the tender.

Iam bound to executetheworkbymaintainingallQualityaspects/parametersmentioned in the

tender terms and conditions. I am also bound to submit all supporting Genuine Original documents

as and when asked and if any discrepancy found in such documents as well as in the executed Work

with respect to Quality/Quantity at any stage of work or even after completion of work, it will be

solely my Responsibility. I am bound to prove originality of all documents submitted by me and if

any Documents found false/fake then Municipal Commissioner/AMC has right to take any

action/penalty/punishment against me.

SignatureofBidder Page5of36

AhmedabadMunicipalCorporation

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality

and/or the construction of road is found to be of an inferior quality under this contract than in such

case Municipal Commissioner/AMC has right to debar/ blacklistpermanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi

duties, Royalty on material (i.e. Aggregate, Sand etc.)And any other taxes prevailing and from time

to timeon suchitemsonwhichthesameareleviable and theratesquotedbyme/usare inclusiveof the

Yoursfaithfully

SealandSignofContractor

SignatureofBidder Page6of36

AhmedabadMunicipalCorporation

INSTRUCTIONS TO BIDDERS

Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal Corporation

(referred to as Employer in these documents) invites sealed bids for the

constructionofworks(asdefinedinthesedocumentsandreferredtoas“thework”)detailed in

thetablegiven inthe InvitationforBid(hereinafter calledasIFB.)fromcompetentbidder. The

bidders may submit bids for the works detailed in the table given in IFB.

2.0 SourceofFunds

AhmedabadMunicipalCorporationhasarrangedthefundforthisproject.

3.0 Eligible Bidders

The Invitation for Bidsis open to alleligiblebidders meeting the eligibility criteria asdefined in this

AllbiddersshallprovideQualificationInformationandFormsofBidmentionedintheClause-

14. An agency that has beenengagedby the Employer to provide consulting services for the

preparation or supervision of the works,and any of its affiliates, shallnot be eligibletobid.

Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those are

blacklisted/ debarred for specified period by AMC, Governement of Gujarat, Government of

India orany other entity controlled by it, would notbe eligible to submit the Bid.

QualificationoftheBidder

Requires registration:-Register“E-2” classhaving in Road Works in PWD in Govt. R&B / CPWD / AMC

or equivalent register with any other state Govt. or institutions.

DISQUALIFICATION

Eventhoughthebiddersmeettheabovementionedqualifyingcriteria,theyaresubjecttobe

disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and

attachments submitted in proof of the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the

contract, inordinate delays in completion, litigation history, or financial failures etc. or

debarring from AMC work etc.

• Tamperedthebiddocumentinanymanner.

• Colluded with other prospective bidders for this work to arrive at quotedprices for

thepurpose of restricting competition.

• Indulged in inducementofanyofficialof AMC and/ortheir consulting engineerand other

advisors in any manner whatsoever.

• Proposalnotsubmittedinaccordancewiththistender.

• Duringvalidityoftheproposal,oritsextendedperiod,ifany,thebidderchangeshis

commercialterms.

• Thebidderqualifiestheproposalwithhisownconditions.

• Proposalisreceivedafterduedateandtime.

• Commercialproposalisenclosedwiththesameenvelopeastechnicalproposal

• Theenvelopedoesnotshowontheoutsidethereferenceofbidandthusgets opened

before the due date of opening.

• TheE.M.D.is not depositedinfull andinthemanneras specifiedintheclause of Earnest

SignatureofBidder Page7of36

AhmedabadMunicipalCorporation

• ThetenderisinalanguageotherthanEnglishordosenotcontainsitsEnglish Translation in

case of other language adopted for tender preparation.

• Thetenderdocumentsreceivedarenotdulysignedby authorizedperson.

• Thevalidityoftenderislessthanwhatisstatedinthetender.

• Anyofthepageorpagesoftenderis/areremovedorreplaced.

• Anyconditionwhichaffectthecost.

• Ifitisjointventure.

Debarment/Blacklisting

Notwithstanding the above, the Employer maydebar or blacklist any of the bidder(s)

fortheirmisleadingorfalserepresentationsintheformsstatementsetc.fortheperiod to be

decided by the Employer.

6.0 CostofBidding

The bidder shall bear all costs associated with the preparation and submission of his Bid.

Employer will in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and

familiarize himself with the site of Works and its surroundings including source of earth,

water, road aggregates etc. and obtain all information that may be necessary for preparing

the Bid and entering into a contract for construction of the Works. The costs of visiting the

Site shall be at the Bidder's own expense.

8.0 Biddersshallnothaveanydisputeorclaimforanykindofcompensationincaseof,

• Ifthequantitystipulatedinthetenderitemsvariesorthescopeofworkchangesandthereby total

amount of work increases / decreases up to any extent.

• Iftheworksgetsdelayed/postponedforsomeadministrative/technicaldecision whatsoever.

• Iftheitemsstipulatedinthetendershallnotbeexecutedaspersitecondition/requirements. No

claim shall be entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and

no claim shall be entertained for the same.

B. BIDDINGDOCUMENTS

9.0 ContentofBiddingDocuments

The set of bidding documentscomprises the documents listed belowandaddendum (if any) issued.

1. Noticeinvitinge-Tender

2. SpecialconditionsofContract

3. Instructions toBidders

4. QualificationInformation

5. ConditionsofContract

6. TechnicalSpecifications

8. BillofQuantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract

data, forms, terms, technical specifications, forms, Annexes in the bid document. Failure to

complywiththerequirementsof biddocumentsshallbeatthebidder’sownrisk.Bidswhich are not

substantiallyresponsive to the requirements of thebid documents shall be rejected.

AmendmentofBiddingDocuments

SignatureofBidder Page8of36

AhmedabadMunicipalCorporation

Beforethedeadlineforsubmissionofbids,theEmployermaymodifythebiddingdocuments by issuing

Any addendum thus issued shall be part of the bidding documents and shall be placed on

websitewww.nprocure.com The prospective bidder shall refer to website to check any

addendum before 24 hours of opening of bids. AMC will not give any advertisement for the

To give prospective bidders reasonable time in which to take an addendum into account in

preparing theirbids,the Employer may,athisdesecration, extendasnecessarythe deadline for

submission of bids.

Prospective bidders should attach the addendum made for the work & if fails to do so than also the

changesmade through such addendum shallbeapplicable &bound to the bidder.

C PREPARATIONOFBIDS

11.0 LanguageoftheBid

AlldocumentsrelatingtothebidshallbeintheEnglishlanguageonly.

12.0 Documentscomprisingbid

Theebidsubmittedbythebiddershallbeintwoseparateparts.

Toqualifyforawardofthecontract,eachbiddermustsubmitthefollowingdocumentsalong with

• RequiredRegistrationCertificate

• Otherrequesteddocuments

• Any other material/ information required to be submitted in accordance with these

Instructions to Bidders (ITB)

Failuretosubmitthesecertificates/documentsshallmakethebidnon-responsive.

Aboveoriginaldocumentsinphysicalformintwocopies,onemarkedas“original”andother

marked as “Duplicate”, shall be submitted in a sealed envelope by 18:00 Hrs on the date of

physicalsubmissionofbidandaddressedtotheaddresseegivenintheNITdulysuperscribed “Name

of Work, Bid due date and time, Name and address of the bidder”

• The contract shall be for the whole works as described in Bill of Quantity based on the

percentage rate in the Bill of Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any

othercauseshallbe included in therates,pricesandtotal BidPrice submittedbythe Bidder,

except otherwise statedintheBid document. Employer will not compensate the bidder

(contractor)foranychange induties,taxesand otherlevies payablebythe contractorunder the

contract and any other reasons.

• Thepercentagerateandbidpricequotedbythebiddershallbefixeduptothecompletionof Work

and shall not be subject to adjustment on any account, except where expressly specified,

otherwise, in the contract.

14.0 CurrenciesofBidandPayment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in

SignatureofBidder Page9of36

AhmedabadMunicipalCorporation

15.0 BidValidity

Bidsshallremainvalidfor120daysfromlastdateofsubmissionoftender.Abidvalidfora shorter period

shall be rejected by the Employer as non-responsive.

In exceptional circumstances,priortoexpiryof thebidvalidity(120days),theEmployermay request that

thebidders mayextend the period of validity for a specified additional period. The request

and the bidders' responses shall bemade in writing orby cable. A biddermay

refusetherequestwithoutforfeitinghisbidsecurity.Abidderagreeingtotherequestwillnot be

required orpermitted to modify his bid, but will be required to extend the validity of his bid

security for a period of the extension.

16.0 EarnestMoney/BidSecurity

The Bidder shall furnish, a Bid Security of the amountas shown in the Table of IFB as part of his bid,

in the form of Demand Draft / pay order / Bank Guarantee in favour of Municipal

Commissioner, Ahmedabad valid for 120 days.

Theissuingbranch ofthebankguaranteeshallbeof Ahmedabad Cityonly.

SignatureofBidder Page10of36

AhmedabadMunicipalCorporation

Any bid not accompanied by an acceptable Bid Security shall be rejected by theEmployer as non-

Anybidhavingbidsecurityforlesservalueandshortervalidityperiodshallbetreatedasnon-responsive.

(a)Thebidsecurityoftheunsuccessfulbidders,exceptforL1,L2andL3bidderswillbe returned as promptly

(b)Thebidsecurityofthesuccessfulbidder,along with secondandthird lowesttenders,will be

returned when the successful bidder has furnished the required security deposit and

signed the agreement.

The Bid Security of the Successful Bidder will be discharged when the bidder has signed the

Agreement and furnished the required security deposit.

TheBidSecurityshallbeforfeited,

a) iftheBidderwithdrawstheBidafterBidopeningduringtheperiodofBidvalidity;

b) inthecaseofasuccessfulBidder,iftheBidderfailswithinthespecifiedtimelimitto

(i) signtheAgreement;or

(ii) Furnishtherequiredsecuritydeposit.

(iii) commencetheworkaftersigningtheagreementwithin15days

SignatureofBidder Page10of35

AhmedabadMunicipalCorporation

No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank

guarantee shall be of Ahmedabad City only.

BankGuaranteeforEarnestMoneyDepositshouldbeexecutedonnon-judicialStamppapers of requisite

value in accordance with the stamp Act applicable to that particular state of Indian Union,

where executed.

The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly indicate in

(block letters) his name, designation, Power of Attorney No. / Signing Power No. etc.

Eachpageof thebankguaranteefor Earnest MoneyDeposit shall bedulysigned/initialed by the

executing officers and the last page shall be signed in full, indicating the particulars as

aforesaid under the seal of the Bank.

D. SUBMISSIONOFBIDS

Sealing andMarkingofBids

The biddershallsubmit the TechnicalBid only.The Bid shallbe sealed in separate envelopes

andthethreesealedenvelopesshallbesealedinanouterenvelope.TheBidenvelopesshall be

marked as follows:-

• Complete Tender Documentwith all necessary qualification related documents (in two

Above two envelopes shall be kept in one envelope and it should be marked as “Technical

Bid”andsealed.ThisOuterenvelopeshouldmentionthenameoffirmofbidder,hisaddress,

contact details & name of the work.

Theinnerandouterenvelopes

a)ShallbeaddressedtotheEmployeratthefollowingaddress:

AssistantManager-CentralZone,

3rdFloor,B–Wing,SardarPatelBhavan,

Danapith,Ahmedabad-380001.

c)Bearthefollowingidentification:

Indicatethenameandaddressofthebidder.

• If the outer envelope is not sealed and marked as above, the Employer will assume no

responsibility for the misplacement or premature opening of the bid.

DEADLINEFORSUBMISSIONOFTHEBID

Complete Bids (including Technical bid and necessary documents) must be received by the

Employerattheaddressspecified inbidinformationnotlaterthanthedateindicatedonthe face

sheet of the document. In the event of the specified date for the submission of bids

declaredaholidayfortheEmployer,theBidswillbereceiveduptotheappointedtimeonthe

nextworkingday.TheBidderisfurtherrequiredtosubmitDocumentsinPhysicalFormonor before

the Bid Due Date and before the time of submission as specified in NIT, at the

followingaddress:

AssistantManager-CentralZone,

3rdFloor,B–Wing,SardarPatelBhavan,

Danapith,Ahmedabad-380001.

SignatureofBidder Page11of36

AhmedabadMunicipalCorporation

AMC assumes no responsibilityforinabilityofabidder to submit bids through (n)procure e-tendering

portal on account of delay in submission at bidder's end. Bidder shall ensure that they

submit thebid well beforethe"Due Date & Time of Bid- Submission". AMC shallnotbe

responsible if bidder is not able to submit the bid on account of failure in network/internet

connection or any other technical reason.

The Employer may extend the deadline for submission of bids by issuing an amendment in

accordance with respective Clause, in which case all rights and obligations of the Employer

and the bidders previously subject to the original deadline will then be subject to the new

All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and returned

unopened to the bidder.

Any Bid received by the Employer after the deadline prescribed in NIT will be returned

unopened to the bidder.

20.0 NOTIFICATIONOFAWARD&SIGNINGOFAGREEMENT

TheBidderwhoseBidhasbeenacceptedwillbenotifiedoftheawardbytheEmployerprior

toexpiration of theBidvalidityperiodbywriting,facsimileore-mailconfirmedbyregistered letter.

This letter (hereinafter and in the Conditions of Contract called the “Letter of

Acceptance”willstatethesumthattheEmployerwillpaytheContractorinconsiderationof

theexecution,completion,andmaintenanceoftheWorksbytheContractorasprescribedby the

Contract (hereinafter and in the Contract called the “Contract Price”).

The notification of award will constitute the formation of the Contract, subject only to the

furnishing of a Security Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the

Successful Bidder. It will be signed by the Employerand the Successful Bidder.

21.0 SIGNINGOFCONTRACTAGREEMENT

TheEmployerandthesuccessfulbiddershallenterintoaContractAgreementwithin28days after the

successful bidder (hereinafter called the Contractor) receives the Letter of Acceptance,

unless they agree otherwise, subject to furnishing the security deposit before signing the

Agreement with the Employer.

Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify the

other Bidders that their Bids have been unsuccessful and release their Earnest Money

Deposit / Bid Security.

22.0 SECURITYDEPOSIT

Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the

Employer a security deposit in the form of Bank Guarantee for an amount equivalent to

5%oftheContractPricevalidfortheperiodofvalidtill90daysbeyondDateofcompletionof work.

The Security Deposit shall be payable in 10 days (for tenders upto Rs.10.0 Lacs) or

days(fortendersofRs.10.0Lacsandabove)fromdateof receiptofLOAfailingwhichinterest @ 4%

per annum will be charged by AMC.

The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from

Ahmedabad branch of any Banks mentioned in the clause no. 16.2 of these tender

SignatureofBidder Page12of36

AhmedabadMunicipalCorporation

Thissecuritydepositshallbereleasedonlyaftertheclearanceoffinalbillincludingpre&post Audit.

Interest @ 4 % per annum shall be deducted from contractor in case of late submission of security

deposit or late renewal of bank guarantee for the number of days delayed for submission or

discontinuity of the bank guarantee.

Bank Guarantee to be submitted in the prescribed format enclosed and shall be same

verbatimaspertheformat.BankGuaranteeshallbesubmittedonrightvalueofstamppaper and

for correct value of contract.

Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall constitute

sufficient groundsfor cancellation of theaward and forfeiture of the Bid Security.

In case of any contract amendment during execution of the contract enhancing value of the

contracttheBGvalueshallbeenhancedaccordingly.ValidityofBGshallbecommercialterms and

conditions of the tender.

All compensation or other sums of money payable by the Contractor to the Employer under the

termsof this Contractor any other contract oron anyotheraccount whatsoevermaybe

deducted from SecurityDeposit. Also in the event of the Contractor's SecurityDeposit being

reduced by reasons of such deductions, as aforesaid, the Contractor shall, within 14 days of

receipt of notice of demand from the Engineer-in-Charge, make good the deficit in Security

Should there arise any occasion under the Contract due to which the periods of validities of Bank

Guarantees as may have been furnished by the Contractor from time to time, are required

to be extended/renewed, the Contractor shall get the validity periods of such guarantees

extended/renewed, and furnish these to the Engineer-in- Charge one month before the

expiry date of the aforesaid Guarantees originally furnished failing which the existing Bank

Guarantees shall be invoked by the Engineer – in – charge. Also in case of any

deficitinsecuritiesonanyaccountasmightoccurorisnoticed,theContractorshallforthwith

recoup/replace the same with acceptable Security Deposit.

The Bank Guarantee shall be extended within the expiry dates wherever activities as per contract

are not completed in all respects.

The Security Deposit less any amount due shall, on demand, be returned to the contractor after

days of completion date / Final Bill paid date which ever is later. No interest on the amount

of Security Deposit shall be paid to the Contractor at the time of release of Security Deposit

as stated above.

The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at Employer’s

office within 15 days of LOA.

23.0 AdvancePaymentandSecurity

TheEmployerwillnotprovideanyadvancepayment.

24.0 DisputeReviewExpert

Incaseofallthedisputes,decisionoftheMunicipalCommissioner,Ahmedabadshallbefinal and

binding to the bidder.

25.0 LITIGATIONHISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting

from Contractors completed or under execution by him over last five years. If the details of

LitigationHistoryarehiddenbytheBidderandlateronitcomestotheknowledgeofthe

SignatureofBidder Page13of36

AhmedabadMunicipalCorporation

Employer,theBiddershallbedisqualifiedfortheproposedworkandotherappropriate actions shall be

taken against the bidder.

DETAILSOFCOMPLETED/ONGOINGLITIGATION/ARBITRATION

Employer Valueofthe Reasons/Detailsfor Remarksshowing

Year Nameof Project(Rs.) litigation/arbitration Present Status

 Thebiddershallfurnishseparatetableforindividualproject.

 The above information shall be supported with necessary documents otherwise the same

shall be treat as null and void.

 Aconsistenthistoryofarbitrationawards?Judgmentsagainsttheapplicantsoranypartnerof a

joint venture may result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to

knowledgeof the employer thebidder shallbedisqualifiedforthe proposed workand other

appropriate actions shall be taken against the bidder.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

SignatureofBidder Page14of36

AhmedabadMunicipalCorporation

GENERALCONDITIONSOFCONTRACT

LiquidatedDamages

If the Contractor fails to complete the works within the original or extended time limit, the

Contractorshallpaypenaltyof10%ofamountofactualremainingwork.Theamountofwork for

which the scope of contractor is reduced shall not be considered for the calculation of

Liquidated Damages.

ConditionsmentionedintheAMCFinanceDepartmentCircularAMCno.18Date:23/05/2017 and all

latest Circulars shall be applicable.

2.0RetentionMoney

2 %amount of each Running Bill shall be deducted as a Retention Money. Such retention

money shall be released in the final bill of the said work. AMC reserves right to deduct any

amount to compensate the poor performance of the contractor i.e. poor quality or

abandoned / incomplete work.

Except where expressly specified in the Contract, the Contractor shall not subcontract any portion of

Work without the approvalof the Employer’s Representative. Any subcontracting shall not

relieve the Contractor from any contractual obligations or responsibility under the Contract.

The Contractorshallnotbe required toobtainconsentfora subcontractforwhichthename

ofthesubcontractorandscopeofworksactivitiestobeperformedbyhimisalreadystatedin the

contract or supply of material or engagement of labour.

The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred

to in the Bid document to carry out the functions stated in the Schedule or other

personnelapprovedbytheEngineer.TheEngineerwillapproveanyproposedreplacementof key

personnel only if their qualifications, abilities, and relevant experience are substantially

equal to or better than those of the personnel listed in the Schedule.

IftheEngineeraskstheContractortoremoveaperson,withoutassigningreasonsthereof,for his

misconduct or inadequacy of technical skills and experience, who is a member of the

Contractor’s staff or his work force, the Contractor shall ensure that the person leaves the

Site within seven days and hasno further connection with the work in the Contract.

No residential accommodation is allowed at the site of work. The labour huts shall not be erectedon

thesiteofworkandcontractorshallmakehisownarrangementstoprovidesuch

accommodationsaspertherulesofthelocalbodies.Heshallmakehisownarrangementsfor

housing, stores, field office etc. He shall submit a site layout plan indicating the location of

various site facilities to be created by him at his cost for the execution of work. The Owner

shall in no way be responsible for any delay on this account and no claim on this account

whatsoever shall be entertained. All Basic amenities shall be provided by the Contractor to

Labours as per the prevailing labour Laws.

The Contractor shall have full regard throughout execution, completion and defects liability period

tofollowing safetyaspectsand shalltakeall necessary steps to ensurethatdanger to safety is

avoided all the time in respect of,

Safetyoftheworks

SignatureofBidder Page15of36

AhmedabadMunicipalCorporation

• SafetyoftheContractor’semployeesandallthepersonsdirectlyorindirectly engaged by

him for the works

• SafetyofalltheemployeesincludingpersonsworkingonothercontractsofEmployer atthe

same site of the Employer and Engineers employees engaged at work site.

• Anyauthorizedthirdpartypersonsonthesite.

• Contractor’splantandequipment

The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs,

barricading, and cones; when and where necessary, or required by Engineer in Charge or by

any duly constituted authority for the protection of the works or for the safety and

convenience of the public or other.

The Contractorshalltakeall reasonablestepstoprotect the environmenton andoff the site and avoid

damage or nuisance to persons or property of the public and others arising as a

consequence of his method of operation.

The Contractor shall maintain in good condition all work throughout execution, completion, and

defects liability period. The contractor shall be responsible for and to make good all

injuries,damagesandrepairs,renderednecessarybyfire,rain,traffic,floodsorothercauses.

All the scaffolding work, wherever required for the execution of work, shall be provided by the

contractor. Nothing extra shall be payable on this account. It shall be provided strictly with

double scaffolding system withall the accessories etc.with adjustable suitable working

platforms to access the areas, with ease for working and inspection. It shall be designed to

take all incidental loads. It should cater to the safety features for workmen. It shall be

ensured that no damage is caused to any structure due to scaffolding.

All temporarywarning/caution boardsdisplayshallbe provided and displayed duringdayas well as

night time by the contractor, wherever required and as directed by the Engineer.

Arrangementoftemporarywaterandelectricityandtelephoneconnectionrequired,byhim,

shallbemadebytheContractorathisowncostandalsonecessarypermissionsdirectlyfrom

relevant Owners shallbe obtained by him under intimation to the Owner. Also all initial and

running charges and security deposit, if any in this regard shall be borne by him. The

Contractorshallabidebyalltherules/byelawsapplicableinthisregardandheshallbesolely

responsible for any penalty on account of violation of any of the rules and byelaws in this

In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the

sameshallbecompletelycontractor’sresponsibility.Allthe losses duetosuchaccidentsand

expenses of legal matters shall be borne by contractor.

The Contractor shall be responsible for maintenance and watch and ward of the complete

installation and shallalso be responsible forany pilferage, theft, damage,penalty etc. in this

regard. The Contractor shall indemnify the Owneragainstany claimarising outof pilferage /

theft, damage, penalty etc. whatsoever on this account.

The Contractor shall depute Site Engineer& skilled workers as required for the work. Necessary

protective and safety equipments shall be provided to them by the Contractor at his own

cost and used at site.

6.0 Contractortokeepsiteclean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage

rubbish, excess materials, temporary works no longer required will be removed from site

7.0 Clearanceofsiteoncompletion:

SignatureofBidder Page16of36

AhmedabadMunicipalCorporation

TheContractorshallclearawayandremoveallContractorsequipment,surplusmaterials, rubbish,

temporary works of every kind.

8.0Billof Quantities

a. The schedule-B shall contain Memorandum showing items for the construction,

installation, testing, and commissioning work to be done by the Contractor.

b. Thequantities stated inthe schedule Bare estimated quantities.The Contractorshallbe

paid only quantities calculated after taking measurements of executed work. The rate

stated in the schedule B for each item of work shall apply. The works shall be measured

by the Contractor jointly with the authorized representative of the Engineer and all

particulars required by the representative of the Engineer shall be supplied by the

c. Theworkshallbemeasurednet.Noallowanceforgeneralorlocalcustom,workingspace etc. is

TheEngineerinChargeshallhavepowertomakeanyvariationofform,qualityorquantityof the works

oranypartthereof that may, inhisopinion, benecessary andforthatpurpose,or if for any other

reason it shall, in his opinion, be appropriate, he shall have the authority to instruct the

Contractor to do and the Contractor shalldo any of the following:

 Increaseordecreasethequantityofanyworkuptoanyextentincludedinthecontract,

 Omitanysuchwork,

 Changethecharacterorqualityorkindofanysuchwork,

 ExecuteadditionalworkofanykindnecessaryforthecompletionoftheWorksor

 Changeanyspecifiedsequenceor timingof constructionofanypart ofwork.

No such variation shall in any way vitiate or invalidate the contract,but the effects, if any, of

allsuchvariationsshallbevaluedinaccordancewiththefollowingsubclauses.Providedthat

wheretheissueofaninstructiontovarytheWorksisnecessitatedbysomedefaultorbreach of

contract by contractor or for which he is responsible, any additional cost attributable to such

default shall be borne by the Contractor.

The Contractor shall not make any such variation without an instruction of the Engineer. No

instructionisrequiredforquantitiesvaryingfromthoseprovidedfortheitemsinthecontract

The basis for the valuation of variations for addition to the Contract Price shall be as follows in the

same order of priority.

a) Variationsinthequantitiesofworkinscheduleofquantitiesshallnotvitiatethe contract.

b) Thecontractorshallbeboundtoexecuteextraitemsofworkasdirectedbythe Engineer-in-

c) Contract unit rates for individual items shall apply to varied quantities where there is a

quantity variation.

d) Thepricevariationsonextraitemwillnotbegiven.

e) Incaseof othernontenderitemsfollowingprocedureshallapply.

If any extra item crops up during the progress of work the same shall be carried out by the

ContractorandheshallbepaidattheratefixedbyEmployerwhichshallbefixedaslowestof the

rates derived by rateanalysisbased on the following three methods. , the priority of the

documents forming the Contract shall be as follows:

(i) If theextraitem isincludedintheS.O.R.of Road&BuildingDepartment,Year2013-14,

therateofextraitemshallbethatrateandpremium(aboveorbelow)quotedby

SignatureofBidder Page17of36

AhmedabadMunicipalCorporation

(ii) RateanalysisbasedonprevailingGovt.ofGujarat’sSORrates.

(iii) Rateanalysisbasedoncurrentmarketrates.Thisshallbebasedon

 The material costs, the labour costs, the cost of use of all plant, machinery and

equipment, the cost of all temporary and incidental works, the overheads and the

Contractorsprofit.

 Theoverheadsshallbetakenat5%ofthesumofmaterialcosts,thelabourcosts,the cost of

use of all plant, machinery, and equipment, the cost of all temporary and incidental

Incaseoftherateistobederivedfromprevailingmarketrate,theContractorsprofitshallbe taken at 10 %

of the final rate derived.

In the event of disagreement,the Engineer in Chargeshallfix such ratesand pricesasare, in his opinion

appropriate and shall notify the Contractor accordingly with a copy to the Employer.

The Engineer shalldetermine provisional rates and prices to enable on account payments to be

included in the Interim Payment Certificates, until rates and prices are agreed as final by the

Employer, the Contractor, and the Engineer.

The Contractor shall not be entitled to additional payment for costs, which could have been avoided

by giving early warning.

Paymentsshallbeadjustedfordeductionsforadvancepayments,retention,otherrecoveries in termsof

thecontractand taxesat source,asapplicable under the law. The Employershall pay the

Contractor the amounts certified by the Engineer.

If an amount certified is increased in a later date certificate due to corrections in previous

certificates or as a result of an award from disputes review experts, Contractor shall be paid

suchamountonly.TheContractorshallnotbepaidanyinterestuponsuchdelayedpayment.

Items of the work for which no rate or price has been entered in will not be paid for by the

Employerand shall be deemed covered by other rates and prices in the Contract.

AllpaymentsshallbemadeinAhmedabad.

12 Taxesandduties

The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local

Governingbodiesprevailingonthedateofawardofthecontract.TheContractorwillhaveto payall

such taxes and duties for the performance of this Contract. The Employer will deduct

fromtheContractor’smonthlyandotherpaymentsalltaxesandduties,whichheisboundto

recover in accordance with the applicable law.

The Contractor shall keep himself fully informed of all acts and laws of the Central & State and local

Governing bodies, all orders, decreesof bodies,tribunalshaving any jurisdiction or authority

which in any manner affect those engaged or employed, and anything related to carrying

out the work. All the bye-laws lay down by AMC/AUDA and any other local bodies while

executing the work shall be adhered to. All taxes of local bodies shall be borne by the

contractor. The Contractor shall arrange to give all notices required by any authority and to

pay to such authority all the fees that may have to be paid for the material, plants,

equipmentsetc.TheContractorshallalsoadheretoalltrafficrestrictionsnotifiedbythelocal

authorities. He shall protect and indemnify the Owner and its officials & employees against

anyclaimorliabilityarisingoutofviolationsofanysuchlaws,ordinances,orders,decree,

SignatureofBidder Page18of36

AhmedabadMunicipalCorporation

whetherbyhimselforbyhisemployeesorhisauthorizedrepresentatives.Nothingextrashall be

payable on these accounts.

13.0 LabourWelfareCess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-

1831-M(3) dt. 9/12/05 issued by G.O.G. (non-refundable) shall be deducted from every bills

which shall be deposited to Govt. Labour Department for Labour welfare fund.

14.0 Currencies

AllpaymentsshallbemadeinIndianRupees.

15.0 AdvancePayment

NoAdvancePaymentshallbemade.

16.0 CostofRepairs

LossordamagetotheWorksorMaterialstobeincorporatedintheWorksbetweentheStart Date

and the end of the Defects Correction periods shall be remedied by the Contractor at the

Contractor's cost if the loss or damagearises from the Contractor's acts or omissions.

B. FINISHINGTHECONTRACT

17.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works

and the Engineer will do so upon deciding that the Work is completed.

18.0 Termination

TheEmployershallbeentitledtoterminatethecontractifthecontractor:

(a) Failstocarryoutanyobligationunderthecontract.

(b) Withoutreasonableexcusefails–

1. TocommencetheworksonsitewithintheperiodstatedintheAppendixtoBidafter

receiptbyhimofaNoticetothiseffectfromtheEngineer/Employeraftersigningthe

2. To proceed with the works, or any section thereof, within 28 days after received

3. Hasfailedtocomplywithanoticeissuedoraninstructionissuedwithin28daysafter having

4. Abandonstheworksorotherwiseplainlydemonstratestheintentionnottocontinue

performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written

permission of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or

administration order made against him, compounds with his creditors, or carries on

business under receive, trustee or manager for the benefit of his creditors, or if any

act is done or event occurs which (under applicable Laws) has a similar effect to any

of these acts of event.

Inanyoftheseeventsorcircumstances,theEmployermay,upongiving14daysnoticetothe contractor,

terminate the contract and expel the contractor from the site. However, in the caseofsub-

paragraphs(h),theEmployermaybenoticeterminatethecontractimmediately.

The Employer’s decision to terminate the contractshallnot prejudiceanyother rightsof the Employer,

under the contract or otherwise.

SignatureofBidder Page19of36

AhmedabadMunicipalCorporation

After termination, the Employer may complete the works and/or arrange for any other entities to

do so. The Employer and these entities may then use any goods, contractor’s documents

and other design documents madeby or on behalf of the contractor.

The Employer or the Contractor may terminate the Contract if the other party causes a fundamental

breach of the Contract.

FundamentalbreachesofContractinclude,butshallnotbelimitedto thefollowing:

(a) theContractorstopsworkfor14dayswhennostoppageofworkisshownonthecurrent

Program and the stoppage has not been authorized by the Engineer;

(b) the Employeror theContractor ismadebankruptorgoes into liquidation otherthanfor a

reconstruction or amalgamation;

(c) Thecontractorfailstofulfillrequirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental

breach of Contract and the Contractor fails to correct it within a reasonable period of

time determined by the Engineer;

(e) theContractordoesnotmaintainasecuritywhichisrequired;

(f) theContractorhasdelayedthecompletionofworksbythenumberofdaysforwhichthe

maximum amount of liquidated damages becomes payable as defined in the Contract

(g) if the Contractor, inthejudgmentof the Employerhasengaged incorrupt orfraudulent

practices in competing for or in the executing the Contract.

(h) Forthepurposeofthisparagraph:“corruptpractice”meanstheoffering,giving,receiving or

soliciting of anything of value to influence the action of a public official in the

procurement process or in contract execution. “Fraudulent practice” means a

misrepresentation of facts in order to influence a procurement process or the execution

of a contract to the detriment of the Borrower, and includes collusive practice among

Bidders(priortoorafterbidsubmission)designedtoestablishbidpricesatartificialnon-

competitive levels and to deprive the Borrower of the benefits of free and open

When either party to the Contract gives notice of a breach of contract to the Engineer for a cause

other than those listed above, the Engineer shall decide whether the breach is fundamental

Notwithstandingtheabove,theEmployermayterminatetheContractforconvenience.

If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and

secure and leave the Site as soon as reasonably possible and handover the site to the

Employer including all materials and plant and equipment existing there upon.

19.0 Contractor'sownresponsibility

Thecontractoristosetoutandleveltheworksandwillberesponsiblefortheaccuracyofthe

same.Heshallalsoberesponsibleforthecorrectnessofthepositions,levels,dimensions,and

alignmentofallpartsofthestructuresasperinstructionsgiventohim.Ifatanytimeanyerror shall

appear during the progress of any part of the work, the contractor shall at his own expense

rectifysuch error if called upon to the satisfaction of the Engineer in charge.

20.0 Overpayment&Underpayment

Whenever any claimFifthspayment of a sum to the Municipal Corporation arisesout of or under this

Contract against the contractor the same may be deducted by the Municipal Corporation

from any sum then due or which at any time thereafter may become due to the contractor

under this contract and failing that under anyother contract with the Municipal Corporation

or from any sum due to the contractor with the Municipal Corporation (which may be

available with MunicipalCorporation), or from his retention money, or he shall pay

theclaimondemand.TheMunicipalCorporationreservestherighttocarryoutpostpayment

SignatureofBidder Page20of35

AhmedabadMunicipalCorporation

audit and technical examination of the final bill including all supporting vouchers, abstracts,

TheMunicipalCorporationfurtherreservestherighttoenforcerecoveryofanyoverpayment when

detected notwithstanding the fact that the amount of the finalbill may be included by the

If as a result of such audit and technical examination any over payment isdiscovered in respect of any

work done by the Contractor or alleged to have beendone by him under the

contract,itshallberecoveredbytheMunicipalCorporationfromthecontractorbywayofall the

means prescribed above or ifany under payment is discovered by the Municipal

Corporation,anyamountdue tothecontractorunderthiscontractorunderpaymentmaybe

adjusted against any amount then due or which may at any time thereafter become due

before payment is made to the contractor from him to the Municipal Corporation on any

other contract account whatsoever.

21.0 Materialsobtainfromdismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for

reasons other than on account of bad or imperfect work, the materials obtained from

dismantling will be the property of the A.M.C. and will be disposed of as per instruction of

Engineer-in-charge in the best interest of the A.M.C.

22.0 DisputetobereferredtoArbitrator

The disputes relating to this contract, so far as they relate to any of the following matters,

whether such disputes arise during the progress of the work or after the completion or

abandonment thereof, shall be referredan independent Arbitrator appointed by AMC as far

possibleinconsultationwiththeagencyifitisnecessaryandsuchdisputesshallbesettledin

accordance with the arbitration and conciliation Act.1996.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon

the works of the site thereof or belonging to the contractor or procured by him and

intended to be used for execution of the work or any part thereof possession of

which may have been taken by the Engineer-in-charge under the said clause –5.

(ii) ThereductioninratesmadebytheEngineer-in-chargeunderclause9fromtheitems of

works not accepted as completed fully in accordance with the sanctioned

specifications.

(iii) The rate of part of payment for any class of work which is included in the additional

or altered work carried out by the contractor in accordance with the instructions of

the Engineer-in-charge under clause 14 and the rates for which is to be determined

under the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by

thecontractorbefore receiptof noticegiven bythe Engineer-in-charge under clause

and/or amount of compensation payable to the contractor under the said clause for

loss in respect of such materials.

(v) Theamountofcompensationwhichthecontractorshallbeliabletopayunderclause 17 in

the event of this failure to rectify, remove or reconstruct the work within the period

specified inthewritten intimationor theamountof expensesincurredbythe Engineer-

in-charge under the said clause17 in rectifying, removing or re-executing the work or

in removing and replacing the materials or articles complained of.

(vi) The reductionof ratesasmaybe fixed bytheEngineer-in-charge underclause17for the

inferior work or materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates

and assessed under clause

SignatureofBidder Page21of36

AhmedabadMunicipalCorporation

(viii) The amount payable to the contractor for the work carried out under clause 33 in

accordance with the instructions and the requirement of the Engineer-in-charge in

case where there are no specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and

calculations to every item of claims. The decision willhave to be implemented by all

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation

approachingonCourtofLaw.Itshallbewithinthejurisdictionwherethesiteofwork is

Thereferencetoarbitrationproceedingunderthisclauseshallnot:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause

to take possession of all or any tools, plants, materials and stores in or upon the works of

sitethereofbelongingtothecontractororprocuredbyhimandintendedtobeusedforthe

execution of the work or any part thereof.

ii) PrecludetheEngineer-in-chargefromutilizingthematerialspurchasedbythecontractorin any

work or from removing such materials to other places, during the period the work is

stopped or suspended in pursuance, of notice given to thecontractor underclause

iii) Progressof thework or the carrying out the additionalor altered work in accordance with

the provisions of clause 14 or as the case may be, of clause

23.0 DrawingsandPhotographsoftheWorks

Thecontractorshalldophotography/videographyofthesiteasandwhenaskedbyAMC.No separate

payment will be made to the contractor for this. . The contractor shall have to submit the

same in hard copyaswellassoft copy asand when demanded by the AMC.

No photograph of the works or any part thereof or plant employed thereon, except those

permittedunderclause59.1,shallbetaken,orpermittedtobetakenbytheContractororby any of

his employees or any employees of his sub-Contractors without the prior approval of the

Engineer in writing. No photographs/ videography shall be published or otherwise circulated

without the approval of the Engineer in writing.

Seal and Signature of the Bidder Additional City Engineer

Date: AhmedabadMunicipalCorporation

SignatureofBidder Page22of36

AhmedabadMunicipalCorporation

yb>tJt> BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe >hJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt yb>tJt> BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg

gt>elt ftuLx[fxhtu Che NfNu. dJobuLxlt btLg ftuLx[tfxhu yb>tJt> BGþrl.ftuvtuohuNlbtk btLg

ftuLx[tfxhtule gt>ebtk hSMxuNl fhtJJtlwk hnuNu.

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u

stuzJtle hnuNu.

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt

mûtb ntug <ublu s ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs

xtRb jebexbtk ÃþY fhJt sYhe mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt

z:- yb>tJt> Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t

mexe.Rsluh mh¾gwjh,lk -17,<t.09/12/2012 bwsc yb>tJt> Bgwrlrmvj ftuvtuohuNlbtk

ftuLx[t¾xh hSMxuNl Ve, heLgwyj Ve <&t yvd{uzuNl Ve ylu btv>kztu ægtlbtk htFe <u bwsc

ybj fhJtltu hnuNu.

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe

btdo, mkath ylu JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu

mtRx ylu rcÕzekd(fu su ftb fhJt, ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj

ntug).<ubs xuLzhhu yt mtRxlt ftb btxu, rcÕzekd btxu, gtzo, zevtu btxule søgt vtu<tle he<u

bu¤Je juJtle hnuNu. (xuLzhlwk ftb fhJt, ftb vwhwk fhJt <&t ftblt buRxulLm btxule søgt)

(h) yt ftble mbg bgto>t bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle >hufu >huf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt >M<tJus

vh< fhJtlt hnuNu.

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]<

fh<wk bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

SignatureofBidder Page23of36

AhmedabadMunicipalCorporation

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt >huf vtlt ylu rJd<tu vh ftuLx[tfxhu mne

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh >eM<tJustult jFtKbtk ftuR AufAtf fu VhuVth

fhJt >uuJtNu lrn ylu ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug

<tu <ult vh l Dwkx<t Ftuxt jFtK fu ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ

Wfju <u he<u jFJt. «ðguf mw^tht vh xwkfe mne fhJe.

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk >NtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug

<tu xuLzh ybtLg dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu

ftuLx[tfxhtult btdo>Nol btxu mtbtLg rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK >NtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt

vîr< y&Jt rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu c>ÕGþ / c>Õgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk >huf Ctde>th y&Jt <u ykdulwk bwFðgthltbwk ^htJlth

Ôgrf< mne l fhu y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR

mtûteyu mtF fhe l ntug.

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, h> fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu

rlKog ytFhe hnuNu. ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh

ftuRvK «fthltu lwfNtle fu J¤<hltu nff>tJtuu fhe NfNu lrn fu ftg>tfeg ftgoJtne yt ykdu

&R NfNu lrn. xuLzh bkswh &gtltu y&o ftb ytve >uJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh

MJefthJtbtk ytJNu lne.

(9) rJmkdr< ylu rnmtc stud:

SignatureofBidder Page24of36

AhmedabadMunicipalCorporation

nt& ^hJtlt ftbtule ctc< >NtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK

Cwjawf leault rlgbtu ylwmth mhCh fhJtbtk ytJNu.

(1) xuLzh Chlthu >hlt Ftltbtk sKtJuj Nç>tu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nç>tuubtk

sKtJuj hfb btLg htFJtbtk ytJNu.

(2) yufb >h ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu >NtoJ<e CtJ vºtflt

Ftltbtk&e hfbbtk Cwj sKtg <tu yufb >h btLg htFJtbkt ytJNu ylu >hlt yt^thu dwKtfth

mw^thJtbkt ytJNu.

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgto>t bwsc fhJtltu hnuNu. yt mbgbgot>t 10 jtF mw^elt ftb btxu

yuj.ytu.ytR. ytÃgt <theF&e 10 r>Jm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg

<theF&e 15 r>Jm&e NY &guj dKJtbt ytJNu. <&t <u >hBgtl ftble 5% juFu zevtuÍex Che

fhthvºt fhJtltu hnuNu.

xuLzhbtk ftuLx[t¾xh îtht Chujt CtJ <btb «fthlt su <u «J<o<t mhfthe xuût mrn<lt

CtJ dKJtbtk ytJNu. ylu <ubtk atjw ftb >hBgtl su ftuR VuhVth &Nu <ultu J^thtu awfJJtbtk

c:- mûtb m•tt îtht Yt.10,00,000.00 (>m jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ct>

(LOI) ytvJtbtk ytJNu ðgth ct> r>l - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu.

rm¾gtuhexe zevtuÍex btuze ChJtlt rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth

ftgoJtne fhJtbtk ytJNu.

f:- bkswh &guj xuLzhle mbgbgto>tbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz

xuLzh) btk sKtJuj «btKu bkswh &guj mbgbgto>t ct>lt FhuFh ctfe ftble hfblt bn•tb

10% juFu (jefJezexe zubuSm) vulÕxe Jmwj fhJtbtk ytJNu.

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt >h vwhtk &gujt ftb btxult Au ylu <ubtk

bswhe, vtjF, ÃjtLx, >uFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu

<btb Faoltu <&t sYh sKtg <tu ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu

mbtJuN &Nu ylu xtkfujt CtJ fu >h fh<t J^thtle ftuR awfJKe ykdult <ublt ftuR >tJt

ægtlbtk juJtNu lnek ylu xuLzh Chlth Ftuxe hswyt<lu fthKu y&Jt ftuR Ôgrf<yu (vAe<u

ctk^ftb rJCtdltu fboathe ntug fu l ntug) <ublu ytvuje btne<elu yt^thu vtA¤&e ftuR

>tJt> hsw fhJt nf>th hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk sw>t sw>t CtJ ylu >h ChJt

btxu sYhe yuJe <btb btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u xuLzh hsw fhJtlu je^u

y&Jt <ubtk&e WCt &<t ftuR stuFb fu sJtc>thebtk&e Axfe NfNu lnek. m>h ftbbtk ftuR

vK ò<lt ctk^ftblt bxehegj Wvh CtJ J^thtu ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt

ytJNu. <&t Bgwrl. frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu

ftbdehe/ybj fhJt rcl Nh<e ckDlf<ot hnuNu.

SignatureofBidder Page25of36

AhmedabadMunicipalCorporation

f:- ftuLx[t¾xhlt >huf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk

vubuLx + yu¾x[t ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh<

ytvJtbtk ytJNu.

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftg>t bwsc su ftuR hfble fvt< fhJtle &Nu <u

bwsc ftuLx[tfxhlt cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{

ftblu jtdw vzNu.

ce:- xuLzhbtk >NtoJuj ftb mkck^e >M<tJusbtk >NtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau >NotJuj

¢btlwmth >M<tJusbtk >NtoJuj rJd< d{tng htFJtbkt ytJNu.fhth mkc^e >M<tJustu fhthlt

ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu f>:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk f>, ytfth, ytkfzt f>ta Ftuxt ntug <tu btvujt f>, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^

bwfe yuze.mexe yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc

fhJtbkt ytJuj rlKog ykr<b dKJtbkt ytJNu.

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe

ylu Rsluh Rlatsuo Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) yufe JF<u yuf fh<t J^w søgtytuyu ftb NY fhJtltu Jfo ytuzoh b¤u <tu ftb yuf mt&u s c^u

(16) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu

lwfNtl &Nu <tu <ule mkvwKo sJtc>the (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb

>hBgtl bswhtu fu sl<tlt ftuR btKmlt òlbtj lu lwfNtl &tg <ule sJtc>the

ftuLx[tfxhle hnuNu. vtujem Vrhgt> &tg <tu <ule sJtc>the vK ftuLxtfxhle hnuNu. CuFz

Dme l vzu <ule sJtc>the vK vtujem Vrhgt>bt ftuLx[tfxhle hnuNu. CuFz Dme l vzu <u btxu

mjtb<elt vdjt (suJt fu >tuhzwk ctk^e bswh Ftztbtk W<thJt, mtuhekd ylu Mx[xekd fhJt

rJduhu) je^t Jdh bsqhlu Ftztbtk W<thNu <tu ftuLx[tfxh s vtujem Vrhgt>bt sJtc>th hnuNu

SignatureofBidder Page26of36

AhmedabadMunicipalCorporation

ylu Bgwrl.ftuvtuohuNlltu ftuRvK MxtV ytlt btxu sJtc>th hnuNu lrn. ytxjwk mbSlu s

xuLzh ChJwk. bswhtultu rJbtu vK W<thJtu.

(17) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu

fhtJJtlt hnuNu. bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.

(18) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu

rlgb ylwmth <u ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(19) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< r>l 1btk vh< jR

sJtltu hnuNu. yLg&t <ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(20) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc

ve.yuV/juch yufx <&t bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftg>tlw vtjl fhJtlwk

hnuNu <&t yt ykdu Bgwrl.ftuvtuohuNl îtht su btne<e btkdJtbtk ytJu <u ytvJtle hnuNu.

bu.BGþrl.frbNlh©elt mh¾âwjh Bþsc sYhe ctknu^he vºtf ytvJtLþk hnuNu.

(21) ftuRvK ftg>tfeg jexeduNl yb>tJt> Nnuhle ftuxobt hnuNu.

(22) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu

<ubs dtuXJJtltu hnuNu.

(23) ftuR vK mhfthe fhJuht ChJtle <btb sJtc>the ftuLx[tfxhle hnuNu.

(24) ftuLx[tfxh îtht xuLzhbt >NtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc

jtJJtlt hnuNu.<&t xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw

vtjl fhJtlw hnuNu.

(25) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l

ntug <uJe J^thtle ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb

ylwmth J^thtle ytRxblt CtJ lffe fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk

(26) atjw ftb >hBgtl «tuxufNlle mkvwKo sJtc>the ftuLx[tfxhle hnuNu. subtk vevzt, >tuhzt

Cgmwaf ctuzo, ÃjtMxef vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK

yfMbt< &Nu <tu <ule mkvwKo sJtc>the ftuLx[tfxhle hnuNu.

(27) M&¤ Wvh atjw ftbdehe >hBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg

Ôgrf<lt yfMbt<lt rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem

ftgoJtnele sJtc>the ftuLx[tfxhle hnuNu.

(28) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk >hhtus fhuj

ftbdehe <&t yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk

ftuBÃjtgLm ytvJtlwk hnuNu ytJe ltu^lt sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu

ftuLx[tfxhlu vulÕxe fhJtle m•ttt yuze.mexe yuLSlehgh©elu hnuNu.

(29) >huf ytRxblt MvuNeVefuNl yb>tJt> Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg

htFuj MvuNeVefuNl Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk

yuze.mexe.yuLSlegh©eltu rlKog ytFhe hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu >hhtus

SignatureofBidder Page27of36

AhmedabadMunicipalCorporation

J^thtltu zucheÍ WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu sutFbu Jdh ltuxemu Jtuxhekd

fhtJJtbtk <&t zucheÍ WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(30) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve

(31) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg >hBgtl

ftuLx[tfxh îtht ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk

(32) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu

VhSgt< ytvJtlt hnuNu.

(33) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk

ftb btk ftuRvK mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj

M¾{uJSkd ykdule btdoœrNoft lwk vtjl fhJwk.

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le

bwjtft< je^e Au ylu ftblu jd<t btjmtbtl, bswhe ylu ceS ctc<tulu jd<e

M&trlf vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu

jd<t >M<tJustu ft¤SvwJof yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb<

ftuLx[tfxhle mne ylu rmfft

SignatureofBidder Page28of36

AhmedabadMunicipalCorporation

TECHNICALSPECIFICATIONS:

FollowingtechnicalspecificationsshallbeapplicabletotherelevantitemsofBOQ

Item No1Excavation for foundation upto 1.5 m depth including sorting out and

stacking of useful materials and disposing off the excavated stuff upto

Meter lead.(A) Loose or soft soil

item no 2Excavation for foundation for depth from 1.5m to 3.0 m including sorting out and

stacking of useful materials and disposing off the excavated stuff upto 50 Meter

lead.(A) Loose or soft soil

Anysoilwhichgenerallyyieldstotheapplicationofpickaxesandshovels,spades,rakesor any

such ordinary excavating implement or organic soil, gravel, silt, sand turf loam, clay, peat

etc. falls under this category. For materials and workmanship for earthwork and

excavation, relevant specification IS: 3764 & IS 1200 (Part I) shall be followed.

Thedepthoftheexcavationshallbeaspertheitemdescription.

Clearingthe Site:

The site where the Development has to be carried out shall be cleared and all

obstructions, loose stones, materials and rubbish of all kind, bush; wood and all type

trees shall be removed, as directed. The materials so obtained shall be the property of

theClientand shallbeconveyed andstackedasdirected, within50-m.lead.Therootsof the

trees coming in the sides of the trenches shall becut and coated with hot Bitumen.

Alltypesoftrees,woodsetc.whichrequirespriorpermissionofGovt./ForestAuthority/

MunicipalCommissioner,beforecuttingshallbecutafterobtainingsuchpermissionfrom

them.ItshallbetheClient'sresponsibilitytoobtain suchpermissionfrom therespective

Therateofsiteclearanceisdeemedtobeincludedintherateofearthwork,forwhichno extra

After cleaning the site, the centerline of the central verge & other constructions will be

given by the Engineer-in-charge. The Contractor shall assume full responsibility for

alignment, elevation and dimension of each and all parts of the work. Contractor shall

supply labours, materials, etc. required for setting out the reference marks and bench

marks made of MS angle iron and embedded in 1:2:4 CC.

Theyshallmaintainthesameaslongasrequiredanddirected.

SignatureofBidder Page29of36

AhmedabadMunicipalCorporation

The excavation shall be carried out in true line and level and shall have the width and

depth, as shown in the drawings or as directed. The Contractor shall do the necessary

shoring and strutting or shall provide necessary slopes to a safe angle or steps, as

required or directed, at his own cost.

Noextrapaymentshallbemadeforsuchprecautionarymeasures,taken.

Thebottomoftheexcavatedareashallbeleveledbothlongitudinallyandtransversely,as

directed, by removing excess soil and watering, as required. No earth filling will be

allowed for bringing it to level, if by mistake or any other reason, excavation is made

deeper or wider than shown on the drawings or as directed. The extra depth or width

shall be made up with sand filling, as specified for the bottom level of the subsequent

finishing at the cost of the Contractor or as directed by Engineer-In-Charge.

The Contractor shall at his own expense and without extra charge make provision of

supporting all utility services, lighting the excavated areas, separating and stacking

serviceable materials neatly, shoring, timbering, strutting, bailing out water either sub-

soil or rainwater, including pumping at any stage of the work. Excavated areas shall be

kept freeof waterwhilemasonryorconcrete orrelevant baseworksare inprogressand till

the Engineer-in-charge considers it necessary.

DisposaloftheExcavatedStuff:

The excavated stuff of the selected type shall be used in filling the excavated areas

wherever required inlayers, including ramming and watering, ensuring proper

compaction etc. complete. The Contractor shall remove the balance of the excavated

quantity from the site of work, to a place, as directed and for all lift.

The lead is the shortest practical route and not necessarily the route actually taken. The

decision of Engineer-In-charge shall be final in this regard.

ModeofMeasurementandPayment:

The measurement of excavation of excavated area shall be made according tothe

sections shown on the drawing or as per sections given by the Engineer-in-charge. No

payment shall be made for surplus excavation made in excess of above requirements or

duetosteppingandslopingbackasfoundnecessary,onaccountofconditionsofsoiland

requirements of safety. The rate shall include for clearing the site, surface dressing,

makinglayoutforroad,fixingpermanentgridpointswithMSironposts,embeddedin

C.C. 1:2:4, placed sufficiently away from the existing traffic lines and establishing bench

The rates shall include for necessary shoring, timbering and strutting for protection of

sides of the excavated area, pumping out rain or surface water at any stage of

constructionsoastokeeptheexcavatedareadry,tothesatisfactionofthe/Engineer-in-

charge.Therateshallincludelevelingandrammingthebottomsofexcavationstoreceive

concrete, etc. including trimming to slope wherever necessary etc. complete. In filling

clodsbiggerthan50mm.shallnotbeallowed.Onlyconsolidatedmeasurementsoffilling shall

be paid. Consolidation to be done by mechanical compactor as per relevant item. The

rate shall be for a unit of one m3.

SignatureofBidder Page30of35

AhmedabadMunicipalCorporation

Item No3Conveyance charge of Earth,Lime, Murrum, building rubbish earch

manure or sludge and excavatedrock and fly ash,aggregate of any kind

etc.comp.upto 1 km lead.

Allthe surplusearth &debris remainingon site after sufficientwateringshallbecarried

awayimmediatelyfromsiteofwork.totheplacewithin5km.distanceasdirectedbythe Engineer

in charge, so as not to cause any inconvenience to the public or traffic.

If the instructions of Engineer in charge of work are not followed within 7 days from the

site, the work shall be carried out by the Municipal Corporation at the risk & cost of the

contractor & any claim dispute will not be entertained in the respect.

If the filling in trenches after settlement of the earth filling in trenches is to be done and

the same shall be carried out by the contractor without asking any extra rate. The

contractor shall have to cart the surplus earth after the trenches we will watered and

refilled with the sand. The rate of carting including carting of brick bats, metal, rubble

vegetable and garbage, if necessary to clear the road surface.

ModeofmeasurementshallbeforCmt.Basis

ItemNo4 :Rent for provide j.c.b withtocarryout differentworksforshallbecarried

outaspertheinstrucitonsofEngineerIn-Charge.Noextrachargedshall be

paid for night shift.

Modeofmeasurement:TherateshallbeforaunitofHrs.basis

Item No 5Supplying, labour for excavation of all types of soil at any depth including

excavationofasphaltpavementofanythickness,demolitionofbrickwork in

CM of any proportion including stacking of serviceable materials and

disposal of unserviceable material etc. comp.labour-day, labour-day,

supervisor as directed.

FordetailedspecificationreferA.R.C.

Modeofmeasurement:Therateshallbeforaunitofnobasis

ItemNo6providing arrengement for making protection of site to avoid accident

byusing bericating rolls, bamboo,Teka ,kathi with all labours etc. comp.

FordetailedspecificationreferR.A.

Modeofmeasurement:Therateshallbeforaunitofrmtbasis

Item No7:Brick pitching work using common burnt clay building bricks having

crushing strength not less than 35 Kg/sq cm. in foundation and plinth in

cement mortar 1:5 Conventional

FordetailedspecificationreferR.A.

Modeofmeasurement:Therateshallbeforaunitofsmtbasis

ItemNo8:ExtraOverItemforCementSlurryOverBrickPitching.

SignatureofBidder Page31of36

AhmedabadMunicipalCorporation

AspersiteengineerModeofmeasurement:Therateshallbeforaunitof smt basis

ItemNo9:P/FgoodqualitityHDPEplasticcoverofrequiredsizebyjointingthepieces of

coverbyspecialsewing&usingchemicaladhesivestoretainwaterin

alsoincl.labourworkforsettingcoverinsitu.

FordetailedspecificationreferR.A.

Modeofmeasurement:Therateshallbeforaunitofsmtbasis

ItemNo10makingnecessarydiversion boardaspertrafficrequirementofsize 0.90x

0.60withradiumcolouretc.comp.

FordetailedspecificationreferR.A.

Modeofmeasurement:Therateshallbeforaunitofsmtbasis

ItemNo 11Providing and operation dewatering Pump including fuel charges& operator

Charges etc. as directed etc. comp. (Shift for Eight Hour) (For

EachPumpSet,Nopaymentshould be allowed fornonworking condition of

machinery ) ( Based on Previously approved rate by C E sir )

Providing and operation dewatering Pump including fuel charges& operator Charges

etc. as directed etc.comp. (Shift for Eight Hour)(For EachPump Set, Nopaymentshould be

allowed for non working condition of machinery )

M/s.shallbeonShift.basis.

Providing and fixing to wall ceiling and floor 10.0 Kg. F/Cm2 working pressure

poluthene pipes of the following outside Dia. Low densidy, complete with special falnge

compression type fittings, wall clipsetc. includingmaking good the wall ceiling and floor

Providing and fixing to wall ceiling and floor 10.0 Kg. F/Cm2 working pressure

poluthene pipes of the following outside Dia. Low densidy, complete with special falnge

compression type fittings, wall clipsetc. including making good the wall ceiling and floor

SignatureofBidder Page32of36

AhmedabadMunicipalCorporation

Supplying5000literscapacityPortablewatertankerfor8hoursperday(net8 hours) of

AMC Central Zone as & when req.by Eng.incharge.

AspersiteengineerModeofmeasurement:

Modeofmeasurement:Therateshallbeforaunitoftripbasis

SealandSignatureoftheBidder Addl.CityEngineer

Date: AhmedabadMunicipalCorporation

SignatureofBidder Page33of36

AhmedabadMunicipalCorporation

AHMEDABADMUNICIPALCORPORATION

ENGINEERINGDEPARTMENT(CENTRALZONE)

NameofWork:- bægÍtu l Ntnectd Jtu zo b tk œNtbtk lt bkrœh ytd¤ lt rJM<thbtk dKu N fwk z <i g th fhJtlt ftb

Sr.No. Quantity ItemDescription Ratein Per Amountin

Excavation for foundation upto 1.5 m depth

including sorting out and stacking of useful

materials and disposing off the excavated

stuffupto50Meterlead.(A)Looseorsoft

1 500 soil 77.28 cmt

Excavationforfoundationfordepthfrom1.5 m

to 3.0 m including sorting out and stacking

of useful materials and disposing off the

excavated stuff upto 50 Meter

2 400 lead.(A)Looseorsoft soil 85.68 cmt

Conveyance charge of earth ,lime, murrum,

building rubbish,manual garbage, sludge,

excavated rock ,fly ash, aggregate of any

kind etc. comp.up to 1.0 Km. lead

Rent for provide j.c.b Machine for Refilling

WorkandLevellingthesiteasDirected.Rate

also includes all necessary Operating like

Diesel,toolsandDriverexpencesetc.

4 90 comp. 600 hrs

Supplying ,labour for excavation of all types

of soil, levelling work and Security Work to

avoid an accident during Visarjan bypilgrims

120 (4A)Mazdooratday 329 Nos

20 (4b)Mukadamat day 425 Nos

120 (4c)Mazdoorat Night 329 Nos

20 (4d)MukadamatNight 425 Nos

Providing arrengement for double layer

berricating for protection of site avoid

accident by using bericating rolls, bamboo,

teka , kathi with all labours etc. Comp.

Providing & laying cement concrete 1:4:8 (1

cement : 4 coarse sand : 8 hand broken

stone aggregates 40 mm nominal size) and

curing complete excludingcostof formwork

in Foundation and plinth

Brickpitchingworkusingcommonbumtclay

bulding bricks having crushing strength not

less than 35 kg/sq cm in foundation and

ExtraOverItemforCementSlurryOver Brick

SignatureofBidder Page34of36

AhmedabadMunicipalCorporation

P/F good qualitity HDPE plastic cover of

requried size by jointing the pices of cover

by special sewing& using chemical

adhesvies to retain water inkund. Rate also

incl. labour work for setting cover in situ.

making necessary diversion board as per

trafic requirment of size 0.90X0.60 with

11 10 radium coloue etc comp. 1200 Nos

Providing and operation dewatering Pump

including fuel charges& operator Charges

etc. as directed etc. comp. (Shift for Eight

Hour) (For Each Pump Set, No payment

should be allowed for non working condition

of machinery ) ( Based on Previously

approved rate by C E sir )

12 20 600 Shift

Supplying 5000 liters capacity Portable

water tanker for 8 hours per day (net

hours) of AMC Central Zone as& when

req.byEng.incharge.

SealandSignatureoftheBidder Addl.CityEngineer

Date: AhmedabadMunicipalCorporation

SignatureofBidder Page35of36