Tender For Work of loading and unloading materials at Divisional Store Office under Dhrangadhra Division office.

2 Estimated cost in Rs. 9,90,000/-

3 Tender Fee in Rs. ( non-refundable) with 18 % GST 885/-

Payment of tender fees to be deposited online by

RTGS/NEFT to the details of bank account is the

details of bank account is

SBI Account No:-56100000320

IFSC code :- SBIN0060100 and name of account

holder _ Paschim Gujarat Vij Company Limited

(Payment RTGS/NEFT to the

details of bankaccount is

the detailsof bank account is

Earnest Money Deposit amount in Rs.

5 SBI Account No :-

(1 % of Tender Amount)

56100000320 IFSC code :-

SBIN0060100 and name of

account holder_ Paschim

Gujarat Vij Company Limited.)

On line ( e-tendering ) tender offer submission last

Starting From 30.10.2026

6 Date 06.11.2026 up to 18:00 hours only.(This is

Date of Opening of Online Technical Bid at Date:

07.11.2026 @ 12 hours (if possible)

Date of online opening of Online Price bid, Date

07.11.2026 @ 15 hours (if possible)

9 Time Limit 1 Years.

10 Validity of Bid 120 Days

Executive Engineer

Dhrangadhra Division

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

PASCHIM GUJARAT VIJ COMPANY LIMITED

(A Gujarat Govt. Undertaking)

Division Office, DCW Road, Dhrangadhra-363310

e-mail:[email protected] web site:www.pgvcl.com

Registered & Corporate Office:

“Paschim Gujarat Vij Seva Sadan” Off. Nana Mava Main Road, Laxminagar, Rajkot

CIN : U40102GJ2003SGC042908

INSTRUCTIONS FOR FILLING THE TENDER

1.All the relevant documents as per requirement of the Tender also to be submitted Online

only along with the Tender Fee Receipt with GST @ 18% & EMD Receipt in sealed cover on

OR before due date and time. The tender document upload while submitting tender. . If tender is

submitted in physical form, same will not be opened and not qualify for technical bid, only

on-line submitted Tender bid will be considered for evaluation.

2. Any deviation found in Data / Details / Documents between on line offer (e-tendering)

and physically submitted documents (Tender document fee, EMD, Vender Registration,

Technical and commercial documents etc.) of bidder, offer of the same bidder will not be

considered and no any further communication in the matter will be entertained.

3. Further bidders are requested to submit price – bid (Schedule – A) on-line only and not to

submit the price bid in physical form. This is mandatory. If price bid is submitted in physical

form, same will not be opened and only on-line submitted price bid will be considered for

4. It is mandatory for all the bidders to submit their tender documents by viz. on – line (e –

tendering) and physically in schedule time. If tender documents submitted in only on line, in

that case the same tender will not be considered, physical submission is compulsory. Any

discrepancy arise between online and physical data, online data should be consider for

5. No tender shall be accepted / opened in any case after due date & time of Receipt of

tender irrespective of delay due to postal services or any other reasons and that the PGVCL

shall not assume any responsibility for late receipt of tender.

6.Any technical questions, information and clarifications that may be required pertaining to

this enquiry should be referred to the EXECUTIVE ENGINEER, PASCHIM GUJARAT VIJ

COMPANY LTD., DIVISION OFFICE-DHRANGADHRA, OLD POWER HOUSE COMPOUND , D.C.W.

ROAD , DHRANGADHRA. PGVCL, Executive Engineer, Dhrangadhra reserves the right to reject

any OR all tenders without assigning any reasons thereof.

7. The Security Deposit will have to be paid by successful bidder 10% of the total contract

price within 15 days after receipt of LOA at PGVCL Division Office, Dhrangadhra. The amount

will be paid in cash /NEFT/RTGS/DD or bank guarantee .The bank guarantee of nationalized

bank shall be valid up to 90 days after the completion of the entire contract work period.

8. The specification of schedule, and the terms and conditions of the booklets of “Tender

Contract for Works” shall be binding to the contractors in token of its acceptance.

9. The rate contract will be in force for one year from the date of issue of order.

10. All P.F rules & GST will be applicable to this Tender.

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

11. Contractor have to submit Following Documents:

I. GSTN certificate

IV. Solvency / Bank Guarantee (20% Tender Value)

VI. Experience Certificate

VIII. Valid Labour Insurance Policy

12. After submission of Online & Physical bids, cancellation cannot be done.

13. The quantities mentioned are approximate & may be increased or decreased while

placing the order, please quote your rate exclusive of GST clearly making remarks to the

effect. Also please quote your Sales Tax registration No. and VAT No., GST Number in your

quotations. As we are exempted from payment of S.T. necessary Tax declaration from will

be issued against Bills.

14. The rates may please be quoted for delivery at FOR destination or at Divisional store

situated at Dhrangadhra.

15. The material is required from ready within 30 days from the date of receipt order

alternatively please quote your time limit has which you will be able to supply the

materials. This time limit has to be strictly adhered to.

16. Samples can be seen at this office during working hours and it must be approved by

authorities. In case when required sample may be sent along with quotations. SAMPLE MUST

BE SENT ALONG WITH THE QUOTATION.

17. The successful tenderer has to pay the security deposit 05 % of the ordered value and

the same will be refund as soon as materials are supplied in full as per order & on receipt of

no objection certificate from our Engineer.

18. Please mark your envelope with "Quotations for ...As Above...& due DT. & time.

19. Quotation will be valid up to 90 days as per company's Rule.

20. “If any agency is accused in criminal case or is having pending civil suite, against

him/her firm by PGVCL or against PGVCL filed by him/her firm, is not eligible to take part in

this tender/limited inquiry”.

21. All agencies taking part in this tender has to submit notarized self-notarized, self-

declaration for above matter along with technical bid.

22. Material will be supply for 365 Days from the receipt of the purchase/work order date.

And this order/tender will be valid only for one year.

Signature of Contractor

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

PASCHIM GUJARAT VIJ COMPANY LIMITED

(A Gujarat Govt. Undertaking)

Division Office, DCW Road, Dhrangadhra-363310

e-mail:[email protected] web site:www.pgvcl.com

Registered & Corporate Office:

“Paschim Gujarat Vij Seva Sadan” Off. Nana Mava Main Road, Laxminagar, Rajkot

CIN : U40102GJ2003SGC042908

GENERAL INFORMATIOS FOR BIDDERS

1. TENDER FEES:

Payment of tender fee and EMD can be accepted Online RTGS/NEFT in PGVCL only.

The detail of Bank Account of SBI (Account holder Paschim Gujarat Vij Company Limited.)

BANK ACCOUNT NUMBER :-

IFSC CODE :-SBIN0060100.

2.1 The EMD payable, between the dates mentioned in Table no 1 , Payment RTGS/NEFT

to the details of bank account is the details of bank account is SBI Account No :-56100000320

IFSC code :- SBIN0060100 and name of account holder _ Paschim Gujarat Vij Company

Limited. The EMD Amount is 1 % of the Tender Estimated Cost.

2.2 The digital copy of amount transfer towards Tender fee and EMD is to be uploaded

with the tender documents.

2.3 The EMD of all unsuccessful bidders except that of the successful bidder will be

returned after the award of the contract.

2.4 EMD of the successful bidder to whom a contract is awarded will be returned after

the said bidder pays the security deposit and signs the contract agreement.

2.5 If the successful bidder fails to submit a Security Deposit within 15days from the date

of LOA of the contract or fails to sign the contract agreement then the EMD amount will be

forfeited in favour of PGVCL without any notice or and action for “Stop deal” will be

initiated as decided by tender inviting authority.

2.6 No interest will be payable by the PGVCL on the above Deposit.

2.7 Tenders without Earnest Money Deposit by the firms/Name will be rejected without

entering in to further Correspondence in this regard and no reference will also be made.

3. SECURITY DEPOSIT (SD):

The successful bidder will be required to pay an amount equivalent to 5% of the value of the

Order as a Security Deposit before placing the work order for satisfactory performance of

the execution of Contract. If the full Security Deposit amount is not paid within 15 (Fifteen)

days after the receipt of the LOA, then the LOA will be out rightly cancelled & work order

will not be placed (at the discretion of PGVCL). EMD amount of such bidder/s will be

forfeited without entering into any correspondences and this will be binding on the Bidder.

PGVCL will also take action against such bidder/s like stop deal/black list/works at the risk

& cost of the bidder or actions as desired by the Company. Security Deposit will be payable

by Online Only.

The detail of Bank Account of SBI (Account holder Paschim Gujarat Vij Company Limited.)

BANK ACCOUNT NUMBER :-

IFSC CODE :-SBIN0060100.

The security deposit will be refunded only after the finalization of final bill and no any

interest will be paid against SD amount. The same shall be refunded on completion of work,

successfully and on receipt of “NOC” from concerned Dept. i.e. after completion of Twelve

months of date of commencement of work.

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

4. PENALTY FOR DELAY IN COMPLETION OF CONTRACT:

In case of delay, penalty shall be levied at 0.5(Zero Point Five) % of contract value per week

with maximum 10(TEN) % selling of per bill value per week. This will be deducted from your

bill payable either from this contract or from any other contract with the Company or from

EMD or Security deposit amount.

5. CONTRACT AGREEMENT:

Successful bidder shall have to execute the contract agreement Bond on non-judicial stamp

paper of Rs. 300.00 the cost of the same will be borne by the bidder.

The prices should be inclusive of all applicable taxes excluding prevailing GST.

In the wider interest of safety you contractor will have to provide all required safety gadgets

as per PGVCL norms to your all workmen while working. Use of same must be ensured by you

and for any consequences that arise out of non-use of these safety gadgets, PGVCL will not

be responsible. Certificate by contractor must be given while submission of bill that

necessary safety Gadgets is issued to and used by all workmen working for contractor. For

any deviation PGVCL will take action as per norms. It will be the responsibility of bidder /

contractor to cover sufficient amount of insurance of their personnel involved in the

erection work of tender item/s during execution of works. PGVCL shall in no way be

responsible for any injury, damages, accident etc. to their personnel execution / erection

work, supervision etc. under the contract.

8. OTHER CONDITIONS OF SUPPLY:

The PGVCL General Conditions of Contract will apply to all Supplies and Contracts and you

will deemed to be fully aware of the this General Conditions of Contract for the supply of

Materials particularly in respect of Security Deposit, Terms of Payment, Penalty for late

delivery etc. and any ignorance of these Conditions will not exempt you from liability to

abide by the same.

9. FAILURE TO EXECUTE THE CONTRACT:

On failure to execute the order placed on successful bidder, under the terms & conditions

set forth therein, to the satisfaction of PGVCL, the contractor will be liable to make good

the loss sustained by PGVCL. Under such circumstances, PGVCL shall cancel the order and

forfeit the SD. PGVCL may also go for fresh order on other party at the risk & cost of

successful tendered or may carry out departmentally, debiting the cost to the successful

bidder / contractor.

10. TERMINATION OF CONTRACT:

The PGVCL, upon written notice of default to the contractor, shall terminate in the

circumstances detailed as under: If, in the opinion of the PGVCL, the contract or fails to

complete the work specified in the scope of works given in Schedule-A within the time

specified for the same in the contract or within the period for extension has been granted by

PGVCL to the contractor. If, in the opinion of the PGVCL, the contractor fails to comply with

any of the other provision of the contract The PGVCL shall also be empowered to cancel the

contract, if any deficiency in erection work and or bad performance is noticed. The work

specified in the scope of works given in Schedule -A within the time specified for the same

in the contract or within the period for extension has been granted by PGVCL to the

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

11. CHANGE AND QUANTITIES:

The PGVCL shall have the rights to make any changes /addition / deletions or modification

in any terms / conditions of the tender and / or specifications as may be deemed necessary

by PGVCL at its sole discretion at any time before the due date of opening of the tender.

The quantities mentioned in the accompanying Schedule are only approximate. Actual

quantities may increase or decrease according to the requirements. The Company reserves

the right of revising or deleting any of the quantities to be executed against the contract

And final quantities actually executed by the contractor will be calculated and paid at the

rate given in contract schedule of rates.

13. PGVCL reserves the right to cancel any or all the offer / bids or to accept any offer

without assigning any reasons. PGVCL reserves the right to place the order by split ting the

tender items / quantity by awarding to more than one contractor.

14. JURISDICTION:

All questions, disputes or differences arising under out of or in connection with the Tender /

Contract if concluded shall be subject to the exclusive jurisdiction of the court under whose

jurisdiction the place from which the tender / Acceptance of tender is issued, is situated.

15. PGVCL as well as supplier / contractor will be bound by rules and regulation of Indian

16. Income Tax (TDS), GST (TDS) & CESS whenever applicable will be deducted / recovered

as per Govt. rules and regulation

17. Contractors must have valid solvency as per Company’s rules. Contractor Licence, Bank

Solvency, Registration of line / cable laying work & Experience certificate to be attached as

per requirement of tender.

18. ontractors will have to submit full documents set i.e. PF Registration, Pan card,

Solvency, Contractor Registration License, GST Registration, Partnership deed (if partnership

firm), Company’s memorandum etc., of all the legal papers required for the purpose with

rates quoted by them.

19. Bidder shall mention Registered E.P.F. & I.T. Dept. Pan -Card, GST etc. in his offer and

submit the photocopy of certificate of each, otherwise Tender shall not be considered in

20. It is declared that we have no any stop deal / black list with GUVNL & its subsidiary

21. No tools, tackles nor their maintenance and labor for execution of order will be provided

22. PERIOD OF CONTRACT:

The contract will be remained in force for period of 12 Month. The contractor shall call /

indent the required material from S/dn / Dn Store in advance & on completion of the work,

prepare and render the final detailed material account of the received by him from the SDn.

/ Dns store within one month from the date of completion of work.

23. INDEMNITY BOND:

The contractor will have to executed an indemnity bond on stamp paper of Rs.300/-at his

cost before commencement of work stating the matter conversing that for any accident to

the contractor’s staff/equipment or any person, either fatal or non-fatal, due to non-

observing of safety measures, PGVCL, shall not be responsible.

24. CONTRACTOR LIABILITY:

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

For any accident either fatal or non-fatal to the workers due to non-observances of the

safety measures as per rules or due to lack of proper care by the contractor’s labor, PGVCL

shall not be responsible.

All offers should be kept valid for acceptance for a period 120 (One Hundred Twenty) days

from the date of opening of tender. Offers with short validity will be liable for rejection

without any correspondence.

26. Contractor shall submit the bill of work at regular period of stipulated time.

27. STATUTORY VARIATION:

Any statutory increase or decrease in the taxes subsequent to contractor / bidder offer if it

takes place within the original contractual delivery date will be to PGVCL account subject to

the claim being supported by documentary evidence. However, if any decrease takes place

after the contractual delivery date, the advantage will have to be passed on to PGVCL.

28. PAYMENT TERMS:

Payment of works shall be made in 45 Days after scrutinizing of Bill submitted by contractor

if found in order.

29. The contractor has to store all the allotted materials in safe custody on their end. The

allotted materials by PGVCL should be insured at their cost towards theft, loss, damaged

etc. The contractor is fully responsible for storing of all the materials allotted by PGVCL for

the works under contract.

30. PGVCL shall issue the required materials under the contract from any store of PGVCL and

the contractor has to carry out all the transportation at their cost up to the sites.

31. PGVCL reserves the right to cancel any or all the offer/bids or to accept any offer

without assigning any reasons.

32. Agencies /Contractor has to submit notarized self-declaration for " criminal case or is

having pending Civil Suite, against him/her firm by PGVCL or against PGVCL filed by him/her

firm “ along with Technical bid.

33. Dispute Resolution Mechanism

(Old Arbitration Clause Repealed and Dispute Resolution Mechanism clause inserted

by GUVNL circular No. GUVNL/CS/Legal/03 Dated: 26.06.2025)

(1) Amicable Settlement

Any dispute, difference, controversy or claim. between the Parties arising out of or

relating to this contract with reference to the construction, interpretation, breach,

termination or validity thereof (hereinafter referred as "the Dispute") shall, upon the

written request of either Party be referred to the authorized representatives of the

Disputing Parties for resolution. The authorized representatives shall promptly meet

and attempt to negotiate in good faith a resolution of the Dispute within thirty days of

the service of the request.

(2) Arbitration

If the Parties fail to amicably resolve the disputes or differences or contrary claims as

indicated herewith in sub clause (1) of Clause arising under or in connection with the

present works contracts, whether pertaining to works contracts alone or works and

procurement both, the same shall be referred to arbitration under the Gujarat Public

Works Contracts Disputes Arbitration Tribunal Act, 1992."

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

(DECLARATION IN REGARDS TO NO CRIMINAL OFFENSE / NO PENDING CIVIL

Sub: -Declaration in regard of no criminal offense/no pending civil suite & there of

(All bidders/agencies will have to furnish the following declaration duly filled in,

signed and stamped and notarized on Rs.300.00 Non-Judicial Stamp Paper, with

self-declaration/authorized declaration submit for each quoted item of the tender

along with the Technical Bid.)

I/We solemnly declare that there is no criminal offense and or no pending civil

suite before the court filled by PGVCL or other subsidiary company of GUVNL

signatory of M/s________________________________________ hereby certify that

M/s__________________________________________and their proprietor / any

partner / any directors of the firms/Agencies/company’s. (Strike out which is not

I/we take the oath and solemnly declare that, the above particulars furnished by

me/us (on behalf of the Firm/Agencies/ Partner / Proprietor /Director of

companies, are correct and that I/we have not concealed or misrepresented any

Signature of Contractor

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

(DECLARATION IN REGARDS TO NO CRIMINAL OFFENSE / NO PENDING CIVIL SUITE

I/We solemnly declare that there is no criminal offense and or no pending civil suite

before the court filled by PGVCL or other subsidiary company of GUVNL against

M/s__________________________________________and their proprietor / any

partner / any directors of the firms/Agencies/company’s. (Strike out which is not

(UNDERTAKING IN REGARD TO STOP DEAL/BANNED FOR BUSINESS DEALING/BLACK LIST &

authorized signatory of M/s_____________________________________________

hereby certify that M/s__________________________________________and their

proprietor / any partner / any directors of the firm is not stop deal and/or banned for

business dealing and/or black listed by GUVNL and/or their any subsidiary company

viz. GSECL/GETCO/ DGVCL/ MGVCL/UGVCL/PGVCL.

I/we take the oath and solemnly declare that, the above particulars furnished by me/us

(on behalf of the Firm/Agencies/ Partner / Proprietor /Director of companies, are correct

and that I/we have not concealed or misrepresented any facts.

Seal of the Firm

Signature of the Tenderer

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

e-mail:[email protected] web site:www.pgvcl.com

CIN : U40102GJ2003SGC042908

Item Description UOM Rate

1 34mm2, 55mm2,100mm2 ALL ALLUMINIUM ALLOY CONDUCTOR DRUM

2 G I WIRE 8 No., 10 No. and GI Stay wire 7/12 MT

3 3.5C X 25/50 mm2 PVC CABLE DRUM

4 3.5C X 70/150 mm2 PVC CABLE DRUM

5 4 C X 4/6 mm2 PVC CABLE COIL

6 4 C X 10/16 mm2 PVC CABLE DRUM

7 2 C X 2.5/4 mm2 LT PVC CABLE COIL

8 2CX2.5 mm2 ARMOURED ALUMINIUM CABLE COIL

9 11KV XLPE 3C X 185 mm2 CABLE (Approx. 300 MTR) DRUM

10 11KV XLPE 3C X 185 SQMM CABLE (Approx. 1000 MTR) DRUM

11 11KV XLPE Arial Bunch Cable 3C x 70 + 70 Sq.mm Cable(Approx.500 Mtr) DRUM

11KV XLPE Arial Bunch Cable 3C x 70 + 70 Sq.mm Cable(Approx.1000

13 11KV XLPE Arial Bunch Cable 3C x 95 + 80 Sq.mm Cable DRUM

14 LT AERIAL BUNCH CABLE OF SIZE 1C, 2C, 3C or OTHER SIZE DRUM

15 11 KV AB SWITCH SET

16 CAST IRON EARTHING PLATE NO

GI EARTHING BOLT & NUTS WITH WASHER & SPRING WASHER SIZE 40 X

18 LT SHACKLE BOLT BAG

19 KITKAT FUSE (All SIZE) BOX

20 11 KV DO FUSE NO

21 M S BOLTS AND NUTS ALL SIZE BAG

22 1 PHASE AND 3 PHASE 10-60AMP ENREGY METER BOX

23 3 PHASE 100/5AMP AND 200/5 ENREGY METER BOX

24 HHE Paper roll Box

25 HT Meter Box Nos

26 Polycarbonate seal Box

27 SMC METER BOX FOR SINGLE PHASE METER BOX

28 SMC METER BOX FOR THREE PHASE METER BOX

29 3 PHASE SMC METER BOX FOR CT OPERATED ENERGY METER BOX

30 POLE MOUNTED SINGLE PHASE JUNCTION BOX (FOR 8 CONNECTIONS) NO

31 11 KV/22 KV PIN & DISC INSULATOR (POLYMER & PORCELAIN) BOX

32 GUY INSULATOR (H .T/L. T), LT SHACKLE INSULATOR BAG

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

33 PIN HARDWARE FOR 11KV/22KV INSULATOR, DISC HARDWARE BAG

34 L T DISTRIBUTION BOX FOR 16/25/63/100/200 KVA TRANSFORMER NO

35 SMC Distribution box NO

36 LIGHTNING ARRESTOR BOX

37 11 KV FRP V CROSS ARM SET

38 Galvanized V Cross Arm Ready made SET

39 PVC RIGID PIPE BUNCH

40 LT BILL FORMS Single copy/ DOUBLE COPY BOX

41 DMR, HT BILL FORM, AG CARD Box

42 QMR, TMR, DMR, All type MB Bunch

43 Ring type CT All capacity Box

C Clamp, D Clamp, Angle bara, Tp clamp, Guy rod, Tuen buckle, guy clamp, Eye

rod,11 KV V cross arm

45 M S ANGLE, MS FLAT, MS ROUND BAR, MS CHANNEL ALL SIZE MT

46 M S Girder ALL SIZE Nos.

47 CT PT All size Nos.

48 5 KVA Transformer all type NO

49 10/16 KVA Transformer all type No

50 25/63/100 KVA Transformer NO

51 200 KVA Transformer All type NO

52 TRANSFORMER OIL WITH BARREL (FRESH) BARREL

53 CONDUCTOR DRUM CHARGE FOR MEASUREMENT Drum

54 CABLE DRUM CHARGE FOR MEASUREMENT Drum

55 Furniture (Chair, Cupboard, Table) NO.

56 Furniture metal NO.

Ground cleaning or other misc. work in RSO Premises Per person per day

(as per instruction of RSO In charge)

58 Uniform, raincoat with cap, shoes Nos

59 Uniform, raincoat with cap, shoes Bunch

60 APFC Panel Nos.

61 VCB Panel No

62 Electronic items No.

63 Conductor/Cable Cutting (Cutting from Drum with measurement) Meter

64 All scrap MT

65 HT TVM/ TTB modem Box

66 All scrap transformer up to 100 KVA/CTPT No.

67 All scrap transformer above 100 KVA/CTPT No.

68 Scrap meter all size Nos.

69 Scrap oil barrel No

70 Crain’s As & When Required With Fuel Hrs.

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

e-mail:[email protected] web site:www.pgvcl.com

CIN : U40102GJ2003SGC042908

2. સીકયુરીટી ડીપોઝીટની રકમ કોન્રાકટરે વકકઓડકરના ૫% પ્રમાણે NEFT/RTGS/ BANK GUARANTEE ના

14. સરકારી ધારાધોરણ મુજબ પ્રવતકમાન દરે બીલમાંથી આવકવેરો તેમજ GST કાપવામાં આવિે.

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

22. ઈ-ટેન્ડર પી.જી.વી.સી.એલની વેબ સાઈટ www.pgvcl.com પર ફક્ત જોઈ િકાિે તથા (n)procure for e-

tendering ની સાઈટ www.tender.nprocure.com પરથી ડાઉનલોડ કરી િકાિે.

23. ઈ-ટેન્ડરની પ્રાઈઝબીડ ફકત (n)procure for e-tendering ની સાઈટ પર અપલોડ કરવાની રહેિ.ે ફીઝીકલ ટેન્ડર

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra

Prepared By Checked By Approved By

Signature of Tenderer :- Company’s Round Seal J.A. (Tech) D.E. (Tech) Dy.S.A. (Exp) S.A. (Exp) E.E. (O&M)

D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra D.O. D’dhra