Construction of New R.C.C road and New interlocking paver block work MP/MLA AND COUN.BUDGET at different society and chali area in Viratnagar ward in East Zone (ARC)

2 TOTAL ESTIMATED COST  ₹

3 EARNEST MONEY  ₹

In DEMAND DRAFT / PAY ORDER FROM

BANK ACCEPTABLE TO THE AMC

4 VALIDITY PERIOD  120 DAYS FROM THE DATE OF

OPENING OF THE TENDER.

5 SECURITY DEPOSIT  5% OF SANCTIONED TENDER AMOUNT

IN FORM OF CASH / DEMAND DRAFT /

BANK GUARANTEE.

6 RETENTION MONEY  2% FROM EACH RUNNING BILL WILL BE

RETAINED AND WILL BE RELEASED

AT THE TIME OF FINAL BILL

7 TIME ALLOWED FOR

COMPLETION OF THE WORK  12 Months

FROM THE DATE OF WRITTEN

ORDER TO COMMENCE WORK

8 TENDER FEE Rs. --  ₹ 1500 TENDER CLASS -- E1

In DEMAND DRAFT / PAY ORDER FROM

BANK ACCEPTABLE TO THE AMC

Contractor's Name :-

Contractor's Address :-

Contractor's Register Number / Renewal Year / class :-

Contractor's Bank, Branch Name :-

Bank Account Number :- Banks MICR Number-

8 DOWN LOAD DATES FOR

TENDER FROM WEB SITE  ------ TO --------

9 DATE ON OR BEFORE WHICH

THE TENDER MUST REACH

THE OFFICE  29-Apr-26 6.00 PM

10 OPENING DATE OF THE

TENDER BY THE OFFICE  30-Apr-26 5.00 PM

11 LOCAL COMPETITIVE BIDDING

-- TENDER CLASS -- E1

12 MODE OF SENDING THE   IN SEALED COVER BY REGISTERED

TENDER POST OR IN PERSON.

 TENDER SENT BY ORDINARY POST

WILL BE REJECTED OUTRIGHT.

 CONDITIONAL TENDER WILL BE

REJECTED OUTRIGHT.

13 DESCRIPTION ESSENTIAL TO   NAME OF THE WORK.

BE MADE ON SEALED COVER TENDER No.--

 DATE OF RECEIVING TENDER BY

14 MODE OF QUOTING RATES IN   PERCENTAGE RATE IN FIGURES AS

SCHEDULES OF RATES.  WELL AS IN WORDS.

  TENDER SHALL BE SUBMITTED IN

DUPLICATE.(EXCEPT E-TEDER)

NAME OF WORK --

Construction of New R.C.C road and New interlocking paver block work

MP/MLA AND COUN.BUDGET at different society and chali area in

Viratnagar ward in East Zone (ARC)

E TENDER NOTICE No. -- 33 TENDER No. --

LOCAL COMPETITIVE BIDDING -- TENDER CLASS -- E1

Time Limit (Months)

Issue Date ------ Last Date of 29-Apr-26 Opening 30-Apr-26

ofT ender --- -------- Receiving of 6.00 PM Date of 5.00 PM

From - To Tender --- Tender-

The Municipal Commissioner of Ahmedabad Municipal Corporation, invites Percentage

rate tender for the above works from the contractors registered with Municipal

Corporation of Ahmedabad in Class E1 or registered with Government of Gujarat

in Class E1 or from contractors registered in similar class with any other

State Government of India who have the financial capability and technical ability to

carry out the work. Also Private pre qualified reputed experience builders can also

apply. Experience in carrying out works of comparable nature is essential.

Filled up tender shall be received by Asst. Manager, East Zone Zonal Office,

Ahmedabad Municipal Corporation, Harubhai Maheta Bhavan, Viratnagar Char Rasta,

Nikol, Ahmedabad - 382415 on or before last date of receiving tender with Tender Fee

and E.M.D.as per information in memorandum above.

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

SPECIAL GENERAL INSTRUCTIONS TO TENDERERS

NAME OF WORK --

Construction of New R.C.C road and New interlocking paver block work

MP/MLA AND COUN.BUDGET at different society and chali area in

Viratnagar ward in East Zone (ARC)

1 The work is to be completed in all respects within 12 months reckoned

from the date of written order to commence the work.

2 The tender shall be valid for acceptance for a period of 120 days from the date of

opening of tenders.

3 Each tender must be accompanied by a receipt for a deposit as Earnest Money

of ₹ 30260.00 in Pay order, Demand Draft, Bank Guarantee or Cheque from

bank acceptable to the AMC.

4 Tender deposit is accepted as detailed out in Ahmedabad Municipal Corporation,

Section B-1, Engineering Department, percentage Rate Tender and General condition's of

Contract for Works here in afterwards referred as Form- B-1.

5 An overall schedule of the "Work Plan "of the project based "Network Technique Method"

Programmer Evaluated and Review Technique (PERT) / Critical Path Method (CPM) for

appreciating his method of planning, scheduling and control of project execution

should be submitted by the contractor.

6 After the demand of R.A. Bills by contractors, work shall be verified by the Engineer in

charge of AMC or the Architect / Consultant will give his certificate, whether the work has

been executed according to the standard norms and approved designs and the

workmanship is of acceptable quality. Also the progress of work shall be according to

the construction programme approved by AMC or the Architect /Consultant. On

recommandations of Engineer in charge of AMC or Architect / consultant , R.A. Bills will

processed for the payment.

7 2% FROM EACH RUNNING BILL WILL BE RETAINED AND SHALL BE RELEASED

AT TIME OF FINAL BILL

8 In the circumstances of dispute, the decision of Add. City Engineer ( Zones) shall

be final & bound for the contractor. In case, in the detailed specifications of materials

and code of practice specifications of Index Nos. are found missing thus they must be

referred to the of specification of materials and code of practice.

PAYMENT CONDITIONS TO CONTRACTOR

9 Without proper Refilling, compaction and watering no payment shall be given to

contractor for excavation, refilling and or earth filling items.

10 Contractor shall have to submit a demand letter for running bill as well as final bill..

11 If progress of work is not in proportion to the time limit, otherwise penalty will be imposed.

MATERIAL PROCUREMENT

12 All material like Cement, M. S. Bars / Tor steel reinforcement and structural steel,

Bitumen etc. required for this work shall be procured by the contractor from the open

13 No difference in rates of cement and steel prevailing in the market in Ahmedabad at a

later date shall be paid /Recovered by A.M.C.(as the case may be) to / from contractor for

the procurement of Cement and Steel from open market in Ahmedabad. Contractor will

not be paid for any transport, handling & storage expenses separately and he

should quote for the works accordingly.

14 Test certificate for all materials like Cement , Steel, Bitumen and other important

materials shall be obtained and submitted by contractor. Contractor shall have to

produce test certificates for all procurement of Cement , Steel, Bitumen and other

important materials

INSTRUCTION TO THE TENDERER

15 ALL INSTRUCTIONS TO TENDERERS, SPECIAL INSTRUCTIONS FOR

CONTRACTORS, DOCUMENTS, RULES FOR GRANT OF ADVANCES, CLAUSE

FOR ARBITRATION, GENERAL SPECIFICATIONS, PROJECT INFORMATION

GENERAL,PAYMENT CONDITION TO THE CONTRACTOR, DEFINITION OF TERMS

EARNEST MONEY, SUBMISSION OF TENDERS, GENERAL RULES AND

DIRECTIONS FOR THE GUIDANCE OF CONTRACTORS TERMS AND

CONDITIONS OF CONTRACT AS PER FORM B-1. ETC. SHALL BE AS PER

STANDARD PERFORMA OF AHMEDABAD MUNICIPAL CORPORATION OF

ENGINEERING DEPARTMENT AND SHALL BE APPLIED TO THIS TENDER

CONTRACTOR MUST HAVE THIS DOCUMENT AND SHALL BOUND FOR THE

I HAVE READ AND VERIFIED ABOVE DOCUMENT AS WELL AS P.W.D.

GENERALTECHNICAL SPECIFICATIONS , CONDITIONS, CLAUSES,

INSTRUCTIONS ETC. AND AGREE TO ABIDE BY THEM.

I HAVE ALSO GONE THROUGH CONDITIONS AND CLAUSES OF FORM B -1

AND AGREE TO ABIDE BY THEM.

I HAVE ALSO GONE THROUGH TECHNICAL SPECIFICATIONS FOR THE

ITEMS AND AGREE TO ABIDE BY THEM.

IN THIS TENDER THERE ARE MANY POSSIBILITIES OF ADDITIONAL AND

ALTERATION ITEMS HENCE MANY ITEMS ARE LIKELY TO BE DROPPED OR

THERE QUANTITIES ARE LIKELY TO BE VARY UP TO ANY EXTENT AND

HENCE FOR THIS CONTRACTOR WILL NOT CLIAM FOR ANY EXTRA

AMOUNT OR COMPENSATION FOR THE SAME I AGREE TO ABIDE BY THEM.

GENERAL RULES & DIRECTIONS FOR THE GUIDANCE OF CONTRACTORS

TERMS AND CONDITIONS OF CONTRACT AS PER FORM B-1. ETC. SHALL BE AS

PER STANDARD PROFORMA FOR TENDER OF AHMEDABAD MUNICIPAL

CORPORATION OF ENGINEERING DEPARTMENT AND SHALL BE APPLIED TO

THIS TENDER . CONTRACTOR MUST HAVE THIS DOCUMENT.

Dated Signature Of Contractor ADD. CITY ENGINEER

With Seal EAST ZONE

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

16 DECLARATION FORM :- TENDER No

Name of the work for which the Tender is under consideration-

Construction of New R.C.C road and New interlocking paver block work

MP/MLA AND COUN.BUDGET at different society and chali area in

Viratnagar ward in East Zone (ARC)

1 I / We hereby declare that I / We have visited the above site & fully acquainted my self /

our selves with the local situation regarding materials, labour and other factors pertaining

to the work before submitting this tender.

2 I / We hereby declare that I / We have carefully studied the conditions of contract,

sections and other tender documents of this work and agree to execute the same

3 I / We hereby declare that I / We shall not charge any costs towards the visit of site for

preparing the tender for submission accordingly.

4 I / We hereby declare that My / Our near relatives are not working in A.M.C. as City

Engineer, Add. City Engineer, Dy. City Engineer, Asst. City Engineer, Assistant

Engineer, Add. Assistant Engineer, Technical Supervisor, Assistant Manager,

Accountant, Store Keeper or any such category. If yes, then, the names should be

Dated Signature Of Contractor

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

GENERAL SPECIFICATION

1 The work shall be completed with in 12 months time limit.

2 The details of reinforcement of R.C.C. work shall be as per design and instruction of

Add. City Engineer or his representative and his order will be considered final. The

contractor shall have to maintain account of steel, cement and other materials, that may

be brought by him on site. This account shall be regularly maintained and kept open for

inspection by municipal staff. Watering of all the items shall be done as per

instructions. Mixing of concrete shall be done by concrete mixer machine.

3 Arrangements of bringing vibrator for R.C.C. works if required shall have to be made by

the contractor othervise concrete work shall not be allowed.

4 The contractor shall remain responsible for workman's compensation of any accident that

may occur. The contractor shall arrange for lights at night and fencing and security

guard and shall be responsible for any damage of life and property if any happen, during

the execution of work in case of dispute for unseen or over looked items, the decision of

the Add. City Engineer or his representative shall be final. The contractor shall have to

clean all rubbish on completion of work and hand over the building with final finishing

as directed. All the rejected materials shall be removed from site with in 24 hours by

contractor at his risk and cost.

5 For mixing mortar either for masonry or for plaster; or for any other purpose contractor

shall have to prepare trough of bigger size and mix the mortar in the required

proportion in case he shall be allowed to mix the mortar either on solid floor or any

finish surfaces.

6 The contractor shall have to make his own arrangement for water required for the work

7 If any extra item crops up during the progress of work, the same shall be carried out by

the contractor and he shall be paid at the rate fixed by Add. City Engineer or his

representative as per the rate analysis based on current market rates and as per

prevailing circular of AMC..

8 If in the interest of the Corporation it is necessary to change either any site or the design

of the proposed work, the contractor shall carry out the same at his quoted rates without

charging any extra and the contractor will have to carry out the works and he will be paid

at the rates quoted by him in the tender and no claim for extra charges entertained.

9 The cubical contents of the cement bag shall be taken as 1.25 cft. or 0.035 cmt. / bag

and the contractor shall have to prepare the measure box according to this measures.

10 Retention money at the rate of 2% shall be deducted from every running bill of the

contractor and which will be paid at the time of final bill.

11 Contractor will be fully responsible for compliance of the various provision under

contract Act. 1970 and rules framed there under.

12 The tender for the work shall remain valid for a period of 120 days from the date of

opening of the tenders for this work and that the Tenderer shall not be allowed to

withdraw or modify the offer on his own during this period. If any Tenderer withdraws or

makes any, modifications or additions in the terms and conditions of tender. His tender

will not be acceptable to the Municipal Corporation. The Municipal Corporation

,without prejudice to any right or remedy be at liberty to forfeit the Earnest Money

13 No Materials shall be supplied by A.M.C. The contractor have to make their own

arrangement for procurement of materials from open market. But the contractor

shall have to give necessary test certificates for different materials as per relevant

I.S. code before using the same in the work at his cost in presence of AMC Engineers..

14 As per circular No MGR 2176(96),2418 (ii)GHH dated 31-3-77 issued by Government of

Gujarat contractors are requested to procure their quarry materials required for

construction work through legal sources i.e. Only from the quarry lease. holders permit

holder or middleman who satisfies the contractor as the legality of the source of

purchase by him on these materials.

15 If the work is not carried out within the specified time limit

12 months from the date

order to start the work. Penalty shall be recovered at the rate of 10% on the amount

of the non completion of the remaining work for delay in allotted,/ extended time limit

and shall be recovered from the immediate bills payable to the Contractor.

16 The contractor shall have to take labour License of the work as per Labour act.

The contractor shall have to follow Child Labour act. The Tenders are to be

submitted in duplicate except E-Tender without which the tenders are liable to be

rejected. Conditional tender will not be accepted.

Dated Signature Of Contractor ADD. CITY ENGINEER

With Seal EAST ZONE

TECHNICAL SPECIFICATIONS FOR MATERIALS AND ITEMS

NAME OF WORK -- Tender No.

Construction of New R.C.C road and New interlocking paver block work

MP/MLA AND COUN.BUDGET at different society and chali area in

Viratnagar ward in East Zone (ARC)

GENERAL AND STANDARD TECHNICAL SPECIFICATIONS FOR WORK.

1 In the specifications “as directed” / “ approved shall be taken to means "'directed” /

“approved” by the Engineer-in-charge.

2 Wherever a reference to any Indian Standard appears in the specifications, it shall be

taken to mean as a reference to the latest edition of the same inforce on the date of

3 In“Mode of Measurement”in the specification wherever a dispute arises in the absence of

specific mention of a particular point or aspect, the provisions on these particular

points or aspects in the relevant Indian Standards shall be referred to.

4 All measurements and computations, unless otherwise specified, shall be carried out

nearest to the following limits:

(i) Length, width and depth (height) 0.01 meter.

(ii) Areas 0.01 Sq. Mt.

(iii) Cubic Contents 0.01 Cu. Mt.

In recording dimensions of work, the sequence of length, width, and height (depth) or

thickness shall be followed.

5 The distance which constitutes lead shall be determined along the shortest practical

route and note necessarily the route actually taken. The decision of the

Engineer-in-charge in this regard shall be taken as final.

6 Where no lead is specific, it shall mean “all leads".

7 Lift shall be measured from plinth level.

8 Up to “floor two level” means actual height of floor (Maxi. 4 M) up to 3 Mt. Above plinth

9 Definite particulars covered in the items of work, though not mentioned or included in it

specifications shall be deemed to be included therein.

10 Reference to specifications of Materials as made in the detailed specification of the

items of works is in the form of a designation containing them number of the

specification of the Materials and prefix „M‟ e.g. "M-5"

11 Approval to the samples of various Materials given by the Engineer in charge shall not

absolve the contractor from the responsibility of replacing defective Materials brought on

site or Materials used in the work found defective at later date. The contractor shall

have no claim to any payment or compensation whatsoever on accounts any such

Materials being rejected by the Engineer-in-charge.

12 The contract rate of the item of work shall be for the work completed in all aspects.

13 No collection of Materials shall be made on site before it is got approved from

the Engineer-in-charge.

14 Collection of approved Materials shall be done at site of work in a systematic manner.

Materials shall be stored in such manner as to prevent damage ,deterioration of

intrusion of foreign matter and to ensure the preservation of their quality and fitness for

15 Materials , if

and when rejected by the Engineer - in - charge, shall be immediately

removed from the site of work.

16 No Materials shall be stored prior to, during and after execution of a structure in such a

way as to cause or lead to damage or overloading of the various components of the

17 All works shall be carried out in a workman like manner as per the best techniques for

the particular item.

18 All tools, templates, machinery and equipment for correct execution of the work as well

as for checking lines, levels, alignment of the work during execution shall kept in

sufficient numbers and in good working condition on the site of the work.

19 The mode, procedure and manner of execution shall be such that it does not cause

damage or overloading of the various components of the structure during execution or

after completion of the structure.

20 Special modes of construction not adopted in general Engineering practice, if

proposed to be adopted by the Contractor, shall be considered only if the contractor

provides satisfactory evidence that such special mode of construction is safe, sound

and helps in speedy construction and completion of work to the required strength and

quality. Acceptance of the same by the Engineer- in- charge shall not, however, absolve

the contractor of the responsibility of any adverse effects and consequence of adopting

here in the course of execution or completion of the work.

21 All installations pertaining to water supply and fixtures thereof as

well as drainage lines

and sanitary fittings shall be deemed to be completed only after giving satisfactory tests

by the contractor.

22 The contractor shallbe responsible for observing the rules and regulations imposed

under the “ Minor Minerals Act ”, and such other laws and rules prescribed by

Government from time to time.

23 All necessary safety measures and precautions (including those laid down in the

various relevant Indian Standards) shall be taken to ensure the safety of men, Materials

and machinery on the works as also of the work itself.

24 The testing charges of all Materials shall be borne by the Contractor.

25 Approval to any of the executed items for the work does not in any way relieve the

contractor of his responsibility for the correctness, soundness and strength of the

structure as per the drawings and specifications.

26 I HAVE ALSOGONE THROUGH TECHNICAL SPECIFICATION FOR THE ITEMS AS

PER STANDARD P.W.D. TECHNICAL SPECIFICATION FOR THE ITEMS AND

AGREE TO ABIDE BY THEM. (ALSO AVAILABLE ON AMC WEB SITE)

27 IN CASE OF WHERE THERE IS NO TECHNICAL SPECIFICATION FOR THE ANY

ITEMS AVAILABLE, SPECIFICATION GIVEN BY THE ENGINEER IN CHARGE

SHALL BE FOLLOWED. AND FOR THE SAME I AGREE TO ABIDE BY THEM.

Dated Signature Of Contractor ADD. CITY ENGINEER

With Seal EAST ZONE

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

SUMMARY OF COST AND

SCHEDULE OF QUANTITIES AND RATES

_ SUMMARY OF COST AND RECAPITULATION SHEET

_ SCHEDULE OF QUANTITIES & RATES

PAGE -- 1 of 2 SHEDULE

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

1 The schedule of quantities and rates are to be read for the purpose of pricing in

conjunction with instructions to tenderers, technical specifications, drawings and

general conditions of contract for civil works.

2 The Price quoted in the summary of costs; sheet of schedule of quantities and rates

shall be in all inclusive value for the work described including all costs and expenses

which may be required in and for the execution of the work described together with all

general risks, liabilities and obligations set forth or implied in the document on which

the tender is based.

3 The quantities furnished are approximate. In the event of actual quantities varying from

those furnished herein below or items deleted or added, the Rates quoted for the entire

work shall remain firm and no extra claims in this respect will be entertained. The

payment shall be made based on the actual quantities in the completed work.

4 All works shall be carried out strictly as per detailed specifications whether actually

specified or not. If not specified, as per directions of Engineer in charge

5 Rates quoted by Tenderer shall be firm even if the contract is split. If tenderer does not

agree to keep his quoted Rates valid under such a condition he shall clearly state so in his

6 Rates and the total amount entered in the summary of cost sheet of schedule of

6 Rates and the total amount entered in the summary of cost sheet of schedule of

quantities and rates shall be written in ink and shall be entered both in figures and

7 If Tenderer need any clarifications, they should obtain the same in writing from

owner/ Engineer. No notice will be taken of any verbal discussion in such matter.

1 Rate and amount shall be written both in figures and words.

2 Refer Schedule of quantities for items of Works & Estimated Quantities.

3 Plans are available with Asst. City Engineer. Tenderers are instructed to see

them during office hours in his office before quoting tender.

PAGE -- 2 of 2 SHEDULE

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

GENERAL TENDER CONDITIONS

1 After sanctioning of tender, a work order will be issued to the contractor. In response

contractor shall have to arrange for Security Deposit within 10 days for works up to

lacks of tender amount and 15 days for works above 10 lacks of tender amount. The time

limit shall be counted after 10 days for works up to 10 lacks of tender amount and 15 days

for works above 10 lacks of tender amount after issuance of work order. The contractor

shall be fined 4% of interest per year for delay in submission of S.D. and shall be

deducted from contractor‟s bill. Security Deposit of 5% of sanctioned tender amount shall

be deposited by pay order / demand draft / cheque or Bank Guarntee of nationalized

bank/scheduled bank only. Contractor shall have to sign contract paper with AMC.

2 In case of earnest money cheque bounce back, contractor‟s tender shall treated as

cancelled and the contractor shall not be given any tender, offer, quotation work in AMC

3 Muni. Commissioner shall have right to accept, reject the tender as well as the rate at

which tender to be accepted and awarded.

4 Specification of tender items shall be as per PWD manual in general / AMC‟s norms and

B-1 form conditions shall be applicable. In case of controversy, Addl.C.E.‟s decision shall

5 If watering is not done as per norms/specifications or if debris is not removed within

hours, then without notice, AMC shall have a right to execute that work at contractor‟s risk

and the amount shall be recovered from the bill.

6 Contractor shall have to work in such a system that there shall be no damage to any

service line of electric, telephone, gas, any type of service cable, drainage or water lines

etc. In case of damage to service line, the contractor will be responsible for damage and

shall have to repair/reinstate the damaged existing services. The contractor shall have to

safe guard the labours against any accident or damage of lives or public property if any..

In case of police complain, Contractor shall be held responsible for negligence. In case of

soil/land collapse, contractor shall be held responsible for not supporting the soil with

shoring, strutting and shuttering. Contractor shall safeguard the labour before allowing

labour to enter in excavated pit or other hazardous site. In case of accident to labours,

contractor shall be held responsible for police complain against him. AMC‟s staff will not

be responsible for any accident at the site of the work.

7 Contractor shall take insurance of his all labour and supervisory staff.

8 Only registered contractor shall quote the tender, if the contractor is registered with

government then they shall have to apply for registration in AMC within 180 days from the

date of work order.

9 AMC‟s general condition and Form-B-1 shall be binding to the contractor B-1 Form is put

up on AMC‟s web site.

10 Payment of running bill, final bill shall be as per policy of AMC in force at time of payment.

11 Any time of litigation shall be in court of Ahmedabad city jurisdiction only.

12 As per site conditions/requirement of site, there shall be increase or decrease in tender

item quantities. In such case contractor shall not have right to any price rise. In case of

decrease in any tender item quantity, contractor shall not ask for compensation.

13 If any construction material brought to site by contractor is not as per specification, or any

inferior quality material brought to site, then such rejected material shall be removed from

the site within 24 hours, otherwise AMC can throw away such material at any place and

recover the amount for such removal work from contractor bill. In this case contractor shall

not be entitled for compensation.

14 Cost of testing of material shall be borne by the contractor. He shall provide vehicle for

taking material / staff from site to testing laboratory / manufacturing site and contractor

shall be bear the cost of transportation of staff and material.

15 Contractor shall work as per labour Act. Contractor shall not be given any payment if

labour act rules are not followed or insurance of labour is not taken for work.

16 Contractor shall deposit the material on site in such a way that it should not become

obstruction to any one in any way.

17 All type of taxes(e.g. sales tax, surcharge, vat etc) to be borne by the contractor.

18 If asked by AMC Engineering staff, contractor shall take photograph of site of work /

before start of work, during work and after the completion of work, with digital camera and

deposit to AMC office or transfer photograph from camera to AMC computer. No

additional cost shall be paid.

19 In case of cancellation / rejection of tender, contractor shall not be entitled for any

compensation or right.

20 In case of extra item, AMC circular no. 9 Dt.08.05.12 shall be follwed in general If item is

not available in SOR, then market rate shall be derived by the Eng. dept by rate analysis.

Contractor shall not ask for the rates as per his rate analysis. This should be clearly

understood and taken in to consideration while quoting the tender by the contractor.

21 During execution of work, contractor shall take safely measures like protection by ropes,

drums, danger sign boards, plastic strips, bamboos, wooden poles etc as per requirement

& instruction of Egg.- in –charge. In case of accident due to lack of protection, contractor

shall responsible for police complains, compensation etc AMC staff shall not be held

responsible for contractor‟s negligence.

22 If instructed by AMC officials, contractor shall have to keep daily progress register and

get it signed by Ass. City Engineer. Contractor shall maintain record of daily No.of labours

employed, work done. If rectification work is not done by contractor within 24 days, the

contractor shall be finned Rs.250/- per day for delay & shall be recovered from the

contractors bill.

23 Contractor shall not be entitled for any type of compensation or right for the cancellation

of tender or tender items by any means.

24 Deduction from bills shall be done as per rules prevailing or the rules which shall come in

to force, by State or Central Govt.

25 1% amount shall be deducted for labour welfare fund as per state Govt. order.

26 All the above conditions shall over rule the conditions given in Form B-1.

27 Specifications are placed on AMC website www.egovamc.com for tender items, PWD

manuals should be followed in general.

28 Contractor shall have to register the work as per labour act & as per building safely act,

1906 with, Dy.Director building safety act., Shram Bhavan, 5th floor labour commissioner

office, Khanpur, Ahmedabad.

29 In case, at the time of submitting tender copy in duplicate, if single copy of tender bid is

quoted by contractor then it shall be treated as cancelled at the time of opening ( except

30 At the time quoting tender, if tender fee or EMD is not deposited then tender shall be

treated as cancelled at the time of opening of tender.

31 In case of the bank detail are not given then EMD return procedure shall be delayed.

32 In case of water pipe line work, If materials are not available from AMC central stores,

then the time limit delay of providing materials by central stored shall be given to the

33 In case of road grouting work tender, if at the time of resurfacing paver work, If paver gets

stucked in grouting work then contractor shall have to rectify the poor grouting work

without any cost.

34 Before quoting the tender contractor should know that, he has seen the site understood

the item of works, site conditions. He should be in a positions to provide labours at the

time of festivals like Holi, Diwali, Navratri, Marriage season, rainy season or any other

time of the year Contractor cannot say that he has no labours due to festivals.

35 Running bill amount should be restricted to 90% sanctioned tender amount and remaining

10% amount shall be paid in final bill after completion of work..

I have read all above conditions carefully and ready to work as per above conditions.

Contractor’s Name and seal Add. City Engineer

Mobile No. EAST ZONE

Address Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

Construction of New R.C.C road and New interlocking paver block work MP/MLA AND

COUN.BUDGET at different society and chali area in Viratnagar ward in East Zone

vwJoÍtullt rJhtxldh Jtuzobtk yub.ve./ yub.yuj.yu./ <&t ftWLmejh©elt Vt¤Juj csux btk&e sw>e sw>e atjeytu <&t

mtumtgxeytubt yth.me.me htuz <ubs vuJh çjtuf jdtzJtlltk ftb ctc<. (Jtr»tof xuLzh)

RECAPITULATION SHEET Months

Sr.No DESCRIPTION AMOUNT

MAIN ESTIMATED TENDER COST

C.F. THIS TOTAL FROM TENDER#########

AMOUNT ( A )#########

(1) WRITE HOW MUCH PERCENTAGE HIGHER

OR LOWER IN FIGURES _______________ % LOWER / HIGHER

(Strikeout which ever is not applicable)

(2) WRITE HOW MUCH PERCENTAGE HIGHER or LOWER IN WORDS -

PERCENT LOWER/HIGHER

(Strikeout which ever is not applicable)

(3) AMOUNT ( B ) IN ₹.

IF PERCENTAGES QUOTED IS HIGHER THAN ADD AND SUM IT. ( i.e. C=A+B)

OR IF PERCENTAGES QUOTED IS LOWER THAN DEDUCT AND SUBSTRATE IT.

(4) WRITE TOTAL TENDER AMOUNT IN WORDS - ₹

Dated Signature Of Contractor ADD. CITY ENGINEER

With Seal EAST ZONE

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPPARTMENT

Name of Construction of New R.C.C road and New interlocking paver block work MP/MLA AND

Work :- COUN.BUDGET at different society and chali area in Viratnagar ward in East Zone (ARC)

vwJoÍtullt rJhtxldh Jtuzobtk yub.ve./ yub.yuj.yu./ <&t ftWLmejh©elt Vt¤Juj csux btk&e sw>e sw>e atjeytu <&t

mtumtgxeytubt yth.me.me htuz <ubs vuJh çjtuf jdtzJtlltk ftb ctc<. (Jtr»tof xuLzh)

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

Box cutting the road surface to proper slope and

camber for making a base for road work including

removing the excavated stuff and depositing on the

road side slope as directed upto 200 Mt.lead

Conveyance charge of earth, lime, murrum, building

rubbish, manual garbage, sludge, excavated rock , fly

2 ash, aggregate of any kind etc complete up to 10.0 KM 0.00

a) Lead up to 1 Km. 0.00 23.388 Cu.M

b) Lead From 1Km to 2 Km. 0.00 30.94 Cu.M

c) Lead From 2 Km to 3 Km. 0.00 38.37 Cu.M

d) Lead From 3 Km to 4 Km. 0.00 45.52 Cu.M

e) Lead From 4 Km to 5 Km. 0.00 52.42 Cu.M

f) Lead From 5 Km to 10 Km. 540.00 78.54 Cu.M

g) Lead From 10 Km to 15 Km. 0.00 104.65 Cu.M

Providing and laying Cement Concrete 1:3:6 (1-

3 Cement : 3-Coarse sand : 6-Hand broken stone 105.00 2339.59 Cu.M

aggregates 40mm nominal size) and curing complete

Providing and laying in position Ready Mixed M-200

grade concrete for reinforced cement conctere work,

using cement content as per approved Design Mix

manufactured in fully automatic batching plant and

transported to site of work in transit mixer for a lead up

to 10 kms having continuous agitated mixer,

manufactured as per mix design of specified grade for

reinforced cement concrete work including pumping of

R.M.C. from transit mixer to site of laying, excluding

the cost of centering shuttering finishing and 225.00 3980.17 Cu.M

reinforcement including cost of admixtures in

recommended proportions as per IS: 9103 to

accelerate/retard setting of concrete, improve

workability without impairing strength and durability as

per direction of the Engineer - in - charge. Without Fly

Ash (Min cement level as per latest IS 456 shall be

maintained) (Item Code : 5055, SOR 2021-22, R & B

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

Providing Formwork of ordinary timber planking so as

to give a rough finish including centering shuttering

strutting and propping etc. Height of propping and

centering below supporting floor to ceiling not

5 exceeding 4 M. and removal of the same for in situ 165.00 99.79 smt

reinforced concrete and plain concrete work in.

(A)Foundations Footings Bases of Columns etc. and

Mass concrete. (Item Code : 09001AA, SOR 2021-22,

R & B Ahmedabad City

Providing TMT Bar FE500D reinforcement for

R.C.C. Work including bending,binding and placing in

6 position complete upto floor two level. (As Per Road 5100.00 63.1 kg

P/A Tremix with dewartering machine and floater

machine on constructed CC work for finishing the

surface as per requirement. The rate including all

7 machinaries, labor, loading, unloading, transportaion 1200.00 54 smt

etc complete as per direction given by engineer in

Making 15 mm. Groove in RCC work on road & filling it

8 with polysulfied selant & finished ot good incl. all labour 165.00 30 Rmt

charges etc. comp.as directed.

Repairing damaged M.H. and rasing M.H. up to road

level incl. removing damaged brick work and repairing

by brick masonry in C.M. 1:5 and plaster in C.M. 1:3

9 and fixing C.I. steps and existing MH sheet cover, 0.00

removing the debris from MH and carting the same as

(A) up to 0.15 mt. (@ Two Coarse) 15.00 728.82 No

(B) up to 0.35mt. (@ Four Coarse) 15.00 1155.44 No

(C) up to 0.65 mt. (@ Seven Coarse) 15.00 1786.49 No

Providing F.R.C. MH seat cover incl. carting to the

work site etc. comp.Directed.

F.R.C. Extra Heavy Duty (EHD-35) Manhole Covers &

Frames Cover : 728mm ø & 100 mm thick circular

cover, 35.00 MT load design, 100x2mm MS flat

allround, 16mm ø plain round bar for lifting the cover &

should be fitted with plastic cups. Frame : 560 mm ø

a clear opening, outer size- 888x888x175 mm. On the 3.00 3354.74 SET

upper periphery of frame 25 x 3 mm wide MS flat

should be well embed in concrete to protect the edges

of frame. FRC E.H.D.-35 manhole cover & frame

F.R.C. Heavy Duty [HD-20] Machinehole Covers -

mm ø clear opening, The dimension of frame and

b cover as per mentioned in Amend No.1 to IS 12592 : 15.00 1720.44 SET

F.R.C. Medium Duty [MD-10] Machinehole Covers -

560mm ø clear opening, The dimension of frame and

c cover as per mentioned in Amend No.1 to IS 12592 : 0.00 1255.52 SET

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

F.R.C. Medium Duty [MD-10] Chamber Covers &

Frame- 600 x 450 mm clear opening, The dimension

d of frame and cover as per mentioned in 3.00 2254.98 SET

Amend No.1 to IS 12592 : 2002 table

F.R.C. Light Duty [LD-2.5] Machinehole Covers &

Frames-560mm ø clear opening, The dimension of

e frame and cover as per mentioned in Amend 3.00 1915.14 SET

No.1 to IS 12592 : 2002 table

CatchPit Jali (Heavy duty) Fixing P/F FRC catch pit jali

with frame 600mm x 600mm clear opening etc. comp..

As directed by engineer in charge.

Providing and fixing S.W. Gully Trap with C.I. Grating

brick masonry chamber and water tightC.I. cover with

frame of 300mm x 300mm size(inside) with standard

12 weight.(i) Square mouth traps. (A) 100mm x 100mm 15.00 1127.81 No

size P type. (SOR 2021-22 Item no-24.19 page no-

Leveling or orientation of existing Gully Trap chamber

incl.nece. masonry in CM (1:6) and plaster in CM (1:3)

13 etc. using old GT stone and cover etc.comp 15.00 71.43 No

Extra rate over item of excavation of earth for

excavation of asphalt pavement / RCC of thickness up

to 0.20 meter including demolishing the asphalt carpet,

14 metal,s oiling/cutting Reinforcement etc.comp. with 0.00

stacking the material as directed. (Based on Previously

approved rate by C E sir )

0.20 meter thickness 15.00 71.1 smt

Providing & Supplying JCB Machine on rental basis in

case of emergency situation and break down type

work & also during unavoidable condition as per

instruction of engg. in charge, rate includes all nece.

shifting, fuel and operating charges and stacking of

useful & non-useful materials separately up to store.

(No payment should be allowed for non working

condition of machinery and for pipe line excavation

and laying work)

Estimate- B ( Paver Block)

Box cutting the road surface to proper slope and

camber for making a base for road work including

removing the excavated stuff and depositing on the

road side slope as directed upto 200 Mt.lead

Conveyance charge of earth, lime, murrum, building

rubbish, manual garbage, sludge, excavated rock , fly

2 ash, aggregate of any kind etc complete up to 10.0 KM 0.00

a) Lead up to 1 Km. 0.00 23.388 Cu.M

b) Lead From 1Km to 2 Km. 0.00 30.94 Cu.M

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

c) Lead From 2 Km to 3 Km. 0.00 38.37 Cu.M

d) Lead From 3 Km to 4 Km. 0.00 45.52 Cu.M

e) Lead From 4 Km to 5 Km. 0.00 52.42 Cu.M

f) Lead From 5 Km to 10 Km. 0.00 78.54 Cu.M

g) Lead From 10 Km to 15 Km. 450.00 104.65 Cu.M

Providing and laying Cement Concrete 1:5:10 (1-

Cement : 5-Fine Sand : 10-Graded Brick Bat

3 Aggregates 40 mm Nominal Size) and curing 144.00 1901.59 Cu.M

Providing and Laying of Rubber Moulded Paver Block

Grey/Coloured 60 mm thick, M-35 Grade of any

size;shape (Usually Uni-Paver Blocks) using black trap

good quality aggragate of 20 mm nominal size for

footpath, parking areas, service lanes and other areas

as mentioned in the drawing/instruction of engineer in

charge. Cost includes formworks using rubber mould,

Rate providing and laying paver blocks as per required

grading and specification. The paver block shall be

mechanically compacted. The work of paving blocks

shall be executed in line and level by skill mason of 1425.00 501.6 smt

flooring work only. It should be laid in such a way that

the no cutting of the paver block to be necessary. if

cutting of paver block necessary then it should be cut

by machine only and carting. The finished surface of

the paver block shall have resonably good, plain

finished. Paver blocks shall be compacted and shall be

relaid if necessary. Gravel or such type of materials

shall not be allowed for production. Laying on 5cms

thick sand beddding

Providing, supplying and fixing pre cast C.C. blocks (M-

20) edge kerb having size of 75 x 300 x 300 mm depth

and as per design conveying it to the site, jointing into

C:M 1:3 and racking out the joints incl. necessary 150.00 195.54 Rmt

asphalt, soil etc. completed. ( App Rate )

Extra rate over item of excavation of earth for

excavation of asphalt pavement / RCC of thickness up

to 0.20 meter including demolishing the asphalt carpet,

6 metal,s oiling/cutting Reinforcement etc.comp. with 0.00

stacking the material as directed. (Based on Previously

approved rate by C E sir )

a 0.20 meter thickness 30.00 71.1 smt

Repairing damaged M.H. and rasing M.H. up to road

level incl. removing damaged brick work and repairing

by brick masonry in C.M. 1:5 and

7 plaster in C.M. 1:3 and fixing C.I. steps and existing 0.00

MH sheet cover, removing the debris from MH and

carting the same as directed.

(A) up to 0.15 mt. (@ Two Coarse) 6.00 728.82 No

(B) up to 0.35mt. (@ Four Coarse) 6.00 1155.44 No.

(C) up to 0.65 mt. (@ Seven Coarse) 6.00 1786.49 No

Providing F.R.C. MH seat cover incl. carting to the

work site etc. comp.Directed.

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

F.R.C. Extra Heavy Duty (EHD-35) Manhole Covers &

Frames Cover : 728mm ø & 100 mm thick circular

cover, 35.00 MT load design, 100x2mm MS flat

allround, 16mm ø plain round bar for lifting the cover &

should be fitted with plastic cups. Frame : 560 mm ø

a clear opening, outer size- 888x888x175 mm. On the 3.00 3354.74 SET

upper periphery of frame 25 x 3 mm wide MS flat

should be well embed in concrete to protect theedges

of frame. FRC E.H.D.-35 manhole cover & frame

F.R.C. Heavy Duty [HD-20] Machinehole Covers -

mm ø clear opening, The dimension of frame and

b cover as per mentioned in Amend No.1 to IS 12592 : 15.00 1720.44 SET

F.R.C. Medium Duty [MD-10] Machinehole Covers -

560mm ø clear opening, The dimension of frame and

c cover as per mentioned in Amend No.1 to IS 12592 : 3.00 1255.52 SET

F.R.C. Medium Duty [MD-10] Chamber Covers &

Frame- 600 x 450 mm clear opening, The dimension

d of frame and cover as per mentioned in Amend No.1 3.00 2254.98 SET

to IS 12592 : 2002 table

F.R.C. Light Duty [LD-2.5] Machinehole Covers &

Frames-560mm ø clear opening, The dimension of

frame and cover as per mentioned in Amend

No.1 to IS 12592 : 2002 table

CatchPit Jali (Heavy duty) Fixing P/F FRC catch pit jali

with frame 600mm x 600mm clear opening etc. comp..

As directed by engineer in charge.

Providing and fixing S.W. Gully Trap with C.I. Grating

brick masonry chamber and water tightC.I. cover with

frame of 300mm x 300mm size(inside) with standard

10 weight.(i) Square mouth traps. (A) 100mm x 100mm 3.00 1127.81 No

size P type. (SOR 2021-22 Item no-24.19 page no-

Leveling or orientation of existing Gully Trap chamber

11 incl.nece. masonry in CM (1:6) and plaster in CM (1:3) 3.00 71.43 No

etc. using old GT stone and cover etc.comp

Sr.No. DESCRIPTION QTY. RATE PER AMOUNT

Supplying and fixing of 300 mm-L x 150 mm-B x

mm-H Kerb Block for Footpath in M-20 grade using

mm nominal size black trap aggregate of

Sevaliya/Timba or equivalent quality for pre-cast

blocks, reasonably exposed finish/ formwork , mould

with well equipped with vibratory system for kerb

stones of approved design including curing,

etc. complete, including the cost of formwork etc.

complete. The rate shall also include necessary cutting

of asphalt, fixing the Kerb stones in line and level on

12 cm thick sand bedding with necessary equipments and 45.00 350.89 Rmt

materials. The rate shall also include the flush pointing

in CM (1:3) for all joints of the kerbstones. Filling of

zari alone the sides of the kerb stone fixed with

Bituminous concrete mixed in proper position as

directed by Engineer in change to form a portable

mixture. In any case Gravel or such type of materials

shall not be allowed for production.

a)Laying on 5 cm thick Sand Bedding.

Filling available excavated earth (excluding

rock) in trenches, plinth, sides of foundations etc.

13 in layers not exceeding 20 cm. in depth 45.00 90.85 Cmt

consolidation each deposited layer by ramming and

Supplying and fixing Nimbhada ladi 37 to 50 mm thick for

walk-way, covering the activity of excavation, ramming,

Laying on sand bedding as per requirement to fix the

14 Nibhada Stone in Line & Level with cement pointing in 100.00 236.61 Smt

cement mortar 1:2 etc complete as directed. (AMC

approved SOR Rate Jan-2016)

P/L brickbats sand concrete (1:2) of one part of sand and

two part of old brickbats including spreading, laying,

15 ramming, watering and consolidation etc complete as 10.00 312.50 Cmt

(AMC approved SOR Rate Jan-2016)