Wanakbori Thermal Power Station

No. Reqd.

Supply (Part-A)

COMPLETE ASSEMBLY OF

ENERGY EFFICIENT LUBRICATED

ROTARY SCREW COMPRESSOR

Air COOLED FOR INSTRUMENT

1 5 Numbers

AIR & SERVICE AIR HAVING

MAXIMUM PRESSURE OF 8.0 BAR,

CFM 580 AT STAGE-1 UNITS

Works(Part-B)

Lump sum charges for Removal of

Existing K.G Khosla Reciprocating

2 comp.& installation of new Lubricated 5 Lumpsum

screw compressor stage-1 units,

Comprehensive Maintenance

3 contract( with spares ) for lubricated 2 Job

screw compressor of TMD-1 ,WTPS

Buyback(Part-C)

Cost of buy back for old removed

4 reciprocating air compressor as 5 Numbers

per scope of work.

(1) Order will be placed at submitted offered rate for SUPPLY (PART-A) + WORK (PART-B)

– (Minus) BUY-BACK after considering Terms and Conditions no. D of Annexure-A

(2) Applicable GST rate for buyback value will be borne by bidder.

(3) TCS (tax collected at source on buy back value) at the rate of 02 % (TWO percent) will be

borne by bidder.

(4) Offer for existing Buy-back old removed reciprocating air compressor shall be consider as

per quoted rate by party.

(5) The offered rates are excusive of GST and any other taxes and duties. Same shall be paid

extra. Which shall have force of law. However, amount of GST and applicable cess will be

kept under retention till submission of documentary proof of payment of GST or till reflection

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

of payment of GST pertain to respective bill amount in GST return for concern order after due

verification.

(6) Payment will be made as per actual work carried out only.

(7) Provision related to TDS on GST @ 2% shall be made applicable if value exceeds contract

threshold limit. (i.e. at present threshold limit Rs. 250000.00)

Details of statutory requirement:

GSECL PAN NO. AAACG6864F

GSECL GST NO. 24AAACG6864F1ZO

Your PAN No.______________

Your GST No. ______________

Annexure-A

Party shall to Supply and Installed an Energy Efficient lubricated Rotary screw air compressor, air

cooled at stage-1 units of Wanakbori TPS; GSECL.

Details of existing Air compressor of Unit No.1, 2 & 3 are as under:

Make : K. G. Khosla

Type : 2HA2QT – 2 cylinders non lubricated water cooled

Discharge : 16.4 M3/min at 658 RPM; CFM:

Working/Disch Pr. : 7.0/8.0 Kg / cm2

Receiver Tank : 02 No's in each Unit of 4.6 M3 capacity

Motor capacity : 90/110 KW, 1490 RPM, 172 Amp.

Total Installed Qty : 14 nos.

Party shall have to supply and installed the Lubricated screw compressor of Atlas capco,

ElGI, Kaeser compressors, KPCL, Ingersoll Rand or GSECL approved Make compressor suitable to

capacity of existing installed reciprocating compressor Mentioned above.

The brief specification of required compressor and technical terms and conditions are as

A. Technical specifications:

Sr. Description Description

Lubricated screw Lubricated screw compressor, Air cooled, minimum CFM:

compressor working pr. / max pr. 7.0 / 8.0 bar.

Make Make of Compressor: Atlas Copco/ELGI/Ingersol

Rand/Kirloskar/Kaeser compressors or GSECL approved make

Type Lubricated rotary Screw Type Air cooled.

Maximum pressure 8.0 bar

requirement

1 Free air delivery: 16.4 M3/min (580 CFM) or more

Total input power @ 7.00 bar Minimum as possible as (will be measure from given input

Cooling media Air cooled

Max. Air temp Up to 55 deg C

Useful Life of screw Minimum 30,000 working hours / 5 years

Noise level Noise level of offered package screw compressor should be as

per IS

Electrical motor Below 110 KW /150 HP, squirrel cage induction motor,(

2 Existing Motor specifications: 90/110 KW, RPM 1480)

suitable for operation on 415 V , 3 phase 50 HZ , AC supply

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

F/H class insulation with IP55 deg. of protection , other details

1. Voltage / Frequency: 415V+/-10% / 50Hz +/-5%

2. Ambient temp: 50 deg C

3. Electrical Motor: Star – delta starter

4. Class F OR H insulation

5. IE3 OR above efficiency

6. Material of Construction as per vendor standard

Motor make: ABB/Crompton Greaves Ltd. /Siemens only

Junction Box and control for instruments wiring from instruments to junction box, junction

/power panel box carbon steel, IP55

Instrument Cable Cables type shielded 2 pair, make poly bond, cables installed in

galvanized open grid cable tray

5 Level sensor/ Indicator cum Full Interlock Instruments as well as Local Indicators to be

Switch supplied

6 Pressure Transmitter

7 Pressure Indicator As per OEM standard

8 Flow Indicator

9 Temperature Switch Party shall have to submit tech. specification with T.B

10 Temperature Indicator

11 Filters As per OEM standard

13 Gear Drive Gear Train should be of highest transmission efficiency and

lowest noise level as per latest Std.

14 Oil carries over after filters Oil carry over after filters should not be more than 0.005 PPM

15 Cable /pipe line It should be required to match with existing system up to

mtr. approx.

B. The below-mentioned material shall be required for the erection & commissioning of

the lubricated screw air compressors. The quantity shall be as per site requirement.

The below-mentioned material shall be required for the erection & commissioning of the

lubricated rotary screw compressor packages. The quantity shall be as per site requirement.

Material required for providing piping connections from compressor out let to cooling

1 tank. This includes gate valves, piping, hangers, supporters, etc. As per site

requirement.

Material required for air cooled line from source to compressors. This includes Reputed

piping, valves, hangers, supporters, etc. As per site requirement. vendors

All C&I items required for final operation of the screw compressors packages from /

main control room with protection and logic. This excludes any item for supply and Qty as

installation in the DCS/main control room. All Required Electrical Panels/junction box required

etc. are in party scope. at

All electrical items like cables, panels etc. all required for electrical operation of the site

4 screw compressors packages from main control room including facility for local

operation.

5 All material required for preparation of the Civil Foundation.

C. Scope of service

Sr DESCRIPTION

1 Erection, installation, testing and commissioning of lubricated screw air compressor

packages, including:

a. Supply, storage and transportation at site

b. Civil Works

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

c. Mechanical Works

d. Electrical and C&I works

e. Commissioning of the lubricated screw air comp packages with the system in all respect.

D. Criteria for placement of order:

Offered rate will be considered on the basis of total input power. The least total input power offered

will be considered as the base and the loading of additional power will be loaded on the other

bidders considering 5 years life. The sample calculation for the same is as below. Order will be

placed to L1 bidder after considering the addition power loading and at the rate offered by bidder.

Bidder -1 Bidder -2 Bidder -3

ASSEMBLY OF

ENERGY EFFICIENT

LUBRICATED

ROTARY SCREW

COMPRESSOR Air

Supply Part-A COOLED FOR

Sr-1 INSTRUMENT AIR &

SERVICE AIR

HAVING MAXIMUM

PRESSURE OF

BAR, CFM 580 AT

STAGE-1 UNITS

Lump sum charges for

Removal of Existing

K.G Khosla

Works Part-B Reciprocating comp.&

Sr-2 installation of new

Lubricated screw

compressor stage-1

units, WTPS

Comprehensive

Maintenance contract(

Works Part-B with spares ) for

Sr-3 lubricated screw

compressor of TMD-1

Cost of buy back for

old removed

Buyback Part-C

reciprocating air 50,000 50,000

compressor as per

scope of work.

Total of Total cost of

(1+2+3-4) compressor

Offered Specific

6 power consumption 0.14 0.18

Power consumption

7 for 05 years and 8760 27436320

running hrs. (Rs.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

unit/rate) = total input

power *580*8760*6*5

Additional loading on

offered rate for higher

power consumption in

Final rate after

9 Total of (5+8) loading additional 52,00,000 1,07,96,960

power consumption

Order will be placed on bidder-1 as overall offered rate considering total input power is Lowest than other

E. Technical Terms and Condition:

1. Bidders shall have to submit past executed purchase order copy of “supplied package of

lubricated screw Type Air cooled compressor” within preceding 07 (Seven) years with

GSECL/NTPC/SEB‟s/Govt/semi Govt. organization/Central/State PSU/Private limited

company/Public Limited Company etc. prior to the date of techno-commercial bid opening

along with successfully trial run and satisfactory performance certificate.

2. Offer from OEM or their authorized dealer is acceptable. In case of dealer, Bidder shall have

to submit latest valid authorization certificate from OEM.

3. Dismantling of existing air compressors and Installation / erection & commissioning and trial

run of new installed lubricated screw compressor with all related Civil, Mechanical, Electrical

and C& I work are in the scope of party. All work should be carried out under trained

supervisor of OEM only.

4. Dismantling/Assembling/replacement of cooling water lines/valve /NRV for new compressors

etc. as per requirement and as per instruction of EIC.

5. Electrical cables, junction box, MCC and all Instruments are to be needed to run the

compressor as per requirement & instruction of EIC after completion conversion job.

6. Bidder shall have to ensure that proposed compressor will be fitted in same area after

dismantling existing one.

7. Bidder shall have to supply complete package of compressor + motor on single frame

suitable for handling like plug and play type of arrangement including sound proof hood.

8. PAYMENT TERMS:

A. Supply:

1. 80% supply prices shall be released within 30 days on receipt of material at Wanakbori

TPS site and site certification thereof.

2. Balance 20% of supply prices shall be released after successfully commissioning and

trial run the lubricated screw compressor units.

B. Erection, Testing and commissioning:

1. 80% of erection, testing & commissioning / installation charges after completion of

Erection work.

2. Balance 20 % payment will be released after successfully erection, testing &

commissioning and trial run of New installed screw compressor and submission of PBG.

9. Performance Guarantee: Party shall have to submit PBG of 15% of order amount. After

completion of guarantee period i.e. 12 or 18 moths 10% PBG will be released however, 5%

PBG will be released after completion of 5 years guaranteed life of screw with reducing

amount 1% per year.

10. Guarantee / warrantee certificate:

The bidder should have to submit guarantee certificate against any defect, bad design & poor

workmanship for the 12 months from the date of commissioning or 18 months from the date

of supply whichever is earlier.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

11. During the Guarantee/Warrantee period, if supplied screw compressor is found defective due

to bad design/material/model or poor workmanship, the same shall have to be repaired /

replaced by the party free of cost.

12. Bidder shall have to submit material test certificate, performance certificate and all other

relevant test certificate from manufacturer or Government approved laboratory along with

13. Security deposit clause: Security deposit should be paid within 10 days after receipt of LOI

i.e. before placement of order. The successful bidder if Enterprises or Organizations which

are exempted from paying Tender Fees & EMD as per GOG Procurement Policy has to pay

an amount @ EMD- 3% of the work order value and other all enterprises have to pay @

security deposit - 5% of the order value.

14. Penalty clause: Bidder shall have to offer energy efficient lubricated screw compressor

with specific power consumption (SPC) should be minimum at working parameter @

bar. Bidder shall have to prove the same at their work and WTPS site. The total power

consumption will be considered for the given input terminal only. If bidder fail to prove the

guaranteed total input power than penalty for difference in total input power will be

applicable considering 5 years life of compressor or 15% of order amount, whichever is

15. Rejection clause: Performance accepted as per ISO 1217 annex C for screw compressor in

factory test with permissible tolerance as per ISO standard. After ISO tolerance machine will

be rejected.

16. LD clause:

 Delay in completion of supply: One-half percent (0.5%) of the unit Contract Price per

 Delay in completion of work: One-half percent (0.5%) of the unit Contract Price per

17. TIME LIMIT: Bidder shall have to supply full material within 05 month from the date of LOI

issued. For Erection, Testing and commissioning bidder shall complete the installation work

with 02 months from the clearance given by the GSECL. Delay in execution of order on

account of any other reason will be subject to penalty.

18. Party shall have furnished the all-test certificates of supplied compressor and related to its

factory tests, performance test reports.

19. GSECL reserves rights for testing of materials from the supplied items randomly if required. If

the results of all tested items will not be as per above specifications or the entire or part of

supply is not found dimensionally ok, then the entire or part of supply will be rejected.

20. All the work / any activity which is required to complete the specified job of this tender & not

mentioned in this tender is also in the scope of the contractor & they have to carry out the

same at free of cost in the quoted rates only.

21. Bidder shall have to submit all the technical and electrical & instrumentation

Specification/features, performance data and General Assembly drawing along with

Technical bid for rough idea of dimension and requirement to EIC.

22. Comprehensive maintenance contract:

 Bidder shall have to carry out complete maintenance of installed compressor as per

OEM recommendation with required spares and consumable at contract rate only.

 One Job will be considered as comprehensive maintenance work of total 05 numbers

of installed new compressor for 12 months. Payment will be given on prorate basis.

 Party shall have to submit the list of spares and consumable required during AMC

with the technical bid.

 Party shall have to supply the listed spares and consumable in advance before

servicing. The unused spares will be credited to TMD store and it is the property of

 Bidder shall have to visit the plant and carry out preventive maintenance as per the

standard practice of OEM OR site requirements / healthiness of lubricated screw

compressors minimum four times in a year and unlimited visit if any problem arises

in installed screw compressors.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

 Party shall have to ensure compressor oil, oil level and its quality and all types of

filters condition OR as per OEM guide lines.

 Attending to the plant / site defects when called /e-mail by users upon within 24 hrs.

 Party shall have to submit all spare parts and its schedule for replacement on

quarterly basis OR as per OEM guide lines / running hours of existing lubricated

screw compressors.

 Whenever call / E-mail given to party by user section for attending the any defects at

the plant, party shall have to visit the plant for attending the defect within 24 hrs.

Otherwise penalty clause i.e. 1/2 % per day of services will be deducted as

GSECL norms.

 During the AMC period, party has whole responsibility to maintain the healthiness of

new package compressors hence there is no limit in no. of visit, party has to attend

all complain / breakdown.

 Reporting the healthiness of the compressors on monthly basis.

23. Successful bidder shall have to give an inspection call to EIC before dispatch of compressor

for general testing and for offered guaranteed parameters.

24. All the work/activity which is required for successfully installation, erection/commissioning &

final trial run of new package screw compressor & if anything is not mentioned in this tender

is also in the scope of the contractor & party shall have to carry out the same at free of cost

in the quoted rates only.

F. FACILITIES GIVEN BY GSECL FREE OF COST:

1. GSECL will provide water and electricity at free of cost as per requirement of work and as

per availability.

2. GSECL will provide workshop facility free of cost only related to this work, if available.

3. Oil (recommended by OEM) for replacement/topping will be provided by GSECL after

completion of guarantee/warranty at free of cost.

4. GSECL will provide hydra & for clip for lifting & shifting compressors.

G. CONTRACTOR WILL PROVIDE FOLLOWING FREE OF COST:

1. All require man power (OEM supervisor, skilled technician, unskilled labours as per

requirement) is to be done by party at free of cost.

2. Special types of T&P not available with GSECL for conversion of compressor are to be

arranged by party free of cost.

3. To and Fro transport and conveyance of their staff shall be borne by the party at his own

4. All PPE‟s appropriate for the jobs are to be arranged by the contractor at his own cost.

5. M/s GSECL shall provide accommodation in hostel / guest house as per availability on

Chargeable basis only.

6. All required welding machines, electrodes, Oxygen & DA gas, along with welder, other

accessories, etc. are to provide by GSECL free of cost as per requirement of job and as per

availability.

7. All the work related to civil, mechanical, electrical and instrumentation i.e. C&I is to be

done/cover by party scope

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist: Kheda -388239

Ph: 91-2699-235522 Fax: 91-2699-235607

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018 Certified Power Plant

Technical qualification criteria:

1) The bidder shall be the manufacturer and supplier of Rotary screw compressors.

2) The bidder should have executed / completed similar works during the last seven (7) years in

Government / semi government / state electricity board / private limited company i public limited

company / IPP , as on last date of the month preceding the month of publication of tender, having

minimum contract /order values as indicated below :

1. One order of value not less than the amount equal to 1, 94,

2. Two orders, each of value not less than the amount equal to

3. Three orders, each of value not less than the amount equal to

Similar work means - "Supply & installation or Supply, of lubricated screw type Air cooled

compressor".

Financial qualification criteria:

1) The Average Annual Turnover of the bidder, shall not be less than Rs. 72.90 lacs

during the preceding three (3) financial years as one date of Techno-Commercial bid opening.

2) Net worth of bidder shall not be less than 100% of the bidder‟s paid up share capital as on the

last day of the preceding financial year. In case the Bidder meets the requirement of Net worth

based on the strength of its Subsidiary (ies) and/or Holding company and/or Subsidiaries of its

Holding Companies wherever applicable, the Net worth of the Bidder and its Subsidiary (ies)

and/or Holding company and/or Subsidiary (ies) of the Holding Company, in combined manner

should not be less than 100% of their total paid up share capital. However individually, their Net

worth should not be less than 75% of their respective paid share capitals.

Net worth in combined manner shall be calculated as follows:

Net worth (combined )= (x1+x2+X3)/(y1+y2+y3) X 100, where x1,x2, x3 are individual

net worth which shall not be less than 75 % of the respective paid up share capitals and

y1, y2, y3 are individual paid up share capitals.

3) In case the bidder is not able to furnish its audited financial statements on stand-alone entity

basis, the unaudited unconsolidated financial statements of the bidder can be considered

acceptable provided the bidder further furnishes the following documents for substantiation of

its qualification.

 Copies of the unaudited unconsolidated financial statements of the bidder along with

copies of the Audited consolidated financial statements of its Holding Company.

 A Certificate from the CEO/CFO of the Holding Company, stating that the unaudited

unconsolidated financial statements form part of the Consolidated Annual Report of the

4) In cases where audited results for the last preceding financial year as on the date of techno-

commercial bid opening are not available, the financial results certified by a practicing

Chartered Accountant shall be considered acceptable. In case, Bidder is not able to submit

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

the Certificate from practicing Chartered Accountant certifying its financial parameters, the

audited results of three consecutive financial years preceding the last financial year shall be

considered for evaluating the financial parameters. Further, a Certificate would be required

from the CEO/CFO, stating that the Financial results of the Company are under audit as on

the date of Techno-commercial bid opening and the Certificate from the practicing Chartered

Accountant certifying the financial parameters is not available.

Note for point No.1, 2, 3 &4:

i. Other income shall not be considered for arriving at annual turnover.

ii. “Holding Company" and “Subsidiary Company” shall have the meaning ascribed to them as

per Companies Act of India, in vogue.

iii. Net worth means the sum total of the paid up share capital and free reserves. Free reserve

means all reserves credited out of the profits and share premium account but does not

include reserves credited out of the revaluation of the assets, write back of depreciation

provision and amalgamation. Further, any debit balance of Profit and Loss account and

miscellaneous expenses to the extent not adjusted or written off, if any, shall be reduced

from reserves and surplus.

Other requirements:

1) Bidder should have a separate valid GST registration number and PAN Number.

2) Copy of P.F. code from the appropriate provident fund authorities.

3) Labour License for Labour Contract: The contractor on getting the work order but before starting

the work shall have to furnish the copy of Labour License under the Contract Labour

(Regulation & Abolition) from the appropriate authorities. Also required workman group

insurance policy covering labour engaged.

4) The bidder must submit performance certificates or satisfactory work completion certificates

(issued directly by the utility) or Copy of Processed Final Bill of the executed / submitted PO

from the utility. Bidders shall be required to submit all the documents, in support of Technical

QR (Such as copies of Purchase orders/work orders / Contract Agreements, Client Certificates,

etc), shall be digitally signed by the Specified Third party inspection Agency (TPIA).

5) The bidder must submit Average Annual Turnover and Net worth Certificate in support of

Financial QR, duly certified and verified for authenticity from Independent Statutory Auditor of

their company / Practicing Charted Accountant/ C.A. Firms / TPIA (Third-Party Inspection

Agency ) empaneled / approved by GSECL along with copy of Annual Audited Accounts of last

three years.

6) Tender fee & EMD will be applicable as per NIT

7) Bidder shall have to submit Details of tools; tackles and equipment are in possession relevant to

8) Document for sole proprietor of firm / copy of partnership deed in case of partnership firm.

9) Bidder must have minimum 5 years‟ experience in manufacturing and supply rotary screw

compressors. Also having local service support availability.

10) Certificate for satisfactory performance certificate of supply and installation for same screw

compressors along with testing trial run at site from any Govt./semi Govt.

organization/private/NTPC Organization should be submitted along with technical bid.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

11) Party has to offer all the items including supply & work portion, otherwise offer will be ignored

without any correspondence. Offer of overall lowest will be considered only.

12) Party has to submit detail technical specifications for offered model of screw compressors,

catalog and technical data sheet to be used clearly mentioning the make & source.

13) Bidder shall have to submit Past Three-year ITR form balance duly attested by CA.

Yours faithfully

Chief Engineer (C&O)

GSECL, WTPS

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist: Kheda -388239

Ph: 91-2699-235522 Fax: 91-2699-235607

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018 Certified Power Plant

GENERAL TERMS & CONDITIONS

Name of Supply and Installation of an Energy Efficient lubricated Rotary screw air

Work compressor at stage-1 units of Wanakbori TPS; GSECL

GENERAL CONDITIONS OF CONTRACT

1. The contractor shall at their own expense make all necessary provision for housing water supply

and sanitary arrangement for their employee as well as for works and shall pay direct to the

authorities concerned all rates and taxes.

2. The contractor shall make their own arrangements for the necessary approach road, for

transport of their materials and be responsible for the Compensation on account of damage to

crop on Corporations‟ property.

3. All the royalty charges octroi other duties will be paid by the contractor and no extra could be

claimed on this account.

4. The organization will supply articles at the place and rates mentioned in schedule „A‟ of Tender

form.In case of the materials issued either through or with the recommendation of this

organization it will be absolutely necessary for the contractor to maintain a correct and honest

record of the daily consumption of the said materials/with inside particular reference to the work

during the day.

The Engineer-in-charge of this department or his authorized agent shall have the right to inspect

and check the stores containing these materials and the account for these materials shall be

presented for inspection whenever asked for by them. Every facility shall be afforded by the

contractors for all these inspections Engineer-in-charge will supply the materials in any quantity

as deemed fit.

5. Godown of sheds hired or constructed for storage of controlled materials and more/ particularly

of cement shall be such as would prevent the materials from getting damages in any way.

6. It will be absolutely incumbent of the contractors to have on the site of work only such of the

materials as have been dully passed by the Engineer-in-charge Materials that have been

rejected must on no account be allowed to remain on the side and in spite of written order to do

so any such rejected material is on the site beyond a period of 48 hours, notice the Engineer-in-

charge shall have the right to remove it at the risk and cost of the contractor and even destroy it.

7. It must be distinctly understood that the conditions of the contract and of claims in respect of

extra work will not be allowed, unless the works to which they relate is clearly without the spirit

and meaning of the specifications or unless such work are ordered in writing by the Engineer-in-

charge and claimed for in specified manner.

8. On completion of the work, the site shall be cleared by the contractors within the stipulated

period, and ground brought to original state and they shall not be entitled for any extra claim on

this account.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

9. DAMAGE CAUSES TO WORKS:

The work whether fully constructed or not, and all materials, machinery plant tools, temporary

building and other things connected there shall be at the risk and in the sole charge of the

contractor until the works have been delivered, completed to the Engineer- in-charge and

certificate from him to that effect obtained until such delivery the contractor shall at their own cost

take all the precautions reasonably necessary to keep all the aforesaid works materials

machinery, plant, tools, temporary building and other things connected with the work, free from

any loss or damage and in the event to the same or any part there of being lost or damage shall

from with within possible speed, reinstate and make good such loss or damage at contractor‟s

10. Supply of controlled articles will be invariably recommended after the actual requirements have

been carefully scrutinized. In the event of any such materials remaining in surplus in charge of

the contract, on account of some modifications either in the design or changes in construction or

any other reason will be returned to the department.

11. There will be generally no objection on the component parts of the works being given over to

responsible sub contractors but it must be borne in mind that this department would under no

circumstances recognize these sub contractors and responsibility of executing the work in

accordance with the condition of the contract will entirely rest on the main contractors. The main

contractors will therefore always have the very responsible member preferably a technical hand,

present on the works with power to sign all work order issued on the site of work and to take

requisite actions in the interest of very efficient execution of works.

12. With a view to ensure rapid progress on the works purchaser may store at work sites certain

quantities of the materials such as cement etc. and it will be incumbent on the tender to

purchase these materials, at the rates mentioned in schedule „A‟ of tender form for supply of

necessary articles, all necessary help will be tendered but in must be clearly understood that the

purchases does not accepted and responsibility for the delay that may be cause in their supply

on account of circumstances beyond the purchaser‟s control.

13. Contractor will be asked to present the sample of materials and the approved sampled will be

preserved at the site of work and no change in the approved sample will be allowed without the

written permission of the Engineer-in-charge.

14. Contract will have to communicate the name of his authorized agent who shall be presentation

the works and shall be authorized to sign the materials requisitions receive instruction given

verbally, or on the order book on behalf of the contractor.

15. The materials issued to the contractor as per schedule „A‟ of the tender shall not be removed

from the work and all surplus material at the end of the works which is considered serviceable

shall be returned to the organization even the unserviceable material shall be removed only with

the prior permission to the E.E. in writing.

16. The contractor will have to sign the conditions of the contract and execute the agreement, send

the list of previous works executed solvency certificates and pay up the security deposits, failing

to that the tender will be rejected and earnest money deposit will be forfeited. The value of the

stamp paper and stamp duty charges shall be borne by the contactor.

17. The contractor must arrange for all transport of materials weighting of material issued at

department stores and all such cost include in the rates of schedule „B‟.

18. The competent authorities can delete to any items in the schedule „B‟ of the tender order if they

feel that the items is not essential to be executed.

19. A schedule of quantities is included in the tender document it shall definitely understood that the

Corporation does not accept any responsibility for the correctness or complication of this

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

schedule-B. The tender documents shall be written legibly and free from grouser, over written on

conversion of figures correction where unavoidable shall be made by crossing out initialing

dating and rewriting both in figures and in words in case of my discrepancy in figures the price

quoted in words shall prevail.

20. This notice to tenders shall form a part of the contract.

21. The entire work is to be completed within the stipulated time limit from the date of work order.

The contractor will not be eligible for any extra for the idle period of work or waiting period that

may be required to suit other considerations and no claim for compensation on account of such

will be considered. However in case or delay due to circumstances beyond the control contractor

either in date of commencement or due to waiting during construction extension time may be

considered for completion of work.

22. In case contractor is unable to account for full quantity of materials issued to him from the

department stores, recovery will be effected from him at cost rates or market rates prevailing at

the time of issue whichever is higher, plus 15% to cover Corporation‟s departmental supervision

charges for all material unaccounted for.

23. Bill shall be submitted by the contractor monthly on or before the date fixed by the E.E., for all

works executed in the previous months.

24. SUPPLY OF WATER AND ELECTRICITY:

If possible water for construction purpose only may be supplied by the Corporation at one point

as decided by the Engineer & recovery for water charges shall be effected at two percent of cost

of time as executed in which the water supplied by the Corporation is used as certified by the

Engineer in charge Electric supply is required the contractor shall be given Free of cost by

GSECL. (Applicable to CIVIL WORKS only).

25. Should this tender be accepted, I/We have agreed to abide by and full fill all the terms and

provision of „Tender and Contract of works‟ as applicable, and in default thereof, to forfeit and

pay to the Corporation the some of money due.

26. The work will have to be carried out in co ordination with other Agencies on the same site on

account of this in case the contractor has to stop or delay his works for same time he will not

claim anything extra only Corporation may consider to give suitable extension in time limit if

necessary on such account.

27. Any disputes arising out of the contract if not settled mutually, than the same shall be settle by

Gujarat Public Work Arbitration Tribunal act-1992.

28. Following clauses of this section are not applicable to this contract i.e.

CIRCULAR – I

The following are the major obligations to be fulfilled by the Contractors as per the Contract

Labor (R&A) Act 1970 and rule mentioned there under:

1. License to be obtained before starting the Work where number of contract laborers in Fifty or

2. Payment to contract laborers has to be made in presence of IRO/LWO. Wages rates for contract

laborers are applicable as per the terms and conditions of the license. The contractor shall have

to pay wages to workers as notified by Government of Gujarat., from time to time

3. Every contractor shall have to maintain the muster roll and wages register in respect of his

contract labor.

4. Every contractor is required to issue employment card, wages slip and attendance card to their

5. The contractor has to maintain the register No. 13 containing details of contract labors employed

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

6. Earned leave register/ card as per the Factories Act. And Rules.

7. Other registers required under Contract Labor Rules and the Factories Act. And Rules.

8. Every contractor shall have to obtain insurance policy in respect of the contract labors engaged

by him to cover them under workmen‟s Compensation Act.

9. To send half yearly return to licensing officer as per Rule 82 (1) as per schedule time.

10. Before starting the work as per the contract awarded to him, he should make arrangement to

enter into the agreement in the prescribed format on the stamp paper as applicable. Before

fulfilling the above requirement the contractor is instructed not to start the work. The

responsibility will be on his head in case he fails.

11. Contractor should posses separate P.F. code on their firm, name otherwise their offer may must

be considered.

All the contractors are informed to adhere to the rules and regulations applicable to them,

particularly in respect of the laborers engaged by them, the contractor not fulfilling the obligations

will not be allowed or continue with work/ not be held qualified to carry out the work at TA-

Galteshwar Dist. - Kheda Power Station.

CIRCULAR-2

It has been directed by our CO that, no new labor contract be entrusted to any agency without

getting prior approval from CO. Further the existing contract, on their expiry, may not be

extended without approval from HO, Vadodara.

In light of the instruction conveyed by HO, it is necessary to check up the following documents of

each and every contractor before awarding the contract to these contractors. For preliminary

checking of valid contractors, the following documents are required to be checked by the

concern DE/EE/SE. On their checking the same and by recommending the number of labors,

gate pass will be issued by the Sr. Security officer. But before awarding and finalizing any

contracts, following information must reach to IRO for his confirmation.

1. The contractor should not allowed to engage fifty or more contract labors without initiating to

obtain the labor license under the Contract Labor Act from the Assistant Commissioner of Labor,

Nadiad (The same number i.e. fifty or more includes Supervisor and other staff).

2. Number of days of the contract should be informed first before allowing the contract to start. The

Contractor also must obtain group insurance under WC Act before starting the work.

3. The contract laborers must be paid minimum wages as per notification issued by competent

authority under the said Act from time to time upon issuance of Circular by Chief Engineer,

WTPS. The above instruction must be followed scrupulously to avoid labour liabilities under

Contract labor Act.

“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTOR

All the contractors working in Gujarat State Electricity Corporation LimitedFactory like

Coal/Lignite/Gas/Hydro/Pumping Station shall have to strictly observe the following Safety

Rules. Concern principle contractors are responsible for informing & observance of these rules

by their supervisors/contract workers as well as the owner/supervisors/ workers of sub-

Contractors engaged, if any, by them for the work contract awarded to them. Prior to

commencement of the work, Contractor shall have to submit a written assurance on their

letterhead to the concerned Sectional Head / Engineer-in-charge that they have thoroughly gone

through these Rules, have educated their employees / workers of their sub contractor and will

strictly observe the said Rules while execution of work under work contract awarded to them.

They will have to indemnify the company for any loss or damage / accident / injury to the

company‟s property / employee or employee of their own in default of non - observing these

1. Contractor should issue photo gate pass for their workers from GSECL Factory Manager as per

Gujarat Factories rules, 1963 & details shall be filled up in GSECL gate pass format as per

Aadhar card /Election card id proof & to follow the gate pass issue procedure through concern

department EE & SE, Security Officer, LWO/IRO/DGM, Factory Medical Officer, Safety

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Officer/Dy. Safety Officer & Factory Manager.

2. In case of emergency, temporary photo gate pass shall be issued by Security Officer only for

three days with prior permission of Factory Manager only. More than three days, Permanent

photo gate pass procedure shall be completed by contract agency for their contract workers.

3. Certificate of Fitness of employment in hazardous process & operations in form no.33 of Gujarat

Factories rules, 1963 shall be issued by GSECL Factory Medical Officer for all contractor

workers before commencement of work & examination responsibility shall be taken by contractor

as well as concerned Head of Department .Pre-employment & Periodical medical examination of

contractor workers shall be carried out in form no.32 from GSECL Factory Medical Officer after

every six (06) months of contractor with their contractor workers. Contractor shall be fulfilled all

health requirements before commencement of work. After completion of medical examination in

form no.32/33, GSECL Factory Medical Officer shall be signed in contract worker gate pass

procedure format.

4. If work executed outside factory premises, Principle Contractor shall be registered compulsory

under The Building & Other Construction Workers (Regulation of Employment and condition of

service) Act, 1996 and The Gujarat Building & Other Construction Workers (Regulation of

Employment and condition of service) Rules, 2003 before execution the ”building or other

construction work” means the construction, alteration, repairs, maintenance or demolition, of or,

in relation to, buildings, streets, roads, railways, tramways, airfields, irrigation, drainage,

embankment and navigation works, flood control works (including storm water drainage works),

generation, transmission and distribution of power, water works (including channels for

distribution of water), oil and gas installations, electric lines, wireless, radio, television, telephone,

telegraph and overseas communications, dams, canals, reservoirs, watercourses, tunnels,

bridges, viaducts, aqueducts, pipelines, towers, cooling towers, transmission towers and such

other work as may be specified in this behalf by the appropriate Government, by notification but

does not include any building or other construction work to which the provisions of the Factories

Act, 1948 (63 of 1948), or the Mines Act, 1952 (35 of 1952), apply.

5. Contract worker gate pass will issue after completion of safety induction 3D animation movie &

Training record is to be maintained in IMS/OHSAS training format by TK Office/LWO.

6. As per Gate pass format of GSECL, Safety Officer/Dy. Safety Officer shall be checked the issue

PPE to contract workers as per nature of job, Form no.10 of lifting tools and tackles, Driving

license, Electrical contractor license, Electrical trade qualifications, Safety induction training,

SOP, supervisor qualifications etc. After fulfillment of all Safety compliances, Safety Officer/Dy.

Safety Officer shall be signed in Contract worker Gate pass procedure format.

7. Work Contract shall be completed by principle contractor/agency/person who is awarded the

work order. Subletting of contract shall be allowed only if prior approval of Power station chief

before execution of work. Contractor/agency shall be submitted the entire subletting contract

documents with gate pass application through concern department EE & SE, LWO/DGM, Safety

Officer/Dy.Safety Officer & Factory Manager.

8. Under The Conditions Framed Under Rule-45 Of The Indian Electricity Rules, 1956, Valid Electrical contractor License

shall be submitted to concern electrical department EE/SE/Electrical Safety Officer/ Safety

Officer/Factory Manager at the time of apply gate pass by agency/Contractor with latest renewal

from Chief Electrical Inspector, Gandhinagar- Gujarat. Electrical License photocopy shall be

checked by Concerned HOD of Electrical Department/Electrical Safety Officer/Dy.Safety Officer/

Safety Officer/Factory Manager.

9. As per nature of job/work, Qualified supervisor (Diploma (Electrical/ Mechanical/Civil/C&I) +

3 years experiences or ITI + 10 years) shall be engaged by contract agency & qualification

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

certificate with experience certificate shall be submitted to concern EE/SE/LWO/IRO/DGM/

Dy.Safety Officer /Safety Officer/Factory Manager at the time of apply gate pass.

10. As per rule 3 of CEA regulation ,2010: Designating person(s) to operate and carry out the

work on electrical lines and Apparatus, Contract person/worker possesses a certificate of

competency or electrical work permit, issued by the Appropriate Government. That means,

Electrical trade Qualification of contract worker/person like ITI-wireman/ Electrician, Diploma

(Elect), BE/B. TECH (Elect), ME/ M. TECH (Elect) shall be submitted to concern

EE/SE/LWO/IRO/DGM, Dy.Safety Officer/ Safety Officer/Factory Manager at the time of apply

for photo gate pass procedure.

11. As per nature of job/work & during capital overhauling work /Annual overhauling work /24X7

round the clock work/major shut down work, Qualified Safety Officer/Manager/Supervisor

(BE/Diploma (Elect/Mech/Civil) + PDIS-Post Diploma in Industrial Safety) shall be engaged by

contractor during dangerous operations/dangerous works as well as day to day dangerous

activities, safety supervision, tool box talk, Safety awareness programme, SOP preparation with

hazards & its control measures with each step , checking of lifting tools & tackles, hydra mobile

crane, Safety precautions, coordination with Safety Department etc.

12. License of driver shall be submitted with gate pass issue application as per nature of vehicles &

to follow the Motor vehicle Act,1988,the Central Motor Vehicles (Amendment) Rules,2016 as well

as Gujarat Motor Vehicles rules,1989 & driver license shall be checked every day by security

shift in charge before entry in the Factory premises.

13. SOP with JSA (Job Safety Analysis) shall be prepared by contractor through competent person

as per GFR, 1963 or Qualified Safety Officer as per GFR, 1963 with 05 years experiences. SOP

will review & approve by concern JE/DE/EE/SE/Elect. Safety Officer/Dy. Safety Officer /Safety

Officer/Factory Manager before execution of work.

14. It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as per the job

requirement. Do not work without use of required P.P.Es. Contractor is responsible to provide

standard make (ISI/DGMS/CE/EN/ANSI approved) & to checked standard/make in PPE issue

format by concern JE/DE/EE/SE/Safety Officer/Factory Manager. Personal Protective

Equipments / Safety Gadgets suitable to give sufficient protection against hazards involved in

their work / job to their staff, as per the job requirement and insist / enforce their workers to put

on the same while at works.

The ongoing work is liable to be stopped at any time if your contract workers/staffs found working

without P.P.Es. Following is the list of various P.P.Es (as per ISI/DGMS/CE/ EN/ ANSI approved

only) to be used for various works / worksites.

In any work, Contractor shall be issued the minimum 06 nos. of PPEs like Safety Shoes, Safety

Helmet, Safety goggles, Mask & Reusable Ear plug, hand gloves to their workers/supervisor

compulsory & it will check by concern section HOD & Dy. Safety Officer /Safety Officer at the

time of gate pass procedure.

Quality of PPE shall be approved from Safety Officer as per Indian Standard and International

Standard before executions of work or at the time of gate pass apply procedure.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

List of safety equipments

Industrial Safety Helmet For protection of head against falling objects or during fall

of person from height. YellowColour helmet is used for

contract worker with agency logo.

Safety Goggles/welding goggles/ For protection of eyes against flying particles / dust,

chemical splash goggles chemical splash, welding spark, arc, flashover etc.

Full Face shield For protection of face against flying particles / dust,

chemical splash, spark, arc, flashover etc.

Reusable Earplug / Ear muffs. For ear / hearing system protection while working in high

noise level area.

Chemical suit/Gas tight suit /Fire For body protection against chemicals, oils, sharp edged

proximity suit/FR Boiler Suit objects, heat, hot objects etc.

Safety Hand Gloves For protection of hands against chemicals, oils, sharp

edged objects, heat, hot metals/objects, electricity etc.

Safety shoes/ Gum Boots with For protection of leg/feet against falling objects, sharp

Oil/Chemical/water/heat/ edged objects, heat, hot metals/objects, electricity etc..

Electrical resistance etc.

Safety Belt(full body hardness For fall prevention while working at heights or in depth,

with double lanyard & shock working in vessel or in confined space.

absorber) / Rope / Life line / Fall

arrestor etc.

Dust Mask/Respirator with Protection of respiratory system against dust.

valve(FFP2)

Chemical Cartridge Respirator Protection against toxic chemical fumes /

with full face mask type gases/vapors/dust etc.

Trolley mounted Air line Working in oxygen deficient zone or confine space area

respirators with full face mask

Portable Single gas detector like Working in hazardous storage/process area

Chlorine, Ammonia, Hydrogen,

Portable Multi gas Detector Working in oxygen deficient zone & use in entry of confine

( LEL,O2,CO,H2S,SO2, etc) space & Major fire

Automatic voltage detector To check the present voltage or induction voltage of

electrical equipments/ bus/switch gears from 01 (one) feet

distance before starting the any electrical work .

Auto darkening welding helmet The new auto darkening welding helmet combines

(EN 379 & EN 175 Level-B) with legendary Speed glass quality and auto darkening

PAPR as per EN 12941:1998, technology with an innovative wide-view grinding visor to

class TH2 and AS/NZS 1716 give welders an all-in-one solution for more flexibility,

precision, and efficiency.

Respiratory System is a combined face and breathing

protection device, for increased comfort and safety in

welding. The unit is equipped with a particle filter which

removes particles from the air. The unit provides a

constant airflow independent of filter combinations and

clogging. The unit can also be equipped with a gas filter

(for example A1B1E1). The unit supplies air to the head

top via the connecting breathing tube. The airflow creates

a slight positive pressure which together with the sealing to

the face prevents particles and other contaminants from

entering the head top.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

15. All PPEs (as per ISI/DGMS/CE/EN/ANSI approved only) Should issued by

party/agency/contractor to their contractor workers as per nature of job and allotment of PPE list

shall be submitted to Safety Officer, Wanakbori on his letter head as per below mentioned format

by Contractor before commencement of work through concerned JE,DE,EE/SE .

Sub: Issue of PEE to Contractor workers

Sub of work Order:

Work order no.

Name of Agency:

Date of Commencement:

Time limit for work order:

Sr Nam De Name Name of IS Make Qt Unit Dat Receivin

. e of sig of PPE :Code of y e of g

N work nat Section no. of PPE issu signatur

o ers ion under PPE e e

Safety Nos

01 Helmet .

Safety Nos

goggles .

Reusable Pair

Dust Mask Nos

Safety Pair

16. Shift Security Inspector/Security Officer shall be checked Safety Shoes & Safety Helmet of all

contractor workers at entry gate of Factory Premises & shall entered contractor workers with

Safety Shoes & Safety Helmet with photo ID Gate Pass.

17. Shift Security Inspector/Security Officer shall be checked validity of Gate pass of all contractor

workers on daily basis.

18. During the work execution, one trained & competent supervisor of agency should always remain

present at work site. Concern JE/DE of GSECL shall be supervised the contract work as per

19. Approved NABL laboratory calibration certificates of electrical/mechanical/Civil/C&I/Environment

survey/Chemical etc measuring /testing equipments/instruments which are used during contract

work shall be submitted before starting the work & shall be checked by concern JE/DE/EE before

starting work & it‟s record shall be maintained in concern section.

20. The contractor shall take all the required safety measures prior to commencement of work on

dangerous substances, machineries or area at which cautionary notice is displayed and obtain

“Line Clear” or “Work Permit” through the concern Department / Section JE/DE and shall be

informed to concern section JE/DE for closed/ returned after completion of work.

21. Safety talk/Safety work instructions shall be given to contractor workers by concern JE/DE

regarding hazards of specific work, risk & it‟s control measure (mentioned in HIRA) before

starting the job work and records shall be maintained for each & every job works.

22. Display Safety instructions shall be strictly followed by all workers who are working in factory

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

23. Material Safety Data Sheet (MSDS) of each chemical shall be available with Chief

Chemist/Control room &work related Chemical information shall be taken by contractor &

contractor workers from Concern EE/Chief Chemist before starting of chemical handling work.

24. The contractor shall be checked & securely covered or securely fenced any opened fixed vessel,

sump, tank, pit or opening in ground or in floor which, by reason of its depth, situation,

construction or contents ,is or may be a source of danger before starting the work each & every

days or after interval/recess. Contractor supervisor shall be informed to concerned HOD

regarding any unsafe conditions.

25. Prohibition of smoking, fires, lights, spontaneous ignition substance, matches; fuses, mobile

phone etc are to be strictly followed by all workers who are working in factory premises.

26. Prior to carrying out welding, gas cutting, furnace heating or any other hot work job, remove all

the inflammable material lying at or nearby worksite or cover it properly by suitable protective

covering. Also, special care shall be taken before carrying out such job & see that all possible

contributing factors to set fire shall be removed / vanished prior to commencement of the work.

Advance intimation shall be given to concerned section / fire section to commence the work in

fire prone areas. They should also keep ready all the First Aid Fire Extinguishers / equipments&

fire extinguishing media / material like sand / water buckets or other appropriate equipment at

such place.

27. While carrying out work in confined space or inside vessel, obtain necessary “Confined Space /

Vessel Entry Permit” from concerned department prior to commencement of the work.

For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp shall be

used. For taking care of the persons working inside the confined space / vessel, a supervisor /

person capable to keep continuous watch on person(s) working inside, assist them in case of

emergency or arrange to get immediate outside help, shall remain present at entry point. Use full

body safety belt without failed.

While working inside sewage, trench or in-depth, a person to warn outsiders / entrants / passers

etc shall remain available near entry point or the entry point shall be cordoned by a barricaded

tape with a cautionary notice. After completion of the works, all the lids / covers / grills / grits

opened, shall be re-fixed / re-placed in the original position as it were prior to commencement of

the work and leave the work place in safe condition in all respect, so as to prevent accident to

fellow workers.

28. The contractor shall see that he / his persons do not work on or block (by stacking material,

spare parts, tools-tackles, equipmentsetc), any passages / walkways / gangways / aisles /

staircases / ladders / lifts or any other approaches / roads leading to plans or its auxiliaries, on

which there is traffic movements or possible traffic movements in case of emergency. Such

passages are meant for safe escape in the event of emergency. If it is utmost necessary to carry

out work in such area with blocking of passage, prior permission of Competent Authority or the

Engineer-In-Charge shall be obtained. To demarcate / declare the area as “UNSAFE”, cordon it

using barricading tape & display suitable caution notice or keep a person to restrict / divert the

traffic on this route through other safe passage.

29. Prior to use power / electrically operated hand tools / equipments / machines / gadgets like

welding machine, hand grinder, hand drill etc, ensure for its safe operation & use it only if it is

found safe to use. Do not use defective, unsafe or improperly maintained equipments.

30. The electrical power supply required to run such equipments shall not be taken directly at their

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

own but shall be obtained through concerned Electrical Maintenance Departments or their

authorized persons or under their observations / guidance only. The Electrical Section shall

provide temporary electrical connection up to contractor‟s Mains Board on which it is compulsory

to install mains switch, ELCB & fuses of adequate capacity. All such equipments shall invariably

be earthed adequately to prevent electrical shock, sparking, short circuit etc. Power cord to be

used shall be of adequate capacity, without any joint & shall consist of earth wire also. Hence, it

is necessary to use adequate capacity 3-wire power cord for single & 5-wire power cord for three

phase power connections. The plugs, receptacles, pins, holders etc shall be of adequate

capacity & safe to use.

All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting machine,

Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used during work execution

shall be of standard make & bear ISI certification mark on it. The consumables like welding

electrodes, grinding wheels / discs etc which has specific prescribed life span shall not be used

in any case if its expiry date is over.

31. Non-Sparking Non-Magnetic electrical hand tools and tool kits shall be used by Electrical

contractor for safe use in areas where hazardous, flammable, or combustible vapors, liquids,

dusts, or residues may be present in Gas Based power plant and list of tools and tackles shall

be submitted with technical bid. Non-Sparking Non-Magnetic electrical hand tools and tool kits

shall be checked by JE/DE before commencement of Electrical work.

32. Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift, mobile crane,

EOT crane etc) & its attachments (like D-shackles, slings, U-clamps, Eye bolts or any fixtures), it

shall be checked and used only if found safe to use. Also, ensure that these are tested,

examined & certified in form no.10 by Competent Person as per the Factory act-1948 & Gujarat

Factories Rules and its validity do not expire. Further, it shall be fixed properly and firmly prior to

lifting the weight. Valid Test certificate of all Lifting machines used by Contractor to be

submitted to Dy.Safety Officer/ Safety Officer before commencement of work through

concerned EE/SE.

33. Metal Scaffoldings to be used for working at height shall be of adequate size & capacity. Obtain

the work permit when working at height. While climbing on such scaffolding or working on any

structure at height, use of full body safety belt /full body hardness with double lanyard & Fall

arrestor & Helmet is compulsory. It is also necessary to fasten chinstraps of the helmet.

34. Contractor or their employee shall not interfere in day-to-day routine plant activities / works

except the work assigned to them, shall not loiter in the areas other than their work jurisdiction,

as well as shall not temper / operate / touch the machineries/equipments/auxiliaries with which

they are not concerned. Also, the contractor shall strictly instruct their staff for not to sit or take

rest at/near/below running plants, auxiliaries, systems or any place which is risky, hazardous &

prone to accident.

35. The cylinders containing poisonous / toxic or inflammable / explosive gas like Oxygen,

Acetylene, LPG, Hydrogen, Ammonia, Chlorine, CO2etc shall be handled safely taking due care.

To handle / shift such cylinders a special trolley /cage meant for it must be used but in no case it

should be rolled.

36. In Gas Based Power station/Hydrogen storage area /Hydro carbon fumes-vapour generated

area, Spark arrestor (as per approved manufacturer of CCOE, Nagpur) shall be provided on

each vehicle by party/agency and it will check by shift security in charge before entry of vehicles

in the factory premises.

37. No women or young person shall be employed or permitted to work in Lead-compound area like

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

battery room etc. as per schedule VI of GFR

38. No women or young person shall be allowed to clean, lubricate or adjust any part of a prime

mover or of any transmission machinery while the prime mover or transmission machinery is in

motion. Examination or operation of motion machinery shall be made or carried out only by a

specially trained adult male worker wearing tight fitting clothing as per section 22 of factories act

39. In all risky job, before start the work, contractor should obtain General Safety Work Permit

through concerned section from Shift –in-charge well in advance.

40. In case of noticing smoke or fire during their work execution, they shall make immediate efforts to

extinguish / control it and simultaneously inform the Fire Station Mobile No as well as Station Fire

Officer or Emergency Control room no which is displayed at prominent place of factory like Main

Security Gate, All unit control room, Canteen area, Safe Assembly points, Fire Station, All

security gates, Occupational Health Centre.

41. In case of any injury / accident while working, it shall immediately be reported to Safety

Department through concerned Sectional Head / Engineer. The prescribed Form No.

21&ANNEXURE may be obtained from concerned section or Dy.Safety Officer/Safety Officer.

In case of any electrical accident, it shall immediately be reported to Electrical Safety Officer

through concern Sectional Head / Engineer. The prescribed Electrical accident form no. A as

per electricity act-2003 & Form No. 21 & ANNEXURE as per Gujarat Factories rules shall be

filled up by concern department JE/DE with written consent of contractor. The Form may be

obtained from concerned Electrical section or Electrical Safety Officer. Electrical accident

investigation shall be carried out by Electrical Safety Officer with Factory Manager.

After any reportable accident, Contract agency shall be submitted the fitness certificate of injured

person with endorsement of GSECL factory Medical Officer to LWO/Dy.Safety Officer/Safety

Officer/Electrical Safety Officer then after injured person may allow for work.

42. For any incident occurred but have no injury to any persons should also reported as per GSECL

format and informed to Dy.Safety Officer/Safety Officer as Near Miss Incident.

43. Safety penalty shall be imposed against Offences by contract workers: If any contract

worker worked in a factory contravenes any provision of Factories act or any rules or orders

made there under ,imposing any duty or liability on workers, contractor/agency shall be

punishable with fine which mentioned as under.

Sr. Description of penalty Amount

(i) Work without PPEs Rs.300/- per person

(ii) Work without work Safety permit like working at Rs.1000/- per day

height, confine space entry, hot work etc.

(iii) License of driver as per type of vehicles not Rs.750/- per person

registered.

(iv) Welding work without flashback arrestor/double Rs.1000/- per set

gauge regulator set

(v) Operate Portable power tool without ELCB Rs.1000/-per equipment

(vi) Work without qualified Supervisor as per nature of Rs.1000/-per day

job like mechanical, electrical, civil, C&I, chemical

(vii) Work without SOP & JSA Rs.2000/-per day

(viii) Work without test report of lifting machines / Rs.2000/- per equipment

tackles (like C.P.Bs., Hook chooks, winch, forklift,

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

mobile crane, EOT crane etc) & its attachments

(like D-shackles, slings, U-clamps, Eye bolts or

any fixtures) in Form No.10 of Gujarat Factories

Rules,1963

(ix) Work without Double lynyer Safety belt during Rs.3000/-per person

working at Height work, work without anchoring in

hook/line line

(x) Work without 24 Volt supply in Confine space Rs.3000/-per person

(xi) (a) Grinding machine used without safety guard / Rs. 500/- per equipment / per set

machine guard

(b) Unsafe welding machine like open body, Knob

without insulation, connection without lug

(c) Damaged welding cables/gas pipelines

(d) Welding work doing without welding blanket

(e) Electrical supply without 3 pin plug/ Industrial

(f) Use of damaged electrical wire for lighting /

equipments

(g) Use of lighting lamp without cage

(h) Use of open halogen tube

(i) Use of damaged PPEs/use of non standard

(j) Unsafe lifting and handling of gas cylinders

(k) Cylinder handling without safety cap

(l) Temporary connection without ELCB etc.

During plant visit/supervision of concern JE/DE/EE, SE, Safety Officer/Safety Officer/Electrical

Safety Officer and Factory Manager/Occupier, if they will observed any safety violations as per

CO circular/statutory requirements then they must imposed Safety Penalty through office note

directly against contract workers/ contract agency and Office note process through proper

channel to concern Section head and Account head for recovery purpose. Photograph/CCTV

camera footage is to be put up with penalty note by imposed individual officer.

44. Contractor will damage any fire equipments or property or machinery in factory during execution

of work, total damage cost will be recovered from Contractor RA bill and recovery Office note put

up by concern HOD.

45. All the relevant labour and industrial laws shall also be followed compulsorily.

46. After completion of work, cotton waste, grease, oil, unused material, welding rod pieces, scrap

etc. are to be removed by contractor and scrap shall be deposited to scrap yard of Main Store.

47. For performance evaluation of contractor, safety factors of work accident, fire incident & near

miss accident will be considered. Steps can be taken to review the job assignment up to

cancellation for negligence.

48. Over & above these, contractor shall have to follow all the safety requirements /rules &

regulations / norms and legal provisions laid down in various statutes. Particularly the provisions

of The Factories Act-1948 & the Gujarat State Factories Rules-1963 (Amended up to date), The

Electricity Act-2003 & rules, BOCW Act/Rules shall be followed strictly. The contractor shall also

obey the rules / regulations / instructions of the local Competent Authority for safety & health

requirements.

49. The above rules shall be scrupulously followed and where required, Contractor /contractor

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

workers may contact to the Dy.Safety Officer/Safety Officer/Electrical Safety Officer in case of

any ambiguity or needs further guidance in this regard.

GENERALCONDITION AT CONTRACT

1. “Contract” means the documents forming tender and the subsequent agreement that may be

entered in to.

2. “Work” or “Works” means the work related to the subject mentioned in tender.

3. Contractor” means a firm or an individual undertaking these works or offers the rates for this

4. The general rules and regulations of the GSECL for tender and contract for works will apply to

the extent of the same and not modified herein. The contractor is deemed to have gone through

and considered to be fully aware of the conditions mentioned therein.

5. Earnest Money Deposit:

Tender should be submitted along with Earnest Money Deposit (EMD), without which tender is

liable to be rejected.

The exemption in payment of EMD shall be given under following clauses.

1. Micro & small-scale enterprises which participate directly in tendering process for the

product which they are manufacturing / service which they are providing and have

Udyam registration for items / service under procurement.

2. Start-ups which participate directly in tendering process for the product which they are

manufacturing/ service which they are providing and re-cognized by DPIIT under the

Start-up India Program and has obtained Udyam registration.

3. Organization which has registration certificate for the manufacturing product of the

tender, from Gujarat Khadi Gramodyog Board or Khadi and Village Industries

Commission (K.V.I.C) or Commissioner of Cottage Industries.

4. Board/Corporations/PSUs of the Central/ State Government for their own manufactured

5. State Government recognized organizations like (i) organizations for blinds, dumb and

deaf, disabled, mentally disabled persons; (ii) women's self-help group recognized by

Gujarat Livelihood Promotion Company; which participate directly in tendering process

for the product which they are manufacturing / service which /they are providing.

6. Security Deposit:

It is mandatory to submit security deposit before order placement. Contractor shall have to pay

security deposit of 5% of contract value within 10 days from the date of letter of intent. Such

security deposit will be payable either in D.D./ Bank guarantee. Bank guarantees from

scheduled/ nationalized banks will be acceptable if the amount of security deposit payable

exceed Rs 5000/- . The bank guarantee will be excruciated on the standard form prescribe by

the corporation. In case of bank guarantees furnished/ submitted they should have clear one

time validity till the completion of the order in all respects and up to the expiry of the guarantee

period from the date of work completion. Bank guarantee for interim period will not be allowed. If

by any reason the work period is extended than contractor should undertake to renew the bank

guarantee at least one month before the expiry of the validity failing which GSECL will be at

liberty to encash the same.

If the full security amount is not paid immediately after the receipt of the letter of intent,

than the order will not be placed (at the discretion of the GSECL) and without entering to

any correspondence and this will be binding on the tenderer.

If the tenderer fails to pay the security deposit or defaults in execution of the orders place

or if GSECL suffers any financial loss due to this, then GSECL will be liberty to adjust the

amount of others orders of the same firms or by encasing the bank guarantee.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Failure to deposit the S.D. will entail for failure of EMD and the contract shall be treated

as terminated. You shall not be, allow to start the work if, S.D. is not paid. Any loss to the

GSECL due to late start of the work because of the late payment of S.D shall be

contractor‟s liability.

SD will be accepted in form of Bank guarantees issued by ….

[A] Any nationalized bank

[B] Guarantees issued by following banks will be accepted as SD/EMD for the period

up to Dt:31.03.2027. The validity cut-off date In the GR is with respect to the date

of issue of Bank Guarantee irrespective of the date of termination of Bank

Guarantee.

A. All Nationalized banks

B. Guarantees issued by following banks will be accepted for the period up to 31-03-2027.The

validity cutoff date in GR is with respect to date of issue of bank Guarantee irrespective of

the date of termination of Bank Guarantee.

1 Axis Bank 23 AU Small Finance Bank

2 Bandhan Bank 24 City Union Bank

3 CSB Bank. 25 DBS Bank India Limited

4 DCB Bank 26 Dhanlaxmi Bank

5 Equitas Small Finance Bank 27 FEDERAL BANK

6 HDFC Bank 28 HSBC Bank

7 ICICI Bank 29 IDBI Bank

8 IDFC First Bank 30 Induslnd Bank

9 Jammu and Kashmir Bank 31 Jana Small Finance Bank

10 Karnataka Bank 32 Karur Vysya Bank

11 Kotak Mahindra Bank 33 RBL Bank

12 South Indian Bank 34 Standard Chartered Bank

13 Tamil nadu Mercantile Bank 35 Ujjivan Small Finance Bank

14 YES Bank 36 Ahmedabad Mercantile CO-op. Bank

15 Nutan Nagrik Sahakari Bank

37 Rajkot Nagrik Sahakari Bank Ltd.

16 Saraswat Co-Operative Bank

38 SBPP Co-Operative Bank Ltd.

17 SVC Co-Operative Bank Ltd. 39 The Cosmos Co-op bank Ltd.

18 The Gujarat State Co-

40 The Surat District Co-Op. Bank

Operative Bank

19 The Surat People‟s Co-Op. The Baroda Central Co-operative

Bank Ltd. Bank

20 The Panchmahal District Co-

42 The Kalupur Commercial Co-op. Bank

Operative Bank

The Rajkot Commercial Co- The Banaskantha Mercantile Co-opelative

operative Bank Bank Ltd.

22 Gujarat Gramin Bank

In tender process, for L-1 Bidder Security Deposit will be charged as per table below.

Security Deposit

Category of the Unit Purchase Up-to Rs. 5 Purchase of more than

Lakhs Rs. 5 Lakhs

Enterprises or organizations Exempted 3% of order value

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

which are Exempted from

paying tender fee & EMD as

per procurement policy

For all other enterprises 5% of order value 5% of order value

7. The security Deposit/ Bank guarantee covering execution of the contract will be released only on

successful execution of contract and on receipt of the “NO Objection Certificate” from the

Engineer In charge of the work.

8. Sublet or transfer of contract without prior written approval of G.S.E.C.L., will be treated, as

breach of contract and it will be punishable by forfeiting the Security Deposit as well as

termination of contract.

9. The G.S.E.C.L. reserves the right to forfeit the S.D. in case of any breach of contract and in case

of disputes the decision of C.E., G.S.E.C.L Wanakbori T.P.S. shall be final and binding and shall

be acceptable to the contractor. If the contractor fails to start the work as stipulated the EMD and

the SD shall be forfeited.

10. The following are the major obligations to be fulfilled by the Contractors as per the Contract

Labor (R&A) Act 1970 and rule mentioned there under:

1) The contractor should not be allowed to engage fifty or more contract labourers

without initiating to obtain the labour license under the Contract Labour Act from the

Assistant Commissioner of Labour Nadiad (the said number i.e., fifty or more includes

Supervisor and other staff.)

2) The contractors shall have to obtain group insurance under Employee‟s

Compensation Act before starting the work.

3) All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized Bank

compulsory, preferably situated in the premises of Wanakbori TPS area in case of ARC

/BRC works Contract. The Contractor shall supply copy of Bank Statement duly stamped by

the Concerned Bank as a token of proof towards payment of Wages to HR Department. In

Case of Non ARC/ BRC works contract, it is also expected the same practice to be adopt

by the contractor.

4) Payment to contract laborers has to be made through Bank/ Cheque/ RTGS only.

Wages rates for contract laborers are applicable as per the terms and conditions of the

license. The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

5) It should be ensured that all the labours engaged by contractor are covered under

the provident fund scheme and employee‟s pension scheme and their contribution are

remitted regularly to the concerned RPFC. The Xerox copies of challan along with ECR in

this regards should be submitted regularly in G.S.E.C.L. office.

6) In case the contractor having more than one contract in the same TPS, the

contractor shall have to submit contract wise separate list of the workmen to the concerned

7) The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

11. Labour Laws:

The labour laws applicable and amended from time to time have to be followed scrupulously. A

few of them for information are as under:

a) Person below the age of 18 years and above 60 years should not be employed for the work.

b) No female worker shall be employed in the night shift between 7.00 P.M. to 6.00 A.M.

c) The contractor shall maintain a valid labour license under the contract labour (Regulation and

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Abolition) Act for employing necessary man power to be required by contractor. In the

absence of such license the contract shall be liable to be terminated without assigning any

reasons thereof.

d) The contractor shall at his own expense comply with all labour laws and keep the G.S.E.C.L.

Indemnified in respect thereof. Some of the major liabilities under various labour and

industrial laws, which the contractor shall have to comply, which are as under:

I) Payment of contribution by way of employee‟s contribution towards provident fund,

family pension scheme, deposit linked insurance scheme, administrative charge etc., at

the rates made applicable from time to time by Govt. of Gujarat /Govt. of India and other

statutory authorities.

II) Payment of deposit in respect of each contract labour at the rate applicable of with the

offices of Commissioner of Labour as per the contract labour (Regulation and Abolition)

III) License fee as prescribed under the contract labour (Regulation and Abolition) Act and

rules framed there under depending upon the number of workmen employed by

contractor.

IV) Identity cards as prescribed under the factories Act shall be issued to workmen.

VI) Payment of retrenchment compensation, Notice pay and other liabilities as per

Industrial Disputes Act. Any payment to the contractor's employees arising out of any

claim or disputes under the Industrial Dispute Act 1947 or any other labour laws

VI) Payment of compensation in case of accidental injury shall be made as per the WC Act.

VII) If the female workmen are more than 50 numbers engaged then provision of crèches,

shall be complied accordingly.

VIII) Maternity leave as per the provision of the maternity benefit Act.

The above are some of the major liabilities of the contractor in addition to other liabilities

prescribed under the various labour laws in force from time to time from statutory Authorities like

State Government / Government of India, which the contractor shall have to comply with.

12. Provident Fund and Family Pension Scheme:

The contractor shall submit along with his bill (month wise) statement regarding deductions

against employees‟ provident fund and family pension scheme in respect of each concerned

employee. Provident fund and family pension scheme at the rate of 12 % of wages (or at the

rates made applicable by the Government time to time). The contractor‟s contribution and his

workers contribution towards provident fund and family pension scheme shall deposited by the

contractor with Regional Provident Fund Commissioner, Ahmedabad. In case if the contractor

deposits the contribution to the Assistant Provident Fund Commission, the zerox copy of challans

and schedule must be submitted in the office. For maintaining the CPF Account of contractor‟s

employees the contractor will have to pay administrative charges as applicable of the

emoluments of the employer of the contractor's every month.

13. Group Insurance Scheme:

The contractor has to take Group Insurance for all workmen engaged by him and copy of the

same shall be produced to Concerned Officer.

14. Paid Leave Facility:

Paid leave facility at the rate of one day for every 20 days worked by the contract, labour shall be

provided the contractor to his workers. It shall be duly verified and approved/certified by the

authorized officer of the GSECL.

15. The contractor shall employ adequate number of experienced staff at site for daily supervision

and for maintaining of various registers and records required under the law and contracts. No

payment for such supervision shall be admissible.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

16. Contractor to Indemnify the GSECL:

The contractor shall indemnify and keep indemnified the GSECL, and every member, officer and

employees of the GSECL, also Engineer-in-charge and his staff against all actions, proceedings,

claims, demands, costs and expenses whatsoever arising out of or in connection with the matter

referred in above clauses and elsewhere and against all actions, claims demands, cost and

expenses which may be made against the GSECL by any workman/ employees of contractor or

any sub contractor and or from any liability any wise to any workman/employees of the contractor

or sub-contractor under any laws, rules or regulation having in force of law including but not

limited to claims against the owner under workmen compensation Act, 1923. The Employee‟s

Provident Fund Act.1952, and/or the contract labour (Abolition and Regulation) Act,

The GSECL shall not be liable for or in respect of or in consequence of any accident or injury to

any workmen or other person in the employment of the contractor or his sub-contractor, and the

contractor shall indemnify and keep indemnified the GSECL against all such damage and

compensation and against all claims, demands proceedings costs, charges and expenses

whatsoever in respect of or in relation thereto.

17. Workmen’s Compensation Fund and Employer’s Liability Insurance:

Insurance shall be affected for all the contractor‟s employees engaged in the execution of these

contracts. If any of the work is sublet, the contractor shall required the sub-contractor to provide

workmen's compensation and Employer's liability insurance for the latter's employees unless

such employees are covered under the contractor‟s insurance. It shall be liability of contractor

for employees of his sub-contractor.

18. Any other rules and regulations, conditions, circulars etc. that are in force at present and that

may be framed by the GSECL from time to time in connection with the contract will be binding

and acceptable to the contractor.

19. The contractor must possess separate P.F. code for the above subject work.

20. Attendance rolls shall be maintained up to date. All the written registers, Performa etc…shall be

filled up and maintained up to date and kept ready for inspection at any time or submitted in-time

to the concerned authorities as per contract labour etc. Factory Act. etc... By contractor.

21. It is the responsibility of the contractor to ensure that his employees maintain strict discipline as

regards security, methods of safe working etc., and not to cause any hindrance to smooth

running of power station or in execution of duties by GSECL staff. Any lapse in this regard will

be viewed seriously and contract is liable to be terminated. If any of contractor‟s staff is found

unsuitable or not behaving properly, the contractor shall have to remove him from the work-site

on demand by GSECL. The contractor shall have to strictly observe the rules and conditions

specified in the enclosed works contract booklet of the GSECL, which are not modified

hereunder. To keep harmonious Industrial Relations amongst contract labours is the sole

responsibility of the contractor. Any breach of the same will be viewed seriously.

22. Before starting the work, the contractor should contract Industrial Relation Officer/ Labour

Welfare Officer for all formalities and obtaining the gate passes of all contract labourers and for

other formalities.

23. Follow the following procedure at each milestone for the execution of works contract.

(A) On Commencement of Contractual Work:

(1) The Contractors shall have to obtain Photo-Gate-Pass before the commencement of

contractual work awarded. Contractor shall have to apply for the gate passes in triplicate

in a prescribed application form which is to be available from Security Section for the

entry of workmen in the premises.

(2) Such application shall have to be proceed for the approval of Factory Manager. After

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

obtaining approval of Competent Authority, contractor shall have to prepare the Gate

Passes and obtain the signature of Factory Manager.

(3) If Labours are required to be engaged in Emergency during Public Holiday , Contractors

Can apply for Temporary Gate-Pass for the period of only three days with

recommendation of respective EE/SE and the same shall have to be regularized after

following the procedure of Gate Pass applications on the office working day from HR

Department. It is to note that No Temporary Gate-Pass shall be issued for the work other

than acute emergency to carry out the work in power station premises.

(4) The Contractor shall have to obtain the Group Insurance Policy under the Employee

Compensation Act, 1923 prior to commencement of work.

(5) The Contractor who intend to engaged 50 or More than 50 labours to Carry out the

awarded contractual work then necessary - Form No. V under the Contract Labour (R&

A) Act, 1970 / Form No. VI under the Interstate Migrant worker (employment regulation)

rule 1979 as applicable is to be obtained from HR Department for the purpose of

obtaining Labour License from the Licensing Authority.

(B) During Contractual Work under the progress:

(1) Bill Recording Officer of User department shall have to ensure as to whether contractor

has engaged minimum number of contract workmen per day as per the terms of work

(2) All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized Bank

compulsory, preferably situated in the premises of Wanakbori TPS area in case of ARC

/BRC works Contract. The Contractor shall supply copy of Bank Statement duly stamped

by the Concerned Bank as a token of proof towards payment of Wages to HR

Department. In Case of Non ARC/ BRC works contract, it is also advisable the same

practice to be adopted by the contractor.

(3) All Contractors has to comply & maintain statutory documents / registers at site under the

provision of labour laws & EPF Act.

(C) Submission of Statutory documents to ensure the compliances:

The Contractor shall have to submit following statutory documents, work order wise, under the

labour laws and EPF to the recording officer of user department for ensuring the compliances of

provision of labour laws and EPF Act for the respective working period.

site (duly signed & stamp by Contractor ) - Form XVI

 Copy of Wage Payment Sheet – with signature of workmen, duly signed & stamped by

Contractor - Form XVII

 Copy of Bank Statement of Wage Payment (duly signed & Stamp by Concern Bank)

 Copy of PF Challan along with ECR Statement

 Copy of Gate Pass Permission ( duly signed by Authorities ) -

 Copy of Work Order ( First Time )

 Copy of Valid W.C. Policy

 Copy of Valid Labour License ( If Applicable in case of More than 50 manpower

Engaged by Contractor for said work )

 Form No. XIII – Register of workers employed by Contractor

 Form –C – copy of Bonus Register

 Form -19 – copy of Leave with wages Register

Prescribed under the Contract Labour (R&A) Act, 1970 Contractor shall specify the Name of

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Work, Place of Work and Work order number in Muster Roll- Form No. XVI& Wage Register –

Form No XVII.

24. Submission of the bill by the contractor:

Bills shall be submitted by the contractor for each month on or before the date fixed by the Site In

charge, for all works, executed in the previous month and the Site In charge shall take or cause

to be taken the requisite measurement for the purpose or having the same verified and the claim

so far as it is admissible, shall be adjusted, if possible, within ten days from the presentation of

the bills. If the contractor does not submit the bill, within the time fixed, as aforesaid, the Site In

charge may depute a subordinate to measure up the said work in the presence of the contractor

or his duly authorized agent, whose counter signature in the measurement list shall be sufficient

warrant and the Site In charge may prepare a bill from such list which shall be binding on the

contractor in all respect. Along with the R.A. Bill, the contractor should submit material Account

wherever applicable, proof of payment of provident fund and other statutory dues, certificate

issued by I.R.O. / L.W.O certifying average number of labour deployed during the month and

total amount of wages and salaries paid to labour. Payment will be made as per actual work

total amount of wages and salaries paid to labour. Payment will be made as per actual work

done only after taking joint measurement and The contractor will be paid 100 % amount of

actual work done on satisfactory completion of job work .Payment will be released within 30 days

from receipt of recorded bill in all respect as per corporation‟s rules. However, amount of GST

and applicable cess will be kept under retention till submission of documentary proof of payment

of GST or till reflection of payment of GST pertain to respective bill amount in GST return after

due verification.

25. Income Tax:

Income tax will be deducted at source from each bill as per statutory requirements. The GSECL

will be entitled to deduct directly from the bills to be paid to the contractor any sum or sums

payable by the contractor and which sum/sums the GSECL is required to pay as a principal

employer on account of contractor‟s default in respect of all liabilities referred to in above

 No sales tax, professional tax or any other taxes, cess or levy, excise duty, octroi, royalty

or other duties will be payable by the GSECL against this contract.

 Service tax at the rate prevalent during period of execution of contract and if applicable

will be reimbursed on production of certified copy of registration number and paid Challan

for payment of service tax from time to time.

26. The quantities mentioned in the Schedule-B are approximate only and may vary widely. The

contractor shall be paid for the actual works carried out at the rates quoted by him.

27. The TDS @ 2% as per Sections 57A and 57B GST Act shall be deducted from the contractor‟s

28. Compensation for the Delay:

The time allowed for carrying out the work as entered in the tender shall be strictly observed by

the contractor and shall be reckoned from the date on which the order to commence work is

given to the contractor. The work shall throughout the stipulated period of contract be proceeded

with all due diligence (time being deemed to be the essence of contract) and the contractor shall

pay, as compensation, an amount equal to ½ percent or such smaller amounts, as the

Competent Authority (whose decision in writing shall be final) may decide of the amount of the

contracted cost of whole work as shown by the tender for every day that the work remains un-

commenced or unfinished after the proper dates. Provided always that the total amount of

commenced or unfinished after the proper dates. Provided always that the total amount of

compensation, to be paid under the provisions of the clause, shall not exceed 10 percent of the

contracted cost of the work as shown in tender.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

29. Deposit Linked Insurance Scheme:

The contractor shall have to deposit 0.50% (half percent) or the rate applicable from time to time

of the wages in respect of employees who are members of the PF, as the contribution to the

Deposit Linked Insurance Scheme, with the Regional Provident Fund Commissioner,

Ahmedabad.

30. Liability towards Gratuity:

The contractor shall deposit 15 days salary at the rate of last drawn salary for every completed

one year of service for each worker for the liability of gratuity.

31. Minimum Wages Act:

The contractor shall pay prevailing minimum wages as applicable from time to time to the labours

engaged by him as per the minimum wages Act, in presence of the GSECL officer or

representative.

32. E.S.I. Act.:

The contractors shall comply with the provisions of E.S.I. Act wherever applicable as per the

prevailing provisions of the Act and as amended from time to time.

33. Administrative Charges:

Administrative charges for maintaining Provident Fund account shall be deposited by the

contractor with the Regional Provident Fund Commissioner, Ahmedabad, at the rates applicable.

34. Safety:

The contractor shall strictly observe all safety rules and provide safety equipment to the contract

labours as per the Factories Act, 1948, and whatever amendments made from time to time to

avoid any chance of accident. The contractor shall strictly observe all instructions of Safety

Officer and Factory Inspector to avoid any chance of accident.The contractor has to provide

safety articles to his contract labour as per the nature of work they have to perform in the

contract. A certificate in this regard has to be obtained from Safety Officer then the detailed work

order will be issued.

35. Compliance to Security Matters:

The power station being a restricted / prohibited area, all the formalities as required by the

Security and Vigilance staff of GSECL should be complied with, to whom the contractor should

36. Submission of Returns & Maintenance of Records:

The contractor shall submit the returns under the Contract Labour Act, Payment of Bonus Act,

and Payment of Gratuity Act etc. and shall have to maintain all up-to date records/registers in

respect his employees as prescribed under various Labour Laws and produce the same as and

when demanded by GSECL‟s appropriate authorities.

37. Contract agreement & indemnity Bond:

As per Corporation‟s rules, Contractor will have to submit an agreement with the Corporation on

stamp paper of appropriate value Rs.300/- in the prescribed form within one month of receipt of

this A.T. or before starting the work. The cost of the stamp fee shall be borne by you. The tender

with the specification, price schedule, drawing and the contract booklet are to be signed by you.

This letter and subsequent correspondence shall be deemed to be part of the Contract.

Contractor will have to submit an Indemnity Bond also with the corporation on stamp paper of

appropriate value Rs.300/- in the prescribed form before commencement of the work. The cost of

the stamp fee shall be borne by you.

38. The contractor must be maintaining regular labour record and should be paying all acquired

benefits to labour force and contractor should obtain certificates to this effect from Labour

Commissioner.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

39. Because of this contract, the GSECL shall not accept any additional labour liabilities than stated

40. The contractor will make arrangements at his own cost to insure all men, materials and

equipment employed for this work. The GSECL will not be responsible for any loss or damage

either to the contractor‟s personnel or his equipment.

41. Dispute, if any, taking place between the contractor and labourers must be intimated to Labour

Welfare Officer, Wanakbori TPS, immediately.

42. The contractor must insure all the labourers before starting the works.

43. Any casualty will also have to be borne by the contractor for the period the contract continues.

44. The contractor shall not engage any sub-contractor without written prior permission of the Chief

Engineer or the authorized officer of the GSECL. In no case the GSECL will be liable in any

manner regarding any liability in respect of any contract labours engage by the sub-contractor

and the liability of such contract labours will solely rest with the principal contractor.

45. The GSECL reserves the right to terminate this contract at any time during its currency without

giving notice of termination or any reason thereof.

46. In case of default, the work will be got done through other agency / agencies at the risk and cost

of the original contractor, and the GSECL shall be entitled to recover such expenses from

defaulting contractor by such methods as deemed fit. The contractor shall not, however, be

entitled to terminate the contract or stop works undertaken by him before expiry of the contract

period / extended period due to any reason whatsoever.

47. Under the contract, the contractor should either himself be present at the site or should nominate

persons in writing, who must be available at site and who should be authorized to take decisions

about the works and receive the instructions from Site In charge of the work at any time. In

absence of any responsible man of contractor at the time of any emergency, adhoc decision of

Site In charge will be binding on the contractor.

48. The contractor is bound to execute the work for any item as per the instruction of the Site In

charge. On refusal to do so, the work will be carried out at the risk and cost of contractor by

using the contractor‟s tools and tackles, for which no compensation whatsoever shall be payable

to the contractor.

49. If any immovable articles/tools/equipment will be found stolen from the working place, the

contractor would be held responsible and cost will be recovered from his bill.

50. For any conflict and ambiguity, the decision of the Chief Engineer (C&O) shall be final and

binding on the contractor.

51. DISPUTE RESOLUTION MECHANISM:

(1) Amicable settlement

Any dispute, difference, controversy or claim between the Parties arising out of or relating to

this contract with reference to the construction, interpretation, breach, termination or validity

thereof (hereinafter referred as “the Dispute”) shall, upon the written request of either Party

be referred to the authorized representatives of the Disputing Parties for resolution. The

authorized representatives shall promptly meet and attempt to negotiate in good faith a

resolution of the Dispute within thirty days of the service of the request.

(2) Arbitration

If the Parties fail to amicably resolve the disputes or differences or contrary claims as

indicated herewith in sub clause (1) of this Clause, arising under or in connection with the

present Works Contracts, whether pertaining to works contracts alone or works and

Procurement both, the same shall be referred to arbitration under the Gujarat Public works

Contracts Disputes Arbitration Tribunal Act,1992”

52. “D.G.S. & D. Force Majeure Clause”

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

“ If, at any time during the continuance of this contract, the performance in whole or in part by

either Contractor of any obligation under this contract shall be prevented or delayed by reason of

any war, hostility, act of the public enemy, civil commotion, sabotage fires, floods, explosion,

epidemics, quarantine restrictions, strikes lockouts or acts of God ( hereinafter referred to as

event)”, then provided notice of the happening of any such event is given by either Contractor to

the other within twenty one days from the date of occurrence there of neither Contractor shall by

any claim for damage against the other in respect of such non-performance of delay in

performance, and deliveries under the contract shall be resumed as soon as practicable after

such event has come to end or ceased to exist, and the decision of the Managing Director as to

whether the deliveries have been so resumed or not shall be final and conclusive.

Provided further that if the performance in whole or part of any obligation under this contract is

prevented or delayed by reasons of any such event for a period exceeding 60 days, either

Contractor may at its option terminate the contract provided also that if the contract is terminated

under this clause, the Purchaser shall be at liberty to take over from the supplier at a price to be

fixed by the Managing Director of the GSECL, which shall be final, all unused undamaged and

acceptable materials bought out components, and stores in course of manufacture in the

possession of the supplier at the time of such termination or such portion thereof as the

Purchaser may be deem fit excepting such materials, bought out component and stores as the

supplier may with concurrence of the Purchaser elect to retain”.

53. The contractor shall quote rate & also furnish GST, if any, as per Schedule-B. Nothing will be

paid extra as a part of contract unless & until, it is specified in the tender documents by GSECL.

54. The rates quoted shall be firm and valid for 180 days for acceptance from the date of opening.

55. The contractor, if desired, can see the plant and site on any working day and during working

hours with permission of the Chief Engineer.

56. Conditional tender is liable to be rejected withdrawal or insertion of conditions unilaterally after

opening of tenders will not be permitted unless it is so desired by the GSECL.

57. Office correspondence will be carried out in English language, and if at any time to facilitate the

contractor, Gujarati translation may be furnished, if deemed fit. The English version will be the

correct one and the same only will held good for legal matters.

58. The contractor should intimate to the office the name and address of authorized and responsible

representatives, so that our field officers can contact them when required in connection with the

execution of the said works.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Contract Labour Information Management System (CLIMS)

GSECL has developed a Contract Labour Information Management System (CLIMS)- a

comprehensive digital platform designed to manage all activities related to contract labour

transparently and efficiently.

The primary objectives of CLIMS are to save time for both agencies and GSECL personnel, to

ensure full legal and regulatory compliance and to reduce the operational burden on agencies,

allowing them to focus on their core activities. To ensure the successful implementation and

operation of CLIMS, the following guidelines are hereby issued.

A. Gate Pass:

l. CLIMS is a web-based system that can be accessed by agencies from any location using a

desktop, laptop, or mobile device.

2. To begin using the system, agencies must register by entering their EPO (E Urja Order)

number. All other necessary details are automatically fetched from the E-Urja system.

3. The issuance of gate passes for contract labour is managed entirely through CLIMS. Agencies

can generate and track gate passes within the system.

4. In order to enable gate pass issuance, agencies are required to input and upload the

necessary details of their contract labourers into the system.

5. Once the required information is submitted, the gate pass approval process is initiated and

managed through the system. The request automatically moves through the predefined workflow

levels. Agencies can monitor the real-time status of their gate pass applications via CLIMS.

6. Upon completion of all required approvals within the system, the gate pass is issued to the

B. Attendance and wages of workers:

1. Once contract workers gate passes are approved in the system, they are required to be

registered in Bio-Metric/Face Reader Punching machines by HR Department.

2. The attendance of all contract workers can be monitored and maintained through CLIMS by

contractors.

3. Access to data of Bio-Metric is given to agencies. It should be the duty of agencies or his

supervisor to ensure the supply of specified number of manpower and to ensure their Bio-Metric

punching and reporting at the location of work.

4. Attendance register and wage register of the worker will be generated by CLIMS from the login

of agency only.

C. Compliance to various labour laws:

l. All the contractors have to comply various labour laws and they shall submit the attached

Declaration-cum Indemnity Bond before staring of work. This Bond may also be made part of

ensuing tenders/contracts.

2. Contractors shall upload the CLIMS generated previous month attendance sheet, wage register

duly signed by workers, wage bank statement, ECR copy, PF Challan and Remittance slip.

3. The said submitted documents in CLIMS will go to user department, after verification of

completeness of documents, user department will forward it to HR Department for further

verification and approval.

4. If the documents are complete, HR Department will approve in CLIMS and send to Account

Department for further process of bill.

5. If non-compliance is found in submitted documents, it will be returned to user department in

CLIMS with specific remarks and user department will forward it to contractor for compliance. In

such cases, 75% of the bills may be released subject to a maximum ceiling of 20% of the contract

values. Such system of payment shall be allowed only for 3 monthly Running Accounts (RA) bills

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

(Maximum cumulative amount up to 20% of the contract value) of the contractor in a period

contract (AMC) of 12 months or 6 RA bills in a period contract (BMC) of 24 months if there is non-

compliance. All other RA bills and specifically final bill shall not be processed if the previous &

current compliances are not made by contractor. No such relaxation will be granted for non-

periodic, one time or overhauling type contract.

D. Special Case:

In case of work order issued for expert services to PSU or OEM/OES following procedure may be

1. If officers / specialized manpower / expert Engineers from Govt / Semi Govt Companies / PSUs

/ OEM/OES/foreign experts are deployed for short-term, specialized, or ad-hoc technical /

consultancy services (e.g., commissioning, maintenance, consultancy or inspections), concerned

Engineer In-Charge (EIC) shall certify the same

2. The EIC must obtain following documents from the concerned Govt / Semi Govt Companies /

PSUs/OEM/OES etc:

(i) Declaration cum undertaking (As Per Annexure-A) that visiting experts are their regular

employees with documentary proof, and

(ii) Declaration towards compliance of applicable labour laws.

The above documents shall be submitted along with the bill / Invoices by EIC to HR department

for the purpose of HR clearance in lieu of the procedure at Clause -C above.

SIGNATURE OF CONTRACTOR

WITH SEAL & DATE

Chief Engineer (C&O)

GSECL, WTPS

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Annexure A

Declaration –cum-Undertaking

This is to certify and declare that Shri [Employee's Full Name] , son/daughter of [Father's Name], is

a permanent/regular employee of [Company Name], employed in the capacity of [Designation].

His/Her Employee ldentity Card is attached herewith for reference.

It is further declared that his/her Universal Account Number (UAN) under the Employees'

Provident Fund and Miscellaneous Provisions Act, 1952, is IUAN Number] as applicable

We hereby undertake and declare that:

1. We have complied with all applicable provisions of all the labour laws , including but not

limited to the Employees' Provident Fund and Miscellaneous Provisions Act, 1952; the

Employees' State lnsurance Act, 1948; the Payment of Wages Act, 1936; the Payment of

Bonus Act, 1965; the Contract Labour (Regulation and Abolition) Act, 1970; the Minimum

Wages Act, 1948; and other relevant labour and industrial legislations, in respect of Shri

[Employee's Full Name] as applicable to us.

2. We further undertake to produce, as and when required, all statutory records, registers,

Challans , and returns as proof of compliance to the Gujarat State Electricity Corporation

Limited (GSECL) or any other statutory/government authority.

3. We hereby indemnify GSECL in respect of any civil or criminal liability which may arise due

to any non-compliance of the law of the land in respect of our above-mentioned

This Declaration-cum-Undertaking is issued in good faith and to the best of our knowledge and

belief and shall be binding upon us.

Authorised Signatory,

For [Company Name]

[Authorised Signatory Name]

IDesignation]

[Seal/Stamp of Company]

[contact Details]

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Job Safety Analysis sheet

JSA for: Supply and Installation of an Energy Efficient lubricated Rotary screw air

compressor at stage-1 units of Wanakbori TPS; GSECL.

Section: TMD-1

Job Step Hazard Risk Control Measures Responsibility

1. Dismantling of Fall of object High  All job related PPE Contractor &

Existing KG Khosla & person should be use. It‟s Supervisor

Air compressors. from height  Area barricaded.

 Helmet must be used by

2. Lifting & shifting all personal in

new screw barricading area.

compressors form  Close supervision

Main store to required.

site/location Failure of High  Crane / Hydra must be

lifting tools / operated by operator

3. Installation of tackles  Confirm crane/hydra to

new Lubricated be used as per load of

rotary screw air vehicles.

compressors at  Form no 10 must

site/locations. available for lifting

machine is to be used.

Electric High  Electric supply through Contractor &

shock ELCB. It‟s Supervisor

(Electrocution  Industrial plug socket

due to live / should be used.

naked wires)  Three pin used with

earthling wire

connection.

 Three cord cable to be

 Lamp guard to be used.

 Cable cord to be laying

on dry surface only.

Exposure to High  Use PPE Contractor &

eyes  Close supervision It‟s Supervisor

 Area barricaded.

Exposure to High  Use PPE Contractor &

hot surfaces  Close supervision It‟s Supervisor

 Area barricaded.

Injury to High  Load should be hang in

human body vertical direction only.

due to  Hazard due to

unbalancing unbalancing of load

of hanging should be considered

load before dismantling of

any load/ plant structure.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

Lighting in Ramp Electric High  Electric supply through Contractor &

area shock ELCB. It‟s Supervisor

 Industrial plug socket

should be used.

 Three pin used with

earthling wire

connection.

 Three cord cable to be

 Lamp guard to be used.

 Cable cord to be laying

on dry surface only.

 Industrial plug socket

should be used for

extend the supply board.

NOTE: Required check list should be filled up by contractor at time of work

execution.

Prepared by Reviewed by Checked by Approved by

EE Dy. Safety SE Factory Chief Engineer

Officer Manager

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

DECLARATION FORM

ON LETTER HEAD OF SUPPLIER

Subject: Supply and Installation of an Energy Efficient lubricated Rotary screw air

compressor at stage-1 units of Wanakbori TPS; GSECL

Reference No.:- WTPS/S/TECH/RFQ -75447M/TMD-1

I/We hereby declare that I/We have carefully & thoroughly studied the entire tender placed on

the website and General terms & conditions, technical specification, PQR and other

Documents of the tender mentioned under reference along with the Commercial terms and

Conditions.

1. I/We hereby confirm and certify that the offer submitted by me/us is strictly in accordance

with the GSECL‟s Tender specifications, Guaranteed Technical Particulars and drawing as

mentioned in the Tender Specifications. There is no commercial or Technical deviation

(except the deviations shown in respective Annexure-12 of Technical Deviations of this

tender document) in the offer from the Board‟s Tender Specification. I undertake to abide by

the GSECL‟s Technical specification / Guaranteed Technical Particulars / Drawing, I

undertake to supply materials strictly as per the GSECL‟s Technical specification /

Guaranteed Technical Particulars / Drawing, even if any technical deviations are mentioned

by me. I also undertake to abide by all commercial conditions of the GSECL, including

delivery schedule. I have submitted all the annexure-1 to 15,form of integrity pact etc along

with the technical Bid dully filled along with all the details”

2. I / We, hereby declare that our Technical Bid is strictly in line with the Tender specifications

(except the deviations shown in Annexure-12 of Technical Deviations of this tender

document).

3. I / We also agree that additional conditions / deviations, if any, found in the Commercial

terms & conditions (except the deviations shown in Annexure-12 of Technical Deviations of

this tender document) our offer shall be out rightly rejected without assigning any reason

4. I/We hereby abide to execute the contract agreement & submitted the same along with the

acceptance of LOI and the same will be acceptable to me/us.

5. I/We hereby accept and confirm that any dispute on this regard shall not be entertained by

6. The full value of the “Earnest Money Deposit” paid herewith should be absolutely forfeited to

the Corporation, should I/ we do not deposit the specified amount of specified Security

Deposit within 10 Days from receipt of the Letter of Intent.

7. If, I fail to submit all required documents with application or tender copy ( in each tender )

then my tender will be cancelled, which is binding to me.

authorized signatory of M/s ______________________________________________ here

by certify that M/s _________________________________________________ and their

proprietor / any partner / any directors of the firm is not stop deal and / or banned for

business dealing and / or black listed by GUVNL and / or their any subsidiary company viz.

GSECL / GETCO / DGVCL / MGVCL / UGVCL / PGVCL as well as Government and / or

Semi Government company / department.

9. We here by confirm that we have not stake in one or more other agencies / bidders who are

participating in same tender and if it is found that the submitted information / declaration are

wrong in the tender / enquiry as stated in tender terms, than we will be disqualified

automatically &it will be accepted to us. EMD / SD will be forfeited. More over if GSECL

shall take stern action including stop dealing with our firms which is also accepted to us

Seal of the Firm Signature of the Tenderer with Designation.

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page

<On the letterhead of the vendor/ payee>

To, Date : __________

Subject : Declaration for TDS/TCS under the Income Tax Act (IT Act)

Reference : Provisions of S. 206AB/ 206CCA/139AA of the IT Act

Dear Sirs,

This is with reference to the determination of appropriate Tax deduction at source (TDS) or Tax

collected at source (TCS) as per the provisions of the Act i.e. Section 206AB/ 206CCA/139AA of the

IT Act. In relation to the said provision of the Act: I / We, having status of <<mention status i.e.

Individual/Company/ Firm etc.)>>hereby declare and confirm that: -

a) I/We have<<mention PAN>>Permanent Account Number (PAN) under the IT Act.(Copy of

PAN card is enclosed herewith.)

b) I/We have linked / will be linking Aadhar number with PAN as required under section 139AA

(2) read with Rule 114AAA.latest by 30th June

c) I/We have/have not filed income tax returns (ITR) for two previous years immediately prior to

the year in which tax is required to be deducted and for which last date of filing of income tax

return is expired u/s139(1) of the Act.

I/ We am/ are hereby attaching a copy of acknowledgment of ITR filed for any one of

previous two financial years of which due date u/s139(1) is expired, as proof of filing ITR.

(Strike out full sentence if not filed IT returns)

d) The aggregate amount of Tax Deductible at Source (TDS) and Tax Collectible at Source

(TCS) exceed/don‟t exceed Rs. 50,000 or more in each of the two aforesaid previous years

in my/our case (Vendor has to provide the extract of its Form 26AS if copy of ITR is not

provided as above)

e) I/ We shall, indemnify the Company for any consequences arising out of any acts of

commission or omission including incorrect declaration basis which the Company would act

I/We agree that Company shall determine applicability of section 206AB/206CCAof the IT Act

based on the aforesaid declaration/documents filed by me/us and would deduct TDS/TCS

accordingly. The decision of Company shall be final and acceptable to me/us. Strikeout

whichever is not applicable.

Thanking you,

Yours faithfully,

<<Signature>>

< Full Name of Vendor & seal >

BIDDER’S SIGN WITH SEAL

RFQ- 75447M Page