Construction of Masonary Compound wall at different A.M.C Plot possession and demarcation given by Estate Department in CHANDKHEDA WARD Ward OF West Zone.

Name of work: Construction of Masonary Compound wall at different A.M.C Plot possession

and demarcation given by Estate Department in CHANDKHEDA Ward OF West Zone.

Tender Invited on Behalf of AMC, West Zone.

Assistant Manager, West Zone,

Dr. Ramanbhai Patel Bhavan,

Usmanpura, Ahmedabad.

Tender Fee Rs;-

Earnest Money Rs

Contractor’s Name & Address :

AHEMDABAD MUNICIPAL CORPORATION

MEMORANDUM OF WORK IN BRIEF

1. Name of Work : Construction of Masonary Compound wall at different

A.M.C Plot possession and demarcation given by Estate

Department in CHANDKHEDA WARD Ward OF West

2. Tender Estimated Cost : Rs:-

: 1% of the Tender Cost in the form of Rs. 1,50,000.00 (D.D. /B.G.)

3. Earnest Money

4 Tender Fee Rs : Demand Draft of Rs.3600.00

5 S.D. : 5 % of tender amount

6. Time-Limit : 12 months (INCLUDING MONSOON)

7. Validity Period : 120 Days

8. (i) Last Date of Submission of :

(ii) Mode of Sending : a) In Sealed cover in duplicate copies by Registered Post A.D, or by

Courier.or hand delivery

b) Tender sent by ordinary post will be rejected out right.

(iii) Description essential to be : a) Name of work, Tender Notice No. & Tender No.

made on sealed cover b) Date of receiving tender by Corporations.

(iv) Mode of quoting rates in : The Price bid shall be submitted online only.

Schedule of Quantities and Rates It shall not be submitted Physically.

9. Date of Opening : 01/05/2026 Upto 15:00 hrs.

10 Place of Submission & Opening : Submission of EMD. Tender fee and other Documents during office hours: On

of Tender date.01/05/2026 Upto 12:00 hrs.West Zone, 2nd Floor, A.M. Office, Dr.

Ramanbhai Patel Bhavan, Usmanpura.Ahmedabad Municipal Corporation, W.Z.

Office, Ahmedabad-380013.

11 Penalty Due to Delay of work (1) Rs.1000/- per day (for tenders amounting upto 10 Lakhs), (2) Rs.2500 per

day (for tenders amounting above 10 Lakhs and upto 30 Lakhs), (3) Rs.5000 per

day (for all tenders amounting above 30 Lakhs) but not more then 10% of bill

12 Defect Liability : As per ‘B-1 Form Close

Whenever a work is allotted by Engineering staff, whether minor or major of part

thereof of any amount, the contractor shall be bound to start the works within

hours of intimation of work. Communication done telephonically via SMS, Via

Whatsapp and through letter / E-mail shall be considered legal and binding for

the same. Failure of comply to start the works in 48 hours of intimation as above

Time permitted to start parts of

13 by contractor the contractor shall be levied penalty of (1) Rs.1000/- per day (for

tenders amounting upto 10 Lakhs), (2) Rs.2500 per day (for tenders amounting

above 10 Lakhs and upto 30 Lakhs), (3) Rs.5000 per day (for all tenders

amounting above 30 Lakhs). Three times failures by contractor shall make

contractor responsible to be black listed unless and otherwise justified properly in

writing / binding within 15 days of last notice of penalty.

ybœtJtœ Bgwrlrmvj ftuvtuohuNlbtk Ítulj ytuVem/v.J.yu./«tusufx rJCtd îtht htuz/rcÕzekd/jtRx/c{es

GST Ft<tytu îtht cnth vtzJtbtk ytJujt xuLzh sulwk mcbeNl <t.01-07-2017 vAe fhJtlwk &tg Au,<uJt

14 ltKtk Ft<w vhuvºt lk-31 <t:-07-07- <btb xuLzhtubtk <&t nJu vAe Cth vtzJtbtk ytJlth Wvhtuf< rJCtd/Ft<tltk <btb xuLzhtubtk

2017 bwsc (bxehegj+juch mÃjtg mt&u) GST ltk ltuxeVefuNl bwsc GST sgtk jtdw vz<tu ntug ðgtk mœhnwk

ftbltk Bidder yu GST ltuxeVefuNl bwscle yuÃjefucejexe ægtlbtk htFelu huxlwk cezekd fhJtlwk hnuNu.

dwsht< mhfth ©b, ftiNÕg rJftm ylu htusdth rJCtd XhtJ ¢btkf : LED/WRT/e-

dwsht< mhfth ©b, ftiNÕg rJftm ylu

15 file/11/2024/0293/M2 mraJtjg, dtk^eldh, <t.15.02.2024btk mbtrJÐ Nh<tulwk cezh©e yu

vtjl fhJtlwk hnuNu.

• All the circulars which were published by Authorities of AMC time by time will be applicable on

said Tender and bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the rights to

reject any or all the tenders without assigning any reasons thereof.

• The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In case

authorized signatory holding Power of Attorney and Digital Signatory are not the same, the bid shall

be considered non-responsive.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

Engineering Department -chandkheda ward

Name of Work :- Construction of Masonary Compound wall at different A.M.C Plot

possession and demarcation given by Estate Department in CHANDKHEDA Ward OF

Demolition of Brick work and stone masonry

1 25.00 including stacking of serviceable materil as and 544.95 Cu.M.

disposalof unserviceable materials with all lead and

lift.(ii) In Cement Mortar.

S.O.R for Building works 2023-24 Item Code :

20003B Item no. 20.11 Pg no.140

Demolition including stacking of serviceable materilas

2 25.00 and disposal of unserviceable materials with all lead 1047.38 Cu.M.

and lift. (i) R.C.C. work

S.O.R for Building works 2023-24 Item Code : 20002

Item no. 20.3 Pg no.140

Removing and scraping of old deteriorated

plaster of any thickness from wall / R.C.C

3 250.00 member including stacking of serviceable 19.38 Smt

material and disposal of unserviceable from site of

work with all lead and lift

S.O.R for Building works 2023-24 Item Code : 20045

Item no. Pg no.145

Excavation for foundation up to1.5 m depth including

4 4905.00 sorting out and stacking of useful materials and 115.92 Cmt

disposing of theexcavated stuff upto 50 Meter

lead.(A) Loose or soft soil

S.O.R for Building works 2023-24 Item Code :

1.5 to 3.0 mt.depth Cu.M.

S.O.R for Building works 2023-24 Item Code :

Providing and laying cement concrete1:5:10

(1-Cement: 5- coarses sand and:10-hand broken

5 162.00 stone aggregates 40mm nominal size) and 2492.51 Cmt

curing complete excluding cost of formworkin

(A) Foundation and Plinth (upto 10 ton).

S.O.R for Building works 2023-24 Item Code :

05006A Item no. 5.3.4 Pg no.52

Providing and laying controlled cement concrete

6 / Ready Mix Concrete of M-200 and curing

complete, excluding the cost of form work and

reinforcement for reinforced concrete work in:

S.O.R for Building works 2023-24 Item Code :

05024KA Item no. 5.8.2 Pg no.56,57

(A) 392.00 Foundations, footings, base of columns, and mass 3977.88 Cu.M.

(B) 0.00 Walls from top of foundations /level up to floor Four 4484.17 Cu.M.

Slabs,landing,shelves,Balconies Lintels, Beams,

(C) 200.00 Girders and Cantilever upto floor 4460.36 Cu.M.

(D) 90.00 Columns, pillars, posts, and struts, up to floor Four 4558.20 Cu.M.

Staircase up to floor four level. (excluding landing)

Vertical and horizontal fins up to floor four level.

Brick work using common burnt clay building

7 0.00 bricks having crushing strength not less than

35kg./Sq.Cm.in foundation and plinth in Cement

Mortar1:6 (1-Cement :6 - fine sand)

S.O.R for Building works 2023-24 Item Code :

06002AA, 06002BA Item no.6.13 Pg no.70

33.00 (A) Conventional (upto 10 ton) 3981.21 Cmt

27.00 B) Modular 4241.70 Cmt

Extra Rate for brickwork in Above Item for

0.00 super structure above plinth level upto floor two

level (B) Conventional

S.O.R for Building works 2023-24 Item Code :

06006A, 06006B Item no.6.19 Pg no.71

a 575.00 (A) Conventional (upto 10 ton) 4253.46 Cmt

.Providing TMT Bar FE 415 reinforcement for R.C.C.

8 47500.00 work including bending, binding and placing in 66.59 Kg.

position complete up to floor two level (up to 10 ton)

S.O.R for Building works 2023-24 Item Code :

05014BA Item no. 5.4.11 Pg no.54

Providing 15 mm thick cement plaster in single

coat on Rough (Similar) side of single or half brick

9 3440.00 walls for interior plastering up to floor two level 174.83 Sqm

and finished even and smooth in (i) Cement mortar

1:3 (1-cement :3-sand)

S.O.R for Building works 2023-24 Item Code :

17002A Item no.17.6 Pg no.129

Providing 20mm thick sand faced cement plaster on

walls upto height 10 metres above ground level

10 3250.00 consisting of 12mm thick backing coat of C.M. 1:3 (1- 297.68 Sqm

cement : 3-sand) and 8mm thick finishing coat of C.M.

1:1 (1-cement : 1-sand) etc. complete.

S.O.R for Building works 2023-24 Item Code : 17009

Item no.17.95 Pg no.130

Providing and fixing M.S. grills of required pattern

to wooden frames of windows etc. with M.S. flats

11 4500.00 at required spacings and frame alround, square 100.17 kg

or round bars with round headed bolts and nuts or by

screws (A) Plain Grill. (upto 10 ton)

S.O.R for Building works 2023-24 Item Code :

10025AA Item no. 10.1 Pg no.87

Providing form work in ordinary timber planking

so as to give a rough finish including centering,

shuttering, strutting and propping etc. height of

12 propping and centering below supporting floor to

celling not exceeding 4 M & removal of the

same for in situ reinforced or plain concrete work

upto floor four level

S.O.R for Building works 2023-24 Item Code :

a 1530.00 Foundation, footings, bases of columns etc. and 171.68 Smt

(B) Flat surfaces such as soffits of supspened floors

b 0.00 slabs Landings and the like. (1) Floors etc. upto 200 252.00 Smt

mm in thickness.

(B) Flat surfaces such as soffits of suspended floor roof

c 0.00 slabs Landings and the like. (2) Floors etc. above 270.90 Smt

200mm in thickness.

Vertical surface such as walls (any thickness) partitions

d 0.00 and the like including attached buttresses & string 229.95 Smt

course & the like.

(ii) Sides And Soffits Of Beam, Haunchings

e 2255.00 Cantilevers, Girders, Bressumers And Lintels 192.15 Smt

Not Exceeding 1 M In Depth.

f 2000.00 (G) Columns PillarsPosts and struts. (1) Square 297.68 Smt

Rectangular Polygonal in plan.

g 0.00 (2) Circular or curved in plan. 422.10 Smt

(H) (2) Sides and soffits of Beams Beam Haunchings

h 0.00 canti-levers Girders Bressumers and Lintels exceeding 259.88 Smt

Finishing wall with weather proof exterior emulsion

paint on wall surface (two coats) to give an

13 6690.00 required shape even shade after thoroughly brushing 113.40 Sqm

the surface to remove all dirt, and remains of

loose powdered materials.etc complete

S.O.R for Building works 2023-24 Item Code : 19031

Item no. Pg no.139

Filling available excavated earth (excluding rock)

14 5336.00 in trenches, plinth, sides of foundations etc. in layers 129.10 Cmt

not exceeding 20 cm. in depth consolidation each

deposited layer by ramming and watering.

S.O.R for Building works 2023-24 Item Code : 4006

Item no. 4.12 Pg no.48

Conveyance charge of Earth,Lime, Murrum, building

15 554.00 rubbish earch manure or sludge and excavated rock and 235.51 Cu.M.

fly ash,aggregate of any kind etc.comp.upto 5 km

Providing and fixing 1.20 Metre high fencing with

Metre long M.S. Angle posts 40mm x 40 mm x6 mm

and oil painting 3 coats fixed at 2.5 Mt,C/c. with five

16 650.00 Horizontan lines and two diagonals of galvanised steel 385.40 Rmt

barbed wire weighting 9.38 Kg. per 100 Metre, strained

and fixed to posts with G.I,staples including fixing the

postsin ground with 0.5 M x 0.5.M x 0.5 M. block in

C.C1:5:10 etc complete

(in words also)

CONTRACTOR'S SIGNATURE ADDL.CITY ENGINEER

& STAMP (West Zone)

The Rates are Exclusive of G.S.T. Prevaling G.S.T Will be paid Seperatly.

Contractor’s Quoted Rate: -

Net Quoted Tender Amount Rs.

Seal and Signature of the Bidder Addl.City Enginee

Date: (West Zone)

AMC Finance dept. circular No –10,Dt.05/08/2024

(A) A. Guarantees issued by following banks will be accepted as SD/EMD on permanent

basis. All nationalized Banks

(B) B. Guarantees issued by following banks will be accepted as SD/EMD for the period

up to March- 31, 2025. The validity cut-off date in the GR is with respect to the date of

issue of Bank Guarantee irrespective of the date of termination of Bank Guarantee..

1. Commercial Banks :-

1. A U Small Finance Bank

3. Bandhan Bank

4. City Union Bank

6. DBS Bank India Limited

8. Equitas Small Finance Bank

9. Federal Bank

14. IDFC First Bank

15. IndusInd Bank

16. Jana Small Finance Bank

17. Karnataka Bank

18. Karur Vysya Bank

19. Kotak Mahindra Bank

20. South Indian Bank

21. Tamilnadu Mercantile Bank

22. Utkarsh Small Finance Bank

2. Co-operative and Rural Banks Of Gujarat :-

1. The Ahmedabad Mercantile Co-operative Bank Limited

2. Kalupur Commerical Co-operative Bank Limited

3. Nutan nagrik Sahakari Bank Limited

4. Rajkot Nagarik Sahakari Bank Limited

5. Saraswat Co-operative Bank

6. SVC Co-operative Bank

7. The Cosmos co-opretive Bank

8. Baroda Gujarat Gramin Bank

9. Saurashtra Gramin Bank

10. The Gujarat State Co-Operative Bank

11. The Mehsana Urban Co-operative Bank Limited

12. The Surat District Co-operative Bank

13. The Surat Peoples Co-operative Bank

Seal and Signature of the Bidder Addl City Engineer

AHMEDABAD MUNICLPAL CORPORATION

MAHANAGAR SEVA SADAN

DETAILS OF BANK ACCOUT

1 Contractor's name

3 Telephone/ mobile no

4 Permanent account no. (PAN

5 Name of the bank

6 Branch name and address

11 Contractor/ supplier's

signature and stamp

SPECIAL CONDITION OF CONTRACT

1.0 The Contractor shall have to maintain all required registers for quality control, material

management and progress of the work as per the AMC's prevailing circulars and as directed by

engineer- in-charge on daily basis.

1.1 Contractor has to manage proper storage of all the materials.

1.2 Contractor has to use good shuttering material for the project.

1.3 Contractor has to take all risk policy & workman compensation policies of the project & should be

effective up to handing over the possession. Incase of any Incident i.e. fatal accident that occurs at

site, complete responsibility will be of the Contractor.

1.4 Contractor is responsible for all liasioning for seeking all the permission required during the

1.5 Municipal Commissioner reserves the rights to reduce / increase the scope of work up to any extent

without assigning reason thereof and the contractor has to execute the BOQ items at his tender

1.6 All rates quoted by the contractor to be inclusive of all applicable taxes (GST).

1.7 The Contractor shall make his own arrangements for the engagement of all staff and labour, local or

other, and for their payment, housing, feeding, transport and other facilities according to prevailing

1.8 AMC may at its discretion no coplains/no work for a period, single or multiple works at any given

time. once the work is given by SMS, Phonecalls, Whatsapp, Letter; the contractor has to

attend the work within 24 hours. Failure of the same shall invite penalty of 10,000/- per

occurance. Repeated failure of more than 3 times, the contractor shall be blacklisted. No

further claim shall be entertained and the work shall be carried out of current market rate

and supervision charges of 27% at the risk and cost of contractor after the due date of

1.9 All Bidders follow all terms & conditions as per Gujarat sarkr shram, kaushaly vikas nd rojgar

vibhag reso. LED / WRT/e-file/11/2024/0293/M2 Sachivalay, Gandhinagar D: 15.02.2024

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmadabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

GENERAL CONDITION

1. Contractor shall produce the relevant registration certificate of AMC / State Govt /Central Govt.

2. Contractor shall register the work to labour commissioner as per labour act.

3. Contractor shall not sub-let the work without permission of the authority

4. Contractor should have sufficient skilled and unskilled laborers so that he shall start work at

different sites simultaneously. Contractor's having labour force available during festivals shall only

apply. Contractor can not stop the work due to on availably of labour force. In case progress is

delayed, contractor shall be penalized 0.1% of Tender amount per day for work done after time

limit, maximum up to 10% for remaining work.

5. Bitumen rate difference will be paid as per tender conditions, if applicable.

6. Advance payment / machinery advance will not be paid.

7. Payment of running bill will be made as per recent A.M.C. policy in force.

8. No extra payment will be made due to increase of central / state Govt. Taxes.

9. If the work is not completed within time limit the penalty will be recovered from immediate bills of

10. If the material i.e. MH cover C.C block etc. supplied from Municipal Corporation store then

contractor shall not claim for any extra rate for non execution of such item, partly/fully.

11. In the specifications, "as directed"/"Approved" shall be taken to mean, "as directed"/approved" by

the Engineer-in-charge.

12. Wherever a reference to any Indian Standard appears in the specifications, it shall be taken to

mean as a reference to the latest edition of the same in force on the date of agreement.

13. In "Mode of Measurement" in the specifications wherever a dispute arises in the absence of specific

mention of a particular point or aspect, the provisions on these particular points, or aspects in the

relevant Indian Standards shall be referred to.

14. All measurements and computations, unless otherwise specified, shall be carried out nearest to the

following limits:

(i) Length, width and depth (height)------- 0.01 Meter.

(ii) Areas -----0.01 Sq. Mt.

(iii) Cubic Contents ------0.01 Cu.Mt.

15. The distance, which constitutes lead, shall be determined along the shortest practical route and not

necessarily the route actually taken. The decision of the Engineer-in-charge in this regard shall be

taken as final.

16. Where no lead is specified, it shall mean "all leads"

17. Lift shall be measured from plinth level.

18. Definite particulars covered in the items of work, through not mentioned or elucidated in it,

specifications shall be deemed to be included there in.

19. Reference to specifications of materials as made in the detailed specification of the items of work is

in the form of a designation containing the number of the specification of the material and prefix

20. Approval to the samples of various materials given by the Engineer-in-charge shall not absolve the

contractor from the responsibility of replacing defective material brought on site or materials used

in the work found defective at a later date.

21. The contract rate of the item of work shall be for the work completed in all respects.

22. No collection of materials shall be made before it is got approved from the Engineer-in-charge.

23. Collection of approved materials shall be done at site of work in a systematic manner. Materials

shall be stone at site of work in a systematic manner. Materials shall be stored in such a manner as

to prevent damage, deterioration or intrusion of foreign matter and to-ensure the preservation of

their quality and fitness for the work.

24. Materials, if and when rejected by the Engineer-in-charge, shall be immediately removed from the

site of work within 24 hours.

25. No materials shall be stored prior to, during and after execution shall be kept in sufficient numbers

and in good working condition on the site of the work.

26. All works shall be carried out in workmanlike manners per the best techniques for the particular

27. All tools, templates, machinery and equipment for correct execution of the work as well as for

checking lines, levels, alignment of the works during execution shall be kept in sufficient numbers

and in good working condition on the site of the work.

28. The mode, procedure and manner of execution shall be such that it does not cause damage or over

loading of the various components of the structure during execution or after completion of the

29. All necessary safety measures and precaution (including those laid down in the various relevant

Indian Standards) shall be taken to ensure the safety of men, materials and machinery on the works

as also of the work itself.

30. The testing charges of all materials shall be borne by the Contractor unless recovery at one percent

towards testing charges is separately made.

INSTRUCTION TO TENDERERS

TENDER VALIDITY PERIOD:

The tender shall be kept valid for acceptance for a period of One Hundred Twenty Calendar days

(120) from opening of price bids.

SECURITY DEPOSIT

Within 10 days of receipt of Acceptance from the Corporation, the successful tender shall furnish to

the Corporation Security Deposit of 5% (five percent) of the contract price cheque or Bank

Guarantee, pay order, or demand draft of Nationalized Banks and Schedule Banks only.

CONTRACTOR'S SIGNATURE ADDL.CITY ENGINEER

& STAMP (West Zone)

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

GENERAL SPECIFICATION

Time limit for the work shall be 12 Months after the order to start the works. Progress of work should be in

proportion to time limit.

The contractor shall be remain responsible for Workmen’s compensation if any accident. The contractor shall

arrange for barricading at night and arrangement of Pagi at night to direct the traffic. He shall be responsible for

any damage to public. If any incident happen, during the execution of work. In case of dispute for unseen or

overlooked items the decision of the Dy. City Engineer shall be final. The contractor shall have to give site clean

of all rubbish during the work and at the time of completion of work and hand over the site with final finishing

of the work as directed. All the rejected materials shall be removed from site within 24 hours by contractor at

this risk and cost. Debris shall have to cart daily from site.

If any extra item crops up during the progress of work the same shall be carried out by the contractor and he

shall be paid at the rate fixed by Add.C.E. as per the rate analysis based on latest SOR or if item is not available

in SOR than based on current market rates. In case of extra item decision of Add. City Engg. shall remain final

regarding rate.

If in the interest of the Corporation it is necessary to change either any site or the design of the propose work

the contractor shall carry out the same at his quoted rates without charges any extra and the contractor will

have to carry out the works and he will be paid at the rate quoted by him. No claim for extra rate for

subsequent changes in site and design is entertained.

Octroi exemption passes shall not be given for any materials required for the work. Contractor will be fully

responsible for compliance of the various provisions under contract Act. 1970 and the Rules framed the to

The tender for the work shall remain open for a period (120) days from the date of opening of the tenders for

this work and that the tenderer shall not be allowed to withdraw on modify the offer on his own during the

period. If any tenderer withdraw or makes any modifications or addition in the terms and conditions of his

tender not acceptable to the Municipal Corporation the Municipal Corporation shall without prejudice to any

right or remedy be at liberty to forfeit in full the said earnest money and black list the contractor.

If the work is not carried out within the specified time limit. from the date of order to start the work the penalty

of Rs.- ( As per Form - B1) per day of delay shall be recovered from the immediate bills payable to the

contractor. Contractor has to make his own arrangement for procurement of steel and cement.

Contractors should note the following conditions carefully:-

i) Conditional tender shall not be accepted.

ii) All tenders are to be submitted in duplicate without which the tenders are liable to be rejected.

iii) In case of tender downloaded from website, tender fee & EMD should be submitted in form of

demand draft or in cash.

iv) Condition of Form - B1 Standard Specification of material & code of practice will be applicable.

Form B1 can be is available in website. Specification shall be as per ' R& B Dept. - Govt. of Gujarat

booklets of Building Works & and Road Works Specifications published by Gujarat Book Depot, Sector-

21. Gandhinagar.

CONTRACTOR'S SIGNATURE ADDL.CITY ENGINEER

& STAMP (West Zone)

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

STANDARD DETAILED TECHNICAL SPECIFICATION OF ITEMS

Name of Work: Construction of Masonary Compound wall at different A.M.C Plot possession and

demarcation given by Estate Department in CHANDKHEDA WARD Ward OF West Zone.

Demolition of Brick work and stone masonry including stacking of serviceable materil as and

disposalof unserviceable materials with all lead and lift.(ii) In Cement Mortar.

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of Cmt

The rate shall be for a unit of Cmt

Demolition including stacking of serviceable materilas and disposal of unserviceable materials with all

lead and lift. (i) R.C.C. work

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of Cmt

The rate shall be for a unit of Cmt

Removing and scraping of old deteriorated plaster of any thickness from wall /

R.C.C member including stacking of serviceable material and disposal of unserviceable from

site of work with all lead and lift

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of Smt

The rate shall be for a unit of Smt

Item No. 4 Excavation for foundation upto 1.5 M depth including sorting out and stacking useful materials

disposing of the excavated stuff upto 50 meter lead in loose or soft soil.

Any soil which generally yields to the application of ackaxes and shoves, phawaras rakes or any

such ordinary excavating implement or organic soil, gravel silt, sand turfloam, clay, peat etc., fall

under this category.

Clearing the site :

The site on which the structure is to be built shall be cleared and all obstructions, loose stone,

materials and rubbish of all kind, bush, wood and trees shall be removed as directed. The

materials so obtained shall be property of the Government and be conveyed and stacked as

directed. within 50 M. lead. The roots of the trees coming in the sides shall be cut and coated with

The rate of site clearance is deemed to be included in the rate of earth work for which no extra will

After clearing the site, the center lines will be given by the Engineer-in-charge. The contractor shall

assume full responsibility for alignment, elevation and dimension of each and all parts of the work.

Contractor shall supply laborers, materials, etc. required for setting out the reference marks and

bench marks and shall maintain them as long as required and directed.

The excavation in foundation shall be carried out in true line and level and shall have the width

and depth as shown in the drawings or as directed. The contractor shall do the necessary shoring

and shutting or providing necessary slopes to a safe angle, at his own-cost. The payment for such

precautionary measures shall be paid separately if not specified. The bottom of the excavated

area shall be 1 evened both longitudinally and transversely. as directed by removing and watering

as required. No earth filling will be allowed for bringing it to level, if mistake or any other reason

excavation is made. deeper or wider that shown on the plan or directed. The extra depth or width

shall be made up with concrete of same proportion as specified for the foundation concrete at the

cost of the contractor. The excavation up to 1.5 m. depth shall be measured under this item.

Disposal of the excavated stud :

The excavated stuff of the selected type shall be used in filling the trenches and plinth or leveling

the ground in layer including ramming and watering etc.

The balance of the excavated quantity shall be removed by the contractor from the site of work to

a place as directed with lead upped 50 M. and all lift.

Mode of measurement and payment :

The measurement of excavation in trenches for foundation shall be made according to the

sections of trenches shown on the drawing or as per sections given by the Engineer-in-charge. No

payment shall be made for surplus excavation made in excess of above requirements or due to

slopping and sloping back as found necessary on account of conditions of soil , and requirements

The rate shall be for a unit of one cubic meter.

Item No. 4aExcavation for foundation for depth from 1.5 m to 3.0 m including sorting out

and stacking of useful materials and disposing off the excavated stuff upto 50 Meter

lead.(C) Hard Murrum

The rate shall be for a unit of one cubic meter.

Providing and laying cement concrete1:5:10 (1-Cement: 5-coarses sand and:10-hand broken stone aggregates 40mm

nominal size) and curing complete excluding cost of formworkin (A) Foundation and Plinth (upto 10 ton)

1.0 Materials: Water shall conform to M-1. Cement shall conform to M-3. Sand shall conform to M-6, Grit shall

conform to M-8 Graded stone aggregate 20 mm nominal size shall conform to M-12.

2.1 The concrete mix is not required to be designed by preliminary tests. The proportion of the concrete

mix shall be 1:2:4 (1 cement :2 coarse sand : 4 graded stone aggregate 10 mm nominal size) by volume.

Concrete work shall have exposed concrete surface or as specified in the item.

2.2 The designation ordinary M-100, M-150, M-200, M-250 specified as per I.S Correspond

approximately to 1:3:6, 1:2:4, 1 1/2 :3 and 1:1:2 nominal mix of ordinary concrete by volume respectively.

2.3 The ingredients required for ordinary concrete containing one beg of cement of 50 Kg. by weight

(0.0342 Cu. M) for different proportions of mix shall be as under:

Grade of Total quantity of dry Proportion of fine Quantity of

concrete aggregate by volume aggregate to coarse water per

per 50 Kgs, of cement aggregate 50 Kgs. of

to be taken as the cement

sum of individual maximum.

volume of fine and

coarse aggregates,

M-100 (1:3:6) 300 Liters Generally 1:2 for fine 34 Liters

M-150 (1:2:4) 220 ” aggregate by volume but 32 “

M-200 (1:1 1/2 :3) 160 “ subject to and upper 30 “

M-250 (1:1:2) 100 “ limit of 1:1/2 and lower 27 “

2.4 The water cement ratios shall not more than those specified in the above table. The cement content of

the mix specified in the Table shall be increased if the quantity of water in a mix has to be increased to

overcome the difficulties of placement and compaction so that the water cement ratio specified in the Table is

2.5 Work ability of the concrete shall be controlled by maintaining a water cement ratio that is bound to

give a concrete mix which is just sufficiently wet to be placed and compacted without difficulty with the means

2.6 the maximum size of coarse aggregate shall be as large as possible within the limits specified but in

no case greater than surround all reinforcement thoroughly and to fill the corners of the form.

2.7 For reinforced concrete work, coarse aggregates having a nominal size of 20mm are generally

considered satisfactory.

2.8 For heavily reinforced concrete members as in the case of ribs of main beams the nominal maximum

size of coarse aggregate should usually be restricted to 5 mm less than the minimum clear distance between

the main bars, or 5 mm less than the minimum cover to the reinforcement whichever is smaller.

2.9 Where the reinforcement is widely spaced as in solid slabs, limitations of size of the aggregate may

not be important and the nominal maximum size may sometimes be as greater than the minimum cover.

2.10 Admixture may used in concrete only with approval of Engineer-in-charge based upon the evidence

that with the passage of time, neither the compressive strength of concrete is reduced nor are other requisite

qualities of concrete and steel impaired by the use of such admixtures.

3.0 Workmanship:

3.1 Proportioning: Proportioning shall be done by volume, except cement which shall be measured in

terms of bags of 50 Kg. weight. The volume of one such bag being taken as 0.0342 Cu. Meter. Boxes of

suitable sizes shall be used for measuring sand aggregate. The size of the boxes (internal) shall be 35 cms x

25 cms. and 40 cms deep. White measuring the aggregate and sand, the box shall be filled without shaking

ramming or hammering. The proportioning of sand shall be on the basis of its dry volume and in case of damp

sand, allowances for bulkage shall be made.

3.2.1 For all work, concrete shall be mixed in a mechanical mixer which along with other

accessories shall be kept in first class working condition and so maintained throughout the construction.

Measured quantity of aggregate, sand, cement required for each batch shall be poured into the drum of the

mechanical mixer while it is continuously running. After about half a minute of dry mixing, measured quantity

of water required for each batch of concrete mix shall be added gradually and mixing continued for another

one and half a minute. Mixing shall be continued till materials are uniformly distributed and uniform color of the

entire mass is obtained and each individual particle of the coarse aggregate shows complete coating of mortar

containing its proportionate amount of cement. In no case shall the mixing be done for less than 2 minutes

after all ingredients have been put into the mixer.

3.2.2 When hand mixing is permitted by the Engineer-in-charge for small jobs or for certain other

reasons, it shall be done on the smooth watertight platform large enough to allow efficient turning over the

ingredients of concrete before and after adding water. Mixing platform shall be so arranged that no foreign

material gets mixed with concrete nor does the mixing water flow out. Cement in required number of bags

shall be placed in a uniform layer on top of the measured quantity of fine and coarse aggregate, which shall

also be spread in a layer of uniform thickness on the mixing platform. Dry coarse and fine aggregate and

cement shall then be mixed thoroughly by turning over to get a mixture to uniform color. Specified quantity of

water shall then be added gradually through a rose-can and the mass turned over till a mix of required

consistency is obtained. In hand mixing quantity of cement shall be increased by 10 percent above that

3.2.3 Mixers which have been out of use for more than 30 minutes shall be thoroughly cleaned

before putting in a new batch. Unless otherwise agreed to by the Engineer-in-charge the first batch of

concrete from the mixture shall contain only two thirds of normal quantity of coarse aggregate. Mixing plant

shall be thoroughly cleaned before changing from one type of cement to another.

3.3 Consistency :

3.3.1 The degree of consistency which shall depend upon the nature of the work and methods of vibration of

concrete, shall be determined by regular slump tests in accordance with I.S. 1199-1959. The slump of 10mm

to 25mm. shall be adopted when vibrators are used and 80mm when vibrators are not used.

3.4 Inspection:

3.4.1 Contractor shall give the Engineer-in-charge due notice before placing any concrete in the

forms to permit him to inspect and accept the false work and forms as to their strength, alignment, and general

fitness but such inspection shall not relieve the contractor of his responsibility for the safety of men,

machinery, materials and for results obtained. Immediately before concreting, all forms shall be thoroughly

3.4.2 Centering design and its erection shall be got approved from the Engineer-in-charge. One

carpenter with helper shall invariably be kept present throughout the period of concreting. Movement of labour

and other persons shall be totally prohibited for reinforcement laid in position. for access to different parts,

suitable mobile platforms shall be provided so that steel reinforcement in position is not disturbed. For

ensuring proper cover, mortar blocks of suitable size shall be provided so that steel reinforcement in position

is not disturbed. For ensuring proper cover, mortar blocks of suitable size shall be cast and tied to the

reinforcement. Timber kapachi or metal pieces shall not be used for this purpose.

3.5 Transporting and laying:

3.5.1 The method of transporting and placing concrete shall be as approved. Concrete shall be so

transported and placed that no contemination, segregation or loss of its constituent material takes place.

All form wok shall be cleaned and made free from standing water, dust, show or ice immediately before

placing of concrete.

No concrete shall be placed in any part of the structure until the approval of the Engineer-in-charge has been

3.5.2 Concreting shall proceed continuously over the area between construction joints. Fresh

concrete shall not be placed against concrete which has been in position for more than 30 minutes unless a

proper construction joint is formed. Concrete shall compacted in its final position within 30 minutes of its

discharge from the mixer. Except where otherwise agreed to by the Engineer-in-charge concrete shall be

deposited n horizontal layers to a compacted depth of not more than 0.45 meter when internal vibrators are

used and not exceeding 0.30 meter in all other cases.

3.5.3 Unless otherwise agreed to by the Engineer-in-charge, concrete shall not be dropped into

place from a height exceeding 2 meters. When trunking or chutes are used they shall be kept close and used

in such a way as to avoid segregation. When concreting has to be resumed on a surface which has hardened,

it shall be roughened, swept clean, thoroughly wetted and covered with a 13 mm thick layer of mortar

composed of cement and sand in the same ratio as in the concrete mix itself. This 13 mm layer of mortar shall

be freshly mixed and placed immediately before placing of new concrete. Where concrete has not fully

hardened, all laitance shall be removed by scrubbing the wet surface with wire or bristle brushes, care being

taken to avoid dislodgment of any particles of coarse aggregate. The surface shall then be thoroughly wetted,

all free water removed and then coated with neat cement grout. The first layer of concrete to be placed on this

surface shall not exceed 150 mm in thickness and shall be well rammed against old work particular attention

being given to corners and close spots.

3.5.4 All concrete shall be compacted to produce a dense homogeneous mass with the assistance

of vibrators, unless, otherwise permitted by the Engineer-in-charge for exceptional cases, such as concreting

under water, where vibrators cannot be used. Sufficient vibrators in serviceable condition shall be kept at site

so that spare equipment is always available in the event of breakdowns.

Concrete shall be judged to be compacted when the mortar fills the spaces between the coarse aggregate

and begins to cream up to form an even surface. Compaction shall be completed before the initial setting

starts i.e. within 30 minutes of addition of water to dry mixture. During compaction, it shall be observed that

needle vibrators are not applied on reinforcement which is likely to destroy the bond between concrete and

3.6 Curing: Immediately after compaction, concrete shall be protected from weather including rain,

running water, shocks, vibration, traffic, rapid temperature changes, frost and drying out process. It shall be

covered with wet sacking, hassain or other similar absorbant material approved, soon after the initial set and

shall be kept continuously wet for a period of not less than 14 days from the date of placement. Masonary

work over foundation concrete may be started after 48 hours of its laying but curing of concrete shall be

continued for a minimum period of 14 days.

3.7 Sampling and Testing of concrete:

3.7.1 Samples from fresh concrete shall be taken as per I.S. 1199-1959 and cubes shall be made,

cured and tested at 7 days or 28 days as per requirements in accordance with I.S. 516-1959. A random

sampling procedure shall be adopted to ensure that each concrete batch shall have a reasonable chance of

being tested i.e. the sampling should be spread over the entire period of concreting and cover all mixing units.

The minimum frequency of sampling of concrete of each grade shall be in accordance with following:

Quantity of concrete No. of Quantity of concrete in No. of samples

in the work samples the works

51 and above 4+ one additional for each additional 50 M. or part thereof.

NOTE : At least one sample shall be taken from each shift. Ten test specimens shall be made from each sample, five

for testing at 7 days and the remaining five at 28 days. The samples of concrete shall be taken on each day of

the concreting as per above frequency. The number of specimens may be suitably increased as deemed

necessary by the Engineer-in-charge when procedure of tests given above reveals a poor quality of concrete

and in other special cases.

3.7.2 The average strength of the group of cubes cast for each day shall not be less than the

specified cube strength of 150 Kg/Cm at 28 days. 20% of the cubes cast for each day may have value less

than the specified strength provided the lowest value is not less than 85% of the specified strength. If the

concrete made in accordance with the proportions given for a particular grade, does not yield the specified

strength; such concrete shall be classified as belonging to the appropriate lower grade. Concrete made in

accordance with the proportions given for a particular grade shall not, however, be placed in a higher grade

on the ground that the test strength are higher than the minimum specified.

3.8.1 The Engineer-in-charge shall be informed in advance by the contractor of his intention to

strike the form work. While fixing the time for removal of form work, due consideration shall be given to local

conditions, character for the structure, the weather and other condition that influence the setting of concrete

and of the materials used in the mix. In normal circumstances (generally where temperatures are above

C) and where ordinary concrete is used, forms may be struck after expiry of periods specified in item No

9.1(A) for respective item of form work.

3.8.2 All form work shall be removed without causing any shock or vibration as would damage the

concrete. Before the soffit and struts are removed, the concrete surface shall be exposed, where necessary in

order to ascertain that the concrete has sufficiently hardened. Centering shall be gradually and uniformly

lowered in such manner as to permit the concrete to take stresses due to its own weight uniformly and

gradually. Where internal metal ties are permitted, the or their removable parts shall be extracted without

causing any damage to the concrete and remaining holes filled with mortar. No permanently embedded metal

part shall have less than 25 mm cover to the finished concrete surface. Where it is intended to re-use the form

work, it shall be cleaned and made good to the satisfaction of the Engineer-in-charge. After removal of form

work and shuttering, the Executive Engineer shall inspect the work and satisfy by random checks that

concrete produced is of good quality.

3.8.3 Immediately after the removal of forms, all exposed bolts etc., passing through the cement

concrete member and used for shuttering or any other purpose shall be cut inside the cement concrete

member to a depth of at least 25 mm below the surface of the concrete and the resulting holes be filled by

cement mortar. All fine caused by form joints, all cavities produced by the removal of form ties and all other

holes and depressions honeycomb spots, broken edges or corners and other defects shall be thoroughly

cleaned, saturated with water and carefully pointed and rendered true with mortar of cement and fine

aggregate mixed in the proportions used in the grade of concrete that is being finished and of as dry

consistency as is possible to use. Considerable pressure shall be applied in filling and pointing to ensure

thorough filling in all voids. Surfaces which are pointed shall be kept most for a period of 25 hours.

If rock pockets/honeycombs in the opinion of the Engineer-in-charge are of such an extent or character as to

effect the strength of the structure materially or to endanger the life of the steel reinforcement, he may declare

the concrete defective and require the removal and replacement of the portion of the structure affected.

4.0 Mode of measurement and payment:

4.1 The consolidated cubical contents of concrete work as specified in item shall be measured. The

concrete laid in excess of section shown on drawings or as directed shall not be measured. No deduction shall

(a) Ends of dis-similar materials such as joints, beams, posts, girders, rafters, purline trusses, corbels and

steps etc. up to 500 Sq. Cm. in section.

(b) Opening up to 0.1 Sq. M.

4.2 The rate includes cost of all materials, labour, tools and plant required for mixing, placing in position,

vibrating and compacting, finishing, as directed, curing and all other incidental expenses for producing

concrete of specified strength. The rate excludes the cost of form work.

4.3 The rate shall be for a unit of one cubic meter.

5.4.1 Providing and laying cement concrete 1:2:4 (1 cement : 2 coarse sand : 4 graded stone aggregate 20 mm

nominal size) and curing complete excluding cost of form work and reinforcement for reinforced concrete work

(A) Foundation footing, base of columns and mass (B) Slabs, landings, shelves, balconies, internals beams

girders and cantilever up to floor two level (C) Columns, pillars, posts and struts up to floor two level (D)

Staircase up to floor two level (E) Vertical and horizontal fins up to floor two level.

1.0 Materials & Workmanship

1.1 The relevant specification of item No. 5.3.13 shall be followed except that the work shall be carried out

for reinforced concrete work for work as specified in item 1.2. In addition, the following stipulations shall be

(a) The bars shall be kept in position by the following methods:

(i) In case of beam and slab construction, sufficient number of precast cover blocks in cement mortar

1:2 (1 cement : 2 coarse sand) about 4 cms x 4 cms section and of thickness equal to the specified cover shall

be placed between the bars and shuttering as to secure and maintain the requisite cover of concrete over the

In case of cantilevered or doubly reinforce beams of slabs, the main reinforcing bars shall be held in position

by introducing chain spacers or supports bars at 1.0 to 1.2 meters centers.

(ii) In case of columns walls, the vertical bars shall be kept in position by means of timber temphtes with

slotes accurately out in them. The temphtes shall be removed after concreting has been done below it. The

bars may also be suitably tied by means of annealed steel wires to the shuttering to maintain their position

during concreting.

1.2 All bars projecting from pillars, columns beams, slabs etc., to which other bars and concrete are to be

attached or bounced to later on, shall be protected with a coat of thin neat cement grout, if the bars are not

likely to be incorporated with succeeding mass of concrete within the following 10 days. This coat of thin neat

cement shall be removed before concreting.

2.0 Mode of measurement and payment:

2.1 Relevant specifications of item No. 5.3.13 shall be followed.

2.2 The volume occupied by reinforcement shall not be deducted from R.C.C. work.

2.3 The rate shall be for a unit of one cubic meter.

Providing and laying controlled cement concrete / Ready Mix Concrete of M-200 and curing

complete, excluding the cost of form work and reinforcement for reinforced concrete work in:

Work should be done as per instruction of Engg. In charge.

Mode of Measurement shall be on cubic meter basis.

Brick work using common burnt clay building bricks having crushing strength not less than 35kg./Sq.Cm.in

foundation and plinth in Cement Mortar1:6 (1- Cement :6 - fine sand) (A) Conventional (upto 10 ton)

Materials: Water shall conform to M-1 Cement shall conform to M-3 Sand shall conform to M-6. Brick

shall conform to M-15 Cement mortar shall conform to M-11.

The proportion of the cement mortar shall be 1:6 (1 cement : 5 fine sand) by volume.

Wetting of bricks:

The bricks required for masonry shall be thoroughly wetted with clean water for about two hours before use

or as directed. The cessation of bubbles, when the bricks are wetted with water is an indication of through

wetting of bricks.

Bricks shall be laid in English bond unless directed otherwise. Half or cut bricks shall not be used except

when necessary to complete to bond; closer in such case shall be cut to required size and used near the ends

A layer of mortar shall be spread on full width for suitable length of the lower course. Each brick shall first

be properly bedded and set home by gently tapping with handle of trowel or wooden mallet. It side face shall

be flushed with mortar before the next brick is laid and pressed against it. On copletion of course, the

vertical joints shall be fully filled form the top with mortar.

The walls shall be taken up truly in plumb. All courses shall be laid truly horizontal and all vertical joint

shall be truly vertical. Vertical joints in alternate course shall generally be directly one over the other. The

thickness of brick course shall be kept uniform.

The brick shall be laid with frog upwards. A set of tools comprising of wooden straight edges, mason’s sprit

level, square half meter rub, and pins, string and plumb shall be kept on the site of work for frequent

checking during the progress of work.

Both the faces of walls of thickness greater than 23 cms shall be kept in proper place. All the connected

brick work shall be kept not more than one meter over the rest of the work. Where this is not possible, the

work shall be raked back according to bond (and not left toothed) at an angle not steeper than 45 degrees.

All fixtures, pipes, outlets of water, hold fasts of doors and windows etc. which are required to be built in

wall shall be embedded in cement mortar.

Bricks shall be so laid that all joints are quite flush with mortar. Thickness of joins shall not exceed 12 mm.

The face joints shall be raked out as directed by taking tools daily during the progress of work, when the

mortar is still green so as to provide key for plaster or pointing to done.

The face of brick shall be cleaned the very day on which the brick work is laid and all mortar dropping

Green work shall be protected from rain suitably. Masonry work shall be kept moist on all the faces for a

period seven days. The top of masonry work shall be kept well wetted at the close of the day

Preparation of foundation bed:

If the foundation is to be laid directly on the excavated bed, the bed shall be leveled, cleared of all loose

materials, cleaned and wetted before starting masonry. If masonry is to be laid on concrete footing, the top

of concrete shall be cleaned and moistened. The contractor shall obtain the engineer'’ approval for the

foundation bed, before foundation masonry is started. When puccas flooring is to be provided flush with the

top to plinth, the inside plinth offset shall be kept lower than the outside plinth top by the thickness of the

Mode of measurements and payment:

The measurements of this item shall be taken for the brick masonry fully completed in foundation up to

plinth. The limiting dimensions not exceeding those shown on the plans or as directed shall be final.

Battered, tapered and curved portions shall be measured net.

No deduction shall be made from the quantity of brick work nor any extra payment made for embedding in

masonry or making holes in respect of following items:

Ends of joints, beams, posts, girders, rafters, purlins, trusses, corbel steps etc. where cross sectional area

does not exceed 500 Sq. cm.

Opening not exceeding 1000 Sq. cm.

Wall plates and bed plates, bearing of slabs, chhajas an the like whose thickness does not exceed 10 Cms.

and the bearing does not extend to the full thickness of wall.

Drainage holes, and recesses for cement concrete blocks to embed hold fasts for doors, windows etc.

Iron fixtures, pipes up to 300 mm dia hold fasts and doors and windows built into masonry and pipes etc. for

concealed wiring.

Forming chases of section not exceeding 350 Sq. Cm. in masonry.

Apertures for fire places shall not be deducted nor shall extra labour required to make splaying of jambs,

throating and making Arches over the aperture be paid for separately.

The rate shall be for a unit of one cubic meter.

Extra for brickwork in super structure above plinth level upto floor two level (B) Conventional

Materials: Water shall conform to M-1 Cement shall conform to M-3 Sand shall conform to M-6. Brick shall conform to

M-15 Cement mortar shall conform to M-11.

The proportion of the cement mortar shall be 1:6 (1 cement : 5 fine sand) by volume.

Wetting of bricks:

The bricks required for masonry shall be thoroughly wetted with clean water for about two hours before use or as

directed. The cessation of bubbles, when the bricks are wetted with water is an indication of through wetting of bricks.

Bricks shall be laid in English bond unless directed otherwise. Half or cut bricks shall not be used except when

necessary to complete to bond; closer in such case shall be cut to required size and used near the ends of walls.

A layer of mortar shall be spread on full width for suitable length of the lower course. Each brick shall first be properly

bedded and set home by gently tapping with handle of trowel or wooden mallet. It side face shall be flushed with

mortar before the next brick is laid and pressed against it. On copletion of course, the vertical joints shall be fully filled

form the top with mortar.

The walls shall be taken up truly in plumb. All courses shall be laid truly horizontal and all vertical joint shall be truly

vertical. Vertical joints in alternate course shall generally be directly one over the other. The thickness of brick course

shall be kept uniform.

The brick shall be laid with frog upwards. A set of tools comprising of wooden straight edges, mason’s sprit level,

square half meter rub, and pins, string and plumb shall be kept on the site of work for frequent checking during the

progress of work.

Both the faces of walls of thickness greater than 23 cms shall be kept in proper place. All the connected brick work shall

be kept not more than one meter over the rest of the work. Where this is not possible, the work shall be raked back

according to bond (and not left toothed) at an angle not steeper than 45 degrees.

All fixtures, pipes, outlets of water, hold fasts of doors and windows etc. which are required to be built in wall shall be

embedded in cement mortar.

Bricks shall be so laid that all joints are quite flush with mortar. Thickness of joins shall not exceed 12 mm. The face

joints shall be raked out as directed by taking tools daily during the progress of work, when the mortar is still green so

as to provide key for plaster or pointing to done.

The face of brick shall be cleaned the very day on which the brick work is laid and all mortar dropping removed.

Green work shall be protected from rain suitably. Masonry work shall be kept moist on all the faces for a period seven

days. The top of masonry work shall be kept well wetted at the close of the day

Preparation of foundation bed:

If the foundation is to be laid directly on the excavated bed, the bed shall be leveled, cleared of all loose materials,

cleaned and wetted before starting masonry. If masonry is to be laid on concrete footing, the top of concrete shall be

cleaned and moistened. The contractor shall obtain the engineer'’ approval for the foundation bed, before foundation

masonry is started. When puccas flooring is to be provided flush with the top to plinth, the inside plinth offset shall be

kept lower than the outside plinth top by the thickness of the flooring.

Mode of measurements and payment:

The measurements of this item shall be taken for the brick masonry fully completed in foundation up to plinth. The

limiting dimensions not exceeding those shown on the plans or as directed shall be final. Battered, tapered and curved

portions shall be measured net.

No deduction shall be made from the quantity of brick work nor any extra payment made for embedding in masonry or

making holes in respect of following items:

Ends of joints, beams, posts, girders, rafters, purlins, trusses, corbel steps etc. where cross sectional area does not

exceed 500 Sq. cm.

Opening not exceeding 1000 Sq. cm.

Wall plates and bed plates, bearing of slabs, chhajas an the like whose thickness does not exceed 10 Cms. and the

bearing does not extend to the full thickness of wall.

Drainage holes, and recesses for cement concrete blocks to embed hold fasts for doors, windows etc.

Iron fixtures, pipes up to 300 mm dia hold fasts and doors and windows built into masonry and pipes etc. for

concealed wiring.

Forming chases of section not exceeding 350 Sq. Cm. in masonry.

Apertures for fire places shall not be deducted nor shall extra labour required to make splaying of jambs, throating and

making Arches over the aperture be paid for separately.

The rate shall be for a unit of one cubic meter.

Providing TMT Bar FE 415 reinforcement for R.C.C. work including bending, binding and placing in

position complete up to floor two level (up to 10 ton)

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of kg

Providing 15 mm thick cement plaster in single coat on Rough (Similar) side of single or half brick walls for

interior plastering up to floor two level and finished even and smooth in (i) Cement mortar 1:3 (1-cement :3-

Mode of payment shall be in Sqm

Providing 20mm thick sand faced cement plaster on walls upto height 10 metres above ground level

consisting of 12mm thick backing coat of C.M. 1:3 (1-cement : 3-sand) and 8mm thick finishing coat of C.M.

1:1 (1-cement : 1-sand) etc. complete.

The specification is as per above Item except thickness of the plaster is 20 mm sand faced and 12 mm th. Backing coat in

C.M. (1:3) and 8 mm thick finishing coat no machine paster will be allowed for spray od sand for plastering etc comp as directed

by Engg i charge.

Mode of measurements & payment : The rate shall be for a unit of one Square Meter.

Water M-1. The Cement mortar of proportion 1:3 shall conform to M-13.

Scaffolding : Wooden ballies, bamboos, planks, treatles and other scaffolding shall be sound. These shall be properly

examined before erection and use Stage scaffolding shall be provided for ceiling plaster, which shall be independent

Preparation of back-ground :

The surface shall be cleaned of all dust, loose mortar droppings, traces of algae, afflorescence and other foreign

matter by water or by brushing. Smooth surface shall be roughened by wire brushing if it is not hard and by racking if it

is hard. In case of concrete surface, if a chemical retarder has been applied to the form work, the surface shall be

roughened by wire brushing and all the resulting dust and loose particles cleaned off and care shall be taken that none

of the retarder is left on the surface. Trimming of projections on brick/concrete surface where necessary shall be

carried out to get an even surface.

Raking of joints in case of masonry where necessary shall be allowed to dry out for sufficient period before carrying

out the plaster work.

The work shall not be soaked but only damped evenly before applying the plaster. If the surface becomes dry such

area shall be moistened again.

For external plaster, the plastering operation shall be started from top floor and carried downwards. For internal

plaster, the plastering operations may be started wherever the building frame and cladding work are ready and the

temporary supporting ceiling resting on the wall of the floor have been removed, Ceiling plaster shall be completed

before starting plaster to walls.

Applications of Plaster :

The plaster about 15 x 15 cms. Shall be first applied horizontally and vertically at not more than 2 metre intervals over

the entire surface to serve as gauge. The surfaces of these gauges shall be truly inplane of the finished plastered

surface. The mortar shall then be applied in uniform surface slightly more than the specified thickness, then brought to

a true surface by working a wooden straight edge reaching across the gauges with small upward and sideways

movement at a time. Finally, the surface shall be finished off true with a trowel or wooden float according as a smooth

or a sandy granular texture is required. Excessive trowelling or overworking the float shall be avoided. All corners,

arrises, angles and junctions be truly vertical or horizontal as the case may be and shall be carefully finished.

Rounding or chamfering corners, arrises junctions etc. shall be carried out with proper templates to the size required.

Cement plaster shall be used within half an hour after addition of water. Any mortar or plaster which is partially set

shall be rejected and removed forthwith from the site :

In suspending the work at the end of the day, the plaster shall be left out clean to the line both horizontally and

vertically. When recommending the plaster, the edges of the old work shall be scraped clean and wetted with cement

putty before plaster is applied to the adjacent area to enable the two to properly joint together. Plastering work shall be

closed at the end of the day on the body of the wall and nearer than 15 cm. To any corners or arrises. Horizontal joints

in plasterwork shall not also occur on parapet tops and copings as these invariably lead to leakage. No portion of the

surface shall be left out initially to be packed up later on.

Each coat shall be kept dam continuously till the next coat is applied or for a minimum period of 7 days. Moistening

shall commence as soon as plaster is hardened sufficiently. Soaking of walls shall be avoided and only as much water

as can be readily absorbed shall be used excessive evaporation on the sunny or windward side of building in hot air or

dry weather shall be prevented by handling mattings or gunny bags on the outside of the plaster and keeping them

Mode of measurement & payment :

The rate shall include the cost of all materials, labour and scaffolding etc, involved in the operations described under

All plastering shall be measured in square metres unless, otherwise specified length, breadth or height shall be

measured correct to a centimeter.

Thickness of the plaster shall be exclusive of the thickness of the key i.e. grooves or open joints in brick work, stone

work etc. or space between laths. Thickness of plaster shall be average thickness with minimum 10 mm. at any point

on this surface.

This item includes plastering upto floor two level.

The measurement of wall plastering shall be taken between the walls or partition (dimensions before plastering being

taken) for length and from the top of floor or skirting to ceiling for height. Depth of cover of cornices if any shall be

Soffits of stairs shall be measured as plastering on ceilings, Flowing soffits shall be measured separately.

For jambs, soffits, sills etc. for openings not exceeding 0.5 sq. mt. each in area for ends of joints, beams, posts,

girders, steps etc. not exceeding 0.5 sq. mt. each in area and for openings exceeding 0.5 sq.mt. and not exceeding

3.0 sq. mt. in each area deductions and additions shall be made in the following manner :

No deductions shall be made for ends joints, beams posts etc. and openings not exceeding 0.5 sq. mt. each and no

addition shall be made for reveals, jambs, soffits, sills etc. of these opening for finish to plaster around ends of joints,

beams, posts etc.

Deduction for openings exceeding 0.5 sq. mt. but not exceeding 3 sq. mt. each shall be made as follows and no

addition shall be made for reveals, jambs, soffits etc. sills etc. of these openings.

When both faces of all wall are plastered with same plaster, deduction shall be made for one face only

When two faces of wall are plastered with different types of plasters or if one faces is plastered and the other pointed,

deductions shall be made from the plaster or pointing on the side of frame for door, window etc. on which width or

reveals is less than that on the other side but no deductions shall be made on the other side. Where width of reveals

on both faces of all are equal, deductions of 50% of area of opening on each face shall be made from area of plaster

and/or pointing as the case may be.

For openings having door frames equal to projecting beyond the thickness of wall, full deduction for opening shall be

made from each plastered face of the wall.

In case of openings of area above 3 sq. mt. each, deduction shall be made for opening but jambs, soffits and sills shall

The rate shall be for a unit of one sq. metre.

Providing and fixing M.S. grills of required pattern to wooden frames of windows etc. with M.S.

flats at required spacings and frame alround, square or round bars with round headed bolts and

nuts or by screws (A) Plain Grill. (upto 10 ton)

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of kg

Providing form work of ordinary timber planking so as to give a rough finish including centering shuttering,

strutting and propping etc. height of propping and centering below supporting floor to celling not exceeding

m. and removal of the same for in site reinforced concrete and plain concrete work in foundations, footing,

bases of columns, and mass concrete. ( up a to h)

The shuttering to be provided shall be of ordinary timber planks and shall conform to M-26.

The dimensions of scantlings and battens shall conform to the design. The strength of the wood shall not be less than

that assumed in the design.

The form work shall conform to the shape lines and dimension as shown on the plans and be so constructed as to

remain sufficiently rigid during the placing and compacting of the concrete. Adequate arrangements shall be made by

the contractor to safe guard against any settlement of the form work during the course of concreting and after

concreting. The form work of shuttering, centering, scaffolding bracing etc shall be as per design.

Cleaning & Treatment of forms:

All rubbish, particularly chippings shaving and saw dust shall be removed from the interior of the form before the

concrete is placed and the form work in contact with concrete shall be cleaned and thoroughly wetted or treated. The

surface shall be then coated with soap solution applied before concreting is done. Soap solution for the purpose shall

be prepared by dissolving yellow soap in water to get consistency of paint. Alternatively a coat of raw linseed oil or

form oil of approved manufacture may be applied in case steel shuttering is used. Soap solution or raw linseed oil

shall be applied after thoroughly cleaning the surface. Care shall be taken that the coating does not get on

construction joint surface and reinforcement bars.

Stripping time:

In normal circumstances and where ordinary cement is used forms may be struck after expiry of following periods:

Sides of walls columns and vertical faces of beam 24 to 48 hours.

Beams soffits (Props left under) 7 days.

Removal of props slabs

(i) Slabs spanning up to 4.5 m – 7 days (ii) Spanning over 4.5 mm 14 days

Removal of props to beams and arches

(i) Spanning up to 6 m – 14 days (ii) Spanning over 6 m 21 days

Procedure when removing the form work:

All form work shall be removed without such shock or vibration as would damage the reinforced concrete surface.

Before the soffits form work and struts are removed, the soffits and the concrete surface shall be exposed where

necessary in order to ascertain that the concrete has sufficiently hardened.

The centering to be provided shall be got approved. It shall be sufficiently strong to ensure absolute safely of the form

work and concrete work before, during and after pouring concrete. Watch should be kept to see that behavior of

centering and form work is satisfactory during concreting. Erection should also be such that it would allow removal of

forms in proper sequence without damaging either the concrete or the forms to be removed.

The props of centering shall be provided on firm foundation or base of sufficient strength to carry the loads without

any settlement.

The centering and form work shall be inspected and approved by the Engineer-in-charge before concreting. But this

will not relieve the contractor of his responsibility for strength, adequacy and safety of form work and centering. If there

is a failure of form work or centering, contractor shall be responsible for the damages to the work, injury to life and

damage to property.

All scaffolding, hoisting arrangements and ladders etc required for the facilitating of concreting shall be provided and

removed on completion work by contractor at his own expense. The scaffolding, hoisting arrangements and ladders

etc. shall be strong enough to with stand all live, dead and impact loads expected to act and shall be subject to the

approval of the Engineer-in-charge. However, contractor shall be solely responsible for the safety of the scaffolding,

hoisting arrangement, ladders, work and workman etc.

The scaffolding hoisting arrangements and ladders shall allow easy approach to the work spot and afford easy

The rate is applicable to all conditions of working and height up to 4 mts. The rate shall include the cost of materials

and labour for various operations involved such as:

Splayed edges, notching, allowance for overlaps and passing at angles, battens centering, shuttering propping,

bolting, nailing, wedging, easing, striking and removal.

Filleting to form stop chamfered edges or splayed external angles not exceeding 20 mm width to beams, columns and

Temporary openings in the forms for pouring concrete, if required, removing rubbish etc.

Dressing with oil to prevent adhesion of concrete with shuttering, and

Raking or circular cutting.

Rate shall be paid in Sq.m

Finishing wall with weather proof exterior emulsion paint on wall surface (two coats) to give an required

shape even shade after thoroughly brushing the surface to remove all dirt, and remains of loose powdered

materials.etc complete

The rate shall be for a unit of one sq. metre

Filling available excavated earth (excluding rock) in trenches, plinth, sides of foundations etc. in layers

not exceeding 20 cm. in depth consolidation each deposited layer by ramming and watering.

The earth obtained from excavation shall be filled in layers not exceeding 20 cms. in depth and

water thoroughly after each layer and shall be properly consolidated with rammers so that no

hollow voids remain there. In general the work shall be carried out in the best manner so that no

hollow voids remain after work. Workmanship in general confirm to C –2.

Mode of Measurement shall be on cubic meter basis.

Conveyance charge of Earth,Lime, Murrum, building rubbish earch manure or sludge and excavated

rock and fly ash,aggregate of any kind etc.comp.upto 5 km lead.(L.S.)

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of Cmt.

Providing and fixing 1.20 Metre high fencing with 2.0 Metre long M.S. Angle posts 40mm x 40 mm x6 mm

and oil painting 3 coats fixed at 2.5 Mt,C/c. with five Horizontan lines and two diagonals of galvanised

steel barbed wire weighting 9.38 Kg. per 100 Metre, strained and fixed to posts with G.I,staples including

fixing the postsin ground with 0.5 M x 0.5.M x 0.5 M. block in C.C1:5:10 etc complete

Item shall be executed AS PER SITE REQUIREMENTS AND CONDITIONS AND INSTRUCTIONS GIVEN BY

The rate shall be for a unit of Rmt

Important Note:-

As well as Considered Item Specifications as Per Item Given, not by serial number, the specifications of items which

are not mentioned in BOQ Item, Specifications should be considered as per AMC Sor Current Approved Rates for

Civil and Electrical Works, as per Available on Site of Ahmedabadcity.gov.in All the Specifications should be

Considered as per Schedules Rates of R & B Division of both civil and Electrical Works. Hence it an ARC Tender All

the Quantity Would Vary as per Instruction of Engineer in Charge. No Rate would be given Extra for Increase or

Decrease in the Quantity of The BOQ Scheduled Items. All work should be done as per instruction of Engg. In charge.

Contractor signature Additional City Engineer

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal Corporation

(referred to as Employer in these documents) invites sealed bids for the construction of works (as

defined in these documents and referred to as “the work”) detailed in the table given in the Invitation

for Bid (hereinafter called as IFB.) from competent bidder. The bidders may submit bids for the

works detailed in the table given in IFB.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined in this tender.

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-14. An agency

that has been engaged by the Employer to provide consulting services for the preparation or supervision of

the works, and any of its affiliates, shall not be eligible to bid.

3.3 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those are

blacklisted/ debarred for specified period by AMC, Governement of Gujarat, Government of India or

any other entity controlled by it, would not be eligible to submit the Bid.

4.0 Qualification of the Bidder

4.1 Requires registration:- Register as per Notice Inviting Tender having in Road Works in PWD in

Govt. R&B / CPWD / AMC or equivalent register with any other state Govt. or institutions.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to be

disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and attachments

submitted in proof of the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the contract,

inordinate delays in completion, litigation history, or financial failures etc. or debarring from

• Tampered the bid document in any manner.

• Colluded with other prospective bidders for this work to arrive at quoted prices for the purpose of

restricting competition.

• Indulged in inducement of any official of AMC and/or their consulting engineer and other

advisors in any manner whatsoever.

• Proposal not submitted in accordance with this tender.

• During validity of the proposal, or its extended period, if any, the bidder changes his commercial

• The bidder qualifies the proposal with his own conditions.

• Proposal is received after due date and time.

• Commercial proposal is enclosed with the same envelope as technical proposal

• The envelope does not show on the outside the reference of bid and thus gets opened before

the due date of opening.

• The E.M.D. is not deposited in full and in the manner as specified in the clause of Earnest

• The tender is in a language other than English or dose not contains its English Translation in

case of other language adopted for tender preparation.

• The tender documents received are not duly signed by authorized person.

• The validity of tender is less than what is stated in the tender.

• Any of the page or pages of tender is/are removed or replaced.

• Any condition which affect the cost.

• If it is joint venture.

5.1 Debarment / Black listing

Notwithstanding the above, the Employer may debar or blacklist any of the bidder(s) for

their misleading or false representations in the forms statements etc. for the period to be

decided by the Employer.

6.0 Cost of Bidding

The bidder shall bear all costs associated with the preparation and submission of his Bid. Employer

will in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and familiarize

himself with the site of Works and its surroundings including source of earth, water, road aggregates

etc. and obtain all information that may be necessary for preparing the Bid and entering into a

contract for construction of the Works. The costs of visiting the Site shall be at the Bidder's own

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby total

amount of work increases / decreases up to any extent.

• If the works gets delayed / postponed for some administrative / technical decision whatsoever.

• If the items stipulated in the tender shall not be executed as per site condition/ requirements. No

claim shall be entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and no claim

shall be entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any) issued.

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

8. Bill of Quantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract data,

forms, terms, technical specifications, forms, Annexes in the bid document. Failure to comply with

the requirements of bid documents shall be at the bidder’s own risk. Bids which are not substantially

responsive to the requirements of the bid documents shall be rejected.

10.0 Amendment of Bidding Documents

10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by

issuing addendum.

10.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on website

www.nprocure.com The prospective bidder shall refer to website to check any addendum before

hours of opening of bids. AMC will not give any advertisement for the same.

10.3 To give prospective bidders reasonable time in which to take an addendum into account in preparing

their bids, the Employer may, at his desecration, extend as necessary the deadline for submission of

10.4 Prospective bidders should attach the addendum made for the work & if fails to do so than also the

changes made through such addendum shall be applicable & bound to the bidder.

C PREPARATION OF BIDS

11.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

12.0 Documents comprising bid

The e bid submitted by the bidder shall be in two separate parts.

• Technical Bid

• Financial Bid

To qualify for award of the contract, each bidder must submit the following documents along with

• Required Registration Certificate

• Other requested documents

• Any other material / information required to be submitted in accordance with these

Instructions to Bidders (ITB)

Failure to submit these certificates/documents shall make the bid non-responsive.

Above original documents in physical form in two copies, one marked as “original” and other

marked as “Duplicate”, shall be submitted in a sealed envelope by 18:00 Hrs on the date of physical

submission of bid and addressed to the addressee given in the NIT duly super scribed “Name of

Work, Bid due date and time, Name and address of the bidder”

13.0 Bid Prices

• The contract shall be for the whole works as described in Bill of Quantity based on the percentage

rate in the Bill of Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any other cause

shall be included in the rates, prices and total Bid Price submitted by the Bidder, except otherwise

stated in the Bid document. Employer will not compensate the bidder (contractor) for any change

in duties, taxes and other levies payable by the contractor under the contract and any other reasons.

• The percentage rate and bid price quoted by the bidder shall be fixed up to the completion of Work

and shall not be subject to adjustment on any account, except where expressly specified, otherwise,

in the contract.

14.0 Currencies of Bid and Payment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in Indian

15.0 Bid Validity

15.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a shorter

period shall be rejected by the Employer as non-responsive.

15.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may

request that the bidders may extend the period of validity for a specified additional period. The

request and the bidders' responses shall be made in writing or by cable. A bidder may refuse the

request without forfeiting his bid security. A bidder agreeing to the request will not be required or

permitted to modify his bid, but will be required to extend the validity of his bid security for a period

of the extension.

16.0 Earnest Money / Bid Security

16.1 The Bidder shall furnish, a Bid Security of the amount as shown in the Table of IFB as part of his

bid, in the form of Demand Draft / pay order / Bank Guarantee in favour of Municipal

Commissioner, Ahmedabad valid for 120 days.

16.2 The issuing branch of the bank guarantee shall be of Ahmedabad City only.

16.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as non-

16.4 Any bid having bid security for lesser value and shorter validity period shall be treated as non-

16.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be returned as

promptly as possible.

(b) The bid security of the successful bidder, along with second and third lowest tenders, will be

returned when the successful bidder has furnished the required security deposit and signed the

16.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the

Agreement and furnished the required security deposit.

16.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) sign the Agreement; or

(ii) Furnish the required security deposit.

(iii)commence the work after signing the agreement within 15 days

16.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank

guarantee shall be of Ahmedabad City only.

16.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp papers of

requisite value in accordance with the stamp Act applicable to that particular state of Indian Union,

where executed.

16.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly indicate

in (block letters) his name, designation, Power of Attorney No. / Signing Power No. etc.

16.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by the

executing officers and the last page shall be signed in full, indicating the particulars as aforesaid

under the seal of the Bank.

D. SUBMISSION OF BIDS

17.0 Sealing and Marking of Bids

17.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes and

the three sealed envelopes shall be sealed in an outer envelope. The Bid envelopes shall be marked

• Complete Tender Document with all necessary qualification related documents (in two copy)

Above two envelopes shall be kept in one envelope and it should be marked as “Technical Bid” and

sealed. This Outer envelope should mention the name of firm of bidder, his address, contact details &

name of the work.

17.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- West Zone,

2nd Floor, A.M. Office,

Dr. Ramanbhai Patel Bhavan,

Usmanpura, Ahmedabad.

Bear the following identification:

Indicate the name and address of the bidder.

• If the outer envelope is not sealed and marked as above, the Employer will assume no responsibility

for the misplacement or premature opening of the bid.

18.0 DEADLINE FOR SUBMISSION OF THE BID

18.1 Complete Bids (including Technical bid and necessary documents) must be received by the

Employer at the address specified in bid information not later than the date indicated on the face

sheet of the document. In the event of the specified date for the submission of bids declared a holiday

for the Employer, the Bids will be received up to the appointed time on the next working day. The

Bidder is further required to submit Documents in Physical Form on or before the Bid Due Date and

before the time of submission as specified in NIT, at the following address:

Assistant Manager- West Zone,

2nd Floor, A.M. Office,

Dr. Ramanbhai Patel Bhavan,

Usmanpura, Ahmedabad.

18.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-

tendering portal on account of delay in submission at bidder's end. Bidder shall ensure that they

submit the bid well before the "Due Date & Time of Bid- Submission". AMC shall not be

responsible if bidder is not able to submit the bid on account of failure in network/internet

connection or any other technical reason.

18.3 The Employer may extend the deadline for submission of bids by issuing an amendment in

accordance with respective Clause, in which case all rights and obligations of the Employer and the

bidders previously subject to the original deadline will then be subject to the new deadline.

18.4 All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

18.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and returned

unopened to the bidder.

Any Bid received by the Employer after the deadline prescribed in NIT will be returned unopened to

20.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to

expiration of the Bid validity period by writing, facsimile or e-mail confirmed by registered letter.

This letter (hereinafter and in the Conditions of Contract called the “Letter of Acceptance” will state

the sum that the Employer will pay the Contractor in consideration of the execution, completion, and

maintenance of the Works by the Contractor as prescribed by the Contract (hereinafter and in the

Contract called the “Contract Price”).

The notification of award will constitute the formation of the Contract, subject only to the furnishing

of a Security Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the Successful

Bidder. It will be signed by the Employer and the Successful Bidder.

21.0 SIGNING OF CONTRACT AGREEMENT

21.1 The Employer and the successful bidder shall enter into a Contract Agreement within 28 days after

the successful bidder (hereinafter called the Contractor) receives the Letter of Acceptance, unless

they agree otherwise, subject to furnishing the security deposit before signing the Agreement with

21.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify the

other Bidders that their Bids have been unsuccessful and release their Earnest Money Deposit / Bid

22.0 SECURITY DEPOSIT

22.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the

Employer a security deposit in the form of Bank Guarantee for an amount equivalent to 5% of the

Contract Price valid for the period of valid till 90 days beyond Date of completion of work. The

Security Deposit shall be payable in 10 days (for tenders upto Rs.10.0 Lacs) or 15 days (for tenders

of Rs.10.0 Lacs and above)from date of receipt of LOA failing which interest @ 4% per annum will

be charged by AMC.

22.2 The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from

Ahmedabad branch of any Banks mentioned in the clause no. 16.2 of these tender documents.

22.3 This security deposit shall be released only after the clearance of final bill including pre & post

22.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of security

deposit or late renewal of bank guarantee for the number of days delayed for submission or

discontinuity of the bank guarantee.

22.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same verbatim as per

the format. Bank Guarantee shall be submitted on right value of stamp paper and for correct value of

22.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall constitute

sufficient grounds for cancellation of the award and forfeiture of the Bid Security.

22.6 In case of any contract amendment during execution of the contract enhancing value of the contract

the BG value shall be enhanced accordingly. Validity of BG shall be commercial terms and

conditions of the tender.

22.7 All compensation or other sums of money payable by the Contractor to the Employer under the terms

of this Contract or any other contract or on any other account whatsoever may be deducted from

Security Deposit. Also in the event of the Contractor's Security Deposit being reduced by reasons of

such deductions, as aforesaid, the Contractor shall, within 14 days of receipt of notice of demand

from the Engineer-in-Charge, make good the deficit in Security Deposit.

22.8 Should there arise any occasion under the Contract due to which the periods of validities of Bank

Guarantees as may have been furnished by the Contractor from time to time, are required to be

extended/renewed, the Contractor shall get the validity periods of such guarantees extended/renewed,

and furnish these to the Engineer-in- Charge one month before the expiry date of the aforesaid

Guarantees originally furnished failing which the existing Bank Guarantees shall be invoked by the

Engineer – in – charge. Also in case of any deficit in securities on any account as might occur or is

noticed, the Contractor shall forthwith recoup/replace the same with acceptable Security Deposit.

22.9 The Bank Guarantee shall be extended within the expiry dates wherever activities as per contract are

not completed in all respects.

22.10 The Security Deposit less any amount due shall, on demand, be returned to the contractor after

days of completion date / Final Bill paid date which ever is later. No interest on the amount of

Security Deposit shall be paid to the Contractor at the time of release of Security Deposit as stated

22.11 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at Employer’s

office within 15 days of LOA.

23.0 Advance Payment and Security

The Employer will not provide any advance payment.

24.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final and

binding to the bidder.

25.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting from

Contractors completed or under execution by him over last five years. If the details of Litigation

History are hidden by the Bidder and later on it comes to the knowledge of the Employer, the Bidder

shall be disqualified for the proposed work and other appropriate actions shall be taken against the

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Remarks

Year Name of Value of the Reasons/Details for showing

Project Project (Rs.) litigation/arbitration Present Status

 The bidder shall furnish separate table for individual project.

 The above information shall be supported with necessary documents otherwise the same shall be

treat as null and void.

 A consistent history of arbitration awards? Judgments against the applicants or any partner of a joint

venture may result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to knowledge of the

employer the bidder shall be disqualified for the proposed work and other appropriate actions shall

be taken against the bidder.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Liquidated Damages

1.1 If the Contractor fails to complete the works within the original or extended time limit, the

Contractor shall pay penalty of 10% of amount of actual remaining work. The amount of work for

which the scope of contractor is reduced shall not be considered for the calculation of Liquidated

1.2 Conditions mentioned in the AMC Finance Department Circular AMC no. 18 Date: 23/05/2017 and

all latest Circulars shall be applicable.

2.0 Retention Money

2 % amount of each Running Bill shall be deducted as a Retention Money. Such retention money

shall be released in the final bill of the said work. AMC reserves right to deduct any amount to

compensate the poor performance of the contractor i.e. poor quality or abandoned / incomplete work.

3.0 Subcontracting

3.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any portion of

Work without the approval of the Employer’s Representative. Any subcontracting shall not relieve

the Contractor from any contractual obligations or responsibility under the Contract.

3.2 The Contractor shall not be required to obtain consent for a subcontract for which the name of the

subcontractor and scope of works activities to be performed by him is already stated in the contract

or supply of material or engagement of labour.

4.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred to

in the Bid document to carry out the functions stated in the Schedule or other personnel approved by

the Engineer. The Engineer will approve any proposed replacement of key personnel only if their

qualifications, abilities, and relevant experience are substantially equal to or better than those of the

personnel listed in the Schedule.

4.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof, for his

misconduct or inadequacy of technical skills and experience, who is a member of the Contractor’s

staff or his work force, the Contractor shall ensure that the person leaves the Site within seven days

and has no further connection with the work in the Contract.

4.3 No residential accommodation is allowed at the site of work. The labour huts shall not be erected on

the site of work and contractor shall make his own arrangements to provide such accommodations as

per the rules of the local bodies. He shall make his own arrangements for housing, stores, field office

etc. He shall submit a site layout plan indicating the location of various site facilities to be created by

him at his cost for the execution of work. The Owner shall in no way be responsible for any delay on

this account and no claim on this account whatsoever shall be entertained. All Basic amenities shall

be provided by the Contractor to Labours as per the prevailing labour Laws.

5.1 The Contractor shall have full regard throughout execution, completion and defects liability period to

following safety aspects and shall take all necessary steps to ensure that danger to safety is avoided

all the time in respect of,

Safety of the works

• Safety of the Contractor’s employees and all the persons directly or indirectly engaged by him

• Safety of all the employees including persons working on other contracts of Employer at the

same site of the Employer and Engineers employees engaged at work site.

• Any authorized third party persons on the site.

• Contractor’s plant and equipment

5.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs,

barricading, and cones; when and where necessary, or required by Engineer in Charge or by any

duly constituted authority for the protection of the works or for the safety and convenience of the

public or other.

5.3 The Contractor shall take all reasonable steps to protect the environment on and off the site and avoid

damage or nuisance to persons or property of the public and others arising as a consequence of his

method of operation.

5.4 The Contractor shall maintain in good condition all work throughout execution, completion, and

defects liability period. The contractor shall be responsible for and to make good all injuries,

damages and repairs, rendered necessary by fire, rain, traffic, floods or other causes.

5.5 All the scaffolding work, wherever required for the execution of work, shall be provided by the

contractor. Nothing extra shall be payable on this account. It shall be provided strictly with double

scaffolding system with all the accessories etc. with adjustable suitable working platforms to access

the areas, with ease for working and inspection. It shall be designed to take all incidental loads. It

should cater to the safety features for workmen. It shall be ensured that no damage is caused to any

structure due to scaffolding.

5.6 All temporary warning/ caution boards display shall be provided and displayed during day as well as

night time by the contractor, wherever required and as directed by the Engineer.

5.7 Arrangement of temporary water and electricity and telephone connection required, by him, shall be

made by the Contractor at his own cost and also necessary permissions directly from relevant

Owners shall be obtained by him under intimation to the Owner. Also all initial and running charges

and security deposit, if any in this regard shall be borne by him. The Contractor shall abide by all the

rules/ bye laws applicable in this regard and he shall be solely responsible for any penalty on account

of violation of any of the rules and byelaws in this regard.

5.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the same

shall be completely contractor’s responsibility. All the losses due to such accidents and expenses of

legal matters shall be borne by contractor.

5.9 The Contractor shall be responsible for maintenance and watch and ward of the complete installation

and shall also be responsible for any pilferage, theft, damage, penalty etc. in this regard. The

Contractor shall indemnify the Owner against any claim arising out of pilferage / theft, damage,

penalty etc. whatsoever on this account.

5.10 The Contractor shall depute Site Engineer & skilled workers as required for the work. Necessary

protective and safety equipments shall be provided to them by the Contractor at his own cost and

6.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage rubbish,

excess materials, temporary works no longer required will be removed from site immediately.

7.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials, rubbish,

temporary works of every kind.

A. COST CONTROL

8.0 Bill of Quantities

a. The schedule-B shall contain Memorandum showing items for the construction, installation,

testing, and commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be paid only

quantities calculated after taking measurements of executed work. The rate stated in the schedule

B for each item of work shall apply. The works shall be measured by the Contractor jointly with

the authorized representative of the Engineer and all particulars required by the representative of

the Engineer shall be supplied by the contractor.

c. The work shall be measured net. No allowance for general or local custom, working space etc. is

9.1 The Engineer in Charge shall have power to make any variation of form, quality or quantity of the

works or any part thereof that may, in his opinion, be necessary and for that purpose, or if for any

other reason it shall, in his opinion, be appropriate, he shall have the authority to instruct the

Contractor to do and the Contractor shall do any of the following:

 Increase or decrease the quantity of any work up to any extent included in the contract,

 Omit any such work,

 Change the character or quality or kind of any such work,

 Execute additional work of any kind necessary for the completion of the Works or

 Change any specified sequence or timing of construction of any part of work.

9.2 No such variation shall in any way vitiate or invalidate the contract, but the effects, if any, of all such

variations shall be valued in accordance with the following sub clauses. Provided that where the issue

of an instruction to vary the Works is necessitated by some default or breach of contract by

contractor or for which he is responsible, any additional cost attributable to such default shall be

borne by the Contractor.

9.3 The Contractor shall not make any such variation without an instruction of the Engineer. No

instruction is required for quantities varying from those provided for the items in the contract

10.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows in the

same order of priority.

a) Variations in the quantities of work in schedule of quantities shall not vitiate the contract.

b) The contractor shall be bound to execute extra items of work as directed by the Engineer-in-

c) Contract unit rates for individual items shall apply to varied quantities where there is a quantity

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

10.2 If any extra item crops up during the progress of work the same shall be carried out by the Contractor

and he shall be paid at the rate fixed by Employer which shall be fixed as lowest of the rates derived

by rate analysis based on the following three methods. , the priority of the documents forming the

Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2013-14, the

rate of extra item shall be that rate and premium (above or below) quoted by contractor.

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and equipment, the

cost of all temporary and incidental works, the overheads and the Contractors profit.

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs, the cost of

use of all plant, machinery, and equipment, the cost of all temporary and incidental works.

10.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall be taken at 10 %

of the final rate derived.

10.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in his

opinion appropriate and shall notify the Contractor accordingly with a copy to the Employer.

10.5 The Engineer shall determine provisional rates and prices to enable on account payments to be

included in the Interim Payment Certificates, until rates and prices are agreed as final by the

Employer, the Contractor, and the Engineer.

10.6 The Contractor shall not be entitled to additional payment for costs, which could have been avoided

by giving early warning.

11.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in terms

of the contract and taxes at source, as applicable under the law. The Employer shall pay the

Contractor the amounts certified by the Engineer.

11.2 If an amount certified is increased in a later date certificate due to corrections in previous certificates

or as a result of an award from disputes review experts, Contractor shall be paid such amount only.

The Contractor shall not be paid any interest upon such delayed payment.

11.3 Items of the work for which no rate or price has been entered in will not be paid for by the Employer

and shall be deemed covered by other rates and prices in the Contract.

11.4 All payments shall be made in Ahmedabad.

12 Taxes and duties

12.1 The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local

Governing bodies prevailing on the date of award of the contract. The Contractor will have to pay all

such taxes and duties for the performance of this Contract. The Employer will deduct from the

Contractor’s monthly and other payments all taxes and duties, which he is bound to recover in

accordance with the applicable law.

12.2 The Contractor shall keep himself fully informed of all acts and laws of the Central & State and local

Governing bodies, all orders, decrees of bodies, tribunals having any jurisdiction or authority which

in any manner affect those engaged or employed, and anything related to carrying out the work. All

the bye-laws lay down by AMC/AUDA and any other local bodies while executing the work shall be

adhered to. All taxes of local bodies shall be borne by the contractor. The Contractor shall arrange to

give all notices required by any authority and to pay to such authority all the fees that may have to be

paid for the material, plants, equipments etc. The Contractor shall also adhere to all traffic

restrictions notified by the local authorities. He shall protect and indemnify the Owner and its

officials & employees against any claim or liability arising out of violations of any such laws,

ordinances, orders, decree, whether by himself or by his employees or his authorized representatives.

Nothing extra shall be payable on these accounts.

13.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-1831-

M(3) dt. 9/12/05 issued by G.O.G. (non-refundable) shall be deducted from every bills which shall

be deposited to Govt. Labour Department for Labour welfare fund.

14.0 Currencies

All payments shall be made in Indian Rupees.

15.0 Advance Payment

No Advance Payment shall be made.

16.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date

and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's

cost if the loss or damage arises from the Contractor's acts or omissions.

B. FINISHING THE CONTRACT

17.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the

Engineer will do so upon deciding that the Work is completed.

18.0 Termination

18.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after receipt

by him of a Notice to this effect from the Engineer/Employer after signing the agreement or

2. To proceed with the works, or any section thereof, within 28 days after received notice

3. Has failed to comply with a notice issued or an instruction issued within 28 days after having

4. Abandons the works or otherwise plainly demonstrates the intention not to continue

performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written permission

of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the contract.

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order

made against him, compounds with his creditors, or carries on business under receive, trustee

or manager for the benefit of his creditors, or if any act is done or event occurs which (under

applicable Laws) has a similar effect to any of these acts of event.

18.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to the

contractor, terminate the contract and expel the contractor from the site. However, in the case of sub-

paragraphs (h), the Employer may be notice terminate the contract immediately.

18.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the

Employer, under the contract or otherwise.

18.4 After termination, the Employer may complete the works and/or arrange for any other entities to do

so. The Employer and these entities may then use any goods, contractor’s documents and other

design documents made by or on behalf of the contractor.

18.5 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental breach

of the Contract.

18.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the current

Program and the stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a

reconstruction or amalgamation;

(c) The contractor fails to fulfill requirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach of

Contract and the Contractor fails to correct it within a reasonable period of time determined by

(e) the Contractor does not maintain a security which is required;

(f) the Contractor has delayed the completion of works by the number of days for which the

maximum amount of liquidated damages becomes payable as defined in the Contract data;

(g) if the Contractor, in the judgment of the Employer has engaged in corrupt or fraudulent practices

in competing for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving, receiving or

soliciting of anything of value to influence the action of a public official in the procurement

process or in contract execution. “Fraudulent practice” means a misrepresentation of facts in

order to influence a procurement process or the execution of a contract to the detriment of the

Borrower, and includes collusive practice among Bidders (prior to or after bid submission)

designed to establish bid prices at artificial non-competitive levels and to deprive the Borrower of

the benefits of free and open competition.”

18.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a cause

other than those listed above, the Engineer shall decide whether the breach is fundamental or not.

18.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

18.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and

secure and leave the Site as soon as reasonably possible and handover the site to the Employer

including all materials and plant and equipment existing there upon.

19.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the same.

He shall also be responsible for the correctness of the positions, levels, dimensions, and alignment of

all parts of the structures as per instructions given to him. If at any time any error shall appear during

the progress of any part of the work, the contractor shall at his own expense rectify such error if called

upon to the satisfaction of the Engineer in charge.

20.0 Overpayment & Underpayment

20.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or under

this Contract against the contractor the same may be deducted by the Municipal Corporation from any

sum then due or which at any time thereafter may become due to the contractor under this contract

and failing that under any other contract with the Municipal Corporation or from any sum due to the

contractor with the Municipal Corporation (which may be available with Municipal Corporation), or

from his retention money, or he shall pay the claim on demand. The Municipal Corporation reserves

the right to carry out post payment audit and technical examination of the final bill including all

supporting vouchers, abstracts, etc.

20.2 The Municipal Corporation further reserves the right to enforce recovery of any over payment when

detected notwithstanding the fact that the amount of the final bill may be included by the Contractor.

20.3 If as a result of such audit and technical examination any over payment is discovered in respect of

any work done by the Contractor or alleged to have been done by him under the contract, it shall be

recovered by the Municipal Corporation from the contractor by way of all the means prescribed

above or if any under payment is discovered by the Municipal Corporation, any amount due to the

contractor under this contract or under payment may be adjusted against any amount then due or

which may at any time thereafter become due before payment is made to the contractor from him to

the Municipal Corporation on any other contract account whatsoever.

21.0 Materials obtain from dismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for reasons

other than on account of bad or imperfect work, the materials obtained from dismantling will be the

property of the A.M.C. and will be disposed of as per instruction of Engineer-in-charge in the best

interest of the A.M.C.

22.0 Dispute to be referred to Arbitrator

The disputes relating to this contract, so far as they relate to any of the following matters, whether

such disputes arise during the progress of the work or after the completion or abandonment thereof,

shall be referred an independent Arbitrator appointed by AMC as far possible in consultation with

the agency if it is necessary and such disputes shall be settled in accordance with the arbitration and

conciliation Act.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon the works

of the site thereof or belonging to the contractor or procured by him and intended to be used

for execution of the work or any part thereof possession of which may have been taken by the

Engineer-in-charge under the said clause –5.

(ii) The reduction in rates made by the Engineer-in-charge under clause 9 from the items of

works not accepted as completed fully in accordance with the sanctioned specifications.

(iii) The rate of part of payment for any class of work which is included in the additional or

altered work carried out by the contractor in accordance with the instructions of the Engineer-

in-charge under clause 14 and the rates for which is to be determined under the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by the

contractor before receipt of notice given by the Engineer-in-charge under clause 15 and/or

amount of compensation payable to the contractor under the said clause for loss in respect of

such materials.

(v) The amount of compensation which the contractor shall be liable to pay under clause 17 in

the event of this failure to rectify, remove or reconstruct the work within the period specified

in the written intimation or the amount of expenses incurred by the Engineer-in-charge under

the said clause17 in rectifying, removing or re-executing the work or in removing and

replacing the materials or articles complained of.

(vi) The reduction of rates as may be fixed by the Engineer-in-charge under clause 17 for the

inferior work or materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates and assessed

(viii) The amount payable to the contractor for the work carried out under clause 33 in accordance

with the instructions and the requirement of the Engineer-in-charge in case where there are no

specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and calculations

to every item of claims. The decision will have to be implemented by all the concerned.

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation

approaching on Court of Law. It shall be within the jurisdiction where the site of work is

The reference to arbitration proceeding under this clause shall not:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause 5 to take

possession of all or any tools, plants, materials and stores in or upon the works of site thereof

belonging to the contractor or procured by him and intended to be used for the execution of the

work or any part thereof.

ii) Preclude the Engineer-in-charge from utilizing the materials purchased by the contractor in any

work or from removing such materials to other places, during the period the work is stopped or

suspended in pursuance, of notice given to the contractor under clause

iii) Progress of the work or the carrying out the additional or altered work in accordance with the

provisions of clause 14 or as the case may be, of clause

23.0 Drawings and Photographs of the Works

23.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No

separate payment will be made to the contractor for this. . The contractor shall have to submit the

same in hard copy as well as soft copy as and when demanded by the AMC.

23.2 No photograph of the works or any part thereof or plant employed thereon, except those permitted

under clause 59.1, shall be taken, or permitted to be taken by the Contractor or by any of his

employees or any employees of his sub-Contractors without the prior approval of the Engineer in

writing. No photographs/ videography shall be published or otherwise circulated without the

approval of the Engineer in writing.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

yb>tJt> BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe >hJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt yb>tJt> BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg gt>elt ftuLx[fxhtu

Che NfNu. dJobuLxlt btLg ftuLx[tfxhu yb>tJt> BGþrl.ftuvtuohuNlbtk btLg ftuLx[tfxhtule gt>ebtk hSMxuNl

fhtJJtlwk hnuNu.

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u stuzJtle hnuNu.

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt mûtb ntug

<ublu s ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs xtRb jebexbtk ÃþY fhJt

sYhe mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt hnuNu.

z:- yb>tJt> Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t mexe.Rsluh

mh¾gwjh,lk -17,<t.09/12/2012 bwsc yb>tJt> Bgwrlrmvj ftuvtuohuNlbtk ftuLx[t¾xh hSMxuNl Ve,

heLgwyj Ve <&t yvd{uzuNl Ve ylu btv>kztu ægtlbtk htFe <u bwsc ybj fhJtltu hnuNu.

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe btdo, mkath ylu

JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu mtRx ylu rcÕzekd(fu su ftb

fhJt, ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj ntug).<ubs xuLzhhu yt mtRxlt ftb btxu, rcÕzekd

btxu, gtzo, zevtu btxule søgt vtu<tle he<u bu¤Je juJtle hnuNu. (xuLzhlwk ftb fhJt, ftb vwhwk fhJt <&t

ftblt buRxulLm btxule søgt)

(h) yt ftble mbg bgto>t bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle >hufu >huf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt >M<tJus vh< fhJtlt

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]< fh<wk

bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u cezJtle hnuNu.

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt >huf vtlt ylu rJd<tu vh ftuLx[tfxhu mne fhJe.

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh >eM<tJustult jFtKbtk ftuR AufAtf fu VhuVth fhJt >uuJtNu lrn

ylu ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug <tu <ult vh l Dwkx<t Ftuxt

jFtK fu ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ Wfju <u he<u jFJt. «ðguf mw^tht vh xwkfe

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk >NtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug <tu xuLzh

ybtLg dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu ftuLx[tfxhtult btdo>Nol

btxu mtbtLg rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK >NtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk ytJNu.

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt vîr< y&Jt

rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu c>ÕGþ / c>Õgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk >huf Ctde>th y&Jt <u ykdulwk bwFðgthltbwk ^htJlth Ôgrf< mne l

fhu y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR mtûteyu mtF fhe l ntug.

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, h> fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu rlKog ytFhe

hnuNu. ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh ftuRvK «fthltu lwfNtle fu

J¤<hltu nff>tJtuu fhe NfNu lrn fu ftg>tfeg ftgoJtne yt ykdu &R NfNu lrn. xuLzh bkswh &gtltu y&o

ftb ytve >uJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh MJefthJtbtk ytJNu lne.

(9) rJmkdr< ylu rnmtc stud:

nt& ^hJtlt ftbtule ctc< >NtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK Cwjawf leault

rlgbtu ylwmth mhCh fhJtbtk ytJNu.

(1) xuLzh Chlthu >hlt Ftltbtk sKtJuj Nç>tu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nç>tuubtk sKtJuj hfb

btLg htFJtbtk ytJNu.

(2) yufb >h ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu >NtoJ<e CtJ vºtflt Ftltbtk&e hfbbtk

Cwj sKtg <tu yufb >h btLg htFJtbkt ytJNu ylu >hlt yt^thu dwKtfth mw^thJtbkt ytJNu.

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgto>t bwsc fhJtltu hnuNu. yt mbgbgot>t 10 jtF mw^elt ftb btxu yuj.ytu.ytR.

ytÃgt <theF&e 10 r>Jm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg <theF&e 15 r>Jm&e NY

&guj dKJtbt ytJNu. <&t <u >hBgtl ftble 5% juFu zevtuÍex Che fhthvºt fhJtltu hnuNu.

xuLzhbtk ftuLx[t¾xh îtht Chujt CtJ <btb «fthlt su <u «J<o<t mhfthe xuût mrn<lt CtJ

dKJtbtk ytJNu. ylu <ubtk atjw ftb >hBgtl su ftuR VuhVth &Nu <ultu J^thtu awfJJtbtk ytJNu lrnk.

c:- mûtb m•tt îtht Yt.10,00,000.00 (>m jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ct> (LOI)

ytvJtbtk ytJNu ðgth ct> r>l - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu. rm¾gtuhexe zevtuÍex

btuze ChJtlt rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth ftgoJtne fhJtbtk ytJNu.

f:- bkswh &guj xuLzhle mbgbgto>tbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj

«btKu bkswh &guj mbgbgto>t ct>lt FhuFh ctfe ftble hfblt bn•tb 10% juFu (jefJezexe zubuSm)

vulÕxe Jmwj fhJtbtk ytJNu.

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt >h vwhtk &gujt ftb btxult Au ylu <ubtk bswhe,

vtjF, ÃjtLx, >uFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu <btb Faoltu <&t

sYh sKtg <tu ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu mbtJuN &Nu ylu xtkfujt CtJ fu >h

fh<t J^thtle ftuR awfJKe ykdult <ublt ftuR >tJt ægtlbtk juJtNu lnek ylu xuLzh Chlth Ftuxe

hswyt<lu fthKu y&Jt ftuR Ôgrf<yu (vAe<u ctk^ftb rJCtdltu fboathe ntug fu l ntug) <ublu ytvuje

btne<elu yt^thu vtA¤&e ftuR >tJt> hsw fhJt nf>th hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk sw>t sw>t

CtJ ylu >h ChJt btxu sYhe yuJe <btb btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u xuLzh hsw

fhJtlu je^u y&Jt <ubtk&e WCt &<t ftuR stuFb fu sJtc>thebtk&e Axfe NfNu lnek. m>h ftbbtk ftuR vK

ò<lt ctk^ftblt bxehegj Wvh CtJ J^thtu ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt ytJNu. <&t

Bgwrl. frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu ftbdehe/ybj fhJt rcl Nh<e

ckDlf<ot hnuNu.

f:- ftuLx[t¾xhlt >huf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk vubuLx + yu¾x[t

ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh< ytvJtbtk ytJNu.

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftg>t bwsc su ftuR hfble fvt< fhJtle &Nu <u bwsc

ftuLx[tfxhlt cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

ce:- xuLzhbtk >NtoJuj ftb mkck^e >M<tJusbtk >NtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau >NotJuj ¢btlwmth

>M<tJusbtk >NtoJuj rJd< d{tng htFJtbkt ytJNu.fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu

ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu f>:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk f>, ytfth, ytkfzt f>ta Ftuxt ntug <tu btvujt f>, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^ bwfe

yuze.mexe yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc fhJtbkt ytJuj

rlKog ykr<b dKJtbkt ytJNu.

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe ylu Rsluh

Rlatsuo Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl fhtJJwk.

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) yufe JF<u yuf fh<t J^w søgtytuyu ftb NY fhJtltu Jfo ytuzoh b¤u <tu ftb yuf mt&u s c^u NY fhJw

(16) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu lwfNtl &Nu <tu

<ule mkvwKo sJtc>the (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb >hBgtl bswhtu fu sl<tlt

ftuR btKmlt òlbtj lu lwfNtl &tg <ule sJtc>the ftuLx[tfxhle hnuNu. vtujem Vrhgt> &tg <tu <ule

sJtc>the vK ftuLxtfxhle hnuNu. CuFz Dme l vzu <ule sJtc>the vK vtujem Vrhgt>bt ftuLx[tfxhle

hnuNu. CuFz Dme l vzu <u btxu mjtb<elt vdjt (suJt fu >tuhzwk ctk^e bswh Ftztbtk W<thJt, mtuhekd ylu

Mx[xekd fhJt rJduhu) je^t Jdh bsqhlu Ftztbtk W<thNu <tu ftuLx[tfxh s vtujem Vrhgt>bt sJtc>th hnuNu

ylu Bgwrl.ftuvtuohuNlltu ftuRvK MxtV ytlt btxu sJtc>th hnuNu lrn. ytxjwk mbSlu s xuLzh ChJwk.

bswhtultu rJbtu vK W<thJtu.

(17) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu fhtJJtlt hnuNu.

bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.

(18) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu rlgb ylwmth

<u ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(19) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< r>l 1btk vh< jR sJtltu hnuNu.

yLg&t <ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(20) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc ve.yuV/juch yufx

<&t bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftg>tlw vtjl fhJtlwk hnuNu <&t yt ykdu

Bgwrl.ftuvtuohuNl îtht su btne<e btkdJtbtk ytJu <u ytvJtle hnuNu. bu.BGþrl.frbNlh©elt mh¾âwjh

Bþsc sYhe ctknu^he vºtf ytvJtLþk hnuNu.

(21) ftuRvK ftg>tfeg jexeduNl yb>tJt> Nnuhle ftuxobt hnuNu.

(22) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu <ubs

dtuXJJtltu hnuNu.

(23) ftuR vK mhfthe fhJuht ChJtle <btb sJtc>the ftuLx[tfxhle hnuNu.

(24) ftuLx[tfxh îtht xuLzhbt >NtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc jtJJtlt

hnuNu.<&t xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw vtjl fhJtlw hnuNu.

(25) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l ntug <uJe

J^thtle ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb ylwmth J^thtle

ytRxblt CtJ lffe fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk ytJNu.

(26) atjw ftb >hBgtl «tuxufNlle mkvwKo sJtc>the ftuLx[tfxhle hnuNu. subtk vevzt, >tuhzt Cgmwaf ctuzo,

ÃjtMxef vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK yfMbt< &Nu <tu <ule mkvwKo

sJtc>the ftuLx[tfxhle hnuNu.

(27) M&¤ Wvh atjw ftbdehe >hBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg Ôgrf<lt

yfMbt<lt rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem ftgoJtnele sJtc>the

ftuLx[tfxhle hnuNu.

(28) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk >hhtus fhuj ftbdehe <&t

yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk ftuBÃjtgLm ytvJtlwk hnuNu ytJe

ltu^lt sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu ftuLx[tfxhlu vulÕxe fhJtle m•ttt yuze.mexe

yuLSlehgh©elu hnuNu.

(29) >huf ytRxblt MvuNeVefuNl yb>tJt> Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg htFuj

MvuNeVefuNl Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk

yuze.mexe.yuLSlegh©eltu rlKog ytFhe hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu >hhtus J^thtltu zucheÍ

WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu sutFbu Jdh ltuxemu Jtuxhekd fhtJJtbtk <&t zucheÍ

WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(30) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve juJtbtk ytJNu.

(31) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg >hBgtl ftuLx[tfxh

îtht ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk ytJNu.

(32) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu VhSgt<

(33) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk ftb btk

ftuRvK mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj M¾{uJSkd ykdule btdoœrNoft

lwk vtjl fhJwk.

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le bwjtft< je^e Au ylu ftblu

jd<t btjmtbtl, bswhe ylu ceS ctc<tulu jd<e M&trlf vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu jd<t >M<tJustu ft¤SvwJof

yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb< Awk/Aeyu.

ftuLx[tfxhle mne ylu rmfft

1. Wvhtuf< xuLzhtu su <u Jdobtk hSMx[uNl ^htJ<t ftuLx[tfxh©eytuyu ztWljtuz fhelu ChJt. ÂJÂNÐ ÂfMmtbtk stu xuLzhbtk

œNtoJuj ntug <u bwsc yLg ftuLx[tfxh / buLgwVu¾ah xuLzh Che NfNu.

2. yt E-xuLzhbtk >NtoJuj «tEÍcez rmJtglt ztu¾âwbuLx zwÃjefux ftuveytu mt&u Chelu Wvhlt mhltbu ÁcÁ /Mvez vtuMx

&e rlg< mbgbtk btufjJtlt hnuNu.

3. Nh<e xuLzhtu hœ ct<j dKtNu.

4. xuuLzhtu ftuEvK fthK ytÃgt rmJtg MJefthJt fu lrnk MJefthJt <ule mkÃËKo m•tt BGþrlrmvj frbNlh©ele hnuNu.

5. ftuLx[tfxh©eytuyu xuLzh mt&u BGþrlrmvj hSMx[uNlle/dJobuLx hSMx[uNlle ftuve bwfJtle hnuNu ylu fJh Wvh xuLzh

lkch <&t ftuLxufx lkch MvÐ jFJtu. BGþrlrmvj hSMx[uNlle/dJobuLx hSMx[uNlle ftuve bwfJtbtk ln´ ytJu <tu

xuLzh h> dKJtbtk ytJNu.

6. xuLzh Ve vu ytuzoh / zebtLz z[tVx&e aqfJJtle hnuNu. ylu <ule vtA¤ ‘ E ’ xuLzhltu xuLzh ytR.ze lkch yawf jFJtltu

7. xuLzh Ve <&t R.yub.ze le hfblt z[tVx <&t vu ytuzoh xuLzh bwsc >huf xuLzh btxu yawf yjd yjd ChJtlt hnuNu.

8. ftuLx[tfxhtuyu xuuLzhbt cukflw ltb, Ft<t lkch, btRfh lkch ylu mhltbw MvÐ yûthtubt jFJw.

9. xuLzh Ve, R.yub.ze. ÂJltlt <&t ytuAe auf hfblt xuLzhtu hœct<j (fuLmj) dKtNu.

10. su ftuLx[tfxh©eytuyu hSMx[uNl heLgw fhuj l ntug <u ftuLx[tfxhu xuLzh ChJt lne.

11. xuLzhtu mt&u BþfJtbtk ytJ<e yluoMx ble xuLzhle hfblt 1% «btKu cukf duhLxe / zebtLz z[tVx / jtufj btRfh auf &e

s MJefthJtbtk ytJNu. ylu <ule vtA¤ ‘ E ’ xuLzhltu xuLzh ytR.ze lkch yawf jFJtltu hnuNu. cukf duhuLxe

yb>tJt> NtFtle ntuJe sYhe Au.

12. ftuLx[tfxh©eytuyu JucmtEx Wvh xuLzh ltuxembtk >NtoÔgt Bþsc òu ftuE Mþ^tht J^tht fhJtbtk ytJuj nNu <tu btLg

htFJtlt hnuNu su ykdu AuÕjt 72 fjtf vnujt Juc mtEx Wvh su <u xuLzh auf fhe ChJtLþk hnuNu.

zebtLz z[tVx / auf “BgwÂlÂmvj fÂb§h©e,ybœtJtœ” lt ltbltu fZtJJtu.

vrµbÍtul Esluh Ft<t îtht «ftrN<

Contractor signature Additional City Engineer

Contractor signature Additional City Engineer