Making Name Board at Diff. Places in Shahibaug Ward.

Name of work: - bægÍtulltk Ntnectd Jtuzobtk swœe swwœe søgtyu ltb œNtoJ<t ctuzo jdtJJtltk ftb ctc<. (yu.yth.me.

Tender Invited on Behalf of AMC, Central Zone.

Assistant Manager, Central Zone,

Central Zone Zonal Office”, B – Wing,

Third Floor,Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

Signature of Bidder Page 2 of

AHMEDABAD MUNICIPAL CORPORATION

Notice inviting Tender

Competent authority on behalf of Municipal Commissioner of A.M.C. invites percentage rate sealed tenders

from interested contractors for the following work at different locations within the limit of A.M.C.

1 Name of work bægÍtulltk Ntnectd Jtuzobtk swœe swwœe søgtyu ltb œNtoJ<t ctuzo jdtJJtltk ftb

ctc<. (yu.yth.me. xuLzh)

2 Estimated Tender Amount

Rs. 10,00,000.00 exclusive of GST). GST will be paid extra

by AMC/Authority at prevailing rate to the contractor

3 Tender fee Rs.900.00

(Non refundable) (Demand Draft in favour of Municipal Commissioner, Ahmedabad)

4 Time Limit 12 Months

5 Download of Tender Tenders from the website www.nprocure.com or shall be down

Documents loaded mentioned AS PER TENDER NOTICE INVITED

6 Required registration Register “E-2” class having in Road Works in PWD in Govt. R&B /

CPWD / AMC or equivalent register with any other state Govt. or

7 Earnest Money Deposit Rs.10,000.00 (Demand Draft / pay order / Bank Guarantee in favour of

(Bid security) Municipal Commissioner, Ahmedabad is to be submitted as prescribed

(1 % of Estimate put to as below. Demand Draft/Bank Guarantee shall be from approved list of

AMC of banks and the issuing branch of bank guarantee shall be of

Ahmedabad city only and it should be valid for for 180 days. ( As

Per AMC finance Dept . Circular No. 5 Dt. 5/5/2007 & F.D.

Circular No. 29 Dt. 7/8/2010 & attched ANNEXURE - 1 finance

dept.circular No-40 Dt.05/11/2020. E.M.D. shall be submitted

physically along with the Physical Submission when applicable.

8 Submission of EMD and Tender Fee & EMD should Submitted physically along with tender

Tender Fees documents as described in the invitation of tender should be

submitted to Assistant Manager- Central Zone, 3rd Floor, B – Wing,

Sardar Patel Bhavan, Danapith, Ahmedabad-380001.

Bid submitted without bid security & tender fee shall be treated as

non responsive and shall be summarily rejected.

9 Mode of sending the The whole tender shall be submitted by two modes.

Tender Documents • Whole tender shall be submitted only on www.nprocure.com

website as per Schedule mentioned in Notice inviting

• Tender Fee, EMD, technical bid and other relevant PQ Documents

as per check list given in tender shall be submitted physically in

two copies (Original & duplicate) in sealed envelope as per

Schedule mentioned in Notice inviting Tender.

10 Last date of receiving As per Notice inviting Tender / Addendum / Corrigendum.

Tenders. The tenders received after latest schedule date and time will not

be entertained under any circumstances.

11 Submission of Price Bid The Price bid shall be submitted online only. The bidder shall fill

percentage rate on amount of BOQ online only until specified.

Price Bid shall be submitted physically duly signed & seal without

mentioning quoted rated, else it shall be considered as rejected.

12 Opening of Technical bid As per Notice inviting Tender / Addendum / Corrigendum.

13 Tender validity period 120 days from the last date of submission of Tender.

14 Security Deposit 5 % of Contract Value to be submitted in the form of (Demand Draft /

pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad. Bank Guarantee shall be from approved list of AMC of

banks as per attched ANNEXURE - 1 finance dept. latest circular.

and the issuing branch of bank guarantee shall be of Ahmedabad City

only. The validity of the Security Deposit shall be up to valid till

days beyond Date of completion of work.

The Security Deposit shall be payable in 10 days (for tenders upto

Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above) from

date of receipt of LOI failing which interest @ 4% per annum will be

charged by AMC.

15 Deductions from Running

a. Retention Money 2 % amount of each Running Bill shall be deducted as a Retention

Money. Such retention money shall be released in the final bill of the

b. Labour welfare cess Labour welfare cess as per the Act, 1996 (non refundable) shall be

deducted from each running bill.

16 Defect & Liability Period Not applicable in this case. If applicable than refer condition of

contract attached over rule as per form B-1 published by Government.

17 Compansation for Delay 10 % of the actual balance work after Time limit expired.

• All the circulars which were published by Authorities of AMC time by time will be applicable on said

Tender and bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the rights to

reject any or all the tenders without assigning any reasons thereof.

• The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In case

authorized signatory holding Power of Attorney and Digital Signatory are not the same, the bid shall be

considered non-responsive.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

(On contractor’s Letter Head / certified with Stamp and Sign with Contact Detail)

TENDER DECLARATION FORM

Additional City Engineer

Ahmedabad Municipal Corporation,

Name of Work:- bægÍtulltk Ntnectd Jtuzobtk swœe swwœe søgtyu ltb œNtoJ<t ctuzo jdtJJtltk ftb ctc<. (yu.yth.me. xuLzh)

I/We the undersigned have carefully gone through and clearly understood the Tender documents of

above mentioned project comprising of Notice Inviting tenders, Articles of Agreement, Scope

of work, Definition of terms, notes Instructions/Information to Bidder, Condition of Contract,

special condition of contract, Appendices, Specifications, Bill of Quantities, furnished by

AHMEDABAD MUNICIPAL CORPORATION.

I/We do hereby offer to execute and complete the whole of the work within the time specified all in

accordance with the specification, designs, drawing and instruction in writing referred to in the said document

and with such materials as mentioned for, at the respective rates which I/we have quoted in the Price Bid or at

such other rates as may be fixed under the provisions of these conditions.

In the event of this tender being accepted I/We agree to enter into an agreement and when required,

execute the contract, according to your form 1 of agreement as or in default where of I/we bound

myself/ourselves to forfeit the "Earnest Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided by AMC

from the date of receipt of letter of acceptance, you will forfeit the earnest money paid by me/us and take

necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for the sum as

mentioned in NIT, the full value of which is to be absolutely forfeited to the Employer If I/We fail to commence

the work specified. Otherwise the Employer shall retain the said sum, as on account of such Security Deposit as

provided for in the aforesaid documents.

I/We agree not to employ sub-contractors other than those that may be approved in accordance with

conditions in the aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any tender, which

are received. I / We also understand & agree that Municipal Commissioner Reserves the right to allot number of

tenders to successful bidders at his sole discretion in case if I / We am/are lowest in more than one tender.

I/We am/are bound to execute the job if the work order is issued within 120 days from the date of

opening of the tender.

I am bound to execute the work by maintaining all Quality aspects/parameters mentioned in the tender

terms and conditions. I am also bound to submit all supporting Genuine Original documents as and when asked

and if any discrepancy found in such documents as well as in the executed Work with respect to

Quality/Quantity at any stage of work or even after completion of work, it will be solely my Responsibility. I am

bound to prove originality of all documents submitted by me and if any Documents found false/fake then

Municipal Commissioner/AMC has right to take any action/penalty/punishment against me.

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality and/or the

construction of road is found to be of an inferior quality under this contract than in such case Municipal

Commissioner/AMC has right to debar/ blacklist permanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi duties, Royalty

on material (i.e. Aggregate, Sand etc.) And any other taxes prevailing and from time to time on such items on

which the same are leviable and the rates quoted by me/us are inclusive of the same.

Yours faithfully

Seal and Sign of Contractor

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal Corporation

(referred to as Employer in these documents) invites sealed bids for the construction of works (as

defined in these documents and referred to as “the work”) detailed in the table given in the Invitation

for Bid (hereinafter called as IFB.) from competent bidder. The bidders may submit bids for the works

detailed in the table given in IFB.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined in this

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-14. An

agency that has been engaged by the Employer to provide consulting services for the preparation or

supervision of the works, and any of its affiliates, shall not be eligible to bid.

3.3 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those are

blacklisted/ debarred for specified period by AMC, Governement of Gujarat, Government of India or any

other entity controlled by it, would not be eligible to submit the Bid.

4.0 Qualification of the Bidder

4.1 Requires registration:- Register as per Notice Inviting Tender having in Road Works in PWD in Govt.

R&B / CPWD / AMC or equivalent register with any other state Govt. or institutions.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to be

disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and attachments

submitted in proof of the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the contract,

inordinate delays in completion, litigation history, or financial failures etc. or debarring from AMC

• Tampered the bid document in any manner.

• Colluded with other prospective bidders for this work to arrive at quoted prices for the purpose of

restricting competition.

• Indulged in inducement of any official of AMC and/or their consulting engineer and other advisors in

any manner whatsoever.

• Proposal not submitted in accordance with this tender.

• During validity of the proposal, or its extended period, if any, the bidder changes his commercial

• The bidder qualifies the proposal with his own conditions.

• Proposal is received after due date and time.

• Commercial proposal is enclosed with the same envelope as technical proposal

• The envelope does not show on the outside the reference of bid and thus gets opened before

the due date of opening.

• The E.M.D. is not deposited in full and in the manner as specified in the clause of Earnest Money

• The tender is in a language other than English or dose not contains its English Translation in case

of other language adopted for tender preparation.

• The tender documents received are not duly signed by authorized person.

• The validity of tender is less than what is stated in the tender.

• Any of the page or pages of tender is/are removed or replaced.

• Any condition which affect the cost.

• If it is joint venture.

5.1 Debarment / Black listing

Notwithstanding the above, the Employer may debar or blacklist any of the bidder(s) for their

misleading or false representations in the forms statements etc. for the period to be decided by

6.0 Cost of Bidding

The bidder shall bear all costs associated with the preparation and submission of his Bid. Employer will

in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and familiarize

himself with the site of Works and its surroundings including source of earth, water, road aggregates

etc. and obtain all information that may be necessary for preparing the Bid and entering into a contract

for construction of the Works. The costs of visiting the Site shall be at the Bidder's own expense.

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby total

amount of work increases / decreases up to any extent.

• If the works gets delayed / postponed for some administrative / technical decision whatsoever.

• If the items stipulated in the tender shall not be executed as per site condition/ requirements. No claim

shall be entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and no claim

shall be entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any) issued.

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

8. Bill of Quantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract data, forms,

terms, technical specifications, forms, Annexes in the bid document. Failure to comply with the

requirements of bid documents shall be at the bidder’s own risk. Bids which are not substantially

responsive to the requirements of the bid documents shall be rejected.

10.0 Amendment of Bidding Documents

10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by issuing

10.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on website

www.nprocure.com The prospective bidder shall refer to website to check any addendum before

hours of opening of bids. AMC will not give any advertisement for the same.

10.3 To give prospective bidders reasonable time in which to take an addendum into account in preparing

their bids, the Employer may, at his desecration, extend as necessary the deadline for submission of

10.4 Prospective bidders should attach the addendum made for the work & if fails to do so than also the

changes made through such addendum shall be applicable & bound to the bidder.

C PREPARATION OF BIDS

11.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

12.0 Documents comprising bid

The e bid submitted by the bidder shall be in two separate parts.

• Technical Bid

• Financial Bid

To qualify for award of the contract, each bidder must submit the following documents along with bid:

• Required Registration Certificate

• Other requested documents

• Any other material / information required to be submitted in accordance with these Instructions

to Bidders (ITB)

Failure to submit these certificates/documents shall make the bid non-responsive.

Above original documents in physical form in two copies, one marked as “original” and other marked as

“Duplicate”, shall be submitted in a sealed envelope by 18:00 Hrs on the date of physical submission of

bid and addressed to the addressee given in the NIT duly super scribed “Name of Work, Bid due date

and time, Name and address of the bidder”

13.0 Bid Prices

• The contract shall be for the whole works as described in Bill of Quantity based on the percentage rate

in the Bill of Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any other cause

shall be included in the rates, prices and total Bid Price submitted by the Bidder, except otherwise

stated in the Bid document. Employer will not compensate the bidder (contractor) for any change in

duties, taxes and other levies payable by the contractor under the contract and any other reasons.

• The percentage rate and bid price quoted by the bidder shall be fixed up to the completion of Work and

shall not be subject to adjustment on any account, except where expressly specified, otherwise, in the

14.0 Currencies of Bid and Payment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in Indian

15.0 Bid Validity

15.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a shorter

period shall be rejected by the Employer as non-responsive.

15.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may request

that the bidders may extend the period of validity for a specified additional period. The request and the

bidders' responses shall be made in writing or by cable. A bidder may refuse the request without

forfeiting his bid security. A bidder agreeing to the request will not be required or permitted to modify

his bid, but will be required to extend the validity of his bid security for a period of the extension.

16.0 Earnest Money / Bid Security

16.1 The Bidder shall furnish, a Bid Security of the amount as shown in the Table of IFB as part of his bid, in

the form of Demand Draft / pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad valid for 120 days.

16.2 The issuing branch of the bank guarantee shall be of Ahmedabad City only

AMC Finance dept. circular No – 03, Dt.28/04/2023

(A) Guarantees issued by following banks will be accepted as SD/EMD on permanent basis.

(1) All Nationalized Banks

(B) Guarantees issued by following banks will be accepted as SD/EMD for the period up to March- 31, 2022. The

validity cut-off date in the GR is with respect to the date of issue of Bank Guarantee irrespective of the date of

termination of Bank Guarantee. Guarantees issued or Authorized by Ahmedabad Branch Only.

Commercial Banks :-

1. A U Small Finance Bank

3. City Union Bank

4. DBS Bank India Limited

6. Equitas Small Finance Bank

7. Federal Bank

10. 10.IndusInd Bank

11. 11.Kotak Mahindra Bank

12. 12.Standard Chartered Bank

13. 13.Tamilnadu Mercantile Bank

14. 14.Bandhan Bank

15. 15.BNP Paribas

16. 16.CSB Bank

17. 17.HSBC Bank

18. 18.Karnataka Bank

19. 19.Krur Vysya Bank

20. 20.South Indian Bank

21. 21.Utkarsh Small Finance Bank

Co-operative and Rural Banks Of Gujarat :-

1. The Ahmedabad Mercantile Co-operative Bank Limited

2. Kalupur Commerical Co-operative Bank Limited

3. Nutan nagrik Sahakari Bank Limited

4. Rajkot Nagarik Sahakari Bank Limited

5. Saraswat Co-operative Bank

6. Saurashtra Gramin Bank

7. The Gujarat State Co-Operative Bank

8. The Mehsana Urban Co-operative Bank Limited

9. The Surat District Co-operative Bank

10. 10.The Surat Peoples Co-operative Bank

11. 11.SVC Co-operative Bank LTD

Seal and Signature of the Bidder Dy. City Engineer-02

16.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as non-

16.4 Any bid having bid security for lesser value and shorter validity period shall be treated as non-

16.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be returned as

promptly as possible.

(b) The bid security of the successful bidder, along with second and third lowest tenders, will be

returned when the successful bidder has furnished the required security deposit and signed the

16.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the Agreement

and furnished the required security deposit.

16.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) sign the Agreement; or

(ii) Furnish the required security deposit.

(iii) commence the work after signing the agreement within 15 days

16.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank

guarantee shall be of Ahmedabad City only.

16.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp papers of

requisite value in accordance with the stamp Act applicable to that particular state of Indian Union,

where executed.

16.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly indicate in

(block letters) his name, designation, Power of Attorney No. / Signing Power No. etc.

16.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by the

executing officers and the last page shall be signed in full, indicating the particulars as aforesaid under

the seal of the Bank.

D. SUBMISSION OF BIDS

17.0 Sealing and Marking of Bids

17.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes and the

three sealed envelopes shall be sealed in an outer envelope. The Bid envelopes shall be marked as

• Complete Tender Document with all necessary qualification related documents (in two copy)

Above two envelopes shall be kept in one envelope and it should be marked as “Technical Bid” and

sealed. This Outer envelope should mention the name of firm of bidder, his address, contact details &

name of the work.

17.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

c) Bear the following identification:

Indicate the name and address of the bidder.

• If the outer envelope is not sealed and marked as above, the Employer will assume no responsibility for

the misplacement or premature opening of the bid.

18.0 DEADLINE FOR SUBMISSION OF THE BID

18.1 Complete Bids (including Technical bid and necessary documents) must be received by the Employer at

the address specified in bid information not later than the date indicated on the face sheet of the

document. In the event of the specified date for the submission of bids declared a holiday for the

Employer, the Bids will be received up to the appointed time on the next working day. The Bidder is

further required to submit Documents in Physical Form on or before the Bid Due Date and before the

time of submission as specified in NIT, at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

18.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-tendering

portal on account of delay in submission at bidder's end. Bidder shall ensure that they submit the bid

well before the "Due Date & Time of Bid- Submission". AMC shall not be responsible if bidder is not able

to submit the bid on account of failure in network/internet connection or any other technical reason.

18.3 The Employer may extend the deadline for submission of bids by issuing an amendment in accordance

with respective Clause, in which case all rights and obligations of the Employer and the bidders

previously subject to the original deadline will then be subject to the new deadline.

18.4 All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

18.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and returned

unopened to the bidder.

Any Bid received by the Employer after the deadline prescribed in NIT will be returned unopened to the

20.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to

expiration of the Bid validity period by writing, facsimile or e-mail confirmed by registered letter. This

letter (hereinafter and in the Conditions of Contract called the “Letter of Acceptance” will state the sum

that the Employer will pay the Contractor in consideration of the execution, completion, and

maintenance of the Works by the Contractor as prescribed by the Contract (hereinafter and in the

Contract called the “Contract Price”).

The notification of award will constitute the formation of the Contract, subject only to the furnishing of

a Security Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the Successful Bidder. It

will be signed by the Employer and the Successful Bidder.

21.0 SIGNING OF CONTRACT AGREEMENT

21.1 The Employer and the successful bidder shall enter into a Contract Agreement within 28 days after the

successful bidder (hereinafter called the Contractor) receives the Letter of Acceptance, unless they

agree otherwise, subject to furnishing the security deposit before signing the Agreement with the

21.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify the

other Bidders that their Bids have been unsuccessful and release their Earnest Money Deposit / Bid

22.0 SECURITY DEPOSIT

22.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the Employer

a security deposit in the form of Bank Guarantee for an amount equivalent to 3% of the Contract Price

valid for the period of valid till 90 days beyond Date of completion of work. The Security Deposit shall be

payable in 10 days (for tenders upto Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above)from

date of receipt of LOA failing which interest @ 4% per annum will be charged by AMC.

22.2 The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from

Ahmedabad branch of any Banks mentioned in the clause no. 16.2 of these tender documents.

22.3 This security deposit shall be released only after the clearance of final bill including pre & post Audit.

22.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of security

deposit or late renewal of bank guarantee for the number of days delayed for submission or

discontinuity of the bank guarantee.

22.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same verbatim as per

the format. Bank Guarantee shall be submitted on right value of stamp paper and for correct value of

22.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall constitute

sufficient grounds for cancellation of the award and forfeiture of the Bid Security.

22.6 In case of any contract amendment during execution of the contract enhancing value of the contract the

BG value shall be enhanced accordingly. Validity of BG shall be commercial terms and conditions of the

22.7 All compensation or other sums of money payable by the Contractor to the Employer under the terms of

this Contract or any other contract or on any other account whatsoever may be deducted from Security

Deposit. Also in the event of the Contractor's Security Deposit being reduced by reasons of such

deductions, as aforesaid, the Contractor shall, within 14 days of receipt of notice of demand from the

Engineer-in-Charge, make good the deficit in Security Deposit.

22.8 Should there arise any occasion under the Contract due to which the periods of validities of Bank

Guarantees as may have been furnished by the Contractor from time to time, are required to be

extended/renewed, the Contractor shall get the validity periods of such guarantees extended/renewed,

and furnish these to the Engineer-in- Charge one month before the expiry date of the aforesaid

Guarantees originally furnished failing which the existing Bank Guarantees shall be invoked by the

Engineer – in – charge. Also in case of any deficit in securities on any account as might occur or is

noticed, the Contractor shall forthwith recoup/replace the same with acceptable Security Deposit.

22.9 The Bank Guarantee shall be extended within the expiry dates wherever activities as per contract are

not completed in all respects.

22.10 The Security Deposit less any amount due shall, on demand, be returned to the contractor after 45 days

of completion date / Final Bill paid date which ever is later. No interest on the amount of Security

Deposit shall be paid to the Contractor at the time of release of Security Deposit as stated above.

22.11 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at Employer’s office

within 15 days of LOA.

23.0 Advance Payment and Security

The Employer will not provide any advance payment.

24.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final and

binding to the bidder.

25.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting from

Contractors completed or under execution by him over last five years. If the details of Litigation History

are hidden by the Bidder and later on it comes to the knowledge of the Employer, the Bidder shall be

disqualified for the proposed work and other appropriate actions shall be taken against the bidder.

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Value of the Reasons/Details for Remarks showing

Year Name of Project (Rs.) litigation/arbitration Present Status

 The bidder shall furnish separate table for individual project.

 The above information shall be supported with necessary documents otherwise the same shall be treat

as null and void.

 A consistent history of arbitration awards? Judgments against the applicants or any partner of a joint

venture may result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to knowledge of the

employer the bidder shall be disqualified for the proposed work and other appropriate actions shall be

taken against the bidder.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Liquidated Damages

1.1 If the Contractor fails to complete the works within the original or extended time limit, the Contractor

shall pay penalty of 10% of amount of actual remaining work. The amount of work for which the scope

of contractor is reduced shall not be considered for the calculation of Liquidated Damages.

1.2 Conditions mentioned in the AMC Finance Department Circular AMC no. 18 Date: 23/05/2017 and all

latest Circulars shall be applicable.

2.0 Retention Money

2 % amount of each Running Bill shall be deducted as a Retention Money. Such retention money shall be

released in the final bill of the said work. AMC reserves right to deduct any amount to compensate the

poor performance of the contractor i.e. poor quality or abandoned / incomplete work.

3.0 Subcontracting

3.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any portion of

Work without the approval of the Employer’s Representative. Any subcontracting shall not relieve the

Contractor from any contractual obligations or responsibility under the Contract.

3.2 The Contractor shall not be required to obtain consent for a subcontract for which the name of the

subcontractor and scope of works activities to be performed by him is already stated in the contract or

supply of material or engagement of labour.

4.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred to in

the Bid document to carry out the functions stated in the Schedule or other personnel approved by the

Engineer. The Engineer will approve any proposed replacement of key personnel only if their

qualifications, abilities, and relevant experience are substantially equal to or better than those of the

personnel listed in the Schedule.

4.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof, for his

misconduct or inadequacy of technical skills and experience, who is a member of the Contractor’s staff

or his work force, the Contractor shall ensure that the person leaves the Site within seven days and has

no further connection with the work in the Contract.

4.3 No residential accommodation is allowed at the site of work. The labour huts shall not be erected on the

site of work and contractor shall make his own arrangements to provide such accommodations as per

the rules of the local bodies. He shall make his own arrangements for housing, stores, field office etc. He

shall submit a site layout plan indicating the location of various site facilities to be created by him at his

cost for the execution of work. The Owner shall in no way be responsible for any delay on this account

and no claim on this account whatsoever shall be entertained. All Basic amenities shall be provided by

the Contractor to Labours as per the prevailing labour Laws.

5.1 The Contractor shall have full regard throughout execution, completion and defects liability period to

following safety aspects and shall take all necessary steps to ensure that danger to safety is avoided all

the time in respect of,

Safety of the works

• Safety of the Contractor’s employees and all the persons directly or indirectly engaged by him

• Safety of all the employees including persons working on other contracts of Employer at the

same site of the Employer and Engineers employees engaged at work site.

• Any authorized third party persons on the site.

• Contractor’s plant and equipment

5.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs,

barricading, and cones; when and where necessary, or required by Engineer in Charge or by any duly

constituted authority for the protection of the works or for the safety and convenience of the public or

5.3 The Contractor shall take all reasonable steps to protect the environment on and off the site and avoid

damage or nuisance to persons or property of the public and others arising as a consequence of his

method of operation.

5.4 The Contractor shall maintain in good condition all work throughout execution, completion, and defects

liability period. The contractor shall be responsible for and to make good all injuries, damages and

repairs, rendered necessary by fire, rain, traffic, floods or other causes.

5.5 All the scaffolding work, wherever required for the execution of work, shall be provided by the

contractor. Nothing extra shall be payable on this account. It shall be provided strictly with double

scaffolding system with all the accessories etc. with adjustable suitable working platforms to access the

areas, with ease for working and inspection. It shall be designed to take all incidental loads. It should

cater to the safety features for workmen. It shall be ensured that no damage is caused to any structure

due to scaffolding.

5.6 All temporary warning/ caution boards display shall be provided and displayed during day as well as

night time by the contractor, wherever required and as directed by the Engineer.

5.7 Arrangement of temporary water and electricity and telephone connection required, by him, shall be

made by the Contractor at his own cost and also necessary permissions directly from relevant Owners

shall be obtained by him under intimation to the Owner. Also all initial and running charges and security

deposit, if any in this regard shall be borne by him. The Contractor shall abide by all the rules/ bye laws

applicable in this regard and he shall be solely responsible for any penalty on account of violation of any

of the rules and byelaws in this regard.

5.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the same shall

be completely contractor’s responsibility. All the losses due to such accidents and expenses of legal

matters shall be borne by contractor.

5.9 The Contractor shall be responsible for maintenance and watch and ward of the complete installation

and shall also be responsible for any pilferage, theft, damage, penalty etc. in this regard. The Contractor

shall indemnify the Owner against any claim arising out of pilferage / theft, damage, penalty etc.

whatsoever on this account.

5.10 The Contractor shall depute Site Engineer & skilled workers as required for the work. Necessary

protective and safety equipments shall be provided to them by the Contractor at his own cost and used

6.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage rubbish, excess

materials, temporary works no longer required will be removed from site immediately.

7.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials, rubbish,

temporary works of every kind.

A. COST CONTROL

8.0 Bill of Quantities

a. The schedule-B shall contain Memorandum showing items for the construction, installation, testing,

and commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be paid only

quantities calculated after taking measurements of executed work. The rate stated in the schedule B

for each item of work shall apply. The works shall be measured by the Contractor jointly with the

authorized representative of the Engineer and all particulars required by the representative of the

Engineer shall be supplied by the contractor.

c. The work shall be measured net. No allowance for general or local custom, working space etc. is to

9.1 The Engineer in Charge shall have power to make any variation of form, quality or quantity of the works

or any part thereof that may, in his opinion, be necessary and for that purpose, or if for any other

reason it shall, in his opinion, be appropriate, he shall have the authority to instruct the Contractor to do

and the Contractor shall do any of the following:

 Increase or decrease the quantity of any work up to any extent included in the contract,

 Omit any such work,

 Change the character or quality or kind of any such work,

 Execute additional work of any kind necessary for the completion of the Works or

 Change any specified sequence or timing of construction of any part of work.

9.2 No such variation shall in any way vitiate or invalidate the contract, but the effects, if any, of all such

variations shall be valued in accordance with the following sub clauses. Provided that where the issue of

an instruction to vary the Works is necessitated by some default or breach of contract by contractor or

for which he is responsible, any additional cost attributable to such default shall be borne by the

9.3 The Contractor shall not make any such variation without an instruction of the Engineer. No instruction

is required for quantities varying from those provided for the items in the contract schedule B.

10.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows in the same

order of priority.

a) Variations in the quantities of work in schedule of quantities shall not vitiate the contract.

b) The contractor shall be bound to execute extra items of work as directed by the Engineer-in-charge.

c) Contract unit rates for individual items shall apply to varied quantities where there is a quantity

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

10.2 If any extra item crops up during the progress of work the same shall be carried out by the Contractor

and he shall be paid at the rate fixed by Employer which shall be fixed as lowest of the rates derived by

rate analysis based on the following three methods. , the priority of the documents forming the

Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2013-14, the rate of

extra item shall be that rate and premium (above or below) quoted by contractor.

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and equipment, the

cost of all temporary and incidental works, the overheads and the Contractors profit.

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs, the cost of

use of all plant, machinery, and equipment, the cost of all temporary and incidental works.

10.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall be taken at

10 % of the final rate derived.

10.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in his opinion

appropriate and shall notify the Contractor accordingly with a copy to the Employer.

10.5 The Engineer shall determine provisional rates and prices to enable on account payments to be included

in the Interim Payment Certificates, until rates and prices are agreed as final by the Employer, the

Contractor, and the Engineer.

10.6 The Contractor shall not be entitled to additional payment for costs, which could have been avoided by

giving early warning.

11.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in terms

of the contract and taxes at source, as applicable under the law. The Employer shall pay the Contractor

the amounts certified by the Engineer.

11.2 If an amount certified is increased in a later date certificate due to corrections in previous certificates or

as a result of an award from disputes review experts, Contractor shall be paid such amount only. The

Contractor shall not be paid any interest upon such delayed payment.

11.3 Items of the work for which no rate or price has been entered in will not be paid for by the Employer

and shall be deemed covered by other rates and prices in the Contract.

11.4 All payments shall be made in Ahmedabad.

12 Taxes and duties

12.1 The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local Governing

bodies prevailing on the date of award of the contract. The Contractor will have to pay all such taxes and

duties for the performance of this Contract. The Employer will deduct from the Contractor’s monthly

and other payments all taxes and duties, which he is bound to recover in accordance with the applicable

12.2 The Contractor shall keep himself fully informed of all acts and laws of the Central & State and local

Governing bodies, all orders, decrees of bodies, tribunals having any jurisdiction or authority which in

any manner affect those engaged or employed, and anything related to carrying out the work. All the

bye-laws lay down by AMC/AUDA and any other local bodies while executing the work shall be adhered

to. All taxes of local bodies shall be borne by the contractor. The Contractor shall arrange to give all

notices required by any authority and to pay to such authority all the fees that may have to be paid for

the material, plants, equipments etc. The Contractor shall also adhere to all traffic restrictions notified

by the local authorities. He shall protect and indemnify the Owner and its officials & employees against

any claim or liability arising out of violations of any such laws, ordinances, orders, decree, whether by

himself or by his employees or his authorized representatives. Nothing extra shall be payable on these

13.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-1831-M(3) dt.

9/12/05 issued by G.O.G. (non-refundable) shall be deducted from every bills which shall be deposited

to Govt. Labour Department for Labour welfare fund.

14.0 Currencies

All payments shall be made in Indian Rupees.

15.0 Advance Payment

No Advance Payment shall be made.

16.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and

the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if

the loss or damage arises from the Contractor's acts or omissions.

B. FINISHING THE CONTRACT

17.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the

Engineer will do so upon deciding that the Work is completed.

18.0 Termination

18.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after receipt by

him of a Notice to this effect from the Engineer/Employer after signing the agreement or

2. To proceed with the works, or any section thereof, within 28 days after received notice

3. Has failed to comply with a notice issued or an instruction issued within 28 days after having

4. Abandons the works or otherwise plainly demonstrates the intention not to continue

performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written permission of

6. Has failed to furnish the required securities or extension thereof in terms of the contract.

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order

made against him, compounds with his creditors, or carries on business under receive, trustee

or manager for the benefit of his creditors, or if any act is done or event occurs which (under

applicable Laws) has a similar effect to any of these acts of event.

18.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to the

contractor, terminate the contract and expel the contractor from the site. However, in the case of sub-

paragraphs (h), the Employer may be notice terminate the contract immediately.

18.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the Employer,

under the contract or otherwise.

18.4 After termination, the Employer may complete the works and/or arrange for any other entities to do so.

The Employer and these entities may then use any goods, contractor’s documents and other design

documents made by or on behalf of the contractor.

18.5 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental

breach of the Contract.

18.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the current Program

and the stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a

reconstruction or amalgamation;

(c) The contractor fails to fulfill requirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach of

Contract and the Contractor fails to correct it within a reasonable period of time determined by the

(e) the Contractor does not maintain a security which is required;

(f) the Contractor has delayed the completion of works by the number of days for which the maximum

amount of liquidated damages becomes payable as defined in the Contract data;

(g) if the Contractor, in the judgment of the Employer has engaged in corrupt or fraudulent practices in

competing for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving, receiving or

soliciting of anything of value to influence the action of a public official in the procurement process

or in contract execution. “Fraudulent practice” means a misrepresentation of facts in order to

influence a procurement process or the execution of a contract to the detriment of the Borrower,

and includes collusive practice among Bidders (prior to or after bid submission) designed to

establish bid prices at artificial non-competitive levels and to deprive the Borrower of the benefits of

free and open competition.”

18.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a cause other

than those listed above, the Engineer shall decide whether the breach is fundamental or not.

18.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

18.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and secure

and leave the Site as soon as reasonably possible and handover the site to the Employer including all

materials and plant and equipment existing there upon.

19.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the same. He

shall also be responsible for the correctness of the positions, levels, dimensions, and alignment of all

parts of the structures as per instructions given to him. If at any time any error shall appear during the

progress of any part of the work, the contractor shall at his own expense rectify such error if called upon

to the satisfaction of the Engineer in charge.

20.0 Overpayment & Underpayment

20.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or under this

Contract against the contractor the same may be deducted by the Municipal Corporation from any sum

then due or which at any time thereafter may become due to the contractor under this contract and

failing that under any other contract with the Municipal Corporation or from any sum due to the

contractor with the Municipal Corporation (which may be available with Municipal Corporation), or from

his retention money, or he shall pay the claim on demand. The Municipal Corporation reserves the right

to carry out post payment audit and technical examination of the final bill including all supporting

vouchers, abstracts, etc.

20.2 The Municipal Corporation further reserves the right to enforce recovery of any over payment when

detected notwithstanding the fact that the amount of the final bill may be included by the Contractor.

20.3 If as a result of such audit and technical examination any over payment is discovered in respect of any

work done by the Contractor or alleged to have been done by him under the contract, it shall be

recovered by the Municipal Corporation from the contractor by way of all the means prescribed above

or if any under payment is discovered by the Municipal Corporation, any amount due to the contractor

under this contract or under payment may be adjusted against any amount then due or which may at any

time thereafter become due before payment is made to the contractor from him to the Municipal

Corporation on any other contract account whatsoever.

21.0 Materials obtain from dismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for reasons

other than on account of bad or imperfect work, the materials obtained from dismantling will be the

property of the A.M.C. and will be disposed of as per instruction of Engineer-in-charge in the best

interest of the A.M.C.

22.0 Dispute to be referred to Arbitrator

The disputes relating to this contract, so far as they relate to any of the following matters, whether such

disputes arise during the progress of the work or after the completion or abandonment thereof, shall be

referred an independent Arbitrator appointed by AMC as far possible in consultation with the agency if

it is necessary and such disputes shall be settled in accordance with the arbitration and conciliation Act.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon the works of

the site thereof or belonging to the contractor or procured by him and intended to be used for

execution of the work or any part thereof possession of which may have been taken by the

Engineer-in-charge under the said clause –5.

(ii) The reduction in rates made by the Engineer-in-charge under clause 9 from the items of works

not accepted as completed fully in accordance with the sanctioned specifications.

(iii) The rate of part of payment for any class of work which is included in the additional or altered

work carried out by the contractor in accordance with the instructions of the Engineer-in-charge

under clause 14 and the rates for which is to be determined under the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by the

contractor before receipt of notice given by the Engineer-in-charge under clause 15 and/or

amount of compensation payable to the contractor under the said clause for loss in respect of

such materials.

(v) The amount of compensation which the contractor shall be liable to pay under clause 17 in the

event of this failure to rectify, remove or reconstruct the work within the period specified in the

written intimation or the amount of expenses incurred by the Engineer-in-charge under the said

clause17 in rectifying, removing or re-executing the work or in removing and replacing the

materials or articles complained of.

(vi) The reduction of rates as may be fixed by the Engineer-in-charge under clause 17 for the inferior

work or materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates and assessed

(viii) The amount payable to the contractor for the work carried out under clause 33 in accordance

with the instructions and the requirement of the Engineer-in-charge in case where there are no

specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and calculations to

every item of claims. The decision will have to be implemented by all the concerned.

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation approaching

on Court of Law. It shall be within the jurisdiction where the site of work is situated.

The reference to arbitration proceeding under this clause shall not:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause 5 to take

possession of all or any tools, plants, materials and stores in or upon the works of site thereof

belonging to the contractor or procured by him and intended to be used for the execution of the work

or any part thereof.

ii) Preclude the Engineer-in-charge from utilizing the materials purchased by the contractor in any work

or from removing such materials to other places, during the period the work is stopped or suspended

in pursuance, of notice given to the contractor under clause

iii) Progress of the work or the carrying out the additional or altered work in accordance with the

provisions of clause 14 or as the case may be, of clause

23.0 Drawings and Photographs of the Works

23.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No separate

payment will be made to the contractor for this. . The contractor shall have to submit the same in hard

copy as well as soft copy as and when demanded by the AMC.

23.2 No photograph of the works or any part thereof or plant employed thereon, except those permitted

under clause 59.1, shall be taken, or permitted to be taken by the Contractor or by any of his employees

or any employees of his sub-Contractors without the prior approval of the Engineer in writing. No

photographs/ videography shall be published or otherwise circulated without the approval of the

Engineer in writing.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

ybœtJtœ BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe œhJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt ybœtJtœ BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg gtœelt

ftuLx[fxhtu Che NfNu. dJobuLxlt btLg ftuLx[tfxhu ybœtJtœ BGþrl.ftuvtuohuNlbtk btLg ftuLx[tfxhtule

gtœebtk hSMxuNl fhtJJtlwk hnuNu.

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u stuzJtle hnuNu.

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt mûtb ntug

<ublu s ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs xtRb jebexbtk ÃþY

fhJt sYhe mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt hnuNu.

z:- ybœtJtœ Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t

mexe.Rsluh mh¾gwjh,lk -17,<t.09/12/2012 bwsc ybœtJtœ Bgwrlrmvj ftuvtuohuNlbtk ftuLx[t¾xh

hSMxuNl Ve, heLgwyj Ve <&t yvd{uzuNl Ve ylu btvœkztu ægtlbtk htFe <u bwsc ybj fhJtltu hnuNu.

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe btdo, mkath

ylu JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu mtRx ylu rcÕzekd(fu

su ftb fhJt, ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj ntug).<ubs xuLzhhu yt mtRxlt ftb

btxu, rcÕzekd btxu, gtzo, zevtu btxule søgt vtu<tle he<u bu¤Je juJtle hnuNu. (xuLzhlwk ftb fhJt, ftb

vwhwk fhJt <&t ftblt buRxulLm btxule søgt)

(h) yt ftble mbg bgtoœt bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle œhufu œhuf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt œM<tJus vh<

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]< fh<wk

bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u cezJtle hnuNu.

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt œhuf vtlt ylu rJd<tu vh ftuLx[tfxhu mne fhJe.

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh œM<tJustult jFtKbtk ftuR AufAtf fu VhuVth fhJtbtk

ytJtNu lrn ylu ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug <tu <ult vh

l Dwkx<t Ftuxt jFtK fu ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ Wfju <u he<u jFJt.

«ðguf mw^tht vh xwkfe mne fhJe.

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk œNtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug <tu xuLzh

ybtLg dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu ftuLx[tfxhtult

btdoœNol btxu mtbtLg rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK œNtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk ytJNu.

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt vîr<

y&Jt rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu cœÕGþ / cœÕgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk œhuf Ctdeœth y&Jt <u ykdulwk bwFðgthltbwk ^htJlth Ôgrf<

mne l fhu y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR mtûteyu mtF fhe

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, hœ fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu rlKog

ytFhe hnuNu. ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh ftuRvK «fthltu

lwfNtle fu J¤<hltu nff œtJtuu fhe NfNu lrn fu ftgœtfeg ftgoJtne yt ykdu &R NfNu lrn. xuLzh

bkswh &gtltu y&o ftb ytve œuJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh MJefthJtbtk ytJNu lne.

(9) rJmkdr< ylu rnmtc stud:

nt& ^hJtlt ftbtule ctc< œNtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK Cwjawf

leault rlgbtu ylwmth mhCh fhJtbtk ytJNu.

(1) xuLzh Chlthu œhuf Ftltbtk sKtJuj Nçœtu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nçœtuubtk sKtJuj

hfb btLg htFJtbtk ytJNu.

(2) yufb œh ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu œNtoJ<e CtJ vºtflt Ftltbtk&e

hfbbtk Cwj sKtg <tu yufb œh btLg htFJtbkt ytJNu ylu œhlt yt^thu dwKtfth mw^thJtbkt

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgtoœt bwsc fhJtltu hnuNu. yt mbgbgotœt 10 jtF mw^elt ftb btxu

yuj.ytu.ytR. ytÃgt <theF&e 10 rœJm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg <theF&e

15 rœJm&e NY &guj dKJtbt ytJNu. <&t <u œhBgtl ftble 3% juFu zevtuÍex Che fhthvºt fhJtltu

xuLzhbtk ftuLx[t¾xh îtht Chujt CtJ <btb «fthlt su <u «J<o<t mhfthe xuût mrn<lt CtJ

dKJtbtk ytJNu. ylu <ubtk atjw ftb œhBgtl su ftuR VuhVth &Nu <ultu J^thtu awfJJtbtk ytJNu lrnk.

c:- mûtb m•tt îtht Yt.10,00,000.00 (œm jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ctœ (LOI)

ytvJtbtk ytJNu ðgth ctœ rœl - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu. rm¾gtuhexe

zevtuÍex btuze ChJtlt rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth ftgoJtne fhJtbtk

f:- bkswh &guj xuLzhle mbgbgtoœtbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk

sKtJuj «btKu bkswh &guj mbgbgtoœt ctœlt FhuFh ctfe ftble hfblt bn•tb 10% juFu

(jefJezexe zubuSm) vulÕxe Jmwj fhJtbtk ytJNu.

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt œh vwhtk &gujt ftb btxult Au ylu <ubtk bswhe,

vtjF, ÃjtLx, œuFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu <btb Faoltu

<&t sYh sKtg <tu ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu mbtJuN &Nu ylu xtkfujt

CtJ fu œh fh<t J^thtle ftuR awfJKe ykdult <ublt ftuR œtJt ægtlbtk juJtNu lnek ylu xuLzh Chlth

Ftuxe hswyt<lu fthKu y&Jt ftuR Ôgrf<yu (vAe<u ctk^ftb rJCtdltu fboathe ntug fu l ntug) <ublu

ytvuje btne<elu yt^thu vtA¤&e ftuR œtJt hsw fhJt nfœth hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk

swœt swœt CtJ ylu œh ChJt btxu sYhe yuJe <btb btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u

xuLzh hsw fhJtlu je^u y&Jt <ubtk&e WCt &<t ftuR stuFb fu sJtcœthebtk&e Axfe NfNu lnek. mœh

ftbbtk ftuR vK ò<lt ctk^ftblt bxehegj Wvh CtJ J^thtu ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt ytJNu. <&t

Bgwrl. frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu ftbdehe/ybj fhJt rcl Nh<e

ckDlf<ot hnuNu.

f:- ftuLx[t¾xhlt œhuf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk vubuLx +

yu¾x[t ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh< ytvJtbtk ytJNu.

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftgœt bwsc su ftuR hfble fvt< fhJtle &Nu <u bwsc

ftuLx[tfxhlt cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e œM<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw

ce:- xuLzhbtk œNtoJuj ftb mkck^e œM<tJusbtk œNtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau œNotJuj

¢btlwmth œM<tJusbtk œNtoJuj rJd< d{tng htFJtbkt ytJNu.fhth mkc^e œM<tJustu fhthlt ydðglt

Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu fœ:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk fœ, ytfth, ytkfzt fœta Ftuxt ntug <tu btvujt fœ, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^ bwfe

yuze.mexe yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc fhJtbkt ytJuj

rlKog ykr<b dKJtbkt ytJNu.

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe ylu

Rsluh Rlatsuo Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl fhtJJwk.

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) yufe JF<u yuf fh<t J^w søgtytuyu ftb NY fhJtltu Jfo ytuzoh b¤u <tu ftb yuf mt&u s c^u NY fhJw

(16) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu lwfNtl

&Nu <tu <ule mkvwKo sJtcœthe (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb œhBgtl bswhtu fu

sl<tlt ftuR btKmlt òlbtj lu lwfNtl &tg <ule sJtcœthe ftuLx[tfxhle hnuNu. vtujem Vrhgtœ

&tg <tu <ule sJtc>the vK ftuLxtfxhle hnuNu. CuFz Dme l vzu <ule sJtc>the vK vtujem

Vrhgtœbt ftuLx[tfxhle hnuNu. CuFz Dme l vzu <u btxu mjtb<elt vdjt (suJt fu œtuhzwk ctk^e bswh

Ftztbtk W<thJt, mtuhekd ylu Mx[xekd fhJt rJduhu) je^t Jdh bsqhlu Ftztbtk W<thNu <tu ftuLx[tfxh s

vtujem Vrhgtœbt sJtcœth hnuNu ylu Bgwrl.ftuvtuohuNlltu ftuRvK MxtV ytlt btxu sJtcœth hnuNu

lrn. ytxjwk mbSlu s xuLzh ChJwk. œhuf ftb fh<t bswhtultu rJbtu vK W<thujtu ntuJtu stuRyu.

(17) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu fhtJJtlt hnuNu.

bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.<&t atjw ftb œhBgtl

yuLSlegh Rlatso îtht ybœtJtœ Bgwrlmevj ftuvtuohuNlle buxjzuvtu jucbtk xuMxekd fhtJJt

sKtJJtbtk ytJu <tu ftuLx[t¾xh îtht <ulw vtjl fhJtlw hnuNu.

(18) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu rlgb

ylwmth <u ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(19) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< rœl 1btk vh< jR sJtltu

hnuNu. yLg&t <ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(20) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc ve.yuV/juch

yufx <&t bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftgœtlw vtjl fhJtlwk hnuNu <&t yt ykdu

Bgwrl.ftuvtuohuNl îtht su btne<e btkdJtbtk ytJu <u ytvJtle hnuNu. bu.BGþrl.frbNlh©elt mh¾âwjh

Bþsc sYhe ctknu^he vºtf ytvJtLþk hnuNu.

(21) ftuRvK ftgœtfeg jexeduNl ybœJtœ Nnuhle ftuxobt hnuNu.

(22) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu <ubs

dtuXJJtltu hnuNu.

(23) ftuR vK mhfthe fhJuht ChJtle <btb sJtcœthe ftuLx[tfxhle hnuNu.

(24) ftuLx[tfxh îtht xuLzhbt œNtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc jtJJtlt

hnuNu.<&t xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw vtjl fhJtlw

(25) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l ntug <uJe

J^thtle ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb ylwmth J^thtle

ytRxblt CtJ lffe fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk ytJNu.

(26) atjw ftb œhBgtl «tuxufNlle mkvwKo sJtcœthe ftuLx[tfxhle hnuNu. subtk vevzt, œtuhzt Cgmwaf

ctuzo, ÃjtMxef vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK yfMbt< &Nu <tu <ule

mkvwKo sJtc>the ftuLx[tfxhle hnuNu.

(27) M&¤ Wvh atjw ftbdehe œhBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg Ôgrf<lt

yfMbt<lt rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem ftgoJtnele sJtc>the

ftuLx[tfxhle hnuNu.

(28) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk œhhtus fhuj ftbdehe <&t

yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk ftuBÃjtgLm ytvJtlwk hnuNu

ytJe ltu^lt sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu ftuLx[tfxhlu vulÕxe fhJtle m•tt

yuze.mexe yuLSlehgh©elu hnuNu.

(29) œhuf ytRxblt MvuNeVefuNl ybœtJtœ Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg htFuj

MvuNeVefuNl Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk

yuze.mexe.yuLSlegh©eltu rlKog ytFhe hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu œhhtus J^thtltu

zucheÍ WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu sutFbu Jdh ltuxemu Jtuxhekd fhtJJtbtk <&t

zucheÍ WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(30) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve juJtbtk

(31) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg œhBgtl

ftuLx[tfxh îtht ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk ytJNu.

(32) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu VhSgt<

(33) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk ftb btk

ftuRvK mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj M¾{uJSkd ykdule

btdoœrNoft lwk vtjl fhJwk.

(34) mœh xuLzhle ytRxbtult CtJtu ltKt Ft<t lt mhfgwjh lk.38, <t.21/11/22 <&t mûtb m•ttle b¤uj bkswhe bwsc GST rmJtg

dKºtebtk juJtbt ytJuj <&t «Jo<btl rlgb bwsc GST awfJJt vtºt &Nu su&e <btb cezomu <u bwsc dK<he fhe xuLzhtu ChJtlt hnuNu.

(35) mœh xuLzh yk<od<lt ftb mkjøl y.Bgw.ftu.btk vJo<btl <btb rlgbtu/mhfgwjhtu jtdw vzNu <ubs JF<tu JF< &lth mw^thtytu vK

jtdw vzNu. sule ltuk^ jR xuLzhtu ChJtlt hnuNu.

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le bwjtft<

je^e Au ylu ftblu jd<t btjmtbtl, bswhe ylu ceS ctc<tulu jd<e M&trlf

vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu jd<t

œM<tJustu ft¤SvwJof yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb< Awk/Aeyu.

ftuLx[tfxhle mne ylu rmfft

TECHNICAL SPECIFICATIONS:

ftblw ltb:- bægÍtulltk Ntnectd Jtuzobtk swœe swwœe søgtyu ltb œNtoJ<t ctuzo jdtJJtltk ftb ctc<. (yu.yth.me. xuLzh)

Item No : 1:- P/F structural steel frame as per design using angles,chanel secction the rate

incl.cleaning cutting ,bending ,welding and fabrication as per design the rate

incl.carting the frame to thae site applying red oxide and two coat of oil paint

colour as directed.name board indicating pole/street name of approach should be

of plain MS sheet (C.R.C. sheet) to be fixed on 80 mm dia.M.S.pipe or any

appropriate dia.of pipe & 40 mm x 40 mm x 5 mm size angle and 30 mmx6 mm

flates framing work having M.S.decorative basket design artical which given as

per drawing or engg.in charge.

P/F structural steel frame as per design using angles,chanel secction the rate

incl.cleaning cutting ,bending ,welding and fabrication as per design the rate incl.carting

the frame to thae site applying red oxide and two coat of oil paint colour as

directed.name board indicating pole/street name of approach should be of plain MS

sheet (C.R.C. sheet) to be fixed on 80 mm dia.M.S.pipe or any appropriate dia.of pipe &

40 mm x 40 mm x 5 mm size angle and 30 mmx6 mm flates framing work having

M.S.decorative basket design artical which given as per drawing or engg.in charge.

Mode of Measurement shall be on Kg basis.

Item No : 2:- Lettering (with painting / radium patti) charges and printing Muni.corporation

Symbol with help of skelled artist including colour cost.

Painting two coat of oil paint on exi.steel board with lettering the name of pole and

painting the same etc. comp.painting AMC logo and pipe with one coat of primer incl.all

labour charges etc. comp as dire by engg.in.charge.work should be done as per

instruction of engg. in charge.

Mode of payment shall be in no

Item No : 3 :- Providing and laying cement concrete work 1:2:4 (1- Cement : 2- Coarse sand : 4-

graded stone aggregates 20 mm nominal size) and curing complete excluding

cost of formwork and reinforcement for reinforced concrete work in (A)

Foundations, footings, Base or columns and Mass concrete

Providing and laying cement concrete work 1:2:4 (1- Cement : 2- Coarse sand : 4-

graded stone aggregates 20 mm nominal size) and curing complete excluding cost of

formwork and reinforcement for reinforced concrete work in (A) Foundations, footings,

Base or columns and Mass concrete Mode of payment shall be in cmt

Item No : 4 :- Prismatic grade reflective sheeting with super high perfomance durable micro

prisnatic material confirming to type XI as per ASTM-D 4956-09 & cutting pesting

letter according to IRC standard in singal language with micro prismatic

confirming to type XI.App.rate

Prismatic grad reflective sheeting with super high perfomance durable micro prismatic

material confirming to type XI as per ASTM-D 4956-09 & cutting pesting letter according

to IRC Standard in Singal language with micro prismatic confirming to type XI.Item

should be executed as per site requirements amd instructions given by Engg-In-Charge.

Mode of payment shall be in Smt.

Item No : 5 :- Providing And Fixing 75 mm MS pipe 5 mt long with nece.hold fast incl.nece

excavation in asphlat c.c.1:1.5:3 and three coat of oil paint erecting the same as

dire.(app.rate)

Providing And Fixing 75 mm MS pipe 5 mt long with nece.hold fast incl.nece excavation

in asphlat c.c.1:1.5:3 and three coat of oil paint erecting the same as dire

Mode of payment shall be in No.

Item No : 6 :- P/F 0.45 mt.wide 14 gauge MS Steel with outer perifery angel 40 mm x 40 mm x

mm with MS flat 40 mm x 5 mm m c/c ereceting the same with pipe incl.providing

and erecting logo with two coat of oil paint etc.comp incl.all labour charges as

dire by engg.in chargs.(app.rate)

P/F 0.45 mt.wide 14 gauge MS Steel with outer perifery angel 40 mm x 40 mm x 5 mm

with MS flat 40 mm x 5 mm m c/c ereceting the same with pipe incl.providing and

erecting logo with two coat of oil paint etc.comp incl.all labour charges as dire by engg.in

chargs.(app.rate)

Mode of payment shall be in Rmt.

Seal and Signature of the Bidder Addl. City Engineer

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

E TENDER NOTICE NO. – 07 /2026-27

Special Tender Clause For CCRS SLA

Ahmedabad Municipal Corporation has to make a special clause as per for SLA

Name of work :-

<t.22.01.2026 lt htus bu.Bgwrlrmvjfrb§hmtnucle Jefje bexekdbtk &guj aatobtk bwÆt lk.21 bwsc

su <u me.me.yth.yum.le Vhegtœlu y.Bgw.ftu.îtht cltJuj Ôntuxmyuv d{wvbtk bwfgt ctœ «tuçjubJtRÍ yum.yuj.yu.lt mbgdt¤t

ctœ fhuj ftbdehe btxu,awftJJtlt &<t ltKtkbtk&e y.Bgw.ftu.lt rl<e-rlgb bwsc vulÕxe leau bwsc fhJtbtk ytJNu.

(A) Penlty For Maintenance and SLA Purpose

CCRS within SLA time (Category & Problem wise) CCRS After SLA time

(Category & Problem wise

Department Category Problem SLA Penalty Penalty Penalty

(Hours) (Hours) (Hours)

Engineering Water>>Engineering Water-low presure 240 240 480

Engineering Water>>Engineering Water-No Supply 240 240 480

Engineering Water>>Engineering Water-Other 72 72 144

Engineering Water>>Engineering Water-Leakage In 48 48 96

Main Line Hours

Engineering Water>>Engineering Water-Pollution In 24 24 48

Engineering Drainage>>Engineering Drainage-Manhole 24 24 48

Cover Missing Hours

Engineering Drainage>>Engineering Drainage-Other 48 48 96

Signature of Bidder Page 1 of

Ahmedabad Municipal Corporation

Engineering Drainage>>Engineering Drainage-Choking Of 48 48 96

Engineering Drainage>>Engineering Drainage-Public 72 72 144

Toilets and Urinals- Hours

Blockage or Choking

Engineering Road Road-Other 48 48 96

Engineering Road Road-Bhuva On 48 48 96

Engineering Road Road-Repair Require 72 72 144

Engineering Storm Water Road-Water logged 24 24 48

Due To Rain Hours

Engineering Storm Water Road-Catch Pit 96 96 192

Repairing Hours

Engineering Public Building Public Building- 360 360 720

Public Toilets and Hours

Urinals-Repairing of

Doors,Windows,Tiles

Engineering Footpath Road-Footpath 168 168 336

Repairing Hours

Engineering Building>>Engineering Building-Municipal 168 168 336

Schools Repairing Hours

Wvhtuf< vulÕxele mbgbgtoœt ctœ vK ftbdehe fhJtbtk l ytJu <tu vwhuvwhe ftbdehele hfb suxje vulÕxe

(A) Penalty 10% for New Allocated Works.

(B) The Work Order under this Annual Rate Contract (ARC) Tender shall be issued

only against the approved and sanctioned estimate for the respective work.

The time limit for execution of each work shall be specified in the respective

Work Order issued under this tender.

Signature of Bidder Page 2 of

Ahmedabad Municipal Corporation

Any penalty for delay or non-compliance shall be calculated and imposed based

on the approved sanctioned estimate amount of the respective work and shall be

governed by the relevant terms, conditions, specifications, and penalty clauses

of this tender.

Seal and Signature of the Bidder Additional City Engineer (CZ)

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 3 of

Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

Engineering Department - Central Zone

ftblwk ltb :- bægÍtulltk Ntnectd Jtuzobtk swœe swwœe søgtyu ltb œNtoJ<t ctuzo jdtJJtltk ftb ctc<. (yu.yth.me. xuLzh)

Sr. Rate Amount

Quantity Item Description Per

1 604.12 P/F structural steel frame as per design using

angles,chanel secction the rate incl.cleaning cutting

,bending ,welding and fabrication as per design the

rate incl.carting the frame to thae site applying red

oxide and two coat of oil paint colour as directed.name

board indicating pole/street name of approach should

be of plain MS sheet (C.R.C. sheet) to be fixed on

mm dia.M.S.pipe or any appropriate dia.of pipe &

mm x 40 mm x 5 mm size angle and 30 mmx6 mm

flates framing work having M.S.decorative basket

design artical which given as per drawing or engg.in

2 100.00 Lettering (with painting / radium patti) charges and

printing Muni.corporation Symbol with help of skelled 1785.71 No.

artist including colour cost.

3 30.00 Providing and laying cement concrete work 1:2:4 (1-

Cement : 2- Coarse sand : 4- graded stone aggregates

20 mm nominal size) and curing complete excluding

cost of formwork and reinforcement for reinforced

concrete work in (A) Foundations, footings, Base or

columns and Mass concrete

4 75.00 Prismatic grade reflective sheeting with super high

perfomance durable micro prisnatic material confirming

to type XI as per ASTM-D 4956-09 & cutting pesting 3214.29 smt

letter according to IRC standard in singal language with

micro prismatic confirming to type XI.App.rate

5 65.00 Providing And Fixing 75 mm MS pipe 5 mt long with

nece.hold fast incl.nece excavation in asphlat

c.c.1:1.5:3 and three coat of oil paint erecting the same

as dire.(app.rate)

6 140.96 P/F 0.45 mt.wide 14 gauge MS Steel with outer perifery

angel 40 mm x 40 mm x 5 mm with MS flat 40 mm x

mm m c/c ereceting the same with pipe incl.providing

and erecting logo with two coat of oil paint etc.comp

incl.all labour charges as dire by engg.in

chargs.(app.rate)

Seal and Signature of the Bidder Addl. City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 4 of