Regarding of maintaining water lines and laying new water lines at Dudheshwar area, Old Shahpur, Mahendikuva area and other places under water pollution from M.P., M.L.A., Muni. Councilor, and Swarnim (70:20:10) Budget in Shahpur Ward. (A.R.C.)

Name of work: - btl ^thtmÇg©e, btl ftWLmejh©e (70:20:10) yk<do< Vt¤Juj csuxbtk&e bægÍtul Ntnvwh Jtuzobtk

œwDuµh rJM<th,swlt Ntnvwh <&t bnukœefwJt rJM<th <&t yLg søGttyu vtKele vtuÕgwNl yk<do< vtKele

jtRl buRxulLm fhJt <&t lJe vtKele jtRl ltkFJtlt ftb ctc<.(yu.yth.me.)

Tender Invited on Behalf of AMC, Central Zone.

Assistant Manager, Central Zone,

Central Zone Zonal Office”, B – Wing,

Third Floor,Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

Signature of Bidder Page 1 of

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

Notice inviting Tender

Competent authority on behalf of Municipal Commissioner of A.M.C. invites percentage rate sealed

tenders from interested contractors for the following work at different locations within the limit of

1 Name of work btl ^thtmÇg©e, btl ftWLmejh©e (70:20:10) yk<do< Vt¤Juj csuxbtk&e

bægÍtul Ntnvwh Jtuzobtk œwDuµh rJM<th,swlt Ntnvwh <&t bnukœefwJt rJM<th <&t

yLg søGttyu vtKele vtuÕgwNl yk<do< vtKele jtRl buRxulLm fhJt <&t lJe

vtKele jtRl ltkFJtlt ftb ctc<.(yu.yth.me.)

2 Estimated Tender Amount Rs. 1,49,00,000.00 (EXCLUDING OF GST) GST WILL BE PAID

EXTRA BY AMC/AUTHORITY AT PREVALLING RATE TO

3 Tender fee Rs.

(Non refundable) (Demand Draft in favour of Municipal Commissioner, Ahmedabad)

4 Time Limit 18 Months

5 Download of Tender Tenders from the website www.nprocure.com or shall be down

Documents loaded mentioned AS PER TENDER NOTICE INVITED

6 Required registration Register “C” class having in Road Works in PWD in Govt. R&B / CPWD /

AMC or equivalent register with any other state Govt. or institutions.

7 Earnest Money Deposit Rs.1,49,000.00 (Demand Draft / pay order / Bank Guarantee in favour

(Bid security) of Municipal Commissioner, Ahmedabad is to be submitted as

(1 % of Estimate put to prescribed as below. Demand Draft/Bank Guarantee shall be from

approved list of AMC of banks and the issuing branch of bank

guarantee shall be of Ahmedabad city only and it should be valid for

for 180 days. ( As

Per AMC finance Dept . Circular No. 5 Dt. 5/5/2007 & F.D.

Circular No. 29 Dt. 7/8/2010 & attched ANNEXURE - 1 finance

dept.circular No-40 Dt.05/11/2020. E.M.D. shall be submitted

physically along with the Physical Submission when applicable.

8 Submission of EMD and Tender Fee & EMD should Submitted physically along with tender

Tender Fees documents as described in the invitation of tender should be

submitted to Assistant Manager- Central Zone, 3rd Floor, B – Wing,

Sardar Patel Bhavan, Danapith, Ahmedabad-380001.

Bid submitted without bid security & tender fee shall be treated as

non responsive and shall be summarily rejected.

9 Mode of sending the The whole tender shall be submitted by two modes.

Tender Documents • Whole tender shall be submitted only on www.nprocure.com

website as per Schedule mentioned in Notice inviting

• Tender Fee, EMD, technical bid and other relevant PQ Documents

as per check list given in tender shall be submitted physically in

two copies (Original & duplicate) in sealed envelope as per

Schedule mentioned in Notice inviting Tender.

10 Last date of receiving As per Notice inviting Tender / Addendum / Corrigendum.

Tenders. The tenders received after latest schedule date and time will not

be entertained under any circumstances.

11 Submission of Price Bid The Price bid shall be submitted online only. The bidder shall fill

Signature of Bidder Page 1 of

Ahmedabad Municipal Corporation

percentage rate on amount of BOQ online only until specified.

Price Bid shall be submitted physically duly signed & seal without

mentioning quoted rated, else it shall be considered as rejected.

12 Opening of Technical bid As per Notice inviting Tender / Addendum / Corrigendum.

13 Tender validity period 120 days from the last date of submission of Tender.

14 Security Deposit 5 % of Contract Value to be submitted in the form of (Demand Draft /

pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad. Bank Guarantee shall be from approved list of AMC of

banks as per attched ANNEXURE - 1 finance dept. latest circular.

and the issuing branch of bank guarantee shall be of Ahmedabad City

only. The validity of the Security Deposit shall be up to valid till

days beyond Date of completion of work.

The Security Deposit shall be payable in 10 days (for tenders upto

Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above) from

date of receipt of LOI failing which interest @ 4% per annum will be

charged by AMC.

15 Deductions from Running

a. Retention Money 2 % amount of each Running Bill shall be deducted as a Retention

Money. Such retention money shall be released in the final bill of the

b. Labour welfare cess Labour welfare cess as per the Act, 1996 (non refundable) shall be

deducted from each running bill.

16 Defect & Liability Period Not applicable in this case. If applicable than refer condition of

contract attached over rule as per form B-1 published by Government.

17 Compansation for Delay 10 % of the actual balance work after Time limit expired.

• All the circulars which were published by Authorities of AMC time by time will be applicable on said

Tender and bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the rights to

reject any or all the tenders without assigning any reasons thereof.

• The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In case

authorized signatory holding Power of Attorney and Digital Signatory are not the same, the bid shall

be considered non-responsive.

Seal and Signature of the Bidder Add.City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 2 of

Ahmedabad Municipal Corporation

(On contractor’s Letter Head / certified with Stamp and Sign with Contact Detail)

TENDER DECLARATION FORM

Deputy City Engineer

Ahmedabad Municipal Corporation,

Name of Work:- btl ^thtmÇg©e, btl ftWLmejh©e (70:20:10) yk<do< Vt¤Juj csuxbtk&e bægÍtul Ntnvwh Jtuzobtk œwDuµh

rJM<th,swlt Ntnvwh <&t bnukœefwJt rJM<th <&t yLg søGttyu vtKele vtuÕgwNl yk<do< vtKele jtRl

buRxulLm fhJt <&t lJe vtKele jtRl ltkFJtlt ftb ctc<.(yu.yth.me.)

I/We the undersigned have carefully gone through and clearly understood the Tender documents of

above mentioned project comprising of Notice Inviting tenders, Articles of Agreement, Scope of work,

Definition of terms, notes Instructions/Information to Bidder, Condition of Contract, special condition of

contract, Appendices, Specifications, Bill of Quantities, furnished by AHMEDABAD MUNICIPAL

I/We do hereby offer to execute and complete the whole of the work within the time specified all in

accordance with the specification, designs, drawing and instruction in writing referred to in the said

document and with such materials as mentioned for, at the respective rates which I/we have quoted in the

Price Bid or at such other rates as may be fixed under the provisions of these conditions.

In the event of this tender being accepted I/We agree to enter into an agreement and when

required, execute the contract, according to your form 1 of agreement as or in default where of I/we bound

myself/ourselves to forfeit the "Earnest Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided by AMC

from the date of receipt of letter of acceptance, you will forfeit the earnest money paid by me/us and take

necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for the sum

as mentioned in NIT, the full value of which is to be absolutely forfeited to the Employer If I/We fail to

commence the work specified. Otherwise the Employer shall retain the said sum, as on account of such

Security Deposit as provided for in the aforesaid documents.

I/We agree not to employ sub-contractors other than those that may be approved in accordance

with conditions in the aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any tender,

which are received. I / We also understand & agree that Municipal Commissioner Reserves the right to allot

number of tenders to successful bidders at his sole discretion in case if I / We am/are lowest in more than

I/We am/are bound to execute the job if the work order is issued within 120 days from the date of

opening of the tender.

I am bound to execute the work by maintaining all Quality aspects/parameters mentioned in the

tender terms and conditions. I am also bound to submit all supporting Genuine Original documents as and

when asked and if any discrepancy found in such documents as well as in the executed Work with respect to

Quality/Quantity at any stage of work or even after completion of work, it will be solely my Responsibility. I

am bound to prove originality of all documents submitted by me and if any Documents found false/fake

then Municipal Commissioner/AMC has right to take any action/penalty/punishment against me.

Signature of Bidder Page 3 of

Ahmedabad Municipal Corporation

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality and/or

the construction of road is found to be of an inferior quality under this contract than in such case Municipal

Commissioner/AMC has right to debar/ blacklist permanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi duties,

Royalty on material (i.e. Aggregate, Sand etc.) And any other taxes prevailing and from time to time on such

items on which the same are leviable and the rates quoted by me/us are inclusive of the same.

Yours faithfully

Seal and Sign of Contractor

Signature of Bidder Page 4 of

Ahmedabad Municipal Corporation

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal Corporation

(referred to as Employer in these documents) invites sealed bids for the construction of works (as

defined in these documents and referred to as “the work”) detailed in the table given in the

Invitation for Bid (hereinafter called as IFB.) from competent bidder. The bidders may submit bids

for the works detailed in the table given in IFB.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined in this

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-14. An

agency that has been engaged by the Employer to provide consulting services for the preparation or

supervision of the works, and any of its affiliates, shall not be eligible to bid.

3.3 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those are

blacklisted/ debarred for specified period by AMC, Governement of Gujarat, Government of India or

any other entity controlled by it, would not be eligible to submit the Bid.

4.0 Qualification of the Bidder

4.1 Requires registration:- Register as per Notice Inviting Tender having in Road Works in PWD in Govt.

R&B / CPWD / AMC or equivalent register with any other state Govt. or institutions.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to be

disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and attachments

submitted in proof of the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the

contract, inordinate delays in completion, litigation history, or financial failures etc. or debarring

from AMC work etc.

• Tampered the bid document in any manner.

• Colluded with other prospective bidders for this work to arrive at quoted prices for the purpose

of restricting competition.

• Indulged in inducement of any official of AMC and/or their consulting engineer and other

advisors in any manner whatsoever.

• Proposal not submitted in accordance with this tender.

• During validity of the proposal, or its extended period, if any, the bidder changes his commercial

• The bidder qualifies the proposal with his own conditions.

• Proposal is received after due date and time.

• Commercial proposal is enclosed with the same envelope as technical proposal

• The envelope does not show on the outside the reference of bid and thus gets opened

before the due date of opening.

• The E.M.D. is not deposited in full and in the manner as specified in the clause of Earnest

Signature of Bidder Page 5 of

Ahmedabad Municipal Corporation

• The tender is in a language other than English or dose not contains its English Translation in

case of other language adopted for tender preparation.

• The tender documents received are not duly signed by authorized person.

• The validity of tender is less than what is stated in the tender.

• Any of the page or pages of tender is/are removed or replaced.

• Any condition which affect the cost.

• If it is joint venture.

5.1 Debarment / Black listing

Notwithstanding the above, the Employer may debar or blacklist any of the bidder(s) for their

misleading or false representations in the forms statements etc. for the period to be decided

by the Employer.

6.0 Cost of Bidding

The bidder shall bear all costs associated with the preparation and submission of his Bid. Employer

will in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and familiarize

himself with the site of Works and its surroundings including source of earth, water, road

aggregates etc. and obtain all information that may be necessary for preparing the Bid and entering

into a contract for construction of the Works. The costs of visiting the Site shall be at the Bidder's

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby total

amount of work increases / decreases up to any extent.

• If the works gets delayed / postponed for some administrative / technical decision whatsoever.

• If the items stipulated in the tender shall not be executed as per site condition/ requirements. No

claim shall be entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and no claim

shall be entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any) issued.

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

8. Bill of Quantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract data,

forms, terms, technical specifications, forms, Annexes in the bid document. Failure to comply with

the requirements of bid documents shall be at the bidder’s own risk. Bids which are not

substantially responsive to the requirements of the bid documents shall be rejected.

10.0 Amendment of Bidding Documents

10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by

issuing addendum.

Signature of Bidder Page 6 of

Ahmedabad Municipal Corporation

10.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on website

www.nprocure.com The prospective bidder shall refer to website to check any addendum before

hours of opening of bids. AMC will not give any advertisement for the same.

10.3 To give prospective bidders reasonable time in which to take an addendum into account in

preparing their bids, the Employer may, at his desecration, extend as necessary the deadline for

submission of bids.

10.4 Prospective bidders should attach the addendum made for the work & if fails to do so than also the

changes made through such addendum shall be applicable & bound to the bidder.

C PREPARATION OF BIDS

11.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

12.0 Documents comprising bid

The e bid submitted by the bidder shall be in two separate parts.

• Technical Bid

• Financial Bid

To qualify for award of the contract, each bidder must submit the following documents along with

• Required Registration Certificate

• Other requested documents

• Any other material / information required to be submitted in accordance with these

Instructions to Bidders (ITB)

Failure to submit these certificates/documents shall make the bid non-responsive.

Above original documents in physical form in two copies, one marked as “original” and other

marked as “Duplicate”, shall be submitted in a sealed envelope by 18:00 Hrs on the date of physical

submission of bid and addressed to the addressee given in the NIT duly super scribed “Name of

Work, Bid due date and time, Name and address of the bidder”

13.0 Bid Prices

• The contract shall be for the whole works as described in Bill of Quantity based on the percentage

rate in the Bill of Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any other

cause shall be included in the rates, prices and total Bid Price submitted by the Bidder, except

otherwise stated in the Bid document. Employer will not compensate the bidder (contractor) for

any change in duties, taxes and other levies payable by the contractor under the contract and any

• The percentage rate and bid price quoted by the bidder shall be fixed up to the completion of Work

and shall not be subject to adjustment on any account, except where expressly specified, otherwise,

in the contract.

14.0 Currencies of Bid and Payment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in Indian

15.0 Bid Validity

Signature of Bidder Page 7 of

Ahmedabad Municipal Corporation

15.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a shorter

period shall be rejected by the Employer as non-responsive.

15.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may

request that the bidders may extend the period of validity for a specified Deputy period. The

request and the bidders' responses shall be made in writing or by cable. A bidder may refuse the

request without forfeiting his bid security. A bidder agreeing to the request will not be required or

permitted to modify his bid, but will be required to extend the validity of his bid security for a period

of the extension.

16.0 Earnest Money / Bid Security

16.1 The Bidder shall furnish, a Bid Security of the amount as shown in the Table of IFB as part of his bid,

in the form of Demand Draft / pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad valid for 120 days.

16.2 The issuing branch of the bank guarantee shall be of Ahmedabad City only.

16.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as non-

Signature of Bidder Page 8 of

Ahmedabad Municipal Corporation

16.4 Any bid having bid security for lesser value and shorter validity period shall be treated as non-

16.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be returned as

promptly as possible.

(b) The bid security of the successful bidder, along with second and third lowest tenders, will be

returned when the successful bidder has furnished the required security deposit and signed

16.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the

Agreement and furnished the required security deposit.

16.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) sign the Agreement; or

(ii) Furnish the required security deposit.

(iii) commence the work after signing the agreement within 15 days

16.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank

guarantee shall be of Ahmedabad City only.

16.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp papers of

requisite value in accordance with the stamp Act applicable to that particular state of Indian Union,

where executed.

16.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly indicate in

(block letters) his name, designation, Power of Attorney No. / Signing Power No. etc.

16.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by the

executing officers and the last page shall be signed in full, indicating the particulars as aforesaid

under the seal of the Bank.

D. SUBMISSION OF BIDS

17.0 Sealing and Marking of Bids

17.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes and the

three sealed envelopes shall be sealed in an outer envelope. The Bid envelopes shall be marked as

• Complete Tender Document with all necessary qualification related documents (in two copy)

Above two envelopes shall be kept in one envelope and it should be marked as “Technical Bid” and

sealed. This Outer envelope should mention the name of firm of bidder, his address, contact details

& name of the work.

17.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

c) Bear the following identification:

Indicate the name and address of the bidder.

Signature of Bidder Page 9 of

Ahmedabad Municipal Corporation

• If the outer envelope is not sealed and marked as above, the Employer will assume no responsibility

for the misplacement or premature opening of the bid.

18.0 DEADLINE FOR SUBMISSION OF THE BID

18.1 Complete Bids (including Technical bid and necessary documents) must be received by the Employer

at the address specified in bid information not later than the date indicated on the face sheet of the

document. In the event of the specified date for the submission of bids declared a holiday for the

Employer, the Bids will be received up to the appointed time on the next working day. The Bidder is

further required to submit Documents in Physical Form on or before the Bid Due Date and before

the time of submission as specified in NIT, at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

18.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-

tendering portal on account of delay in submission at bidder's end. Bidder shall ensure that they

submit the bid well before the "Due Date & Time of Bid- Submission". AMC shall not be responsible

if bidder is not able to submit the bid on account of failure in network/internet connection or any

other technical reason.

18.3 The Employer may extend the deadline for submission of bids by issuing an amendment in

accordance with respective Clause, in which case all rights and obligations of the Employer and the

bidders previously subject to the original deadline will then be subject to the new deadline.

18.4 All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

18.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and returned

unopened to the bidder.

Any Bid received by the Employer after the deadline prescribed in NIT will be returned unopened to

20.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to

expiration of the Bid validity period by writing, facsimile or e-mail confirmed by registered letter.

This letter (hereinafter and in the Conditions of Contract called the “Letter of Acceptance” will state

the sum that the Employer will pay the Contractor in consideration of the execution, completion,

and maintenance of the Works by the Contractor as prescribed by the Contract (hereinafter and in

the Contract called the “Contract Price”).

The notification of award will constitute the formation of the Contract, subject only to the furnishing

of a Security Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the Successful

Bidder. It will be signed by the Employer and the Successful Bidder.

21.0 SIGNING OF CONTRACT AGREEMENT

21.1 The Employer and the successful bidder shall enter into a Contract Agreement within 28 days after

the successful bidder (hereinafter called the Contractor) receives the Letter of Acceptance, unless

they agree otherwise, subject to furnishing the security deposit before signing the Agreement with

21.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify the

other Bidders that their Bids have been unsuccessful and release their Earnest Money Deposit / Bid

22.0 SECURITY DEPOSIT

Signature of Bidder Page 10 of

Ahmedabad Municipal Corporation

22.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the

Employer a security deposit in the form of Bank Guarantee for an amount equivalent to 5% of the

Contract Price valid for the period of valid till 90 days beyond Date of completion of work. The

Security Deposit shall be payable in 10 days (for tenders upto Rs.10.0 Lacs) or 15 days (for tenders of

Rs.10.0 Lacs and above)from date of receipt of LOA failing which interest @ 4% per annum will be

charged by AMC.

22.2 The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from

Ahmedabad branch of any Banks mentioned in the clause no. 16.2 of these tender documents.

22.3 This security deposit shall be released only after the clearance of final bill including pre & post Audit.

22.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of security

deposit or late renewal of bank guarantee for the number of days delayed for submission or

discontinuity of the bank guarantee.

22.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same verbatim as

per the format. Bank Guarantee shall be submitted on right value of stamp paper and for correct

value of contract.

22.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall constitute

sufficient grounds for cancellation of the award and forfeiture of the Bid Security.

22.6 In case of any contract amendment during execution of the contract enhancing value of the contract

the BG value shall be enhanced accordingly. Validity of BG shall be commercial terms and conditions

22.7 All compensation or other sums of money payable by the Contractor to the Employer under the

terms of this Contract or any other contract or on any other account whatsoever may be deducted

from Security Deposit. Also in the event of the Contractor's Security Deposit being reduced by

reasons of such deductions, as aforesaid, the Contractor shall, within 14 days of receipt of notice of

demand from the Engineer-in-Charge, make good the deficit in Security Deposit.

22.8 Should there arise any occasion under the Contract due to which the periods of validities of Bank

Guarantees as may have been furnished by the Contractor from time to time, are required to be

extended/renewed, the Contractor shall get the validity periods of such guarantees

extended/renewed, and furnish these to the Engineer-in- Charge one month before the expiry date

of the aforesaid Guarantees originally furnished failing which the existing Bank Guarantees shall be

invoked by the Engineer – in – charge. Also in case of any deficit in securities on any account as

might occur or is noticed, the Contractor shall forthwith recoup/replace the same with acceptable

Security Deposit.

22.9 The Bank Guarantee shall be extended within the expiry dates wherever activities as per contract

are not completed in all respects.

22.10 The Security Deposit less any amount due shall, on demand, be returned to the contractor after

days of completion date / Final Bill paid date which ever is later. No interest on the amount of

Security Deposit shall be paid to the Contractor at the time of release of Security Deposit as stated

22.11 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at Employer’s

office within 15 days of LOA.

23.0 Advance Payment and Security

The Employer will not provide any advance payment.

24.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final and

binding to the bidder.

Signature of Bidder Page 11 of

Ahmedabad Municipal Corporation

25.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting from

Contractors completed or under execution by him over last five years. If the details of Litigation

History are hidden by the Bidder and later on it comes to the knowledge of the Employer, the Bidder

shall be disqualified for the proposed work and other appropriate actions shall be taken against the

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Value of the Reasons/Details for Remarks showing

Year Name of Project (Rs.) litigation/arbitration Present Status

 The bidder shall furnish separate table for individual project.

 The above information shall be supported with necessary documents otherwise the same shall be

treat as null and void.

 A consistent history of arbitration awards? Judgments against the applicants or any partner of a

joint venture may result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to knowledge of

the employer the bidder shall be disqualified for the proposed work and other appropriate actions

shall be taken against the bidder.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 12 of

Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Liquidated Damages

1.1 If the Contractor fails to complete the works within the original or extended time limit, the

Contractor shall pay penalty of 10% of amount of actual remaining work. The amount of work for

which the scope of contractor is reduced shall not be considered for the calculation of Liquidated

1.2 Conditions mentioned in the AMC Finance Department Circular AMC no. 18 Date: 23/05/2017 and

all latest Circulars shall be applicable.

2.0 Retention Money

2 % amount of each Running Bill shall be deducted as a Retention Money. Such retention money

shall be released in the final bill of the said work. AMC reserves right to deduct any amount to

compensate the poor performance of the contractor i.e. poor quality or abandoned / incomplete

3.0 Subcontracting

3.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any portion of

Work without the approval of the Employer’s Representative. Any subcontracting shall not relieve

the Contractor from any contractual obligations or responsibility under the Contract.

3.2 The Contractor shall not be required to obtain consent for a subcontract for which the name of the

subcontractor and scope of works activities to be performed by him is already stated in the contract

or supply of material or engagement of labour.

4.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred to

in the Bid document to carry out the functions stated in the Schedule or other personnel approved

by the Engineer. The Engineer will approve any proposed replacement of key personnel only if their

qualifications, abilities, and relevant experience are substantially equal to or better than those of

the personnel listed in the Schedule.

4.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof, for his

misconduct or inadequacy of technical skills and experience, who is a member of the Contractor’s

staff or his work force, the Contractor shall ensure that the person leaves the Site within seven days

and has no further connection with the work in the Contract.

4.3 No residential accommodation is allowed at the site of work. The labour huts shall not be erected on

the site of work and contractor shall make his own arrangements to provide such accommodations

as per the rules of the local bodies. He shall make his own arrangements for housing, stores, field

office etc. He shall submit a site layout plan indicating the location of various site facilities to be

created by him at his cost for the execution of work. The Owner shall in no way be responsible for

any delay on this account and no claim on this account whatsoever shall be entertained. All Basic

amenities shall be provided by the Contractor to Labours as per the prevailing labour Laws.

5.1 The Contractor shall have full regard throughout execution, completion and defects liability period

to following safety aspects and shall take all necessary steps to ensure that danger to safety is

avoided all the time in respect of,

Safety of the works

• Safety of the Contractor’s employees and all the persons directly or indirectly engaged by

him for the works

Signature of Bidder Page 13 of

Ahmedabad Municipal Corporation

• Safety of all the employees including persons working on other contracts of Employer at the

same site of the Employer and Engineers employees engaged at work site.

• Any authorized third party persons on the site.

• Contractor’s plant and equipment

5.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs,

barricading, and cones; when and where necessary, or required by Engineer in Charge or by any

duly constituted authority for the protection of the works or for the safety and convenience of the

public or other.

5.3 The Contractor shall take all reasonable steps to protect the environment on and off the site and

avoid damage or nuisance to persons or property of the public and others arising as a consequence

of his method of operation.

5.4 The Contractor shall maintain in good condition all work throughout execution, completion, and

defects liability period. The contractor shall be responsible for and to make good all injuries,

damages and repairs, rendered necessary by fire, rain, traffic, floods or other causes.

5.5 All the scaffolding work, wherever required for the execution of work, shall be provided by the

contractor. Nothing extra shall be payable on this account. It shall be provided strictly with double

scaffolding system with all the accessories etc. with adjustable suitable working platforms to access

the areas, with ease for working and inspection. It shall be designed to take all incidental loads. It

should cater to the safety features for workmen. It shall be ensured that no damage is caused to any

structure due to scaffolding.

5.6 All temporary warning/ caution boards display shall be provided and displayed during day as well as

night time by the contractor, wherever required and as directed by the Engineer.

5.7 Arrangement of temporary water and electricity and telephone connection required, by him, shall

be made by the Contractor at his own cost and also necessary permissions directly from relevant

Owners shall be obtained by him under intimation to the Owner. Also all initial and running charges

and security deposit, if any in this regard shall be borne by him. The Contractor shall abide by all the

rules/ bye laws applicable in this regard and he shall be solely responsible for any penalty on

account of violation of any of the rules and byelaws in this regard.

5.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the same

shall be completely contractor’s responsibility. All the losses due to such accidents and expenses of

legal matters shall be borne by contractor.

5.9 The Contractor shall be responsible for maintenance and watch and ward of the complete

installation and shall also be responsible for any pilferage, theft, damage, penalty etc. in this regard.

The Contractor shall indemnify the Owner against any claim arising out of pilferage / theft, damage,

penalty etc. whatsoever on this account.

5.10 The Contractor shall depute Site Engineer & skilled workers as required for the work. Necessary

protective and safety equipments shall be provided to them by the Contractor at his own cost and

6.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage rubbish,

excess materials, temporary works no longer required will be removed from site immediately.

7.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials, rubbish,

temporary works of every kind.

A. COST CONTROL

8.0 Bill of Quantities

Signature of Bidder Page 14 of

Ahmedabad Municipal Corporation

a. The schedule-B shall contain Memorandum showing items for the construction, installation,

testing, and commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be paid

only quantities calculated after taking measurements of executed work. The rate stated in the

schedule B for each item of work shall apply. The works shall be measured by the Contractor

jointly with the authorized representative of the Engineer and all particulars required by the

representative of the Engineer shall be supplied by the contractor.

c. The work shall be measured net. No allowance for general or local custom, working space etc. is

9.1 The Engineer in Charge shall have power to make any variation of form, quality or quantity of the

works or any part thereof that may, in his opinion, be necessary and for that purpose, or if for any

other reason it shall, in his opinion, be appropriate, he shall have the authority to instruct the

Contractor to do and the Contractor shall do any of the following:

 Increase or decrease the quantity of any work up to any extent included in the contract,

 Omit any such work,

 Change the character or quality or kind of any such work,

 Execute Deputy work of any kind necessary for the completion of the Works or

 Change any specified sequence or timing of construction of any part of work.

9.2 No such variation shall in any way vitiate or invalidate the contract, but the effects, if any, of all such

variations shall be valued in accordance with the following sub clauses. Provided that where the

issue of an instruction to vary the Works is necessitated by some default or breach of contract by

contractor or for which he is responsible, any Deputy cost attributable to such default shall be borne

by the Contractor.

9.3 The Contractor shall not make any such variation without an instruction of the Engineer. No

instruction is required for quantities varying from those provided for the items in the contract

10.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows in the

same order of priority.

a) Variations in the quantities of work in schedule of quantities shall not vitiate the contract.

b) The contractor shall be bound to execute extra items of work as directed by the Engineer-in-

c) Contract unit rates for individual items shall apply to varied quantities where there is a quantity

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

10.2 If any extra item crops up during the progress of work the same shall be carried out by the

Contractor and he shall be paid at the rate fixed by Employer which shall be fixed as lowest of the

rates derived by rate analysis based on the following three methods. , the priority of the documents

forming the Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2013-14, the

rate of extra item shall be that rate and premium (above or below) quoted by contractor.

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and equipment,

the cost of all temporary and incidental works, the overheads and the Contractors profit.

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs, the cost

of use of all plant, machinery, and equipment, the cost of all temporary and incidental

Signature of Bidder Page 15 of

Ahmedabad Municipal Corporation

10.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall be taken

at 10 % of the final rate derived.

10.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in his

opinion appropriate and shall notify the Contractor accordingly with a copy to the Employer.

10.5 The Engineer shall determine provisional rates and prices to enable on account payments to be

included in the Interim Payment Certificates, until rates and prices are agreed as final by the

Employer, the Contractor, and the Engineer.

10.6 The Contractor shall not be entitled to Deputy payment for costs, which could have been avoided by

giving early warning.

11.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in

terms of the contract and taxes at source, as applicable under the law. The Employer shall pay the

Contractor the amounts certified by the Engineer.

11.2 If an amount certified is increased in a later date certificate due to corrections in previous

certificates or as a result of an award from disputes review experts, Contractor shall be paid such

amount only. The Contractor shall not be paid any interest upon such delayed payment.

11.3 Items of the work for which no rate or price has been entered in will not be paid for by the

Employer and shall be deemed covered by other rates and prices in the Contract.

11.4 All payments shall be made in Ahmedabad.

12 Taxes and duties

12.1 The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local Governing

bodies prevailing on the date of award of the contract. The Contractor will have to pay all such taxes

and duties for the performance of this Contract. The Employer will deduct from the Contractor’s

monthly and other payments all taxes and duties, which he is bound to recover in accordance with

the applicable law.

12.2 The Contractor shall keep himself fully informed of all acts and laws of the Central & State and local

Governing bodies, all orders, decrees of bodies, tribunals having any jurisdiction or authority which

in any manner affect those engaged or employed, and anything related to carrying out the work. All

the bye-laws lay down by AMC/AUDA and any other local bodies while executing the work shall be

adhered to. All taxes of local bodies shall be borne by the contractor. The Contractor shall arrange

to give all notices required by any authority and to pay to such authority all the fees that may have

to be paid for the material, plants, equipments etc. The Contractor shall also adhere to all traffic

restrictions notified by the local authorities. He shall protect and indemnify the Owner and its

officials & employees against any claim or liability arising out of violations of any such laws,

ordinances, orders, decree, whether by himself or by his employees or his authorized

representatives. Nothing extra shall be payable on these accounts.

13.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-1831-

M(3) dt. 9/12/05 issued by G.O.G. (non-refundable) shall be deducted from every bills which shall be

deposited to Govt. Labour Department for Labour welfare fund.

14.0 Currencies

All payments shall be made in Indian Rupees.

Signature of Bidder Page 16 of

Ahmedabad Municipal Corporation

15.0 Advance Payment

No Advance Payment shall be made.

16.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date

and the end of the Defects Correction periods shall be remedied by the Contractor at the

Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.

B. FINISHING THE CONTRACT

17.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the

Engineer will do so upon deciding that the Work is completed.

18.0 Termination

18.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after receipt

by him of a Notice to this effect from the Engineer/Employer after signing the agreement or

2. To proceed with the works, or any section thereof, within 28 days after received notice

3. Has failed to comply with a notice issued or an instruction issued within 28 days after

having received.

4. Abandons the works or otherwise plainly demonstrates the intention not to continue

performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written

permission of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the contract.

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration

order made against him, compounds with his creditors, or carries on business under receive,

trustee or manager for the benefit of his creditors, or if any act is done or event occurs

which (under applicable Laws) has a similar effect to any of these acts of event.

18.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to the

contractor, terminate the contract and expel the contractor from the site. However, in the case of

sub-paragraphs (h), the Employer may be notice terminate the contract immediately.

18.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the

Employer, under the contract or otherwise.

18.4 After termination, the Employer may complete the works and/or arrange for any other entities to

do so. The Employer and these entities may then use any goods, contractor’s documents and other

design documents made by or on behalf of the contractor.

18.5 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental

breach of the Contract.

18.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the current

Program and the stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a

reconstruction or amalgamation;

(c) The contractor fails to fulfill requirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach of

Contract and the Contractor fails to correct it within a reasonable period of time determined by

(e) the Contractor does not maintain a security which is required;

Signature of Bidder Page 17 of

Ahmedabad Municipal Corporation

(f) the Contractor has delayed the completion of works by the number of days for which the

maximum amount of liquidated damages becomes payable as defined in the Contract data;

(g) if the Contractor, in the judgment of the Employer has engaged in corrupt or fraudulent

practices in competing for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving, receiving or

soliciting of anything of value to influence the action of a public official in the procurement

process or in contract execution. “Fraudulent practice” means a misrepresentation of facts in

order to influence a procurement process or the execution of a contract to the detriment of the

Borrower, and includes collusive practice among Bidders (prior to or after bid submission)

designed to establish bid prices at artificial non-competitive levels and to deprive the Borrower

of the benefits of free and open competition.”

18.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a cause

other than those listed above, the Engineer shall decide whether the breach is fundamental or not.

18.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

18.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and

secure and leave the Site as soon as reasonably possible and handover the site to the Employer

including all materials and plant and equipment existing there upon.

19.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the same.

He shall also be responsible for the correctness of the positions, levels, dimensions, and alignment of

all parts of the structures as per instructions given to him. If at any time any error shall appear during

the progress of any part of the work, the contractor shall at his own expense rectify such error if

called upon to the satisfaction of the Engineer in charge.

20.0 Overpayment & Underpayment

20.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or under

this Contract against the contractor the same may be deducted by the Municipal Corporation from

any sum then due or which at any time thereafter may become due to the contractor under this

contract and failing that under any other contract with the Municipal Corporation or from any sum

due to the contractor with the Municipal Corporation (which may be available with Municipal

Corporation), or from his retention money, or he shall pay the claim on demand. The Municipal

Corporation reserves the right to carry out post payment audit and technical examination of the final

bill including all supporting vouchers, abstracts, etc.

20.2 The Municipal Corporation further reserves the right to enforce recovery of any over payment when

detected notwithstanding the fact that the amount of the final bill may be included by the

20.3 If as a result of such audit and technical examination any over payment is discovered in respect of

any work done by the Contractor or alleged to have been done by him under the contract, it shall be

recovered by the Municipal Corporation from the contractor by way of all the means prescribed

above or if any under payment is discovered by the Municipal Corporation, any amount due to the

contractor under this contract or under payment may be adjusted against any amount then due or

which may at any time thereafter become due before payment is made to the contractor from him

to the Municipal Corporation on any other contract account whatsoever.

21.0 Materials obtain from dismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for reasons

other than on account of bad or imperfect work, the materials obtained from dismantling will be the

property of the A.M.C. and will be disposed of as per instruction of Engineer-in-charge in the best

interest of the A.M.C.

Signature of Bidder Page 18 of

Ahmedabad Municipal Corporation

22.0 Dispute to be referred to Arbitrator

The disputes relating to this contract, so far as they relate to any of the following matters, whether

such disputes arise during the progress of the work or after the completion or abandonment

thereof, shall be referred an independent Arbitrator appointed by AMC as far possible in

consultation with the agency if it is necessary and such disputes shall be settled in accordance with

the arbitration and conciliation Act.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon the

works of the site thereof or belonging to the contractor or procured by him and intended to

be used for execution of the work or any part thereof possession of which may have been

taken by the Engineer-in-charge under the said clause –5.

(ii) The reduction in rates made by the Engineer-in-charge under clause 9 from the items of

works not accepted as completed fully in accordance with the sanctioned specifications.

(iii) The rate of part of payment for any class of work which is included in the Deputy or altered

work carried out by the contractor in accordance with the instructions of the Engineer-in-

charge under clause 14 and the rates for which is to be determined under the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by the

contractor before receipt of notice given by the Engineer-in-charge under clause 15 and/or

amount of compensation payable to the contractor under the said clause for loss in respect

of such materials.

(v) The amount of compensation which the contractor shall be liable to pay under clause 17 in

the event of this failure to rectify, remove or reconstruct the work within the period

specified in the written intimation or the amount of expenses incurred by the Engineer-in-

charge under the said clause17 in rectifying, removing or re-executing the work or in

removing and replacing the materials or articles complained of.

(vi) The reduction of rates as may be fixed by the Engineer-in-charge under clause 17 for the

inferior work or materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates and

assessed under clause

(viii) The amount payable to the contractor for the work carried out under clause 33 in

accordance with the instructions and the requirement of the Engineer-in-charge in case

where there are no specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and

calculations to every item of claims. The decision will have to be implemented by all the

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation

approaching on Court of Law. It shall be within the jurisdiction where the site of work is

The reference to arbitration proceeding under this clause shall not:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause 5 to take

possession of all or any tools, plants, materials and stores in or upon the works of site thereof

belonging to the contractor or procured by him and intended to be used for the execution of the

work or any part thereof.

ii) Preclude the Engineer-in-charge from utilizing the materials purchased by the contractor in any

work or from removing such materials to other places, during the period the work is stopped or

suspended in pursuance, of notice given to the contractor under clause

iii) Progress of the work or the carrying out the Deputy or altered work in accordance with the

provisions of clause 14 or as the case may be, of clause

23.0 Drawings and Photographs of the Works

Signature of Bidder Page 19 of

Ahmedabad Municipal Corporation

23.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No

separate payment will be made to the contractor for this. . The contractor shall have to submit the

same in hard copy as well as soft copy as and when demanded by the AMC.

23.2 No photograph of the works or any part thereof or plant employed thereon, except those permitted

under clause 59.1, shall be taken, or permitted to be taken by the Contractor or by any of his

employees or any employees of his sub-Contractors without the prior approval of the Engineer in

writing. No photographs/ videography shall be published or otherwise circulated without the

approval of the Engineer in writing.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 20 of

Ahmedabad Municipal Corporation

yb>tJt> BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe >hJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt yb>tJt> BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg gt>elt

ftuLx[fxhtu Che NfNu. dJobuLxlt btLg ftuLx[tfxhu yb>tJt> BGþrl.ftuvtuohuNlbtk btLg ftuLx[tfxhtule

gt>ebtk hSMxuNl fhtJJtlwk hnuNu.

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u stuzJtle

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt mûtb

ntug <ublu s ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs xtRb jebexbtk

ÃþY fhJt sYhe mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt hnuNu.

z:- yb>tJt> Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t

mexe.Rsluh mh¾gwjh,lk -17,<t.09/12/2012 bwsc yb>tJt> Bgwrlrmvj ftuvtuohuNlbtk

ftuLx[t¾xh hSMxuNl Ve, heLgwyj Ve <&t yvd{uzuNl Ve ylu btv>kztu ægtlbtk htFe <u bwsc ybj

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe btdo,

mkath ylu JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu mtRx ylu

rcÕzekd(fu su ftb fhJt, ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj ntug).<ubs xuLzhhu yt

mtRxlt ftb btxu, rcÕzekd btxu, gtzo, zevtu btxule søgt vtu<tle he<u bu¤Je juJtle hnuNu. (xuLzhlwk

ftb fhJt, ftb vwhwk fhJt <&t ftblt buRxulLm btxule søgt)

(h) yt ftble mbg bgto>t bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle >hufu >huf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt >M<tJus vh<

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]<

fh<wk bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

Signature of Bidder Page 21 of

Ahmedabad Municipal Corporation

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u cezJtle

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt >huf vtlt ylu rJd<tu vh ftuLx[tfxhu mne fhJe.

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh >eM<tJustult jFtKbtk ftuR AufAtf fu VhuVth fhJt

>uuJtNu lrn ylu ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug <tu <ult

vh l Dwkx<t Ftuxt jFtK fu ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ Wfju <u he<u

jFJt. «ðguf mw^tht vh xwkfe mne fhJe.

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk >NtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug <tu

xuLzh ybtLg dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu

ftuLx[tfxhtult btdo>Nol btxu mtbtLg rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK >NtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk ytJNu.

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt vîr<

y&Jt rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu c>ÕGþ / c>Õgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk >huf Ctde>th y&Jt <u ykdulwk bwFðgthltbwk ^htJlth

Ôgrf< mne l fhu y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR

mtûteyu mtF fhe l ntug.

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, h> fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu rlKog

ytFhe hnuNu. ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh ftuRvK

«fthltu lwfNtle fu J¤<hltu nff>tJtuu fhe NfNu lrn fu ftg>tfeg ftgoJtne yt ykdu &R NfNu

lrn. xuLzh bkswh &gtltu y&o ftb ytve >uJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh MJefthJtbtk

(9) rJmkdr< ylu rnmtc stud:

nt& ^hJtlt ftbtule ctc< >NtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK Cwjawf

leault rlgbtu ylwmth mhCh fhJtbtk ytJNu.

Signature of Bidder Page 22 of

Ahmedabad Municipal Corporation

(1) xuLzh Chlthu >hlt Ftltbtk sKtJuj Nç>tu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nç>tuubtk

sKtJuj hfb btLg htFJtbtk ytJNu.

(2) yufb >h ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu >NtoJ<e CtJ vºtflt Ftltbtk&e

hfbbtk Cwj sKtg <tu yufb >h btLg htFJtbkt ytJNu ylu >hlt yt^thu dwKtfth mw^thJtbkt

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgto>t bwsc fhJtltu hnuNu. yt mbgbgot>t 10 jtF mw^elt ftb btxu

yuj.ytu.ytR. ytÃgt <theF&e 10 r>Jm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg

<theF&e 15 r>Jm&e NY &guj dKJtbt ytJNu. <&t <u >hBgtl ftble 5% juFu zevtuÍex Che fhthvºt

xuLzhbtk ftuLx[t¾xh îtht Chujt CtJ <btb «fthlt su <u «J<o<t mhfthe xuût mrn<lt

CtJ dKJtbtk ytJNu. ylu <ubtk atjw ftb >hBgtl su ftuR VuhVth &Nu <ultu J^thtu awfJJtbtk

c:- mûtb m•tt îtht Yt.10,00,000.00 (>m jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ct>

(LOI) ytvJtbtk ytJNu ðgth ct> r>l - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu.

rm¾gtuhexe zevtuÍex btuze ChJtlt rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth ftgoJtne

f:- bkswh &guj xuLzhle mbgbgto>tbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk

sKtJuj «btKu bkswh &guj mbgbgto>t ct>lt FhuFh ctfe ftble hfblt bn•tb 10% juFu

(jefJezexe zubuSm) vulÕxe Jmwj fhJtbtk ytJNu.

z:- yu.yth.me. xuLzhbtk bkswh &guj sw>t sw>t yk>ts vifelt ftbtu Jfo ytuzoh b¤u&e NY fhJtlt hnuNu.

E:- yu.yth.me. xuLzhbtk ftb «btKu yk>ts hfb Bþsc mbgbgto>t dKtNu.

(1) Yt.1,00,000.00 &e 3,00,000.00 Mþ^elt ftbtu btxu 1 btm

(2) Yt.3,00,000.00 &e 5,00,000.00 Mþ^elt ftbtu btxu 2 btm

(3) Yt.5,00,000.00 &e Wvhlt ftbtu btxu 3 btm

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt >h vwhtk &gujt ftb btxult Au ylu <ubtk

bswhe, vtjF, ÃjtLx, >uFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu

<btb Faoltu <&t sYh sKtg <tu ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu mbtJuN

&Nu ylu xtkfujt CtJ fu >h fh<t J^thtle ftuR awfJKe ykdult <ublt ftuR >tJt ægtlbtk juJtNu

lnek ylu xuLzh Chlth Ftuxe hswyt<lu fthKu y&Jt ftuR Ôgrf<yu (vAe<u ctk^ftb rJCtdltu

fboathe ntug fu l ntug) <ublu ytvuje btne<elu yt^thu vtA¤&e ftuR >tJt> hsw fhJt nf>th

Signature of Bidder Page 23 of

Ahmedabad Municipal Corporation

hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk sw>t sw>t CtJ ylu >h ChJt btxu sYhe yuJe <btb

btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u xuLzh hsw fhJtlu je^u y&Jt <ubtk&e WCt &<t

ftuR stuFb fu sJtc>thebtk&e Axfe NfNu lnek. m>h ftbbtk ftuR vK ò<lt ctk^ftblt

bxehegj Wvh CtJ J^thtu ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt ytJNu.

<&t Bgwrl. frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu ftbdehe/ybj fhJt

rcl Nh<e ckDlf<ot hnuNu.

f:- ftuLx[t¾xhlt >huf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk vubuLx

+ yu¾x[t ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh< ytvJtbtk

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftg>t bwsc su ftuR hfble fvt< fhJtle &Nu <u bwsc

ftuLx[tfxhlt cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu

ce:- xuLzhbtk >NtoJuj ftb mkck^e >M<tJusbtk >NtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau >NotJuj

¢btlwmth >M<tJusbtk >NtoJuj rJd< d{tng htFJtbkt ytJNu.fhth mkc^e >M<tJustu fhthlt

ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu f>:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk f>, ytfth, ytkfzt f>ta Ftuxt ntug <tu btvujt f>, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^ bwfe

yuze.mexe yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc fhJtbkt

ytJuj rlKog ykr<b dKJtbkt ytJNu.

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe ylu

Rsluh Rlatsuo Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl fhtJJwk.

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) yufe JF<u yuf fh<t J^w søgtytuyu ftb NY fhJtltu Jfo ytuzoh b¤u <tu ftb yuf mt&u s c^u NY

Signature of Bidder Page 24 of

Ahmedabad Municipal Corporation

(16) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu

lwfNtl &Nu <tu <ule mkvwKo sJtc>the (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb

>hBgtl bswhtu fu sl<tlt ftuR btKmlt òlbtj lu lwfNtl &tg <ule sJtc>the ftuLx[tfxhle

hnuNu. vtujem Vrhgt> &tg <tu <ule sJtc>the vK ftuLxtfxhle hnuNu. CuFz Dme l vzu <ule

sJtc>the vK vtujem Vrhgt>bt ftuLx[tfxhle hnuNu. CuFz Dme l vzu <u btxu mjtb<elt vdjt

(suJt fu >tuhzwk ctk^e bswh Ftztbtk W<thJt, mtuhekd ylu Mx[xekd fhJt rJduhu) je^t Jdh bsqhlu

Ftztbtk W<thNu <tu ftuLx[tfxh s vtujem Vrhgt>bt sJtc>th hnuNu ylu Bgwrl.ftuvtuohuNlltu

ftuRvK MxtV ytlt btxu sJtc>th hnuNu lrn. ytxjwk mbSlu s xuLzh ChJwk. bswhtultu rJbtu vK

(17) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu fhtJJtlt

hnuNu. bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.

(18) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu rlgb

ylwmth <u ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(19) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< r>l 1btk vh< jR sJtltu

hnuNu. yLg&t <ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(20) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc ve.yuV/juch

yufx <&t bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftg>tlw vtjl fhJtlwk hnuNu <&t yt ykdu

Bgwrl.ftuvtuohuNl îtht su btne<e btkdJtbtk ytJu <u ytvJtle hnuNu. bu.BGþrl.frbNlh©elt

mh¾âwjh Bþsc sYhe ctknu^he vºtf ytvJtLþk hnuNu.

(21) ftuRvK ftg>tfeg jexeduNl yb>tJt> Nnuhle ftuxobt hnuNu.

(22) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu

<ubs dtuXJJtltu hnuNu.

(23) ftuR vK mhfthe fhJuht ChJtle <btb sJtc>the ftuLx[tfxhle hnuNu.

(24) ftuLx[tfxh îtht xuLzhbt >NtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc

jtJJtlt hnuNu.<&t xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw

vtjl fhJtlw hnuNu.

(25) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l ntug

<uJe J^thtle ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb ylwmth

J^thtle ytRxblt CtJ lffe fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk ytJNu.

(26) atjw ftb >hBgtl «tuxufNlle mkvwKo sJtc>the ftuLx[tfxhle hnuNu. subtk vevzt, >tuhzt Cgmwaf

ctuzo, ÃjtMxef vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK yfMbt< &Nu <tu

<ule mkvwKo sJtc>the ftuLx[tfxhle hnuNu.

(27) M&¤ Wvh atjw ftbdehe >hBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg Ôgrf<lt

yfMbt<lt rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem ftgoJtnele sJtc>the

ftuLx[tfxhle hnuNu.

(28) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk >hhtus fhuj ftbdehe

<&t yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk ftuBÃjtgLm ytvJtlwk

Signature of Bidder Page 25 of

Ahmedabad Municipal Corporation

hnuNu ytJe ltu^lt sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu ftuLx[tfxhlu vulÕxe fhJtle

m•ttt yuze.mexe yuLSlehgh©elu hnuNu.

(29) >huf ytRxblt MvuNeVefuNl yb>tJt> Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg htFuj

MvuNeVefuNl Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk

yuze.mexe.yuLSlegh©eltu rlKog ytFhe hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu >hhtus J^thtltu

zucheÍ WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu sutFbu Jdh ltuxemu Jtuxhekd fhtJJtbtk

<&t zucheÍ WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(30) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve juJtbtk

(31) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg >hBgtl

ftuLx[tfxh îtht ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk

(32) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu

VhSgt< ytvJtlt hnuNu.

(33) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk

ftb btk ftuRvK mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj M¾{uJSkd

ykdule btdoœrNoft lwk vtjl fhJwk.

(34) mœh xuLzhle ytRxbtult CtJtu ltKt Ft<tlt mh¾gwjh lkk.38, <t.21/11/2022 <&t mûtb

m<tle b¤uj bkkswhe bwsc Syumxe rmJtg dK<hebtkk juJtbt ytJuj <&t «Jo<btl rlgb bwsc

Syumxe awfJJt vtºt &Nu. su ægtlu jR <btb rczomu xuLzhtu ChJtlt hunNu.

(35) mœh xuLzh ykk<od<olt ftb mkkjøl y.Bgw.ftuvtuo.btkk «Jo<btl <btb rlgbtu/mh¾gwjhtu jtdw vzNu,

<ubs JF<tu JF< &lth mw^thtytu vK jtdw vzNu. suule ltuk^ jR xuLzhtu ChJtlt hunNu.

(36) mœh xuLzh yu.yth.me. «fthlw Au ytvlu mtukvJtbtkk yuxju fu ytv îtht ChJtbtkk ytJuj

ftbdehelt sÚ&t bwsc mbg bgtoœt lffe fhe yjd&e bkswh &guj ykœtsJtRs Jfo ytuzoh

ytvJtbtkk ytJNu ylu mbg bgtoœtbtkk ftbdehe vqKo fhJtlw awM< vKu vtjl fhJtlw hunNu.

(37) mœhnw ftbbtkk Jtuzobtkk sYhegt< bwsc ytuAtbtkk ytuAe xuLzhle Nh< bwsc bkkswh &lth xuLzh vife

yjd yjd ykkœtsle bkkswhe bu¤JJtbtkk ytJ<e ntuR, ytuAtbtkk ytuAe yuf mt&u œN søgtyu

sYhegt< bwsc ftbdehe NY fhJtle Nh<u ylu <u «btKu bulvtJh, bNelhe, bxehegÕm <ubs

ltkkKtfeg studJtRle vwh<t «btKbtkk ÔgJM&t fhe su <u xuLzhhu xuLzh Cgto vqJuo ytdtu<Y

ytgtuslle <igthe mt&u ftbdehe fhJtle &tg Au.

Signature of Bidder Page 26 of

Ahmedabad Municipal Corporation

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le

bwjtft< je^e Au ylu ftblu jd<t btjmtbtl, bswhe ylu ceS ctc<tulu jd<e

M&trlf vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu

jd<t >M<tJustu ft¤SvwJof yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb<

ftuLx[tfxhle mne ylu rmfft

Signature of Bidder Page 27 of

Ahmedabad Municipal Corporation

TECHNICAL SPECIFICATIONS:

Following technical specifications shall be applicable to the relevant items of BOQ

btl ^thtmÇg©e, btl ftWLmejh©e (70:20:10) yk<do< Vt¤Juj csuxbtk&e bægÍtul Ntnvwh Jtuzobtk œwDuµh

rJM<th,swlt Ntnvwh <&t bnukœefwJt rJM<th <&t yLg søGttyu vtKele vtuÕgwNl yk<do< vtKele

jtRl buRxulLm fhJt <&t lJe vtKele jtRl ltkFJtlt ftb ctc<.(yu.yth.me.)

ItemNo.1:-Transporting from AMC store and laying spigot and socket New DI pipe

line DI-k-9 pipes of various classes with CI/DI/MS specials of

following diameters. Rate includes excavation up to minimum 1.0 mt.

depth from top of pipe / as per requirement in any soil, refilling

after laying pipe, covering and temptation of carting surplus

earth up to 30 mt. lead and watering and compaction.

Clearing the site. All Joints shall be made tight & leak free etc.

comp. (As per previous tender Rates).

Transporting from AMC store water pipe line including disconnectingspecials,

valves,andjointing materials.Cartingtherecovered pipelinesetc.to theMuni. Storeandincludes

stacking properlyasdirectedincludingnecessaryexcavationandrefillingtrenchesetc.complete

ThePaymentshallbemadeonRmt.basisforallthejointingworkmadeforthiswork.

ItemNo.2:-OnlyRemoving&recoverofexistingCI/DIpipeline&Specials,removinganytype of

joint,carting it to the Muni. Stores as &where directed as

perinstructionofEngg.Inchargewithexcavation&refilling.

(a) 80 mm to 100 mm dia (b)150 mm dia.

ItemNo.3:-Removing&relayingofexistingCI/DIpipeline&Specials,

Cleaningofpipe&SpecialsfromInside,includingexcavation,refillingetc.comp.i

nline&levelwithanytypeofjointsasperinstructionofengg.incharge.(a)100mmd

ia.(b)150mm dia. (c) 200 mm dia. (d) 250 mm dia. (e) 300 mm dia

Specificationsfor ItemNo.2&3areasunder

Labourchargesincludesclearingrecoveredpipesbymeans

oflongrigidpipeofsuitablelength.Pipeshouldbecleanedfrominside.Thecontractorshouldremo

veallclotsandrustedpartsfrominsidepipe surface.

This Specification covers the requirements for collecting from Municipal

Storesorcontractor’sstackyardtransportationofcasttoworksites,laying,jointingandfieldtesting

ofcastironpipesandfittingsforthewaterdistributionNetwork.

Castiron/DuctileironpipesandfittingsshallbetransportedfromtheMunicipalStoresorcontr

actor’sstackyardtotheworksitesatplacesalongthealignmentofpipeline asdirectedbyOwner/En

gineer.The Contractor shallbe responsibleforthesafetyofpipesand

fittingintransit,loading/unloading.Everycareshallbeexercisedin handlingpipesandfittingstoav

oiddamage.W hileunloading,thepipesandfittingsshallnot bethrowndownfromthetruckon the

hardsurfaces.Theyshallbeunloadedontimberskidswithsteadyingropesofbyanyother

means.Paddingshallbeprovidedbetweencoatedpipes,fittingsandskidstoavoiddamagetothec

oating.Suitablegapsbetween pipesshouldbeleftatintervalsinordertopermitaccess

fromonesidetotheother.Incaseofspigotsocketpipes,careshouldbetakenregardingorientation

sofpipes whileunloading.Asfaraspossiblepipesshallbeunloadedononesideofthestretchonly.

Thepipesshallbecheckedforanyvisibledamage(suchasbrokenedges,cracking orspallingofpip

e)whileunloadingandshallbesortedoutforreclamation.Anypipewhichshowssufficientdamage

toprecudeitfrombeingusedshallbediscarded.Draggingof pipes andfittings alongconcrete

andsimilarpavementwithhard

surfacesshallbeprohibited.necessarywarningboardsandlampsshouldbeprovidedinfrontand

Signature of Bidder Page 28 of

Ahmedabad Municipal Corporation

toavoidanyaccident.Pipesshouldbestackedwithsufficientpackingto preventrollingofthesame.

Contractorwillbefullyresponsibleforanyaccidentduetopipesorothermaterialsstackedonsiteof

yard.Contractorwillbefullyresponsibleforanylegalformalitiesarisingduetosuchaccidentandall

legalcompensationsandlegalchargesthereofshallbepaidbycontractorof

willberecoveredfromhisrunningbillofthesameorotherAMCworks.

LAYING/RELAYINGOFRECOVEREDPIPES GENERAL

The Contractor shall visit the site before tendering and get himself

acquaintedsiteconditionandtheregulationsregardingthelayingofpipesincongested areas,heavytraffic

areasetc.Thesuccessfulbiddershalltakethenecessarypermission andclearanceofalltheauthoritieslikede

partmentofroads,trafficwatersupplyandthedrainage,electricityboard,telephonecompanyetc.wherever n

Roadreinstatementshallnotbeincludedinbackfillingunlessspecified.Toprotectpersonfrominjuryandto

avoiddamagetoproperty,adequatebarricades,constructionsigns,red

lanternsandguardsasrequiredshallbeplacedandmaintainedduringtheprogressofthe

constructionworkanduntilitissafeforthetraffictousetheroadways.TherelevantIndianStandardsandtherul

esandregulationsofthelocalauthoritiesinregardstosafetyprovisionsshallbeobserved.Generallightingfor

workssite,warninglights,signboards,fencingetc.shall

beprovidedbycontractorathisowncost.Water fortestingC.Ipipesandfittingatworksiteshall

bearrangedbycontractorathisowncost.Draggingofpipesandfittingsalongconcreteand

similarpavementswithard surface shallbeprohibited.

Before excavating the trench, the alignment of pipeline shall be approvedby

Owner/Engineer.Theexcavationfortrenchesandpitsformanholes/chambersshall becarried

outinaccordancewithspecificationandshallbedonesuchthatitdoesnotgetfaraheadofthelayingoperations

asapprovedby the Owner/Engineer.

Utmostcare shallbetaken to seethatwidthofthe trench at the top

ofpipeisnotmorethanthatspecifiedinDataSheet.Incaseadditionalwidthisrequireditshallbe providedonlyin

the topportionfromthegroundlevelupto300mmabovethecrownofpipe.Ifanyextrawidthis excavated in

the area below this portion, the Contractor shall have toprovide

remedialmeasuresasdirectedbyEngineer.Contractorshallnotbepaidanyadditionalcompensation

forextraexcavationaswellasforremedialmeasures.Ifrockismetwith,itshallberemovedto

15cmbelowtheinvertlevelofpipesandfittingsandthespaceresultingshallberefilledwithexcavatedmaterial

sandproperlyconsolidated.Bottomoftrenches/pitsshallbesaturatedwithwaterwellrammedwherevertheO

wner/Engineermayconsideritnecessarytodoso.

Wherevera socketofpipeorfitting occurs,agripisto becutin the

bottomofthetrenchorconcretebedtoadepthofatleast75mmbelowthebedofthepipeand doesnotrestupon

itssocket.Suchgripshallbeofsufficientsizeineveryrespecttoadmitthehandallaroundthe

socketinordertomakethejointandthegripshallbemaintained clearuntilthejointhasbeenapprovedbyOwner

Theroadmetalandalsotherubblepackingshall firstbestrippedofffor thewholewidthof the

trench/pit and separately deposited in such places as may bedeterminedby the

Owner/Engineer.IncaseofthemetalpackingorKhandkiesnotbeingsodepositedorbeingmixed up with

excavated materials and not available forbackfilling and making good the

excavation,thecostofthenewmetal,packingorKhandkiesrequiredshallbechargedtotheContractor.

Thematerialfromexcavationshallbedepositedoneithersideofthe trenchleavingadequatecleardista

ncefromtheedgesofthetrenchandpitorasmaybenecessarytopreventthesideofthetrench/pittosliporfallora

tsuchadistanceandinsuchamannerastoavoidcoveringfirehydrants,sluicevalves,manholecoversetc.and

soastoavoidabuttinganyexistingwallorstructureorcausinginconveniencetothe publicandotherserviceorg

anizationsofotherwiseasOwner/Engineermaydirect.

Contractorshallattheratesenteredinthescheduleadditionalexcavation,takeintoaccountadditional

excavationifanyasOwner/Engineermayrequireinorder tolocatethepositionofwaterpipes,drains,sewers,e

tcoranyotherworkswhichmaybeencountered.Suchservicelinesifmetwithduringexcavationshallbeprope

rlymaintainedbyContractorbymeansofshoring,strutting,plankingover,paddingorotherwiseasOwner/En

gineermaydirect

andshallbeprotectedbytheContractorfromdamageduringtheprogressofthework.Allprecautionsshallbet

akenduringexcavationandlayingoperationstoguardagainstpossibledamagetoanyexistingstructure/pipe

lineofwater,gas,sewageetc.Ifthereisanydamage then such damageshall be made good either by

Contractor or by other agency,

asOwner/Engineermaydecideandwhollyineithercaseattheexpenseof Contractor.

Ifworkforwhichtheexcavationhasbeenmade isnotcompletedbytheexpected date

ofsettinginofrainorbeforethedayfixedbyOwner/Engineerforfillinginanyexcavationonaccount of any

festival or special occasion, Contractor shall backfill suchexcavation andconsolidatethe filling at his

own expenses as directed byOwner/Engineer and shall re-excavatewhenrequiredathisowncost.

Theexcessexcavatedmaterialshallbetransportedfromsiteofworkstoaplaceuptoadistance of

Signature of Bidder Page 29 of

Ahmedabad Municipal Corporation

km. as directed by Owner/ Engineer immediately so as not tocause anyinconvenienceto

thepublicortraffic.

Contractorshallnotbepaidanyadditionalcompensationforexcessexcavationoverwhatisspecifi

edaswellasforanyremedialmeasuresthatare specified.

Theexcessexcavatedmaterialshallbecarriedawayfromsiteofworksasspecified,

failingwhichinviewofpublicsafetyandtrafficconvenienceOwner/Engineermaycarry

outtheworkbyanyotheragencyatContractor'sriskand cost.

ItemNo. 4:-Labour charges for installing and jointing Sluice Valves including loading,

transporting from owner's store, lowering in location to the required with

excavation refilling alignment by crane/ tripod and chain block including cost

of total nos. of nuts, bolts, Necessary gaskets and excluding fixing of tail pieces

with lead & jute etc complete as directed by Engg. in charge. (As per previous

(a)100mmdia.(b)150mm dia. (c) 200 mm dia. (d) 250 mm dia. (e) 300 mm dia.

LabourchargesforcollectingSluicevalveswithtailpiecesfromMunicipalstoresloading,transportingt

othesite,installingandjointingC.I.SluicevalvesinclusiveofalljointingmaterialslikeBolts,Nuts,Washers,

Rubberpackingetc.comp..

CARTING AND H ANDLING

CastironpipesandfittingsshallbetransportedfromtheMunicipalStoresorcontractor’sstackyardtothewor

ksitesatplacesalongthealignmentofpipelineasdirected byOwner/Engineer.The Contractor shall be

responsible for the safety of pipesandfitting in transit,loading/unloading. Every care shall be

exercised in handlingpipes and fittings to avoid

damage.W hileunloading,thepipesandfittingsshallnot bethrowndownfromthetruckononthehardsurfac

es.Theyshallbeunloadedontimberskidswithsteadyingropesofbyanyothermeans.Paddingshallbeprov

idedbetweencoatedpipes,fittingsandskidstoavoiddamagetothecoating.Suitablegaps

betweenpipesshouldbeleftatintervalsinordertopermitaccessfromonesidetotheother.Incaseofsp

igotsocketpipes,careshouldbetakenregardingorientationsofpipeswhile

unloading.Asfaraspossiblepipesshallbeunloadedononesideofthe stretchonly.Thepipesshallbecheck

edforanyvisibledamage(suchasbrokenedges,crackingorspallingofpipe)while unloading and shall be

sorted out for reclamation. Any pipewhich shows

sufficientdamagetoprecudeitfrombeingusedshallbediscarded. Draggingofpipesandfittings

alongconcrete and similar pavement with hard surfaces shall beprohibited. necessary warning

boardsandlampsshouldbeprovidedinfrontandsideofpipes

toavoidanyaccident.Pipesshouldbestackedwithsufficientpackingtopreventrollingofthesame.Contrac

torwillbefully responsibleforanyaccidentduetopipesorothermaterialsstackedonsiteofyard.Contractor

willbefullyresponsibleforanylegalformalitiesarisingduetosuchaccidentandalllegal

compensationsandlegalchargesthereofshallbepaidbycontractorofwillberecoveredfromhisrunningbill

ofthesameorotherAMCworks.

Fittingshallbestackedundercoverandseparatedfrompipes.

Rubberrings shall be stored in clean,cool storeaway fromwindows,boiler,electrical

equipmentandpetrol,oilsorotherchemicals.Particularlyin the

fieldwheretherubberringsarebeinguseditisdesirablethattheyarenotleftoutonthegroundinthesunorove

rnightunderheavy frostofsnowconditions

TheContractorshallvisitthesitebeforetenderingandgethimselfacquainted siteconditionandtheregulat

ionsregardingthelayingofpipesincongestedareas,heavytrafficareasetc.Thesuccessfulbiddershalltak

ethenecessarypermissionandclearanceofalltheauthoritieslikedepartmentofroads,trafficwatersupply

andthedrainage,electricityboard,telephone companyetc.wherevernecessary.

Roadreinstatementshall notbeincludedin backfilling unlessspecified.

Toprotectpersonfrominjuryandtoavoiddamagetoproperty, adequatebarricades,

constructionsigns,redlanternsandguardsasrequiredshallbeplacedandmaintainedduringtheprogress

oftheconstructionworkanduntilitissafeforthetraffictousetheroadways.TherelevantIndianStandardsan

dtherulesandregulationsofthelocalauthoritiesinregardsto safety provisionsshallbe observed.

General lighting forworkssite,warninglights,signboards,fencing etc.shall

beprovidedbycontractorathisowncost.

Suitablefencingshallbeprovidedalongthesidesoftrenchesandpits.Thepostof the

fencingshallbeoftimbersecurelyfixedinthegroundnotmorethan3mapartandtheyshallnotbelessthan75

mmindiameteroflessthan1.2mabovethesurfaceof theground.Thereshallbetworails,onenearthetopoft

hepostandtheotherabout450mmabovethegroundandeachshallbefrom50mmto70mmindiameterand

sufficientlylongtorunfromposttopostwhichtheyshallbeboundwithstrongrope.Themethodofprojectingr

ailsbeyondtheposts andtyingthemtogetherwherethey

Signature of Bidder Page 30 of

Ahmedabad Municipal Corporation

meetwillnotbeallowedonanyaccount.Allalongtheedgesoftheexcavated

trenchesabankofearthabout1.2mhighshallbeformedasrequired

bytheOwner/Engineerforfurtherprotection.Theaboveworkshallnotbepaidforseparatelyandthecontra

ctorshalltakeintoaccountthecostsofsuchworksandquote accordingly.

WaterfortestingC.Ipipesandfittingatworksiteshallbearrangedbycontractorat hisowncost.

Draggingofpipesandfittingsalongconcreteandsimilarpavementswithardsurface shallbeprohibited.

ItemNo. 5:- Labour Chargesforremovingandrecoverofex.C.I.Sluice

valvewithtailpiecesandcartingituptoMuni.StoreorsiteasperinstructionofEngg.Incha

rgeiteminclude.necessaryExcavation, removingormakingjoints,refilling

etc.comp.asdirectedbyEnggincharge.

(a)80mmdia.(b)100mmdia.(c)150mm dia. (d)200mm dia.

Measurement willbeonNo.basis.

ItemNo. 6:- Cutting of existing pipelines of following diameters including carting of nece.

specials from AMC store to site and from site to AMC store (recovered

materials) nace. labours for excavation, jodan & backfilling fitter, supervisor,

etc. complete. Rate also includes electric cutter, dewatering pump fuel and

transportation of machineries, chain pulley block if requires working at an

instructed specific time of day or night etc. complete. (As per previous tender

Rates)(a)80mmdia.(b)100mmdia.(c)150mmdia.(d) 200 mm dia. (e) 250 mm dia. (f)

Theexcavationforjointingworkshallbedoneto therequired for

width,length&depthasdirectedbyEngineer-in-

chargeorhisrepresentative.Theexcavatedmaterialsfromthegapshallhavetobedepositedwithinaleadof

50mt.orasdirectedbyEngineer-in-

charge.Therelevantspecificationforexcavation&refillingshallconfirmtoitemNo.2above.

Aftercompletionofexcavationwork,jointingshallbedonebetweentheperiod oftwo

watersupplytime,insuchawaythatitwillnotaffectthewatersupplytimeinanypartof city

.ThisitemincludestheworkofcuttingtheexistinglinelabourforjointingofCIspecials &valveswiththeexistin

glinethedewateringrequiredetc.complete.

Allthenecessarycareshallbetakenbythecontractorduringjointingwork,so thatpipeshallnotbecrack

edthecuttinglimit.

Aftercompletionofjointingwork&testingofleadjoints,thegapshallberefilled after

obtainingnecessarypermissionofEngineer-inchargeofthework.

Thejointingworkshallbeinline&levelwithotherexisting network.

ThePaymentshallbemadeonNo.basisforallthejointing workmadeforthiswork.

ItemNo. 7:-Labours charges for collecting specials from Municipals store loading

transportation, unloading to the site, laying and fixing CI specials inclusive of

all jointing materials like lead, spun etc.and labour, exacavation re-filling and

nece. dewatering as per instrucation of engg. incharge (As per previous tender

CI/DIspecialsshouldbecartedbycontractorfromtheMuni.storetothesite.Rate

includes loweringthespecialsinthetrench/pitandfixingitforcompletingthepipeline net-work

Themode ofmeasurement willbeonKg.Basis

ItemNo.8:-LabourchargesforrecoveringCIspecialsfromoldlinebyheatingtheoldjoints

bygas/anyheatingdeviceandrecoveringthe fittingsinre-

usableconditionandloading,carting,unloadingthem tonearbyMunicipalstores.

CI/DIspecialsshouldbecartedbycontractorfromtheMuni.storetothesite.Rate

includes loweringthespecialsinthetrench/pitandfixingitforcompletingthepipeline net-work

Themode ofmeasurement willbe onKg.Basis

ItemNo.9:-Fixing of valve Road box incl .locating valve, nece. excavation, Brick

Masonary,PCC work. Item also inclues cartring form AMC store to site.

Signature of Bidder Page 31 of

Ahmedabad Municipal Corporation

Etc.Comp.asdirected

Themode ofmeasurement willbeon No.Basis

ItemNo.10:-Labour charges for repairing of lekage CI/DI pipe line of following diameter at

different places including necessary excavation manually or by machinery,

removing of mud, dewatering, cleaning of pipe, cutting of pipe, Jointing &

repairing using CID joints including CID joints, rubber rings, nut bolts,

hiring excavator, Hydra/ Crane, dewatering machine, fuel, operator etc

complete ( including cost of jointing material but excluding cost of pipe)

(GWSSB SOR 22-23 SECTION 1 G I.NO.3)

ThespecificationsofLabourworkforrepairingtheleakageintheexistingC.I./D.Iwater pipe

lineinclneceexcavationinanytypeofsoilorasphalt,repairing,refillingetc.comp.inanydiaexistingpipeline

Contractorshouldhavetofindoutthepoinofleakagehimselfbymakingsometrialpitsin

affected area. After finding the point of leakage, The contractor shall have toexcavate

necessarysizepittoworkinany

typeofsoilinclasphaltandthanattheplaceofleakagenece.repairingworkshouldbedone.Therepairworkc

anbereplacementofpipe,jointleakageorany type of leakage. After repair work completes the

excavatedearth should be refilled,necessary watering,levellingshouldbedone.

Measurement willbeonNo.basis.

ItemNo.11:-Excavation for trial pit for location of existing line including excavation of any

depth including refilling, watering etc. Comp (As per previous tender Rates)

Trail pit should be made for locating existing water pipe line as per instruction

theworkincludesexcavationofanydepthrefilling,wateringetccomp.

Themodeofmeasurement willbeonNo.basis.

ItemNo. 12:-Providing and Making hole for House connection on C.I./D.I. or M.S. with labour

cost. Instruction of engg. In charge (As per previous tender Rates)

(a)15mmDia. (b)20mm Dia c) 25 mm dia d) 32 mm dia e) 40 mm dia f) 50 mm dia

Itemincludeslabourworkformaking 15mmdia to

2"dia.holeonmainwaterpipelinetoconnecttobranchlinerateincludesP/F.G.Isetandmakingconectionwit

hjointingmaterialandmakingleakproofjointetc.comp.rateincl.excavationandrefillingthetrenches

Themodeofmeasurement willbeonNob asis

ItemNo.13:-Labour for change of GI water pipe line up to customer end.(in Muni.Limit)

Themodeofmeasurement willbeonRmt.basis

LabourWorkfortempJodanofex.lineforrunningwatersupplyinclmakingcollarbetweeng

apofpipe&jointingwithjute&dayafterremovingallthisasperinstetc.compasdire.

Themodeofmeasurement willbeonNo.basis

ItemNo.15:-Labour charges for doing washout of water pipe line at end including necessary

excavation of pit, allowing the water to flow for 15 minutes twice or thrice as per site

condition during supply hour, dewatering the pit and plugging with existing

wooden butch and refilling the pit .etc. comp .as per instruction (As per previous

washoutofwaterpipelineofanydia.shoudbedoneasperinstruction.Theworkincludes

removingtheboochfromdeadendandletthepollutedwatertoflowfrompipeuntilclearwater flow from

thepipe.itemincludesfixing theboochandrefillingthepit

Themodeofmeasurement willbeonNo.basis.

ItemNo.16:-Supplying wooden taper butches from jungle wood (Like limda, ambo) Etc. comp.

(As per previous tender Rates).

asdirectedByinstructionofEngg.incharge

Themodeofmeasurement willbeonNo. basis

ItemNo.17:-P/SOFgood qualityofrubber ringsfor followig diameter.

Modeofmeasurement.ShallbeonNo. basis.

Item No.18 :- Providing , Supplying and fixing ISI mark approved quality for ferrul

Signature of Bidder Page 32 of

Ahmedabad Municipal Corporation

connecting to existing CI/DI pipe line of water tight joints per inst.of engg. in

Modeofmeasurement.ShallbeonNo. basis.

Item No. 19:-Conveyance charge of earth, lime, murrum, building rubbish, manual garbage,

sludge, excavated rock , fly ash, aggregate of any kind etc complete up to 15.0 KM

Allthesurplusearthetc.shallbecarriedawayimmediatelyfromthesiteof worktoaplacewithin5km.

distanceorasdirectedandorderedbytheEngineer,soasnottocauseanyinconveniencetothepublictraffic

findingwhichinviewofpublicsafetyandtrafficconvenience.TheCorporationshallcarryouttheworkby

anyotheragencyatthe contractor’sriskandcost.iftheinstructionsarenot

compliedwithin7daysfromthedateofordertocartthesurplusmaterialsandclearthesite,thesaidworkshall

becarriedoutbytheMunicipalCorporationattheriskandcostofthecontractorandnoclaimordisputeshallb

eentertainedinthisrespect.

Ifthefillingintrenchesaftersettlementoftheearthistobedonethesameshallbecarriedoutbythecontract

orwithoutaskinganyextrarate.Thecontractorshallhaveto cartthesurplusearthafterthetrencheswellwater

edandrefilledwiththeearth.Therateofcartingincluding

cartingofbrickbats,metal,rubblevegetableandgarbage,ifnecessaryto cleartheroadsurface.

Measurement willbeonCMT.basis.

ItemNo.20:- Extra rate over item of excavation of earth for excavation of asphalt

pavement of thickness upto 0.20 meter including demolishing the asphalt

carpet, metal, soiling etc. comp. with stacking the material as directed. (As per

Road ARC tender 22-23.(a)upto 0.20 meterthickness(ByManual)

Extrarateforexcavationofasphaltpavementofanythicknessincludingdemolishingtheasphalt

carpet,metal,soilingetc.completewithstackingthematerialsasdirected.Theroadsurfaceofasphaltshallcar

efullybeopenedtofullwidthasdirectedbytheEngineerinchargesoasto removeallcracksorotherdamagedp

ortionsofroadeithermanuallyorwiththesoilingshallbefirstbestrippedoffforthewholewidthof

trenches.Allthe materials shall be separatelydepositedinsuchplaces as maybedetermined

bytheEngineer-in-

charge.Incaserubblenotbeingsodepositedorbeingmixedupwiththeexcavatedmaterialswillnotbeallowed

forrefilling.Thecostofmaterialsshallbechargedfromthecontractor.ThedecisionoftheC.E.shallbefinaland

bindingto thecontractor.

Therate persq.mt. inthisitem shallbeextrarateadditiontotherateforexcavation.

(b)0.20 to 0.30 meter (By any type of Breaker Machine or R.C.C.Cutter

machine including cost of operator, fuel & transportation etc complete.

Demolition of old RCC slab / Asphalt Road by breaker machine as

per standardspecificatonworkshouldbecarriedoutatanydepthrunningseverline.necessarytools,plan

t,fuleetc.providingby thecontractor,.

Modeofmeasurement.Shallbeon sq.mt. basis.

ItemNo.21:-Providing & Supplying JCB Machine on rental basis in case of emergency situation

and break down type work & also during unavoidable condition as per instruction

of engg.incharge , rate includes all nece. shifting, fuel and operating charges and

stacking of useful & non-useful materials separately up to store. (No payment

should be allowed for non working condition of machinery and for pipe line

excavation and laying work)

TheitemisforsupplyingJCBonrentforvariousconstructionactivities Therateincludesvariouso

perationalcostsuchasoperatinggenerater/electricitydiesel,petrol,operater'ssalary,etccomp.

whenmachineisinworkingconditionallprecautionsshallbetakenbycontractor

toavoidtheaccident.ifanyaccidentoccurscontractorshallbefullyresonsiblefor that.

thepaymentshallbegivenonhourbasis.Nopaymentshallbegivenforidlehourandnotime

shallbecountedforcarryingmachinetositeandfromshiftingsite tosite.

thepaymentshallbegivenonhourbasis.

ItemNo.22:-Dewatering by pumping set of required capacity including temporary platform

carting pumping at site and fixing the same in position including all accessories, and

fuel and labour etc. Complete (A) Pump set of Capacity (GWSSB SOR 22-23

Section 2E-miscellaneous Item no. 1)

Theitemisforsupplyingdewatering Pump incl.Costoffuelandoperatoronrentfor

variousconstructionactivitiesTherateincludesvariousoperationalcostsuch as

operatinggenerater/electricity diesel,petrol,operater'ssalary,etccomp.

Signature of Bidder Page 33 of

Ahmedabad Municipal Corporation

whenmachineisinworkingconditionallprecautionsshallbetakenbycontractor

toavoidtheaccident.ifanyaccidentoccurscontractorshallbefullyresonsiblefor that.

thepaymentshallbegivenonhourbasis.Nopaymentshallbegivenforidlehourandnotime

shallbecountedforcarryingmachinetositeandfromshiftingsite tosite.

thepaymentshallbegivenon hourbasis.

ItemNo.23:-Supplying Pneumatic Breaker Machine for RCC Slab or Asphalt Demolishing Work

on site by using Operator, fuel, power Supply etc. Complete as Directed. (As per

previous tender Rates)

Themodeofmeasurement willbeonHourBasis

ItemNo.24:-Providing, laying and jointing in true line and level U.P.V.C pipe (SCH - 40) of following dia.

including fittings of standard make as approved by Engineer - in - charge. Pipe shall be

fixed on the wall with the help of clamp at every shall be concealed as directed

including necessary Tee ,bend, any joint & any fittings etc. including testing of pipe and

joints and fixing the same with adhesive solvent, including cost of all materials

(Building SOR 21-22 )

thepaymentshallbegivenonRmtbasis.

Item No 25:-Removing any kind of pavement incl stacking of serviceble material disposal of unserviceble

material with 50 meter lead and lift.

Demolishing work shall be carried out as per instructions given by the Engineer in charge.

Demolishing of stone slab pavement or any other type of paving, proportion of cement or lime, sorting

out materials, carting them up to lead of 50 mts. & Stacking the different materials separately as

directed by the Engineer in charge of work. The work shall be done carefully.

The rate shall be for a unit of one square meter.

ItemNo. 26:-Supplying, labour for excavation of all types of soil at any depth including

excavation of asphalt pavement of any thickness, demolition of brick work

in CM of any proportion including stacking of serviceable materials and

disposal of unserviceable material etc. comp. as directed.

Measurement willbeonNo.basis.

Item No 27:-Repairing damaged M.H. and rasing M.H. up to road level incl. removing damaged

brick work and repairing by brick masonry in C.M. 1:5 and plaster in C.M. 1:3 and

fixing C.I.steps and existing MH sheet cover, removing the debris from MH and

carting the same as directed.

(A) up to 0.15 mt. (@ Two Coarse)

(B) up to 0.35mt. (@ Four Coarse)

Repairing of ex. Twin I.C. with necessary bk masonary cement plaster, fixing screen and fixing of ex-

seat at top in c.c. & p/f precast chamber cover at top etc. comp. as directed as per site

conditionThe rate shall be for a unit of one number.

Item No 28:- Repairing damaged I.C./ Raising removing damaged brick work and repairing by

brick masonry in C.M. 1:5 and plaster in C.M. 1:3 and fixing C.I. steps and existing

chamber sheet cover, removing the debris from chamber and carting the same as

Repairing of ex. Twin I.C. with necessary bk masonary cement plaster, fixing screen and fixing of ex-

seat at top in c.c. & p/f precast chamber cover at top etc. comp. as directed as per site

conditionThe rate shall be for a unit of one number.

Item No 29:- Providing and supplying and jointing ISI mark only standard length stoneware pipes of

following class and diameter including excavation for laying of pipes, insurance,

Signature of Bidder Page 34 of

Ahmedabad Municipal Corporation

transportation, freight charges, octroi, inspection charges, loading, unloading,

conveyance to departmental stores, stacking etc. compl. (IS651/1989 or its latest

revision) including labour work for lowering, laying, joiting with cement mortar (1:1)

proportion, proper postion, grade and alignment and all level as directed by engineer in

charge including store to site of work jointing material etc complete..

As per Item and instructed by engineer incharge

The rate shall be for a unit of one rmt basis

Item No 30:- Providing & Supplying And Fixing Following Size Spindle For Sluice Valve Of

Following Size. The Rate Is inclusive of removing exsting damaged spindle, take it

away & replacing a new spindle of the same size & shape made from gun

metal/stainless steel or mild steel as the case may be the rate is also inclusive of

excavation, removing/refixing the spindle with req nut bolts rubber gasket, gallen

dori etc and making the valve feeting leak proof. (Up to 150 mm)

As per Item and instructed by engineer incharge

The rate shall be for a unit of no basis

Item No 31:- Providing & Supplying And Fixing Following Size Check nut For Sluice Valve Of

Following Size. The Rate Is inclusive of removing exsting damaged Check nut, take it

away & replacing a new Check nut of the same size & shape made from gun

metal/stainless steel or mild steel as the case may be the rate is also inclusive of

excavation, removing/refixing the Check nut with req nut bolts rubber gasket, gallen

dori etc and making the valve feeting leak proof. (Up to 150 mm)

As per Item and instructed by engineer incharge

The rate shall be for a unit of no basis

Item No 32:- Providing, supplying and laying diff dia sluice valves galen dory leakage reparing the

excavation in any type of soil, refiling, necessary nuts, boults etc complete engg in

As per Item and instructed by engineer incharge

The rate shall be for a unit of no basis

Item No 33:- Barricading the entire break down or excavated area on rental basis using

wooden ballies/M.S. angles at max. 2.00 meter centre to centre, C.G.I. Sheet,

reflective paint/Board outside to avoid accident & for smooth traffic diversion

& movement including cautionary board etc. Item also includes for making

temporary sufficient nos of lighting arrangement throughout the work with

necessary required arrangement. ..The same shall be removed after completion of

work. (Only for break down work from start to complete) (As per previous ARC

As per Item and instructed by engineer incharge

Signature of Bidder Page 35 of

Ahmedabad Municipal Corporation

The rate shall be for a unit of No basis

Seal and Signature of the Bidder Add.City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 36 of

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT (CENTRAL ZONE)

BILL OF QUANTITY

btl ^thtmÇg©e, btl ftWLmejh©e (70:20:10) yk<do< Vt¤Juj csuxbtk&e bægÍtul Ntnvwh Jtuzobtk œwDuµh rJM<th,swlt Ntnvwh

<&t bnukœefwJt rJM<th <&t yLg søGttyu vtKele vtuÕgwNl yk<do< vtKele jtRl buRxulLm fhJt <&t lJe vtKele jtRl

ltkFJtlt ftb ctc<.(yu.yth.me.)

Sr.No QTY Description Rate Per Amount

1 Transporting from AMC store and laying spigot and

socket New DI pipe line DI-k-9 pipes of various

classes with CI/DI/MS specials of following diameters.

Rate includes excavation up to minimum 1.0 mt. depth

from top of pipe / as per requirement in any soil,

refilling after laying pipe, covering and temptation

of carting surplus earth up to 30 mt. lead and

watering and compaction. Clearing the site. All

Joints shall be made tight & leak free etc. comp. (As

per previous tender Rates)

2000 (B) 100 mm dia 64 Rmt.

1000 (C) 150 mm dia. 78 Rmt.

50 (D) 200 mm dia. 94 Rmt.

20 (E)250 mm dia. 113 Rmt.

20 (F) 300 mm dia. 137 Rmt.

Only Removing & recover of existing CI/DI pipe line &

Specials, removing any type of joint , carting it to the

Muni. Stores as & where directed as per instruction of

Engg. In charge with excavation & refilling.

20 A 80 to 100 mm dia 64 Rmt.

20 (C) 150 mm dia. 78 Rmt

3 Removing & relaying of existing CI/DI pipe line &

Specials, Cleaning of pipe & Specials from Inside,

including excavation, refilling etc. comp. in line & level

with any type of joints as per instruction of engg. in

1500 (B) 100 mm dia 64 Rmt.

1500 (C) 150 mm dia. 78 Rmt.

20 (D) 200 mm dia. 94 Rmt.

20 (E)250 mm dia. 113 Rmt.

20 (F) 300 mm dia. 137 Rmt.

Signature of Bidder Page 37 of

Ahmedabad Municipal Corporation

4 Labour charges for installing and jointing Sluice Valves

including loading, transporting from owner's store,

lowering in location to the required with excavation

refilling alignment by crane/ tripod and chain block

including cost of total nos. of nuts, bolts,

Necessary gaskets and excluding fixing of tail pieces

with lead & jute etc complete as directed by Engg.

in charge. (As per previous tender Rates)

200 (B) 80 to 100 mm dia 1411 No

30 (c) 200 mm dia 2125 No

20 (d) 250 mm dia 3000 No

20 (e) 300 mm dia 3777 No

5 Labour Charges for removing and recover of ex. C.I.

Sluice valve with tail pieces and carting it up to

Muni.Store or site as per instruction of Engg. In charge

item include. necessary Excavation, removing or

making joints, refilling etc.comp. as directed by Engg

100 (A) 80 mm dia 610 No

100 (B) 100 mm dia 830 No

20 (C) 150 mm dia. 1000 No

10 (D) 200 mm dia 1260 No

6 Cutting of existing pipelines of following diameters

including carting of nece. specials from AMC store to

site and from site to AMC store (recovered

materials) nace. labours for excavation, jodan &

backfilling fitter, supervisor, etc. complete. Rate

also includes electric cutter, dewatering pump fuel

and transportation of machineries, chain pulley

block if requires working at an instructed specific

time of day or night etc. complete. (As per

previous tender Rates)

1000 (A) 80 mm dia 1125 No

600 (B) 100 mm dia 1446 No

10 (E)250 mm dia. 3170 No

10 (F) 300 mm dia. 5143 No

7 12,000.00 Labours charges for collecting specials from 21 Kg.

Municipals store loading , transportation, unloading

to the site, laying and fixing CI specials inclusive of

all jointing materials like lead, spun etc.and labour,

exacavation re-filling and nece. dewatering as per

instrucation of engg. incharge (As per previous

8 1000 Labour charges for recovering CI specials from old line 11 kgs.

by heating the old joints by gas / any heating device

and recovering the fittings in re-usable condition and

loading, carting, unloading them to nearby Municipal

Signature of Bidder Page 38 of

Ahmedabad Municipal Corporation

9 100 Fixing of valve Road box incl .locating valve, nece. 446 Nos

excavation, Brick Masonary,PCC work. Item also

inclues cartring form AMC store to site. Etc.Comp.

10 Labour charges for repairing of lekage CI/DI pipe line

of following diameter at different places including

necessary excavation manually or by machinery,

removing of mud, dewatering, cleaning of pipe,

cutting of pipe, Jointing & repairing using CID joints

including CID joints, rubber rings, nut bolts, hiring

excavator, Hydra/ Crane, dewatering machine,

fuel, operator etc complete ( including cost of

jointing material but excluding cost of pipe) (GWSSB

SOR 22-23 SECTION 1 G I.NO.3)

11 1000 Excavation for trial pit for location of existing line 290 No

including excavation of any depth including refilling,

watering etc. Comp (As per previous tender Rates)

12 Providing and Making hole for House connection on

C.I./D.I. or M.S. with labour cost. Instruction of

engg. In charge (As per previous tender Rates)

1000 A) 15 mm Dia 313 No

40 B) 20 mm Dia 402 No

60 C) 25 mm Dia 536 No

20 D) 32 mm Dia 670 No

60 D) 40 mm Dia 1786 No

50 E) 50 mm Dia 2679 No

13 2000 Labour for change of GI water pipe line up to 35 Rmt.

customer end.(in Muni.Limit)

14 800 Labour Work for temp Jodan of ex.line for running 300 No

water supply incl making collar between gap of pipe &

jointing with jute & day after removing all this as per

inst etc.comp as dire.

15 1000 Labour charges for doing washout of water pipe 670 No

line at end including necessary excavation of pit,

allowing the water to flow for 15 minutes twice or

thrice as per site condition during supply hour,

dewatering the pit and plugging with existing

wooden butch and refilling the pit .etc. comp .as per

instruction (As per previous tender Rates)

16 Supplying wooden taper butches from jungle wood

(Like limda, ambo) Etc. comp. (As per previous tender

1000 (A) 15 Mm dia. to 20 MM dia. 13 No

200 (B) 25 Mm dia. to 37 MM dia. 18 No

40 (C) 50 Mm dia. 89 No

500 (D) 80 mm dia to 100 mm dia line 313 No

Signature of Bidder Page 39 of

Ahmedabad Municipal Corporation

200 (E) 150 mm dia 446 No

200 (F) 200 mm dia 714 No

17 P/S OF good quality of rubber rings for following dia

40 (A) 80 mm dia 22 No

800 (B) 100 mm dia 45 No

200 (C) 150 mm dia. 54 No

30 (D) 200 mm dia. 94 No

20 (E)250 mm dia. 125 No

18 Providing, Supplying and fixing ISI mark approved

quality for ferrul connecting to existing CI/DI pipe

line of water tight joints per inst.of engg. in charge

1000 (A) 15 mm dia 223 No

2 (B) 20 mm dia 313 No

2 (C) 20 mm dia 491 No

19 1000 Conveyance charge of earth, lime, murrum, building 140.37 Cu.M

rubbish, manual garbage, sludge, excavated rock , fly

ash, aggregate of any kind etc complete up to 15.0 KM

Extra rate over item of excavation of earth for

excavation of asphalt pavement of thickness upto

0.20 meter including demolishing the asphalt

carpet, metal, soiling etc. comp. with stacking the

material as directed. (As per Road ARC tender 22-23)

1000 up to 0.20 meter thickness (By Manual) 71.1 smt

1000 0.20 to 0.30 meter (By any type of Breaker 177.76 smt

Machine or R.C.C.Cutter machine including cost

of operator, fuel & transportation etc complete.

21 1000 Providing & Supplying JCB Machine on rental basis in 600 hr

case of emergency situation and break down type

work & also during unavoidable condition as per

instruction of engg.incharge , rate includes all nece.

shifting, fuel and operating charges and stacking of

useful & non-useful materials separately up to store.

(No payment should be allowed for non working

condition of machinery and for pipe line excavation

and laying work)

22 10000 Dewatering by pumping set of required capacity 18.32 Hr

including temporary platform carting pumping at site

and fixing the same in position including all

accessories, and fuel and labour etc. Complete (A)

Pump set of Capacity (GWSSB SOR 22-23

Section 2E-miscellaneous Item no. 1)

23 1000 Supplying Pneumatic Breaker Machine for RCC Slab or 600 hr

Asphalt Demolishing Work on site by using Operator,

fuel, power Supply etc. Complete as Directed. (As per

previous tender Rates)

Signature of Bidder Page 40 of

Ahmedabad Municipal Corporation

24 Providing, laying and jointing in true line and level

U.P.V.C pipe (SCH - 40) of following dia. including

fittings of standard make as approved by Engineer -

in - charge. Pipe shall be fixed on the wall with the

help of clamp at every shall be concealed as

directed including necessary Tee ,bend, any joint &

any fittings etc. including testing of pipe and joints and

fixing the same with adhesive solvent, including cost

of all materials (Building SOR 21-22 )

a 3000 15 mm (I.code no. 23061) 84.87 Rmt.

b 1000 25 mm (I.code no. 23062) 107.29 Rmt.

c 1000 32 mm (I.code no.23063) 139.2 Rmt.

d 100 40 mm (I.code no. 23064) 173.03 Rmt.

e 100 50 mm (I.code no. 23065) 228.61 Rmt.

25 1000 Removing any kind of pavement incl stacking of 14 Smt

serviceble material disposal of unserviceble material

with 50 meter lead and lift.

26 Supplying, labour for excavation of all types of soil at

any depth including excavation of asphalt pavement

of any thickness, demolition of brick work in CM

of any proportion including stacking of serviceable

materials and disposal of unserviceable material etc.

comp. as directed.

1500 Mazdoor at day /night (As per min.wages circular of 363.3 No

500 Fitter at day / Night (As per min.wages circular of 380.3 No

300 Makadam/ supervision/Fitter at day / Night 379.45 No

27 Repairing damaged M.H. and rasing M.H. up to road

level incl. removing damaged brick work and repairing

by brick masonry in C.M. 1:5 and plaster in C.M. 1:3

and fixing C.I.steps and existing MH sheet cover,

removing the debris from MH and carting the same as

directed. (Based on Drainage SOR 2009-10)

100 (A) up to 0.15 mt. (@ Two Coarse) 732.14 no

100 (B) up to 0.35mt. (@ Four Coarse) 1160.71 no

28 400 Repairing damaged I.C./ Raising removing damaged 401.79 no

brick work and repairing by brick masonry in C.M. 1:5

and plaster in C.M. 1:3 and fixing C.I. steps and

existing chamber sheet cover, removing the debris

from chamber and carting the same as directed.

(Based on Drainage SOR 2009-10)

29 Providing and supplying and jointing ISI mark only

standard length stoneware pipes of following class

and diameter including excavation for laying of pipes,

insurance, transportation, freight charges, octroi,

inspection charges, loading, unloading, conveyance to

departmental stores, stacking etc. compl. (IS651/1989

or its latest revision) including labour work for

lowering, laying, joiting with cement mortar (1:1)

proportion, proper postion, grade and alignment and

all level as directed by engineer in charge including

store to site of work jointing material etc complete..

Signature of Bidder Page 41 of

Ahmedabad Municipal Corporation

a 60 100 mm dia 165.52 Rmt

b 60 150 mm dia 242.98 Rmt

c 60 230 mm dia 400.54 Rmt

30 Providing & Supplying And Fixing Following Size

Spindle For Sluice Valve Of Following Size. The Rate Is

inclusive of removing exsting damaged spindle, take it

away & replacing a new spindle of the same size &

shape made from gun metal/stainless steel or mild

steel as the case may be the rate is also inclusive of

excavation, removing/refixing the spindle with req nut

bolts rubber gasket, gallen dori etc and making the

valve feeting leak proof. (Up to 150 mm) (Approved

31 Providing & Supplying And Fixing Following Size Check

nut For Sluice Valve Of Following Size. The Rate Is

inclusive of removing exsting damaged Check nut, take

it away & replacing a new Check nut of the same size

& shape made from gun metal/stainless steel or mild

steel as the case may be the rate is also inclusive of

excavation, removing/refixing the Check nut with req

nut bolts rubber gasket, gallen dori etc and making the

valve feeting leak proof. (Up to 150 mm) (Approved

32 30 Providing, supplying and laying diff dia sluice valves 343.75 No

galen dory leakage reparing the excavation in any type

of soil, refiling, necessary nuts, boults etc complete

33 549 Barricading the entire break down or excavated 344.75 No

area on rental basis using wooden ballies / M.S.

angles at max. 2.00 meter centre to centre, C.G.I.

Sheet, reflective paint / Board outside to avoid

accident & for smooth traffic diversion &

movement including cautionary board etc. Item

also includes for making temporary sufficient nos of

lighting arrangement throughout the work with

necessary required arrangement. ..The same shall be

removed after completion of work. (Only for break

down work from start to complete) (As per previous

ARC tender rates)

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 42 of

Ahmedabad Municipal Corporation

Signature of Bidder Page 43 of