Tender for Work of Mechanical Strengthening and Stub strengthening of 66Kv Sardargadh - Sheradi, 66Kv Sheradi - Chauta and 66Kv Sardargadh - Pajod H-Frame Line under R and M 2026-27 With Buyback of OLM under Manavadar AM Division of Junagadh Circle

Tender for Work of Mechanical Strengthening and Stub strengthening

of 66Kv Sardargadh – Sheradi, 66Kv Sheradi - Chauta and 66Kv

Sardargadh - Pajod H-Frame Line under R&M 2026-27 With Buyback

of OLM under Manavadar AM Division of Junagadh Circle.

REMARK: Bidder shall quote on erection part only. No option shall be

given to the bidder for selection of price bid in OLM Part. The OLM cost

Technical Bid (All relevant documents) and Price Bid both must be

submitted online only. No physical bid accepted.

Payment of Tender Fee/E.M.D. can be accepted by

RTGS/NEFT/Online Only.

IMPORTANT NOTE:

IF BIDDER FAILED TO SUBMIT ANY OF THE REQUIRED DOCUMENT ALONG WITH

THE ONLINE TECHNICAL BID AS PER QUALIFICATION REQUIREMENT, THEIR BID

MAY BE REJECTED WITHOUT INTIMATION TO BIDDER.

HENCE, BEFORE QUOTE THE BID, BIDDER HAVE TO ENSURE THAT ALL THE

DOCUMENTS ARE SUBMITTED ONLINE ALONG WITH TECHNICAL BID.

Seal and Signature of Contract Page 1 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Sr. Particulars Code

1 Tender Notice

2 Integrity pact

3 Detail to be furnished by the tenderer

4 Qualification requirement QR

5 Safety clause

6 General commercial Conditions GCC

7 Terms & Conditions regarding Industrial Laws and Other Related

8 General condition GTC

9 Specification for Erection of 66 kV SS & “H” Frame/Tower Line

10 Appendices I to VIII

11 Performa for Safety Bond, Safety cum indemnity bon, Contract

Seal and Signature of Contract Page 2 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Tender notice no. : TCJND/2026-27/N-29

Superintending Engineer, Transmission Circle GETCO Junagadh invites “On line Tenders” (e-tendering) for the work

of “Tender for Work of Mechanical Strengthening and Stub strengthening of 66Kv Sardargadh – Sheradi, 66Kv

Sheradi - Chauta and 66Kv Sardargadh - Pajod H-Frame Line under R&M 2026-27 With Buyback of OLM under

Manavadar AM Division of Junagadh Circle.“ from registered contractors in appropriate class with GETCO and who

has executed similar nature of work successfully as mentioned in Qualification requirement criteria given in the tender

document. Bidders should fulfill all the qualification criteria. Otherwise, their bids will not be considered & price bid will

not be opened. All the bidders should have valid e-tender vender registration. Tender papers & specifications may be

down loaded from web site https://getco.nprocure.com (for view, download and online submission) and GUVNL/

GETCO websites www.getcogujarat.com (for view & download only). Tender fee plus GST and EMD may be paid along

with submission of tender by RTGS/NEFT/Online. “All the relevant documents of tender to be submitted online.

The Superintending Engineer

Gujarat Energy Transmission Corporation Limited.,

Circle office GETCO – Junagadh,

“ NO COURIER SERVICE OR HAND DELIVERY” will be allowed.

Sr. Name of Work Estimated Time Tender EMD amount Appropriat

No. Cost Rs. Limit Fee e class

Tender for Work of Mechanical

Strengthening and Stub

strengthening of 66Kv Sardargadh

– Sheradi, 66Kv Sheradi - Chauta 218691.83 Any Class

1. and 66Kv Sardargadh - Pajod H- (Fix)

Frame Line under R&M 2026-27 Months 180.00 =

(OLM Scrap GETCO

With Buyback of OLM under

Manavadar AM Division of cost incl.

Junagadh Circle 18% GST and

1 On line (e-tendering) tender/offer submission last date up to 16:00 hours only

(This is mandatory)

2 Date of opening of Tender Fee, EMD, and technical bid on line opening at 16:30

hrs. if possible

3 Tentative Date of online opening of price bid After Evolution of

1. All the relevant documents as per requirement of the tender to be submitted online i.e. Technical bid, Qualification

requirement data, detail specification, Tender Fee plus GST as applicable, EMD. Otherwise the offer will not be considered

and no any further communication in the matter will be entertained.

2. Any deviation found in Data/Details/Documents in on line offer (e-tendering) submitted documents (Tender document fee,

EMD, Vendor Registration, Technical and commercial documents etc.) of bidder, offer of the same bidder will not be

considered and no any further communication in the matter will be entertained. Tender will be evaluated on

Data/Details/Documents of the “on line” offer.

3. It is mandatory for all the bidders to submit their tender documents by on-line (e-tendering) and Tender Fee, EMD in

schedule time. After schedule time the same tender will not be considered.

4. The bidders are required to fill up all the online appendices (annexure)/forms. This is intended for transparency and speedy

evaluation of the bids. Instead of simply confirming, the bidder shall fill in the particulars against appropriate place in

respect of each line appearing in each online annexure.

(In the absence of required details in the online annexure, the corporation has every right to evaluate the bids accordingly

and bidder cannot raise any objection against any point during evaluation.)

5. Bidders are requested to remain in touch with the web site for any amendment/ corrigendum or extension of due date etc.

6. No tender shall be accepted/opened in case of receipt after due date and time of tender, irrespective of delay due to any

reasons and the Corporation shall not assume any responsibility for late receipt of tender.

Seal and Signature of Contract Page 3 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

7. The Earnest Money Deposit and tender fee plus GST as applicable will be accepted by NEFT/RTGS/Online payable at

Junagadh drawn in favor of “GUJARAT ENERGY TRANSMISSION CORPORATION LTD.” Tender without EMD and tender

fee plus GST as applicable shall be rejected.

8. The GETCO reserves the right to award the work to one or more bidders, considering their technical and financial capacity

OR to reject any or all tenders or accept any tender without assigning any reason thereof.

9. Suitable payment option can be selected for Tender Fee & EMD. Amount should be paid either by

RTGS/NEFT/Online. Payment of tender fee & EMD by RTGS/NEFT shall be encouraged.

In case of payment through RTGS/NEFT/Online bidder has to mail following details:

Sr. No. Required Details

1 Name & Address of Bidder

2 Bidder GST No.

3 Tender Notice No. with due Dt.

4 Mode of Transfer

5 Ref. ID with Bank details

7 Payment against (Tender Fee/EMD)

1. [email protected]

2. [email protected]

3. [email protected]

Bidder has to provide all above details on the same date of payment so that receipt can be generated.

Any technical questions, information and clarification that may be required pertaining to this enquiry should be referred to: The

Superintending Engineer (TR), Gujarat Energy Transmission Corporation Limited. Circle office Junagadh.

GETCO reserves the right to reject any OR all tenders without assigning any reasons thereof.

Yours faithfully,

Superintending Engineer (TR)

Transmission Circle office

To view the PDF file please use “Acrobat Reader” software which can be downloaded from ‘Adobe” website.

Download Tender Documents in (PDF Format) which consists of:

Part-I: Commercial Terms & conditions

Part-II: Technical specifications & GTP’S, Schedule “A” indicating the quantity & drawings if any.

To view the PDF file please use “Acrobat reader” software which can be downloaded from “Adobe” website.

In case bidder needs any difficulty in accessing/submission of on line bid/ clarification or if training required for participating in

online tender, they can contact the following office:

(n) Procure Cell, (n) code solutions-A division of GNFC Ltd.,

403, GNFC Infotower, S.G.Road,

Bodakdev Ahmedabad-380054 (Gujarat)

Fax: 079-26857321/ 40007533, Email: [email protected]

Seal and Signature of Contract Page 4 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

GETCO Junagadh Circle Beneficiary Bank Detail Is As Under

1 Name of Account Holder THE SUP ENG (TRANS) GETCO TR CIRCLE

NON OPERATIVE A/C

2 Account Number

3 Name Of Bank STATE BANK OF INDIA

5 Address Of Bank ZANZARDA ROAD – JUNAGADH

6 IFSC Code SBIN0060445

7 PAN No. AABCG4029R

8 TAN No. RKTG00895G

9 GST No. 24AABCG4029R2ZC

Payment of Earnest Money Deposit (EMD) and Tender Fee should be accepted by RTGS/NEFT/Online only along

with Tender. Also submit bank payment proof i.e. Bank statement. If possible, please inform to our Account

Department for the said payment through phone/email for verification.

1. Payment of Tender Fee

 Payment of Tender Fees can be accepted by RTGS/NEFT/Online.

2. Payment of Earnest Money Deposit (EMD)

 Payment of Earnest Money Deposit (EMD) can be accepted by RTGS/NEFT/Online.

3. Documents with Bid submission

 Bidder has to upload scanned copies of original (Notarized/ Self attested copies of original – as

specified in tender documents) documents with bid and no physical documents to be called from

It shall be sole Responsibility of the bidder that the uploaded scanned documents (in PDF form) remain

legible and should not be password protected.

Seal and Signature of Contract Page 5 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Seal and Signature of Contract Page 6 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Details of the Firm

Name of the Firm

1 Address of registered office

2 Contact personnel

4 Residential Address

7 Telegraphic code

8 E-mail address

1 Address of WORK

2 Contact personnel

4 Residential Address

7 Telegraphic code

8 E-mail address

Seal of the Firm Signature of the Tenderer

Seal and Signature of Contract Page 7 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Details of experience in last two years from the due date of tender

Order Nos. of sub- Due date Actual

Sr. Name of Order fully order

reference no. stations/feeder of Date of

No. s/s value executed under

& Date bays completion completion

A Gujarat Energy Transmission Corporation Ltd.

B Other state electricity board

C Private Firms

Seal of the Firm Signature of the Tenderer

List of work completion certificate submitted with technical bid

Name of the authority by whom

Sr.No. Name of work the work completion certificate Reference No. & Date

Seal of the Firm Signature of the Tenderer

Seal and Signature of Contract Page 8 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

ANNEXURE-4 (to be upload online)

1. PRICES: [FIRM ONLY] (Please Specify YES / NO.)

2. PENALTY TERMS AGREED (Please Specify YES / NO.)

3. SECURITY TERMS AGREED:

(Please Specify YES / NO.)

4. TENDER TERMS AGREED:

(Please Specify YES / NO.)

5. VALIDITY Of the offer for 180 DAYS From the date of

opening of the Technical Bid: AGREED:

(Please Specify YES / NO.)

6. PAYMENT TERMS AGREED:

(Please Specify YES / NO.)

7. MOBILE NOS., TELEPHONE NOS. & FAX NO:

8. Authorized person of the firm :

9. Name of the proprietor, partners, directors [as the case may

be], along with address, telephone, fax no. etc.

Qualification Requirement Terms.

Contractor must fill up below details

TENDER NOTICE No: TCJND/2026-27/N-29

Signature of Tenderer Company’s Round Seal

ANNEXURE-5 (to be upload online)

(On the letter pad of the company)

(UNDERTAKING IN REGARD TO STOP DEAL / BANNED FOR BUSINESS DEALING/

BLACK LIST THEREOF)

Sub: Undertaking in regard to Stop Deal/ Banned for Business dealing/ Black List thereof

Ref: Tender Notice No. TCJND/2026-27/N-29

All bidders will have to furnish the following undertaking dully filled in, signed and stamped for

each quoted item of the tender along with the Technical Bid.

here by certify that M/S

any partner / any directors of the firm is not stop deal and / or banned for business dealing and / or

black listed by GUVNL and / or their any subsidiary company viz. GSECL / GETCO / DGVCL /

MGVCL / UGVCL / PGVCL.

Seal of the Firm Signature of the Tenderer

Seal and Signature of Contract Page 9 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

ANNEXURE-6 (to be upload online)

(On the letter pad of the company)

UNDERTAKING IN RESPECT OF REFERENCE TO NCLT UNDER INSOLVENCY &

BANKRUPTCY CODE

Subject: - Undertaking in respect of reference to nclt under insolvency & bankruptcy code

Tender No. TCJND/2026-27/N-29

In connection with above subject, I / We confirm that our firm is not declared in NCLT under

Insolvency & Bankruptcy Code. Further, I / We also agree that, if any found NCLT under Insolvency

& Bankruptcy Code, the offer shall be out rightly rejected without assigning any reason thereof.

(Seal, Sign & Name of Authorized Signatory of Bidder)

ANNEXURE-7 (to be upload online)

Declaration Of Conflict On Interest

(On the letter pad of the company)

The Superintending Engineer

Gujarat Energy Transmission Corporation Limited.,

Circle Office, Dhandhusar road, Opp. Nandbava Gaushala,

66KV Zanzarda substation,

Ref: Tender Notice No: TCJND/2026-27/N-29

With reference to above your tender Notice No……………………………………………..

We do not have any conflict of interest with any other bidder who has submitted the bid in this

Yours Faithfully,

Stamp & Signature of contractor

Seal and Signature of Contract Page 10 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

No deviation certificate

(On the letter pad of the company)

Reference: Tender Notice no. : TCJND/2026-27/N-

In connection with the above subject and reference, I/ We confirm the following:

1. I / We, the under signed have read and examined the Tender Specifications in tender mentioned

under reference along with the Commercial terms and conditions.

2. I / We, declare that our Technical Bid is strictly in line with the Tender specifications.

3. Further, I /We also agree that additional conditions / deviations, if any, found in the commercial

terms & conditions, our offer shall be out rightly rejected without assigning any reason thereof.

Seal of the Firm Signature of the Authorized

Representatives of the firm

Declaration Relationship with employee

(On the letter pad of the company)

UNDERTAKING FOR LABOUR LAWS

(On the letter pad of the company)

Seal and Signature of Contract Page 11 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Qualifying Criteria Table:

Bidder has to upload scanned copies of original (Notarized/ Self attested copies of

original – as specified in tender documents)

Sr. Qualifying Requirements

1. Registration : The bidder shall be strictly a GETCO register contractor of any class

2. Technical Criteria:

The bidder should have erected 40 KM transmission lines including foundation, tower

erection and stringing of conductor and earthwire of 66kV and/or above class lines on

towers/H frame in last three years as a Main contractor

Bidder must have experience in executing similar nature of works (Mechanical

Strengthening, stub strengthening and Earthing etc. work) in H-frame line for

minimum of 50 % value of estimated cost of tender in last three years with the

documentary evidence, preferably photocopy of orders & 3A form secured from GETCO

as satisfactory completion certificate from respective departments. (As a Main

3. Financial Criteria:

The bidder shall submit the Bank solvency of the amount which is 20% of the total

estimated cost of tender.

FINANCIAL CRITERIA

1. Payment of Tender fee and EMD.

2. GST registration certificate.

3. Electrical Contractor License.

4. Details of Partners/Directors of the Firm/Company. Partnership deed if applicable.

5. Copy of power of attorney as the case may be.

6. PF registration.

7. Latest Bank solvency certificate of 20% of the tender value is required to be furnished by the tenderer along with the

8. The Bidder should have to submit copy of PAN card.

9. Last 3-year Income Tax return.

10. Under taking in respect of reference to NCLT under Insolvency & Bankruptcy Code.

The undertaking is to be furnished by the bidder in its bid as per the format attached and shall be deemed to be part

of the bidding schedule and submitted along with QR Bid. (Annex.06)

11. Declaration for Relationship with employee. (Annex.9)

12. ANNEXURE- 1 to 10 (All Declaration should be submitted as duly signed copy instead of just fixing image of

signature on all the declaration.).

13. Technical bid (All pages of TENDER i.e. technical specification & condition etc. of TENDER with stamp & signature.

Also, all the annexure must duly have filled by bidder/’s)

Note: Above technical criteria is for technical scrutiny after opening the technical bid. However, the GETCO

reserves the right to award the work to one or more bidders, considering their technical and financial capacity

OR to reject any or all tenders or accept any tender without assigning any reason thereof.

Seal and Signature of Contract Page 12 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Sr. No. Name of Line Work Description

1 66Kv Sardargadh – Sheradi, 66Kv Tender for Work of Mechanical Strengthening

Sheradi - Chauta and 66Kv Sardargadh - and Stub strengthening of 66Kv Sardargadh –

Pajod H-Frame Line Sheradi, 66Kv Sheradi - Chauta and 66Kv

Sardargadh - Pajod H-Frame Line under R&M

2026-27 With Buyback of OLM under

Manavadar AM Division of Junagadh Circle.

1. The Scope of the proposal shall be on the basis of a single Bidder’s responsibility, completely covering all the services

specified under the accompanying Technical Specifications.

2. The Bidder shall complete all the schedules & annexure in the Bid Proposal Sheets, technical Data Sheets and specified

elsewhere. The Scope of the proposal shall be on the basis of a single Bidder’s responsibility for a particular line completely

covering Tender for Work of Mechanical Strengthening and Stub strengthening of 66Kv Sardargadh – Sheradi, 66Kv

Sheradi - Chauta and 66Kv Sardargadh - Pajod H-Frame Line under R&M 2026-27 With Buyback of OLM under

Manavadar AM Division of Junagadh Circle specified under the accompanying Technical Specifications. It will include

among others as specified therein the following. a) Detailed Engineering. b) Insurance, Dismantling, Re-Stringing

mechanical strengthening of line. The above work shall be done as per GETCO’s approved drawing/ layout.

3. Necessary field quality plan of GETCO shall be implemented and necessary documentation shall also be maintained as per

GETCO’s norms and instruction of EIC. If required field quality plan shall be available at field offices.

4. During the work of erection of feeder bay/transformer bay safety check list shall be followed. Necessary check list will be

available at our field office.

5. Successful bidder has to appoint site Engineer to maintained site register & FQP as per ISO.

6. All work should be done accordingly to ISO & FQP and all require documents including Filled FQP, testing results etc. should

be submitted while handing over the completed work.

7. The quantity mentioned in price bid is tentative and may vary in actual work order.

1. The Contractor shall follow and comply with all GETCO Safety Rules, relevant provisions of applicable laws pertaining to the

safety of workmen, employees, plant and equipment as may be prescribed from time to time without any demur, protest or

contest or reservations. In case of any discrepancy between statutory requirement and GETCO Safety Rules referred above,

the latter shall be binding on the Contractor unless the statutory provisions are more stringent.

1. In case if any safety related fatal Elect. / Mech. accident occurred to any employee of agency or outsider due to

negligence or non-compliance of GETCO safety norms then in addition to the compensation and liability as per statutory

requirement, contractor / agency shall be penalized as under:

Sr. No Amount of Contract in Rs. Penalty amount per person

1 Up to 1 Lac Rs.5000/- plus GST as applicable

2 Above1 Lac to  10 Lacs Rs.25000/- plus GST as applicable

3 10 to  100 Lacs Rs.100,000/- plus GST as applicable

4 > 100 Lacs 1.0 % plus GST as applicable

1. The contractor shall inform concerned Ex. Engineer Const/TR in writing within 24 hours of fatal/Non-fatal accident

occurred to human being.

2. The GETCO investigating officer findings in to accident shall be final and binding to the contractor /Agency.

3. Safety Requirement:

i) Kick off Meeting exclusively for safety shall be done in each contract in presence of contractor’s site in charge and

supervisor. Safety document shall be handed over and vital safety norms and key points of safety related to project

shall be explained and recorded for commitment by erection contractor. Such records are mandatory for clearing first

ii) During site visit by GETCO official of Executive Engineer and above rank, the following checks during execution of work

shall be covered.

I. Safety equipment available and utilize.

Seal and Signature of Contract Page 13 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

(b) Safety belt.

(c) Safety shoes.

(d) Live line Voltage detector

II. Safety procedure adopted.

(a) Permit to work

(b) Earthing at the place of work.

(c) Adequate supervision.

III. T & P physical Check. (Healthiness and Quality)

(b) Wire rope and sling.

(c) Earthing rod

IV. If above-mentioned safety requirements found violated in any of the above three conditions shall attract

penalty of Rs.1000/- plus GST as applicable per occasion. (Max.Rs.3000/--for violation of three conditions)

V. During subsequent visit, if violation is found, then double penalty plus GST as applicable shall be deducted

from the bill of the Contractor/Agency.

4. The contractor will have to give indemnity bond & safety cum indemnity on stamp paper of Rs. 300/- to GETCO against any

possible claim of compensation for damage to contractor’s equipment or staff or any of third parties during the execution

WORK & SAFETY REGULATIONS

1. The contractor shall ensure proper safety of all the workmen, materials, equipment & plant & belonging to him or to GETCO

or to others, working at the site. The contractor shall also be responsible for provision of all safety notices and safety

equipment required both by the relevant legislations and Engineer, as he may deem necessary.

2. Contractor has to provide ISI marked ELCB / MCB having sufficient capacity of standard make at point of supply.

3. All equipment used in construction and erection by contractor shall meet Indian/International Standards and where such

standards do not exist, the contractor shall ensure these to be absolutely safe. All equipment shall be strictly operated and

maintained by the contractor in accordance with manufacturer’s operation manual and safety instructions and as per

guidelines/ rules of GETCO in this regard.

4. Periodical examinations and all tests for all lifting/ hoisting equipment & tackles shall be carried – out in accordance with

the relevant provisions of Factories Act 1948, Indian Electricity Act 1910 and associated Laws/Rules in force from time to

time. A register of such examinations and tests shall be properly maintained by the contractor and will be promptly produces

as and when desired by Engineer or by the person authorized.

5. The contractor shall provide suitable safety equipment of prescribed standard to all employees and workmen according to

6. The contractor shall provide safe working conditions to all workmen and employees at the site including safe means of

access, railings, stairs, ladders, scaffoldings etc. the scaffoldings shall be erected under the control and supervision of an

experienced and competent person. The contractor only shall use good and standard quality of material.

7. The contractor shall not interfere or disturb electric fuses, wiring and other electrical equipment belonging to the owner /

other contractors under any circumstances, whatsoever, unless expressly permitted in writing to handle such fuses, wiring

or electrical equipment.

8. Before the contractor connects any electrical appliances to any plug or socket belonging to the other contractor or owner,

a. Satisfy the Engineer that the appliance is in good working condition;

b. Inform the Engineer of the max. current rating & voltage of the appliances;

c. Obtain permission of the Engineer detailing the sockets to which the appliances may be connected.

9. The Engineer will not grant permission to connect until he is satisfied that;

a. The appliance is in good condition and is fitted with suitable plug

b. The appliance is fitted with a suitable cable having two earth conductors, ones of which shall be an earthed metal

sheath surrounding the cores.

10. No electric cable in use by the contractor/ Owner will be disturbed without prior permission. No weight of any description

will be imposed on any cable and no ladder or similar equipment will rest against or attached to it.

11. No repair work shall be carried out on any live equipment. The equipment must be declared safe by the Engineer and a

permit to work shall be issued by the Engineer before any repair work is carried out by the contractor. While working on

electric lines/ equipment, whether live or dead, suitable type and sufficiently quantity of tools will have to he provided by

the contractor to electricians/ workmen/ officers.

12. In case any accident occurs during the construction/ erection or other associated activities undertaken by the contractor

thereby causing any minor or major fatal injury to his employees due to any reason, whatsoever, it shall be the responsibility

of the contractor provide medical facility / treatment & to promptly inform the same to the Engineer in prescribed form and

to also to all the authorities envisaged under the applicable laws.

13. The Engineer shall have the right at his sole discretion to stop the work, if in his opinion the work is being carried out in

such a way that it may cause accidents and endanger the safety of the persons and/or property and/or equipment. In such

cases, the contractor shall be informed in writing about the nature of hazards and possible injury/ accident and he shall

comply to remove shortcomings promptly. The contractor after stopping the specific work can, if felt necessary, appeal

against the order of stoppage of work to the Engineer within 3 days of such stoppage of work and decision of the Engineer

in this respect shall be conclusive and binding on the contractor.

Seal and Signature of Contract Page 14 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

14. The contractor shall not be entitled for any damages/ compensation for stoppage of work due to safety reasons and the

period of such stoppage of work will not be taken as an extension of time for completion of work and will not be the ground

for waiver of levy of liquidated damages.

15. it is mandatory for the contractor to observe during the execution of the works, requirements of safety rules which would

generally include but not limited to following;

a. Each employee shall be provided with initial indoctrination regarding safety by the contractor, so as to enable him

to conduct his work in a safe manner.

b. No employee shall be given a new assignment of work unfamiliar to him without proper introduction as to the

hazards incident thereto, both himself & his fellow employees.

c. Employee must not leave naked fires unattended, smoking shall not be permitted around fire prone areas and

adequate fire fighting equipment shall be provided at crucial location.

d. There shall be a suitable arrangement at every work site for rendering prompt and sufficient first aid to the injured.

e. Requirements of ventilation in underwater working to licensed and experienced divers, use of gumboots for

working in slushy or in inundated conditions are essential requirements to be fulfilled.

16. The contractor shall follow and comply with all GETCO safety Rules, relevant provisions of applicable laws pertaining to the

safety of workmen, employees, plant and equipment as may be prescribed from time to time without any demur, protest or

contest or reservations. In case of any discrepancy between statutory requirement and GETCO safety rules referred above

the latter shall be binding on the contractor unless the statutory provisions are more stringent.

a. Fatal injury or accident Rs. 1,00,000/- per These are applicable

Causing death person plus GST as applicable for death

b. Major injuries or accident causing Rs. 20,000/- injury to any

25% or more permanent disablement per person person,

To workmen or employees plus GST as applicable

Permanent disablement shall have same meaning as indicated in workmen’s compensation Act. The compensation

mentioned above shall be in addition to the compensation payable to the workmen/ employees under the relevant

provisions of the laws as applicable from time to time. In case the owner is made to pay such compensation then the

contractor is liable to reimburse the owner such amount in addition to the compensation indicated above.

OUR ENDEVOUR - Safety a habit

To create environment where Business Confidence is built through Best Business Practices and is fostered in an

atmosphere of trust and respect between providers of goods and services and their users for the ultimate benefit of

society a the nation, safety guidelines are agreed upon by the agency as under.

Safety is our prime concern and zero accident is our goal. In order to prevent the accident, while execution of works in

indoor and outdoor systems of GETCO, the following guideline and preventive measures are identified.

Indoor safety precaution Outdoor safety precaution

The method of work required T&P and Man power The method of work required T&P and Man power should be

should be discussed between GETCO supervisor, discussed between GETCO supervisor, contractor’s

contractor’s supervisor and gang leaders. supervisor and gang leaders.

Prior to execution of work a joint survey Must be Prior to execution of work a joint survey

conducted by GETCO supervisor and contractor’s mustbeconductedbyGETCOsupervisor,contractor’ssuperviso

supervisor for risk assessment. randDISCOMlinemaninordertoidentifythefollowing:

• Clearly identify the work location, to a. HT/LT line or tap line crossing under

distinguish between the equipment that is Each span of line of the work.

dead and other equipment/part that may b. Isolation point of each line crossing.

be live. c. Each line crossing & isolation point under each span

• Disconnect equipment from supply. must be discussed and noted in maintenance register

• Protect against other live parts.

• Take special precautions when close to bare

conductors/ Busbar.

Seal and Signature of Contract Page 15 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Following safety guidelines are mandatory Contractor’s supervisor and GETCO Supervisor must

For all contractors operating in GETCO premises for ensure all isolations physically with adequate earthing

Electrical, non-electrical & civil works. technically prior to give clearance to gang leader for taking

1. The contractors must provide advance

planning of work to concerned in-

charge of substation in writing.

2. Before starting any work whether While execution of stringing work, the identified line crossing

switchyard, “permit to allow to work” must be isolated /de-energized and written clearance should

must be taken from control room in- be obtained from concerned DISCOM supervisor.

3. Utilizing Electrical / non-electrical The isolation of Tap line must be physically seen and verified

equipments, safety rules must be by Contractor and GETCO supervisor.

4. If the work is to be carried out on At D.O. fuse junction contractors person should be posted to

Sunday or public holiday, the necessary ensure that no person restore D.O. supply while work is

permission must be taken in advance, under execution

requesting in writing.

5. Unwanted person including children of Contractor’s supervisor must ensure that concern officer take

labours will not be allowed at working LCP for EHV line and power line crossing.

site/ in the switchyard and in the

prohibited area.

6. Any electrical work or electrical

connections to equipment for any other

work must be carried out by certified

electrician/wiremen with adequate size of

wire through MCB as per I.E. Rule.

- Live penal area / bus bar must be isolated and

sealed / bifurcated with red colour tape for

visible warning.

- Display Board must hang on LCP panel.

- Transformer must be switched off

whenever and wherever contractor and line workers

are not satisfied with isolation, earthing or any

equipment performance of GETCO, it will be pointed

out and work shall begin only after resolution.

Contractor shall not take up job in absence of GETCO

authorized person. All wire temporary connection &

material whenever erection activity has any connection

and disconnection work of bus bar, string bus.

All workers / labour of contractor & supervisors must All workers / labour of contractor & supervisors must use

use personal protective equipment (PPE) during the personal protective equipment (PPE) during the work like

work like gloves, safety belt, Safety shoes, Helmet, gloves, safety belt, Safety shoes, Helmet, earthing rods, Live

earthing rods, etc, duly approved by GETCO. line detector etc, duly approved by GETCO.

The local earthing must be done at the place of work The local earthing must be done at the place of work before

before execution of any work. execution of any work.

11kVbreakerinpanel must be switched off and racked Circuit breaker opening is not an isolation and isolator on

out only after ensuring no voltage in breaker and either side must be opened. No work during rains and cloudy

without door opening. weather condition.

Transmission line activities.

1) Used of Voltage detector to ensure

2) Earthing at three point, local, left &

right side of bus bar / string bus.

3) Match line colour code with colour of wristband.

Seal and Signature of Contract Page 16 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Local earthing of electrical equipments like filter M/c,

welding machine, testing kits etc. is must.

Crane shall only be used for material handling and erection.

Working platform shall only be used for work in switchyard.

GENERAL COMMERCIAL CONDITIONS

The Gujarat Energy Transmission Corporation Ltd., Junagadh hereinafter called ‘GETCO’/ ‘OWNER’ intends to receive bids for

“Tender for Work of Mechanical Strengthening and Stub strengthening of 66Kv Sardargadh – Sheradi, 66Kv Sheradi - Chauta

and 66Kv Sardargadh - Pajod H-Frame Line under R&M 2026-27 With Buyback of OLM under Manavadar AM Division of

Junagadh Circle. Detailed in the accompanying specifications in accordance with Terms and Conditions herein. The bids shall be

prepared and furnished as per these instructions.

1. The validity of tender is 180 days (AS PER PARTICULAR TENDER REQUIREMENT) from the date of opening of technical bid

2. Earnest Money Deposit :

A. Bidders are requested to pay an earnest money deposit by RTGS/NEFT/Online only for the amount as specified in the

tender notice. Payment of EMD in form of Cheque or any other form shall not be accepted.

B. The EMD shall be submitted along with submission of Technical bid only.

C. Tenders no accompanied by EMD shall be rejected.

D. If during the tender validity period, i.e. 180 days, the tenderer withdraws his tender, the EMD shall be forfeited and the

tenderer may be disqualified from tendering for future works of GETCO.

E. The EMD will be returned promptly to the unsuccessful tenderer. The EMD will be returned to the successful tenderer

after he furnishes the Security Deposit for performance and duly enters into the contract. If he fails to furnish the SD

or to execute the contract for the work offered to him, his EMD shall be forfeited and the tenderer may be disqualified

from tendering for further works for GETCO.

3. All commercial terms and conditions except rates shall be indicated in the technical & commercial bid only.

4. The tenderers shall specifically note that the Tenders are invited on percentage basis only.

5. The tenderers will ensure submission of the Tenders duly filled in before the due date and time.

6. Security deposit: -

The contractor will have to pay the Security Deposit at 5% of the order value by demand draft / in the name of ‘GUJARAT

ENERGY TRANSMISSION CORPORATION LTD/ PAYABLE AT Junagadh, A/c. name of bidder’ upon placement of the LOI

within 10 days. Alternatively you may pay the entire S.D. in the form of B.G. in case S.D value is more than Rs. one lakh as

per approved format of the GETCO issued by Nationalized/Scheduled Bank. The security deposit will be refunded only after

the completion of guarantee period of 1 year of work done or finalization of final bill whichever is later.

(A) Guarantees issued by following banks will be accepted as SD on permanent basis:

i. All Nationalized Banks.

(B) Guarantees issued by following Banks will be accepted as SD for the period up to 31.03.2027. The validity cut-off

date in GR is with respect to date of issue of Bank Guarantee irrespective of date of termination of Bank Guarantee.

2. AU Small Finance Bank

3. Bandhan Bank

4. City Union Bank

6. DBS Bank India Limited

8. Dhanlaxmi Bank

9. Equitas Small Finance Bank

10. FEDERAL Bank

15. IDFC First Bank

16. IndusInd Bank

17. Jammu and Kashmir Bank

18. Jana Small Finance Bank

19. Karnataka Bank

20. Karur Vysya Bank

21. Kotak Mahindra Bank

Seal and Signature of Contract Page 17 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

23. South Indian Bank

24. Standard Chartered Bank

25. Tamilnad Mercantile Bank

26. Ujjivan Small Finance Bank

28. Ahmedabad Mercantile Co-Op Bank

29. Nutan Nagrik Sahkari Bank Ltd.

30. Rajkot Nagrik Sahkari Bank Ltd

31. Saraswat Co-Operative Bank Ltd

32. SBPP Co-operative Bank Ltd.

33. SVC Co-Operative Bank Ltd.

34. The Cosmo Co-Op Bank Ltd.

35. The Gujarat State Co-Operative Bank

36. The Surat District Co-Operative Bank

37. The Surat People’s Co-Op. Bank Ltd

38. The Baroda CentraI Co-operative Bank

39. The Panchmahal District Co-Operative Bank

40. The Kalupur Commercial Co-Op. Bank

41. The Rajkot Commercial Co-operative Bank

42. The Banaskantha Mercanttile Co-op. Bank

43. Gujarat Gramin Bank

Bank Guarantee of other than above mentioned banks towards, Performance Bank Guarantee for Supply, Erection &

Warranty will not be acceptable.

7. Contract Period :-

The time allowed for completion the work is 09 Months (AS PER PARTICULAR TENDER REQUIREMENT) from the date of

the commencement of the work, failing which the penalty ½% per week or part thereof plus GST as applicable on delayed

portion of work and / or supply value subject to ceiling of 10% of the total contract value will be imposed.

8. The time limit for the work may be reduced and contractor should make all his efforts to complete the work within stipulated

time limit as may be given by the Engineer in charge depending upon emergency of work, GETCO reserves the right to reduce

the time limit without giving any notice.

9. WELFARE CESS:-

1. As per the Welfare Cess Act, the welfare cess @ 1% is applicable on supply and erection items for supply, erection,

testing & commissioning of substation, transmission lines, EPC/Turnkey projects, and civil works.

2. Contractor shall get registered under Welfare Cess Act before commencement of work in required head as per nature

of work. Office of the Factory Inspector is authorized at present as a registering authority.

3. GETCO shall pay the welfare cess by way of reimbursing to contractors on production of documentary evidence of

payment. Registration charges will not be reimbursed.

4. The contracts for which supply or part supply of material are in the scope of GETCO, then contractors shall deposit

welfare cess on estimated cost of supplied items to GETCO on progressive basis of utilization. As this part of welfare

cess is on GETCO account, the same shall be reimbursed to the contractor on receipt of request letter along with

documentary evidence of payment. For calculation of welfare cess on supply part, valuation as per MR shall be taken

and informed to the contractor for payment. This will be over and above the A/T value. The modality of payment/

reimbursement of welfare cess will be as under.

5. On receipt of A/T, the contractor / bidder will get them registered under Welfare Cess Act and submit the documentary

evidence to the concern office. Copy of Registration certificate shall be submitted before submission of 1st RA bill

6. Before release of payment of first R.A.Bill, the contractor has to submit the documentary evidence of registration. Only

thereafter, the bill will be processed for payment.

7. Before release of payment of subsequent R.A.Bills, the contractor has to submit the documentary evidence of payment

of welfare cess of previous R.A.Bill.

8. The welfare cess shall be reimbursed to the contractor on submission of copy of documentary evidence of payment by

observing due formalities.

10. GST Registration on GETCO’s web portal:

The Bidder should have to take registration under the “GOODS AND SERVICE TAX (GST)”. Bidder has to register online in given

link before bidding. Link for the same is www.getcogujarat.com/gst/ The certified Xerox copy of such registration shall have to

be submitted along with the bid by the bidder.

On forfeiture of EMD, SD or guarantee under the terms and condition of this tender, applicable GST will also be recovered from

the bidder/ contractor and GETCO reserves all rights of such recovery of such forfeited amount along with GST

“Supplier contractor should charge GST in Invoice at the rate as agreed to / mentioned in acceptance of tender only and any deviation

in the same shall not be accepted. Further, any additional liability of GST (later on due to wrong mentioning of GST rate, mis-

interpretation of HSN/SAC Code etc.) over and above as charged in the invoice shall be borne by the supplier /Contractor. However,

Seal and Signature of Contract Page 18 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

any refund received by the supplier / contractor on account of GST Charged from the company ; such refund shall have to be passed

on to the company , along with interest needs to be passed on suo-moto by the supplier contractor.

Further the Company has a right to recover the amount of GST along with penal interest at the of 15% per annum if GST charged is

not paid /short paid to the government or fail to upload the details or uploads inaccurate particular on GSTIN portal by the Supplier

/Contractor within the stipulated time limit.

In case, GOVT. revise the rate of GST rate /code during the tenure of the contract the provision of statutory variation clause shall

Final bill shall be passed & paid & SD shall be released only if contractor has duly discharged its GST liability related to

the contract and submit C.A. certificate and under taking.

12. STATUTORY VARIATION:

Any statutory increase or decrease in the taxes and duties including GST and Cess as applicable or in the event of introduction

of new tax/cess or cessation of existing tax/cess subsequent to suppliers offer, if it takes place within the original contractual

delivery date will be to GETCO’s account subject to the claim being supported by documentary evidence. However, if any

decrease takes place after the contractual delivery date, the advantage will have to be passed on to GETCO.

Statutory Variation clause will not be applicable in case of Supplier /Contractor has opted for Composition Scheme under GST.

13. The contractor will have to give indemnity bond on Non-Judicial Stamp paper of value Rs. 300/-to GETCO for material as per

attached format. The cost of stamp paper will be born by the contractor.

14. Also the successful bidder will have to execute Agreement on stamp paper of value Rs.300/- at our Circle office Junagadh

before commencement of works as per GETCO’s prescribed Performa. The cost of stamp paper will be born by the contractor.

15. The contractor will have to give safety cum indemnity on Non-Judicial Stamp paper of value Rs. 300/- to GETCO against any

possible claim of compensation for damage to contractor’s staff or any of third party during the execution of work. The cost

of stamp paper will be born by the contractor.

16. Also the successful bidder will have to execute Agreement on stamp paper of value Rs.300/- at our Transmission Circle,

GETCO, Junagadh before commencement of works as per GETCO’s prescribed Performa. The cost of stamp paper will be borne

by the contractor.

17. Guarantee: - It is the responsibility of the contractor to handover the complete work free of all defects. If within a period of

One (1) year from the date of handing over the work it is noticed that any defects occurs due to bad workmanship, it is the

duty of the contractor to rectify / replace the same at his own cost. If within seven days from the date of receipt of such

notice, the contractor does not take up the work, same will be carried out at his risk and cost.

18. 10% retention money will be deducted from each R.A. Bills against material issued to contractor.

19. 10% amount of bill will be retained from each RA bill for the work executed after the scheduled date of completion and on

finalization of time limit extension by competent authority; this amount will be released after deducting amount towards the

time limit penalty if any.

20. As regard damage the materials, equipment and worker of the contractor, he himself will be responsible. If there is any

compensation to be paid in respect of “WORKMAN” compensation act of any other statutory provisions, the same will have

to be paid by the contractor direct. If he thinks fit he may take necessary insurance cover, at his cost.

21. The quantum of the work as mentioned in estimate/ schedule –‘B’ is tentative and it can be varied or differed as per site

condition. The payment shall be made only on actual work executed or order quantity, whichever is less.

22. The tenderer will be abided by and fulfill all the terms and provisions of the “Tender & Contract” for works as applicable and

incase of any default there to the GETCO shall forfeit the S.D. or any other action as may be decided by Superintending

Engineer (TR), GETCO, Junagadh.

23. The cost of damages, if any will be recovered from the Contractor’s bill. The assessment of which will be done by field

Engineer at his sole discretion and his decision shall be binding to the contractor and shall be considered as final and

unchallengeable.

24. GETCO shall deduct the Income-Tax and other taxes as per prevailing rules from each and every bill.

25. No part rate or reduced rate shall be allowed in final bill.

26. The contractor has to follow all labour laws, safety rules and regulations. The GETCO does not take any responsibility in case

of accident or injury to the workers. The safety/ security of men, materials and equipments shall be sole responsibility of the

27. The compliances of all Central/ State Govt. rules, safety and insurance rules etc. and that of local body, is a must condition for

28. The Gujarat Energy Transmission Corporation Limited does not bind itself to accept the lowest or any tender. GETCO reserves

the right to reject any or all tender without signing any reasons whatsoever.

29. The erection work should be commenced immediately from the date of receipt of instructions from office and should be

completed within thereafter.

30. The tender includes all minor accessories and items of work which are not have been specifically mentioned in the

specification schedule etc. but are essential for completion of work. The contractor will not be eligible for any extra payment

in respect of such minor accessories and items of work.

31. Tenderer will be qualified only who have submitted all the required documents as mentioned in tender notice.

32. No higher rate or revised rate will be applicable for the work, if work is held up/ closed due to whatever so reasons.

33. GETCO will not pay any idle charge for any site conditions or any circumstances.

34. In case of any dispute/ doubt, the decision of Superintending Engineer (TR), GETCO, Junagadh. shall be unchallengeable,

final and binding to the contractor.

Seal and Signature of Contract Page 19 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

35. The contractor has to remain in close day to day contact with Engineer in charge of work i.e.DE S/s /Line concern who will

issue detailed instruction for the commencement of the work.

36. Contractor will abide by and fulfill all the terms and conditions and general terms and condition of the contract for works

available in the office.

37. All other general terms and conditions as prevailing in the GETCO shall be applicable to the contract.

38. The contractor will have to complete entire job as per directive and instruction of Engineer in charge. If he fails to do so entire

work will be carried out at contractor’s risk and cost.

39. The contractor must engage sufficient knowledgeable persons round the clock, exclusively for oil filter machine provided by

GETCO for oil filtration work. No loss of oil should occur and in case if occurs; its cost will be recovered from contractor’s bill.

The contractor has to apply sufficient nos. of cycles for oil filtration works as decided by the Engineer in charge.

40. The tender shall be issued to only the experienced contractor who has completed such job of similar nature and magnitude

satisfactorily in time. However, filling of on line tender, does not qualifies the tenderer to offer the bid.

41. Tender offer without payment of EMD required certificate, documents, list of tools, tackles, equipments etc. required for

execution of job will be out rightly rejected without assigning any reason thereof and decision of Superintending Engineer

GETCO,Junagadh will be final and unchallengeable.

42. The Contractor will be governed by The GETCO’s general conditions of works contract. The Booklet will be available in the

concerned office in any working days. In the event of placing order, the contractor will have to sign this booklet along with

other document and agreement. All the usual terms and conditions of the GETCO, through the same might have not been

mentioned in this specification or contractor booklet will applicable to this contract, and the decision of the Superintending

Engineer shall be binding on the contractor.

43. After completion of the work, all the surplus materials issued by the GETCO shall be returned by you to the respective center

of the GETCO as per instruction of Engineer in charge at your cost.

44. Specification in any items mentioned in tender are subject to change without any prior notice and binding to the contractor.

45. If the work is required to be carried out during fix outage then the contractor has to deploy adequate man power, material,

tools etc. well in advance and has to complete the entire work during this specific outage period only, failing to which GETCO

shall be at liberally to deduct the amount of revenue loss due to prolong outage.

46. If required by GETCO you shall have to provide free to and fro traveling facility to our Junior Engineer or Technical staff for

47. The contractor shall not refuse to execute the work order at any time and it will be his sole responsibility to execute and

complete this work as per the instruction of Engineer in charge.

48. For shortages of any materials issued by the GETCO for the work, recovery shall be made from you, on the basis of prices of

the materials (prevailing on the date of settlement of materials account) plus 15% supervision charges.

49. No subcontractor, Power of Attorney shall be allowed without prior approval of competent authority.

50. All the materials issued by GETCO shall be transported to the work site on same day and to be preserved in safe custody

failing to which GETCO shall initiate legal action if required. Similarly as per instruction of Engineer in charge, you have to

credit the material at GETCO store without any loss of time failing to which GETCO shall initiate legal action if required.

51. No tools, tackles, manpower, crane facilities etc. will be provided by the GETCO.

52. The contractor has to submit the list of tools, tackles, equipments with him along with his tender offer. The tender without

this list and other required documents (as mentioned above herein the tender) should be rejected out rightly.

53. The bidder shall specifically note that GETCO will not pay any extra amount towards any type of claim except for the

description indicated in Schedule – ‘B’. The party has to carry out all other/ additional required activities/ works as directed

by Engineer in charge which is not mentioned in Schedule but required to be completed as per site condition and for this

work no extra payment shall be made by GETCO.

a) The interpretation of specifications doubts etc.:- In case of any doubts about what is mentioned in specification or

schedule or elsewhere, the tenderer should get all doubts cleared from the Department in writing and in advance of filling

in the Tender. In case of difference of opinion about interpretation of specification etc the decision of Superintending

Engineer, Transmission Circle, GETCO, Junagadh will be final and shall be binding to the contractor.

b) Accounts of Materials issued:- The contractor shall have to maintain accurate day to day and item wise account of use of

issued materials which shall be got checked from time to time by the representative of the GETCO. The contractor will be

responsible for custody and preserving the issued materials till the work is handed over by the contractor after completion.

c) The contractor has to maintain site register, covering all the daily details of material receipt and utilization, progress of work

etc. This register shall be checked and signed by Engineer in charge and Executive Engineer during the site visit. Any bill

without site register shall not be passed.

55. The contractor shall be responsible for breakages, losses and theft of material during transit or erection after the materials

issued from the stores till the completion of work and is taken over by the GETCO.

56. The contractor will be responsible for the loss, distribution of deterioration of the materials, stores or articles supplied to

him by the GETCO, even if such a loss distribution or deterioration has occurred under any circumstances whatsoever

beyond his control as if the materials, stores or articles so supplied were his property.

57. The contractor shall co-operate with the GETCO in recording measurement etc. as expeditiously as possible and he shall fulfill

all the requirements which are necessary to finalize the accounts on the basis of its records and pay him such amount as if

found due to him together with the amount of security deposit. If any remaining payable to him after deduction there from

the amount due by him to the GETCO. The GETCO shall not entertain further claim from thereafter.

58. The competent authority can delete any item in schedule of the tender, if he feels that the rate quoted by the contractor for

that item is abnormally high when compared to the estimated rates.

Seal and Signature of Contract Page 20 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

59. Delivery of Material: - All material/ equipment required for this work as per schedule shall be delivered at any store centers

of GETCO jurisdiction and contractor has to take delivery from these stores or at his own cost only.

60. You will ensure that completion of erection work i.e. all works connected with substation having been completed correctly

as per Indian Electricity Rules & procedure. Any extra cost involved due to incompleteness of work or bad workmanship

found out Subsequently shall be set right forth with by you at your own cost.

61. Billing and Payment Terms

(a) The contractor shall have to submit the RA bill of order to the concerned Deputy Engineer of sub-division of

concerned division for payment once in a month period.

(b) 90% payment of amount claimed covering various activities such as excavation, foundation, erection, earthing,

stringing of bus bar and earth wire including insulator hoisting works against R.A. bills duly certified by EIC

within 60 days from the date of R.A. bill.

(c) Balance 10% of erection value shall be paid within 60 days against completion of work only after settlement of

material account statement of items supplied, used, erected and successful commissioning of Sub-Station line the

same amount will be release in final bill only and payment will be made only after passing of final bill.

(d) If net payable amount is more than Rs 10.0 Lacs, payment will be released from circle office/corporate office.

(e) The payment will be released within 60 days. However, in case of any delay due to any eventuality no interest

charges shall be paid.

(f) All the bills in accordance with the above clauses must be submitted with the following information:

1) Item wise work done during billing period.

2) Item wise cumulative work done.

3) Account for material consumed and balance stock.

4) For non-submission or part submission of above information, an additional 5% amount of the

respective RA bill shall be withheld and shall only be released at the time of final bill.

(g) Any outstanding recoveries of GETCO for any other than this transaction or anywhere done in GETCO can be recovered

from this contractor’s/ supplier’s payment which is authentically approved by competent authority.

62. PROTECTION OF PROPERTY AND CONTRACTOR’S LIABILITY

The Contractor shall be responsible for any damage resulting from his operations. He shall also be responsible for protection

of all persons including members of public and employees of the Owner and the employees of other Contractors and Sub-

Contractors and all public and private property.

63. Quantities given in the Schedule of erection in price Bid are to be executed by the contractor at the rates accepted by the

Board in the A/T. In case of any deviation in tower quantity / type of tower / length of line, excavation / concreting resulting

into an increase in which event the field officer shall obtain prior approval of the Head Office and excess quantity shall be

paid only at the accepted rate of the A / T. No any Excess work / amount to be executed without prior approval of competent

64. The erection work beyond contractual ceiling amount shall be done only after approval from the GETCO authority.

65. CONTRACTOR’S SITE ESTABLISHMENT

The Contractor shall at all times keep posted an authorized representative for the purpose of the Contract. Any written order

or instruction of the Engineer or his duly authorized representative shall be communicated to the said authorized resident

representative of the Contractor and the representative shall be available at a stated address for this purpose.

66. CO-OPERATION WITH OTHER CONTRACTORS

Contractor shall co-operate with all other Contractors or tradesmen of the Owner, who may be performing other works on

behalf of the Owner and the workmen who may be employed by the Owner and doing work in the vicinity of the Works under

the Contract. The Contractor shall also so arrange to perform his work as to minimize, to the maximum extent possible,

interference with the work of other Contractors and their workmen. Any injury or damage that may be sustained by the

employees of the other Contractors and the Owner, due to the Contractor’s work shall promptly be made good at the

Contractor’s own expense.

67. PROTECTION OF WORK

The Contractor shall have total responsibility for protecting his works till it is finally taken over by the Engineer. No claim will

be entertained by the Owner or by the Engineer for any damage or loss to the Contractor’s works and the Contractor shall

be responsible for complete restoration of the damaged works to original conditions to comply with the specification and

SPECIAL COMMERCIAL CONDITION FOR TENDERER

1. TAKING DELIVARY AND INSURANCE: -

1.1 The contractor has keep S/S materials in safe custody and transport to the respective sites and will be responsible for any

damages to or loss of all materials at any stage during transportation or erection or taking over of the line by GETCO.

1.2 The Contractor has to open site store and ensure for safe custody of all the stored materials at his own cost.

1.3 The Contractor shall have total responsibility for the entire materials stored loose, semi assembled and/or erected by him

at site in his custody. The Contractor shall make suitable security arrangements is at own cost to ensure the protection of

all materials, equipments and works from theft, fire pilferage and any other damages and loss, it shall be the responsibility

of the contractor to arrange for security till the works are finally taken over by the Corporation.

2 STORAGE-CUM-ERECTION-INSURANCE: -

Seal and Signature of Contract Page 21 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

2.1 The contractor shall take suitable storage-cum-erection insurance cover at his cost to the extent of 100% cost of sub-station/line

materials, which are required to complete the sub-station /line. Bidder shall have to take the comprehensive Marine cum

Erection (MCE) insurance policy against any loss, damage, theft, pilferage, fire etc. for the complete period of storage, fire etc.

for the complete period of storage, erection and commissioning up to the time of taking cover of the sub-station/line by GETCO.

The contractor shall deal directly and pursue the claim with the Insurance Company and shall be responsible in regard to

maintenance of all insurance coverage as well as for settlement of claim. The proof of insurance policy taken by the successful

contractor shall be furnished/submitted to Engineer-in-charge of GETCO.

No material shall be issued to bidder/erection agency in absence of such insurance policy. The risk shall be covered for

lifting of materials from store to final handing over to GETCO. Further in absence of the above insurance policy, R.A.

bill payment will be withheld.

2.2 In the event of any damage, theft, loss, pilferage, fire etc, Contractor will be responsible to lodge, pursue and settle all the claims

with the insurance company for all items, materials and the corporation shall be kept informed about it. Contractor shall replace

the lost/damaged materials/items promptly irrespective of the settlement of the claims by underwriter and ensure that the

work progress is as per agreed schedule. The loss, if any, such replacement will have to be borne by the contractor and GETCO

will not entertain any claim/representation in this regard. However it will be contractor’s responsibility to insure the entire

project till the line / sub-station or any other project / works is taken over by the GETCO.

2.3 The estimated cost of line material for insurance is Rs. 6 lacs or (As per instruction of EIC)

3.1 The Contractor at his cost shall arrange, secure and maintain all insurance as may be pertinent to the Works and obligatory

in terms of law to protect his interest and interests of the Owner against all perils detailed herein. The form and the limit of

such insurance as defined herein together with the under-writer in each case shall be acceptable to the Owner. However,

irrespective of such acceptance, the responsibility to maintain adequate insurance coverage at all time during the period of

Contract shall be of Contractor alone. The Contractor’s failure in this regard shall not relieve him of any of his contractual

responsibilities and obligations. The insurance covers to be taken by the Contractor shall be in the joint name of the Owner

and the Contractor. The Contractor shall, however, be authorized to deal directly with Insurance Company or Companies

and shall be responsible in regard to maintenance of all insurance covers. Further the insurance should be in freely

convertible currency.

3.2 Any loss or damage to the material during handling, transportation, storage, erection, and all activities to be performed till

the successful completion of commissioning of the line shall be to the account of the Contractor. The Contractor shall be

responsible for preference of all claims and make good the damages or loss by way of repairs and/or replacement of the

equipment, damaged or lost. The transfer of title shall not in any way relieve the Contractor of the above responsibilities

during the period of Contract. The Contractor shall provide the Owner with copy of all insurance policies and documents

taken out by him in pursuance of the Contract. Such copies of documents shall be submitted to the Owner immediately after

such insurance coverage. The Contractor shall also inform the Owner in writing at least sixty (60) days in advance regarding

the expiry/cancellation and/or change in any of such documents and ensure revalidation, renewal etc., as may be necessary

3.3 The perils required to be covered under the insurance shall include, but not be limited to fire and allied risks, miscellaneous

accidents (erection risks) workman compensation risks, loss or damage in transit, theft, pilferage, riot and strikes and

malicious damages, civil commotion, weather conditions, accidents of all kinds, etc. The scope of such insurance shall be

adequate to cover the replacement/reinstatement cost of the equipment for all risks up to and including delivery of goods

and other costs till the equipment is delivered at Site. The insurance policies to be taken should be on replacement value

basis and/or incorporating escalation clause. Notwithstanding the extent of insurance cover and the amount of claim

available from the underwriters, the Contractor shall be liable to make good the full replacement/rectification value of all

equipment/materials and to ensure their availability as per project requirements.

3.4 Workmen’s Compensation Insurance

This insurance shall protect the Contractor against all claims applicable under the Workmen’s Compensation Act,

(Government of India). This policy shall also cover the Contractor against claims for injury, disability, disease or death of his

or his SubContractor’s employee, which for any reason are not covered under the Workmen’s Compensation Act, 1948. The

liabilities shall not be less than:

Workmen’s Compensation : As per statutory Provisions

Employee’s liability : As per statutory Provisions

3.5 Comprehensive General Liability Insurance

The insurance shall protect the Contractor against all claims arising from injuries, disabilities, disease or death of members

of public or damage to property of others, due to any act of omission on the part of the Contractor, his agents, his employees,

his representatives and Sub-Contractors or from riots, strikes and civil commotion.

3.6 The hazards to be covered will pertain to all the works and areas where the Contractor, his agents and his employees have to

perform work pursuant to the Contract.

Seal and Signature of Contract Page 22 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

3.7 The above are only illustrative list of insurance covers normally required and it will be the responsibility of the Contractors to

maintain all necessary insurance coverage to the extent both in time and amount to take care of all his liabilities either direct

or indirect, in pursuance of the Contract.

4 PENALTY FOR DELAY:-

1. The bidder should note that the completion time allowed for carrying out the work should be strictly observed. Any delay

that may take place in supply and erection beyond contractual cutoff date stated as per stipulated delivery period shall be

subject to the penalty ½% per week or part thereof plus GST as applicable on delayed portion of work and / or supply value

subject to ceiling of 10% of the total contract value plus GST as applicable will be imposed.

2. In event of failure of the Contractor to pay the amount of Penalty as demanded, the Owner shall be entitled to deduct the

amount of Penalty for delay from the amounts payable to the Contractors under any bills raised under this contract or any

other contract with the GUVNL and its Subsidiary Companies i.e. GETCO, GUVNL, GSECL, MGVCL, DGVCL, PGVCL UGVCL. It is

permissible for the Owner to adjust the amount of Penalty of delay against any Bank Guarantee furnished by the Contractor

under this contract or any other contract with GUVNL and/or its subsidiary companies.

3. If it is found that the work is unsatisfactory or not progressing as per the program / BARCHART / Target period, any action

taken by the GETCO, as may be deemed fit, to see that work is completed as required by the GETCO, would be at the risk and

cost of the contractor..

4. Any delay causing extension of outages shall be contractor’s responsibility and appropriate amount (in term of Rupees) as

decided by Ex. Engineer (AM), Manavadar shall be recovered from Contractor’s bill as a penalty.

Taxes and Duties:

3.5.1 As regards the income Tax, surcharge on income tax and any other corporate tax, Excluding GST and excluding welfare

cess at prevailing rate the owner shall not bear any tax liability whatsoever. The bidder shall be liable and responsible for payment

of such taxes as attracted under the provisions of the law.

3.5.2 Not withstanding the tax liabilities as per the sub-clause14.1 above the owner shall have the right to make deduction at

source from the amounts payable to the contractor in respect of Income Tax (on the cost of items of supply included in the works

contract) as may be mandatory in terms of the law. The owner shall not bear any liability in this regard but shall issue necessary

certificate in respect of such deduction made.

3.5.3 In case any tax or duty is newly introduced by the Government applicable for this contract with effect from the next

day of the date submission of the bid and if the contractor is required to pay additional tax or duty, then the owner shall

reimburse the contractor the additional tax or duty so paid by the contractor against submission by the

contractor of documentary evidence to the satisfaction of the owner. This provision will not be applicable to transaction

between the contractor and his sub-contractors. Besides the said statutory variation, no other statutory variation shall be

payable by the owner.

3.5.4 The owner’s liability for all taxes and duties under the contract shall be limited to those indicated by the Bidder in the

Sign & Seal of Contractor Page 8 Bid Proposal Sheets, subject to the statutory variations and variations as per Clause No. 14.3.

If the cost to the Contractor during the performance of the ‘Contract’ shall be increased or reduced by reasons of the

making, passing or promulgation of any law after the date of submission of bid or by any order, regulation or bye-law having

the force of law the amount of such increase or reduction shall be added to or deducted from the “Contract Price” as the

case may be for direct transactions between contactor & owner, and not for bought out items. It is the Bidders responsibility

to furnish details of taxes, duties, levies etc. applicable as on the date of submission of the bid.

3.5.5 No claim for any increase towards the statutory variation regarding enhancement of existing tax or duty or

introduction of a new tax or duty applicable shall be entertained by the Owner during the extended period of contract, if

any, provided the extension of the contract is required by causes attributable to the contractor.

35.6 The provision of statutory variation regarding enhancement of existing tax or duty or introduction of a new tax or duty

will be applicable only to the direct transaction between the contractor and the owner.

3.5.7 Before quoting, the bidder may ascertain from the concerned tax authorities of Government of Gujarat the applicability

of Work Contract Tax. Entry Tax, GST etc. in respect of this work and include the same in the quoted price. No separate

claim in this regard will be entertained by the Owner, as it is the responsibility of the Bidder to pay all these taxes.

In case, GOVT. revise the rate of GST rate /code during the tenure of the contract the provision of statutory variation clause shall

"RIGHTS OF THE OWNER:

Whenever any claim or claims for payment of a sum of money arises out of or under the contract against the Contractor, the

Owner shall be entitled to withhold and also have a lien to retain such sum or sums in whole or in port from the security, If

any, deposited by the Contractor and for the purpose aforesaid, the Owner shall be entitled to encash and withhold the

amount of Performance Bank Guarantee or other security, if any, furnished as the case may be. The Owner shall also have a

Seal and Signature of Contract Page 23 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

lien over the same pending finalization or adjudication of any such claim. In the event Of the security is insufficient to cover

the claimed amount or amounts, the Owner shall be entitled to withhold and have lien to retain to the extent of the such

claimed amount or amounts referred to above, from any sum or sums found payable or which at any time thereafter may

become payable to the Contractor under the same contract or any other contract with the Owner or GUVNL or its subsidiary

companies pending finalization or adjudication of any such claim.

Line in respect of Claims in other Contracts:

a) Any sum of money due and payable, to the Contractor (Including the security deposit) under

the contract may be withheld or retained by way of lien by the Owner against any of its claim in respect of payment of a sum

of money arising out of or under any other contract made by the Contractor with the Owner or GUVNL or any of its subsidiary

b) It is on agreed that the sum of money so withheld or retained under this clause by the Owner will be kept withheld or

retained as such by the Owner till its claim arising out of the same contract or any other contract is either mutually settled

or determined by the arbitrator or competent court, as the case may be, and the Contractor shall have no claim for interest

or damages whatsoever on this account or on any other ground in respect of any sum of money withheld or retained under

this clause and as may be duly notified to the Contractor.

This is put up herewith for perusal and approval so that above stated enabling clauses may be incorporated in the terms

and conditions of Tender / Contracts by our Procurement Department. Project Department, Transmission Department, R&M

Department and Civil department. Further, we may ask CE (Project) to instruct the field offices for incorporating the above

clauses in field tenders.

TERMS & CONDITIONS REGARDING INDUSTRIALLAWS AND OTHER RELATED MATTERS

1) Wages to be paid at time of payment etc. by the contractor.

a. The contractor shall pay minimum prevailing rates per day or as may be specified hereafter or rates fixed under the

minimum wages Act. Whichever is higher. The wages or very contract labour employed by him under this contact shall be

paid by him before the expiry of 7th day of the month in respective of which the wages are payable ( i.e. wages of a month

have to be paid by him in the first week of the next month). The payment shall be disbursed in the presence of management

representative during the working hours in factory premises and the contractor shall get the entries certified in the register

of wages by the representative of the GETCO. Any default will result in cancellation of contract forthwith or also the

contractor shall be paid punishable to the extent of Rs.100/- fine per each day.

b. The contractor shall give his telephone number and address to the GETCO so that in case of labour troubles etc. the

contractor can be contacted. The contractor shall arrange to have his office outside the factory premises and the contractor

shall keep himself present throughout the working hours.

(A) Person below the age of 18 years shall not be employed for the work.

(B) No. female worker shall be employed in the night shift between 7 p.m. to 6 a.m.

(C) Contractor shall maintain a valid labor license under the contract labour (Regulation and Abolition) Act for employing

necessary manpower to be required by him. In the absence of such license the contract shall be liable to be terminated

without assigning any reason thereof.

(D) The contractor shall at his own expenses comply with all labour laws and keep the GETCO indemnified in respective thereof.

Some of the major liabilities under various labour and industrial laws which the contractor shall comply with areas under

(i) Payment of contribution by way of employer’s contribution towards provident fund, family pension scheme, Deposit

linked insurance scheme, Administrative charge etc. at the rates make applicable from time to time by Government of

Gujarat/Government of India or other statutory authority.

(ii) Payment of deposit in respect of each contract labour at the rate as per admissible with the office of commissioner of

Labour as per the contract Labour (Regulation and abolition Act.).

(iii) License fee as prescribed under the contract labour (Regulation and abolition Act) and rules framed there under

depending upon the number of workmen employed by the contractor.

(iv) Paid leave facility and wages as per the provision of the factories Act at the rate of one day for every 20 days of working.

(v) Identify cards as prescribed under the factories Act with photo at fixe there to the same identification. Liabilities as per

industrial Disputes Act any payment to the contractor’s employees arising out of any claim or disputes under the

industrial Disputes Act, 1947 or any other labour laws.

(vi) Payment of compensation in case accidental inury.

(vii) Maternity leave as per the provisions of the maternity Benefit Act. The above are some of the major liabilities of the

contractor in addition to other liabilities. Prescribed under the various labour laws in force from time to time from

statutory authorities like State Government/ Government of India which the contractor shall have to comply with.

3) Provident fund & Family pension Scheme:-

The contractor shall submit along with his bill (month wise) a statement regarding deduction against employees

provident fund and family pension scheme in respective of each concerned employee, provident fund and family pension

scheme at the rate at admissible ( or at the rate made applicable by the Government from time to time ) of the wages.

Seal and Signature of Contract Page 24 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

The contractor’s contribution and his workers contribution towards provident fund and family pension scheme shall be

deposited by the contractor with concern regional Provident Fund Commissioner office.

4) Deposit Linked Insurance Scheme :-

The contractor shall have to deposit ½ % of the wage in respect of employees who is a member of the Provident Fund

as the contribution to the deposit.

Linked insurance Scheme with concern Regional Provident Fund Commissioner office.

(5) Administrative Charges:-

Administrative charges for maintaining provident fund A/C shall be deposited by the contractor with concern Regional

Provident Fund Commissioner office at the rates applicable.

(6) Paid Leave Facility:-

Paid leave facility at the rate of one day for every twenty days worked by the contract labour shall be provided by the

contractor to his workers. He shall maintain leave Records/leave cards for individual labourer which shall be duly

verified and approved/certified by the authorized officer of the GETCO.

(7) Workmen’s compensation fund & Employer’s Liability Insurance:-

The contractor shall cover all his employees under workmen’s compensation fund and under the liability insurance.

Insurance shall be affected for the entire contractor’s employee engaged in the performance of this contract. If any of the

work is subject the contractor shall require the sub-contractor to provide workmen’s compensation and employer’s

liability insurance for the latter’s employees unless such employees are covered under the contractor’s insurance.

(8) The contractor shall employ adequate number of experienced staff at site for dial supervision and for maintenance of

various register and records required under the law and contract No. payment for supervision shall be admissible.

(9) Contractor to Identify the GETCO:-

The contractor shall indemnify the GETCO and every member officer and employees of the GETCO also, engineering in

charge and his staff against all actions, proceeding, claims demands, costs and expenses which may be made against the

GETCO or Government for or in respective of performance of his obligation under the contract documents. The GETCO

shall not liable for or in respective of or in consequence of any accident or injury to any workman or other person in the

employment of the contractor or his sub-contractor and the contractor shall indemnify and keep indemnified the GETCO

against all such damage and compensation and against all claims, demands, proceedings costs, charges and expenses

whatever in respective thereof in relation thereto.

(10) The GETCO reserves the right to terminate this rate contract at any time during its tendency without giving notice of

termination or any reasons thereof.

(11) The GETCO will be entitled to deduct directly from the bills, to be paid to the contractor any sum or payable by you and

which sum/sums the GETCO is required to pay as principal employer on account of your default in respect of all liabilities

referred to in above clauses.

GENERAL TECHNICAL CONDITION:_

1. The erection work should be carried out according to the specification and as per instructions and programmed laid out by

the Engineer in-charge of the work.

2. The contractor should employee as Supervisor with sufficient qualification and experience who can supervise the execution

of work throughout. He should always be present on the site.

3. Cutting, bending, welding, brazing, wherever necessary is to be done by the contractor.

4. The contractor has to carry out all the works in accordance with revised and latest provision under I.E. Rules Act made there

under and as per instruction of Engineer in charge.

5. Contractor has to co-ordinate E.I.C. for planning of outage and work schedule thereof, so as to complete all the planned work

in outage. Contractor has to deploy adequate manpower accordingly.

6. In addition to the general of the construction particular, attention shall be paid to the final finish and every effort shall be

made to have the entire work contented with standard of workmanship by the contractor.

7. Electricity Rules: -All the works shall be carried out in accordance with latest rules under Electricity Act.

8. Testing: - Complete installation shall be put to the necessary test as required and shall be got approved by Government

Electrical Inspector.

9. CONTRACTOR’S MATERIALS BROUGHT TO SITE

a) The Contractor shall bring to Site all materials, including construction equipment, tools and tackles for the purpose of

the works under intimation to the Engineer. All such goods shall, from the time of their being brought vest in the Owner,

but may be used for the purpose of the works only and shall not on any account be removed or taken away by the

Contractor without the written permission of the Engineer. The Contractor shall nevertheless be solely liable and

responsible for any loss or destruction thereof and damage thereto.

b) After the completion of the Works, the Contractor shall remove from the Site under the direction of the Engineer the

materials such as construction equipment, erection tools and tackles, scaffolding etc. with the written permission of the

10. FIELD OFFICE RECORDS

The Contractor shall maintain up to date copies of all drawings, specifications and other Contract Documents and any other

supplementary data complete with all the latest revisions thereto. The Contractor shall also maintain in addition the

continuous record of all changes to the above Contract Documents, drawings, specifications, and supplementary data, etc.

effected at the field and on completion of his total assignment under the Contract shall incorporate all such changes on the

drawings and other Engineering data to indicate as installed conditions of the equipment furnished and erected under the

Contract. Such drawings and Engineering data shall be submitted to the Engineer in required number of copies.

Seal and Signature of Contract Page 25 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

11. Contractor shall purchase all brought out items as per schedule-B with taking prior approval from Executive Engineer (AM),

GETCO, Manavadar. Any item without approval shall not be permitted and GETCO shall not be responsible for accept such

12. DISCIPLINE OF WORKMEN

The Contractor shall adhere to the disciplinary procedure set by the Engineer in respect of his employees and workmen at

Site. The Engineer shall be at liberty to object to the presence of any representative or employee of the Contractor at the Site,

if in the opinion of the Engineer such employee has misconduct himself or is incompetent or negligent or otherwise

undesirable and then the Contractor shall remove such a person objected to and provide in his place a competent

13. CONTRACTOR’S FIELD OPERATION

1 The Contractor shall keep the Engineer informed in advance regarding his field activity plans and schedules for

carrying-out each part of the works. Any review of such plan or schedule or method of work by the Engineer shall

not relieve the Contractor of any of his responsibilities towards the field activities. Such reviews shall also not be

considered as an assumption of any risk or liability by the Engineer or the Owner or any of his representatives and

no claim of the Contractor will be entertained because of the failure or inefficiency of any such plan or schedule or

method of work reviewed. The Contractor shall be solely responsible for the safety, adequacy and efficiency of

plant and equipment and his erection methods.

2 The Contractor shall have the complete responsibility for the conditions of the Work-site including the safety of all persons

employed by him or his Sub–Contractor and all the properties under his custody during the performance of the work. This

requirement shall apply continuously till the completion of the Contract and shall not be limited to normal working hours.

14. PROGRESS REPORT

The Contractor shall furnish three (3) copies each to the Engineer of progress including if any, photographs of the work

done at Site. The monthly progress report detailing-out the progress achieved on all erection activities shall highlight

comparison to the schedules. The report shall also indicate the reasons for the variance between the scheduled and actual

progress and the action proposed for corrective measures, wherever necessary.

15. MAN-POWER REPORT

The Contractor shall submit to the Engineer, on the first day of every month, a man hours schedule for the month, detailing

the man hours scheduled for the month, skill-wise and area-wise.

16. Contract Quality assurance:

The Bidder shall include in his proposal the Quality Assurance Programme containing the overall quality management and

procedures which he proposes to follow in the performance of the Works during various phases. At the time of Award of

Contract, the detailed Quality Assurance Programme to be followed for the execution of the Contract will be mutually

discussed and agreed and such agreed Programme shall form a part of the Contract.

GENERAL CONDITIONS OF CONTRACT

(C) GENERALTERMS &CONDITIONS OF CONTRACT

A. INTRODUCTION

1.0 DEFINITION OF TERMS

1.1 The ‘Contract’ means the agreement entered into between the Owner and the Contractor as per the Contract Agreement

signed by the parties, including all attachments and appendices thereto and all documents incorporated by reference

1.2 ‘Owner’ shall mean the Gujarat Energy Transmission Corporation Ltd, Vadodara or any of its group companies i.e GUVNL,

GSECL, MGVCL, DGVCL, PGVCL, UGVCL and shall include its legal representatives, successors and assigns.

1.3 ‘Contractor’ shall mean the Bidder whose bid is accepted by the Owner for the award of the Works and shall include such

successful Bidder’s legal representatives, successors and permitted assigns.

1.4 ‘Engineer’ shall mean the officer appointed in writing by the Owner to act as Engineer from time to time for the purpose of

1.5 The terms ‘Stores’ and ‘Materials’ shall mean and include equipment, stores and materials to be issued to the Contractor

under the Contract.

1.6 ‘Works’ shall mean and include taking delivery of line materials labour and services, as per the Specifications and complete

erection, testing and putting into satisfactory operation including all transportation, handling, unloading and storage at the

Site as defined in the Contract.

1.7 ‘Specifications’ shall mean the Specifications and Bidding Document forming a part of the Contract and such other schedules

and drawings as may be mutually agreed upon.

1.8 Site’ shall mean and include the land and other places on, into or through which the works and the related facilities are to

be erected or installed and any adjacent land, paths, street or reservoir which may be allocated or used by the Owner or

Contractor in the performance of the Contract.

1.9 The term ‘Contract Price’ shall mean the lump-sum price quoted by the Contractor in his

bid with additions and/or deletions as may be agreed and incorporated in the Letter of

Award and the contract agreement for the entire scope of the works.

Seal and Signature of Contract Page 26 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

1.10 The term “Erection portion” of the contract price shall mean the value of field activities of

the works including erection, testing, and putting into satisfactory operation including

successful completion of performance and guarantee test to be performed at site by the

contractor including cost of insurances.

1.11 Site Engineer ‘Inspector’ shall mean the owner’s Engineers or any person nominated by the time to inspect the equipment;

stores or Works under the Contract and/or the duly authorized representative of the Owner.

1.12 ‘Notice of Award of Contract’/’Letter of Award’/’Telex of Award’ shall mean the official notice issued by the Owner notifying

the Contractor that his bid has been accepted.

1.13 ‘Order’ shall mean the official letter issued by the Owner informing the acceptance of the bid.

1.14 Date of Contract’ shall mean the date on which letter of commencement of work issued by the respective sub division deputy

1.15 ‘Month’ shall mean the calendar month. ‘Day’ or ‘Days’ unless herein otherwise expressly defined shall mean calendar day

or days of 24 hours each.

A ‘Week’ shall mean continuous period of seven (7) days.

1.16 Writing’ shall include any manuscript, type written or printed statement, under or over signature and/or seal as the case

1.17 When the words ‘Approved’, ‘Subject to Approval’, ‘Satisfactory’, ‘Equal to’, ‘Proper’, ‘Requested’, ‘As Directed’, ‘Where

Directed’, ‘When Directed’, ‘Determined by’, ‘Accepted’, ‘Permitted’, or words and phrases of like importance are used the

approval, judgment, direction etc. is understood to be a function of the Owner/Engineer.

1.18 Test on completion shall mean such tests as prescribed in the Contract to be performed by the Contractor before the work

is taken over by the Owner.

1.19 ‘Performance and Guarantee Tests’, shall mean all operational checks and tests required to determine and demonstrate

capacity, efficiency, and operating characteristics as specified in the Contract Documents.

1.20 The term ‘Final Acceptance’/‘Taking Over’ shall mean the Owner’s written acceptance of the Works performed under the

Contract, after successful commissioning/completion of Performance and Guarantee Tests, as specified in the accompanying

Technical Specifications or otherwise agreed in the Contract.

1.21 ‘Latent Defects’ shall mean such defects caused by faulty designs, material or work-man- ship which cannot be detected

during inspection, testing etc, based on the technology available for carrying out such tests.

1.22 ‘Codes’ shall mean the following including the latest amendments and/or replacements, if any:

a) Indian Electricity Act, 1905 and Rules and Regulations made there under.

b) Electricity Act 2003 and Rules & Regulations made there under.

c) Indian Factory Act, 1948 and Rules and Regulations made there under.

d) Indian Explosives Act, 1884 and Rules and Regulations made there under.

e) Indian Petroleum Act, 1934 and Rules and Regulations made there under.

f) A.S.M.E. Test Codes.

g) A.I.E.E. Test Codes.

h) American Society of Materials Testing Codes.

i) Standards of the Indian Standards Institution.

j) Other Internationally approved standards and/or rules and regulations touching the subject matter of the Contract.

1.23 Words imparting the singular only shall also include the plural and vice –versa where the context so requires.

1.24 Words imparting ‘Person’ shall include firms, companies, corporations and associations or bodies of individuals, whether

incorporated or not.

1.25 Terms and expressions not herein defined shall have the same meaning as are assigned to them in the Indian Sale of Goods

Act (1930), failing that in the Indian Contract Act (1872) and failing that in the General Clauses Act (1897) including

amendments thereof, if any.

1.26 In addition to the above the following definitions shall also apply.

a) ‘All equipment and materials’ to be supplied shall also mean ‘Goods’.

b) ‘Constructed’ shall also mean ‘erected and installed’.

c) ‘Contract Performance Guarantee’ shall also mean ‘Contract Performance Security’.

2.0 APPLICATION

These General Conditions shall apply to the extent that they are not superseded by provisions in other parts of the Contract.

The works carried out under this Contract shall conform to the all statutory regulation and provisions the acts, mentioned

in the Technical Specifications, and, when no regulations or standard is mentioned, to the authoritative regulations or

standards/ Act, appropriate to the works and such stipulations shall be the latest issued by the concerned institution.

4.0 LANGUAGE AND MEASURES

Seal and Signature of Contract Page 27 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

All documents pertaining to the Contract including specifications, schedules, notices, correspondences, operating and

maintenance instructions, drawings or any other writing shall be written in English language. The Metric System of

measurement shall be used exclusively in the Contract.

5.0 CONTRACT DOCUMENTS

5.1 The term Contract Documents shall mean and include the following which shall be deemed to form an integral part of the

a) Invitation to Bid including letter forwarding the Bidding Documents, Instructions to Bidders, General Terms and

Conditions of Contract and all other documents included under Volume- I and the Special Conditions of Contract.

b) Specifications of the erection of the equipments and other technical services to be provided under the Contract as

brought out in the accompanying Technical Specifications.

c) Contractor’s Bid Proposal and the documents attached there to including the letters of clarifications thereto between

the Contractor and the Owner prior to the Award of Contract except to the extent of repugnancy.

d) All the materials, literature, data and information of any sort given by the Contractor along with his bid, subject to

the approval of the Owner /Consultant.

e) Letter of Award and any agreed variations of the conditions of the documents and special terms and conditions of

Contract, if any.

5.2 In the event of any conflict between the above mentioned documents the matter shall be referred to the Engineer whose

decision shall be considered as final and binding upon the parties.

6.0 USE OF CONTRACT DOCUMENTS AND INFORMATION

6.1 The Contractor shall not, without the Owner’s prior written consent, disclose the Contract, or any provision thereof, or any

specification, plan, drawing, pattern, sample or information furnished by or on behalf of the Owner in connection therewith,

to any person other than a person employed by the Contractor in the performance of the Contract. Disclosure to any such

employed person shall be made in confidence and shall extend only so far as may be necessary for the purpose of such

6.2 The Contractor shall not, without the Owner’s prior written consent, make use of any document or information enumerated

in various Contract documents except for the purpose of performing the Contract.

6.3 The Contractor shall not communicate or us in advertising, publicity, sales releases or in any other medium, photographs or

other reproduction of the Works under this Contract, or descriptions of the site, dimensions, quantity, quality or other

information, concerning the works unless prior written permission has been obtained from the Owner.

6.4 Any document, other than the Contract itself, enumerated in various Contract documents shall remain the property of the

Owner and shall be returned (in all copies) to the Owner on completion of the Contractor’s performance under the Contract

if so required by the Owner.

7.0 CONSTRUCTION OF THE CONTRACT

7.1 Notwithstanding anything stated elsewhere in the bid documents, the Contract to be entered into will be treated as a single

Award shall be placed on the successful Bidder as follows:

For providing services like inland transportation, insurance for delivery at site, unloading, storage, handling at site,

installation, testing and commissioning including performance testing in respect of all the equipment material

equipment/materials given by the owner after observing standard store procedures for transport from owner’s stores,

insurance, unloading storage handling at site installation testing & commissioning.

7.2 In case erection Contract, or where the Owner hands over his equipment to the Contractor for executing, then the Contractor

shall at the time of taking delivery of the equipment/dispatch documents be required to execute an Indemnity Bond in favor

of the Owner in the form acceptable to the SE GETCO Junagadh for keeping the equipment in safe custody and to utilize the

same exclusively for the purpose of the said Contract. Samples of Performa for the Indemnity Bond will be furnished during

award of Contract.

7.3 The Contract shall in all respects be construed and governed according to Indian Laws.

7.4 It is clearly understood that the total consideration for the Contract(s) has been broken up into various components only

for the convenience of payment under the Contract(s) and for the measurement of deviations or modifications under the

8.0 JURISDICTION OF CONTRACT

8.1 The laws applicable to the Contract shall be the laws in force in India. The Courts of Vadodara shall have exclusive

jurisdiction in all matters arising under this Contract.

9.0 EXECUTION OF CONTRACT:

9.1 The Owner, after the issue of the Letter of Award to the Contractor, will send one copy of the final agreement to the

Contractor for his scrutiny and approval.

9.2 The Agreement, unless otherwise agreed to, shall be signed within 10 days of the acceptance of the Letter of Award, at the

office the Owner at Junagadh on a date and time to be mutually agreed. The Contractor shall provide for signing of the

Seal and Signature of Contract Page 28 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Contract, Performance Guarantee, appropriate power of attorney and other requisite materials. In case the Contract is to be

signed beyond the stipulated time, the Bid Guarantee submitted with the Proposal will have to be extended accordingly.

9.3 The Agreement will be signed in copies to be specified and the Contractor shall be provided with one signed original and

the rest will be retained by the Owner.

9.4 The Contractor shall provide free of cost to the Owner all the Engineering data, drawings, and descriptive materials

submitted with the bid, to form a part of the Contract immediately after issue of Letter of Award

9.5 Subsequent to signing of the Contract, the Contractor at his own cost shall provide the Owner with copies of agreement

within fifteen (15) days after the signing of the Contractor.

10.0 ENFORCEMENT OF TERMS

10.1 The failure of either party to enforce at any time any of the provisions of this Contract or any rights in respect thereto or to

exercise any option therein provided, shall in no way be construed to be a waiver of such provisions, rights or options or in

any way to affect the validity of the Contract. The exercise by either party of any of its rights herein shall not preclude or

prejudice either party from exercising the same or any other right it may have under the Contract.

11.0 COMPLETION OF CONTRACT

11.1 Unless otherwise terminated under the provisions of any other relevant clause, this Contract shall be deemed to have been

completed on the expiry of the guarantee period as provided for under the clause entitled ‘Guarantee’ in this section of the

B. GUARANTEES & LIABILITIES

12.0 TIME – THE ESSENCE OF CONTRACT

12.1 The time and the date of completion of the Contract as stipulated in the Contract by the Owner without or with modifications,

if any, and so incorporated in the Letter of Award, shall be deemed to be the essence of the Contract. The Contractor shall so

organize his resources and perform his work as to complete it not later than the date agreed to.

12.2 The Contractor shall submit a detailed bar chart within the time frame agreed consisting of adequate number of activities

covering various key phases of the work such as field erection activities within five (5) days of the date of Notification of

Award. This network shall also indicate the interface facilities to be provided by the Owner and the dates by which such

facilities are needed. The Contractor shall discuss the network so submitted with the Owner and the agreed network shall

form part of the Contract documents. During the performance of the Contract, if in the opinion of the Engineer, proper

progress is not maintained, suitable changes shall be made in the Contractor’s operations to ensure proper progress without

any cost implication to the Owner. The interface facilities to be provided by the Owner in accordance with the agreed

network shall also be reviewed while reviewing the progress of the Contractor.

12.3 Based on the above agreed network/bar chart fortnightly reports shall be submitted by the Contractor as directed by the

12.4 Subsequent to the finalization of the network, the Contractor shall make available to the Engineer a detailed program in line

with the agreed Contract network.

Such program shall be reviewed, updated and submitted to the Engineer every month thereafter.

12.5 The above bar charts/ program shall be compatible with the Owner’s computer environment and furnished to the Owner

on such media as may be desired by the Owner.

13.0 EFFECTIVENESS OF CONTRACT

The Contract shall be considered as having come into force from the date of the commencement given by the respective

construction sub division unless otherwise provided in the notification of award.

14.0 PENALTY FOR DELAY

14.1 The total amount of penalty for delay under the Contract will be ½ % per week on delayed work amount subject to a

14.1 The total amount of penalty for delay under the Contract will be ½ % per week on delayed work amount subject to a

maximum of 10% of the Contract prices detailed in the Special Conditions of Contract (SCC).

15.1 In the event of any emergency where in the judgment of the Engineer, delay would cause serious loss or damages, repairs

or adjustment may be made by the Engineer or a third party chosen by the Engineer without advance notice to the

Contractor and the cost of such work shall be paid by the Contractor. In the event such action is taken by the Engineer, the

Contractor will be notified promptly and he shall assist wherever possible in making necessary corrections. This shall not

relieve the Contractor of his liabilities under the terms and conditions of the Contract.

15.3 If it becomes necessary for the Contractor to rectify or renew any defective portions of the works the provision of this clause

shall apply to portion of the works so rectified or corrected until the expiry of six (6) months from the date of such

rectification or correction. If any defects are not rectified within a reasonable time, the Engineer may proceed to do the work

at the Contractor’s risk and cost but without prejudice to any other rights which the Owner may have against the Contractor

in respect of such defects.

15.4 The rectification or correction of the work will be carried out free of cost by the Contractor. If any rectification or correction

is carried out on his behalf at the site, the Contractor shall bear the cost of such rectification or correction.

15.5 The acceptance of the works by the Engineer shall in no way relieve the Contractor of his obligations under this clause.

Seal and Signature of Contract Page 29 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

15.6 At the end of the guarantee period, the Contractor’s liability ceases except for latent defects. For latent defects, the

Contractor’s liability as mentioned in Clause Nos. 15.1 through 15.5 above, shall remain till the end of 6 months from the

date of completion of guarantee period.

16.0 TAXES, PERMITS & LICENCES

The Contractor shall be liable and pay all non-Indian taxes, duties, levies lawfully assessed against the Owner or the

Contractor in pursuance of the Contract. In addition to this the Contractor shall be responsible for payment of all Indian

duties, levies and taxes lawfully assessed against the Contractor for his personal income & property only.

18.0 DEFENCE OF SUITS

If any action in court is brought against the Owner or Engineer or an officer or agent of the Owner, for the failure, omission

or neglect on the part of the Contractor to perform any acts, matters, covenants or things under the Contract, or for damage

or injury caused by the alleged omission or negligence on the part of the Contractor, his agents, representatives or his Sub-

Contractors, or in connection with any claim based on lawful demands of Sub-Contractors, workmen, suppliers or

employees, the Contractor shall in all such cases indemnify and keep the Owner, and the Engineer and/or his representative,

harmless from all losses, damages, expenses or decrees arising of such action.

20.0 LIMITATION OF LIABILITIES

The final payment by the Owner in pursuance of the Contract shall mean the release of the Contractor from all his liabilities

under the Contract. Such final payment shall be made only at the end of the Guarantee/Warranty period or after finalization

of material account and final bill and till such time as the Contractual liabilities and responsibilities of the Contractor, shall

prevail. All other payments made under the Contract shall be treated as on-account payments.

21.0 ENGINEER’S DECISION

21.1 In respect of all matters which are left to the decision of the Engineer including the granting or with-holding of the

certificates, the Engineer shall, if required to do so by the Contractor, give in writing a decision thereon.

21.2 If, in the opinion of the Contractor, a decision made by the Engineer is not in accordance with the meaning and intent of the

Contract, the Contractor may file with the Engineer, within fifteen (15) days after receipt of the decision, a written objection

to the decision.

Failure to file an objection within the allotted time will be considered as an acceptance of the Engineer’s decision and the

decision shall become final and binding.

21.3 The Engineer’s decision and the filing of the written objection thereto shall be a condition precedent to the right to request

arbitration. It is the intent of the Agreement that there shall be no delay in the execution of the works and the decision of

the Engineer as rendered shall be promptly observed.

22.0 POWER TO VARY OR OMIT WORK

22.1 No alterations, amendments, omissions, suspensions or variations of the Works (hereinafter referred to as ‘variation’) under

the Contract as detailed in the Contract Documents, shall be made by the Contractor except as directed in writing by the

Engineer, but the Engineer shall have full powers subject to the provisions hereinafter contained, from time to time during

the execution of the Contract, by notice in writing to instruct the Contractor to make such variation without prejudice to the

Contract. The Contractor shall carry out such variation and be bound by the same conditions as far as applicable as though

the said variations occurred in the Contract Documents. If any suggested variations would, in the opinion of the Contractor,

if carried out, prevent him from fulfilling any of his obligations or guarantees under the Contract, he shall notify the Engineer

thereof in writing and the Engineer shall decide forthwith whether or not, the same shall be carried out and if the Engineer

confirms his instructions, the Contractor’s obligations and guarantees shall be modified to such an extent as may be mutually

agreed. Any agreed difference in cost occasioned by any such variation shall be added to or deducted from the Contract

Price as the case may be.

22.2 In the event of Engineer requiring any variation, a reasonable and proper notice shall be given to the Contractor to enable

him to work his arrangement accordingly, and in cases where goods or materials are already prepared or any design,

drawings or pattern made or work done as per the contract requires to be altered, a reasonable and agreed sum in respect

thereof shall be paid to the Contractor.

22.3 In any case in which the Contractor has received instructions from the Engineer as to the requirement of carrying out the

alterations or additional or substituted work which either then or later on, will in the opinion of the Contractor, involve a

claim for additional payment, the Contractor shall immediately and in no case later than thirty (30) days, after receipt of the

instructions aforesaid and before carrying out the instructions, advise the Engineer to that effect. But the Engineer shall not

become liable for payment of any charges in respect of any such variations, unless the instructions for the performance of

the same shall be confirmed in writing by the Engineer.

22.4 If any variation in the Works results in reduction of Contract Price, the parties shall agree, in writing, so to the extent of any

change in the price, before the Contractor proceeds with the change.

22.5 In all the above cases, in the event of a disagreement as to the reasonableness of the said sum, the decision of the Engineer

22.6 Notwithstanding anything stated above in this clause, the Engineer shall have the full power to instruct the Contractor, in

writing, during the execution of the Contract to vary the quantities of the items or groups of items in accordance with the

Seal and Signature of Contract Page 30 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

provisions of clause entitled ‘Change of Quantity’ in section GCC of this Volume-I. The Contractor shall carry out such

variations and be bound by the same conditions as though the said variations occurred in the Contract Documents. However,

the Contract Price shall be adjusted at the rates and the prices provided for the original quantities in the Contract.

23.0 ASSIGNMENT AND SUB-LE TTING OF CONTRACT:

No subletting of contract is allowed. Contractor should carry out work on his own under his or his authorized supervisor and by

labours employed by him.

24.0 CHANGE OF QUANTITY

24.1 During the execution of the Contract, the Owner reserves the right to increase or decrease the quantities of items under the

Contract but without any change in unit price or other terms & conditions. Such variations unless otherwise specified in the

accompanying Special Conditions of Contract and/or Technical Specifications, shall not be subjected to any limitation for

the individual items but the total variations in all such items under the Contract shall be limited to a percentage of the

Contract price as specified in the Special Conditions of Contract.

24.2 The Contract price shall accordingly be adjusted based on the unit rates available in the Contract for the change in quantities

as above. The base unit rates, as identified in the Contract shall however remain constant during the currency of the

Contract, except as provided for in Clause 33.0 below. In case the unit rates are not available for the change in quantity, the

same shall be subjected to mutual agreement.

26.0 COOPERATION WITH OTHER CONTRACTORS AND CONSULTING ENGINEERS

The Contractor shall agree to cooperate with the Owner’s other Contractors and Consulting Engineers and freely exchange

with them such technical information as is necessary to obtain the most efficient and economical design and to avoid

unnecessary duplication of efforts. The Engineer shall be provided with three copies of all correspondence addressed by

the Contractor to other Contractors and Consulting Engineers of the Owner in respect of such exchange of technical

information, wherever needed.

27.0 NO WAIVER OF RIGHTS

Neither the inspection by the Owner or the Engineer or any of their officials, employees, or agents nor any order by the

Owner or the Engineer for payment of money or any payment for or acceptance of, the whole or any part of the Works by

the Owner or the Engineer, nor any extension of time, nor any possession taken by the Engineer shall operate as a waiver of

any provision of the Contract, or of any power herein reserved to the Owner or any right to damages herein provided nor

shall any waiver of any breach in the Contract be held to be a waiver of any other or subsequent breach.

28.0 CERTIFICATE NOT TO AFFECT RIGHT OF OWNER AND LIABILITY OF THE CONTRACTOR.

No interim payment certificate of the Engineer, nor any sum paid on account by the Owner, nor any extension of time for

execution of the Works granted by the Engineer shall affect or prejudice the rights of the Owner against the Contractor or

relieve the Contractor of his obligation for the due performance of the Contract, or be interpreted as approval of the Works

done or of the equipment furnished and no certificate shall create liability for the Owner to pay for alterations, amendments,

variations or additional works not ordered, in writing , by the Engineer or discharge the liability of the Contractor for the

payment of damages whether due, ascertained, or certified or not or any sum against the payment of which he is bound to

indemnify the Owner, nor shall any such certificate nor the acceptance by him of any sum paid on account or otherwise

affect or prejudice the rights of the Owner against the Contractor.

29.0 PROGRESS REPORTS

During the various stages of the work in pursuance of the Contract, the Contractor shall at his own cost submit periodic

progress reports as may be reasonably required by the Engineer with such materials as, charts, net-works, photographs,

test certificates, etc. Such progress reports shall be in the form and size as may be required by the Engineer.

30.0 TAKING OVER

Upon successful completion of work of erection of tower line by the Contractor, the Engineer shall issue to the Contractor a

completion Certificate as a proof of the final acceptance of the erected line. Such certificate shall not unreasonably be

withheld nor will the Engineer delay the issuance thereof on account of minor omissions or defects which do not affect the

commercial operation and/or cause any serious risk to the erected line. Such certificate shall not relieve the Contractor of

any of his obligations which otherwise survive, by the terms and conditions of the Contract after issue of such certificate.

C. CONTRACT SECURITY AND PAYMENTS

31.0 CONTRACT PERFORMANCE GUARANTEE

The Contractor shall furnish Contract Performance Guarantee(s) for the proper fulfillment of the Contract in the prescribed

form within fifteen (15) days of “Notice of Award of Contract”. The performance guarantee(s) shall be as per terms

The contractor should submit the awarded buy-back cost (i.e. upfront amount) in form of the Bank Guarantee/DD,

before/on the date of commencement. Then after each lot/total work, the dismantled material OLM cost is to be

deducted from his R.A.Bill/Final Bill as explained in detail IN OLM-SOP Points. After completion of the total work &

submission of total OLM amount to GETCO, OLM Bank Guarantee will be released. It is the responsibility of

division/circle/zonal office to decide the tenure of Bank guarantee of particular work allotted to the contractor in

concurrence with accounts department. The tenure/ Scheduled Completion Date should be calculated with all

contingencies like tentative time of clearance of ROW, Availability of material etc. The BG tenure should be mentioned

Seal and Signature of Contract Page 31 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

in the tender terms and conditions while tendering.

 IN ADDITION TO THE CONTRACT PERFORMANCE GUARANTEE, CONTRACTOR SHALL HAVE TO SUBMIT SEPARATE

‘BANK GUARANTEE’ FOR OLM UPFRONT AMOUNT, AFTER ISSUANCE OF LOI (LETTER OF INDENT),

 THE AMOUNT SHALL BE MENTIONED IN THE LOI (LETTER OF INDENT) SEPARATELY FOR

1 THE CONTRACT PERFORMANCE GUARANTEE &

2 OLM UPFRONT VALUE BANK GUARANTEE.

REMARK: Bidder shall quote on erection part only. No option shall be given to the bidder for selection of price bid in OLM Part. OLM

32.1 The payment to the Contractor for the performance of the works under the Contract will be made by the Owner as per the

guidelines and conditions specified herein. All payments made during the Contract shall be on account payments only. The

final payment will be made on completion of all Works and on fulfillment by the Contractor of all his liabilities under the

32.2 Currency of Payment

All payments under the Contract shall be in Indian Rupees only.

Payment terms will be as prescribed in the special conditions of contract and on fulfillment of conditions specified thereof.

33.1 Application for Payment

33.2 The Contractor shall submit application for the payment in the prescribed proforma of the Owner. Performa for application

for payment will be as prescribed.

34.1 Each such application shall state the amount claimed and shall set forth in detail, in the order of the Payment Schedule,

particulars of the Works including the Works executed at Site and of the equipment shipped/brought on to the site pursuant

to the Contract upto the date mentioned in the application and for the period covered since the last preceding certificate, if

34.2 Every interim payment certificate shall certify the Contract value of the Works executed upto the date mentioned in the

application for the payment certificate, provided that no sum shall be included in any interim payment certificate in respect

of the works that, according to the decision of the Engineer, does not comply with the Contract.

34.3 Mode of Payment

34.4 Payment due on completion of work shall be made by the Owner through Owner’s Bank or directly to the Contractor as per

the payment schedule.

34.5.1 All payments under the Contract shall be made as stipulated in the Special Conditions of Contract after signing the Contract

Progressive payments linked with erection shall only be made after the issue of certificates by the Engineer, one for the

quantum of work completed and the other for the successful completion of quality check points involved in the quantum of

35.0 DEDUCTIONS FROM CONTRACT PRICE

All costs, damages or expenses which the Owner may have paid, for which under the Contract the Contractor is liable, or any

other retention award will be claimed by the Owner. All such claims shall be billed by the Owner to the Contractor regularly

as and when they fall due. Such bills shall be supported by appropriate and certified vouchers or explanations, to enable the

Contractor to properly identify such claims. Such claims shall be paid by the Contractor within thirty (30) days of the receipt

of the corresponding bills and if not paid by the Contractor within the said period, the Owner may then deduct the amount,

from any monies due or becoming due by him to the Contractor under the Contract or may be recovered by sections of Law

D. RISK DISTRIBUTION

37.1 The Contractor at his cost shall arrange, secure and maintain all insurance as may be pertinent to the Works and obligatory

in terms of law to protect his interest and interests of the Owner against all perils detailed herein. The form and the limit of

such insurance as defined herein together with the under-writer in each case shall be acceptable to the Owner. However,

irrespective of such acceptance, the responsibility to maintain adequate insurance coverage at all time during the period of

Contract shall be of Contractor alone. The Contractor’s failure in this regard shall not relieve him of any of his contractual

responsibilities and obligations. The insurance covers to be taken by the Contractor shall be in the joint name of the Owner

and the Contractor. The Contractor shall, however, be authorized to deal directly with Insurance Company or Companies

and shall be responsible in regard to maintenance of all insurance covers. Further the insurance should be in freely

convertible currency.

37.2 Any loss or damage to the material during handling, transportation, storage, erection, and all activities to be performed till

the successful completion of commissioning of the line shall be to the account of the Contractor. The Contractor shall be

responsible for preference of all claims and make good the damages or loss by way of repairs and/or replacement of the

equipment, damaged or lost. The transfer of title shall not in any way relieve the Contractor of the above responsibilities

Seal and Signature of Contract Page 32 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

during the period of Contract. The Contractor shall provide the Owner with copy of all insurance policies and documents

taken out by him in pursuance of the Contract. Such copies of documents shall be submitted to the Owner immediately after

such insurance coverage. The Contractor shall also inform the Owner in writing at least sixty (60) days in advance regarding

the expiry/cancellation and/or change in any of such documents and ensure revalidation, renewal etc., as may be necessary

37.3 The perils required to be covered under the insurance shall include, but not be limited to fire and allied risks, miscellaneous

accidents (erection risks) workman compensation risks, loss or damage in transit, theft, pilferage, riot and strikes and

malicious damages, civil commotion, weather conditions, accidents of all kinds, etc. The scope of such insurance shall be

adequate to cover the replacement/reinstatement cost of the equipment for all risks up to and including delivery of goods

and other costs till the equipment is delivered at Site. The insurance policies to be taken should be on replacement value

basis and/or incorporating escalation clause. Notwithstanding the extent of insurance cover and the amount of claim

available from the underwriters, the Contractor shall be liable to make good the full replacement/rectification value of all

equipment/materials and to ensure their availability as per project requirements.

37.4 All costs on account of insurance liabilities covered under the Contract will be on Contractor’s account and will be included

in Contract Price, However, the Owner may from time to time, during the pendency of the Contract, ask the Contractor in

writing to limit the insurance coverage, risks and in such a case, the parties to the Contract will agree for a mutual settlement,

for reduction in Contract price to the extent of reduced premium amount. The Contractor, while arranging the insurance

shall ensure to obtain all discounts on premium which may be available for higher volume or for reason of financing

arrangement of the project.

37.5 The clause entitled ‘Insurance’ under the section ECC of this Volume-I, covers the additional insurance requirements for the

portion of the works to be performed at the Site.

37.6 Special Conditions of Contract details out the various insurance liabilities.

38.0 LIABILITY FOR ACCIDENTS AND DAMAGES

Under the Contract, the Contractor shall be responsible for loss or damage to the plant until the successful completion of

commissioning as defined elsewhere in the Bid document.

39.0 DELAYS BY OWNER OR HIS AUTHORISED AGENTS

39.1 In case the Contractor’s performance is delayed due to any act of omission on the part of the Owner or his authorized agents,

then the Contractor shall be given due extension of time for the completion of the Works, to the extent such omission on the

part of the Owner has caused delay in the Contractor’s performance of the Contract.

Regarding reasonableness or otherwise of the extension of time, the decision of the Engineer shall be final.

39.2 In addition, the Contractor shall be entitled to claim demonstrable and reasonable compensation if such delays have resulted

in any increase in cost. The Owner shall examine the justification for such a request for claim and if satisfied, the extent of

compensation shall be mutually agreed depending upon the circumstances at the time of such an occurrence.

40.0 DEMURRAGE, WHARFAGE, ETC.

All demurrage, warfare and other expenses incurred due to delayed clearance of the material or any other reason shall be

to the account of the Contractor.

41.0 FORCE MAJEURE

41.1 Force majeure is herein defined as anycausewhich is beyond the control of the Contractor or the Owner as the case may be,

which they could not foresee or with a reasonable amount of diligence could not have foreseen and which substantially

affects the performance of the Contract, such as:

a. Natural phenomena, including but not limited to floods, droughts, earthquakes and epidemics;

b. Acts of any Government, domestic or foreign, including but not limited to war, declared or undeclared, priorities,

guarantees, and embargoes.

Provided either party shall within fifteen (15) days from the occurrence of such a cause notify the other in writing of such

41.2 The Contractor or the Owner shall not be liable for delays in performing his obligations resulting from any force majeure cause

as referred to and/or defined above:

The date of completion will, subject to hereinafter provided, be extended by a reasonable time even though such cause may

occur after Contractor’s performance of obligation has been delayed due to other causes.

42.0 SUSPENSION OF WORK

42.1 The Owner reserves the right to suspend and reinstate execution of the whole or any part of the Works without invalidating

the provisions of the Contract. Orders for suspension or reinstatement of the Works will be issued by the Engineer to the

Contractor in writing. The time for completion of the works will be extended for a period equal to duration of the suspension.

42.2 Any necessary and demonstrable cost incurred by the Contractor as a result of such suspension of the works will be paid by

the Owner, provided such costs are substantiated to the satisfaction of the Engineer. The Owner shall not be responsible

for any liabilities if suspension or delay is due to some default on the part of the Contractor or his Sub-Contractor.

43.0 CONTRACTOR`S DEFAULT

Seal and Signature of Contract Page 33 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

43.1 If the Contractor shall neglect to execute the works with due diligence and expedition or shall refuse or neglect to comply

with any reasonable order given to him, in writing by the Engineer in connection with the works or shall contravene the

provisions of the Contract, the Owner may give notice in writing to the Contractor to make good the failure, neglect or

contravention complained of. Should the Contractor fail to comply with the notice within thirty (30) days from the date of

serving the notice, then and in such case the Owner shall be at liberty to employ other workmen and forthwith execute such

part of the works as the Contractor may have neglected to do or if the Owner shall think fit, without prejudice to any other

right he may have under the Contract to take the work wholly or in part out of the Contractor’s hands and re-contract with

any other person or persons to complete the works or any part thereof and in that event the Owner shall have free use of

all Contractor’s equipment that may have been at the time on the Site in connection with the works without being

responsible to the Contractor for fair wear and tear thereof and to the exclusion of any right of the Contractor over the same,

If the sum that the contractor is entitled to be paid plus the costs incurred by the Owner in completing the works, exceeds

the Contract Price or the entire works if entire works have been completed or the price for part of the work if part of the

works have been completed, the Contractor shall be liable for such excess.

If such excess is greater than the sums due to the Contractor, the Contractor shall pay the balance to the Owner and if such

excess is less than the sums due to the Contractor, Owner shall pay the balance to the Contractor. For facilitating such

payment, Owner shall pay the balance to the contractor. For facilitating such payment, Owner shall encash the Bank

Guarantees of Contactor available with Owner/s and retain such other payment due to the Contractor under the Contract in

question or any other Contract that the Owner/s may have with the Contractor. Such payment of excess amount shall be

independent of the liquidated damages for delay which the Contractor shall have to pay if the completion of works is delayed.

43.2 In addition, such action by the Owner as aforesaid shall not relieve the Contractor of his liability to pay liquidated damages

for delay in completion of Works as defined in Clause 14.0 of this Section.

43.3 Such action by the Owner as aforesaid the termination of the Contract under this clause shall not entitle the Contractor to

reduce the value of the Contract Performance Guarantee nor the time thereof. The Contract Performance Guarantee shall

be valid for the full value and for the full period of the Contract including guarantee period.

44.0 TERMINATION OF CONTRACT ON OWNER`S INITIATIVE

44.1 The Owner reserves the right to terminate the Contract either in part or in full due to reasons other than those mentioned

under clause entitled ‘Contractor’s Default’. The Owner shall in such an event give fifteen (15) days notice in writing to the

Contractor of his decision to do so.

44.2 The Contractor upon receipt of such notice shall discontinue the work on the date and to the extent specified in the notice,

make all reasonable efforts to obtain cancellation of all orders and Contracts to the extent they are related to the work

terminated and terms satisfactory to the Owner, stop all further sub-contracting or purchasing activity related to the work

terminated, and assist Owner in maintenance, protection, and disposition of the works acquired under the Contract by the

In the event of such a termination the Contractor shall be paid compensation, equitable and reasonable, dictated by the

circumstances prevalent at the time of termination.

44.3 If the Contractor is an individual or a proprietary concern and the individual or the proprietor dies and if the Contractor is

a partnership concern and one of the partners dies then unless the Owner is satisfied that the legal representatives of the

individual Contractor or of the proprietor of the propriety concern and in the case of partnership, the surviving partners,

are capable of carrying out and completing the Contract the Owner shall be entitled to cancel the Contract as to its

incomplete part without being in any way liable to payment of any compensation to the estate of deceased Contractor

and/or to the surviving partners of the Contractor’s firm on account of the cancellation of the Contract. The decision of the

Owner that the legal representatives of the deceased Contractor or surviving partners of the Contractor’s firm cannot carry

out and complete the Contract shall be final and binding on the parties. In the event of such cancellation the Owner shall not

hold the estate of the deceased Contractor and/or the surviving partners of the estate of the deceased Contractor and/or

the surviving partners of the Contractor’s firm liable to damages for not completing the Contract.

45.0 FRUSTRATION OF CONTRACT

45.1 In the event of frustration of the Contract because of supervening impossibility in terms of Section 56 of the Indian Contract

Act, parties shall be absolved of their responsibility to perform the balance portion of the Contract, subject to provisions

contained in sub-clause 45.3 below.

45.2 In the event of non-availability or suspension of funds for any reasons, whatsoever (except for reason of willful or flagrant

breach by the Owner) and/or Contractor then the works under the Contract shall be suspended.

Furthermore, if the Owner is unable to make satisfactory alternative arrangements for financing to the Contractor in

accordance with the terms of the Contract within three months of the event, the parties hereto shall be relieved from

carrying out further obligations under the Contract treating it as frustration of the Contract.

45.3 In the event referred to in sub-clauses 45.1 & 45.2 above the parties shall mutually discuss to arrive at reasonable settlement

on all issues including amounts due to either party for the work already done on quantum merit_ basis which shall be

determined by mutual agreement between the parties.

46.0 GRAFTS AND COMMISSIONS ETC.

Seal and Signature of Contract Page 34 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Any graft, commission, gift or advantage given, promised or offered by or on behalf of the Contractor or his partner(s),

agent(s), officer(s), director(s), employee(s) or servant(s) or any one on his or their behalf in relation to the obtaining or to

the execution of this or any other Contract with the Owner, shall in addition to any criminal liability which it may incur,

subject the Contractor to the cancellation of this and all other Contracts and also to payment of any loss or damage to the

Owner resulting from any cancellation. The Owner shall then be entitled to deduct the amount so payable from any monies

otherwise due to Contractor under the Contract.

E. RESOLUTION OF DISPUTES

47.0 DISPUTE RESOLUTION MECHANISM:

1. Amicable settlements

Any dispute, difference, controversy or claim between the parties arising out of or relating to this contract with reference

to the construction, interpretation, breach, termination or validity thereof (hereinafter referred to as “the dispute”) shall,

upon the written request of either party be referred to the authorized representatives of the disputing parties for resolution.

The authorized representatives shall promptly meet and attempt to negotiate in good faith a resolution of the dispute within

thirty days of the service of the request.

If the parties fail to amicably resolve the disputes or differences or contrary claims as indicated herewith in sub clause (1)

of Clause 47.0 arising under or in connection with the present works contacts, whether pertaining to works contracts alone

or works and procurement both, the same shall be referred to arbitration under the Gujarat Public Works Contracts Disputes

Arbitration Tribunal Act,1992.

48.0 RECONCILIATION OF ACCOUNTS

The Contractor shall prepare and submit every two months, a statement covering payments claimed and the payments

received vis-a-vis the works executed, for reconciliation of accounts with the Owner. The Contractor shall also prepare and

submit a detailed account of Owner Issue materials received and utilized by him for reconciliation purpose in a format to be

discussed & finalized with the Owner before the award of Contract.

49.0 Relationship with employee: -

Every bidder should, at the time of submission of bid. Give a declaration as under

“If any bidder company/firm, the interest (i.e. Shareholding in Company and share in partnership firm) of any employee of

the tendering company or his/her relative as defined in Section 2(77) of the Company’s act 2013 is 10% or more, the

tendering Company will not deal with such Company/Firm at all.”

Tendered therefore, must specifically disclose this fact in his technical bid. Non-disclosure of such facts would immediately

disqualify the tenderer for further dealing with the tendering company.

50.0 Conflict of Interest among Bidders/ Agents

A bidder shall not have conflict of interest with other bidders for particular quoted item. Such conflict of interest can lead to anti-

competitive practices to the detriment of Procuring Entity’s interests. The bidder found to have a conflict of interest shall be

A bidder may be considered to have a conflict of interest with one or more parties in this bidding process for particular quoted item,

a) they have proprietor/ partner(s)/ Director(s) in common; or

b) they receive or have received any direct or indirect subsidy/ financial stake from any of them; or

c) they have the same legal representative/ agent for purposes of this bid; or

d) they have relationship with each other, directly or through common third parties, that puts them in a position to have access

to information about or influence on the bid of another bidder; or

e) bidder participates in more than one bid in this bidding process. Participation by a bidder in more than one Bid will result

in the disqualification of all bids in which the parties are involved. However, this does not limit the inclusion of the components/ sub-

assembly/ assemblies from one bidding manufacturer in more than one bid.

f) in cases of agents quoting in offshore procurements, on behalf of their principal manufacturers, one agent cannot represent

two manufacturers or quote on their behalf in a particular tender enquiry. One manufacturer can also authorise only one agent/

dealer. There can be only one bid from the following:

1. The principal manufacturer directly or through one Indian agent on his behalf; and

2. Indian/ foreign agent on behalf of only one principal.

g) a Bidder or any of its affiliates participated as a consultant in the preparation of the design or technical specifications of the

contract that is the subject of the Bid;

h) in case of a holding company having more than one independently manufacturing units, or more than one unit having

common business ownership/ management, only one unit should quote. Similar restrictions would apply to closely related sister

companies. Bidders must proactively declare such sister/ common business/ management units in same/ similar line of business.

i) Bidder shall not act in contravention/ violation to the provisions of competition act, as amended from time to time.

Seal and Signature of Contract Page 35 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Every bidder should, at the time of submission of bid, give a declaration, that bidder shall not have conflict of interest with other

bidders, as above.

Use of Call before you dig (CBUD) App

All the excavators/excavating agencies engaged by “GETCO (Gujarat Energy Transmission Corporation Limited) must self-register

“Call Before you Dig (CBUD) “ app as excavator.

All digging agencies/Contractors must be mandated to do any type of digging/excavation only after prior intimation through CBUD

Responsibility for correctness of the information submitted in the bid lies with bidder. If any information furnished in the

bid is proved to be false at a later date, GETCO reserve right to reject the bid and the bid will not only be rejected but the

bidder will be BLACKLISTED as per GUVNL Policy

Note: Contractor has to bring the Cement, Reinforcement Steel, Structural Steel etc. from Approved Brand List Published

on GETCO’s website Only

Date: Superintending Engineer

(Signature of Contractor) GETCO,C.O., Junagadh

GENERAL CONDITION

A. GENERAL TERMS :-

1. The Gujarat Energy Transmission Corporation Limited does not bind itself to accept the lowest or any tender. The

Superintending Engineer (TR), Junagadh reserves the right to reject any or all tender without signing any reasons whatsoever

and decision of the The Superintending Engineer (TR), Junagadh will be final and unchallengeable.

2. In case of any dispute / doubt, the decision of The Superintending Engineer (TR), Junagadh, shall be unchallengeable, final and

binding to the Contractor.

3. Tender offer without payment of E.M.D/Tender Fee, required Certificate, Documents, bar chart list of Tools, Tackles,

Equipments, blank tender etc. required for execution of job will be out rightly rejected. The tenderer should furnish details of

past experience of such job of similar nature completed by him satisfactorily within the time limit in GETCO without this

certificate offer shall be rejected out rightly.

4. The competent authority can delete any items in schedule of the tender, if he feels that the rate quoted by contractor act. That

item is abnormally high completed to the estimated rates. Specification in any items mentioned in tender are subject to change

without any prior notice and binding to the Contractor.

B. GENERAL TERMS FOR CONTRACTOR :-

1. The erection work should be carried out according to the specification and as per Instructions & programmed laid out by the DE

/ Executive Engineer-in-charge of the work. Contractor has to co-ordinate E.I.C. of planning of outage & work schedule thereof,

so as to complete all the planned work in outage. Contractor has to deploy adequate manpower accordingly.

2. The contractor should appoint supervisor with sufficient qualification and experience who could supervise the execution of

work throughout. He should always be present on the site as far as possible. Qualification & experience certificate of deputed

supervisor to be submitted to GETCO.

3. The erection work should be commenced immediately from the date of receipt of instructions from office and should be

completed within thereafter. Prior intimation in writing for starting the job will be given by GETCO for the work.

4. The contractor shall see the line route before quoting the rates.

5. The Contractor has to follow all IE rules, Insurance rules, GETCO rules labours laws, safety rules and regulations at his risk &

cost. The GETCO does not take any responsibility in case of accident or injury to the workers. The safety / security of men,

materials & equipments shall be sole responsibility of the contractor. Contractor will abide by and fulfill all the terms and

conditions and general terms and condition of the contract for works available in the office. All other general terms and

conditions as prevailing in the GETCO shall be applicable to this contract. The contractor will be governed by the GETCO’s general

conditions of works contract. The Booklet will be available in the concerned office in any working days. In the event of placing

order, the contractor will have to sign this booklet along with other documents and agreement. All the usual terms and

conditions of the GETCO, though the same might have not been mentioned in this specification or contractor booklet will

applicable to this contract, and the decision of the Executive Engineer (AM), Manavadar shall be binding on the contractor.

6. The bidder shall have the experience of erection line should be as mentioned in Technical/Commercial Bid..

7. The tenderer should quote for complete erection work, testing and commissioning of line as indicated in the Schedule “B” and

as per terms and conditions.

8. It will be bidder sole responsibility for erection of complete line in all respect, accordance with latest rules under Electricity Act

and approved by Electrical Inspector.

9. Above terms and conditions are part and partial of tender and will be observed

10. The Contractors has to engage required strength of skilled persons for Transportation, Loading & unloading work and proper

Supervisor to avoid complication & unnecessary delay to complete work timely. The Contractor will be totally responsible for

labour claims arising out of the labour employed for this job.

Seal and Signature of Contract Page 36 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

11. The detailed drawings of equipments can be seen from concern GETCO office during any working day and the equipments which

are to be erected can also be seen physically at S/s store during any working day and time.

12. Contractor has to ensure safe shifting and erection of all accessories / equipments as per standard norms.

13. The Contractor has to arrange for minor fabrication (if required) at free cost. The tender includes all minor accessories and

items of work which may not have been specifically mentioned in the specification schedule etc. but are essential for completion

of work. The contractor will not be eligible for any extra payment in respect of such minor accessories and items of work.

14. The contractor has to co-ordinate & co-operate fully with Engineer-in-Charge and commissioning Engineer of the supplier for

erection of all equipments / structure / accessories, etc., and any other items which are not conveniently included in the

specification but requires for completing the job.

15. The Contractor has to remain in contact in close days with Engineer in charge of work who in turn shall issue detailed instruction

for the commencement of the work.

16. The Contractor will be solely and responsible for any accident / damage either to equipments or any human being during the

time of execution of work.

17. Either you or your authorized person should contact our concern S/Dn as well Div office, Manavadar AM Div. office daily, for

the availability of equipments required for this work, failing to which this work order shall be terminated without giving any

18. The Contractor will have to give indemnity bond to GETCO against any possible claim of compensation for damage to

contractor’s equipments or staff or any of third party during the execution of work.

19. The Contractor will have to complete entire job as per directive and instruction of Engineer in charge. If he fails to do so entire

work will be carried out at Contractor’s risk and cost.

20. The contractor has the experience of survey work and produces the list of survey instrument and bio-data of Supervisor /

Surveyor / Engineer / Technician to be engaged for the job.

21. If the work is required to be carried out during specified outage then the contractor has to deploy adequate man power, material,

tools etc. well advance and has to complete the entire work during this specific outage period only, failing to which GETCO shall

be at liberally to deduct the amount of revenue loss due to prolong outage. Contractor has to co-ordinate E.I.C. of planning of

outage & work schedule thereof, so as to complete all the planned work in outage.

22. If required by GETCO you shall have to provide free to & for traveling facility to our field Engineer or Surveyor for the work.

23. The Contractor shall not refuse to execute the work order at any time and it will be his sole responsibility to execute and

complete this work as per the instruction of Engineer - in - charge.

24. The tender shall invariably furnish a monthly average erection capacity (in km. and rating) along with list of available machinery,

tools and tackles etc. for erection of line.

25. The tenderer shall not submit offer for erection or foundation work.

26. No subcontractor, Power of Attorney shall be allowed.

27. Any excess work done beyond specification and drawing shall be at Contractor’s risk and cost.

28. During the stringing work of line if any EHT / 11KV / L.T. line comes on the way the Contractor has to dismantle, restringing,

kept on original position etc. work to be carried out. No any charges will be paid extra for this work. Further work to be carried

out in co-ordination with concern DISCOM personnel for proper identification of feeder / LT line as well as you have to strictly

observed all the safety rules of GETCO.

29. The bidder shall specifically note that GETCO will not pay any extra amount to wards any type of claim except for the description

indicated in Schedule “B’. The party has to carry out all other / additional required activities / work as directed by Engineer in

charge which is not mentioned in Schedule but required to be completed as per the site condition and for this work no extra

Payment shall be made by GETCO.

30. In addition to the general of the construction particular attention shall be paid to the final finish and every effort shall be made

to have the entire work contented wish standard of workmanship by the Contractor.

31. No any idling / gang mobilization charge will be paid by GETCO in any circumstances.

32. No part rate or reduces rate shall be allowed in final bill.

33. The interpretation of specification doubts etc: - In case of any doubts about what is mentioned in specification or schedule

or elsewhere, the tenderer should get all doubts cleared from the Department in writing and in advance of filling in the tender.

In case of difference of opinion about interpretation of specification etc. the decision of Ex. Engineer (AM). Manavadar/SE(TR)

Junagadh will be final and shall be binding to the contractor to the tenderer.

34. Power supply should be arranged by contractor at his own cost. For that temporary connection to be obtain by contractor from

PGVCL for the said work.

C. SIGNING AGREEMENT:- The Contractor will have to sign an agreement as per GETCO’s rules in the prescribed form of the

GETCO. The cost Rs. 300/- of the Stamp Paper will have to be borne by the Contractor.

D. WORKING DAYS: In case, it is not possible for the contractor to continue, the work either due to heavy rains or other reasonable

causes, such facts should be immediate reasons to the notice of the Executive Engineer in writing. If the reasons for stopping the

work are genuine, the Engineer may ask the contractor in writing to stop work be cases (for such stoppage) are overcome and

the Engineer will ask the Contractor to start the work again in written, the period of such stoppage will not be considered as a

part of working month moreover the contractor cannot claim compensation for such work. Contractor will not allow to work

after working hours except in special case, if any.

E. TERMS OF PAYMENT:

1. Normally, one R.A. Bills will be paid every month, however, looking to the progress of the work it will be reviewed mutually and

90% of the cost of work done will be paid to the Contractor on his presentation of R.A. Bill giving the material account thereof.

Remaining 10% Payment will be made after the entire work is completed satisfactorily in all respect. The Bill should be

submitted to concern GETCO’s Executive Engineer (AM), Manavadar with a copy to Concern SE, Junagadh. Final bill will be

Seal and Signature of Contract Page 37 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

prepared by Concern Field Executive Engineer (AM), Manavadar within about fortnight from the date of completion of the

work by the Contractor.

2. The GETCO will be untitled to deduct directly from the bills to be paid to the contractor any sum or sums payable by you and

which sum/sums the GETCO is required to pay as principle employers on account of your default in respect of all liabilities

referred to in above clauses.

3. In case of any farmer's objection / ROW, contractor has to mobilize his all efforts to clear the objection in consultation with

GETCO authority. No extra Charge will be paid for such effort.

4. The contactor shall co-operative with the GETCO in recording measurement etc. as expeditiously as possible and he shall fulfill

all the requirement which are necessary to finalizes the accounts on the basic of its records and pay him such amounts as if

found due to him, together with the amount of security deposit if any remaining payable to him after deduction there from the

amount due by him to the GETCO. The GETCO shall not entertain further claim from thereafter.

5. THE GETCO shall deduct the Income - Tax & Taxes as per prevailing rules from each and every bill.

6. All the bills for erection, separately for each line should be presented with the following information on each bill.

(i) 90% bills for erection should be serially numbered giving the work done under each item up to period of billing, work done

for which the claim is made in the bill and up to date work so for done. Items in erection bill should correspond to items

mentioned in schedule of A/T.

(ii) Balance payment bills should be prepared at the end of the job for each line section under the jurisdiction of the concerned

Deputy Engineer which should give the complete information of work carried out, total payment due, actual payment received

up to date and the balance amount claimed, It should also accompany a statement of reconciled material account tower wise

7. 10% retention money will be deducted from each R.A. bill.

8. No higher rate or revised rate will be applicable for the work, if work is held-up / closed due to whatever so reasons.

9. R.A. Bill shall be paid if GETCO satisfy with the output of works otherwise only final bill shall be paid.

10. The cost of damages, if any will be recovered from the Contractor’s bill. The assessment of which will be done by field Engineer

at his sole discretion and his decision shall be binding to the contractor and shall be considered as final and unchallengeable.

11. The contractor shall co-operate with the GETCO in recording measurement etc. as expeditiously as possible and he shall fulfill

all the requirements which are necessary to finalize the accounts on the basis of its records and pay him such amount as if found

due to him together with the amount of security deposit. If any remaining payable to him after deduction there from the amount

due by him to the GETCO.

12. The contractor will not be eligible for any extra payment in respect of minor accessories and items of work.

F. AVAILABILITY OF MATERIALS AND IDLE LABOUR CHARGE: Materials are readily available and arrangement made to

procure the rest. However, the Contractor should be carrying out the work as and when the materials are received. No idle

labour charges will be bourned by the GETCO in case such occasion of idle labour arises, due to want of any materials. However,

this idle period will be counted for the period of assessing the time limit for completion of work as mentioned in the work order.

Contractor has to collect the material as and when available and should be keeping in his safe custody.

G. PROGRESS OF WORK & REPORTING :

1. Contractor has to submit their working schedule along with tender to complete the line in view of time limit given in tender Bar

chart is also to be submitted.

2. PROGRESS REPORT: Fortnightly progress reports in DUPLICATE shall be regularly submitted to the Executive Engineer (AM),

Manavadar and the concern Engineer-in-charge with a copy to SE, Junagadh. Bar chart duly signed by contractor shall be

submitted at the time of commencement of work.

H. MATERIAL, DELIARY & HANDLING :

1. All material / equipment required for this work as per schedule shall be delivered at any store center of GETCO jurisdiction &

contractor has to take delivery from these stores at his own cost only.

2. The contractor shall be responsible for breakages, losses & thefts of material during transit or erection after the materials are

issued from stores will, the completed work is taken over by the GETCO.

3. The contractor will be responsible for loss, distribution or deterioration of the materials, stores or articles supplied to him by

the GETCO, even if such a less distribution of deterioration has occurred under any circumstances whatsoever beyond his control

as if the materials, stores or articles so supplied were his property.

4. STORAGE-CUM-INSURANCE:- The contractor shall take suitable storage-cum-erection insurance cover at his cost to the

extent of 100% cost of s/s or line materials, which are required to complete the s/s or line. Contractor shall have to take

Marine cum Erection (MCE) insurance policy against any loss, damage, theft, pilferage, fire etc. for the complete period of

storage, erection and commissioning up to the time of taking over of the transmission line or S/S by the Board. The contractor

shall deal directly and pursue the claim with the insurance company and shall be responsible in regard to maintenance of all

insurance coverage as well as for settlement of claim. The proof of insurance policy taken by the successful contractor shall be

furnished to Engineer-In-Charge.

No material shall be issued to bidder/erection agency in absence of such insurance policy. The risk shall be covered for lifting

of material from store to final handling over to GETCO. Further In absence of the above insurance policy, R. A. Bill payment will

5. RETURN OF EMPTY CONDUCTOR DRUMS: The empty wooden drum of earth wire and conductor as well as insulator crates

will not be required to be returned back by the contractor to the GETCO stores.

6. ACCOUNTING OF GETCO MATERIALS: - The contractor will be fully answerable and responsible for all the material issued to

him for the work by the GETCO for any theft, loss of pilferage and shall have to furnish account for the same after completion of

the work and before preparation of final bill, If the loss referred to above is not made good before final bill as per rules of the

GETCO. Contractor has to maintain Site Register Material Account Register regularly.

Seal and Signature of Contract Page 38 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

7. The structure & equipment required for line erection work shall be delivered at central store by GETCO at free of cost and it

must be shifted to site without damaging the equipment must be kept in position as per instruction of In charge Engineer and

Manufacturer’s manual. The M.S. Girder required for line erection work will be provided at one end of the line by GETCO. The

trip of Girder should be of minimum 20 Girders.

8. The Contract has to shift the material at site with packing case and it should open carefully without damaging the equipment.

The packing case must be returned to the store in good condition and stacked as directed by Engineer-in-charge.

9. The equipments must be cleaned, washed if required before erection. The initial testing wherever required should be carried

out first with the help of Engineer-in-charge before erection, such as measuring continuity test or any other test found necessary.

10. THE GUJARAT ENERGY TRANSMISSION CORPORATION LTD. shall supply Steel Section required, for earth mesh / structure /

G.I. / M.S. strip for earthings the equipments structures with nut and bolts, power cable, control cable, L.T. cable, Clamps

connectors and C.I. Plate for small pit etc. at free of cost subject to condition mentioned in schedule-B.

11. Wooden charcoal, salt, black cotton soil, G.I. pipe, G.I. strip, G.I. wire, nut & bolts lugs etc. required for earthing shall be procured

by the contractor as per specification given is Schedule B.

12. Contractor will fully and solely responsible for any shortage, damage, leakages to the equipments or any it’s accessories that

may occur during transportation dragging, draining of oil, erection work etc.

13. In case of non - availability of some items / materials you will have to collect the same from other nearly store center for which

you shall be paid as per GETCO’s rules and S.O.R. rate.

14. After completion of the work, all the surplus materials issued by the GETCO shall be returned by you to the respective center of

the GETCO as per instruction of Engineer in charge at your cost.

15. For shortages of any materials issued by the GETCO for the work, recovery shall be made from you, on the basis or prices of the

materials (prevailing the date of settlement of materials Account) plus 15% supervision charges.

16. All the materials issued by GETCO shall be transported to the work site on same day and to be preserved in safe custody failing

to which GETCO shall initiate Police actions, similarly as per instruction of Engineer-in-charge, you have to credit the material

at GETCO store without any loss of time failing to which GETCO shall initiate Police action.

17. Accounts of Materials issued :- The contractor shall have to maintain accurate day to day and item wise account of use of

issued materials which shall be got checked from time to time by the representative of the GETCO. The contractor will be

responsible for custody and preserving the issued materials till the work is handover by the Contractor after completion.

18. The contractor has to maintain site Register, covering all the daily details of Material receipt & utilization, progress of work etc.

This register shall be checked and signed by Engineer in charge, Executive Engineer (AM), Manavadar & SE , Junagadh during

the site visit. Any bill without site register shall not be passed. The GETCO shall not entertain further claim from thereafter.

1. No tools, tackles, manpower, crane facilities etc. will be provided by the GETCO.

2. No special tools and tackles such as compression joint machine, jointing dies, come along clamps, dynamo meter etc. shall be

given by GETCO.

3. Erection tools required during construction of lines shall be arranged by the contractor at his own cost. Adjustable stub

templates will however be supplied by the GETCO which shall be returned by the contractor in Good condition on completion of

4. Contractor will have to make his own arrangement for all tools, tackles, wire ropes etc. for the work.

5. The contractor has to submit the list of tools, tackles, equipment with him along with his tender offer. The tender without this

list and other required documents (as mentioned above herein the tender) should be rejected out rightly.

J. ELECTRICITY RULES : All works shall be carried out in accordance with the revised and latest providing under Indian Electricity

Act and Rules made the rounder.

K. WASTAGE: You shall make every effort to minimize the breakage/Looses and wastage of line materials, etc. supplied “Free of

cost “by the GETCO for erection of line.

The ceiling for wastages permitted is as under :-

i) Conductor and Earth wire. : For jumpering/sag/sister wire: 0.5%

: For credit length up to 30 Mtr.: 0.5%

: For credit in pieces as good conductor from 30 Mtr. to 100 Mtr: 2%

ii) Insulators. : 0.25%

iii) Bolts & Nuts : NIL (No extra Bolts/Nuts will be supplied).

v) Hardware & Accessories. : NIL.

L. INSPECTION BY GETCO REPRESENTATIVES:

The Engineer-in-charge, higher authority of GETCO or his representatives will be free to visit the contractor’s work, their stores

site and erection sites and also verify the GETCO’s materials in the custody of the contractor as and when required.

M. FORCE MAJEURE :-

1. Force majored is defined as “Any cause which is beyond control of contractor or the GETCO as the case may be, natural

phenomena like floods, draught, - earthquake, epidemics etc. acts of any Government Authorize domestic or foreign including

but not limited to war, declare or undeclared, priorities quarantine, embargoes Licensing control or production or distribution

restrictions accidents like Fire, Explosions, Break-Downs etc.”.

2. All legal complication or disputes are subject to Junagadh jurisdiction only.

3. As the case may be, which they could not foresee or with a reasonable amount of diligence could not have foreseen and which

substantially affects the performance of the contract such as:

4. Natural phenomena including but not limited to floods, droughts, earthquakes and epidemics;

5. Acts of any Government, domestic or foreign including but not limited to war, declared or undeclared, priorities, guarantees and

Seal and Signature of Contract Page 39 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

6. Provided either party shall within fifteen (15) days from the occurrence of such a cause notify the other in writing of such causes.

7. The contractor or the owner shall not be liable for delays in performing his obligations resulting from any force majeure cause

as referred to and/or defined above.

N. QUANTITY OF WORK : The quantities of various items of erection indicated in Schedule-B are tentative, final quantities shall

be determined after completion of the details route surveys. The contractor has to carry out the work according to quantities as

determined at site for which the rates quoted in the Tender shall be valid. The department reserves the rights for revising or

omitting any of the quantities. The quantities actually executed by the contractor will be calculated at the rate given in the

contract schedule of the rates. The payment shall be made only on actual work executed or order quantity whichever is less.

O. TAKING DELIVERY AND INSURANCE:

1. As regard damage the materials, equipment and worker of the contractor, he himself will be responsible. If there is any

compensation to be paid in respect of “WORKMAN” compensation act of any other statutory provisions, the same will have to

be paid by the contractor direct. If he thinks fit he may take necessary insurance cover, at his cost.

2. The contractor has to keep ‘H’ frame materials & line materials in safe custody and transport to the respective sites and will be

fully responsible for any damage to or loss of all materials at any stage during transportation or erection or taking over of the

3. The Contractor has to open site store near by the route of the line and ensure for safe custody of all the stored materials at his

4. The contractor shall have total responsibility for the entire materials stored, loose, semi assembled and/or erected by him at

site in his custody. The contractor shall make suitable security arrangement at his own cost to ensure the protection of all

materials, equipment and works from theft, fire pilferage and any other damages and loss. It shall be the responsibility of the

contractor to arrange for security till the works are finally taken over by the corporation.

5. EQUIPMENT INSURANCE: - Contractor shall have to take comprehensive insurance policy against any loss, damage, theft, pilferage,

fire etc. to the material for the complete period of erection and commissioning up to the time of taking over of the Sub Station /

transmission line by the Board. The contractor shall deal directly and pursue the claim with the insurance company and shall be

responsible in regard to maintenance of all insurance coverage as well as for settlement of claim. The proof of insurance policy

taken by the successful contractor shall be furnished to Engineer-In-Charge. In absence of the above insurance policy, R. A. Bill

payment will be with held.

6. In the event of any damage, theft, loss, pilferage, fire etc. contractor will be responsible to lodge, pursue and settle all the claims

with the insurance company for all items, materials and the corporation shall be kept informed about it. Contractor shall replace

the lost/damaged materials/items promptly irrespective of the settlement of the claims by underwriter and ensure that the

work progress is as per agreed schedule. The loss, if any, such replacement will have to be borne by the contractor and Board

will not entertain any claim/representation in this regard. However it will be contractor’s responsibility to insure the entire

project till the line is taken over by the Board.

P. DEPARTURE FROM SPECIFICATION AND DRAWINGS:- Should the tenderer wish to depart from the specification in any

respect, they should draw attention to such departure giving his reasons thereof and should get approved the same before doing

any further work, unless this is done this specification shall held good. The working drawings are attached with the tenders.

However in case of any clarification the decision of Engineer in charge will be final & binding to the Contractor.

Q. TESTING AND COMMISSIONING :

1. The contractor after completion of erection work will ensure that all works connected with line have been completed correctly

as per Indian Electricity Rule and procedure, any extra cost involved due to incompleteness of work or bad workmanship found

out subsequently shall be set right forth with by the contractor at his cost. The clearances at major crossing & earthing resistance

value of H-frame / tower footing to be taken & data to be handed over to EIC.

2. After the erection is completed in all respects, the line should be thoroughly patrolled and checked for continuity and clearances.

The line should be meggered to check its insulating level. Afterwards, a line clear should be given to the Engineer-in-charge that

the line is clear and free of men and materials and is fit to be charged. If on charging the line is found not to hold, the contractor

should arrange to patrol the line and find out the causes for the tripping and rectify the defects.

R. TECHNICAL PARTICULARS : The general technical details of the type of towers to be erected conductors and earth wire to be

strung and relevant loading particulars for the same are given in section of the specification.

S. PROTECTION OF WORK

The Contractor shall have total responsibility for protecting his works till it is finally taken over by the Engineer. No claim will

be entertained by the Owner or by the Engineer for any damage or loss to the Contractor’s works and the Contractor shall be

responsible for complete restoration of the damaged works to original conditions to comply with the specification and drawings.

V. EMPLOYMENT OF LABOUR

1. The Contractor will be expected to employ on the work only his regular skilled employees with experience of his particular work.

No person below the age of eighteen years shall be employed.

2. All traveling expenses including provisions of necessary transport to and from Site, lodging, allowances and other payments to

the Contractor’s employees shall be the sole responsibility of the Contractor.

3. In case the Owner becomes liable to pay any wages or dues to Labour or any Government agency under any of the provisions of

the Minimum Wages Act, Workmen Compensation Act, Contract Labour Regulation Abolition Act or any other law due to act of

omission of the Contractor, the Owner may make such payment and shall recover the same from the Contractor’s bills.

W. FACILITIES TO BE PROVIDED BY THE OWNER

1. Space : Land for Contractor’s Store, Workshop etc.

a) The Engineer shall at his discretion and for the duration of execution of the Contract make available at site, land for construction

of Contractor’s field office, workshop, stores, etc. required for execution of the Contract. Any such temporary construction shall be

done by the Contractor at his cost. b) On completion of work the Contractor shall hand over the land duly cleaned to the Engineer.

Seal and Signature of Contract Page 40 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

Until and unless the Contractor has handed over the vacant possession of land allotted to him for the above purpose, the payment

of his final bill shall not be made.

2. Tools, tackles and scaffoldings

The Contractor shall provide all the construction equipment; tools, tackles and scaffoldings required for pre-assembly,

erection, testing and commissioning of the equipment covered under the Contract. He shall submit a list of all such materials

to the Engineer before the commencement of work at Site. These tools and tackles shall not be removed from the Site without

the written permission of the Engineer.

The Contractor shall provide necessary first-aid facilities for all his employees, representatives and workmen working at the

Site. Enough number of Contractor’s personals shall be trained in administering first-aid.

4.Cleanliness The Contractor shall be responsible for keeping the entire area allotted to him clean and free from rubbish,

debris etc. during the period of Contract. The Contractor shall employ enough number of personnel to keep the work area

clean. Materials and stores shall be so arranged to permit easy cleaning of the area. In areas where equipment might drip oil

and cause damage to the floor surface, a suitable protective cover of a flame resistant, oil proof sheet shall be provided to protect

the floor from such damage.

5. LINES AND GRADES All the works shall be performed to the lines, grades and elevations indicated on the drawings. The

Contractor shall be responsible to locate and lay-out the works. Basic horizontal and vertical control points will be established

and marked by the Engineer at site at suitable points. These points shall be used as datum for the works under the Contract.

The Contractor shall inform the Engineer well in advance of the times and places at which he wishes to do work in the area

allotted to him so that suitable datum points may be established and checked by the Engineer to enable the Contractor to

proceed with his works. Any work done without being properly located may be removed and/or dismantled by the Engineer

at Contractor’s expense.

6. FIRE PROTECTION The work procedures that are to be used during the erection shall be those, which minimize fire

hazards to the extent practicable. Combustible materials, combustible waste and rubbish shall be collected and removed from

the Site at least once each day. Fuels, oils and volatile or inflammable materials shall be stored away from the construction and

equipment and materials storage areas.

7. All the Contractor’s supervisory personnel and select number of workers shall be trained for fire fighting. Enough of such

trained personnel must be available at the Site during the entire period of the Contract.

The Contractor shall have total responsibility for all equipment and materials in his custody/stores, loose, semi-

assembled and/or erected by him at Site. The Contractor shall make suitable security arrangements ensure the protection of

all materials, equipment and works from theft, fire, pilferage and any other damages and loss.

9.PRE-COMMISSIONING TRIALS AND INITIAL OPERATIONS

The pre-commissioning trials and initial operations of the equipment furnished and erected by the Contractor shall be the

responsibility of the Contractor as detailed in relevant clauses of Technical Specifications. The Contractor shall provide, in

addition, test instruments, calibrating devices, etc and labour required for successful performance of these trials. If it is

anticipated that the above test may prolong for a long time, the Contractor’s workmen required for the above test shall always

be present at Site during such trials.

SIGNATURE OF CONTRACTOR

WITH SEAL/STAMP

SPECIAL TECHNICAL CONDITION:_

SPECIFICATION FOR WORK ON TRANSMISSION LINE

1. RIGHT OF WAY, WAY LEAVE, TREE CUTTING AND OTHER OBSTRUCTIONS

1..1 All statutory clearances and permissions from various statutory bodies / Govt. authorities like forest Department, Railway,

Aviation Authority, Maritime GETCO, National High Way Authority, right of way and way leave etc. wherever required

along the entire route of the transmission line shall be arranged by the GETCO.

The successful bidder shall have to also arrange for Right of Way and tree clearance. The contractor should immediately

1.2 clear any obstructions or hindrance from local villagers or the local authorities in the execution of the work so that there

is no delay in execution/completion of various activities and awarded work is completed in the schedule completion

period in consultation with GETCO EIC.

1.3 For clearances, permissions etc. from various authorities, the Contractor shall not remain contended by simply informing

the GETCO, but shall invariably assist and arrange for personal follow up to overcome the difficulties in the interest of

progress of the work.

1.4. The contractor shall instruct his labours and staff to use minimum area while doing the work where there are standing

crops. No persons of the contractor should pick up any items from the standing crops or fruit. The contractor should take

all possible steps to avoid or minimize damages to the standing crops.

1.5. For necessary forest clearance, the processing will be done by the GETCO and the payment to the central

government/state government for compensation of forest clearance will be paid by the GETCO as necessary.

2. ACCESS TO LOCATIONS/USE OF PRIVATE ROAD/APPROACH ROAD TO SITE:

Seal and Signature of Contract Page 41 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

2. 1 It will be the contractor's sole responsibility to take the materials up to the location in path way, temporary road,

temporary bridge required will have to be provided by the contractor at his own cost. If, for any reasons the above is not

feasible, the contractor at his own cost shall have to arrange transportation of line materials by head loads.

2..2 The contractor will be deemed to be very well familiar with the route of the transmission line before giving the offer.

Notwithstanding the difficulties of terrain, location, approaches, way leave and other obstructions the price quoted for

all the items covered in the tender shall not undergo any change at any stage or shall be granted by the GETCO for any

special rates/consideration.

2. 3. The Contractor shall have to make necessary arrangement/permission for use of private/forest/canals for transportation

of materials, construction crew and tools at his own cost. Any charges levied by the concerned parties/authorities for use

of such road etc. shall be born by the contractor.

3 3 REMOVAL/ DISMENTALLING OF OLD LINE MATERIAL:

3.1 Before commencing the stringing work conductors, Hardware, insulators hard wares and conductor/earth wire accessories

of old line shall be removed from the existing tower / h-frame structures. Contractor shall check the towers / H-frames for

its safety for execution of dismantling / stringing work.

3.2 In case of old D/C line above work including removal of earth-wire is to be carried out in Hot line conditions i.e. one circuit

on D/C towers in live condition. The work is to be completed in given/arranged outage

3.3 For dismantling and stringing of conductor/ earth wire of 220 kV D/C lines, practical difficulties if any shall be resolved at

the time of execution of work.

3.4 In case of S/C line above work is to be carried out in cold conditions during arranged / given outage.

3.5 Necessary tools and tackles shall be used for the safety of the erection crew as the work is to be carried out during hot

line conditions.

3.6 Necessary precautions shall be taken by way of providing guys, rollers, etc for safety of towers and work shall be executed

in such a way not causing any damage to tower cross arms or tower body or tower foundations

3.7. Any damage that may occur to existing tower / H-frames during stringing/dismantling work shall have to be made good

by the contractor at no extra cost to the GETCO, including supply of towers / H-frame structures or part thereof, their

foundations including excavation, erection, earthing etc. required for safety and satisfactory performance of the line. All

such activities are to be carried out at no extra cost to the GETCO and in a schedule completion period. No extension in

completion period shall be allowed on such account.

3.8. Dismantled / removed line material of old line shall be transported to contractors store by clearing the site and arranging

their disposal at no extra cost to the GETCO.

3.9. Contractor has to pay cost of the old-line material that is to be retained by him as per the terms and conditions indicated in

the tender specification.

4 INSULATOR HOISTING AND STRINGING:

4.1 The rates for any type of stringing work, out of followings

i) Stringing of single / double circuit line with 3/6 conductor/s.

ii) Hot line / cold line stringing of conductor.

iii) Silicon rubber / conventional anti fog insulator hoisting.

4.2 The rates for stringing of conductors and ground wire for river crossings shall be on per KM basis only and shall be

paid according to actual work done. In case special river crossing towers are suspension type the river crossing shall

mean river crossing section considering the span from one anchor tower to the other end anchor tower i.e. Span

between tension towers adjacent to river crossing towers. Whereas if the special towers are tension type the special

crossing shall mean span from special tower to special tower of other end.

4.3 The rate of dismantling/stringing of single circuit on double circuit tower line for the work to be carried out with one

circuit in live condition.

4.4 The empty drums of conductor and earth wire shall be retained by the contractor and no recovery shall be made from

the contractor on this account.

4.5 REVENUE LOSS: The outages of the other crossing lines for stringing work should be planned in such a manner in

consultation with the Engineer in charge of the work that minimum shut down of other power lines are required.

Recovery against revenue loss to the GETCO due to time over run of the schedule outages, will be decided by MD (Tech.)

and the amount if any, on the revenue loss account will be clubbed with penalty clause so that maximum liability

towards recovery against revenue loss and penalty shall be limited to the extent of maximum of 10% of labour

component of the contract i.e. erection part.

5.1 Before commencing of stringing work, contractor must obtain approval of sag tension charts (these shall have to

be supplied by the contractor) showing final sags and tension for various temperature and spans. The stringing

chart shall be prepared according to appended format only.

5.2 The Contractor shall be responsible and will take care of proper handling of drums from stores to site. Sufficient

numbers of aluminum snatch blocks shall be used for paving out the ACSR/AAA Conductors. Necessary

precautions shall be taken to avoid conductor rubbing on the ground by providing adequate ground roller, rollers

on supports. Additional rollers shall also be provided to cross-thorny hedges, footing and other obstructions to

avoid scratching of conductor. The conductor and ground wire shall be made to sag correctly as per stringing

charts before they are finally transferred to the hard wares for conductors and to clamp for ground wire. No joint

should be made at less than 30 meters from the tower end and no joint shall be permitted in Railway, River, road

Seal and Signature of Contract Page 42 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

and other important crossings spans. There shall not be more than one joint in a span of each conductor. The sag

GETCO, if used shall be adjusted to suit the sag indicated against actual temperature for an individual span. The

thermometer shall be provided at the conductor point during the stringing work. Dynamometers shall be used in

tensioning the conductors. All conductors shall be stressed to their maximum working load at the time of stringing,

as per approved stringing charts.

5.3 The minimum clearance between the lowest point of conductor and ground shall not be less than required. All

compression joints should be carefully made and a record of initial and final lengths of the joints jointly signed by

Contractor and GETCO's representatives should be maintained. Check for sag should also be made at intervals

when conductor is drawn up. Over stressing, causing damage to towers should be avoided. Care should be

exercised not to over tension the conductor. Extra sag of 150 mm be allowed at all the important tension locations

like Railway/River Crossings.

5.4 After being pulled the conductor/ground wire shall not be allowed to hang in the stringing sheaves for more than

hours, before being pulled to the specified sag. During the time the conductor / ground wire is on the stringing sheaves

before sagging-in, it shall be ensured that the conductor / ground wire is not damaged due to wind, vibration, vehicles

or other causes. Scaffolding should be used to cross the important roads and Railway Crossing for minimum interruption

5.5 The conductor shall be pulled up to desired sag and left in serial stringing sheaves for at least one hour after which the

sag shall be rechecked and adjusted, if necessary, before clipping in and transferring the conductors from the serial

stringing sheaves to the suspension clamps.

5.6 Conductor shall be clamped within 24 hours of sagging. The sag will be checked in the larger spans of the section in case

of sections up to eight spans and in one intermediate larger span also for section with more than eight spans.

5.7 The stringing sheaves, when suspended on the transmission structure for sagging, shall be so adjusted that the

conductor will be on the sheaves at the same height as the suspension clamp to which it is to be secured.

5.8 The stringing of the ground wire shall be done in accordance with the stringing charts approved by the GETCO. The

ground wire shall be strung to run continuously over the conductors. The ground wire shall be pulled, sagged and

clamped-in from tension tower to tension tower before the phase conductors are pulled in that section. In case of double

circuit line, stringing of ground wire shall be done in hot line condition i.e. one circuit on double circuit tower in live

condition. For dismantling and stringing of earth wire of 66 kv D/C lines, practical difficulties if any shall be resolved at

the time of execution of work.

5.9 All the line conductors shall be terminated at sub-station structures whose details shall be furnished by the GETCO at

the appropriate time. The contractor shall fix strain insulators on the sub-station structures.

5.10 Amour rods and vibration dampers shall be fitted at each suspension tower before final clamping of conductor with

Insulator strings. Vibration dampers shall be fitted at each tension tower after final clamping of conductor with insulator

strings. Vibration dampers are to be fixed using aluminum tape with each clamping bolt and in correct vertical position

in relation to conductor. Compression type joints are to be used for jointing of conductors. Each part connected with

joints shall be perfectly cleaned by wire brush and properly greased before final compression. All the joints of conductors

and earth wire shall be made in the best workmanship manner and shall be perfectly straight and having maximum

possible strength.

5.11 Proper guys shall be provided to counter balance the paving out tension of conductor/ground wire at the tension

locations, to avoid damage to towers and/or accident.

5.12 Stringing work shall mean, the activities of fixing of insulator and insulator hardware’s, paving, jointing, tensioning,

clamping with Armour-rod, providing dampers, repairing of conductors (if any) and fixing the conductor at tension

hardware’s etc. in hot line condition i.e. one circuit in live condition for double circuit line or stringing in cold condition

for single circuit line.

6. SUPPLY OF MATERIALS BY GETCO:-

Material to be supplied by GETCO from concern GETCO store/Division or any store. Transportation cost is to be borne by

bidder. The contractor has to take delivery of materials from the GETCO’s store/Substation to the respective tower sites and

will be responsible for any damages to or loss of all materials at any stage during the Transportation or erection. The

materials that will be issued by the GETCO will be in ‘AS IS WHERE IS’ conditions at the store centre of the GETCO in the

area during working hours days. All the materials received by the contractor shall be got insured for storages and erection

risk by the contractor at his own cost. An indemnity Bond/Bonds have to be issued by the contractor for the materials take

over by him for erection.

7. MATERIALS TO BE SUPPLIED BY THE CONTRACTOR:- Materials/Tools are to be required for work of replacement of conductor,

Earth wire, SRI, replacement of tower etc, which are to be arranged by Contractor.

8. SPECIAL TOOLS :-Special tools and tackles for working others stringing materials will be arranged by contractor.

9. Minor additional work at site if required is to be carried out by contractor at free cost for complete ting the insulator

10. All the dismantled materials to be stored by contractor in safe custody. Bidder is totally responsible for old line

material storage. Material will be taken by contractor after crediting amount of old line material to GETCO. GETCO

is not responsible for any damage/ loss/ theft of any material.

11. Contractor shall have to compensate the board for damage of Boards property during dismantling / removing of Old line

materials from erection site.

12. Completion Period :- The Contractor has to complete the preliminary activities including joint inspection with GETCO field

staff after issue of letter of intent. As this work is of urgent nature contractor has submit the bar chart and give completion

Seal and Signature of Contract Page 43 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

period considering their capacity to replace conductor/mech stre. with minimum outages. Contractor has to complete above

work as mentioned above . No Mobilization charge will be given to contractor for cancellation of outage or start of work.

13. The above work is to be carried strictly as per instruction of Engineer In charge.

14. Above work to be carried out on in cold line condition replacement work under progress nearby lines should be in

charging condition. Proper safety must be taken by contractor.

15. NEW FRESH MATERIAL WILL ONLY BE ISSUED TO CONTRACTOR AFTER SUBMISSION OF BOTH THE BANK GUARANTEES,

I.E. [1] THE CONTRACTOR PERFORMANCE GUARANTEE & [2] OLM UPFRONT VALUE BANK GUARANTEE.

New material will be issued to contractor from any store and Old material to be stored by contractor at HIS STORE AT

HIS risk and cost. GETCO is not responsible for any damage, theft, missing of replaced old line material.

16.The contractor has to arrange for minor fabrication ( if required) at free of cost & follow all labour laws. IE rules,

safety rules, insurance rules, GETCO rules at his risk & cost.

17. The contractor should immediately notify and obstruction or hindrance from local villages or the local authorities in the

prosecution of the work to the concerned Engineer-in-charge, but should not deal directly in the matter. The Engineer-in-

charge will arrange to remove the obstacles as soon as possible.

18. It will be the contractor’s sole responsibility to take the materials up to the locations required. Any path way, temporary road

or temporary bridge required will have to be provided by the contractor at his cost. If for any reasons the above is not feasible

the contractor at his own cost shall have to arrange transportation by Head roads.

19. The Contractor has to deviate full men power / gangs from his routine work to site for completion of above work in stipulated

time or outage. This includes mobilization and odd hours working of their labor for cancellation of outage or start of work.

20. Contractor will have to deploy adequate resource so as to complete the workwithin stipulated time limit fixed by this office.

21. All the responsibility for stacking, stocking & preservation of material pertains to the contractor, incase of theft or loss of

material recovery shall be done as per GETCO norms.

22. All safety rules are to be strictly followed by the contractor.

23. In case of accidents to the persons engaged by the contractor, GETCO will not be responsible for any claim/ compensation.

24. On completion of the work all surplus new SRI and old removed porcelain insulator shall be returned by the contractor to

the nearest respective stores of the GETCO as per the instructions of the Engineer-in-charge of the works at no extra cost to

25. The contractor shall submit the complete material account immediately after the works is completed and in case not late than

one month of completion and Handing over of the line.

26. Site work register to be maintain strictly duly sign by your supervisor & EIC .Daily progress report to be

submitted to concern Executive Engineer /undersign. Also contractor has to deploy permanent skilled site

supervisor having enough experience and knowledge as per scope of work with enough standard / calibrated

tools & tackles with enough required manpower as per site requirement/as per EIC.

27. MATERIALS HANDLING AND STORAGE

27.1 All the equipment furnished under the Contract and arriving at Site shall be promptly received, unloaded, transported and

stored in the storage spaces by the Contractor.

27.2 Contractor shall be responsible for examining all the shipment and notify the Engineer immediately of any damages,

storage, discrepancy etc, for the purpose of Engineer’s information only. The Contractor shall submit to the Engineer every

week a report detailing all the receipts during the week. However, the Contractor shall be solely responsible for any shortages

or damages in transit, handling and / or in storage and erection of the equipment at Site. Any demurrage, wharf age and other

such charges claimed by the transporters, railways etc, shall be to the account of the Contractor.

27.3 The Contractor shall maintain an accurate and exhaustive record detailing out the list of all equipment materials received

by him for the purpose of erection and keep such record open for the inspection of the Engineer in-charge.

27.4 All equipment shall be handled very carefully to prevent any damage or loss. The equipment stored shall be properly

protected to prevent damage either to the equipment or to the floor where they are stored. The equipment from the store shall

be moved to actual location at the appropriate time so as to avoid damage of such equipment at Site.

27.5 All electrical panels, control gears, motors and such other devices shall be properly dried by heating before they are

installed and energized. Motor bearings, slip ring, commutators and other exposed parts shall be protected against moisture

ingress and corrosion during storage and periodically inspected.

27.6 All the electrical equipment such as motors, generators, etc. shall be tested for insulation resistance at least once in three

months from the date of receipt till the date of commissioning and a record of such measured insulation values maintained by

the Contractor. Such records shall be opened for inspection by the Engineer.

27.7 The consumable and other supplies likely to deteriorate due to storage must be thoroughly protected and stored in a

suitable manner to prevent damage or deterioration in quality by storage.

27.8 All the materials stored in the open or dusty location must be covered with suitable weatherproof and flame proof

covering material wherever applicable.

27.9 If the materials belonging to the Contractor are stored in areas other than those earmarked for him, the Engineer will

have the right to get it moved to the area earmarked for the Contractor at the Contractor’s cost.

27.10 The Contractor shall be responsible for making suitable indoor storage facilities to store all equipment, which require

indoor storage. Normally, all the electrical equipment such as motors, control gears, generators, exciters and consumables like

electrodes, lubricants etc. shall be stored in the closed storage space. The Engineer, in addition, may direct the Contractor to

Seal and Signature of Contract Page 44 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

move certain other materials, which in his opinion will require indoor storage, to indoor storage areas, which Contractor shall

strictly comply.

28. CONSTRUCTION MANAGEMENT

The field activities of the Contractors working at Site will be coordinated by the Engineer and the Engineer’s decision shall be

final in resolving any disputes or conflicts between the Contractor and other Contractors and the tradesmen of the Owner

regarding scheduling and coordination of work. Such decision by the Engineer shall not be a cause for extra compensation or

extension of time for the Contractor.

A. TOWER STRUCTURES :-

1. GENERAL TECHNICAL PARTICULARS FOR ERECTION OF 220 kV D/C TOWER LINES.

1.1 SCOPE : The erection work covered under these sections consists mainly of

i. Taking delivery of tower materials/line materials from the GETCO’s store centre situated at any store centre under GETCO &

storing the same in safe custody.

ii. Distribution of all materials to erection site.

iii. Stub setting.

iv. Tower Erection.

vi. Testing and commissioning and Guarantee of Line.

1.1.1The contractor shall be fully responsible for completing all the above works and till them are taken over by the GETCO.

1.1.2The methods of erection are dealt within details, but are left to the contractor who shall exercise his own judgment with regards

to actual handling of materials and in deciding upon the best methods to be adopted in the erection of the towers, conductors

and other materials.

1.2 FIXING OF LOCATIONS :-

The poles, guys and earthing position will be located by the department before commencement of erection work. The

Contractor will be shown the type of support to be erected at each pole position on joint detailed survey. The route map

attached is a proposed and likely to change a little at the time of actual peg marking. The GETCO will arrange surveyor for

survey only if not mentioned in schedule-B. Other labours required are to be provided by the contractor.

1. PRECAUTION FOR ERECTION :- Structures and guys must not be set along the angle of cuts of embankment where soil is

liable to be washed out unless special precaution is taken to ensure the durable foundation. If it is found that any structure set

along the edge of cuts and embankment the same will have to re-erect by the contractor. Ground level shall maintain between

any two locations as per instruction without any extra cost. Where ever high ground level shall come between any two

locations and at the time of stringing, it is felt that the specified clearance as per prevailing rules not be achieved the contractor

shall have to cut that much of ground as per the instruction of Engineer-in-charge.

2. RATES :- Before tendering rates for the works the contractor must examine the route of the line, the condition of terrain of

land and the strata of land. Also rates quoted by him for each item the rate should be reasonable and proportions to tender. In

case the tender has quoted very exaggerated of work the

tender will be rejected. Also the contractor should read the term and conditions and specifications for this work very carefully and

include the cost of materials to be supplied by him in the unit rate of the corresponding item of work.

3.1 DISTRIBUTION OF MATERIALS :

3.1.1 The contractor has to take delivery of tower materials/lines materials from the GETCO’s store Anywhere under GETCO

and transport it to the respective tower erection sites and will be responsible for any damages to or loss of all materials at

any stage during the Transportation or erection. The materials that will be issued by the GETCO will be in ‘ AS IS WHERE

IS’ conditions at the store

3.1.2 centre of the GETCO in the area during working hours days. All the materials received by the contractor shall be got

insured for storages and erection risk by the contractor at his own cost. An indemnity Bond/Bonds have to be issued by

the contractor for the materials take over by him for erection.

3.1.2 On completion of the work all surplus tower and line materials including the excess Bolts & Nuts and stub materials shall be

returned by the contractor to the nearest respective stores of the GETCO as per the instructions of the Engineer-in-charge of

the works at no extra cost to the GETCO.

3.1.3 The contractor shall submit the complete material account immediately after the works is completed and in case not late than

one month of completion and Handing over of the line.

3.2 SUPPLY OF MATERIALS BY GETCO:- Towers, stubs, templates, tower accessories, bolts-nuts, Tower material

1) Conductor, conductor accessories, earth wire, earth wire accessories.

2) Insulators, insulator hard wares.

3.3 MATERIALS TO BE SUPPLIED BY THE CONTRACTOR:-

1. Cement as per IS –8112

2. Barbed wire.

3. Earthing sets.

4. Zinc rich paint for bolt-nuts welded portion

5. Various plates namely DP / NP / PP / CIP.

6. Other materials and tools-tackles required for erection activities like survey, foundations, tower erection and

7. Tor steel bars required for reinforcement.

8. Nuts/Bolts required for H-frame DP Structure.

9. Boring machine and other tool required for bore type earthing for DP Structure

Seal and Signature of Contract Page 45 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

10. Earthing pipe 32 mm dia, 2 mtr. long G.I. pipe of approved make and fabricated as per specification.

11. Any other materials which shall be required to complete the work satisfactorily in all respects and not specified, in clause

above for supply of materials by the GETCO.

12. Enameled Danger Board and Number plates, G.I. Barbed wire with clamps for anti climbing devices and bolts.

13. G.I. Bolts / Nuts for assembling D.P. Structures and for guy sets.

4. STUB SETTING AND FOUNDATIONS :-

1. The contractor shall be fully responsible for correct setting of stubs in accordance with approved methods at the exact

locations and alignments and in precisely correct level; stub setting templates to the supplied by the GETCO should be used

for proper setting of stubs. The contractor will be responsible for constructing the foundations in accordance with the design

of each type of foundations supplied to him by the GETCO and as per approved final schedules.

2. The foundation work includes stone revetment, concrete or earth filling above ground level where necessary and stacking and

tamping on the site of all surplus excavated soil. Surplus stone should be stacked within the tower base

3. The rates for stub setting are inclusive of cutting of stubs (if any), setting of stubs, leveling at correct level, dismantling

of template after concrete, back-filling work etc.

5. Classification of Soil.

a) Normal Dry Soil: The soil readily removable with ordinary spades and shovels viz. Murram, hard murram etc. and to be used for

location in normal dry cohesive or non cohesive soils. If the black cotton soil is encountered up to 500 mm below ground level,

normal dry soil foundation shall have to be adopted. (The normal dry soil foundation designs shall be inclusive of this

b) Sandy dry soil: To be used for locations where cohesion less pure sand or negligible cohesive sand mixed with soil are met

in dry condition

c) Sandy wet soil: To be used in location where water table is met from top

d) Fully submerged black cotton Soil. To be used at locations where soil is clay type, not necessarily black in color, which shrinks

when dry and swells when wet, resulting in differential movement extending to a max., depth of 3.5 meter below ground level.

For designing foundation for this location the soil is to be considered submerged in nature. If the black cotton soil is

encountered only up to 500 mm from ground level, normal dry soil foundation shall be adopted. (This foundation design shall

be inclusive of this stipulation).

e) Soft Rock: Soft rock to be used at locations where decomposed or fissured rock, hard gravel, kankar, lime stone, laterite or any

other soil of similar nature is met. Undercut type foundation is to be used for soft rock locations.

f) Hard Rock: To be used at locations where chiseling, drilling, and blasting is required.

g) Fully submerged soil: To be used at locations where sub soil water table is met at less than

meter below ground level and up to complete depth of foundation.

h) Partially submerged soil: To be used at the locations where the submerged soil water table is met at 1.5m or more than 1.5 m

below the ground level, the top portion of the strata being normal dry soil. Soil strata for adopting various types of foundations

1. FOUNDATION :

i. The excavation will be limited to the volumes as per approved excavation drawings even though the Bidder may excavate

more for the sake of his own convenience or for any reasons. If the excavated dimension/s is/are more than the dimension/s

shown in the approved drawing, the additional excavated volume should be filled in with M10 mixture concrete at Bidders

cost in respect of materials, labours etc.

ii. In case of rock soil, the extra excavated rock portion on all sides shall be filled with M20 mix concrete at his own cost in respect

of materials, labours etc.

iii. The rates indicated in schedule for excavation work in each soil shall be applicable to all the locations as per actual condition

of the soil strata irrespective of classification of type of foundation.

iv. The rates for excavation indicated in schedule shall also be applicable for benching work, if required.

b. EXCAVATION IN ROCK : Where towers are to be planted in rock, suitable holes should be drilled, but if drilling is difficult,

blasting may be resorted to, but sufficient care should be taken to eliminate the possibility of serious cracking of the rock. Care

should also be taken to minimize the concreting for filling blasted areas. Stubs may be shortened suitably in case of drilled

holes as per design drawings.

c. Curing and back-filling :

i. After 24 hours of pouring, the concrete should be cured by keeping it continuously wet for 14 days. After 48 hours of pouring,

the pit may be backfilled with excavated selected earth (which is free from grass, dung, wooden waste, postures and fodder

woods, shrubs, thorn etc.) sprinkled with necessary amount of water and well compressed and consolidated in layers not

exceeding 150 mm. If the excavated soil consists of large boulders/stone, the same shall be broken to maximum size 80 mm

and mixed with soil to be back filled. At the locations where borrowed earth is required for back filling, this shall be done by

the Bidder at his own cost, irrespective of transportation from any land. Thereafter, the exposed top end fill shall be kept wet

for the remainder of above prescribed curing period. The uncovered portion of concrete chimney above the back filled earth

shall be kept wet by providing empty gunny bags fully wrapped around the concrete chimney for curing and ensure that the

bags are kept wet by frequent pouring of water on them.

ii. Extra ordinary care shall be taken during back filling. The Bidder and GETCO Engineer at site shall ensure that the back filling

is done in the manner referred above so that back-filled earth become homogeneous with surrounding parent soil with the

passage of time. The record for the same with day/date of curing, back filling etc be maintained in the register and duly signed

by the Bidder and GETCO representative. The quantities of excavated earth obtained from a particular location shall be

generally utilized in back filling work in protection of tower footing of same location unless it is unsuitable for such purpose.

In the later case, the back filling shall be done with borrowed earth of suitable quality irrespective of land and the consolidation

of earth shall also be done free of cost.

Seal and Signature of Contract Page 46 of

GUJARAT ENERGY TRANSMISSION CORPORATION LIMITED

TRANSMISSION CIRCLE OFFICE, JUNAGADH.

66KV Substation Compound, Opp Nandbava Gaushala, Dhandhusar Road, Zanzarda Junagadh-

e-mail : [email protected]

iii. The excavation of pits shall be of size 2`x 2`x 7`(600 x 600 x 2100mm) where the condition of soil is normal and size of the pits

should be 2`x 2`x 7 ½` (600 x 600 x 2500mm) where very soft soil is encountered and in this case bottom 6” (150mm) shall be

first concreted ( Ratio 1:3:6 / M-15) and well settled before the structure is erected only if so directed by Engineer in charge

of work. The concrete otta of size 0.4 x 0.4 x 0.3 Mtr. shall be provided and it shall be slopping towards all sides as per

instruction of Engineer in charge. If size of pits are increased more then the given specification no extra payments shall be paid

to the contractor. Due to this the extra concreting will have to be done at the cost of contractor. The excavation in HR / SR for

any items shall be paid extra.

Back filling on the structures shall be done after fixing of earth wire so that wire may not remain out and with mixture of murrum

and field metal for back filling the excavated stuff can be used if it is found suitable for doing so and it is not of very soft nature.

The consolidated back filling materials, should be well wetted and rammed and packed tight. Any sub sequent sinking of the

soil or any fitting of the structure will have to be attended by the contractor free of cost and to the satisfaction of the concern

Deputy Engineer / Executive Engineer. When very hard rock is encountered the depth of the excavation shall be 6` (1800mm)

or shall be reduced by more with written permission of Executive Engineer, where as resulting in tapering excavation, but in

no case the bottom of the pit should be less than 1` x 1` (300 x 300 mm).

iv. All the structures and metal parts will be given one coat of red oxide paint before erection and two coats of Asian / Burgor /

Nerolac make Silver Aluminum after erection including supply of paint. Lowest portion of about 7` (2100 mm) shall be painted

with two coats of good quality of black bituminous anti-corrosive paint. After complete drying of the red oxide coat, the coat

of silver paint will be applied as a final coat before applying any paint, all steel members are to be completely cleaned with

wire brush or rust remover, if initial coat of primer is not given to the issued items. The paint should be get approved before

supplied for change if any.

v. Only girders will be issued at one end of the line. The work under the item (erection of structure) includes transportation of

structures with all accessories from the specified center to the work site, lifting of the all members, excavation in all sort of

soil, erection, painting, painting, numbering, fitting of anti-climbing device, danger boards, muffing etc. The NP, DP, and ACD

are to be supplied by the contractor. Rates for concreting of structure shall be paid extra.

vi. A first coat of primer (Red oxide ) is to be applied (after wire brushing the surface) before erection of D.P. structure.

d. SHORING, SHUTTERING AND DEWATERING : The Bidder has to arrange for shoring, shuttering and dewatering work during