Civil work as required for garden development work at Ganpati Plot located in Kalapinagar area of Asarwa Ward in the Central Zone. (ARC)

Name of work: - bæg Ítulbtkk ymthJt Jtuzobtk ytJuj fjtveldh rJM<thbtk ytJuj dKv<e Ãjtuxbtk dtzol zuJjtuvbuLx ftbbtk

sYhegt< bwsc rmrJj Jfo fhJtlwk ftb.(yu.yth.me)

Tender Invited on Behalf of AMC, Central Zone.

Assistant Manager, Central Zone,

Central Zone Zonal Office”, B – Wing,

Third Floor,Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

Notice inviting Tender

Competent authority on behalf of Municipal Commissioner of A.M.C. invites percentage rate sealed tenders from interested

contractors for the following work at different locations within the limit of A.M.C.

1 Name of work Civil work as required for garden development work at Ganpati Plot

located in Kalapinagar area of Asarwa Ward in the Central Zone. (ARC)

2 Tender Amount Rs.998199.65 (exclusive of GST). GST will be paid extra by

AMC/Authority at prevailing rate to the contractor.

(Estimate put to Tender)

3 Tender fee Rs.900.00 (Demand Draft in favour of Municipal Commissioner, Amdavad)

(Non refundable) Tender Fee shall be submitted physically along with the Physical Submission.

4 Time Limit 12 Months (Excluding Moonsoon)

5 Download of Tender Complete bid documents can be downloaded with effect from

Documents Dt.05/10/2026 to Dt.16/10/2026 up to 18:00 Hrs. from the website

www.nprocure.com.

6 Required registration Register “E-2” class having in PWD in Govt. R&B/CPWD/AMC or

equivalent register with any other state Govt. or institutions.

If successful bidder is not registered with AMC, they will have to register

before submitting his Running Bill No.

7 Earnest Money Deposit (Bid Rs.9982.00 (Demand Draft / pay order / Bank Guarantee in favour of

security) Municipal Commissioner, Ahmedabad is to be submitted as prescribed as

(1 % of Estimate put to tender) below. Demand Draft/Bank Guarantee shall be from approved list of AMC of

banks and the issuing branch of bank guarantee shall be of Ahmedabad city

only and it should be valid for for 120 days. ( As Per AMC finance Dept .

Circular No. 5 Dt. 5/5/2007 & F.D. Circular No. 29 Dt. 7/8/2010 & attched

ANNEXURE - 1 finance dept.circular No-40 Dt.05/11/2020, circular no.

date: 05-08-2024). E.M.D. shall be submitted physically along with the

Physical Submission when applicable.

8 Submission of EMD and Tender Fee & EMD should Submitted physically along with tender

Tender Fees documents as described in the invitation of tender should be submitted to

Assistant Manager- Central Zone, 3rd Floor, B – Wing, Sardar Patel

Bhavan, Danapith, Ahmedabad-380001.

Bid submitted without bid security & tender fee shall be treated as non

responsive and shall be summarily rejected.

9 Mode of sending the Tender The whole tender shall be submitted by two mode.

Whole tender shall be submitted only on www.nprocure.com

website before Date:-16/10/2026 up to 18.00 hrs. Each bidder

must upload the scanned copies of all the documents along with

the submission of online bidding. Tender Fee, EMD, technical bid

and other relevant PQ Documents as per check list given in tender

shall be submitted physically in two copies (Original & duplicate)

in sealed envelope on or before Date.17/10/2026 upto17.00 hrs.

(by hand Delivery/ Courier/ Speed Post/Registered)

10 Last date of online submission Date.16/10/2026 up to 18.00 hrs.

Ahmedabad Municipal Corporation

11 Submission of Price Bid The Price bid shall be submitted online only. It shall not be submitted

12 Opening of Technical bid Technical Bid will be opened on line on Dt.17/10/2026 at 17.00 hrs in the

office of Assistant Manager- Central Zone, 3rd Floor, B – Wing, Sardar

Patel Bhavan, Danapith, Ahmedabad-380001.

13 Tender validity period 120 days from the last date of submission of Tender. it should be valid for

days from the last date of online tender submission.

14 Security Deposit 5 % of Contract Value to be submitted in the form of Bank Guarantee as per.

Bank Guarantee shall be from approved list of AMC of banks and the issuing

branch of bank guarantee shall be of Amdavad City only. The validity of the

Security Deposit shall be up to valid till 90 days beyond Date of completion

of work. The Security Deposit shall be payable in 15 days from date of receipt

of LOI failing which interest @4% per annum will be charged by AMC.

15 Deductions from Running

a. Retention Money 2 % amount of each Running Bill shall be deducted as a Retention Money.

Such retention money shall be released in the final bill of the said work.

b. Labour welfare cess 1% Labour welfare cess as per the Act, 1996 (non refundable) shall be

deducted from each running bill.

16 Defect & Liability Period Not applicable in this case. If applicable than refer condition of contract

attached over rule as per form B-1 published by Government.

17 Compansation for Delay 10 % of the actual balance work after Time limit expired.

18 During execution of works and in defect liability period, in any case if any fatal accident (major or minor)

occurs due to poor work and poor safety precautions, then it will be completely contractor’s responsibility and

compensation for the same has to be paid by contractor. During execution of works if any news is published in

print/Electronic/Social media regarding inferior quality of work and poor safety precautions, and due to inferior

quality work any fatal injuries occurs, all the losses due to such accidents and expenses of legal matters shall be

borne by contractor.

• All the circulars which were published by Authorities of AMC time by time will be applicable on said Tender and

bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the rights to reject any or all

the tenders without assigning any reasons thereof.

• The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In case authorized signatory

holding Power of Attorney and Digital Signatory are not the same, the bid shall be considered non-responsive.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

(On contractor’s Letter Head / certified with Stamp and Sign with Contact Detail)

TENDER DECLARATION FORM

Additional City Engineer

Ahmedabad Municipal Corporation,

Name of Work:- bæg Ítulbtkk ymthJt Jtuzobtk ytJuj fjtveldh rJM<thbtk ytJuj dKv<e Ãjtuxbtk dtzol zuJjtuvbuLx ftbbtk sYhegt< bwsc

rmrJj Jfo fhJtlwk ftb.(yu.yth.me)

I/We the undersigned have carefully gone through and clearly understood the Tender documents of above mentioned

project comprising of Notice Inviting tenders, Articles of Agreement, Scope of work, Definition of terms, notes

Instructions/Information to Bidder, Condition of Contract, special condition of contract, Appendices, Specifications, Bill of

Quantities, furnished by AHMEDABAD MUNICIPAL CORPORATION.

I/We do hereby offer to execute and complete the whole of the work within the time specified all in accordance with

the specification, designs, drawing and instruction in writing referred to in the said document and with such materials as

mentioned for, at the respective rates which I/we have quoted in the Price Bid or at such other rates as may be fixed under the

provisions of these conditions.

In the event of this tender being accepted I/We agree to enter into an agreement and when required, execute the

contract, according to your form 1 of agreement as or in default where of I/we bound myself/ourselves to forfeit the "Earnest

Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided by AMC from the date of

receipt of letter of acceptance, you will forfeit the earnest money paid by me/us and take necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for the sum as mentioned in

NIT, the full value of which is to be absolutely forfeited to the Employer If I/We fail to commence the work specified.

Otherwise the Employer shall retain the said sum, as on account of such Security Deposit as provided for in the aforesaid

I/We agree not to employ sub-contractors other than those that may be approved in accordance with conditions in the

aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any tender, which are received. I /

We also understand & agree that Municipal Commissioner Reserves the right to allot number of tenders to successful bidders

at his sole discretion in case if I / We am/are lowest in more than one tender.

I/We am/are bound to execute the job if the work order is issued within 120 days from the date of opening of the

I am bound to execute the work by maintaining all Quality aspects/parameters mentioned in the tender terms and

conditions. I am also bound to submit all supporting Genuine Original documents as and when asked and if any discrepancy

found in such documents as well as in the executed Work with respect to Quality/Quantity at any stage of work or even after

completion of work, it will be solely my Responsibility. I am bound to prove originality of all documents submitted by me and

if any Documents found false/fake then Municipal Commissioner/AMC has right to take any action/penalty/punishment

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality and/or the construction of

road is found to be of an inferior quality under this contract than in such case Municipal Commissioner/AMC has right to

debar/ blacklist permanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi duties, Royalty on

material (i.e. Aggregate, Sand etc.) And any other taxes prevailing and from time to time on such items on which the same are

leviable and the rates quoted by me/us are inclusive of the same.

Ahmedabad Municipal Corporation

Yours faithfully

Seal and Sign of Contractor

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal Corporation (referred to as

Employer in these documents) invites sealed bids for the construction of works (as defined in these documents and

referred to as “the work”) detailed in the table given in the Invitation for Bid (hereinafter called as IFB.) from

competent bidder. The bidders may submit bids for the works detailed in the table given in IFB.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined in this tender.

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-14. An agency that has

been engaged by the Employer to provide consulting services for the preparation or supervision of the works, and any

of its affiliates, shall not be eligible to bid.

3.3 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those are blacklisted/

debarred for specified period by AMC, Governement of Gujarat, Government of India or any other entity controlled

by it, would not be eligible to submit the Bid.

4.0 Qualification of the Bidder

4.1 Requires registration:- Register “E-2” class having in PWD in Govt. R&B / CPWD / AMC or equivalent register

with any other state Govt. or institutions.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to be disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and attachments submitted in proof of

the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the contract, inordinate delays

in completion, litigation history, or financial failures etc. or debarring from AMC work etc.

• Tampered the bid document in any manner.

• Colluded with other prospective bidders for this work to arrive at quoted prices for the purpose of restricting

• Indulged in inducement of any official of AMC and/or their consulting engineer and other advisors in any manner

• Proposal not submitted in accordance with this tender.

• During validity of the proposal, or its extended period, if any, the bidder changes his commercial terms.

• The bidder qualifies the proposal with his own conditions.

• Proposal is received after due date and time.

• Commercial proposal is enclosed with the same envelope as technical proposal

• The envelope does not show on the outside the reference of bid and thus gets opened before the due date of

• The E.M.D. is not deposited in full and in the manner as specified in the clause of Earnest Money Deposit.

• The tender is in a language other than English or dose not contains its English Translation in case of other

language adopted for tender preparation.

• The tender documents received are not duly signed by authorized person.

• The validity of tender is less than what is stated in the tender.

• Any of the page or pages of tender is/are removed or replaced.

• Any condition which affect the cost.

• If it is joint venture.

5.1 Debarment / Black listing

Notwithstanding the above, the Employer may debar or blacklist any of the bidder(s) for their misleading or false

representations in the forms statements etc. for the period to be decided by the Employer.

6.0 Cost of Bidding

Ahmedabad Municipal Corporation

The bidder shall bear all costs associated with the preparation and submission of his Bid. Employer will in no case be

responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and familiarize himself with the

site of Works and its surroundings including source of earth, water, road aggregates etc. and obtain all information

that may be necessary for preparing the Bid and entering into a contract for construction of the Works. The costs of

visiting the Site shall be at the Bidder's own expense.

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby total amount of work

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby total amount of work

increases / decreases up to any extent.

• If the works gets delayed / postponed for some administrative / technical decision whatsoever.

• If the items stipulated in the tender shall not be executed as per site condition/ requirements. No claim shall be

entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and no claim shall be

entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any) issued.

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

8. Bill of Quantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract data, forms, terms,

technical specifications, forms, Annexes in the bid document. Failure to comply with the requirements of bid

documents shall be at the bidder’s own risk. Bids which are not substantially responsive to the requirements of the bid

documents shall be rejected.

10.0 Amendment of Bidding Documents

10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by issuing addendum.

10.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on website www.nprocure.com

The prospective bidder shall refer to website to check any addendum before 24 hours of opening of bids. AMC will

not give any advertisement for the same.

10.3 To give prospective bidders reasonable time in which to take an addendum into account in preparing their bids, the

Employer may, at his desecration, extend as necessary the deadline for submission of bids.

10.4 Prospective bidders should attach the addendum made for the work & if fails to do so than also the changes made

through such addendum shall be applicable & bound to the bidder.

C PREPARATION OF BIDS

11.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

12.0 Documents comprising bid

The e bid submitted by the bidder shall be in two separate parts.

• Technical Bid

• Financial Bid

To qualify for award of the contract, each bidder must submit the following documents along with bid:

• Required Registration Certificate

• Other requested documents

• Any other material / information required to be submitted in accordance with these Instructions to Bidders

Ahmedabad Municipal Corporation

Failure to submit these certificates/documents shall make the bid non-responsive.

Above original documents in physical form in two copies, one marked as “original” and other marked as “Duplicate”,

shall be submitted in a sealed envelope by 18:00 Hrs on the date of physical submission of bid and addressed to the

addressee given in the NIT duly super scribed “Name of Work, Bid due date and time, Name and address of the

13.0 Bid Prices

• The contract shall be for the whole works as described in Bill of Quantity based on the percentage rate in the Bill of

Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any other cause shall be included

in the rates, prices and total Bid Price submitted by the Bidder, except otherwise stated in the Bid document.

Employer will not compensate the bidder (contractor) for any change in duties, taxes and other levies payable by the

contractor under the contract and any other reasons.

• The percentage rate and bid price quoted by the bidder shall be fixed up to the completion of Work and shall not be

subject to adjustment on any account, except where expressly specified, otherwise, in the contract.

14.0 Currencies of Bid and Payment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in Indian Rupees.

15.0 Bid Validity

15.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a shorter period shall be

rejected by the Employer as non-responsive.

15.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may request that the bidders

may extend the period of validity for a specified additional period. The request and the bidders' responses shall be

made in writing or by cable. A bidder may refuse the request without forfeiting his bid security. A bidder agreeing to

the request will not be required or permitted to modify his bid, but will be required to extend the validity of his bid

security for a period of the extension.

16.0 Earnest Money / Bid Security

16.1 The Bidder shall furnish, a Bid Security of the amount as shown in the Table of IFB as part of his bid, in the form of

Demand Draft / pay order / Bank Guarantee in favour of Municipal Commissioner, Ahmedabad valid for 120 days.

16.2 The issuing branch of the bank guarantee shall be of Ahmedabad City only.

Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

16.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as non-responsive.

16.4 Any bid having bid security for lesser value and shorter validity period shall be treated as non-responsive.

16.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be returned as promptly as

(b) The bid security of the successful bidder, along with second and third lowest tenders, will be returned when the

successful bidder has furnished the required security deposit and signed the agreement.

16.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the Agreement and

furnished the required security deposit.

16.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) sign the Agreement; or

(ii) Furnish the required security deposit.

(iii) commence the work after signing the agreement within 15 days

16.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank guarantee shall be of

Ahmedabad City only.

16.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp papers of requisite value in

accordance with the stamp Act applicable to that particular state of Indian Union, where executed.

Ahmedabad Municipal Corporation

16.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly indicate in (block letters)

his name, designation, Power of Attorney No. / Signing Power No. etc.

16.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by the executing officers

and the last page shall be signed in full, indicating the particulars as aforesaid under the seal of the Bank.

D. SUBMISSION OF BIDS

17.0 Sealing and Marking of Bids

17.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes and the three sealed

envelopes shall be sealed in an outer envelope. The Bid envelopes shall be marked as follows:-

• Complete Tender Document with all necessary qualification related documents (in two copy)

Above two envelopes shall be kept in one envelope and it should be marked as “Technical Bid” and sealed. This

Outer envelope should mention the name of firm of bidder, his address, contact details & name of the work.

17.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

c) Bear the following identification:

Indicate the name and address of the bidder.

• If the outer envelope is not sealed and marked as above, the Employer will assume no responsibility for the

misplacement or premature opening of the bid.

18.0 DEADLINE FOR SUBMISSION OF THE BID

18.1 Complete Bids (including Technical bid and necessary documents) must be received by the Employer at the address

specified in bid information not later than the date indicated on the face sheet of the document. In the event of the

specified date for the submission of bids declared a holiday for the Employer, the Bids will be received up to the

appointed time on the next working day. The Bidder is further required to submit Documents in Physical Form on or

before the Bid Due Date and before the time of submission as specified in NIT, at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

18.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-tendering portal on

account of delay in submission at bidder's end. Bidder shall ensure that they submit the bid well before the "Due Date

& Time of Bid- Submission". AMC shall not be responsible if bidder is not able to submit the bid on account of

failure in network/internet connection or any other technical reason.

18.3 The Employer may extend the deadline for submission of bids by issuing an amendment in accordance with

respective Clause, in which case all rights and obligations of the Employer and the bidders previously subject to the

original deadline will then be subject to the new deadline.

18.4 All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

18.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and returned unopened to the

Any Bid received by the Employer after the deadline prescribed in NIT will be returned unopened to the bidder.

20.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to expiration of the Bid

validity period by writing, facsimile or e-mail confirmed by registered letter. This letter (hereinafter and in the

Conditions of Contract called the “Letter of Acceptance” will state the sum that the Employer will pay the Contractor

in consideration of the execution, completion, and maintenance of the Works by the Contractor as prescribed by the

Contract (hereinafter and in the Contract called the “Contract Price”).

Ahmedabad Municipal Corporation

The notification of award will constitute the formation of the Contract, subject only to the furnishing of a Security

Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the Successful Bidder. It will be

signed by the Employer and the Successful Bidder.

21.0 SIGNING OF CONTRACT AGREEMENT

21.1 The Employer and the successful bidder shall enter into a Contract Agreement within 28 days after the successful

bidder (hereinafter called the Contractor) receives the Letter of Acceptance, unless they agree otherwise, subject to

furnishing the security deposit before signing the Agreement with the Employer.

21.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify the other Bidders

that their Bids have been unsuccessful and release their Earnest Money Deposit / Bid Security.

22.0 SECURITY DEPOSIT

22.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the Employer a security

deposit in the form of Bank Guarantee for an amount equivalent to 5% of the Contract Price valid for the period of

valid till 90 days beyond Date of completion of work. The Security Deposit shall be payable in 10 days (for tenders

upto Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above)from date of receipt of LOA failing which

interest @ 4% per annum will be charged by AMC.

22.2 The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from Ahmedabad branch

of any Banks mentioned in the clause no. 16.2 of these tender documents.

22.3 This security deposit shall be released only after the clearance of final bill including pre & post Audit.

22.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of security deposit or late

renewal of bank guarantee for the number of days delayed for submission or discontinuity of the bank guarantee.

22.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same verbatim as per the format. Bank

Guarantee shall be submitted on right value of stamp paper and for correct value of contract.

22.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall constitute sufficient

grounds for cancellation of the award and forfeiture of the Bid Security.

22.6 In case of any contract amendment during execution of the contract enhancing value of the contract the BG value shall

be enhanced accordingly. Validity of BG shall be commercial terms and conditions of the tender.

22.7 All compensation or other sums of money payable by the Contractor to the Employer under the terms of this Contract

or any other contract or on any other account whatsoever may be deducted from Security Deposit. Also in the event of

the Contractor's Security Deposit being reduced by reasons of such deductions, as aforesaid, the Contractor shall,

within 14 days of receipt of notice of demand from the Engineer-in-Charge, make good the deficit in Security

22.8 Should there arise any occasion under the Contract due to which the periods of validities of Bank Guarantees as may

have been furnished by the Contractor from time to time, are required to be extended/renewed, the Contractor shall get

the validity periods of such guarantees extended/renewed, and furnish these to the Engineer-in- Charge one month

before the expiry date of the aforesaid Guarantees originally furnished failing which the existing Bank Guarantees

shall be invoked by the Engineer – in – charge. Also in case of any deficit in securities on any account as might occur

or is noticed, the Contractor shall forthwith recoup/replace the same with acceptable Security Deposit.

22.9 The Bank Guarantee shall be extended within the expiry dates wherever activities as per contract are not completed in

22.10 The Security Deposit less any amount due shall, on demand, be returned to the contractor after 45 days of completion

date / Final Bill paid date which ever is later. No interest on the amount of Security Deposit shall be paid to the

Contractor at the time of release of Security Deposit as stated above.

22.11 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at Employer’s office within

23.0 Advance Payment and Security

The Employer will not provide any advance payment.

24.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final and binding to the

25.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting from Contractors

completed or under execution by him over last five years. If the details of Litigation History are hidden by the Bidder

Ahmedabad Municipal Corporation

and later on it comes to the knowledge of the Employer, the Bidder shall be disqualified for the proposed work and

other appropriate actions shall be taken against the bidder.

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Value of the Reasons/Details for Remarks showing

Year Name of Project (Rs.) litigation/arbitration Present Status

 The bidder shall furnish separate table for individual project.

 The above information shall be supported with necessary documents otherwise the same shall be treat as null and

 A consistent history of arbitration awards? Judgments against the applicants or any partner of a joint venture may

result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to knowledge of the employer the

bidder shall be disqualified for the proposed work and other appropriate actions shall be taken against the bidder.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT

E TENDER NOTICE NO. – 07 /2026-27

Special Tender Clause For CCRS SLA

Ahmedabad Municipal Corporation has to make a special clause as per for SLA

Name of work :-

<t.22.01.2026 lt htus bu.Bgwrlrmvjfrb§hmtnucle Jefje bexekdbtk &guj aatobtk bwÆt lk.21 bwsc

su <u me.me.yth.yum.le Vhegtœlu y.Bgw.ftu.îtht cltJuj Ôntuxmyuv d{wvbtk bwfgt ctœ «tuçjubJtRÍ yum.yuj.yu.lt mbgdt¤t

ctœ fhuj ftbdehe btxu,awftJJtlt &<t ltKtkbtk&e y.Bgw.ftu.lt rl<e-rlgb bwsc vulÕxe leau bwsc fhJtbtk ytJNu.

(A) Penlty For Maintenance and SLA Purpose

CCRS within SLA time (Category & Problem wise) CCRS After SLA time

(Category & Problem wise

Department Category Problem SLA Penalty Penalty Penalty

(Hours) (Hours) (Hours)

Engineering Water>>Engineering Water-low presure 240 240 480

Engineering Water>>Engineering Water-No Supply 240 240 480

Engineering Water>>Engineering Water-Other 72 72 144

Engineering Water>>Engineering Water-Leakage In 48 48 96

Main Line Hours

Engineering Water>>Engineering Water-Pollution In 24 24 48

Engineering Drainage>>Engineering Drainage-Manhole 24 24 48

Cover Missing Hours

Engineering Drainage>>Engineering Drainage-Other 48 48 96

Ahmedabad Municipal Corporation

Engineering Drainage>>Engineering Drainage-Choking Of 48 48 96

Engineering Drainage>>Engineering Drainage-Public 72 72 144

Toilets and Urinals- Hours

Blockage or Choking

Engineering Road Road-Other 48 48 96

Engineering Road Road-Bhuva On 48 48 96

Engineering Road Road-Repair Require 72 72 144

Engineering Storm Water Road-Water logged 24 24 48

Due To Rain Hours

Engineering Storm Water Road-Catch Pit 96 96 192

Repairing Hours

Engineering Public Building Public Building- 360 360 720

Public Toilets and Hours

Urinals-Repairing of

Doors,Windows,Tiles

Engineering Footpath Road-Footpath 168 168 336

Repairing Hours

Engineering Building>>Engineering Building-Municipal 168 168 336

Schools Repairing Hours

Wvhtuf< vulÕxele mbgbgtoœt ctœ vK ftbdehe fhJtbtk l ytJu <tu vwhuvwhe ftbdehele hfb suxje vulÕxe jtdw

(A) Penalty 10% for New Allocated Works.

(B) The Work Order under this Annual Rate Contract (ARC) Tender shall be issued

only against the approved and sanctioned estimate for the respective work.

The time limit for execution of each work shall be specified in the respective Work

Order issued under this tender.

Ahmedabad Municipal Corporation

Any penalty for delay or non-compliance shall be calculated and imposed based on

the approved sanctioned estimate amount of the respective work and shall be

governed by the relevant terms, conditions, specifications, and penalty clauses of

Seal and Signature of the Bidder Additional City Engineer (CZ)

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Liquidated Damages

1.1 If the Contractor fails to complete the works within the original or extended time limit, the Contractor shall pay

penalty of 10% of amount of actual remaining work. The amount of work for which the scope of contractor is reduced

shall not be considered for the calculation of Liquidated Damages.

1.2 Conditions mentioned in the AMC Finance Department Circular AMC no. 18 Date: 23/05/2017 and all latest

Circulars shall be applicable.

2.0 Retention Money

2 % amount of each Running Bill shall be deducted as a Retention Money. Such retention money shall be released in

the final bill of the said work. AMC reserves right to deduct any amount to compensate the poor performance of the

contractor i.e. poor quality or abandoned / incomplete work.

3.0 Subcontracting

3.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any portion of Work without

the approval of the Employer’s Representative. Any subcontracting shall not relieve the Contractor from any

contractual obligations or responsibility under the Contract.

3.2 The Contractor shall not be required to obtain consent for a subcontract for which the name of the subcontractor and

scope of works activities to be performed by him is already stated in the contract or supply of material or engagement

4.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred to in the Bid

document to carry out the functions stated in the Schedule or other personnel approved by the Engineer. The Engineer

will approve any proposed replacement of key personnel only if their qualifications, abilities, and relevant experience

are substantially equal to or better than those of the personnel listed in the Schedule.

4.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof, for his misconduct or

inadequacy of technical skills and experience, who is a member of the Contractor’s staff or his work force, the

Contractor shall ensure that the person leaves the Site within seven days and has no further connection with the work

in the Contract.

4.3 No residential accommodation is allowed at the site of work. The labour huts shall not be erected on the site of work and

contractor shall make his own arrangements to provide such accommodations as per the rules of the local bodies. He

shall make his own arrangements for housing, stores, field office etc. He shall submit a site layout plan indicating the

location of various site facilities to be created by him at his cost for the execution of work. The Owner shall in no way

be responsible for any delay on this account and no claim on this account whatsoever shall be entertained. All Basic

amenities shall be provided by the Contractor to Labours as per the prevailing labour Laws.

5.1 The Contractor shall have full regard throughout execution, completion and defects liability period to following safety

aspects and shall take all necessary steps to ensure that danger to safety is avoided all the time in respect of, Safety of

• Safety of the Contractor’s employees and all the persons directly or indirectly engaged by him for the works

• Safety of all the employees including persons working on other contracts of Employer at the same site of the

Employer and Engineers employees engaged at work site.

• Any authorized third party persons on the site.

• Contractor’s plant and equipment

5.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs, barricading, and

cones; when and where necessary, or required by Engineer in Charge or by any duly constituted authority for the

protection of the works or for the safety and convenience of the public or other.

5.3 The Contractor shall take all reasonable steps to protect the environment on and off the site and avoid damage or

nuisance to persons or property of the public and others arising as a consequence of his method of operation.

5.4 The Contractor shall maintain in good condition all work throughout execution, completion, and defects liability

period. The contractor shall be responsible for and to make good all injuries, damages and repairs, rendered necessary

by fire, rain, traffic, floods or other causes.

5.5 All the scaffolding work, wherever required for the execution of work, shall be provided by the contractor. Nothing

extra shall be payable on this account. It shall be provided strictly with double scaffolding system with all the

accessories etc. with adjustable suitable working platforms to access the areas, with ease for working and inspection.

Ahmedabad Municipal Corporation

It shall be designed to take all incidental loads. It should cater to the safety features for workmen. It shall be ensured

that no damage is caused to any structure due to scaffolding.

5.6 All temporary warning/ caution boards display shall be provided and displayed during day as well as night time by the

contractor, wherever required and as directed by the Engineer.

5.7 Arrangement of temporary water and electricity and telephone connection required, by him, shall be made by the

Contractor at his own cost and also necessary permissions directly from relevant Owners shall be obtained by him

under intimation to the Owner. Also all initial and running charges and security deposit, if any in this regard shall be

borne by him. The Contractor shall abide by all the rules/ bye laws applicable in this regard and he shall be solely

responsible for any penalty on account of violation of any of the rules and byelaws in this regard.

5.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the same shall be completely

contractor’s responsibility. All the losses due to such accidents and expenses of legal matters shall be borne by

5.9 The Contractor shall be responsible for maintenance and watch and ward of the complete installation and shall also be

responsible for any pilferage, theft, damage, penalty etc. in this regard. The Contractor shall indemnify the Owner

against any claim arising out of pilferage / theft, damage, penalty etc. whatsoever on this account.

5.10 The Contractor shall depute Site Engineer & skilled workers as required for the work. Necessary protective and safety

equipments shall be provided to them by the Contractor at his own cost and used at site.

6.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage rubbish, excess materials,

temporary works no longer required will be removed from site immediately.

7.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials, rubbish, temporary works

8.0 Bill of Quantities

a. The schedule-B shall contain Memorandum showing items for the construction, installation, testing, and

commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be paid only quantities

calculated after taking measurements of executed work. The rate stated in the schedule B for each item of work

shall apply. The works shall be measured by the Contractor jointly with the authorized representative of the

Engineer and all particulars required by the representative of the Engineer shall be supplied by the contractor.

c. The work shall be measured net. No allowance for general or local custom, working space etc. is to be made.

9.1 The Engineer in Charge shall have power to make any variation of form, quality or quantity of the works or any part

thereof that may, in his opinion, be necessary and for that purpose, or if for any other reason it shall, in his opinion, be

appropriate, he shall have the authority to instruct the Contractor to do and the Contractor shall do any of the

 Increase or decrease the quantity of any work up to any extent included in the contract,

 Omit any such work,

 Change the character or quality or kind of any such work,

 Execute additional work of any kind necessary for the completion of the Works or

 Change any specified sequence or timing of construction of any part of work.

9.2 No such variation shall in any way vitiate or invalidate the contract, but the effects, if any, of all such variations shall

be valued in accordance with the following sub clauses. Provided that where the issue of an instruction to vary the

Works is necessitated by some default or breach of contract by contractor or for which he is responsible, any

additional cost attributable to such default shall be borne by the Contractor.

9.3 The Contractor shall not make any such variation without an instruction of the Engineer. No instruction is required for

quantities varying from those provided for the items in the contract schedule B.

10.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows in the same order of

a) Variations in the quantities of work in schedule of quantities shall not vitiate the contract.

b) The contractor shall be bound to execute extra items of work as directed by the Engineer-in-charge.

c) Contract unit rates for individual items shall apply to varied quantities where there is a quantity variation.

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

Ahmedabad Municipal Corporation

10.2 If any extra item crops up during the progress of work the same shall be carried out by the Contractor and he shall be

paid at the rate fixed by Employer which shall be fixed as lowest of the rates derived by rate analysis based on the

following three methods. , the priority of the documents forming the Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2013-14, the rate of extra item

shall be that rate and premium (above or below) quoted by contractor.

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and equipment, the cost of all

temporary and incidental works, the overheads and the Contractors profit.

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs, the cost of use of all plant,

machinery, and equipment, the cost of all temporary and incidental works.

10.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall be taken at 10 % of the

final rate derived.

10.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in his opinion appropriate

and shall notify the Contractor accordingly with a copy to the Employer.

10.5 The Engineer shall determine provisional rates and prices to enable on account payments to be included in the Interim

Payment Certificates, until rates and prices are agreed as final by the Employer, the Contractor, and the Engineer.

10.6 The Contractor shall not be entitled to additional payment for costs, which could have been avoided by giving early

11.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in terms of the contract

and taxes at source, as applicable under the law. The Employer shall pay the Contractor the amounts certified by the

11.2 If an amount certified is increased in a later date certificate due to corrections in previous certificates or as a result of

an award from disputes review experts, Contractor shall be paid such amount only. The Contractor shall not be paid

any interest upon such delayed payment.

11.3 Items of the work for which no rate or price has been entered in will not be paid for by the Employer and shall be

deemed covered by other rates and prices in the Contract.

11.4 All payments shall be made in Ahmedabad.

12 Taxes and duties

12.1 The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local Governing bodies

prevailing on the date of award of the contract. The Contractor will have to pay all such taxes and duties for the

performance of this Contract. The Employer will deduct from the Contractor’s monthly and other payments all taxes

and duties, which he is bound to recover in accordance with the applicable law.

12.2 The Contractor shall keep himself fully informed of all acts and laws of the Central & State and local Governing

bodies, all orders, decrees of bodies, tribunals having any jurisdiction or authority which in any manner affect those

engaged or employed, and anything related to carrying out the work. All the bye-laws lay down by AMC/AUDA and

any other local bodies while executing the work shall be adhered to. All taxes of local bodies shall be borne by the

contractor. The Contractor shall arrange to give all notices required by any authority and to pay to such authority all

the fees that may have to be paid for the material, plants, equipments etc. The Contractor shall also adhere to all traffic

restrictions notified by the local authorities. He shall protect and indemnify the Owner and its officials & employees

against any claim or liability arising out of violations of any such laws, ordinances, orders, decree, whether by himself

or by his employees or his authorized representatives. Nothing extra shall be payable on these accounts.

13.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-1831-M(3) dt. 9/12/05

issued by G.O.G. (non-refundable) shall be deducted from every bills which shall be deposited to Govt. Labour

Department for Labour welfare fund.

14.0 Currencies

All payments shall be made in Indian Rupees.

15.0 Advance Payment

No Advance Payment shall be made.

16.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the

Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises

from the Contractor's acts or omissions.

A. FINISHING THE CONTRACT

17.0 Completion

Ahmedabad Municipal Corporation

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the Engineer will do

so upon deciding that the Work is completed.

18.0 Termination

18.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after receipt by him of a

Notice to this effect from the Engineer/Employer after signing the agreement or

2. To proceed with the works, or any section thereof, within 28 days after received notice

3. Has failed to comply with a notice issued or an instruction issued within 28 days after having received.

4. Abandons the works or otherwise plainly demonstrates the intention not to continue performance of his

obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written permission of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the contract.

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order made against

him, compounds with his creditors, or carries on business under receive, trustee or manager for the benefit of

his creditors, or if any act is done or event occurs which (under applicable Laws) has a similar effect to any

of these acts of event.

18.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to the contractor, terminate

the contract and expel the contractor from the site. However, in the case of sub-paragraphs (h), the Employer may be

notice terminate the contract immediately.

18.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the Employer, under the

contract or otherwise.

18.4 After termination, the Employer may complete the works and/or arrange for any other entities to do so. The Employer

and these entities may then use any goods, contractor’s documents and other design documents made by or on behalf

of the contractor.

18.5 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental breach of the

18.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the current Program and the

stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a reconstruction or

(c) The contractor fails to fulfill requirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach of Contract and the

Contractor fails to correct it within a reasonable period of time determined by the Engineer;

(e) the Contractor does not maintain a security which is required;

(f) the Contractor has delayed the completion of works by the number of days for which the maximum amount of

liquidated damages becomes payable as defined in the Contract data;

(g) if the Contractor, in the judgment of the Employer has engaged in corrupt or fraudulent practices in competing

for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving, receiving or soliciting of

anything of value to influence the action of a public official in the procurement process or in contract execution.

“Fraudulent practice” means a misrepresentation of facts in order to influence a procurement process or the

execution of a contract to the detriment of the Borrower, and includes collusive practice among Bidders (prior to

or after bid submission) designed to establish bid prices at artificial non-competitive levels and to deprive the

Borrower of the benefits of free and open competition.”

18.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a cause other than those

listed above, the Engineer shall decide whether the breach is fundamental or not.

18.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

18.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and secure and leave the

Site as soon as reasonably possible and handover the site to the Employer including all materials and plant and

equipment existing there upon.

19.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the same. He shall also be

responsible for the correctness of the positions, levels, dimensions, and alignment of all parts of the structures as per

instructions given to him. If at any time any error shall appear during the progress of any part of the work, the

contractor shall at his own expense rectify such error if called upon to the satisfaction of the Engineer in charge.

20.0 Overpayment & Underpayment

Ahmedabad Municipal Corporation

20.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or under this Contract

against the contractor the same may be deducted by the Municipal Corporation from any sum then due or which at any

time thereafter may become due to the contractor under this contract and failing that under any other contract with the

Municipal Corporation or from any sum due to the contractor with the Municipal Corporation (which may be available

with Municipal Corporation), or from his retention money, or he shall pay the claim on demand. The Municipal

Corporation reserves the right to carry out post payment audit and technical examination of the final bill including all

supporting vouchers, abstracts, etc.

20.2 The Municipal Corporation further reserves the right to enforce recovery of any over payment when detected

notwithstanding the fact that the amount of the final bill may be included by the Contractor.

20.3 If as a result of such audit and technical examination any over payment is discovered in respect of any work done by

the Contractor or alleged to have been done by him under the contract, it shall be recovered by the Municipal

Corporation from the contractor by way of all the means prescribed above or if any under payment is discovered by

the Municipal Corporation, any amount due to the contractor under this contract or under payment may be adjusted

against any amount then due or which may at any time thereafter become due before payment is made to the contractor

from him to the Municipal Corporation on any other contract account whatsoever.

21.0 Materials obtain from dismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for reasons other than on

account of bad or imperfect work, the materials obtained from dismantling will be the property of the A.M.C. and will

be disposed of as per instruction of Engineer-in-charge in the best interest of the A.M.C.

22.0 Dispute to be referred to Arbitrator

The disputes relating to this contract, so far as they relate to any of the following matters, whether such disputes arise

during the progress of the work or after the completion or abandonment thereof, shall be referred an independent

Arbitrator appointed by AMC as far possible in consultation with the agency if it is necessary and such disputes shall

be settled in accordance with the arbitration and conciliation Act.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon the works of the site

thereof or belonging to the contractor or procured by him and intended to be used for execution of the work

or any part thereof possession of which may have been taken by the Engineer-in-charge under the said clause

(ii) The reduction in rates made by the Engineer-in-charge under clause 9 from the items of works not accepted

as completed fully in accordance with the sanctioned specifications.

(iii) The rate of part of payment for any class of work which is included in the additional or altered work carried

out by the contractor in accordance with the instructions of the Engineer-in-charge under clause 14 and the

rates for which is to be determined under the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by the contractor before

receipt of notice given by the Engineer-in-charge under clause 15 and/or amount of compensation payable to

the contractor under the said clause for loss in respect of such materials.

(v) The amount of compensation which the contractor shall be liable to pay under clause 17 in the event of this

failure to rectify, remove or reconstruct the work within the period specified in the written intimation or the

amount of expenses incurred by the Engineer-in-charge under the said clause17 in rectifying, removing or re-

executing the work or in removing and replacing the materials or articles complained of.

(vi) The reduction of rates as may be fixed by the Engineer-in-charge under clause 17 for the inferior work or

materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates and assessed under clause

(viii) The amount payable to the contractor for the work carried out under clause 33 in accordance with the

instructions and the requirement of the Engineer-in-charge in case where there are no specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and calculations to every item

of claims. The decision will have to be implemented by all the concerned.

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation approaching on Court of

Law. It shall be within the jurisdiction where the site of work is situated.

The reference to arbitration proceeding under this clause shall not:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause 5 to take possession of all

or any tools, plants, materials and stores in or upon the works of site thereof belonging to the contractor or procured

by him and intended to be used for the execution of the work or any part thereof.

ii) Preclude the Engineer-in-charge from utilizing the materials purchased by the contractor in any work or from

removing such materials to other places, during the period the work is stopped or suspended in pursuance, of notice

given to the contractor under clause

iii) Progress of the work or the carrying out the additional or altered work in accordance with the provisions of clause

14 or as the case may be, of clause

Ahmedabad Municipal Corporation

23.0 Drawings and Photographs of the Works

23.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No separate payment will

be made to the contractor for this. . The contractor shall have to submit the same in hard copy as well as soft copy as

and when demanded by the AMC.

23.2 No photograph of the works or any part thereof or plant employed thereon, except those permitted under clause 59.1,

shall be taken, or permitted to be taken by the Contractor or by any of his employees or any employees of his sub-

Contractors without the prior approval of the Engineer in writing. No photographs/ videography shall be published or

otherwise circulated without the approval of the Engineer in writing.

Contractors should note the following conditions carefully:-

i) Conditional tender shall not be accepted.

ii) All tenders are to be submitted in duplicate without which the tenders are liable to be rejected.

iii) In case of tender downloaded from website, tender fee & EMD should be submitted in form of demand draft or

iv) Condition of Form - B1 Standard Specification of material & code of practice will be applicable. Form B1 is

available in website. Specification shall be as per ' R& B Dept. - Govt. of Gujarat booklets of Building Works

& and Road Works Specifications published by Gujarat Book Depot, Sector-21. Gandhinagar.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Ahmedabad Municipal Corporation

yb>tJt> BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe >hJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt yb>tJt> BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg gt>elt ftuLx[fxhtu Che

NfNu. dJobuLxlt btLg ftuLx[tfxhu yb>tJt> BGþrl.ftuvtuohuNlbtk btLg ftuLx[tfxhtule gt>ebtk hSMxuNl fhtJJtlwk

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u stuzJtle hnuNu.

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt mûtb ntug <ublu s

ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs xtRb jebexbtk ÃþY fhJt sYhe

mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt hnuNu.

z:- yb>tJt> Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t mexe.Rsluh

mh¾gwjh,lk -17,<t.09/12/2012 bwsc yb>tJt> Bgwrlrmvj ftuvtuohuNlbtk ftuLx[t¾xh hSMxuNl Ve,

heLgwyj Ve <&t yvd{uzuNl Ve ylu btv>kztu ægtlbtk htFe <u bwsc ybj fhJtltu hnuNu.

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe btdo, mkath ylu

JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu mtRx ylu rcÕzekd(fu su ftb fhJt,

ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj ntug).<ubs xuLzhhu yt mtRxlt ftb btxu, rcÕzekd btxu, gtzo,

zevtu btxule søgt vtu<tle he<u bu¤Je juJtle hnuNu. (xuLzhlwk ftb fhJt, ftb vwhwk fhJt <&t ftblt buRxulLm

(h) yt ftble mbg bgto>t bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle >hufu >huf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt >M<tJus vh< fhJtlt hnuNu.

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]< fh<wk

bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u cezJtle hnuNu.

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt >huf vtlt ylu rJd<tu vh ftuLx[tfxhu mne fhJe.

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh >eM<tJustult jFtKbtk ftuR AufAtf fu VhuVth fhJt >uuJtNu lrn ylu

ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug <tu <ult vh l Dwkx<t Ftuxt jFtK fu

ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ Wfju <u he<u jFJt. «ðguf mw^tht vh xwkfe mne fhJe.

Ahmedabad Municipal Corporation

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk >NtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug <tu xuLzh ybtLg

dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu ftuLx[tfxhtult btdo>Nol btxu mtbtLg

rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK >NtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk ytJNu.

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt vîr< y&Jt

rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu c>ÕGþ / c>Õgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk >huf Ctde>th y&Jt <u ykdulwk bwFðgthltbwk ^htJlth Ôgrf< mne l fhu

y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR mtûteyu mtF fhe l ntug.

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, h> fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu rlKog ytFhe hnuNu.

ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh ftuRvK «fthltu lwfNtle fu J¤<hltu

nff>tJtuu fhe NfNu lrn fu ftg>tfeg ftgoJtne yt ykdu &R NfNu lrn. xuLzh bkswh &gtltu y&o ftb ytve

>uJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh MJefthJtbtk ytJNu lne.

(9) rJmkdr< ylu rnmtc stud:

nt& ^hJtlt ftbtule ctc< >NtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK Cwjawf leault

rlgbtu ylwmth mhCh fhJtbtk ytJNu.

(1) xuLzh Chlthu >hlt Ftltbtk sKtJuj Nç>tu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nç>tuubtk sKtJuj hfb btLg

htFJtbtk ytJNu.

(2) yufb >h ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu >NtoJ<e CtJ vºtflt Ftltbtk&e hfbbtk Cwj

sKtg <tu yufb >h btLg htFJtbkt ytJNu ylu >hlt yt^thu dwKtfth mw^thJtbkt ytJNu.

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgto>t bwsc fhJtltu hnuNu. yt mbgbgot>t 10 jtF mw^elt ftb btxu yuj.ytu.ytR.

ytÃgt <theF&e 10 r>Jm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg <theF&e 15 r>Jm&e NY

&guj dKJtbt ytJNu. <&t <u >hBgtl ftble 3% juFu zevtuÍex Che fhthvºt fhJtltu hnuNu.

c:- mûtb m•tt îtht Yt.10,00,000.00 (>m jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ct> (LOI) ytvJtbtk

ytJNu ðgth ct> r>l - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu. rm¾gtuhexe zevtuÍex btuze ChJtlt

rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth ftgoJtne fhJtbtk ytJNu.

f:- bkswh &guj xuLzhle mbgbgto>tbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj

«btKu bkswh &guj mbgbgto>t ct>lt FhuFh ctfe ftble hfblt bn•tb 10% juFu (jefJezexe zubuSm)

vulÕxe Jmwj fhJtbtk ytJNu.

z:- yu.yth.me. xuLzhbtk bkswh &guj sw>t sw>t yk>ts vifelt ftbtu Jfo ytuzoh b¤u&e NY fhJtlt hnuNu.

Ahmedabad Municipal Corporation

E:- yu.yth.me. xuLzhbtk ftb «btKu yk>ts hfb Bþsc mbgbgto>t dKtNu.

(1) Yt.1,00,000.00 Mþ^elt ftbtu btxu 1 btm

(h) Yt.1,00,000.00 &e 3,00,000.00 Mþ^elt ftbtu btxu 2 btm

(3) Yt.3,00,000.00 &e 5,00,000.00 Mþ^elt ftbtu btxu 3 btm

(4) Yt.5,00,000.00 &e Wvhlt ftbtu btxu 12 btm

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt >h vwhtk &gujt ftb btxult Au ylu <ubtk bswhe, vtjF,

ÃjtLx, >uFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu <btb Faoltu <&t sYh sKtg <tu

ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu mbtJuN &Nu ylu xtkfujt CtJ fu >h fh<t J^thtle ftuR

awfJKe ykdult <ublt ftuR >tJt ægtlbtk juJtNu lnek ylu xuLzh Chlth Ftuxe hswyt<lu fthKu y&Jt ftuR

Ôgrf<yu (vAe<u ctk^ftb rJCtdltu fboathe ntug fu l ntug) <ublu ytvuje btne<elu yt^thu vtA¤&e ftuR

>tJt> hsw fhJt nf>th hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk sw>t sw>t CtJ ylu >h ChJt btxu sYhe yuJe

<btb btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u xuLzh hsw fhJtlu je^u y&Jt <ubtk&e WCt &<t ftuR

stuFb fu sJtc>thebtk&e Axfe NfNu lnek. m>h ftbbtk ftuR vK ò<lt ctk^ftblt bxehegj Wvh CtJ J^thtu

ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt ytJNu. <&t Bgwrl.

frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu ftbdehe/ybj fhJt rcl Nh<e ckDlf<ot hnuNu.

f:- ftuLx[t¾xhlt >huf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk vubuLx + yu¾x[t

ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh< ytvJtbtk ytJNu.

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftg>t bwsc su ftuR hfble fvt< fhJtle &Nu <u bwsc ftuLx[tfxhlt

cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

ce:- xuLzhbtk >NtoJuj ftb mkck^e >M<tJusbtk >NtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau >NotJuj ¢btlwmth

>M<tJusbtk >NtoJuj rJd< d{tng htFJtbkt ytJNu.fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u

mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu f>:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk f>, ytfth, ytkfzt f>ta Ftuxt ntug <tu btvujt f>, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Ahmedabad Municipal Corporation

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^ bwfe yuze.mexe

yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc fhJtbkt ytJuj rlKog ykr<b

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe ylu Rsluh Rlatsuo

Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl fhtJJwk.

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu lwfNtl &Nu <tu <ule

mkvwKo sJtc>the (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb >hBgtl bswhtu fu sl<tlt ftuR

btKmlt òlbtj lu lwfNtl &tg <ule sJtc>the ftuLx[tfxhle hnuNu. vtujem Vrhgt> &tg <tu <ule sJtc>the

vK ftuLxtfxhle hnuNu. CuFz Dme l vzu <ule sJtc>the vK vtujem Vrhgt>bt ftuLx[tfxhle hnuNu. CuFz Dme

l vzu <u btxu mjtb<elt vdjt (suJt fu >tuhzwk ctk^e bswh Ftztbtk W<thJt, mtuhekd ylu Mx[xekd fhJt rJduhu)

je^t Jdh bsqhlu Ftztbtk W<thNu <tu ftuLx[tfxh s vtujem Vrhgt>bt sJtc>th hnuNu ylu Bgwrl.ftuvtuohuNlltu

ftuRvK MxtV ytlt btxu sJtc>th hnuNu lrn. ytxjwk mbSlu s xuLzh ChJwk. bswhtultu rJbtu vK W<thJtu.

(16) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu fhtJJtlt hnuNu.

bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.

(17) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu rlgb ylwmth <u

ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(18) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< r>l 1btk vh< jR sJtltu hnuNu. yLg&t

<ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(19) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc ve.yuV/juch yufx <&t

bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftg>tlw vtjl fhJtlwk hnuNu <&t yt ykdu Bgwrl.ftuvtuohuNl îtht su

btne<e btkdJtbtk ytJu <u ytvJtle hnuNu. bu.BGþrl.frbNlh©elt mh¾âwjh Bþsc sYhe ctknu^he vºtf

ytvJtLþk hnuNu.

(20) ftuRvK ftg>tfeg jexeduNl yb>tJt> Nnuhle ftuxobt hnuNu.

(23) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu <ubs dtuXJJtltu

(24) ftuR vK mhfthe fhJuht ChJtle <btb sJtc>the ftuLx[tfxhle hnuNu.

(25) ftuLx[tfxh îtht xuLzhbt >NtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc jtJJtlt hnuNu.<&t

xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw vtjl fhJtlw hnuNu.

(26) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l ntug <uJe J^thtle

ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb ylwmth J^thtle ytRxblt CtJ lffe

fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk ytJNu.

(27) atjw ftb >hBgtl «tuxufNlle mkvwKo sJtc>the ftuLx[tfxhle hnuNu. subtk vevzt, >tuhzt Cgmwaf ctuzo, ÃjtMxef

vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK yfMbt< &Nu <tu <ule mkvwKo sJtc>the

ftuLx[tfxhle hnuNu.

(28) M&¤ Wvh atjw ftbdehe >hBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg Ôgrf<lt yfMbt<lt

rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem ftgoJtnele sJtc>the ftuLx[tfxhle hnuNu.

(29) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk >hhtus fhuj ftbdehe <&t

yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk ftuBÃjtgLm ytvJtlwk hnuNu ytJe ltu^lt

Ahmedabad Municipal Corporation

sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu ftuLx[tfxhlu vulÕxe fhJtle m•ttt yuze.mexe yuLSlehgh©elu

(30) >huf ytRxblt MvuNeVefuNl yb>tJt> Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg htFuj MvuNeVefuNl

Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk yuze.mexe.yuLSlegh©eltu rlKog ytFhe

hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu >hhtus J^thtltu zucheÍ WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu

sutFbu Jdh ltuxemu Jtuxhekd fhtJJtbtk <&t zucheÍ WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(31) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve juJtbtk ytJNu.

(32) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg >hBgtl ftuLx[tfxh îtht

ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk ytJNu.

(33) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu VhSgt< ytvJtlt

(34) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk ftb btk ftuRvK

mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj M¾{uJSkd ykdule btdoœrNoft lwk vtjl

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le bwjtft< je^e Au ylu ftblu jd<t

btjmtbtl, bswhe ylu ceS ctc<tulu jd<e M&trlf vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu jd<t >M<tJustu ft¤SvwJof

yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb< Awk/Aeyu.

ftuLx[tfxhle mne ylu rmfft

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT (CENTRAL ZONE)

BILL OF QUANTITY

Tender fee Rs.900.00 Opening Date :- 17.10.2026

Earnest money Rs.9994.00 Opening Time:- 18hr

Contractors Name Tender No.92

Name of Work:- bæg Ítulbtkk ymthJt Jtuzobtk ytJuj fjtveldh rJM<thbtk ytJuj dKv<e Ãjtuxbtk dtzol zuJjtuvbuLx ftbbtk sYhegt< bwsc

rmrJj Jfo fhJtlwk ftb.(yu.yth.me)

Qty Item Description Rate Unit Amount

Providing & erecting open well horizontal

mono block pump set with cast iron body,

complete for three phase submersible motor

[B] For 2 HP 3 phase open well horizontal

mono block pump set suitable for 200 LPM @

1.00 25 mtr head suitable for 50 mm dia delivery 10628 Nos.

pipe (R&B Sor year 2023-24,Item Code-9-4-2)

Supplying & erecting approved make

Automatic liquid level controller 6A. with

sensor testing as per instruction of Engineer in

charge on site complete with wiring

2 1.00 connection with existing wires , with copper 2332 Nos.

conductor from pump to upper and lower

tank.(R&B Sor year 2023-24,Item Code-9-5-

Ahmedabad Municipal Corporation

Supplying & erecting approved make motor

control cubical panel (Direct - on - line) made

from 16 G. CRCA sheet duly epoxy powder

painted inside and outside with hinged doors

and locking, arrangement consisting of suitable

size of ON- OFF isolator (AC - 3/23duty) main

fuses, single phasing preventer, indicating

lamps for R- Y - B phases, overload relay,

Automatic water level controller, Ammeter,

3 Voltmeter each with two way selector switch

incoming, wires duly socket crimped, main

contactor & overload relay, start - stop push

buttons, to be erected on angle iron frame

grouted on wall as directed. The isolator,

overload relay & contactors will be of L & T,

Siemens or BCH make only. (R&B Sor year

2023-24,Item Code-9-5-2)

2.00 (A) DOL up to 5.0 H.P. 7646 Nos.

S.I.T.C. submersible pump set suitable for bore

of 150 mm. dia. or more having three phase

motor capacity not more than 5 H.P. with

following capacity . Lifting and Lowering

taken extra.(R&B Sor year 2023-24,Item

(A) (8 stage) 240 to 200 LPM discharge at

1.00 to 78 mtrs. head respectively suitable for 33000 Nos.

50mm dia. delivery pipe

Lowering of submersible motor pump set at

the depth of following ,complete with required.

Nos. and size of casing pipes erected by means

of proper chain pulley block & pipe wrenches

after checking of threads of each pipe with

coupling to take the load of the pump set and

pipe assembly filled up with water (R&B Sor

year 2023-24,Item Code-9-6-18.)

1.00 (B)Above 60 mtrs. and Up to 120 mtrs. 2543 Nos.

Providing and erecting ISI marked PVC

insulated PVC Sheathed Flat flexible

6 Submersible copper cable approved make of

following Size. (R&B Sor year 2023-24,Item

125.00 (C) 3 Core x 4 Sq. mm 145 Mtr.

Providing and erecting Sheet Steel powder

coated MCB distribution board - flush /

surface mounted fitted with busbar, neutral

link, earth bar and DIN rail, Conforms to IS

7 8623-1 & 3, IEC 61439-1 & 3 without MCB to

house appropriate nos. of MCBs.(The DBs

should be used of same company of MCB to

be used) (R&B Sor year 2023-24,Item Code-3-

Ahmedabad Municipal Corporation

(B) three phase incoming and single phase

horizontal type outgoing Per phase isolation

(b) sheet steel double door

1.00 (i)4 way 2885 Nos.

Supply of following size of TOP & BOTTOM

accessories i.e. Adaptor set (CI) long, pump

guard set, starter pipe Rubber ring for

submersible pump & UPVC column pipe as

8 directed by Engineer - in - charge with

necessary plumbing as desired.(R&B Sor year

2023-24,Item Code-9-7-17.)

(A) 40 mm dia. 1010 Nos.

Supplying of following size of HEAVY

9 UPVC column pipe with coupler and wire lock

(R&B Sor year 2023-24,Item Code-9-7-19)

75.00 [C] 40 mm dia 219 Mtr.

Supply of following size of TOP & BOTTOM

accessories i.e. Adaptor set (CI) long, pump

guard set, starter pipe Rubber ring for

submersible pump & UPVC column pipe as

10 directed by Engineer - in - charge with

necessary plumbing as desired.(R&B Sor year

2023-24,Item Code-9-7-20)

1.00 [C] 40 mm dia 509 Mtr.

Providing and fixing ball cock of

11 10 approved.quality as directed.(A) Copper Metal 550 Nos.

Providing layingand jointing intrue lineandlevel 15mm

dia.U.P.V.C.Pipe(SCH-40) for coldwater including

fittings as approved by Engineer In Charge.Pipe shall be

fixed on the wall with the help of clamp at every two

12 50 metre C/C or shall be concealedas directed 71.93 Mtr.

includingnecessary fittings etc. including testing of pipe

and joints and fixing the same with adhesive solvent,

including cost of all materials.(R&B Sor year 2023-

24,Item Code-23061)

Providing layingand jointing intrue lineandlevel

25mmdia.U.P.V.C.Pipe(SCH-40) forcoldwater including

fittings as approved by Engineer In

Charge.Pipeshallbefixedonthewallwiththehelp of clamp

at every twometre C/C or shall be concealedas directed

13 15 includingnecessary fittings etc. including testing of pipe 90.93 Mtr.

and joints and fixing the same with adhesive solvent,

including cost of all materials.(R&B Sor year 2023-

24,Item Code-23062)

Providing layingand jointing intrue line and level 40mm

dia. U.P.V.C. Pipe (SCH-40) forcold water including

fittings as approved by Engineer In Charge. Pipe shall be

fixed on the wall with the help of clamp at every

14 275 twometre C/C or shall be concealedas directed 146.65 Mtr.

includingnecessary fittings etc. including testing of pipe

and joints and fixing the same with adhesive solvent,

including cost of all materials.(R&B Sor year 2023-

24,Item Code-23064)

Ahmedabad Municipal Corporation

Providing, laying and jointing intrueline and level

diametreU.P.V.C (Type B) conforming to IS 13592-1992

with one end plain and other end socketed with rubber

ring, & fittings conforming to ISI 14735-1999 of

approved make for drainage system pipe line, pipe shall

be jointed with each other with rubber lubricant,pipe

shall be fixed on wall using of PVC clamp of the size

15 50 160mm diametre x 210mm lengthx196mm heigh at every 822.99 Mtr.

2000mm center tocenter or shall be concealed in walls as

directed including necessary fittings suchas bends, shoes

etc. including testing of pipes and joints and jointedwith

adhesive solvent cement including cost of all

materials.(R&B Sor year 2023-24,Item Code-23066)

Providing, laying and jointing intrue line and level

diametre U.P.V.C (Type B) conforming to IS 13592-

1992 with one end plain and other end socketed with

rubberring,& fittings conforming to ISI 14735-1999 of

approvedmake for drainage system pipe line, pipeshall be

jointed with each other with rubber lubricant,pipe shall

be fixed on wall using of PVC clamp of the size 110mm

16 30 diametre x149mm lengthx145mm heigh at every 826.88 Mtr.

2000mm center to center or shall be concealed in walls as

directed including necessary fittings such as bends, shoes

etc. including testing of pipes and joints and jointedwith

adhesive solvent cement including cost of all materials

(R&B Sor year 2023-24,Item Code-23067)

Providing and fixing PVC SWR Nahni trap IS 14735 for

drain- 100mm diameter with jali of the following

nominal diameter of self cleansing design withC.Iscread

down or hinged grating including the cost of cutting and

making good the walls (R&B Sor year 2023-24,Item

Constructing Manhole with R.C.C. top slab in 1:2:4 mix

(1-cement :2-coarse sand : 4-graded stone aggregate

20mm nominal size) foundation concrete 1:3:6mix (1-

cement :3- coarse sand:6-Brickbats 40+50mmsize) inside

plastering 15mm thick with Cement Mortar 1:3 (1-

Cement : 3-coarse sand) finished with a floating coat of

neat cement and making channels in cement concrete

1:2:4 mix (1 Cement :2-Coarse sand :4-stone aggregate

20mm nominal size) finished smooth complete including

18 1 curing and festing(i) Inside size 900mmx1200mm 10920.76 Nos.

and1.5M.deep including C.I.cover with frame size

560mm diameter total weight of cover and frame to be

not lessthan128kgs. (Wt.of cover 64Kg.and Wt.of frame

64Kg.)(A)With 230mm thick wallsof brick msonry using

brick having crushing strength not less than 35Kg. /

Sq.cm. in CementMortar 1:5 (1-Cement:5-Coarsesand)

(1)A type depth 0.90 Metre for 150mm diameter

sewer.(R&B Sor year 2023-24,Item Code-24008A)

Ahmedabad Municipal Corporation

Constructing Manhole with R.C.C. top slab in 1:2:4 mix

(1-cement :2-coarse sand : 4-graded stone aggregate

20mm nominal size) foundation concrete 1:3:6mix (1-

cement :3- coarse sand:6-Brickbats 40+50mmsize) inside

plastering 15mm thick with Cement Mortar 1:3 (1-

Cement : 3-coarse sand) finished with a floating coat of

neat cement and making channels in cement concrete

1:2:4 mix (1 Cement :2-Coarse sand :4-stone aggregate

20mm nominal size) finished smooth complete including

19 1 curing and festing(i) Inside size 900mmx1200mm 19139.07 Nos.

and1.5M.deep including C.I.cover with frame size

560mm diameter total weight of cover and frame to be

not lessthan128kgs. (Wt.of cover 64Kg.and Wt.of frame

64Kg.)(A)With 230mm thick wallsof brick msonry using

brick having crushing strength not less than 35Kg. /

Sq.cm. in CementMortar 1:5 (1-Cement:5-Coarsesand)

(1)A type depth 1.5 Metre for 150mm diameter

sewer.(R&B Sor year 2023-24,Item Code-24008B)

(I) Extra rate for constructing B.B.masonry for every

additional depth of 0.1M.or Part there of over item

20 1 No.24008B (I) for depth from 0.9M to 1.5M.(R&B Sor 517.78 Nos.

year 2023-24,Item Code-24009A)

Constructing Brick masonry road gully chamber

500mmx 450mmx 600mm including 500mmx 450mm

21 1 C.I. horizontal grating wih frame complete.(R&B Sor 1997.22 Nos.

year 2023-24,Item Code-24013A)

Providing and fixing S.W. gully trap with C.I. grating

brick masonry chamber and water tight C.I. cover with

22 11 frame of 300mm x 300mm size (inside) with standard 2520.65 Nos.

weight. (i)Square mouth traps.(B)150mm x 100mm size

P or R type (24014)

Constructing brick masonry chamber for underground

C.I. Inspection chamber and bends with bricks having

crushing strength not less than 35Kg/Cm2 in C.M.1:5

C.I. cover with frame (Light duty) 455mmx

610mmintenal dimensions total weight of coverwith

frame to be not less than 38Kg. (Wt.ofcover23Kg.) and

Wt.of frame15Kg.) (R.C.C. top slabe with 1:2:4mix (1-

23 1 cement :2 coarse sand:4-graded stone aggregate 20mm 3624.51 Nos.

size) foundation concrete 1:5:10 inside plaster 15mm

thick with cement mortar 1:3 finished smooth with a

floating coat of neat cement onwalls and bed concrete

etc. complete.(ii) Inside dimensions 500mm x 700mm

and 450mm deep for pipe line with one or two inlets.

(R&B Sor year 2023-24,Item Code-24016BA)

Providing and placing on terrace polyetheylene(HDPE)

water storage tank with minimum double layer approved

brand and manufacture with cover and suitable locking

arrangement and making necessary holes for inlet and

outlets and over flow pipes with fittings and base support

24 1 for tanks including cost and conveyance of all materials 18000 Each

and labour charges , overheads & contractors profit

complete for finished item of work. - 1500 litres.

Cost includes freight, lifting and tank

inlet,outlet,Overflow connection

Excavation for pipe line trenches for water supply,

sewerage line, manhole, etc. all with shoring and struting

if required as per required gradient and line including

safety provisions using site rails and stacking excavated

stuff including up to all required loead cleaning the site

etc. complete for all lifts and strata as specified.

(a) in hard murrum, boulders incl. macadam road.

Ahmedabad Municipal Corporation

Excavation for pipe line trenches for water supply,

sewerage line, manhole, etc. all with shoring and struting

if required as per required gradient and line including

safety provisions using site rails and stacking excavated

stuff including up to all required loead cleaning the site

etc. complete for all lifts and strata as specified.

(a) in hard murrum, boulders incl. macadam road.

Bore well - 6''diameter pipe drilling with labour charge &

pipe lowering depth 200 mtr.Inclusing following items :

Gravel packing (HSN : 251710) (5%)Air compressor

minimum 3 hrs. HSN : 995434) Top line lowering charge

for air compressor.(HSN : 995434) Cement celling

charges (HSN : 995434) Electro logging testing charges

(HSN : 995434) 6" Diameter pipe LCG JOHNSON

TYPE APOLO MAKE OR JOHNSON MAKE brand

(HSN : 7306) 6" Diameter pipe TATA MAKE C-

CLASS brand (HSN : 7306) 6" Dia Stainer 1/16

STAINER (HSN : 995434) 6" Diameter pipe support

27 0.00 welding and fitting charges.(HSN : 995434) Charges for 825625 Each

carting bore pipe to site (HSN : 995434) Pipe truck

loading and unloading charge (HSN : 995434) Charges

for pipe double welding and fixing centre guide. (HSN :

995434)6" dia bottom seal, clamp, top seal with

boult.(HSN : 995434) Geohydrological

investing/Geophysical survey work by

Scientist/Geologist. Labour charges for packing mad

surrounding bore well. Pits necessary for Drilling

NOS. Water tanker required for drilling water tanker

Mud carting tanker charges. Charges for clay ball per

Providing and laying Granite slab (18 mm

thick) one side polished flooring over

mm (average) base of cement mortar 1 :

(1cement : 6 coarse sand) or L.M 1:1.5 laid

28 30.92 and jointed with grey cement slurry 1347.46 sqm

including rubbing and polishing complete

as per Instruction by Site Incharche

( Ahmedabad City SOR 2023-24 Item Code

M253 Page No. 15 )

Providing and laying White glazed tiles 6 mm

thick in skirting risers of steps and dedo on

mm thick cement plaster 1:3 (1 cement:

coarse sand) and ointed with white cement

slurry Ahmedabad City SOR 2023-24 Item

Code 14009AA Page No.

Providing and laying Vitrified tiles 8-10 mm

thick, 24"x24" in flooring treads f steps and

landing on a bed of 12 mm thik cement mortar

30 4.00 1:3 (1 cement: 3 coarse sand) and finished with 1062.50 Sq.M.

flush pointing in white cement Ahmedabad

City SOR 2023-24 Item Code 14008CA Page

Ahmedabad Municipal Corporation

Providing and fixing flush door shutters , solid

core construction with frame of first class hard

wood with cross board and face vineer or

plywood face panels, including anodiesed

31 3.25 aluminium butt hinges with necessary screws 1779.97 Sq.M.

(B)non decorative type and block board core

anodised aluminium butt hinges in flush door

shutters (2) 35 mm thick Ahmedabad City

SOR 2023-24 Item Code 10011 Page No.

Providing and fixing standared extruded of

alluminium section of size 63mmx 38.10mmx

1.2mm@Wt. 0.643Kg/mt with colour anodized

32 0.72 alluminium frame for ventilation with 5mm 1163.92 Sq.M.

thick frosted glass as details etc complete

for Ventilation Ahmedabad City SOR 2023-24

Item Code 11030 Page No.

To provide Tractor with Hydraulic Trolley,

driver with fuel, to carryout different works

during day/night for 8 Hrs. Shift.Work shall

be carried out as per the instructions of

Engineer In-Charge. No extra charged shall be

shift. ( Ahmedabad City SOR 2023-24 Item

Code H033 Page No. 43 )

Providing & Supplying JCB Machine

/ Hydrolic excevatorcapacity @ 60 cum per

hour ( Ahmedabad City SOR 2023-24 Item

Code H016 Page No. 34 )

To provide Pavadi tractor with all tools, driver

and Fuel to Remove existing Soil on

Different roads.Work shall be carried out as

35 1.00 per the instrucitons of Engineer In-Charge. No 245.00 Hour

extra charged shall be paid for night shift.

( Ahmedabad City SOR 2023-24 Item Code

H033 Page No. 34 )

Providing & fixing selected Seating Banches

as per instruction by Engineer in charge.

Ahmedabad Municipal Corporation

Supplying and fixing of 300 mm-L x 150 mm-

B x 380 mm- H Kerb block for Footpath in

M-20 grade using 20mm nominal size black

trap aggregate of Sevaliya/Timba or

equivalent quality for pre-cast blocks,

reasonably exposed finish/ formwork , mould

with well equipped with vibratory system for

kerb stones of approved design including

curing, etc. complete, including the cost of

formwork etc. complete. The rate shall also

include necessary cutting of asphalt, fixing

37 225.00 the Kerb stones in line and level on 5 cm thick 376.43 Rmt.

sand bedding with necessary equipments and

materials. The rate shall also include the

flush pointing in CM (1:3) for all joints of

the kerbstones. Filling of zari alone the sides

of the kerb stone fixed with Bituminous

concrete Bituminous concrete / C.C. mixed

in proper position to flush with the road

surface as directed by Engineer in change

to form a portable mixture. ( Ahmedabad City

SOR 2023-24 Item Code 14023A Page No.

Note :‐ All the item rate are considering excluding cost of GST as per Government of Gujarat Road And Building Dept. Reso. No.

TNC/102022/457/C Dt.05/04/2022. So, bidder shall be consider this change in BOQ.

Seal and Signature of the Bidder Addl. City Engineer

Date: Ahmedabad Municipal Corporation