Annual Rate Contract Tender for Erection, Maintenance and Dismantling work of Overhead HT/LT LINE, TC & HT/LT AB Cable under NARDIPUR S/Dn, KALOL DO, UGVCL

1 Tender Notice No. KLL-DO-17-2025-26 / Sr No-4

Annual Rate Contract Tender for Erection,

2 Tender Item Maintenance and Dismantling work of

Overhead HT/LT LINE, TC & HT/LT AB Cable

under NARDIPUR S/Dn, KALOL DO, UGVCL

3 Estimated cost 4761848/-

Tender Fees plus applicable GST (Non Refundable)-Can be accepted

4 in cash (up to Rs. 10000 only) at the office address specified in the 1180/- (1000+18% GST) As per prevailing

purchase policy (As Per Annexure-D)

tender document or by RTGS/NEFT/online Only.

EMD Amount in Rs.

(If EMD amount more than 3.00 Lakhs in that case EMD can be

accepted by RTGS/NEFT/online/BG/DD/Pay Order/Banker’s

5 40000/- EMD amount 1% of Estimate Cost

Cheque. otherwise paid either in cash (up to Rs. 10000 only) at the

office address specified in the tender document or by

RTGS/NEFT/online Only.

6 Security Deposit (For successful bidder) 5% of cost of LOA

7 Online Preliminary, Technical & Price bid, i.e. On line (e-tendering) Date :- 23-03-2026 ,18:00 Hrs

tender /offer , submission last date (This is mandatory)

Original Documents Relevant to tender Fee & EMD (if not paid

8 through online mode) (By Registered Post A.D. or Speed Post only) Date :- 23-03-202618:00 Hrs

submission last date.

(This is mandatory)

9 Date and time of opening of preliminary bid (Tender Fee & EMD Date :- 24-03-2026, 11:00 Hrs

Online and offline)

10 Date and time of opening of Technical Bid online (Tentative if possible) Date :- 24-03-2026 11:00 Hrs

11 Date of On line Opening of Price Bid Online (Tentative, if possible) Date :- 24-03-2026, 12:00 Hrs

12 Bid Validity 180 Days

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

1. Tender & relevant documents are to be submitted online and only Demand Draft / BG / self-

certified receipt of payment required to submit against TENDER FEE/EMD is to be sent by R.P.A.D /

Speed Post - Otherwise tenders will not be accepted.

2. Date of D.D. for Tender Fee and EMD must be on or before last date and time of on line

submission of tender.

3. Price bid/Technical Bid if submitted in physical form, same will not be opened and only online

submitted price bid/technical bid will be considered for evaluation.

4. All the bidders, in respect of the tender item must have vendor registration with the DISCOM

/ GUVNL or their subsidiary companies prior to the date of opening of technical bid.

Otherwise their bids will not be considered eligible for technical scrutiny and as such, their

technical bids will not be open.(Optional)

5. Any technical questions, information and clarification that may be required pertaining to this

tender should be referred to competent authority.

6. Any deviation found in online Data/Details/Documents in offer (e-tendering) of bidder, offer

of the same bidder will not be considered and no any further communication in the matter

will be entertained.

7. UGVCL reserves the right to reject any OR all tenders without assigning any reasons thereof.

8. UGVCL BANK DETAILS:

Name of Company : UTTAR GUJARAT VIJ COMPANY LIMITED

Bank Name : BANK OF BARODA

Bank Account No :

IFSC Code : BARB0KALOLX (Fifth Letter is ZERO)

Type of Account : Non Operative Account

Superintendent Account Executive Engineer

Exp. Section, DO.,KALOL

DO.,KALOL UGVCL.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

The contractor will have to give the following undertaking on Rs.300/- notarized

stamp paper: (within 15days from the date of LOA)

1. If this tender be accepted, contractor shall agree to abide by and fulfill all the terms and

provision of the Tender and contract of works as applicable and in case of default thereof

to forfeit and pay to the Company the sum of money due.

2. The value of EMD paid herewith should be absolutely forfeited to the company, if contractor

fail to deposit the full amount of specified security deposit, within specified time limit.

3. The contractor shall co-operate with the Company inventory etc. He shall submit all the

requirements which are necessary to finalize his outstanding bills within 10 days from the

date of completion of work, failing which the Company shall finalize the account on the basis

of its inventory records and initiate action as per company’s discretion.

4. The competent authority can delete any item in schedule “B” in the tender, if he feels that

the rate quoted by the contractor for that item is abnormally high when compared to

the estimated rate.

5. In case of any dispute, concern EE/SE will be the final authority for deciding the same and his

decision will be final and binding on the contractor and Department and no further

appeal will be entertained.

6. The contractor will have to see that safety equipments are used by his labours, while working

on the line, equipment etc. contractor will be responsible for any accidents.

7. The contractor will have to under taken responsibility of accidents etc. for his persons

working on the line.

8. The contractors will have to take insurance of suitable amount for his labours.

9. Contractors will have to carry out the work under his eligible and authorized supervisor.

However the work is to be done as per standards and under supervision of UGVCL.

10. The Company does not bind itself to accept the lowest or any tender neither with any reason

be assigned for the rejection. It is also not binding on the company to disclose any analysis

reports on the tender.

I/We hereby agreed and bound for all above conditions mentioned.

Name of Contractor: Signature

Full Address:

Contact Detail

Place: Date:

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

GENERAL DEFINITION FOR BIDDERS

1. DEFINITION

1.1 The "UGVCL" shall mean the Executive Engineer ,DO KALOL, UTTAR GUJARAT VIJ COMPANY LTD.,

having its corporate office at Mehsana. With expression shall unless repugnant to the context include its

permitted assigns or successor / authorized representatives.

1.2 The "Contractor" / Successful Bidders shall mean the Bidders, whose tender has been accepted by the

UGVCL for award of the contract and shall include his authorized representatives.

1.3 The "Engineer-in-Charge" shall mean the authorized officer of the UGVCL to act as Engineer-in-Charge to

supervise the work – for the purpose of the contract.

1.4 The "Specification" shall mean the tender forming a part of the contract along with Performa, schedules

and drawings.

1.5 The "Order" shall mean the official letter issued by the UGVCL, informing the bidder that his tender has

been accepted.

1.6 The "Contract" shall mean the agreement to be entered into by the UGVCL with the contractor and shall

include the commercial technical and general conditions, schedules, drawings and any other conditions

specifically agreed between the parties forming a part of the contract.

1.7 The "EMD" shall mean Earnest Money Deposit.

1.8 The "Contract Value" shall mean the total amount indicated in the contract agreement as per order

1.8 The "Contract Value" shall mean the total amount indicated in the contract agreement as per order

placed by the UGVCL and calculated from the quantities indicated in the tender.

1.9 The "Completion Period" shall mean the period starting from the date of issue of "Order" and required

to complete the work in all respect.

1.10 The "Work" shall mean activities to carry out for the entire scope of this Tender.

1.11 “Inspector” shall mean the any person nominated by UGVCL from time to time to inspect the works

under the contract and/or duly authorized representative of the UGVCL.

1.12 “Letter of Award” shall mean the official notice issued by the UGVCL notifying the contractor that his

bid has been accepted.

1.13 “Date of Contract” Shall mean the date on which Letter of award has been Issued.

1.14 “Month” shall mean the calendar month day or days unless herein otherwise expressly defined shall

mean calendar day or days of 24 hours each.

1.15 “A Week” shall men the continuous period of seven days.

1.16 HT means High Tension electric line

1.17 LT means Low Tension electric line,

1.18 Testing: - After completion of work execution required Tests are to be taken in presence of Engineer in

Charge whenever required.

1.19 Definition of “Similar work” for overhead network: Erection, Maintenance & Dismantling work of

Overhead HT/LT Line, TC & HT/LT AB Cable overhead electrical Network up to voltage level 22 KV.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Important instructions for submitting the Tender

1.0 Executive Engineer ,DO KALOL, UGVCL has invited Tender for Labour charges for erection,

maintenance & dismentaling work of Overhead HT, LT line, T/C & HT/LT AB Cable under

NARDIPUR Sub-Division for various scheme of KALOL Division from the contractors / firms who

have executed works of similar nature and magnitude successfully and who are registered

under appropriate class.

2.0 Physical submission of Tender documents shall be for EMD and Tender fee cover only.

Bidder has to upload scanned copies of original (Notarized/self-attested copies of original- as specified

in tender document) documents with bid and no physical document to be submitted by bidder.

In case of short submission of documents with bid and/or clarification if any required from the bidder,

the required detail/documents may be asked from bidder in physical form.

It shall be sole responsibility of the bidder that the uploaded scanned documents (in PDF Form)

remain legible and should not be password protected.

3.0 Technical & Commercial.

3.1 Technical bid is to be submitted only in online. The below mentioned documents should be

submitted in form of self-attested true copies along with technical bid in N Procure Site

Only. No physical documents to be submit by bidder at KALOL Division Office UGVCL.

(i) Solvency certificate issued from any Nationalized/scheduled Bank of RBI & not older

than 12 month amounting of 20 % equivalent of estimated cost (as per UGVCL Rules).

(Duly Attested).

(ii) Separate EPF Code No. allotted by RPFC & Last Six month of current year EPF Challan

paid copy is required if applicable.

(iii) Vender Registration certificate as contractor in UGVCL. Bid of the bidder without

vender registration, will not be consider for further evaluations.

(iv) Last three financial year income tax return copy if applicable.

(v) Work experiences of the bidder shall be considered only if the works have been

executed under Public electrical utility of Central or State Govt. in India / Government

Sector / Power Utility (Government or Private) / Power sector PSUs & Power Sector

CPSUs. and also include option-II experience if work has been executed under

supervision of UGVCLs Engineer in charge with PO/WO issued by respective firm and

work should be certify by Executive Engineer. Work carried out for similar nature like

erection, maintenance & dismantling of overhear HT/LT line, TC & HT/LT AB Cable shall

have to be considered as a work experience and experience certificate should be issued

by order issuing authority (Not below the rank of Executive Engineer).

(vi) For qualifying the experience criteria; bidder shall submit Copy of Work Order (showing

the statement of quantity & amount in Rs.), work completion certificate (showing

amount of actual work completed) up to last 7 years as per Annexure-A with Experience

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

certificate. Satisfactory work completion certificate for erection of Overhead HT-LT line,

T/C & HT/LT AB Cable work by authorized officer of Distribution Company. Copy of the

annual work orders with amount of erection of Overhead HT/LT line, T/C & HT/LT AB

Cable of any Distribution Company is also required for supporting documents.

(vii) Group Insurance: -A copy of the insurance policy of the insured labourer’s under W.C.

(viii) The contractor will have to under taken responsibility of accidents etc. for his persons

during working on the line and same will be on notarized stamped paper of Rs. 300/- or

the appropriate value (if revised by Govt.) within 15days from the date of LOA. The cost

of stamped will be borne by contractor.

(ix) List of Tools & Tackles and safety equipment’s available with contractors as per

Annexure-B.

(x) Copy of the Electrical contractor license issued by the Office of Govt. of Gujarat. The

contractors outside of Gujarat State must have to take approval from Government of

Gujarat for Electrical Contractor license.

(xi) Labour license if applicable.

(xii) Copy of GST Registration Certificate duly attested.

(xiii) Copy of Permanent Account No. (PAN) duly attested.

(xiv) Details of Partners / Directors of Firm / Company.

(xv) Contractor’s Store address along with proof.

(xvi) Other documents (if required by authority).

(xvii) Bidder has to submit the copy of complete type test reports / certificates of offered

make of major supply items (Any make approved by GUVNL & Its Subsidiaries

Company) as required in overhead work. The Certificates / reports should not be older

than 7 (Seven) years

(xviii) Bidder has to provide the authorization letters from the manufacturer / authorized

dealer of offered make material. Guarantee also required from bidder as well as OEM /

authorized dealer.

(xix) Experience as a sub-contractor shall not be considered for technical evaluation except

mentioned as per Clause No. 3.2 (v).

(xx) Bidder must have Skilled Supervisor having Supervisor License & Skilled Technical staff

& labour for execution of work.

(xxi) Bidder must submit required document such as RTO Registration or a valid tie-up agreement

with a service provider for pole erection device (PED Machine).

Those bidders who have successfully submitted all above requirements are to be considered

for further evaluation.

The above stated criteria are minimum and the UGVCL reserves the right to request for any

additional requirement and also reserves the right to reject the bid of any bidder, if in the

opinion of the UGVCL, the qualification criteria are not fulfilled.

Note: For tender estimated value below 5 Lakhs & ARC tender of estimated value more than Rs.

Lakhs, criteria stated at clause no. 3.2-(V) & 3.2-(Vi) shall not be applicable for New Bidders.

Quantity Allocation will be as per Clause No. 43 General terms and Condition.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

3.3 Technical Criteria for awarding the contract to qualified bidder is as under

Similar Nature of Work: The bidder should have successfully completed or substantially

completed similar nature of work i.e. Erection, Maintenance & Dismantling of overhead HT/LT

Line, TC & HT/LT AB Cable Work for 11kV and above class in last 7 years ending last day of

month previous to the one in which bids are invited should be either of the following:

The amount of work completed by bidder as per work completion certificate shall be considered.

i. Experience in single completed work of projects execution in electrical sub-transmission /

distribution sector costing not less than the amount equal to 70% of the estimated amount of

the tender.

ii. Experience in two completed work of projects execution each in electrical sub-transmission /

distribution sector costing not less than the amount equal to 40% of the estimated amount of

the tender individually.

iii. Experience in three completed work of projects execution each in electrical sub-transmission /

distribution sector costing not less than the amount equal to 30% of the estimated amount of

the tender individually.

The similarity of work shall be pre-defined based on the physical size, complexity, methods/

technology and/ or other characteristics described, and scope of works. Substantial completion

shall be based on 80 (eighty) per cent (value wise) or more works completed under the contract

(Note: Substantial completion should not be defined in terms of percentage completion, rather

it should be based on functional consideration. For contracts under which the applicant

participated as a joint venture member or sub-contractor, only the applicant’s share, by value,

shall be considered to meet this requirement. For arriving at cost of similar work, the value of

work executed shall be brought to current costing level by enhancing the actual value of work at

simple rate of seven percent per annum, calculated from the date of completion to the date of

Bid opening.

Certificate for ‘substantial completion’ of project/work/asset should contain two parts. Part -I

shall contain ‘financial value of work done’ and part-II shall contain ‘certificate of functional

completion of project/work/asset’.

3.4 Minimum Average Annual Turnover (MAAT) for last three years, ending 31 st March of the

previous financial year, of the bidder should be at least 30% of the estimated cost of the

tender. In this regard, separate notarized certificate from CA must be submitted.

3.5 Net-worth of the last Financial Year shall be positive.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Note: Turnover & Net-worth shall be certified by CA on his letter head and duly attested. Turnover

for preceding year shall be considered subject to submission of provisional / audited certificate

from CA by the bidder.

3.6 Details of Partners/Directors of the Firm/Company.

 Partnership deed in case of Partnership firm.

 Memorandum of Association & Article of Association in case of Company.

Note: For tender estimated value below 5 Lakhs & ARC tender of estimated value more than

Rs. 5 Lakhs, criteria stated at clause no.3.3, 3.4 &3.5 shall not be applicable for New Bidders.

Quantity Allocation will be as per Clause No. 43 General terms and Condition.

3.7 Payment of tender fee/EMD can be accepted by RTGS/NEFT in favor of UTTAR GUJARAT VIJ

COMPANY LIMITED.

Bank Name & Branch: BANK OF BARODA

A/C Num.:

IFSC Code: BARB0KALOLX (Fifth Letter is ZERO)

In case of cash payment (up to 10,000/-), the scanned copy of cash receipt shall have to be

uploaded with bid. In case of payment through DD/Banker Cheque/pay order/Bank Gaurantee,

the scanned copy of original document shall have to be uploaded with the bid and original copy

of the same will have to be submitted at the UTTAR GUJARAT VIJ COMPANY LIMITED Division

Office KALOL, within 3 days of specified last date of submission of tender.

The cancelled check of concern bidder is to be attached for further course action of payment as

per rule through RTGS/NEFT by UGVCL.

The tender fees once paid for tender document will not be refunded under any circumstances

or not transferred to other bidder.

3.8 EARNEST MONEY DEPOSIT (EMD)

The EMD payable, between the dates mentioned in Table no 1 only.

The EMD Amount is as per Annexure-E. The digital copy of amount transfer towards Tender fee

and EMD is to be uploaded with the tender documents.

The EMD of all unsuccessful bidders except that of the successful bidder will be returned after

the award of the contract.

EMD of the successful bidder to whom a contract is awarded will be returned after the said

bidder pays the security deposit and signs the contract agreement.

If the successful bidder fails to submit a Security Deposit within 15days from the date of LOA of

the contract or fails to sign the contract agreement, then the EMD amount will be forfeited in

favour of UGVCL without any notice or and action for “Stop deal” will be initiated as decided by

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

No interest will be payable by the UGVCL on the above Deposit.

Tenders without Earnest Money Deposit by the firms/Name will be rejected without entering in

to further Correspondence in this regard and no reference will also be made.

Earnest money deposit will be forfeited in case the successful bidder after his tender has

been accepted shall refuse to pay the prescribed security deposit and execute the contract.

4 Tender Papers & Specifications may be downloaded from web site

https://tender.nprocure.com (To view, download and on-line submission of documents) and

UGVCL web site www.ugvcl.com (To view & download only).

5 Bidders should be in touch with websites https://tender.nprocure.com & www.ugvcl.com for

information regarding revision/corrigendum/Amendment in tender till due date of online

submission and thereafter. No separate information shall be sent in this regards and also not

publish in newspaper.

6 It is mandatory for all the bidders to submit their tender documents/Technical bid with

scanned copy of Tender Fee and EMD evidence by on-line (e-tendering) upload in schedule

7 The Bidder must submit their Technical Bid & price bid online in electronic format only on N-

Procure web site till last date& time for submission. Offers in physical form will not be

accepted in any case.

8 Technical bid shall be opened on date (as mentioned) (If possible) in the presence of the

bidder, who remains present at that time.

9 The bidder shall have to submit their offer without any deviations in general terms and

conditions of the contract or in Technical specification/items. Tenders of such deviations may

also be rejected. Incomplete and conditional tenders shall not be considered.

10 UTTAR GUJARAT VIJ COMPANY LIMITED reserves the right to split up the work covered in the

scope of this contract amongst more than one contractor

11 Intending bidders should submit their tenders after studying all tender’s documents carefully

and visiting the site for satisfying themselves of actual site conditions, location and

accessibility of site and nature, extent of the work involved etc. Submission of tenders implies

that bidders have obtained all necessary information and other data required for executing

the work. No claim for extra charges on account of any misunderstanding or otherwise will

be allowed.

12 All approaches to the site shall be in the scope of bidders.

13 The successful bidder will not be allowed to give sub-contract of the works awarded to him

for any reasons what so ever without permission of the competent authority.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

14 In the experience certificate, contractor has to furnish the details of similar works executed

by him along with the list of equipments, tools and tackles and manpower available with him.

15 Price quoted shall be firm, till overall completion of the work under contract and there will

not be any price escalation.

16 Date of opening of “Price Bid” will be intimated later on to those Bidders who are qualified in

technical bid. “Price bid” of only qualifying bidders on the basis of Technical bid shall only be

opened. Price of bidders, who are not qualified technically as per requirement of technical

bid shall not be opened.

17 Offers shall be valid for the period of 180 days from the date of opening of price bid. Bidders

shall not withdraw tenders during the validity period, failing which their EMD shall be

forfeited during the period of 180 days.

18 All the works shall be carried out as per specifications attached with the tender as per REC

standards & Drawings. All materials procured (if required) should be confirming to relevant

Indian Standard issued by Bureau of Indian Standard and from approval of UGVCL.

19 Tenders, who do not fulfil all or any of the conditions of the tender found incomplete in any

respect, are liable to rejection.

20 A. The tenderer must quote his rate per unit specified in the schedule in figures as well as in

words. If there is difference between rates quoted in words and figures rates quoted in words

shall prevail. Further should there be any discrepancy between rate and amount that rates

shall prevail.

B. The bidder must clearly quote their rates in Schedule – B of this tender, in percentage

above than, below than or equal to, the tender rate in figure as well as in words.

applicable, in force at that time, The bidder must work out the total price of their tender

offered accordingly and the total amount should be clearly written in words & figure, in case

offered accordingly and the total amount should be clearly written in words & figure, in case

of any discrepancy whatever written in words shall prevail. Company shall at liberty to decide

the matter as it deem fit.

D. Any variation in rates etc will not be allowed on any ground once the tender submitted is

opened for consideration.

E. The tenderer’s own conditions of the contract will not be considered as forming the part of

the tender. The tenderers must send in their tenders, only if the Company’s conditions are

acceptable to them.

F. All corrections what so ever made in the tender rate must be signed fully with date by the

tenderer before submitting the tenders.

G. Rates must be quoted without any conditions. In case of divergence between rates in

figures and words; it will be constrained to read the rate most favorable to Company.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

H. The rate quoted should be in percentage higher /lower/rate to rate.

21 Bidders willing to participate in tender should have valid digital certificate / Digital Signature

as per Information Technology Act 2000 using which they can sign their electronic bids.

Bidders can also procure the same from (n) code solutions, a division of GNFC Ltd., who are

licensed certifying authority by Govt. of India.

22 AMENDMENT TENDER

At any time prior to the deadline for submission of bids, as mentioned in Table1, UGVCL may,

for any reason, whether at its own initiative or in response to a clarification requested by a

respective bidder, modify the bidding documents by amendments.

The amendment will be notified, only on UGVCL Website & n-procure website in case of on

line tender, UGVCL will bear no responsibility or liability arising out of noncompliance of the

same in time or otherwise.

Such amendments, clarification etc. shall be binding on the bidders and will be given due

consideration by the bidders while they submit their bids and invariably enclose such

documents as a part of the bid.

23 The tenderer Uttar Gujarat Vij Company Ltd. Reserves the right to reject any or all tenders

without assigning any reason thereof.

24 Conflict of Interest among Bidders/ Agents:-

A bidder shall not have conflict of interest with other bidders for particular quoted item. Such

conflict of interest can lead to anti-competitive practices to the detriment of Procuring

Entity’s interests. The bidder found to have a conflict of interest shall be disqualified. A bidder

may be considered to have a conflict of interest with one or more parties in this bidding

process for particular quoted item, if:

a) they have proprietor/ partner(s)/ Director(s) in common; or

b) they receive or have received any direct or indirect subsidy/financial stake from any of

c) they have the same legal representative/ agent for purposes of this bid; or

d) they have relationship with each other, directly or through common third parties, that puts

them in a position to have access to information about or influence on the bid of another

bidder; or

e) bidder participates in more than one bid in this bidding process. Participation by a bidder

in more than one Bid will result in the disqualification of all bids in which the parties are

involved. However, this does not limit the inclusion of the components/ sub-assembly/

assemblies from one bidding manufacturer in more than one bid.

f) in cases of agents quoting in offshore procurements, on behalf of their principal

manufacturers, one agent cannot represent two manufacturers or quote on their behalf in

a particular tender enquiry. One manufacturer can also authorize only one agent/ dealer.

There can be only one bid from the following:

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

1) The principal manufacturer directly or through one Indian agent on his behalf; and

2) Indian/ foreign agent on behalf of only one principal.

g) a Bidder or any of its affiliates participated as a consultant in the preparation of the design

or technical specifications of the contract that is the subject of the Bid;

h) in case of a holding company having more than one independently manufacturing units, or

more than one unit having common business ownership/ management, only one unit should

quote. Similar restrictions would apply to closely related sister companies. Bidders must

proactively declare such sister/ common business/ management units in same/ similar line

of business.

i) Bidder shall not act in contravention/ violation to the provisions of competition act, as

amended from time to time.

25 Every bidder should, at the time of submission of bid, give a declaration, that bidder shall not

have conflict of interest with other bidders for particular quoted item, as above.

26 For erecting pole the pits should be digging by using pole erection device (PED Machine)

wherever it is not possible to use PED machine in the area lick hard rock, small streets etc. the

permission of the engineer in charge shall be obtained for digging of pits as per conventional

27 INDEMNITY BOND

The successful bidder will have to give indemnity bond to UGVCL against any possible claim of

compensation for damage to Contractor’s equipment or staff or any of third parties during the

execution of work as per attached format.

28 LANGUAGE OF THE TENDER

All information in the bid shall be in English. Information in any other language shall be

accompanied by its translation in English. Failure to comply with this may disqualify a bid. In the

event of any discrepancy in meaning, the English language copy of all documents shall govern.

29 If any bidders firm or/and partner or proprietary firm anywhere in companies (PGVCL, UGVCL,

MGVCL, GETCO, DGVCL, GSEC) under GUVNL are under criminal investigation for any kind of

fraud for public and theft of material or/and with handlings the material and any civil and/or

criminal case pending at any stage than offer of such bidder /firm will be out rightly rejected.

30 Conditional bids shall not be accepted.

Signature of Contractor Executive Engineer

Name of Seal, Details Add. UGVCL, D.O._KALOL

With Cell No/Fax

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

TECHNICAL SPECIFICATIONS FOR THE WORK TO BE CARRIED OUT

For erection work 11 KV and L.T. Distribution lines and Transformer Centers.

(a) Erection of HT and LT Lines:

Site clearing and tree cutting, which come in the way of line, will be done by the contractor at

his cost. The Company will assist the contractor in getting necessary permission for tree

cutting etc. Any claim for compensation in above respect will have to be borne by contractor.

(b) Fixing of Pole Location:

The Points of pole structures, guys and earthing will be fixed by the department and will be

shown to the contractor. He should adhere to these locations in all circumstances unless

directed by the department to make any change. The Poles from One site to other site or at

proposed locations must be carted by loading on Tractor or Hand-Cart. The Poles shall not be

carted by toeing/Dragging with Tractor or Cart or with any other means.

(c) Pole setting:

Where poles are set in good solid ground, the depth of pit shall be 1/6 the height of the pole

and for grounds of any other nature, depth of pit shall be decided by the department. The

poles and guys must not be set at the edge of cuts or embankment where the soil is liable to be

washed or eroded out such setting should be avoided. While back filling, proper care should be

taken for filling of pit.

Extra payment is payable for hard soil or rock under the pole erection item which may be

quoted in the tender. The cost of damage done to the pole during erection will be

recoverable from the contractor. Pole, which is out of plumb/ out of alignment, shall not be

He should be able to render full account of the poles entrusted to him whenever the

Supervising Officer demands to scrutinize the same.

(d) Erection of Complete single Pole Structure

Erection of single pole structure comprises of shifting of pole from the stacking place in the

village, excavation of pit, erection in position (with base plate where required), of 8 meter,

meter PSC poles, 9 meter to 13 meter long rail or suitable size girder or any other suitable pole,

fitting of clamps and cross arms and fabricated materials, fixing of caution boards as per

drawing, and specification inclusive of painting numbering and anti climbing device. Generally

vertical formations will be used on each pole. However horizontal formations will have to be

used in special circumstances as per instruction of Engineer in charge.

(e) Special Two Poles Structure

Special two poles structure such as for HT line tapping, Railway crossing, any other HT/LT or

telephone line crossing, terminal structure for transformer substation comprises of Excavation

suitable pits and refilling of earth erection in position of two nos. of 8 Meter to 10 Meter PSC

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

poles. 9 meter to 13 Meter long rails or any other suitable poles fitting of clamps and cross

arms, bracing, cross bracing etc. as per drawing exclusive of mounting transformer but

inclusive of mounting D.O. fuses/ A.B. switches, numbering fixing of caution Board and anti

climbing device etc. The D.P. must be properly aligned and must be in plumb. Special structure

if included will be erected as per drawing supplied. Each Shackle Points must have “D” type

Jumpers only.

(f) Stringing of conductors

This includes stringing of stranded and solid bare conductor with fitting of necessary HT/LT Pin

and strain insulators, binding on insulators, jumpering. The jointing in HT line will be done

properly as per standard practice. Care must be taken in handling the conductor to protect

against cuts, scratches or kinks. The conductor must not be drawn over rough or rocky

ground, when it is liable to be damaged.

Wastage and cutting should be avoided as far as possible. Sag will be accepted as per RE

Standard in the materials account drawn for proper tension. The sag and spans will be

maintained as per drawing and design. The cross arms insulators must be so fixed that neither

tilts nor bands from position. The rate quoted should be per conductor route kilometer.

The span and sag, however, may vary according to sizes of pole available that these dimensions

will be specified by the field office before commencement of work. The sagging should be

uniform for all conductors and uneven sagging will not be allowed.

All the clearances should be maintained as per latest CEA (Measure relating to safety & Electric

Supply) regulation-2023 clause No-60 to

(g) Erection of Stay Set:

The erection of stay set comprises of anchor rod, turn buckle, eye bolt and excavation of

suitable pit of 4' depth, fixing of stay clamp on pole, binding of GI stay wire. The stay insulators

must be inserted in the stay wire on all stays as per drawing. The wrapping of the Guy wire

strands at both ends the stay insulator must be even and must presents neat appearance and

good workmanship. No stay should be left loose but should be tight and straight to withstand

in say cyclone or sand storm, the item includes refilling of earth and painting of fabrication

material. If stays are not required to be concreted, a pre casted cement concrete block will be

supplied by the department from his division store which the contractor will have to transport

at his own cost to the site of work and will have to use for fixing of anchor rod at site.

(h) Earthing:

The earthing arrangement shall be of pipe type/ plate type/ coil type as indicated in the

drawing. The earthing pipe/earthing plate/earthing coil supplied by the company shall be used

as per specification and drawing. GI wire no. 8 SWG for earthing should be bolted with

earthing pipe/earthing plate/earthing coil. G. I. Wire must be passed through PVC rigid Pipe

which must be buried at least 0.5 Meter in ground and to be kept 2.0 Meters above ground

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

along the Pole. The earthings are to be done at place as indicted in the pole schedule or

cost. Erection of earthing should be carried out by digging separate pit of 1.8 meter for each

earthing under the supervision of the in charge. No amount will be paid if the work is not

done in accordance with these instructions. At least 10 KG of charcoal and 10 KG of salt

should be invariably used by the contractor at his cost and refilled the earthing pit with the

alternate layers of coal / coke and earth. Earthing carried out in pit of pole will not be

considered and no amount will be paid for such type of earthings.

(i) Guarding:

The guarding will have to be provided between crossing of HT and LT lines, at the road

crossing, crossing of telephone and telegraphs line and such other places as indicated by the

department. The work comprises of fixing of guard cross arms, eye bolts, guard cradle as per

design, GI cross lacing wires complete. Any special type of guarding if required will be

designed and erected by the contractor as per requirement of department. The ground

clearance, line to line clearances etc. to be maintained as per latest safety regulation-2023 of

(j) Painting and Numbering:

Rail poles and girder poles shall be given one coat of approved red-lead paint and two coats of

approved aluminum paint, all fabricated material will also be painted in a manner shown

above, there should be sufficient interval between every coat of painting in order to allow for

drying. The bolts and nuts shall be dipped in anticorrosive oil before insertion. The lower

portion of steel poles up 3 fit above ground level shall be cleaned of all dust and rust. This

surface should be given a base coat of red lead and an additional coat of black bituminous

paint before inserting in the ground. The good quality paint will be supplied by the contractor

and should be of I.S.I mark and will be got approved from Executive Engineer, prior to starting

work. Name of the feeder and pole number has to be written on all the poles in English or

Gujarati as per instruction of Engineer In-charge. The colour of back ground and name /

number must be of contras colour. P.S.C poles need not be painted but should be properly

cleaned and all accumulations of earth, dirt etc, should be removed but fabrication material

has to be painted. It is suggested to get one coat of red oxide and two coat of silver paint at

the MS fabrication material.

(k) Muffling:

Unless Specified concreting is to be done for Girder Poles/Guys only. no any PSC Pole/Guys to

be concreted without any special reason. The Concreting of PSC Poles must be approved by

concerned Executive Engineer prior to execution. Concrete for Muffling of poles and stay rods

should be cement one part sand two parts and four parts metal (1:2:4). Muffling is not to be

done for PSC poles. Sand shall be clean and composed of hard siliceous grains. It shall be free

from clay or organic matter. Metal should be having sound hard and durable stone size ½” to

¾” sieve. Drawing of Muffing are attached.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

(l) TRANSFORMER CENTER:

The distribution transformer centre (10 KVA to 200 KVA) will be of outdoor type mounted on

two poles structures as per standard drawing and comprises of,

 Erection of poles with necessary earthings.

 One set of HT D.O fuses/ AB Switch.

 11KV 10 to 200 KVA transformers complete with its accessories.

 One set of HT lightning arrestors.

 Fixing of Distribution box, cross arms and branching with earthing as per drawing,

necessary wiring of appropriate size of cables.

 Stays with insulators, numbering, fixing of danger board and ant climbing device.

 Three independent separate pipe type earthing/plate earthing / coil earthing should be

provided on either side of the transformer center and one at middle of the transformer

center. One separate earthing for LA, one separate earthing for transformer neutral and

one separate earthing for transformer body and other metal parts including distribution

box. Each consisting of one or more earth connection to earth pit.

 The rate should be quoted inclusive of transportation of distributions transformer from the

Company's stores to the site of erection. The cost of damage done to the transformer is

recoverable from contractor.

(m) Stringing of HT/LT Arial Bunched Cable

This includes stringing of Arial Bunched Cable with providing and fitting of necessary

accessories like dead end clamps, suspension clamps, insulation piercing connectors, Eye

Hooks, HT termination kits, jumpering etc. Care must be taken in handling the cable to protect

against cuts, scratches or kinks. The cable must not be drawn over rough or rocky ground,

when it is liable to be damaged.

(n) INSTRUCTIONS TO BE FOLLOW BEFORE STARTING WORK

Before starting the work (New, alteration or addition) and during the progress of works the

contractor must obtain line clear whenever necessary from the concerned officers of this

department or other. During transportation or erection, if any accident occurs or any liability

arises due to non-observance of rules / instructions, contractor will be solely responsible for

All conductor, earth wire and stay set must be tight. Stay rod pit must be as per the

specifications. The entire pole must be in plumb. Fabrication fitting on pole must be tight.

Span of HT/LT line shall have to be kept as per site survey done by Engineer In-Charge and as

per site situation.

So long as the line is not handed over to the company, the responsibility of its safe custody

and of all fixture and materials etc. lying with that of the contractor will be that of the

contractor.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

PROCEDURE TO BE FOLLOW FOR GETTING MATERIAL FROM STORES

A. Issue of materials:

The following materials shall be supplied by the UGVCL free of cost for use on the works to the

contractor as required from RSO / Divisional Stores as well as from the sub-division store if

any. The transportation will have to be arranged by the contractor at his cost (except poles of all

List of Materials:

1. All types of Conductors & AB Cable.

2. The pole will be supplied by UGVCL at convenient place near place of work within 4 KM.

Contractor has to cart poles to the destination from the location where poles staked by

UGVCL within the radius of 4 KM at his cost.

3. HT-LT insulators with hardware.

4. All fabricated steel material with bolts and nuts.

5. Stay wire, G.I wire, earthing plate, earthing coil, earthing bolt, earthing pipes.

6. Distribution Transformer, LT Dist. Box, lightning arrestors, HT D.O. Fuse, AB switch with

accessories, PVC cable.

7. Danger board, anti climbing device of barbed wire.

8. Earthing plate/earthing coil/earthing pipe.

9. Stay set material.

10. All types of Bolts and nuts to be supplied by company as per availability in store, if not

Contractor has to provide the same and at the rate prescribed by company time to time in

statement of rates(SOR) will be reimbursed to the contractor.

The rates quoted should be inclusive of required all type of bolts and nuts (except LT Shackle

bolt) and transportation cost of all type of materials to site from the stores.

B. The quantities in the Schedule are approximate. Actual quantities may increase or decrease

according to the local conditions. The department reserves the right for revising or omitting

any of the quantities to be erected during the execution.

C. The contractor will draw and will be given only those materials and in anticipated quantities

that are just sufficient for the works to be carried out by him.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

D. The materials will be issued to the contractor himself or his duly authorized representative

only. The contractor at the time of drawing materials from the stores shall have to give letter

of authorization in triplicate to the concerned sub-divisional officers, specifically stating the

names of the persons who will draw materials form the store on his behalf and would sign the

requisitions for and on behalf of the contractor and shall be binding upon the contractor. In case

if any authority or power of attorney is to be terminated, written instructions in this respect

must be intimated by Registered Post to the Executive Engineer and concerned sub-divisional

E. The contractor should get the requisition, three days before requires the materials on site,

from the Engineer-in-charge, for the material as per technical sanction. All the materials

mentioned in the requisition should be issued from Divisional store to the name of contractor

with scheme. No any material should be drawn departmentally for the work allotted to the

contractor.

F. In case of loss or damage to materials, contractor will be responsible for the same, he has to

lodge FIR regarding loss of material. Action will be taken as per discretion of UGVCL, the cost of

the same will be recovered from the Contractor at stock issue rate plus 15% overhead charges

with applicable TAXES and shall be considered as final and unchallengeable.

All the materials issued by UGVCL shall be transported to the work site on same day and to be

preserved in safe custody at pre notified stores, failing to which UGVCL shall initiate Police

action. Similarly as per instruction of Engineer In Charge, you have to credit the material at

UGVCL store without any loss of time failing to which UGVCL shall initiate Police action.

G. The contractor will be fully responsible for any damage, breakage, loss or theft of materials

during transit or erection issued to him from stores till the time the work is handed over to and

taken over by the Company. The cost of damage shall be recovered from him as stated

above in F.

H. All materials supplied to the contractor shall remain the absolute property of the company and

shall on no account be removed from the site of the work and shall at all times be opened to

inspection by the Engineer in-charge.

I. Any such materials remaining unused and in perfectly good condition at the time of

completion of the contract shall be returned to the company store for which no carting charges

are payable to the contractor.

J. The contractor will have to make his own arrangements to keep the materials under lock and

key (i.e. Store) and address of all the stores to be submitted before commencement of work.

He will be responsible for theft or loss on account of any reason what so ever.

All the above instructions have been read by me thoroughly or have obtained the thorough

understanding of the same and are acceptable to me unconditionally.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

GENERAL TERMS & CONDITIONS

1) The work should be strictly as per specifications and approved drawings of the Company

which can be supplied by the Engineer In-charge for reference at the request of the

contractor. The inferior and unsatisfactory work is liable to be rejected.

Before commencing the erection of lines, the contractor will be provided with the schedule

and the detailed layout map (proposed sketch). The work will have to be carried out as per

programmed laid down by department and under the entire supervision of UGVCL’s deputed

supervisor and contractor should employ his qualified supervisor who could supervise the

works throughout and he should remain present on site.

Marshy or water logged locations must be avoided as far as possible. If it becomes inevitable

to locate poles at such points, special precautions about foundation will have to taken and

work carried out as per instructions of the Engineer In-charge.

No tools will be supplied by the department. The work if found inferior and not up to

standard of the Company is liable to be rejected at the risk and cost of the contractor.

Any expenditure incurred for rectification work carried out by department will be recovered

from contractor’s bills, if the contractor fails to rectify the inferior work done by him in spite

of the instructions to rectify the same.

Contractor will have to submit the certificate of their supervisor under whose supervision the

work has been carried out.

2) Acceptance of Tenders:

The Company does not bind itself to accept the lowest or any tender, neither will any reason

be assigned for the rejection. It is also not binding on the Company to disclose any analysis

reports of the tenders.

Accepting authority reserves the right of rejection of any or all tenders without assigning any

reason thereof.

Any tender who does not comply with the above requirements is liable to be rejected.

3) Security Deposit:

The successful bidder shall have to pay security deposit of within 15 days from the date of

issuance of LOI/LOA of an amount equivalent to 5% of the value of the work to be allotted to

him and as mentioned in LOI / LOA.

The Security deposit is payable the option of UGVCL by: (a) Demand Draft (b) Bank Guarantee

to cover execution period and, from any Nationalized /schedule Bank Payable at KALOL. The

Security Deposit will be returned to the Contractor without any interest after the successful

completion of work and submission of No Objection Certificate by concern office.

4) Contract Document:

The successful bidder, whose tender is accepted will have to execute a 300 Rs. stamped

agreement in standard form with the company and will have to sign the contract booklet viz.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Tender and contract for works at his own cost. In case of partnership firms, necessary

partnership documents, in original along with its copy will have to be produced for

verification along with authority to sign the bills measurement and enter in to contract as

well as correspondence with the company. Wherever required necessary power of attorney

will have to be produced especially when the partnership deed is silent on the point of

authority to deal with the Company. The contractor will have to execute the documents

and sign the booklet “Tender and contract for work” before starting the work.

If a contractor happens to be a sole trader he will have to produce an affidavit made before

Magistrate to that effect.

5) TAXES AND DUTIES:

5.1 Bought out items from vendors/sub-suppliers: All levies, duties, GST and Cess etc. payable

on equipment/material components, sub- assemblies, raw materials and any other items

used for the bidder's consumption or dispatched directly to the owner from its sub-supplier

and any such taxes, duties levies additionally payable shall be to bidders account and no

separate claim on this behalf shall be entertained by the UGVCL.

5.2 UGVCL’s GSTIN Registration Nos. is 24AAACU6551F1ZI

5.3 The bidder shall be liable and responsible for payment of all taxes as attracted under the

Provisions of the law.

5.4 “In case any tax or duty is newly introduced by the Government applicable for this

contract with effect from the next day of the date submission of the bid and if the contractor

is required to pay new tax or duty, then the owner shall reimburse the contractor the new tax

or duty so paid by the contractor against submission by the contractor of documentary

evidence to the satisfaction of the owner.”

5.5 At the time of payment, statutory deduction will be made as per applicable rules and

rates for TDS, WCT, welfare cess etc. All other statutory liabilities towards contract will be on

the part of contractor.

5.6 Before quoting, the bidder may ascertain from the concerned tax authorities of

Government the applicability of GST and Cess, etc. in respect of this work. No separate claim

in this regard will be entertained by the UGVCL, as it is the responsibility of the Bidder to pay

all these taxes.

5.7 Goods and Service Tax (GST): The F.O.R. destination prices are excluding GST and Cess as

applicable which will be paid extra on a given taxable goods and/or services within the

original contractual delivery period. The amount of GST/ and Cess as applicable should clearly

be indicated separately. (GST/Cess means all applicable Tax/Cess under GST Laws. GST Laws

means IGST Act, GST (Compensation to the State for Loss of Revenue) Act, CGST Act, UTGST

Act and SGSCT Act, 2017and all related ancillary legislations).

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

5.8 You shall have to submit a C.A Certificate & duly authorized Signatory of successful

bidder, certifying that you have not claimed Refund of any applicable GST/ and Cess, charged

to COMPANY or shall not claim any such Refund, on a future date, from the concerned

Authorities and if, any Refund, in respect of such GST/ and Cess, is claimed by you, it will be

immediately passed on to the COMPANY, without /COMPANY making any specific Claim, for

the same, either from the Department or from you.

5.9 The offers having price INCLUSIVE OF GST and Cess is likely to be rejected if the rate of

GST and Cess is not mentioned clearly unless the bidder has opted for Composition Scheme

under GST Act, which should be clearly indicated in the price bid. /COMPANY may at its

discretion consider such offer with presumption of highest applicable rate of GST/Cess

prevailing when the price quoted is inclusive of GST and Cess.

5.10 If the Supplier/Contractor has opted for the Composition scheme of GST, the same must

be clearly specified with valid Declaration & Certificate from Department. In the event of

withdrawal/cessation of the Supplier from Composition scheme during the tenure of the

contract, the rate mentioned in the price bid shall be final and any additional GST will have to

be borne by the Bidder. In no case additional amount towards tax or otherwise will be paid /

reimbursed to supplier/contractor. Further Statutory Variation clause will not be applicable in

case of Supplier / Contractor has opted for Composition Scheme under GST.

5.11 Supplier/Contractor should charge GST in Invoice at the rate as agreed to mention in

acceptance of Bid only and any deviation in the same shall not be accepted. Further, any

additional liability of GST (later on due to wrong mentioning of GST rate, mis-interpretation of

HSN/SAC Code, etc.) over and above as charged in the invoice shall be borne by the

Supplier/Contractor. However, any refund received by the supplier / contractor on account of

GST charged from the company; such refund shall have to be passed on to the company,

along with interest if any. Such refund along with interest needs to be passed on suo-moto by

the supplier / contractor.

5.12 Further, the Company has a right to recover the amount of GST along with penal interest

at the rate of 15% per annum if GST charged is not paid / short paid to the government or fail

to upload the details or uploads inaccurate particulars on GSTIN portal by the Supplier /

Contractor within the stipulated time limit.

5.13 In case, Govt. revises the rate of GST rate / Code during the tenure of the contract, the

provision of UGVCL’s statutory variation clause shall apply.

5.14 Input Tax Credit Benefit In the event of any statutory increase in the rate of Input Tax

Credit and / or due to inclusion of any other additional item of their inputs/input services

under the ambit of the Input Tax Credit provisions under the GST Act, subsequent to the date

of submission of the offer, the same should be passed on to COMPANY and you should

inform such changes to COMPANY from time to time

6) Statutory Variation / Changes in taxes

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Any statutory increase or decrease in the taxes and duties including GST and Cess as

applicable or in the event of introduction of new tax/cess or cessation of existing tax/cess in

the taxes subsequent to your offer if it takes place within the contract period will be UGVCL

account subject to the claim being supported by documentary evidence. However, if any

decrease takes place during contract period the advantage will have to be passed on UGVCL.

Statutory Variation clause shall not be applicable in case of Supplier / Contractor has opted

for Composition Scheme under GST.

7) Taxes, Permits & Licenses

The Contractor shall be liable and pay all foreign taxes, duties, levies lawfully assessed against

the Owner or the Contractor in pursuance of the Contract. In addition, the Contractor shall be

responsible for payment of all Indian duties, levies and taxes lawfully assessed against the

Contractor for his personal income & property only.

8) INCOME TAX –TDS & GST-TDS

“Income-tax at source GST-TDS at the prevailing rate will be deducted from bills in

accordance with the provision of Income-Tax Laws and to that effect a certificate will be

issued to the contractor, however added as contractor has to submit separate invoice for

supply parts item as well as works part item separately, otherwise TDS will be deducted on

entire invoice value.”

Applicable welfare cess will be deducted from contractors each bill by UGVCL to pay the same

to the respective Govt. Department. Tax will be deducted as per applicable statutory rules.

Contractor should quote accordingly i.e. inclusive of welfare cess.

Welfare Cess:

As per Welfare Cess Act, the welfare cess @ 1% is applicable and same is considered in price

THE WELFARE CESS WILL BE PAID TO CONTRACTOR ON ACTUAL WORK EXECUTED AMOUNT AS

PER CONTRACT.

The amount of welfare cess @ 1% of total bill amount is to be withheld from contractor

running bill in case of challan copy is not submitted along with invoice and will be released on

submission of challan of depositing the welfare cess amount to respective department.

The contractor shall deposit 1% welfare cess as applicable to respective government

department. UGVCL shall pay the welfare cess by way of reimbursement to contractor on

production of documentary evidence of payment deposited thereof by contractor.

The modality of payment/reimbursement of welfare cess will be as under:

[a] On receipt of A/T, the contractor/ bidder will get them registered under Welfare Cess Act

and submit the documentary evidence to the concerned office.

[b] Before release of payment of first R.A. Bill, the contractor has to submit the documentary

evidence of registration. Only thereafter, the bill will be processed for payment.

[c] Before release of payment of subsequent R.A. Bills, the contractor has to submit the

documentary evidence of payment of welfare cess of previous R.A. Bill.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

[d] Before release of payment of Final bill, the contractor has to submit the documentary

evidence of payment of welfare cess of previous R.A. Bill as well as of final bill on final bill

amount certified by UGVCL.

[e] Before release of payment in case of 1st & Final Bill, the contractor has to deposit the 1%

welfare cess on bill amount as certified by UGVCL and shall submit the documentary

evidence of payment deposited thereof.

[f] The contractor shall produce the receipt of payment of welfare cess from the respective

Government Department before submission of final bill otherwise final bill of the work

will not be finalized. Welfare cess payment will be reimbursed on production of evidence.

9) Jurisdiction:

Any dispute of differences arising under out of or in connection with the contract shall be

subject to the exclusive jurisdiction of KALOL.

Addressing Tenders: Tenders must be submitted in envelops which must be properly sealed

by the tenderers with their office seal and must be super scribed with the following.

(a) Tender No and the name of the proposed work.

(b) Returnable date and time of tender. It is the responsibility of the tenderer to see that the

tenders are received in company office or tender box within the stipulated time and date. The

envelop must bear full address of the tenderer.

10) Additions and alterations of any kind in tender forms, conditions etc by the bidder without

the consent of the undersigned are not permissible.

a. The bidder must quote his rate per unit specified in the schedule in figures as well as in

words. If there is difference between rates quoted in words and figures, rates quoted in

words shall prevail.

b. The bidder must quote his rates net lowest and the rates not confirming to the unit

specified in schedule may not be considered even though they may be lowest.

c. The rates must be stated for each item separately and in addition percentage of reduction

in the total price if any should also be quoted.

d. Any variation in rates etc will not be allowed on any ground once the tender submitted is

opened for consideration.

11) The rate quoted should be in percentage higher /lower / rate to rate.

12) The company’s general conditions of contract will apply to all the contractors and he is

deemed to be fully aware of the company’s general conditions of contract for the works

in respect of security deposits, penalty for late completion of work etc and any ignorance of

these conditions will not exempt the contractor from the liability to abide by the same.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Submission of a tender by the bidder implies that he has read that the instructions and

conditions of contract contained in booklet and has made himself aware of the scope and

specification of the work to be done and of the conditions and rate at which stores etc. will

be issued to him and local conditions and other factors bearing on the execution of work.

If the contractor stands lowest for more than one tender it will be at the discretion

of the competent authority whether to award more than one work or not without assigning

any reason thereof.

13) In case of any discrepancy between Tender Document condition and the General Conditions

of Contract attached to Tender Document, the condition mentioned in tender document is

14) Any amount payable by UGVCL / Any Circle Office of UGVCL / Any Division office of UGVCL

under any order / sub work order to the contractor can be adjusted against amount

receivable by UGVCL / Any Circle Office of UGVCL / Any Division office of UGVCL / GUVNL or

any of its subsidiary company. The contractor will have no objection whatsoever for the

15) Safety:-

Before starting any work by the labour of the contractor, it will be the responsibility of the

contractor to obtain line clear from the concerned officer / employee.

Successful Bidder has to follow all the rules and Regulations of Work Safety. Required tools and

Tackles for Safety are to be arranged by Bidder only.

No any work should be carrying out without supervisor of the company for safety point of

view. Contractors should observe all the safety rules during execution of work.

The contractor will have to see that labours working on the site should utilize all safety

equipment like helmet, safety belt, hand glows, safety shoes and tool-tackle. If any labour

found without safety equipment at site during execution of work, it is fully responsibility of

contractor for any accident occurred.

The contractor has to follow all labour laws, safety rules and regulations. The UGVCL does not

take any responsibility in case of accident or injury to the workers. The safety, security of

men, materials and equipment shall be sole responsibility of the contractor.

The compliances of all Central / State Govt. Rules, safety and insurance rules etc. and that of

local body is a must condition for the successful bidder.

The Contractor will strictly follow the safety Rules and Regulations during the execution of

aforesaid work. The Contractor will also provide all required Safety Gadgets to his Supervisors

and labours to execute the work mentioned in Tender. On violating or breaking the Safety

Rules and Regulations, and if Supervisors/Labours are found without Safety Gadgets, “The

Company” reserves the right to take actions as per the terms and conditions mentioned in

Tender without any prejudice.

The Company is not liable for any injury or damage to contractor’s workman or his

equipment respectively during execution of this contract and the Company will not pay

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

any compensation for any reasons whatsoever. The contractor is also responsible for any

damage to private property i.e. standing crops in farms or Gram Panchayat property etc.

16) The contractor shall not demand or accept any help from the intending consumers in line

erection works or in transportation of materials.

17) Whenever there is an excess work carried out by a contractor beyond the technically

sanctioned amount against the work order given, the approval for the excess quantity of

work done should be obtained from the competent authority as per Company rules.

18) The erection work should be started from the date of commencement given in the

order and should be completed within the prescribed period for each work. The

contractor is bound to complete the work within the specified period of each separate work

order given by Executive Engineer.

The contractor will be given the separate order for each work on the basis of the rate

contract order. The date of commencement and date of completion of work will be

mentioned in the order, which the contractor has to agree; otherwise the penalty will be levy

for the late completion of work as per Clause No.-32.

19) Priority of work would be decided by the Executive Engineer / Deputy Engineer of SDn and

contractor shall carry the work within the stipulated period of the order given by the

Executive Engineer.

20) You will have to submit fortnightly progress report regularly in duplicate to Engineer In

Charge and Executive Engineer KALOL DIVISION. If found that the work is unsatisfactory or

not progressing as per schedule then any action would be taken by the UGVCL as may

deemed fit to see that work is completed at the risk and cost of contractor. The completion

time allowed for each Sub work Order shall be strictly observed.

21) The contractor must have adequate resources and manpower of skill/unskilled personnel to

undertake the work at different places simultaneously.

22) The contractor will submit the final bill/ sub-work order bill within one months from the work

completion date.

23) The payment will be release within thirty days after submission of bill and all relevant

documents with invoice or part thereof whichever is later.

24) The contract will remain in force for the period of 02 year from the date of issue of work

25) TERMS OF PAYMENT:

a) The payment will be made to the contractor by ECS/RTGS/NEFT subject to an advance

stamped receipt being received from payee.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

b) The payment will be done after successful completion of scope of work of each sub-work

order after furnishing of the material accounts.

c) Mode of Payment: All payments under the Contract shall be made after the issue of work

certificates by the Engineer in charge, for the quantum of work completed.

d) Deductions from Contract: Price All costs, damages or expenses which the Owner may have

paid, for which under the Contract the Contractor is liable, or any other retention award will

be claimed by the Owner. All such claims shall be billed by the Owner to the Contractor

regularly as and when they fall due. Such bills shall be supported by appropriate and certified

vouchers or explanations, to enable the Contractor to properly identify such claims. Such

claims shall be paid by the Contractor within thirty (30) days of the receipt of the

corresponding bills and if not paid by the Contractor within the said period, the Owner may

then deduct the amount, from any amount due or becoming due by him to the Contractor

under the Contract or may be recovered by sections of Law or otherwise.

e) Terms of Payment: The owner shall pay to the Contractor as per the terms of payment

mentioned hereunder:

1. The bidder shall raise sub work order wise bills only after completion of all the specified

activities complete for each sub work order and the work for the next stage is continued.

2. 100% of the bills will be processed and paid within 30 days after submission bills at Sdn

with all relevant documents.

3. Payment of last sub work order shall be made after the work order is completed and the

line is handed over and accepted by the Engineer – in- Charge in all respects subject to

furnishing of performance guarantee of equivalent amount for the guarantee period.

4. The order value is based on the quantity, unit rates and values quoted and shall be subject

adjustment based on actual quantities executed and certified by the Engineer – in – Charge.

5. Payment of the actual material used and work done will be paid on above basis.

26) Presentation of Bills

The bills along with required documents for work executed including cost of material

consumed is to be prepared in Quadruplicate and submitted 03 copies to the concern Deputy

Engineer of Sub Division Office. These bills shall be serially numbered.

Contractor has to submit Bills along with required documents for work executed including

cost of material consumed material account along with quantities of work executed for each

item. Location wise inventory of all the material used is to be submitted in detail. All required

documents including EPF should be produced by the contractor along with bills.

Work Completion certificate duly signed by Contractor for which Bill is submitted.

For non-submission or part submission of above information, no bills shall be processed.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

27) Recording of measurements

If the work has been carried out satisfactorily, the contractor with prior intimation from the

Company Officers shall have to witness the inventory on the appointed date within the

days of the completion of work. If contractor fails to come to the appointed date a notice

under Registered cover with A.D. will be served on him to witness the recording of

inventory prior appointment with the Company officer within ten days of receipt of notice or

within such extended period applied for by the contractor and granted by the Company

Officer. If the contractor still fails to come for the recording of inventory within the original

or extended period of time granted by the Company officer then the recording of inventory

and recording of measurements thereof will be carried out thereafter unliterary by the Company

Officer and the same shall be finalized by the Company’s Officer and the same shall be binding

on the contractor, no request then will be entertained.

28) Submission of materials account by contractor:

The contractor shall submit material account with each bill. Also he shall on completion of the

work have to prepare and render the final detailed material account of the materials

received by him from the Company store within 15 days from the date of inventory, if

however the contractor does not render the material accounts a notice shall be issued to the

contractor under Registered A.D. to render the materials account within ten days from the

date of issue of the notice. On default, the material account will be finalized and the recovery

made as per the Company account and procedure which shall have to be accepted by

contractor and disputes if any raised shall not be entertained. The balance materials also will

have to be returned by the contractor within 7 days from the date of technical scrutinity from

Division office.

Material Accounting for work duly certified by Engineer- In-charge.

The contractor will not be allowed to transfer materials from one work to another without

the written permission of the Executive Engineer justifying the reasons for such transfer.

The contractor will have to use the materials on the work for which they have drawn.

29) On completion of work the contractor will inform the concerned DE in writing and DE will see

that if any rectifications are to be required, will intimate to the contractor within 15 days in

writing from the date of receipt of the letter from the contractor to complete the rectification

works within 7 days. If the contractor fails to do the rectification additions or alterations etc

within the above time limit, then the same will be got done through other agency or

departmental staff at the risk and cost of the contractor without giving any further notice

or any intimation. No complaint will be entertained from the contractor in this regard

and amount will be recoverable with 15% supervision charges.

30) Contractor has to take Earthing & utilization of CC Block in stay set certificate from the UGVCL

supervisor (Line Staff) and it is to be submitted along with the final bill.

31) Audit Inspection

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

UGVCL reserves its right to carry out random and surprise inspection at any time of the

ongoing work / completed work for ensuring its quality and compliance with the REC

standards OR CEA construction standards OR any Indian Standard OR Technical specifications

of UGVCL. If during such audit inspection, any violation of Standards OR Safety regulation is

observed, which may be unsafe for the general public or for the employee of Distribution

licensee, UGVCL shall intimate the Contractor immediately by any written communication

medium (either through mail / letter) and on such intimation, the contractor shall rectify such

defects, within such period, (as may be specified by the UGVCL, depending upon the quantum

of such defects) and shall submit the written report along with site photographs indicating

such rectification to the Engineer In-Charge. Nevertheless, following actions shall be taken

against the Contractor on detection of substandard work.

31.1 On first instance, a stringent penalty of 3% of total value of Sub-work order shall be imposed. In

addition to the above, if the contractor fails to rectify the substandard work despite being

served the legal notice under clause 31, UGVCL shall get the work rectified through the other

contractor and shall recover the total expense incurred for such rectification including labour

and any other amount paid to the other contractor as the case may be which it has to incur for

such rectification.

31.2 On detection of second instance of Substandard work in the same work order OR in different

work order(s) under jurisdiction of UGVCL, the defective/substandard orders shall be

terminated by following procedure as mentioned in tender terms and conditions in addition to

the actions as mentioned above in Clause 31.1.

31.3 On detection of third instance of Substandard work in jurisdiction of entire UGVCL by same

contractor during the last three years, the Contractor shall be stop-dealed after following

due procedure and after giving opportunity to represent as per principles of natural justice.

Definition of Substandard work

The work executed by the Contractor, which is not in compliance to the REC Construction

standards or CEA Construction Standards or any Indian standards (IS) OR violates the provisions of

GERC Distribution Code or Grid Code or CEA Safety regulations or in contradiction to any tender

condition as amended time to time, shall be considered as Substandard work

32) PENALTY

32.1 The time limit allowed for carrying out the work as entered in Bid shall strictly observed by

the contractor. The work shall throughout the stipulated period of contract proceeds with

due diligence (time being essence of the contract).

32.2 The execution of this contract shall be completed within 24 months after commencement

period of 30 days from the date of letter of acceptance (LOA).

32.3 If the work is not completed within the scheduled period as prescribed in Sub Work Order,

penalty shall be @ 0.5% per Week or part thereof plus applicable tax (if any) subject to

ceiling of 10% plus applicable tax (if any) of the Sub Order Value with GST and Cess as

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

applicable rates. This will be deducted from the bills payable either against this contract or

any bank guarantee or any other amount payable under any contract with the UGVCL.

32.4 For calculating delayed portion, start date of sub work order for penalty calculation will be

the Day / Date on which the major material issued against the Sub work order and final

date of actual completion of work shall be consider. The penalty will be invariably deducted

from the bill of the contractor and no refund will be given unless the competent authority

approved the waiver/ reduction in penalty. In case of material supplied late by UGVCL to the

contractor, clause no. 32.11 shall be applicable.

32.5 The concern field office of KALOL Division / SABARMATI Circle will issue sub work order as a

part of contract as per requirement. The work completion period of each sub work order will

be decided by concern Engineer-in-Charge from the date of issue of sub work order. The

delay of commissioning is liable for penalty.

32.6 Penalty for non-submission of bills timely: Sub work order wise bill along with excess

material credited to store to be submitted by contractor within 30 days from the date of work

completion. If the bill for the work, after reconciling inventory given to contractor and

depositing back the surplus material to respective RSO / Divisional Stores, is not submitted

within one months from the work completion date as per work completion date, then penalty

@ Rs. 500 per week or part thereof plus applicable GST subject to maximum of 10% of Sub

Work Order value plus applicable GST will be deducted.

32.7 Penalty for violating safety rules: During the execution of Work, if Contractor/Labour are

found violating the Safety rules and Regulations, then Engineer-in-Charge will serve the

warning Notice on first Instance. On second Instance the amount of Fine will be Rs.

or 0.1 % of amount of SWO (Whichever is higher) with GST and cess. Even If after above two

instances, still Contractor found violating Safety Rules and Regulations then Procedures for

Stop dealing shall be initiated against him as per rules and regulations.

32.8 Further, it is to state that in rainy season and / or for any other reasons beyond the control

of contractor and / or if Municipal Corporation or Nagarpalika or Local Government Bodies

or any other utilities do not allow to execute work or any ROW issues; stoppage period will

be allowed for such period subject to submission of representation with documentary

evidences. Stoppage Period will be approved by next higher authority of order approving

authority.

32.9 FORCE MAJEURE CLAUSE”

“If, at any time during the continuance of this contract, the performance in whole or in part

by either party of any obligation under this contract shall be prevented or delayed by reason

of any war, hostility, act of the public enemy, civil commotion, sabotage fires, floods,

explosion, epidemics, quarantine restrictions, strikes lockouts or acts of God (hereinafter

referred to as event)”, then provided notice of the happening of any such event is given by

either party to the other within twenty one days from the date of occurrence there of neither

shall have any claim for damages against the other in respect of such nonperformance of

delay in performance, and deliveries under the contract shall be resumed as soon as

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

practicable after such event has come to end or ceased to exist, and the decision of the

Managing Director as to whether the deliveries have been so resumed or not shall be final

and conclusive.

32.10 Extension in Contractual Period:

It will be Contractor’s responsibility to ensure that work is completed in stipulated time limit.

However, if on account of reasons beyond one’s control as laid down in the Force Major

Conditions, UGVCL may consider extension of contractual period with or without statutory

variations and with or without price variation.

32.11 Work completion period shall be reckoned from date of issue of material for particular sub

work order. However, decision of Executive Engineer of division with Supt. Accountant (Exp.)

will be authorized for finalization of work completion period if any dispute.

32.12 In case, it is not possible for the successful bidder to continue the work either due to heavy

rains or other reasonable causes, such facts should be immediately brought to notice of the

Engineer In Charge. If the reasons for stopping the work are genuine the Engineer In Charge

may ask the successful bidder to start the work again as per condition. The period of such

stoppage will not be considered as a part of working days moreover the successful bidder

cannot claim compensation for such stoppage.

32.13 It will be the responsibility of the contractor to intimate the closing down and

recommencement of work at all stages to the engineer in charge or vice versa in writing with

reason for the closing down of the work with specific of days for which work will remain

32.14 In case of failure on the part of the contractor, his claim for extension of time limit will be

entertained with penalty.

32.15 In case, intimation is not given in these regard, the reason for delay will not be accepted.

32.16 However, time limit extensions will be considered only after execution of the sub work order

fully and upon submission of documentary evidence for the reasons of delay. Extension of

Contractual period will be approved by next higher authority of order approving authority.

32.17 However, time limit extensions will be considered only after execution of the contract fully

and upon submission of documentary evidence for the reasons of delay.

32.18 In case of extra ordinary situation like COVID-19 Pandemic or any lockdown situation or rainy

season etc. force majeure clause will be applicable and stoppage period in execution of work

may allow, if required.

33) FORCE MAJEURE

Force Majeure means any circumstances beyond the control of the parties including:

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

33.1 War and other hostilities, (whether war be declared or not), invasion, act of foreign enemies,

mobilization, requisition or embargo;

33.2 Ionizing radiation or contamination by radioactivity from any nuclear fuel or from any nuclear

waste from the combustion of nuclear fuel, radioactive toxic explosive, or other hazardous

properties of any explosive nuclear assembly or nuclear components thereof;

33.3 Rebellion, revolution, insurrection, military or usurped power and civil war;

33.4 Riot, commotion or disorder, except where solely restricted to employees of the Contractor.

33.5 Neither party shall be considered to be in default or in breach of his obligations under the

Contract to the extent is that performance of such obligations prevented by any circumstances

of Force Majeure that arise after the date of the Notification of Award.

33.6 If either party considers that any circumstances of Force Majeure have occurred which may

affect performance of his obligations he shall promptly notify the other party.

33.7 Upon the occurrence of any circumstances of Force Majeure, the Contractor shall endeavor to

continue to perform his obligations under the Contract so far as reasonably practicable. The

Contractor shall notify the Engineer-in-Charge of the steps he proposes to take including any

reasonable alternative means for performance, which are not prevented by Force Majeure. The

Contractor shall not take any such steps unless directed so to do by the Engineer-in-Charge.

33.8 If circumstances of Force Majeure have occurred and shall continue for a period of 180 days,

notwithstanding, the Contractor may by reason thereof, having been granted an extension of

Time for Completion of the Works, either party shall be entitled to serve upon the other,

days’ notice to terminate the Contract. If at the expiry of the period of 30 days Force Majeure

shall continue, the Contract shall terminate.

34) Rate to be deducted for not carrying out the work.

a) If Feeder name is not done as per standard specifications due to negligence from contractor

side in that case rate will be deducted from the contractor bill as per UGVCL Rate.

b) Charges for mounting distribution boxes are including in erection of T/C. If distribution box

with wiring is not issued by UGVCL in that case rate will be deducted from the Contractor

bill as per UGVCL Rate.

c) If Transformer is not mounting then actual expenditure of Transformer replacement on

going contract rate for mounting transformer will be deducted from the bill.

d) If earthing of pole or DP structure is not found in a separate pit as per standard then such

bill will not be recorded.

e) Lighting arrestor must be installed otherwise bill will not be recorded.

f) All empty conductor drums will have to be returned by the contractor at concern Divisional

Stores, failing which Rs.500/- per drum will be recovered.

g) GST at the applicable rate will be added to rates / amounts mentioned above.

35) Tax deducted at the source (TDS) under Income Tax and under Goods and Service Tax Act will

be deducted from bill as per applicable rate, if applicable.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

36) ARBITRATION:

All questions, disputes or differences whatsoever which may at any time arise between the

parties to this agreement touching the agreement or subject matter thereof, arising out of or in

relation there to and whether as to construction or otherwise shall be referred to the decision

of the Sole Arbitrator, as appointed by the MD of COMPANY, for that purpose, who shall be a

retired High Court Judge or retired District and Sessions Judge, and the decision of the said

Arbitrator shall be final and binding upon the parties. Reference to the arbitration shall be

governed by the provisions of Indian Arbitration & Conciliation Act. 1996 as amended from

time to time and the rules made there under.

37) If any work not carryout out satisfactory deduction will be made as per prevailing cost data.

However Executive Engineer – KALOL DO is the final authority and decision will be acceptable

Executive Engineer – UGVCL KALOL DO has full right to accept or reject any tender without

assigning any reason.

All the successful tender has to carried out the work under UGVCL competency as per

assigned by competent authority.

38) REVIEW OF ORDER

The company reserves the right to reduce the quantity, if required.

39) CARTEL:

If, the Company during the procurement process, observes or suspects any activity on the part

of bidders or obtains any knowledge which indicates the existence of cartel formation amongst

the bidders or apprehends the possibilities of cartel as defined under The Competition Act,

2002, the Board of the Company being a government Company involved in public procurement

work, reserve all rights to allot quantities to such bidders, who are not part of the cartel, in any

manner deemed fit in the interest of the Company without assigning any reason thereof.

Besides the above the purchaser Company, may initiate actions under the Competition

Act/other laws and / or the bidder(s)/ firm(s) will be black listed / stop deal, at its sole

discretion.

40) Evaluation of Tenders:-

Tenders shall be called for in two bids: (1) Techno-commercial Bid and (2) Price Bid.

The price Bid of Techno-commercially qualified Bidders will be opened.

For modification or relaxation in Techno-commercial Conditions after Technical Bid is opened,

all Bidders shall be given equal opportunity.

41) Price Evaluation:-

No price preference shall be given on any account. All tenders must be submitted firm price

basis (Inclusive of all Taxes) and lowest evaluated bid in the interest of the UGVCL, for the

complete works covered under these specifications and documents.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

If more than one party is to be considered for placement of order, they will have to match their

may go to the L-2, L-3 and so on depending upon the requirement at UGVCL’s sole discretion. If

Inviting Authority) decision shall be final and binding on all the parties.

In case of bid found quoted with abnormally low rates, UGVCLs may reject the offer at its sole

discretion after examining quality and resources of bidders with due approval of next higher

authority.

42) If work is not started / completed within stipulated time limit period, then contract be short

closed with applying risk purchase and Security Deposit is to be forfeited with put on black

listing or stop deal for the period decided by the competent authority.

43) QUANTITY DISTRIBUTION

43.1 The total quantity distribution to the new bidders will be restricted up to 30% of the estimated

amount in case of new bidders stands L-1. However, if the quoted price of new bidders is higher than

regular bidders, then there will be no any quantity distribution is allowed to new bidders.

43.2 The competent authority of the UGVCL as per delegation of power shall decide to consider nos. of

bidders for placement of order under ARC, at its own discretion and considering field requirement.

43.3. The New bidder is to be asked to match the L-1 price of the New Bidder only and the regular Bidder

has to match the L-1 price of the Regular Bidder.

43.3.1 If L-1 New Bidder below company SOR Rate then regular Bidder restricted up to Company SOR Rate

43.3.2 If L1 is New bidder above company SOR Rate Then Regular Bidder Should match with L-1 Bidder.

In case of L1 bidder backs out from tender process before allotment of order or during tender process, UGVCL

has right to call next lowest bidder/bidders to execute work according to Clause no-43.3.

(Note: The said clause is applicable to the ARC tender. If tender is invited with value more than Rs. 5 Lakhs

for specific single work, experience criteria may be kept in line with Important instruction for submitting the

Tender Clause No: 3, Technical & Commercial. Accordingly, this clause may be adopted / deleted while

inviting tenders).

44. CONTRACT QUALITY ASSURANCE:

44.1 The Bidder shall include in his proposal the Quality Assurance Program containing the overall

quality management and procedures which he proposes to follow in the performance of the

Works during various phases as detailed in relevant clause of the General Technical

Conditions.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

44.2 At the time of Award of Contract, the detailed Quality Assurance Program to be followed for

the execution of the Contract. UGVCL reserve the right to inspect the work at any stage of

contract i.e. during the execution and after the execution of work.

44.3 The Bidder shall clearly specify the list of sub-vendors from whom the bought out items (if

any) are being supplied. Such details shall be accompanied by their list of previous supplies

made performance reports etc. However, in case of orders are placed, specific approval shall

be obtained from the UGVCL for the vendor supplied materials. The quality assurance

program shall be furnished for each material separately for approval.

45. SECRECY:

The technical information, drawings, specifications and other related documents forming part

of the enquiry or Contract are property of UGVCL and shall not be used for any other purpose,

except for the execution of the contract. All rights related to the technical specifications,

drawings and records are reserved by UGVCL only and no part or partial should be

reproduced, copied or alter without prior permission to UGVCL in writing. In the event of the

breach of this provision, UGVCL can claim the damages caused by such events.

46. Stop Dealing:

Bidder/Contractor shall be put under Stop Deal due to following reasons.

46.1 Has submitted fake, false or forged documents/certificates.

46.2 Has revised/withdrawn price bid after opening of Techno: commercial bid, until and unless

it is sought for.

46.3 Has tampered with the stipulated tendering process.

46.4 Has refused to accept Letter of Acceptance/Purchase Order/Work Order after the same is

issued by the Company within the validity period and as per agreed terms and conditions.

46.5 Has committed breach of contract or has failed to perform a contract or has abandoned

the contract.

46.6 Has failed to provide suitable expertise for the work as per prescheduled program

46.7 Has failed to submit all the necessary Test reports/documents within time schedule / as

per Company's time limit, as mentioned in the LOA, if the Letter of Acceptance (LOA) is

placed subject to submission of type reports / documents to the firm.

46.8 Has indulged in construction and erection of defective works.

46.9 Has supplied inferior quality / defective materials and refused to replace with stipulated

time frame, as specified by the company.

46.10 Has substituted materials In lieu of materials supplied by the Company or has not

returned or has short returned or has unauthorized disposed of materials/ documents/

drawings/ tools or plants or equipment supplied by the Company

46.11 Has involved in malpractices such as bribery, corruption, fraud, canvassing and pilferage

46.12 Has unauthorized obtained official company information or copies of documents, in

relation to the Tender/Contract

46.13 Has failed to follow the stipulated mode of communication, if specified by the tendering

authority/ purchaser.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

46.14 Any other ground for which in the opinion of the Company makes it undesirable to deal

with the Firm, and

46.15 In case the State Government directs the Company to place a firm in stop dealing/ banned

for business dealing/ blacklisting

46.16 The firm, stop deal and/or banned for business dealing and/ or blacklist by GUVNL or any

subsidiary Companies of GUVNL shall be considered as a stop deal and/ or banned for

business dealing and/ or blacklisting for all Companies.

47 Effect of putting a proprietor/firm for Stop dealing/Banned for business dealing are as

47.1 The proprietor/all the partners/directors of the stop deal/ banned for business dealing/

blacklisting firm shall also be considered for stop deal/ banned for business dealing.

47.2 Once the name of the firm and/ or proprietor/ partner/ director of the firm appears in the

list of Stop dealing / Banned for business dealing in any Company of GUVNL and its

Subsidiary Companies,

I. No enquiry shall be issued to a firm.

II. No bids / tender shall be considered for evaluation and the bid submitted by

the Firm shall be returned.

47.3 Action to be taken, when a Firm and/or proprietor/ partner/ director of the firm is put on

Stop dealing/ Banned for business dealing by GUVNL or any of its subsidiary Companies,

during tender process: -

I. Before opening Technical bids, the bid submitted by the Firm will be treated as

“Disqualified Bid” and automatically stand as “Rejected Bid” at the time of

scrutiny of Preliminary / Technical Bid.

II. After opening Technical bid but before opening the price bid, the price bid of

the Firm should not be opened and the bid submitted by the Firm will be

treated as “Disqualified Bid” and automatically stand as “Rejected Bid” at the

time of scrutiny of Technical Bid.

III. After opening of price bid, the offer of the Firm should be ignored and will not

be further evaluated. The Firm will not be considered for issue of order even if

its price is the lowest. In this situation, the next lowest bidder shall be

considered as L1.

IV. The BG/EMD submitted by the Firm with tender should be returned after

obtaining confirmation from GUVNL and its other subsidiary Companies that

there are no outstanding dues recoverable from the firm.

47.4 If a Firm is put on Stop dealing / Banned for business dealing in one Company and is already

executing work and/ or Letter of Acceptance/ purchase order awarded to them by another

Company, then the firm should be allowed to complete such awarded work / supply.

47.5 The amount of EMD/SD/ any payment against supply withheld at the instance of GUVNL or

any of its subsidiary Companies shall be appropriated against the dues recoverable from the

firm by GUVNL or any of its subsidiary Companies. EMD/ SD/ PG in the form of bank

Guarantee shall be encashed and appropriated.

47.6 The Stop dealing/ Banned for business dealing shall be Firm- specific and when a Firm is put

on Stop dealing/ Banned for business dealing, all the manufacturing works of the Firm shall

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

be on Stop dealing/ Banned for business dealing for GUVNL and its Subsidiary Companies &

for all Services of the Firm.

47.7 If the Firm placed on Stop Dealing/ Banned for business dealing is a Proprietary Concern,

then all the Concerns of the same Proprietor shall also be considered to be on Stop Dealing/

Banned for business dealing.

47.8 The Board of Directors of the concerned Company may however, if he considers it to be in

the interest of the Company, remove the ban in respect of any specific Service from any

Contractor for that Company only.

47.9 Every bidder should, at the time of submission of bid, give a declaration as per Annexure-F

attached with this Tender, that bidder and/or proprietor/ partner/ director of the firm has

not been placed on Stop dealing / Banned for business dealing / blacklisting by GUVNL and

it’s any Subsidiary Companies.

48. Relationship with employee:

Every bidder should, at the time of submission of bid, give a declaration as under,

“If in any Bidder Company/firm, the interest(i.e. shareholding in company and share in

partnership firm) of any employee of the tendering company or his/her relative as defined in

section 2(77) of the company’s Act 2013 is 10% or more, the tendering Company will not deal

with such Company/Firm at all.

Bidder therefore, must specifically disclose this fact in his technical bid. Non –disclosure of such

facts would immediately disqualify the Bidder for further dealing with the tendering Company”

49. Usage of “Call Before you Dig” application:

“Permission letters granted online/offline for enforcing use of ‘Call Before U dig’ mobile

application for any work involving excavation activity.” (Contractor/Bidder has to register

themselves as Excavator/Digger in “Call before you Dig” application and for any

excavation/digging work, contractor has to take permission/NOC from “Call before you Dig”

application)

50. GUARANTEES

The Contractor shall guarantee in accordance with the Contract documents and free from

defects in material/equipment supplied by contractor like Indoor / Outdoor / Joint kits, HDPE

Pipes etc. and workmanship for a period of twelve (12) calendar months from date of

completion of sub work order by contractor. For the same, sticker must be provided

incorporating Date of Installation and due date of guarantee on materials used by Successful

51. Defense of Suits:

If any action in court is brought against the Owner or Engineer or an officer or agent of the Owner,

for the failure, omission or neglect on the part of the Contractor to perform any acts, matters,

covenants or things under the Contract, or for damage or injury caused by the alleged omission or

negligence on the part of the Contractor, his agents, representatives or his Sub-Contractors, or in

connection with any claim based on lawful demands of Sub-Contractors, workmen, suppliers or

employees, the Contractor shall in all such cases indemnify and keep the Owner, and the Engineer

and/or his representative, harmless from all losses, damages, expenses or decrees arising of such

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Tender Notice No KLL-DO-17-2025-26 / SR NO-4 PR NO:- 652381 / RFQ NO:-

Schedule – B

ANNUAL RATE CONTRACT TENDER FOR ERECTION, MAINTENANCE WORK OF OVERHEAD HT/LT LINE, TC

UNDER NARDIPUR SUB DIVISION UNDER KALOL DIVISION

Sr. Description of Work Estimate Unit Rate Amount

No. Qty. in Rs.

1 HT Tapping from the Existing Pole including Fixing of 250 No 459

Cross Arms, Clamps Anti-Climbing Devices, Danger

board, Insulators, ETC. complete and Painting of

Fabricated materials and numbering of pole, complete As

per standard specification but excluding erection of GUY

set and Earthing

2 Erection of PSC POLES of 8 Mtr X 200 KG including 250 No 1113

Fixing of PIT and refilling of Earth, fixing of cross Arms,

Top Fitting Clamps Anti-Climbing Devices, Danger board,

Insulators, ETC. complete and Painting of Fabricated

materials and numbering of pole, complete As per standard

specification but excluding erection of GUY set and

Earthing .

3 Erection of PSC POLES of 10 Mtr X 270 KG including 110 No 2466

Fixing of PIT and refilling of Earth, fixing of cross Arms,

Top Fitting Clamps Anti-Climbing Devices, Danger board,

Insulators, ETC. complete and Painting of Fabricated

materials and numbering of pole, complete As per standard

specification but excluding erection of GUY set and

Earthing .

4 Erection of Steel Poles of 9 Mtr to 11 Meters including 5 No 1865

Fixing of PIT and refilling of Earth, fixing of cross Arms,

Top Fitting Clamps Anti-Climbing Devices, Danger board,

Insulators, ETC. complete and Painting of Fabricated

materials and numbering of pole, complete As per standard

specification but excluding erection of GUY set and

5 Erection of Steel Poles of 13 Meters including Fixing of 5 No 2137

PIT and refilling of Earth, fixing of cross Arms, Top

Fitting Clamps Anti-Climbing Devices, Danger board,

Insulators, ETC. complete and Painting of Fabricated

materials and numbering of pole, complete As per standard

specification but excluding erection of GUY set and

6 Erection of Double POLES structure of 8 Mtr X 200 5 No 2530

KG PSC Pole including Excavation of PIT and refilling of

Earthing, fixing of Channels, Supporting Angles, Clamps

Anti-Climbing Devices, Danger board, Insulators, ETC.

complete and Painting of Fabricated materials and

numbering of pole, complete As per standard specification

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

but excluding erection of GUY set and Earthing (Without

AB Switch)

7 Erection of Double POLES structure of 10 Mtr X 270 10 No 5320

KG PSC Pole including Excavation of PIT and refilling of

Earthing, fixing of Channels, Supporting Angles, Clamps

Anti-Climbing Devices, Danger board, Insulators, ETC.

Complete and Painting of Fabricated materials and

numbering of pole, complete As per standard specification

but excluding erection of GUY set and Earthing (Without

AB Switch)

8 Erection of Double POLES structure of 9 Mtr To 11 2 No 3655

Meter Steel Pole including Excavation of PIT and refilling

of Earth, fixing of Channels, Supporting Angles, Clamps

Anti-Climbing Devices, Danger board, Insulators, ETC.

Complete and Painting of Fabricated materials and

numbering of pole, complete As per standard specification

but excluding erection of GUY set and Earthing (Without

AB Switch)

9 Erection of Double POLES structure with mounting of 5 No 3042

AB Switch, HG Fuses of 8 Mtr X 200 KG PSC Pole

including Excavation of PIT and refilling of Earth, fixing

of Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing

10 Erection of DOUBLE POLE structures with mounting 50 No 9808

of AB Switch, HG Fuses, Transformers, Lightening

Arrestors, Distribution BOX ETC. of 10 Mtr X

KG PSC Pole including Excavation of PIT and refilling of

Earth, carting of Transformers from Store to Site, Fixing of

Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing.

11 Erection of Double POLES structure with mounting of 1 No 3990

AB Switch, HG Fuses of 9 Mtr TO 11 Meter Steel Poles

including Excavation of PIT and refilling of Earth, fixing

of Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

12 Erection of Double POLES structure with mounting of 1 No 4531

AB Switch, HG Fuses of 13 Meter Steel Poles including

Excavation of PIT and refilling of Earth, fixing of

Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing

13 Erection of SINGLE POLE structure with mounting of 5 No 3244

AB Switch, HG Fuses, Transformers, Lightening

Arrestors, Distribution BOX ETC. of 8 Mtr X 200 KG

PSC Pole including Excavation of PIT and refilling of

Earth, carting of Transformers from Store to Site, Fixing of

Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing.

14 Erection of DOUBLE POLE structures with mounting 100 No 8681

of AB Switch, HG Fuses, Transformers, Lightening

Arrestors, Distribution BOX ETC. of 8 Mtr X 200 KG

PSC Pole including Excavation of PIT and refilling of

Earth, carting of Transformers from Store to Site, Fixing of

Channels, Supporting Angles, Clamps Anti-Climbing

Devices, Danger board, Insulators, ETC. complete and

Painting of Fabricated materials and numbering of pole,

complete As per standard specification but excluding

erection of GUY set and Earthing.

15 Erection of DOUBLE POLE structures with mounting 1 No 10151

of AB Switch, HG Fuses, Transformers, Lightening

Arrestors, Distribution BOX ETC. of 9 Mtr to

Meter STEEL Poles including Excavation of PIT and

refilling of Earth, carting of Transformers from Store to

Site, Fixing of Channels, Supporting Angles, Clamps Anti-

Climbing Devices, Danger board, Insulators, ETC.

complete and Painting of Fabricated materials and

numbering of pole, complete As per standard specification

but excluding erection of GUY set and Earthing.

16 Erection of GUY SET including Excavation of PIT and 200 No 537

refilling of Earth, AS PER STANDARD

SPECIFICATION WITH STAY CLAMPS, STAY WIRE,

ANCHOR ROAD, TURN BUCKLE, EYE BOLT, GUY

INSULATORE, CC BLOCK ETC.

17 Erection of COIL TYPE/ CI PLATE TYPE EARTHING 300 No 579

INCLUDING COST OF COAL SALT ETC. BUT

WITHOUT COST OF GI WIRE AS PER STANDARD

SPECIFICATION (10kg salt-10 kg coal)

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

18 STRINGING OF 30MM2 ACSR/34MM2, 55MM2 AAA 100 Km 2020

CONDUCTOR FOR 11/22KV & LT LINES INLCUDING

FIXING OF INSULATORS, BINDING JUMPERING

19 STRINGING OF DOG. CONDUCTOR (100 mm2 25 Km 4651

ACSR/100 mm2 AAAC) FOR 11/22KV & INLCUDING

FIXING OF INSULATORS, BINDING JUMPERING

20 PROVIDING GUARDING TO HT LINE/LT LINEON 500 Meter 67

ROAD / RAIL CORSSING

21 LT LINE TAPPING SINGLE PHASE (WHERE 200 No 49

ADDITIONAL NUT BOLTS & FABRICATIONS/U-

CLAMPS FITTING IS REQUIRED

22 LT LINE TAPPING THREE PHASES (WHERE 200 No 89

ADDITIONAL NUT BOLTS & FABRICATIONS/U-

CLAMPS FITTING IS REQUIRED

23 Stringing / Laying of overhead LT cable for road crossing 10 No 251

HT line crossing & telephone line crossing ETC. (PER

24 Dismantling of 8 Mtr. PSC POLE in usable Condition with 100 No 562

crediting of fabrication at STORE & STACKING OF

POLE AT SAFE AND ON ROAD SIDE

25 Dismantling of 10 mtr psc pole/ 13 MTR. GIRDER SIZE 50 No 1233

100X150 MM IN USABLE CONDITION WITH

CREDITING OF FABRICATION AT STORE &

STACKING OF POLE AT SAFE AND ON ROAD SIDE

26 Dismantling of transformer centre (08 Mtr PSC Pole) with 15 No 4340

crediting of fabrication materials & Transformer at store

and safe stacking of pole at road side with Transformer in

same condition as it was

27 Dismantling of transformer centre (8 Mtr PSC Pole) with 15 No 2263

crediting of fabrication materials & Transformer at store

and safe stacking of pole at road side. Without

Transformer

28 CARTING OF PSC POLE AT DESTINATION (PER 100 L.S. 371

POLE) MORE THAN 4 KM & UP TO WORK

DESTINATION (PER POLE)

29 Replacement of 11 KV PIN INSULATOR by new pin 275 No 45

insulator /Composite Pin Insulator with Binding

30 Replacement of 11 KV DISC INSULATOR WITH H/W 100 No 164

by new Disc Insulator / Composite Disc insulator As per

Specification.

31 Replacement of LT Shackle insulator By New One. 26 No 34.5

32 Re Fixing OF V cross arm in proper positions. 25 No 70

33 Replacement of V cross arm By New One. 25 No 234

34 Re Fixing of Top fitting arm in proper positions 25 No 35

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

35 Replacement of Top Fitting Bye New One 25 No 42

36 Straighting of tilted PSC Poles/ RSJ Poles at Pin Point 20 No 272

37 Straighting of tilted PSC Poles/ RSJ Poles at tension 10 No 315

(shackle) Point

38 Re-Jumpering work of HT/LT LINE for SHACKLE 20 Per 94

POLE, TAPPING DO AB SWITCHES AS PER Pole

SPECIFICATION (PER POLE)

39 Erection Of Support pole (PSC/RSJ) for stay (i.e. stud 25 No 703

40 PIN REBINDING OF CONDUCTOR & CLEANING OF 50 Per 26.5

11 KV/22KV PIN INSULATOR AS PER Pole

INSTRUCTION OF ENGINEER INCHARGE (PER

41 PIN BINDING OF CONDUCTOR & CLEANING OF LT 50 Per 24

SHACKLE INSULATOR AS PER INSTRUCTION OF Pole

ENGINEER INCHARGE (PER POLE)

42 Converting Pin Point to Shackle point including 10 No 1781

dismantling & restringing etc including the cost of Nuts &

43 Removal / Dismantling of Existing HT/LT line conductor 60 Per 1010

from line 34/55 MM2 and crediting to store. Conductor has Cond

to dismantle from shackle to shackle pole, with minimum Per

nos. of cut piece as instruction of Engineer incharge. (Per KM

Cond Per KM)

44 Removal / Dismantling of Existing HT/LT line conductor 20 Per 2326

from line DOG 100 MM2 (Above 55MM2 size conductor) Cond

and crediting to store. Conductor has to dismantle from Pe

shackle to shackle pole, with minimum nos. of cut piece as KM

instruction of Engineer in charge. (Per Cond Per KM)

45 Re-stringing of HT & LT line (34 mm2 to 55mm2) 250 1 106

conductor/coated conductor with new pin binding (1 Wire Wire

per span) per

46 Re-stringing of HT & LT line (Above 55mm2 size 50 1 106

conductor) conductor /coated conductor with new pin Wire

binding (1 Wire per span) per

47 Re-stringing of 11 KV Aerial Bunch Cable (All size) per 50 Per 316

Span with labour of fitting of accessories (Per Span) Span

48 Trimming & Cutting of bigger size of tree branches/whole 100 Per 475

tree obstrutting HT/LT line ((During Mass maintenance Day

Activities 8 Hrs duration) (Per Day per labour) per

49 Trimming & Cutting of bigger size of tree branches/whole 100 Per 375

tree obstrutting HT/LT line (During Local Maintenance Day

activities) (Per Day per labour) per

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

50 Trimming & Cutting of tree branches/whole tree 5 Per 3000

obstrutting HT/LT line with minimum 2 Labours & driver Day

with Tree Cutting machine & Ladder Vehicle (During

Mass Maintenance Activities/Disaster) (Per Day)

51 Numbering of Pole with paint by preparing back ground of 250 No 50.5

one color and have lettering (height 3’’ *width 0.5’’) as per

instruction of EIC (Color must have ISI mark & to be

provided by contractor)

52 Stringing of 11 KV HT Arial Bunch Cable of any size 2 Km 43155

with fittings of all accessories, i.e. Special design

suspension clamp fixing of cross arm, LT shackle insulator

etc for fixing of Messenger wire complete, as required and

directed by Engineer incharge.

53 STRINGING OF LT ARIAL BUNCH CABLE (3.5 Core) 2 Km 23016

any size with fittings of all accessories, i.e. Special design

suspension clamp fixing of cross arm, LT shackle insulator

etc for fixing of Messenger wire complete, as required and

directed by Engineer incharge.

54 STRINGING OF LT ARIAL BUNCH CABLE (1 Ph 2 1 Km 9208

Wire ) of any size with fittings of all accessories, i.e.

Special design suspension clamp fixing of cross arm, LT

shackle insulator etc for fixing of Messenger wire

complete, as required and directed by Engineer incharge.

55 Strip type Earthing of XLPE Cable by providing and fixing 25 No 1986

25*3 mm GI hot dip strip of total length of stip -

Mtr,300*300*10 mm CI earthing plate, 2'' PVC Pipe of

Mtr length; providing of wood charcoal (25 KG Appx.)

and salt cubes ( 25 KG Appx.) or bentonite powder (50 KG

Appx.) with material. Earthing shall be as per REC

standard and specifications.

56 Fixing of LT Line spacers for LT line 100 No 9

57 Painting/Writing consumer no. on SMB/MMB (Urban) 100 No 11

(with letter size- hieght 40mm and width 8 mm)

58 Painting/Writing consumer no. on SMB/MMB (Rural) 100 No 21

(with letter size- hieght 40mm and width 8 mm)

59 Replacement of deteriorated/ Providing LT distribution 10 No 1171

Box with new upto 100 KVA capacity & crediting it to

60 Replacement of deteriorated/ Providing LT distribution 10 No 2107

Box with new above 100 KVA capacity & crediting it to

Supply & Labour Part

61 Supply of Heat Shrinkable type Straight Joint Cable kit 40 No 1400

single Core Suitable for 11 KV 1C*70 & 95 sqmm AB

cable (1 Phase)

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

62 Labour Charges for Fixing Heat shrinkable type Cable 40 No 500

Joint kit for 11 KV 1 C*70 & 95 sqmm AB cable (1 Phase)

63 Labour Charges for Fixing Heat Shrinkable type Cable 40 No 1000

joint for 11 KV 1Cx70 Sqmm / 1C x 95 Sqmm AB Cable

including Restringing of HT AB Cable

64 Providing & fixing Heat Shrinkable type cable jointing kit 40 No 3100

suitable for 11 KV 3 C * 70 & 95 Sqmm AB cable for

outdoor termination application

65 SUPPLY OF SELF TIGHTENING ANCHORING 25 No 149

(DEAD END) CLAMP WITH POLE BRACKET USING

STAINLESS STEEL STRAP & BUCKLE

66 SUPPLY OF SELF LOCKING SUSPENSION CLAMP 25 No 165

WITH POLE BRACKET USING STAINLESS STEEL

STRAP & BUCKLE

67 SUPPLY OF PRE INSULATED MID SPAN JOINTS 25 No 149

FOR PHASE & NEUTRAL FOR 16 SQMM TO

68 SUPPLY OF STAINLESS STEEL OF SIZE STRAP 20 No 42

20MM X 0.7MM & BUCKET WIDTH 20MM

69 SUPPLY OF STAINLESS STEEL OF SIZE STRAP 20 No 42

20MM X 0.7MM & BUCKET WIDTH 20MM

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

70 Supply & Labour charge for fixing of Lightning Arrester 20 No 3812

with separate Strip Earthing with PVC covered for (1)

Supply of following material for fixing of Lightning

Arrester with separate Strip Earthing with PVC covered as

(1) 25*3 mm GI 90’ hot dip strip,

(2) 300*300*10 mm CI earthing plate with two nos. hole

for GI strip fitting.

(3) Rigid PVC Pipe ISI Marked 32 mm Dia, 2 mm Thick

(4) Wood Charcoal and Salt Cube 25 KG each

(5) Nut bolt and washers as per required size.

(6) PVC Pipe bend/connector/T connector as per

requirements on site situation. • Labor Charges for fixing

of Set of 03 Nos Lightning Arrester on existing or new

double pole structure/single pole on top angle

• if three hole patti existing or by providing of three hole

patti if hole existing on angle or by fixing of clamp on

existing angle or by fixing of additional 9/4.5 ft angle with

side clamp and LA fixing of set of 03 Nos LA at one

location including necessary Nut Bolt and 02 Nos plain &

2 Nos spring washer on both side (Detail description as per

technical specification)

• Labor charges for strip earthing at one location by

digging a pit of 1800mm*1200mm*1200mm. The pit shall

be at least 1200 mm far from the nearest support. The pit

will be filled in by alternate layers of wood charcoal and

salt cubes each of 300 mm till 1500 mm from bottom by

25 KG of Charcoal and salt each Remaining 300 mm shall

be refilled by dug out.

• One Earthing strip should be connect properly with

earthing plate by earthing bolt and on other end with set of

all three LA.

• Hot dip galvanized earthing Strip should be cover with

PVC pipe from bottom to all three LA connection.

• PVC Connector or bend or T connector utilized where

joint on pipe, bend on pole or earthing strip connection

with LA. Ensure that no any parts of strip remains open

or not touched to existing or new fabrication or poles)

• Earthing should be done as per REC standard &

specification..

Remark: Required Nut Bolt and washer will be supplied by

contractor No additional charges will be given for nut bolt

(LA will be provided by UGVCL)

71 Welfare Cess @ 1% of Estimated Cost 39955 Each 1

72 GST@18% 726384 Each 1

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Annexure-A

Name of Contractor:-______________________ Mobile no:____________

Contractor’s store address:-

Details of work completion (last seven years):

no work Division order Amt work completed

no. & (Rs.) completed

Date (Rs.)

Details of work order on hand / Work under progress:

Sr. Name of Name Work Tender Amount of Quantity of work

no work of order Amt work completed

Divisio no. & (Rs.) completed

n Date (Rs.)

Contractor’s Signature

---------------------------------------For office use only----------------------------------------

This is to certify that, the above contractor name as

_______________________________ has successfully completed work of above

mention order in this division in stipulated time. The work is found satisfactory.

Executive Engineer

___________ Division

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Annexure-B

Name of Contractor:-______________________ Mobile no:____________

Address:-___________________

Details of Equipments, Tools, and safety equipments available with contractor:

Name of Equipments, Reg. no / Sr.

Quantity Approximate

Sr. no Tools, and safety no of

in Nos. value (Rs.)

equipments equipment

Contractor’s Signature

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

ANNEXURE – C

Details of Pending Orders, tendered for & on hand, as on the date of the submission of

this Tender:

(To be completely filled by the Bidder)

WORK DATE

SR STIPULATED

WITH ITS COST OF ANTICIPATED ESTIMA WHEN

N TENDER DATE OR REMARKS

LOCATION REMAINING DATE OF TED DECISION

O COST PERIOD OF

AND WORK COMPLETION COST IS

COMPLETION

ADDRESS EXPECTED

• If necessary, separate sheet may be used to submit the information.

Tender for -----------------------------------------

Tender No: UGVCL/---------------------------------------------

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

ANNEXURE-D

TENDER FEES

Sr. No. Estimated Cost of tender Tender Fee

1 Up to Rs. 5 Lacs As per DoP.

2 Above Rs. 5 Lacs and Up to Rs. 10 Lacs Rs. 500/-

3 Above Rs. 10 Lacs and Up to Rs. 50 Lacs Rs. 1000/-

4 Above Rs. 50 Lacs and Up to Rs. 100 Lacs Rs. 5000/-

5 Above Rs. 100 Lacs and Up to Rs. 500 Lacs Rs. 7500/-

6 Above Rs. 500 Lacs Rs. 10000/-

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Annexure-F

Sub: -UNDERTAKING IN REGARD TO STOP DEAL/BLACK LIST THEREOF

Ref: - Tender No: UGVCL/_______________________________

All bidders will have to furnish the following undertaking duly filled in signed and stamped for

each quoted item of the tender along with the Technical Bid.

I/We_____________________________________________________ authorized signatory of

M/s_____________________________________________ hereby certify that

M/s_________________________________________________ is not stop deal/black listed by

GUVNL and or any subsidiary companies viz.

PGVCL/UGVCL/DGVCL/MGVCL/GSECL/GETCO for the tendered item.

Signature of the Tenderer

Seal of the Firm

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

On Firm’s Letter Head

CERTIFICATE – “A”

I/We__________________________________________ authorized signatory of

M/s._________________________________________________ hereby certify that

M/s._________________________________________ is not related with other firms who have

submitted tenders for the same items under this inquiry / Tender.

• Seal of the Firm Signature of the Tenderer

• Place: With Designation

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

E.M.D. BANK GUARANTEE FORMAT

FOR TENDER NO.: ……………………………..…….

APPENDIX – I

(Bank Guarantee on Non-Judicial Stamp Paper of Rs.100/-)

WHEREAS M/s. ____________________________________ (Name & Address of the Firm) having their

registered office at _____________________________________ (Address of the firms Registered office)

(hereinafter called the ‘Tenderer’) wish to participate in the tender No.

_________________________for____________________________________________ of (Supply/

Erection/Supply & Erection Work) (Name of the material/equipment/Work) for _________________________,

______ Gujarat Vij Company Ltd. and WHEREAS a Bank Guarantee for (hereinafter called the “Beneficiary”)

Rs._____________ (Amount of EMD) valid till _________ (Mention here date of validity of this Guarantee

which will be 5 (FIVE) months beyond initial validity of Tender’s offer) which is required to be submitted by

the tenderer along with the tender.

We, __________________ (Name of the Bank and address of the Branch giving the Bank Guarantee) having

our registered office at ______________________ (Address of Bank’s registered office) hereby give this Bank

Guarantee No.________________ dated _________ and hereby agree unequivocally and Unconditionally to

pay immediately on demand in writing from the _______ Gujarat Vij Company Ltd. or any officer authorized

by it in this behalf any amount not exceeding Rs. ______________ (Amount of E.M.D.), (Rupees

_________________________________ (In words) to the said ______ Gujarat Vij Company Ltd. on behalf of

the Tenderer.

We ___________________________ (Name of the Bank) also agree that withdrawal of the tender or part

thereof by the Tenderer within its validity or Non submission of Security Deposit by the Tenderer within one

month from the date tender or a part thereof has been accepted by the _______ Gujarat Vij Company Ltd.

would constitute a default on the part of the Tenderer and that this Bank Guarantee is liable to be invoked and

encashed within its validity by the Beneficiary in case of any occurrence of a default on the part of the

Tenderer and that the encashed amount is liable to be forfeited by the Beneficiary.

This agreement shall be valid and binding on this Bank up to and inclusive of ____________________

(Mention here the date of validity of Bank) and shall not be terminable by notice or by Guarantor change in the

constitution of the Bank or the firm of Tenderer Or by any reason whatsoever and our liability hereunder shall

not be impaired or discharged by any extension of time or variations or alternations made, given, conceded with

or without our knowledge or consent by or between the Tenderer and the UGVCL.

“Notwithstanding anything contrary contained in any law for the time being in force or banking practice, this

Guarantee shall not be assignable, transferable by the beneficiary (i.e. GUVNL or Subsidiaries). Notice or

invocation by any person such as assignee, transferee or agent of beneficiary shall not be entertained by the

Bank. Any invocation of the Guarantee can be made only by the beneficiary directly.”

NOTWITHSTANDING anything contained hereinbefore, our liability under this guarantee is restricted to Rs.

__________ (Amt. of E.M.D.) (Rupees ____________________________________) (In words). Our

Guarantee shall remain in force till _________ (Date of validity of the Guarantee). Unless demands or claims

under this Bank Guarantee are made to us in writing on or before_______ (Date of Validity of the Guarantee),

all rights of Beneficiary under this Bank Guarantee shall be forfeited and we shall be released and discharged

from all liabilities there under:

Please Mention here Complete Postal Address Signature of the Bank’s Authorized Signatory

of the Bank with Branch Code, Telephone and with

Fax Nos. Official Round Seal.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

NAME OF DESIGNATED BANKS:

• All Nationalized Banks including Public Sector Banks IDBI Bank Ltd.

• Private Sector Banks authorized by RBI to undertake the state Government business, which are (i) Axis

Bank (ii) ICICI Bank (iii) HDFC Bank

• Co-operative Banks and Commercial Banks and recognized/notified by Government of Gujarat (GoG)

Note: The Banks shall be the Banks recognized / notified by the Finance Department, Government of

Gujarat (GoG) from time to time.

FORM OF BANKER’S UNDERTAKING (For SD)

(Bank Guarantee on Non-Judicial Stamp Paper of .100/-)

We, Bank of ___________________________________ hereby agree unequivocally and unconditionally to

pay immediately on demand in writing from the ______ Gujarat Vij Company Ltd. or any Officer authorized by

it in this behalf any amount up to and not exceeding _______ (in words) Rupees ___________________ to the

said _______ Gujarat Vij Company Ltd. on behalf of M/s.

_________________________________________________who have entered into a contract for the

supply/works specified below

L.O.A. No. __________________________dated_________.

This agreement shall be valid and binding on this Bank up to and inclusive of ______________ and shall not be

terminable by notice or by change in the constitution of the Bank or the firm of Contractors / Suppliers or by

any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension

of time or variations or alterations made, given conceded or agreed, with or without our knowledge or consent,

by or between parties to the said within written contract.

“Notwithstanding anything contrary contained in any law for the time being in force or banking practice, this

Guarantee shall not be assignable, transferable by the beneficiary (i.e. GUVNL or Subsidiaries). Notice or

invocation by any person such as assignee, transferee or agent of beneficiary shall not be entertained by the

Bank. Any invocation of the Guarantee can be made only by the beneficiary directly.”

“NOTWITHSTANDING” anything contained herein before, our liability under this guarantee is restricted to

Rs.___________ (Rupees ___________________________ only). Our guarantee shall remain in force until

____________________ (Date of validity of the Guarantee). Unless demands or claims under this Bank

Guarantee are made to us in writing on or before_______ (Date of validity of the Guarantee), all rights of

Beneficiary under this Bank Guarantee shall be forfeited and we shall be released and discharged from all

liabilities there under:

Please Mention here Complete Postal Address Signature of the

of the Bank with Branch Code, Telephone and Bank’s Authorized Signatory with Official

Fax Nos. Round Seal.

NAME OF DESIGNATED BANKS:

• All Nationalized Banks including Public Sector Banks IDBI Bank Ltd.

• Private Sector Banks authorized by RBI to undertake the state Government business, which are (i) Axis

Bank (ii) ICICI Bank (iii) HDFC Bank

• Co-operative Banks and Commercial Banks and recognized/notified by Government of Gujarat (GoG)

Note: The Banks shall be the Banks recognized / notified by the Finance Department, Government of

Gujarat (GoG) from time to time.

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

AGREEMENT:

This agreement is made at ___________the ___day of______month _______Year between the

______ Gujarat Vij Company Ltd. &__________________________ (hereinafter referred to as “the

Contractor “which expression shall unless excluded by or repugnant to the context included its

successors or permit assigns) of the one part and the _______ Gujarat Vij Company Ltd. Having its

Regd. and Corporate Office at _____________________________ (hereinafter called “The

Company” which expression shall unless excluded by or repugnant of the context include its

successors of assigns) of the other part.

Whereas the aforesaid Company has accepted the tender of the aforesaid contractor for the work of

_________________________________________________________as per Company’s LOA No.

____________________, Dated ___________, hereinafter called “The works and more particularly

desorbed enumerated or referred to in the specifications, terms and

other letters and schedule of price which for the purpose of identification have been signed by The

Superintending Engineer/Executive Engineer,, Circle/Division, UGVCL on behalf of the

Company, a list where of is made out in the schedule here under written and all of which said

documents are deemed to form part of this contract and include in the expression “The works

“wherever herein used, upon the terms and subject to the conditions hereinafter mentioned.

And whereas the Company has accepted the tender of the contractors for the Maintenance &

Erection of HT / LT Line & T/C and HT/LT AB Cable up on the terms and subject to the

conditions herein mentioned.

1.) The contractors shall do and perform all works and things in this contract mentioned and

described or which are implied therein of therefore respectively or are reasonable necessary for

the completion of the works as mentioned and at the time in the manner and subject to the

terms conditions and stipulation contained in this contract and in consideration of the due

provision, executions, construction and completion of the works agreed to by the contractors as

aforesaid the company both hereby covenant with the contractor to pay all the claims of money

as and when they become due and payable to the contractor under the provisions of the

contract such payment to be made at such times in such manner as is provided by the contract.

2.) The conditions and covenant stipulation here in before in this contract are subject to and

without prejudice to the right of the company to enforce for delay and or any other rights

whatever including the right to reject and cancel on default or breach by the contract of the

conditions and the covenant as stipulated in the general conditions specifications form Or

tender schedule drawing etc. attached with the Company LOA No.

____________________________, Dated ____________.

3.) The Contractor will strictly follow the safety Rules and Regulations during the execution of

aforesaid work. The Contractor will also provide all required Safety Gadgets to his Supervisors

and labours to execute the work mentioned in Tender. On violating or breaking the Safety

Rules and Regulations, and if Supervisors/Labours are found without Safety Gadgets, “The

Company” reserves the right to take actions as per the terms and conditions mentioned in

Tender without any prejudice.

4.) The Company reserves the right to terminate the Contract either in part or in full due to reasons

other than those mentioned under clause entitled ‘Contractor’s Default’. The UGVCL shall in

such an event give fifteen (15) days’ notice in writing to the Contractor of his decision to do

5.) The Contractor upon receipt of such notice shall discontinue the work on the date and to the

extent specified in the notice, make all reasonable efforts to obtain cancellation of all orders

and Contracts to the extent they are related to the work terminated and terms satisfactory to the

Company, stop all further sub-contracting or purchasing activity related to the work

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

terminated, and assist “The Company” in maintenance, protection, and disposition of the works

acquired under the Contract by the Company. In the event of such a termination the Contractor

shall be paid compensation, equitable and reasonable, dictated by the circumstances prevalent

at the time of termination.

6.) If the Contractor is an individual or a proprietary concern and the individual or the proprietor

dies and if the Contractor is a partnership concern and one of the partners dies then unless “the

Company” is satisfied that the legal representatives of the individual Contractor or of the

proprietor of the propriety concern and in the case of partnership, the surviving partners, are

capable of carrying out and completing the Contract “the Company” shall be entitled to cancel

the Contract as to its in completed part without being in any way liable to payment of any

compensation to the estate of deceased Contractor and/or to the surviving partners of the

Contractor’s firm on account of the cancellation of the Contract. The decision of the

Company that the legal representatives of the deceased Contractor or surviving partners of the

Contractor’s firm cannot carry out and complete the Contract shall be final and binding on the

parties. In the event of such cancellation the Company shall not hold the estate of the deceased

Contractor and/or the surviving partners of the estate of the deceased Contractor and/or the

surviving partners of the Contractor’s firm liable to damages for not completing the Contract.

The contract value extent of supply delivery dates, specifications as other relevant matters may be

altered by mutual agreement and if so altered shall not be deemed or constructed to mean and to effect

or alter other terms and conditions of the contract and the contract so altered or revised shall be and

shall always be deemed to have been subject without prejudice to and stipulation.

In witness where of the parties here to have set their hands and seal this day and month year first

above written.

1. Signed sealed and delivered by for and on

Behalf of the presence of name and address.

2. Signed sealed and delivered by for and on behalf

Of The _________Gujarat Vij Company Ltd

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

INDEMNITY BOND

In consideration of the _______ GUJARAT VIJ COMPANY LTD., herein after known as the

COMPANY having given contract for the work of _________________________________

___________________________________________________________________as per A/T No.

__________________________, dated _______________ and all future contract that may be

awarded to me in the next one year and in Important instructions for submitting the Tender in clause

27 of the COMPANY’s tender and contract for work.

I residing at by this Bond bind myself responsible for and shall pay compensation to my workmen

payable under the workmen’s compensation ACT – 1923 (viii of 1923) hereinafter called the said Act

for death or injuries caused to the workmen engaged by this presents, if such compensation is paid by

the COMPANY as principal under such sub-section (1) of section 12 of the said Act on behalf of me,

to pay such amount of compensation on demand within 48 hours to the COMPANY that it might have

to spend as legal and other incidental charges in defending any suit or action arising out of the death of

injuries in regard to compensation paid to the workmen or heirs of the deceased workmen.

Now the condition of the above written Bond is such that any suit of action arising out of the death or

injuries to the workmen engaged by me. During the execution of work of said contract and all future

contracts that may be awarded to me in the next one year is filed by the worker against the

COMPANY, I shall imbrues to the COMPANY such sum that the COMPANY is required to spend as

legal and other incidental charges in defending such suit or action and also the amount that may be

ordered to be paid to the worker / or his heirs as compensation and that the above written bind shall

remain in full force and virtue till the COMPANY is required to defend such suit or action filed by the

workers and or heirs against the COMPANY. Further it is applicable on death of contractor himself

also. No any compensation will be claimed by legal heirs of contractor.

Witnesses:

Signature of the Executant

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Arrangement of Transformer

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

EARTHING ARRANGEMENT FOR TRANSFORMER CENTRE

SIGN & STAMP OF THE BIDDER

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Arrangements of Guy

1. Guy Clamp 2. Turn Buckle and Eye Bolt 3. Guy Insulator

4. Guy Wire 5. Guy Rod 6. Guy Pit (2 X 2 X 5 ft.)

7. θ 30 to 40 Deg.

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Double Pole (D.P.) Structure

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Guarding under 11 KV Line

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Guarding under LT Line

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

LT Line Horizontal Formation and Clearances (415 V)

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

LT Line Vertical Formation and Clearances (415 V)

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

LT Line Horizontal Formation and Clearances (230 V)

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

LT Line Vertical Formation and Clearances (230 V)

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal

Division Office: KALOL, Mahendra Mill Road, Kalol (N.G)-382721,

E-Mail:[email protected] Web Site: www.ugvcl.com

Sign & Stamp of the Bidder

Signature of Contractor & seal