Replacement of existing 2x10MVA. 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq. Ballari Dist. on Partial Turnkey Basis Call-5

Karnataka Power Transmission Corporation Limited

TECHNO - COMMERCIAL SHEETS

NOTE* For detailed scope of the work please refer Bid Documents.

BIDDERS TO READ CAREFULLY

THE FOLLOWING DOCUMENTS [DULY SIGNED BY AUTHORISED PERSON, WHEREVER NECESSARY] ARE TO BE UPLOADED AND BANK GUARANTEE TOWARDS EMD OVER AND ABOVE RS.10.00LAKH AS PER ANNEXURE-II OF THE BID DOCUMENT SHALL BE SENT IN ORIGINAL TO CHIEF GENERAL MANAGER, KPTCL, BENGALURU SO AS TO REACH THIS OFFICE AFTER THE LAST DATE OF SUBMISSION OF BID AND ON OR BEFORE THE DATE & TIME NOTIFIED FOR OPENING OF TECHNO COMMERCIAL BIDS, FAILING WHICH THE BID WILL NOT BE OPENED. 1) NO DEVIATION CERTIFICATE (SCHEDULE-16). 2) EMD/BID SECURITY AS DETAILED IN CLAUSE NO. 13 of ITT. 3) BANK GUARANTEE TOWARDS BALANCE EMD/BID SECURITY issued either by a Nationalized/Scheduled Bank. (For the balance EMD above Rs. 10Lakhs (SCHEDULE-17) - as detailed in Clause No. 13 of ITT-The Bidder shall scan the Bank Guarantee towards EMD and upload the same in the prescribed format in the slot specified for “EMD and Tender Fee Payments” in the e-procurement portal to enable the owner for verification of EMD BG at the time of opening of Techno Commercial Bid, failing which the offer will be rejected. 4) LETTER OF UNDERTAKING (SCHEDULE-18). 5) CONSORTIUM AGREEMENT (IF APPLICABLE-SCHEDULE-19) 6) POWER OF ATTORNEY (SCHEDULE- 20). 7) ANY OTHER AGREEMENTS /UNDERTAKINGS/SELF DECLARATIONS SPECIFIED IN THE TENDER.

KARNATAKA POWER TRANSMISSION CORPORATION LIMITED

BID PROPOSAL SHEET

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

Bid Proposal Reference :

Person to be contacted :

E-Mail Address:

The Chief Engineer Electy.,

Transmission (Operations) Zone

KPTCL, Kalaburagi-585105

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

a) * We have submitted bid as individual Bidder. (Indicate Name of the Individual Bidder)

b) * We have submitted bid in Consortium with the following Bidders. (Key in Consortium) VOID

Name of the Consortium Partner Scope / Participation of each Consortium Partner

(* Fill-up whichever is applicable)

1 We, the undersigned Bidder, having read and examined in detail the specifications and all the Bidding documents of the said work and hereby propose to design, manufacture/fabricate, shop test, supply on FOR site basis, and carry out the erection, testing and commissioning including civil, structural and architectural works for

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

2 PRICES AND VALIDITY :

2.1 We declare that the Prices stated in our Proposal are in accordance with subject Bid Documents (including Clause No.40 of "Conditions of Contract (CC)" & Clause No.12 of Instruction to Tenderers (ITT) of Bid Documents. We further declare that all Ex-works price/CIF components of Spares, Maintenance and Testing Equipments and other charges viz., Freight and Insurance, Type Test charges and other charges stated in our proposal shall be as per the Tender conditions. All the Price and other terms and conditions of this Proposal are valid during the Performance of the Contract.

2.2 All Duties, such as Custom Duties on imports, Levies, Surcharge/Cess etc., if any applicable on the transaction excluding GST are included in the Bid Price and shall be to Our account and the Owner is not having any liability whatsoever on this account, whatever may be the contrary elsewhere in the Bid documents. However the component of Duties included in the Bid Price are separately indicated in Schedule - 2 for TDS purpose. We further confirm that our Bid Prices as quoted in Schedule-I, include all import Duties and levies including Licence fees lawfully payable by us on imported items and all other Duties and Levies applicable on Bought-out Components, Materials, Equipment and other items and confirm that any such Duties and Levies additionally payable shall be to our account. We further confirm that, no Sales Tax in any form shall be payable by Owner either for Bought-out items which are despatched by our Sub-Suppliers directly to the Project Site or for items Supplied directly by us. We confirm that, the Prices quoted by us are excluding GST.

2.3 We declare that we have noted and considered Clause No.39 of Conditions of Contract (CC ), Clause No. 11.11 of Instruction to Tenderers(ITT) of Bid Documents regarding Taxes and Duties and quoted our Prices accordingly. We further agree for TDS as per Statutory stipulations.

2.4 The Bid Prices, the Price components of the various items in our Scope of Supply, Erection including Testing & Commisisoning, Civil and Mandatory spares is quoted in Itemwise Financial Bid in e-Procurement Portal for this proposal..

3 CONSTRUCTION OF THE CONTRACT : We, declare that we are making the Offer on the basis of Single Contract for the entire Scope of the Package in accordance with Clause No.26.2 of Instruction to Tenderers (ITT) of Bid Document.

4 We having studied Clause No.39 of Conditions of Contract (CC ), Clause No. 11.11 of Instruction to Tenderers(ITT) of Bid Documents , relating to Tax and we hereby, declare that if any income-tax, surcharge on income tax or any other corporate tax is attracted under the law, we agree to pay the same.

We have also ensured that the above Bid Guarantee furnished by us is in line with the Bid Documents and complete in respect of following :

1. Value of Non judicial Stamp Paper purchased in the name of executing Bank is as per Stamp Act.

2. Power of Attorney Number and Date as well as Signature and Full Name and Designation of Executant along with Bank's Stamp are there.

3. Signature, Full Name, Designation and address of Witness are there.

4. Completed Mailing address of the Head Office of the Bank is indicated.

6.1 We declare that the Works shall be performed strictly in accordance with the Specifications and Documents except for the variations and Deviations, all of which have been detailed out exhaustively in the following Schedules, irrespective of whatever has been stated to the contrary anywhere else in our Proposal.

a Commercial Deviations Schedule Schedule - 5

b Technical Deviations Schedule Schedule - 6

6.2 We further confirm that Specified Stipulation of following Clauses are acceptable to us and No Deviation / Exceptions are taken on any account whatsoever in the following Clauses.

a. Terms of payment Clause No. 37 of Section-5,Conditions of Contract (CC) and Clause No.8 of Special Conditions of Contrac (SCC)

b. EMD/Bid Security Clause No. 6, Section :1, Invitation for Tenders (IFT) and Clause No. 13, Section :2, Instruction to Tenderer (ITT)

c. Contract Performance Guarantee Clause No. 29 of Section:2, Instruction to Tenderers (ITT).

d. Penalty for delay Clause No. 41 of Section-5 : Conditions of Contract (CC).

e. Price Basis/ Price adjustment Clause No. 40 of Section-5 :Conditions of Contract (CC).

f. Defects Liability Period/Guarantee Clause No. 10 of Section-5 Special Conditions of Contract (SCC)

g. Work Schedule Clause No.17 of Section:5 Conditions of Contract (CC)

h. Taxes and Duties Clause No. 11.11 of Section-2: Instruction to Tenderers (ITT).

Further, we agree that additional conditions, if any, found in the Proposal Documents other than those stated in Deviation Schedules, save that pertaining to any rebates offered, shall not be given effect to.

7 PERFORMANCE GUARANTEE ; We declare that the ratings and performance figures of the equipment to be supplied and erected by us are guaranteed. The Guaranteed particulas of different equiment in our Scope are enclosed in Data Requirement Sheets.

8 BID PRICING : We further, declare that the Prices stated in our Proposal are in accordance with your ITT & SCC & all other relevant clauses of Bid Documents.

9 PRICE ADJUSTMENT : We declare that the Prices quoted by us are in accordance Clause No. 40 of Section-5 :Conditions of Contract (CC)

10 SPECIAL TOOLS AND TACKLES : We have given a list of Special Tools and Tackles in Schedule - 7 and Prices thereof are included in our lumpsum Bid Price. We further agree that any items of Special Tools and Tackles, though not included in the aforesaid list, but required for effective Erection, Testing, Commissioning & Operation of the Equipments of Substations & Transmission lines shall also be furnished by us, at no extra cost to you.

11 ADDITIONAL INFORMATION : In addition to the information called for in these Proposal Sheets, we have included with this Proposal, additional information as listed in Schedule - 8. We further confirm that such additional information does not imply any additional deviation beyond those covered in Schedule - 5 & 6 and in case of any contraction between these additional information and other provisions of Bid, the later will prevail.

12 QUALIFICATION DATA : We confirm having submitted the Qualification Data, as required by you in your Bid Documents in e-Procurement Portal along with this Proposal. Further we have filled in the information for Qualification Requirements in Schedule 9. In case you require any further information in this regard, We agree to furnish the same in time.

13 WORK SCHEDULE : If this Proposal is accepted by you, we agree to submit Engineering Data, Provide Services and complete the entire Work from time to time, in accordance with Schedules indicated in the Proposal. We fully understand that the Time Schedule stipulated in this Proposal is the essence of the Contract, if awarded. The completion schedule of the various Major Key Phases of the Work is indicated in Schedule - 11.

14 CONTRACT PERFORMANCE GUARANTEE ; We further agree that if our Proposal is accepted, we shall provide an irrecoverable Contract Performance Guarantee, of value equivalent to Five percent (5%) of the Amount Put to Tender (Excluding GST) plus additional security for unbalanced tenders in accordance with Clause 29 of Instructions To Tenderers (ITT) of the tender valid up to the end of ninety (90) days after the end of the Contract Guarantee Period mandatorily in the form of electronic Bank Guarantee (e-BG) from the Banks which are integrated with NeSL in the form attached as Annexure-III (Section 4: Formats of Annexures) in your favour in accordance with Clause 25.5 of ITT and Clause 43 of the CC (Conditions of Contract), as per the format given in Section 4 and enter into a formal agreement with you within Twenty (20) days from the date of issue of Letter of Intent to Award the Contract.

16 BID PRICE : We declare that our lumpsum Price for the entire scope of work specified in the specifications and documents, shall be as indicated in Schedule - 1.

17 CHECK LIST : We have included a Checklist duly filled in Schedule 22

18 We, hereby, declare that only the Persons or Firms interested in this Proposal are named herein as Principals and that no other Persons are interested in the Proposal or in the Contract to be entered into, if we are awarded the Contract, and that this proposal is made without any connection with any other Person, Firm or Party likewise submitting a Proposal and that this Proposal is in all respect for and in good faith, without collusion or fraud.

19 We declare, in case our bid is accepted, that until a formal Contract is prepared & executed, this bid together with your written letter of acceptance thereof and your notification of award /Letter of Intent to Award the Contract shall constitute a binding contract between us. We further understand that you are not bound to accept the lowest or any bid you may receive.

Thanking you, we remain,

Yours faithfully,

Place Printed Name

Business Address Country of Incorporation (State or Province to be indicated)

Name and Address Principal Officer

Karnataka Power Transmission Corporation Limited

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

FILL ONLY IN LIGHT BLUE COLOURED CELLS.

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

We declare that in terms of Clause No. 11 of ITT, Bid documents, the following are our lumpsum price in Rupees for the entire scope of work as specified in the Specifications and Documents.( Inclusive of all Taxes (Excluding GST) & Duties).

Total Lumpsum Price : ( In Figures) Note: Fill as "YES" against this column in case Prices are indicated in the Item-Wise Bid Financial Offer in figures

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

SCHEDULE - 2 (1 of 2)-SUMMARY OF PRICE COMPONENTS

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

FILL ONLY IN LIGHT BLUE COLOURED CELLS.

Summary of Price Components

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Summary price components for identified in accompanying specifications

( Name of the Work) as per the scope identified in accompanying specifications.

Sl no Description Amount in Rs. (Fill as "YES" against the above Price columns in case Prices are indicated in the Price templates)

A Material / Equipment Price (including Packing & Forwarding charges) in the Scope of the Contractor

i) Ex-works including all taxes & duties [As per schedules -

ii) Freight and Insurance Charges (Not Applicable) [As per schedules - 3A(i) for Station & 3B(i) for Line]

iii) Total FOR site price (i+ii)

B Mandatory spares price (including packing & forwarding charges)

i) Ex-works including all taxes & duties

ii) Freight and Insurance Charges(Not Applicable) (As per schedule -4)

iii)Total FOR site price (i + ii)

C Supply portion total FORD price [A+B]

D Erection portion:

i) Total charges for Erection, Testing & Commissioning of all Supply items [as per schedules-

ii) Total charges for entire civil works [ as per Schedules-

iii) Total civil works, erection, Testing and commisioning charges (i)+(ii)

E Total Bid Price = C+D(iii) In figures : Rs.

Total Bid Price in Figures : Rs.

Total Bid Price in words : Rupees

Note: The erection charges shall include the charges for taking delivery at Owner's store, unloading, handling, storage, erection, testing and commissioning of all equipments .

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

SCHEDULE - 2 ( 2 of 2 ) - TAXES(Excluding GST), DUTIES & OTHER LEVIES

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Fill IN LIGHT BLUE COLOURED CELLS.

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Estimates of Indian Taxes (Excluding GST), Duties and Levies included in the Total Bid Price are as follows:

SL. No. Description of Applicable Tax (Excluding GST) / Duty / Levy

Rate of Tax (Excluding GST)/ Duty / Levy Amount of Taxes (Excluding GST) / Duties in Rupees ⨀ࠀ慒整漠⁦慔⁸⠠硅汣摵湩⁧升⥔⼠䐠瑵⁹ 敌祶 X13Ȉ䄀 ⁦慔數⁳⠠硅汣摵湩⁧升⥔ 畄楴獥椠畒数獥ᄊ堀 ㄀਀䝓呓唯䝔呓tȈ䄀灰楬慣汢⁥慴數⁳⠠硅汣摵湩⁧升⥔‬畤楴獥☠氠癥敩⁳牰癥楡楬杮愠⁳湯琠敨†慬瑳搠瑡⁥景戠摩猠扵業獳潩桳污敢焠潵整ᅤ堀℀㄀ᄀ⹩匠灵汰⁹潐瑲潩ᑮ楩‮牅捥楴湯倠牯楴湯椀楩‮楃楶潐瑲潩Ѯ䝃呓䤀升⁔a䈀極摬湩⁧湡⁤瑯敨⁲潣獮牴捵楴湯眠牯敫獲眠汥慦敲䌠獥⁳潦⁲畓灰祬‬牅捥楴湯愠摮䌠癩汩倠牯楴湯眠牯獫 伀桴牥䰠癥敩硳⹡䄠灰楬慣汢⁥畃瑳浯⁳畄祴⠠⤪⠊楂摤牥⁳桳污污潳挠敬牡祬椠摮捩瑡⁥桴⁥牢慥畫⁰景䌠獵潴獭搠瑵⁹畳档愠⁳䍂ⱄ䌠獥ⱳ瑥⹣⤬¸戀‮晉琠敨敲椠⁳湡⁹硥獩楴杮吠敲瑡⁹敢睴敥湉楤⁡湡⁤桴⁥潣湵牴⁹牦浯眠敨敲琠敨朠潯獤爠煥極敲⁤潦⁲桴獩瀠潲敪瑣愠敲瀠潲潰敳⁤潴戠⁥浩潰瑲摥‬桴湥挠灯⁹景琠敨琠敲瑡⁹桳污敢甠汰慯敤⹤⠠瑏敨⁲慔數⁳…畤楴獥椠⁦湡⁹匨数楣祦 ⨪吀瑯污⠠畓景ㄠ琠〱̩⨨℩湉挠獡⁥景䌠䙉瀠牯楴湯漠⁦畓灰祬Ȯ⨪jȈ倀敬獡⁥灓捥晩⁹桴⁥慮畴敲漠⁦桴⁥瑯敨⁲慔數⁳⠠硅汣摵湩⁧升⥔愠潬杮眠瑩⁨桴⁥敤慴汩⁳湩琠敨∠慒整•潃畬湭⸮騀㴀㈀─䍓䕈啄䕌ⴠ㈠⁁›䍓䕈啄䕌传⁆䥄䍓問呎〠䡓䕅⁔但⁒䕔䡃低佃䵍剅䥃䱁传䕐䥎䝎⠠乕ⴠ倠䥒䕃⥄* 䥆䱌传䱎⁙义䰠䝉呈䈠啌⁅佃佌剕䑅䌠䱅卌‮ꄊ敗栠牥扥⁹景敦⁲湡甠据湯楤楴湯污搠獩潣湵⁴湯漠牵焠潵整⁤牰捩⁥湩匠档摥汵⁥′ㄨ漠㉦ 獡甠摮牥‮湁⁹楤捳畯瑮⁳景敦敲⁤湡睹牥⁥汥敳椠䈠摩猠慨汬渠瑯戠⁥潣獮摩牥摥Ԯ汓丮ቯ慎畴敲漠⁦楄捳畯瑮倀牥散瑮条⁥景搠獩潣湵整ࠀ流畯瑮⠠湩删⹳਩䘨汩湩愠⁳大卅‧湩挠獡⁥牐捩獥愠敲椠摮捩瑡摥椠桴⁥䤠整⵭楗敳䈠摩䘠湩湡楣污传晦牥ᄩᜀ搀㄀܀敒慭歲ų牉ࠀ畓灰祬匠档摥汵獥†††††††††††††††††††††愊 硅眭牯獫瀠楲散ੳ†††††††††††††††††ਠ12'Ȉ戀 牆楥桧⁴…湉畳慲据⁥丨瑯䄠灰楬慣汢⥥›2䤀቉牅捥楴湯匠档摥汵獥䤀䥉䌀癩汩圠牯獫匠档摥汵獥<匀䡃䑅䱕ⵅ㈠䈠ⴠ匠䅔䕔䕍呎传⁆佃䵍剅䥃䱁吠剅卍䄠䑎䌠乏䥄䥔乏╓†䡓䕅⁔但⁒䕔䡃低佃䵍剅䥃䱁传䕐䥎䝎㠠
敄慴汩⁳景瀠祡敭瑮⁳慭敤椠桴⁥潦浲漠⁦牃摥瑩挠牡⽤敄楢⁴慣摲丯䙅⽔呒升伯䍔⠠癯牥琠敨挠畯瑮牥 獡瀠牥琠敨琠湥敤⁲潣摮瑩潩獮猠潨汵⁤敢欠祥摥椠条楡獮⁴潣畬湭渠⹯㌠⠠⥡⸠䈊⁇流畯瑮‬䝂丠⹯愠摮搠瑡ⱥ丠浡⁥湡⁤摡牤獥⁳景琠敨戠湡獩畳湩⁧桴⁥䝂‬慶楬楤祴漠⁦桴⁥䝂†桳畯摬戠⁥敫敹⁤湩†条楡獮⁴潣畬湭渠⹯㌠⠠⥢⸠ਠ
(䘀䱉⁌乏奌䤠⁎䥌䡇⁔䱂䕕䌠䱏問䕒⁄䕃䱌⹓ⴠ匠䅔䕔䕍呎传⁆佃䵍剅䥃䱁吠剅卍䄠䑎䌠乏䥄䥔乏ݓ汓‮潎మ慐瑲捩汵牡⁳䐀瑥楡獬䈀摩瀠潲潰慳潦浲唠汰慯敤⹤"一敤楶瑡潩散瑲晩捩瑡⁥灕潬摡摥خ⸳愠⸩ǡ̉䔀䴀䐀 ⼀ 䈀椀搀 匀攀挀甀爀椀琀礀 ਀䈀椀搀猀 猀栀愀氀氀 戀攀 愀挀挀漀洀瀀愀渀椀攀搀 戀礀 戀椀搀 猀攀挀甀爀椀琀礀 ⠀䔀䴀䐀⤀㬀਀਀㄀⤀ 刀猀㨀㈀Ⰰ Ⰰ ⼀ⴀ਀吀栀攀 昀漀氀氀漀眀椀渀最 洀漀搀攀猀 漀昀 瀀愀礀洀攀渀琀 眀椀氀氀 戀攀 瀀爀漀瘀椀搀攀搀 愀猀 愀 瀀愀爀琀 漀昀 攀ⴀ倀愀礀洀攀渀琀 猀攀爀瘀椀挀攀猀⸀਀∀†䌀爀攀搀椀琀 䌀愀爀搀⼀䐀攀戀椀琀 䌀愀爀搀਀∀†一攀琀 䈀愀渀欀椀渀最਀∀†一䔀䘀吀⼀刀吀䜀匀਀∀†伀瘀攀爀ⴀ琀栀攀ⴀ䌀漀甀渀琀攀爀 ⠀伀吀䌀⤀਀∀†䤀䴀倀匀਀䘀漀爀 昀甀爀琀栀攀爀 搀攀琀愀椀氀 爀攀最愀爀搀椀渀最 洀漀搀攀 漀昀 攀ⴀ瀀愀礀洀攀渀琀 漀昀 䔀䴀䐀 椀渀 攀ⴀ瀀爀漀挀甀爀攀洀攀渀琀 瀀氀愀琀昀漀爀洀Ⰰ 挀漀渀琀愀挀琀 攀ⴀ瀀爀漀挀甀爀攀洀攀渀琀 挀攀氀氀Ⰰ 䜀漀瘀攀爀渀洀攀渀琀 漀昀 䬀愀爀渀愀琀愀欀愀⸀਀਀਀ꘀ圀꜀ᜀ됀㈀܀††⥢⸮ࠀ䔠䑍愠潭湵⁴扡癯⁥獒ㄮ䰰歡⁨祢䈠湡畇牡湡整⁥2嘀污摩瑩⁹景琠敨䈠摩ᠮ畑污晩楹杮删煥極敲敭瑮⹳䘀湩湡楣污挠灡扡汩瑩౹牐捩⁥慂楳⹳吀硡獥☠䐠瑵敩⹳䌀浯汰瑥潩捓敨畤敬 倀祡敭瑮吠牥獭6匀䡃䑅䱕⁅‭䄳椨 ⴠ倠楲散䈠敲歡灵映牯ⴠ匠灵汰⁹潰瑲潩Ѯ潔‬;䈀䑉䕄卒匠䅈䱌䘠䱉⁌乏奌䤠⁎䡔⁅䥌䡇⁔䱂䕕䌠䱏問䕒⁄䕃䱌⹓†匀灵汰⁹潰瑲潩غ汓丠⹯一浡⁥景琠敨䔠畱灩敭瑮䴯瑡牥慩獬唀楮ࡴ畑湡楴祴=䤀摮捩瑡⁥桷瑥敨⁲伢湷洠湡晵捡畴敲⁤瑉浥•牯∠潂杵瑨传瑵䤠整≭䤀摮捩瑡⁥潣湵牴⁹景传楲楧ɮㅁ倀睯牥吠慲獮潦浲牥ɚȈ倀睯牥吠慲獮潦浲牥㩳ਠ⥡㈠‰噍ⱁㄠ〱ㄯ欱ⱖ䐠汥慴匯慴Ⱳ䐠湹ㄱ‬ⴳ桐‬〵穈‬潃敲吠灹ⱥ㈠圠湩楤杮䐠汥慴匯慴⁲牴湡晳牯敭Ⱳ瘠捥潴⁲牧畯⁰奄ㅮ‱楷桴传呌⁃乏乁伯䅎⁆楷桴映湡挠湯牴汯挠扵捩敬‬呒䍃倠湡汥‬畎敭楲慣呒䍃瀠湡汥‬楦獲⁴楦汬湩⁧景传汩愠摮ㄠ┰猠慰敲漠汩椠潮⵮敲畴湲扡敬搠畲獭攠捴Ⱞ挠浯汰瑥⁥楷桴吠牥業慮潣湮捥潴獲猠極慴汢⁥潦⁲楓杮敬䐠慲敫䴯潯敳䄠千⁒湯瀠楲慭祲猠摩⁥漠⁦牴湡晳牯敭⁲湡⁤′潮⁳景挠灯数⁲汦瑡映牯攠捡⁨桰獡⁥牦浯䰠⁖楳敤漠⁦牔湡晳牯敭⁲湡⁤′潎⁳景挠灯数⁲汦瑡⁳牦浯渠略牴污琠牥業慮潴攠牡桴慭⁴桴潲杵⁨䍎⁔污湯⁧楷桴渠捥獥慳祲猠灵潰瑲瀠湩椠獮汵瑡牯⁳獡瀠牥猠数楣楦慣楴湯⹳㐨‵呍)℀᐀Ḁ̀潎మ偋䍔⁌畓灰祬Ü一瑩潲敧湉敪瑣潩楦敲攠瑸湩畧獩楨杮猠獹整⵭畳灰祬湩Ⱨ攠敲瑣潩…湩汣極湤⁧楣楶湅楧敮牥湩⁧潷歲ⱳ猠慯楰⁴瑥⹣‬獡瀠牥琠敨爠捥浯敭摮楡湯漠⁦桴⁥畳灰楬牥漠⁦桴⁥楦敲氠杩瑨湩⁧祳瑳浥映牯倠睯牥吠慲獮潦浲牥戠汥睯〱‰噍Ɂ潎䄀ጲ畃牲湥⁴牔湡晳牯敭潲ㄱ噫挠慬獳漠瑵潤牯䌠牵敲瑮吠慲獮潦浲牥漠⁦慲楴㈱〰㠭〰ㄯㄭㄭ䄠眠瑩⁨⸰′捡畣慲祣挠慬獳映牯ㄠ欱⁖慂歮䤠据浯牥Р潎⹳®㄀欱⁖汣獡ⱳ㈠欵⁁敎瑵慲畃牲湥⁴牔湡晳牯敭⁲景爠瑡潩ㄠ〲ⴰ〸⼰ⴱⴱ‱⁁潦⁲䕒剆瀠潲整瑣潩楷桴琠牥業慮潣湮捥潴⁲畳瑩扡敬映牯㈠丠獯‮景䌠灯数⁲汦瑡⁳愠⁳数⁲灳捥晩捩瑡潩獮Ȯ㍁䤀体䅌佔卒㨠ㄠ欱⁖獉汯瑡牯虳ㄱ噫椠潳慬潴Ⱳ搠畯汢⁥牢慥〴䄰‬㔲䅫挠灡捡瑩⁹楷桴爠杩摩戠⵩敭慴汬捩琠牥業慮潣湮捥潴⁲畳瑩扡敬映牯䌠祯瑯⁥䍁剓映牯†慣慰楣潴⁲慂歮匀瑥v㄀欱⁖獩汯瑡牯‬楳杮敬戠敲歡㐠〰ⱁ眠瑩⁨潒獡整⁲佇ⱓ眠瑩⁨楲楧⁤楢敭慴汬捩琠牥業慮潣湮捥潴⁲畳瑩扡敬映牯挠祯瑯⁥䍁剓献ㄱ噫椠潳慬潴Ⱳ搠畯汢⁥牢慥㈱〰ⱁ㈠欵⁁慣慰楣祴眠瑩⁨楲楧⁤楢洭瑥污楬⁣整浲湩污挠湯敮瑣牯猠極慴汢⁥潦⁲牄歡⁥䍁剓Ƞ㑁w匀剕䕇䄠剒卅佔⁒›倨牯散慬湩栠畯楳杮 敭慴硯摩ⱥ䜠灡敬獳琠灹⁥楷桴爠杩摩戠浩瑥污楬⁣潣湮捥潴獲猠極慴汢⁥潦⁲牄歡⁥䍁剓$㤀欠ⱖㄠ欰⁁楷桴挠湯敮瑣牯愠摮挠慬灭Ƞ㕁 慃慰楣潴⁲慂歮›⸲䴹䅖牒
敄楳湧‬湅楧敮牥湩Ⱨ猠灵汰ⱹ攠敲瑣潩Ɱ琠獥楴杮☠挠浯業獳潩楮杮漠⁦⸲䴹䅖Ⱳㄠ⸲欱⁖慃慰楣潴⁲慂歮‬瑳牡挠湯敮瑣摥‬潄扵敬䈠湡楷桴椠瑮牥慮畦敳ⱳ琠牥業慮潣湮捥潴獲眠瑩⁨畳瑩扡敬渠略牴污䌠⁔湡⁤瑳瑡潩汣獡⁳䅌ⱳ〠㈮‥敳楲獥爠慥瑣牯漠敮瑵慲楳敤眠瑩⁨潭湵楴杮猠牴捵畴敲⁳潦⁲䍎ⱔ䌠灡捡瑩牯䈠湡Ⱬ猠慴楴湯挠慬獳䰠獁‬敓楲獥爠慥瑣牯攠捴⸬挠浯汰瑥⁥獡瀠牥猠数楣楦慣楴湯䄀㜶瑓瑡潩瑳畲瑣牵獥㨠ㄠ欱⁖楳敤⠠噌猠摩⁥景琠慲獮潦浲牥꼩畓灰祬湩⁧…牥捥楴湯漠⁦潄扵敬瀠汯⁥瑳畲瑣牵⁥楷桴㤠㔮䴠獴‮䍒⁃潰敬⁳䱗㌠〰䬠獧映牯洠畯瑮湩⁧ㄱ噫㐠〰䄠删慯瑳牥䤠潳慬潴獲†湡⁤欹ⱖㄠ欰⁁畳杲⁥牡敲瑳牯⠠″潎⤮挠浯汰瑥⁥敳⁴☮ㄱ噫䜠协䌯扡敬吠牥業慮楴杮猠牴捵畴敲†R㄀䬱⁖慃汢⁥敔浲湩瑡湩⁧瑓畲瑣牵⁥潦⁲噌匠摩⁥景吠慲獮潦浲牥〨〮㈷琠倠牥匠牴捵畴敲ԩ潎䴯ݔ⼱⸰㜰匲ㄱ噋䜠协䌯扡敬吠牥業慮楴杮匠牴捵畴敲映牯ㄠ䬱⁖慃慰楣潴⁲慂歮〨ㄮ㠵琠瀠牥猠牴捵畴敲ܩ⼲⸰ㄳȶ㝁{㄀ㄮ欠⁖片摡⁥噐⁃湉畳慬整⁤牡潭牵摥挠灯数⁲潣瑮潲慣汢獥漠⁦楳敺ⱳ楷桴䰠杵⽳敆牲汵獥䜯慬摮愠⁳数⁲整档楮慣灳捥晩捩瑡潩獮㄀䌹砠㈠㔮匠⹱浭䴀牴౳䌴砠㘠匠⹱浭㈀⁃⁸⸲‵煓洮౭䌴砠㐠匠⹱浭䄀းㄱ噫猠楷捴杨慥㩲ȼ㄀欱ⱖ㔲䅫‬敍慴汣摡嘠䉃†睳瑩档敧牡⠠㘱〰⁁潦⁲湩潣敭⁲…㈱〵⁁潦⁲敦摥牥⥳漠瑵潤牯琠灹ⱥ攠捡⁨潣灭楲楳杮漠⁦䤱振㐫⭆䌲⭂䄱⁐爨浥瑯⁥愠湮湵楣瑡潩畣潣瑮潲慰敮眩瑩⁨呃⁳…呐⁳攠捴Ⱞ挠浯汰瑥牥愠⁳数⁲整档楮慣灳捥晩捩瑡潩⹮上瑯㩥ㄠ‮桔⁥睳瑩档敧牡映牯挠灡捡瑩牯戠湡桳污慨敶渠捥獥慳祲漠敶⁲潶瑬条⁥ 湵敤⁲潶瑬条⁥ 楣捲汵瑡湩⁧畣牲湥⁴敲慬獹☠漠桴牥瀠潲整瑣潩敲慬獹愠⁳数⁲灳捥晩捩瑡潩਩⸲吠敨爠浥瑯⁥愠湮畯据慩楴湯挠浵挠湯牴汯瀠湡汥椠⁳楳灭敬⁸祴数ਮ⸳吠敨攠敬瑣潲楮⁣牴癩捥潴⁲敭整獲眠瑩⁨䉁⁔…佔⁄敦瑡牵獥‬䱄卍瀠潲潴潣湥牥祧洠瑥牥栠獡琠敢瀠潲楶敤ɤ㥁I䠀⁖慃汢獥ㄺ欱⁖䝕挠扡敬眠瑩⁨桴⁥敲畱物摥挠扡敬琠牥業慮楴湯⁳瑡戠瑯⁨湥獤Z㄀‱噫挠慬獳ㄠ堠ㄠ〰‰煓洠⁕⁇慃汢⁥堠偌⁅昨潲ㄱ⼰ㄱ噫琠慲獮潦浲牥⁳潴ㄠ欱⁖睳瑩档敧牡̩瑍干ㄱ欠⁖汣獡⁳″⁘㐲‰煓洠⁕⁇慃汢⁥堠偌⁅昨潲ㄱ噫猠楷捴杨慥⁲潴ㄠ欱⁖慴敫漠晦䐠⁐瑳畲瑣牵⥥b䠀慥⁴桳楲歮扡敬琠灹⁥慃汢⁥整浲湩瑡潩楫獴猠極慴汢⁥潦⁲‱⁸〱〰匠⹱浭堠偌⁅慣汢⁥ 湉潤牯琠灹⁥戩效瑡猠牨湩慫汢⁥祴数䌠扡敬琠牥業慮楴湯欠瑩⁳畳瑩扡敬映牯ㄠ砠ㄠ〰‰煓洮䱘䕐挠扡敬⠠畏⁴潤牯琠灹⥥a䠀慥⁴桳楲歮扡敬琠灹⁥慃汢⁥整浲湩瑡潩楫獴猠極慴汢⁥潦⁲″⁸㐲‰煓洮䱘䕐挠扡敬⠠䤠摮潯⁲祴数⤠a䠀慥⁴桳楲歮扡敬琠灹⁥慃汢⁥整浲湩瑡潩楫獴猠極慴汢⁥潦⁲″⁸㐲‰煓洮䱘䕐挠扡敬⠠畏⁴潤牯琠灹⥥䄀〱1䔀畱灩敭瑮⁳潦⁲獥慴汢獩楨杮匠䅃䅄䌠浯畭楮慣楴湯㨠K䴀汵楴䘠湵瑣潩慮牔湡摳捵牥⠠䙍⥔〠㈮⁓汣獡⁳湩汣摵湩⁧慬潢牵⠠慭歲瑥爠瑡⥥6伀瑰潃灵敬⁲ ㄱ嘰䐠⥃椠据畬楤杮氠扡畯⁲洨牡敫⁴慲整ᴩ慃汢獥†匭灵汰楹杮愠摮䰠祡湩

1 ⽌䁳畃牲湥⁴慃汢獥䌭灯数⁲潃敲眠瑩⁨⽣⁳⸴‰煳洮畍瑬獩牴湡⁤‴潃敲A嘀汯慴敧†慃汢獥䌭灯数⁲潃敲眠瑩⁨⽣⁳⸲‵煳洮畍瑬獩牴湡⁤‴潃敲J匀杩慮慃汢獥愭浲畯敲⁤潃灰牥䌠牯⁥楷桴挠猯〠㔮猠⹱浭䴠汵楴猠牴湡⁤〱䌠牯䑥潃瑮潲䌠扡敬⵳䌠灯数⁲潃敲眠瑩⁨⽣⁳⸱‵煳洮畍瑬⁩瑳慲摮ㄠ‰潃敲^Ȉ一瑯㩥吠敨愠瑣慵慭整楲污⽳畱湡楴祴爠煥極敲⁤慭⁹敢愠獳牥慴湩摥椠潣獮汵慴楴湯眠瑩⁨䕓⁅䍓䑁A℀ԀḀ̀ㅁᔱ慅瑲⁨慍⁴潦浲瑡潩债煅極浰湥獴渠浡⁥汰瑡獥☠攠牡桴湩⁧慮敭瀠慬整⁳湩汣摵湩⁧楦楸杮愠⁴畯摴潯⁲慹摲‮䄀㈱TĈ匀䅔䥔乏☠夠剁⁄䥌䡇䥔䝎⠠問䑔住⥒†吨敢搠獥杩敮Ɽ愠獳獥敳⁤…畱瑯摥戠⁹桴⁥楢摤牥〈Ḁ縀畓灰祬湩⁧湡⁤牥捥楴湯漠⁦慹摲氠杩瑨湩⁧瑳畲瑣牵⁥污湯⁤楷桴䜠⁉楰数映牯映硩湩⁧景䰠䑅氠浡⁰〨ㄮ㈸䴠⁔‫┵䈠並 ⸸洵牴†敨杩瑨一獯Á匀灵汰楹杮愠摮映硩湩⁧桳敥⁴敍慴潢⁸慭敤漠瑵漠⁦㠱匠䝗猠敨瑥洠瑥污眠瑩⁨敮散獳牡⁹潨敬⁳潦捲扡敬 潣摮極⁴湥牴⁹獡爠煥極敲⁤楷桴漠敮挠慯⁴景瀠楲敭⁲景愠灰潲敶⁤慭敫攠捴ਮ㈨〰浭砠㈠〰浭砠㘠洵⥭›倀䍖䤠獮汵瑡摥䌠灯数⁲潃瑮潲慃汢獥㨠ㄠㄮ䬠⁖噐⁃湩畳慬整⁤潃灰牥䌠湯牴汯䌠扡敬眠瑩⁨汧湡獤䰯杵⽳䘠牥畲敬⁳瑥⁣獡瀠牥琠捥湨捩污猠数楣楦慣楴湯‮㈊⁃⁸‶煳浭.匀灵汰楹杮愠摮映硩湩⁧景㘠㌭′⁁楓杮敬瀠汯⁥䍍畓灰祬漠⁦䕌⁄瑓敲瑥氠杩瑨氠浵湩楡敲眠瑩⁨牰獥畳敲搠敩挠獡⁴污浵湩畩潨獵湩⁧潢祤映牯漠瑰浩污琠敨浲污搠獩楳慰楴湯‮慌灭挠浯慰瑲敭瑮挠浯牰獩湩⁧景愠瑮⁩汧牡⁥汣慥⁲楤晦獵牥眠瑩⁨湉敪瑣潩潭汵敤⁤潰祬慣扲湯瑡⁥慭整楲污䰊䑅猠牴敥汴杩瑨㈠〰͗ㅁሳ䥍䍓䱅䅌低单䤠䕔卍+刀扵敢⁲慭獴ㄠ〰‰浭砠ㄠ〰‰浭砠ㄠ‰浭猠穩⁥u匀䡃䑅䱕⁅‭䄳椨⥩†‭牐捩⁥牂慥畫⁰潦⁲‭剅䍅䥔乏倠剏䥔乏䤠䍎啌䥄䝎吠卅䥔䝎☠䌠䵏䥍卓佉䥎䝎愠摮䐠卉䅍呎䥌䝎倠剏䥔乏‮K䔀䕒呃佉⁎佐呒佉⁎‬敔瑳湩⁧…潃浭獩楳湯湩⁧愠摮䐠ⵥ潣浭獩楳湯湩⁧潰瑲潩›䔀䕒呃佉⁎佐呒佉⁎娺ࠂ潐敷⁲牔湡晳牯敭獲›愊 〲䴠䅖‬ㄱ⼰ㄱ噫‬敄瑬⽡瑓牡‬祄ㅮⰱ㌠倭ⱨ㔠䠰ⱺ䌠牯⁥祔数‬′楗摮湩⁧敄瑬⽡瑓牡琠慲獮潦浲牥‬敶瑣牯朠潲灵䐠湙ㄱ眠瑩⁨䱏䍔传䅎⽎乏䙁眠瑩⁨慦潣瑮潲畣楢汣ⱥ删䍔⁃慐敮ⱬ丠浵牥捩污删䍔⁃慰敮ⱬ映物瑳映汩楬杮漠⁦楏湡⁤〱‥灳牡⁥楯湩渠湯爭瑥牵慮汢⁥牤浵⁳瑥⹣‬潣灭敬整眠瑩⁨敔浲湩污挠湯敮瑣牯⁳畳瑩扡敬映牯匠湩汧⁥牄歡⽥潍獯⁥䍁剓漠牰浩牡⁹楳敤†景琠慲獮潦浲牥愠摮㈠渠獯漠⁦潣灰牥映慬⁴潦⁲慥档瀠慨敳映潲噌猠摩⁥景吠慲獮潦浲牥愠摮㈠丠獯漠⁦潣灰牥映慬獴映潲敮瑵慲整浲湩污琠慥瑲浨瑡琠牨畯桧丠呃愠潬杮眠瑩⁨敮散獳牡⁹畳灰牯⁴楰湩畳慬潴獲愠⁳数⁲灳捥晩捩瑡潩獮⠮㔴䴠⥔ ;^Ȉ一瑯㩥吠敨愠瑣慵慭整楲污⽳畱湡楴祴爠煥極敲⁤慭⁹敢愠獳牥慴湩摥椠潣獮汵慴楴湯眠瑩⁨䕓⁅䍓䑁A Ԁ㬀대ࠀ片畯摮湩⁧景攠畱灩敭瑮⁳楷桴†〵砠㘠洠䥇映慬⁴湡⁤潣湮捥楴杮†煥極浰湥獴琠桴⁥慥瑲⁨慭⽴牧畯摮瀠瑩椠据畬楤杮愠汬挠湯敮瑣摥眠牯獫眠瑩⁨污慭整楲污⁳畳灰楬摥戠⁹桴⁥潣瑮慲瑣牯Ḯ䜀␀䠀Ԁ浒牴⸮
牐癯摩湩⁧⹃⹉倠灩⁥景ㄠ〰浭䤠⁄㌱浭琠楨正㈠㜮‵瑭⹲氠湯⁧楷桴㈠瀠牡⁴䥇䘠慬⁴〵㙸浭挠慬灭†敷摬摥愠汬爠畯摮琠敨瀠灩⁥瑥⹣‬湩汣摵湩⁧潣瑳漠⁦硥慣慶楴湯⠠污慭整楲污⁳畳灰楬摥戠⁹潣瑮慲瑣牯 牰癯摩湩⁧…慬楹杮栠浯杯湥潥獵洠硩畴敲漠⁦档牡潣污氠浵獰‬慳瑬愠摮猠湡⁤污潲湵⁤桴⁥楰数愠⁳数⁲灳捥楦慣楴湯猀瑥Z匀灵汰楹杮愠摮映硩湩⁧㔴洰楤⁡⁸㔴洰敨杩瑨ㄠ㔮•潴㈠•畈敭瀠灩⁥潣汬牡⁳潦⁲慥瑲⁨楰獴吮ࠀ
呓呁佉⁎…䅙䑒䰠䝉呈义⁇伨呕佄剏 ⠠潔戠⁥敤楳湧摥‬獡敳獳摥☠焠潵整⁤祢琠敨戠摩敤⥲#;}匀灵汰楹杮愠摮攠敲瑣潩景礠牡⁤楬桧楴杮猠牴捵畴敲愠潬摮眠瑩⁨䥇瀠灩⁥潦⁲楦楸杮漠⁦䕌⁄慬灭⠠⸰㠱′呍⬠㔠‥♂⥎㠠㔮瑭⁲栠杩瑨吀獥楴杮☠䌠浯業獳潩楮杮̠瑑ٹ䱓丮⹏䐀捥浯業獳楳湯湩ѧ乕呉儀奔䐀༱慌潢牵挠慨杲獥尺楄浳湡汴湩⁧景ㄠ‰噍ⱁㄠ〱ㄯ欱ⱖ†牔湡晳牯敭⁲楷桴愠捣獥潳楲獥挠浯汰瑥⁥楷桴吠慲獮潦浲牥漠汩s䴀癯湩⁧景吠慲獮潦浲牥映潲桴⁥汰湩桴琠桴⁥潬摡湩⁧潰湩⁴獡瀠牥搠物捥楴湯漠⁦楳整䔠杮湩敥⹲㌊䴵⁔⁸〵瑍獲砠㴲㔳〰䴀⽔瑍獲刀汥慥敳漠⁦ㄱ噫挠慬獳丠呃 低刀汥慥楳杮漠⁦ㄱ噫挠慬獳䌠ɔ低?匀䡃䑅䱕⁅‭䌳椨 ⴠ倠楲散䈠敲歡灵映牯ⴠ匠慴楴湯䌠癩汩倠牯楴湯‮䌀噉䱉圠剏卋倠剏䥔乏㨠ܠ汓ਮ潎ମ慐瑲捩汵牡ѳ瑑⹹䈀༱ࠂ慅瑲⁨潷歲攠捸癡瑡潩潦⁲潆湵慤楴湯戠⁹敭档湡捩污洠慥獮映牯愠汬眠牯獫☠搠灥桴甠瑰″Ɑ愠⁳数⁲牤睡湩⁧湡⁤整档楮慣灳捥晩捩瑡潩獮‬湩汣摵湩⁧敳瑴湩⁧畯ⱴ猠潨楲杮‬瑳畲瑴湩Ⱨ戠牡楲慣楤杮‬慣瑵潩楬桧獴‬湩汣摵湩⁧牤獥楳杮漠⁦硥慣慶整⁤畳晲捡獥‬楤灳獯湩⁧景⁦牯氠癥汥楬杮琠敨攠捸癡瑡摥攠牡桴漠⁲潳瑲湩⁧…瑳捡楫杮琠敨猠汥捥整⁤慥瑲⁨潦⁲敲獵⁥湩愠爠摡畩⁳景㔠‰湡⁤楬瑦甠瑰⸱‵湩汣摵湩⁧潣瑳漠⁦慬潢牵‬潴汯ⱳ甠慳敧漠⁦慭档湩牥⁹…瑯敨⁲灡異瑲湥捡獥爠煥極敲⁤潴挠浯汰瑥⁥桴⁥潷歲‮䤊污楫摮⁳景猠楯獬䐠灥桴甠瑰″m娀㠀嘀㤀㨀威̀畣ɭ㉂ƜЈ䌀湯瑳畲瑣潩景䔠扭湡浫湥⁴祢攠捸癡瑡湩⁧桴⁥癡楡慬汢⁥灡牰癯摥䜠慲敶⽬畍牲浵搠灥獯瑩摥愠⁴⁡汰捡⁥牯戠牯潲⁷楰獴搠牵湩⁧牯瀠楲牯攠捸癡瑡潩楷桴愠汬氠晩獴愠摮氠慥Ɽ琠慲獮潰瑲瑡潩潴猠瑩ⱥ猠牰慥楤杮‬牧摡湩⁧潴爠煥極敲⁤汳灯⁥湡⁤潣灭捡楴杮琠敭瑥琠敨爠煥極敲敭瑮挠浯汰瑥⁥獡瀠牥猠数楣楦慣楴湯ⱳ椠据畬楤杮挠獯⁴景氠扡畯Ⱳ潲汬湩Ⱨ眠瑡牥愬汬洠瑡牥慩獬甬慳敧…污瑯敨⁲灡異瑲湥捡獥爠煥極敲⁤潴挠浯汰瑥⁥桴⁥潷歲.娀ༀ㨀က娀ᬀ㨀Ȁ㍂āȈ䘀汩楬杮愠慶汩扡敬攠捸癡瑡摥攠牡桴⠠硥汣摵湩⁧潲正 湩琠敲据敨ⱳ瀠楬瑮ⱨ猠摩獥漠⁦潦湵慤楴湯⁳湡⁤瑯敨⁲楳業慬⁲潷歲⁳瑥⹣椠慬敹獲渠瑯攠捸敥楤杮㈠挰湩搠灥桴‬潣獮汯摩瑡湩⁧慥档搠灥獯瑩摥氠祡牥戠⁹慲浭湩⁧湡⁤慷整楲杮‬敬摡甠⁰潴㔠‰湡⁤楬瑦甠瑰⸱‵⹭Z!:䈀䄴ࠂ牐癯摩湩⁧湡⁤慬楹杮椠潰楳楴湯䌠浥湥⁴潃据敲整映牯氠癥汥楬杮挠畯獲⁥潦⁲污潷歲⁳湩映畯摮瑡潩⹮吠敨朠慲楮整琯慲⽰慢慳瑬挠畲桳摥朠慲敤⁤潣牡敳愠杧敲慧整⁳湡⁤楦敮愠杧敲慧整⁳獡瀠牥爠汥癥湡⁴卉䌠摯獥洠捡楨敮洠硩摥‬慬摩椠慬敹獲渠瑯攠捸敥楤杮ㄠ〵洠桴捩湫獥ⱳ眠汥潣灭捡整⁤獵湩⁧汰瑡⁥楶牢瑡牯ⱳ椠据畬楤杮愠汬氠慥⁤…楬瑦ⱳ挠獯⁴景愠汬洠瑡牥慩獬漠⁦畱污瑩ⱹ氠扡畯Ⱳ唠慳敧挠慨杲獥漠⁦慭档湩牥ⱹ挠牵湩⁧湡⁤污桴⁥瑯敨⁲灡異瑲湥湡散⁳敲畱物摥琠潣灭敬整琠敨眠牯獡瀠牥琠捥湨捩污猠数楣楦慣楴湯⹳ਠ䴠硩ㄠ㌺㘺⠠ㅍ⤰唠楳杮㈠‰浭渠浯湩污猠穩⁥牧摡摥挠畲桳摥挠慯獲⁥条牧来瑡獥ᠠ娀㄀㨀威Ȁ㕂ʡĈ倀潲楶楤杮愠摮氠祡湩⁧湩瀠獯瑩潩敃敭瑮䌠湯牣瑥⁥潦⁲污潆湵慤楴湯眠牯獫‮桔⁥牧湡瑩⽥牴灡戯獡污⁴牣獵敨⁤牧摡摥挠慯獲⁥条牧来瑡獥愠摮映湩⁥条牧来瑡獥愠⁳数⁲敲敬慶瑮䤠⁓潃敤⁳慭档湩⁥業數⁤楷桴猠灵牥瀠慬瑳捩穩牥⁳慬摩椠楦楮桳摥氠祡牥ⱳ眠汥潣灭捡整⁤獵湩⁧敮摥敬瘠扩慲潴獲‬湩汣摵湩⁧污敬摡☠氠晩獴‬潣瑳漠⁦污慭整楲污ⱳ焠慵楬祴挠湯楦浲湩⁧潴琠敨爠煥極敲敭瑮⁳景爠汥癥湡⁴卉挠摯獥‬慬潢牵‬獕条⁥档牡敧⁳景洠捡楨敮祲‬畣楲杮‬映牯潷歲‬散瑮牥湩⁧…捳晡潦摬湩⁧愠摮愠汬琠敨漠桴牥愠灰牵整慮据獥爠煥極敲⁤潴挠浯汰瑥⁥桴⁥潷歲愠⁳数⁲整档楮慣灳捥晩捩瑡潩獮‮ਠ㉍‵敄楳湧䴠硩唠楳杮㈠‰浭渠浯湩污猠穩⁥牧摡摥挠畲桳摥挠慯獲⁥条牧来瑡獥ⴠ†㌨‥潣楳敤敲⁤潦⁲潆浲眠牯⥫ȹZ䈀ꀶࠂ
牐癯摩湩⁧湡⁤慬楹杮椠潰楳楴湯䌠浥湥⁴潃据敲整映牯愠汬䘠畯摮瑡潩潷歲⹳吠敨朠慲楮整琯慲⽰慢慳瑬挠畲桳摥朠慲敤⁤潣牡敳愠杧敲慧整⁳湡⁤楦敮愠杧敲慧整⁳獡瀠牥爠汥癥湡⁴卉䌠摯獥洠捡楨敮洠硩摥眠瑩⁨畳数⁲汰獡楴楣敺獲氠楡⁤湩映湩獩敨⁤慬敹獲‬敷汬挠浯慰瑣摥甠楳杮渠敥汤⁥楶牢瑡牯ⱳ椠据畬楤杮愠汬氠慥⁤…楬瑦ⱳ挠獯⁴景愠汬洠瑡牥慩獬‬畱污瑩⁹潣普物業杮琠桴⁥敲畱物浥湥獴漠⁦敲敬慶瑮䤠⁓潣敤ⱳ氠扡畯Ⱳ唠慳敧挠慨杲獥漠⁦慭档湩牥ⱹ挠牵湩Ⱨ†潦浲眠牯Ⱬ挠湥整楲杮☠猠慣晦汯楤杮†湡⁤污桴⁥瑯敨⁲灡異瑲湥湡散⁳敲畱物摥琠潣灭敬整琠敨眠牯獡瀠牥琠捥湨捩污猠数楣楦慣楴湯⹳ਠ㉍‵敄楳湧䴠硩唠楳杮㈠‰浭渠浯湩污猠穩⁥牧摡摥挠畲桳摥挠慯獲⁥条牧来瑡獥‭㜨┰挠湯楳敤敲⁤潦⁲潆浲眠牯⥫ȸZ䈀퀷ࠂ
倠潲楶楤杮愠摮氠祡湩⁧湩䌠浥湥⁴潃据敲整†潦⁲污慂敳敭瑮☠猠牵慦散氠癥汥眠牯獫‬敲畴湲眠污獬‬敲慴湩湩⁧慷汬ⱳ猠湵敫汦潯獲攠捴‮桔⁥朠慲楮整琯慲⽰戠獡污⁴挠畲桳摥朠慲敤⁤潣牡敳愠杧敲慧整⁳愠摮映湩⁥条牧来瑡獥†獡瀠牥爠汥癥湡⁴䤠⁓潃敤⁳慭档湩⁥業數⁤楷桴猠灵牥瀠慬瑳捩獩牥ⱳ氠楡⁤湩氠祡牥ⱳ眠汥潣灭捡整⁤獵湩⁧敮摥敬†楶牢瑡牯ⱳ瀠潲楶楤杮眠敥⁰潨敬⁳桷牥癥牥渠捥獥慳祲‬湩汣摵湩⁧污敬摡☠氠晩獴‬挠獯⁴景愠汬洠瑡牥慩獬漠⁦畱污瑩ⱹ氠扡畯Ⱳ唠慳敧挠慨杲獥漠⁦慭档湩牥ⱹ挠牵湩Ⱨ映牯潷歲‬散瑮牥湩⁧…捳晡潦摬湩⁧湡⁤污漠桴牥†灡異瑲湥湡散⁳†敲畱物摥琠潣灭敬整琠敨眠牯獡瀠牥琠捥湨捩污†灳捥晩捩瑡潩獮ਮ㉍‵敄楳湧䴠硩唠楳杮㈠‰浭渠浯湩污猠穩⁥牧摡摥挠畲桳摥挠慯獲⁥条牧来瑡獥ⴠ†㔨┰挠湯楳敤敲⁤潦⁲潆浲眠牯⥫ɦZ䈀䄸ࠃ
牐癯摩湩⁧湡⁤慬楹杮椠潰楳楴湯䌠浥湥⁴潃据敲整†潦⁲污畓⁢瑳畲瑣牵獥漠⁦畢汩楤杮‬牉楲慧楴湯眠牯獫‬畓⁢瑳畲瑣牵⁥潷歲⁳景戠楲杤獥‬牄楡潷歲⁳☠漠桴牥瀠牡污敬潷歲⁳牦浯〠㔮洰琠⸳〵洠栠楥桧⹴吠敨朠慲楮整琯慲⽰慢慳瑬†牣獵敨⁤牧摡摥挠慯獲⁥条牧来瑡獥†湡⁤楦敮愠杧敲慧整⁳愠⁳数⁲敲敬慶瑮䤠⁓潃敤⁳慭档湩⁥業數⁤楷桴猠灵牥瀠慬瑳捩獩牥ⱳ†慬摩椠慬敹獲‬敷汬挠浯慰瑣摥甠楳杮渠敥汤⁥瘠扩慲潴獲‬牰癯摩湩⁧敷灥栠汯獥眠敨敲敶⁲敮散獳牡ⱹ椠据畬楤杮愠汬氠慥⁤…楬瑦ⱳ†潣瑳漠⁦污慭整楲污⁳景焠 ality, confirming to the requirements of relevant IS codes, labour, Usage charges of machinery, curing, form work, centering & scaffolding and all other appurtenances required to complete the work as per technical specifications. M25 Design Mix Using 20mm nominal size graded crushed coarse aggregate (35% considered for Form work)ÛZB9
Providing and laying in position Cement Concrete for all Super structures of building , Road works, Water works, Irrigation works & super structure works of bridges upto 3.50 m height. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS Codes machine mixed with super plasticisers laid in layers, well compacted using needle vibrators. The cost includes all lead & lifts, cost of all materials, quality confirming to the requirements of relevant IS codes , labour, Usage charges of machinery, curing, form work, centering & scaffolding and all other appurtenances required to complete the work as per technical specifications. M25 Design Mix Using 20 mm nominal size graded crushed coarse aggregates (60% considered for Form work) Ground Floor¡ZB10 
Providing and laying in position Cement Concrete for all Super structures of building , Road works, Water works, Irrigation works & super structure works of bridges upto 3.50 m height. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS Codes machine mixed with super plasticisers laid in layers, well compacted using needle vibrators. The cost includes all lead & lifts, cost of all materials, quality confirming to the requirements of relevant IS codes , labour, Usage charges of machinery, curing, form work, centering & scaffolding and all other appurtenances required to complete the work as per technical specifications. M25 Design Mix Using 20 mm nominal size graded crushed coarse aggregates (45% considered for Form work)¡ZB11
Providing and laying in position Cement Concrete for all Super structures of building , Road works, Water works, Irrigation works & super structure works of bridges upto 3.50 m height. The granite/trap/basalt crushed graded coarse aggregates and fine aggregates as per relevant IS Codes machine mixed with super plasticisers laid in layers, well compacted using needle vibrators. The cost includes all lead & lifts, cost of all materials, quality confirming to the requirements of relevant IS codes , labour, Usage charges of machinery, curing, form work, centering & scaffolding and all other appurtenances required to complete the work as per technical specifications. M25 Design Mix Using 20 mm nominal size graded crushed coarse aggregates (50% considered for Form work) Ground Floor¡ZB12f
Steel Fabrication: Supplying, fitting and placing TMT FE 550 / 550D Steel Reinforcement including cost of all materials, machinery, labour, cleaning, straightening, cutting, bending, hooking, laping/welding joints, tying with binding wire / soft annealed steel wire and other ancilary operations complete as per drawing and technical specification BuildingsZ:3ZD:\
V]
ZkgB13w
Providing and fixing Structural Steel work riveted, bolted or welded in built up sections, trusses and framed work, including cutting, hoisting, fixing in position and applying a priming coat of approved steel primer all complete including cost of materials, labour, usage charges of machinery complete as per specifications and as per directions of the Engineer-in-Charge. Z&:B14R
Constructing brick masonry chamber of internal dimension 600x600mm and depth of 600mm (inner dimensions) with modular bricks of CD 75 in cement mortar 1:6, bed concrete 150mm thick with 1:3:6, plastering 12 mm thick with cement mortar 1:4, CC 1:2:4 coping 75mm thk for fixing CI cover & frame etc excluding the cost of CI frame and cover. ZB:eachB15o
Providing and fixing SFRC frame and cover conforming to IS 12592 (part-I)-1988 and IS 12592 (part-II)- 1991 with latest amendment, including cutting slabs to the required size for the opening and fixing the cover in C.C. 1:2:4 and C.M. 1:3 plastering 20 mm thick to all exposed faces, curing for 10 days with all lead and lift with ppurtenances. complete. Medium DutyZ):B16p
Providing Brick work with common burnt clay Non Modular bricks of class designation 3.5 in superstructure above plinth level in all shapes and sizes in Cement mortar 1:6 (1 cement : 6 coarse sand) including cost of all materials, labour, scaffolding and usage charges of machinery & other incidental charges complete as per the direction of engineer incharge of work. Z+:,Z?:B17@
Providing 12 mm cement plaster with cement mortar 1:4 (1 cement: 4 fine sand) to brick masonry including rounding off corners wherever required smooth rendering, providing and removing scaffolding, including cost of materials, labour, curing complete as per specifications and as per directions of Engineer-in-charge.Z9—sqmB18P
Providing 15 mm cement plaster on the rough side of single or half brick wall of mix 1:4 (1 cement: 4 fine sand) including rounding off corners wherever required smooth rendering, providing and removing scaffolding, including cost of materials, labour, curing complete as per specifications and as per directions of Engineer-in-charge. Z—R:[—B19½
Providing and laying 52 mm thick cement concrete flooring with concrete hardener topping, under layer 40 mm thick cement concrete 1:2:4 (1 cement : 2 coarse sand : 4 graded stone aggregate 20 mm nominal size) and top layer 12 mm thick cement hardener consisting of mix 1:2 (1 cement hardener mix : 2 graded stone aggregate 6 mm nominal size) by volume, hardening compound mixed @ 2 L per 50 kg of cement or as per direction of Engineer incharge.Z9:B20
Applying priming coats with primer of approved brand and manufacture, having low VOC (Volatile Organic Compound) content. With water thinnable cement primer on wall surface having VOC content less than 50 g/L as per specifications and as per directions of Engineer in charge.Z—":B21M
Wall painting with premium acrylic emulsion paint of interior grade, having VOC (Volatile Organic Compound ) content less than 50 g/L of approved brand and manufacture, including applying additional coats wherever required to achieve even shade and colour. Two coats as per specifications and as per directions of Engineer in charge.ZD:B22ò
Finishing walls with Acrylic Smooth exterior paint of required shade :New work (Two coat applied @ 1.67L/10 m² over and including priming coat of exterior primer applied @ 2.20 kg/10 m²) with paint of approved quality to give an even shade, after thoroughly brooming the surface to remove all dirt, dust, mortar drops and foreign matter including preparing the surface even and sand paper smooth, cost of materials, labour complete as per specifications and as per directions of Engineer-in-charge.Z3:B23)Supplying PVC ringtite pipes conforming to IS 4985:2000 with latest amendments and conveying to worksite, rolling and lowering into trenches, laying true to line and level and perfect linking at joints, testing and commissioning, including loading unloading at both destinations and cuts of pipes wherever necessary including jointing of PVC pipes and specials (excluding cost of specials) with jointing of approved type, with all labour with all lead & lift including encasing the pipe alround to a depth of not less than 15 cms. with soft gravel or selected earth available from the excavation etc. complete and giving necessary hydraulic test to the required pressure as per ISS (Contractor will make his own arrangements for procuring water for testing) etc. for: PVC pipes 110mm dia., 6 kg/sqcm & class 3 Z:Z
mB24IProviding S&S RCC SPUN / VIBRATED CAST PIPES (REINFORCED) pipes NP-3 Class conforming to IS:458-1988 with latest amentments using ordinary portland cement, for sanitary works and conveying to work site, rolling and lowering into trenches, laying true to line and level including loading and unloading at both destinations and jointing of pipes and specials, perfect linking of joints with jack to correct position including cost of jointing materials, i.e, rubber rings conforming to IS: 5382 for S&S RCC pipes, with all leads and lifts as directed and giving necessary hydraulic test as per ISS to the required pressure and commissioning etc. complete. (Contractor will make his own arrangements for procuring water for testing). Before the execution of the work, the contractor shall carry out the survey. RCC NP3 Class pipe of 300 mm dia.ZJ:(ZB25#Providing and fixing stainless steel (Grade 304) railing made of Hollow tubes, channels, plates etc., including welding, grinding, buffing, polishing and making curvature (wherever required) and fitting the same with necessary stainless steel nuts and bolts complete, i/c fixing the railing with necessary accessories & stainless steel dash fasteners, stainless steel bolts etc., of required size, on the top of the floor or the side of waist slab with suitable arrangement as per approval of Engineer-in- charge, (for payment purpose only weight of stainless steel members shall be considered excluding fixing accessories such as nuts bolts, fasteners etc.) including cost of materials, labour, usage charges of machinery complete as per specifications and as per directions of the Engineer-in-Charge Z8:B26Ô
Concealed Conduit System Supplying heavy gauge PVC conduit pipe ...... mm dia..........mm thick confirming to IS 2509 with suitable size bends, metal/PVC Junction boxes, adhesive paste etc., and running before concreting the slab. The conduit should be tied to the reinforcement rods by using binding wires and unused ways of junction boxes and pipe ends should be covered using PVC end enclosures, run with 18SWG GI fish wire wherever necessary. 25 mm dia 2 mm thickZ:¿
ZB27@Point wiring using Copper wire without switch. Supplying and wiring adopting loop system in existing PVC Conduit /casing capping casing capping using 2x1.5Sqmm (Phase & Neutral) & 1x1.0 sqmm (Earth wire) FRLS multi strand PVC insulated copper wire (confirming to IS-694: and latest amendments) without control switch shall be fixed on the existing plastic sheet/ gang box, the other end of the wires shall be terminated with sufficient loose length in a wood/PVC round block. complete for each outlet. a) Short point up to 3Mtr from tapping point to out let via switch box Z0:ü
Z:pointB28JPoint wiring using Copper wire without switch. Supplying and wiring adopting loop system in existing PVC Conduit /casing capping casing capping using 2x1.5Sqmm (Phase & Neutral) & 1x1.0 sqmm (Earth wire) FRLS multi strand PVC insulated copper wire (confirming to IS-694: and latest amendments) without control switch shall be fixed on the existing plastic sheet/ gang box, the other end of the wires shall be terminated with sufficient loose length in a wood/PVC round block. complete for each outlet. b) Medium point above 3Mtr up to 6Mtr from tapping point to out let via switch boxZ/:û
Z:B29Õ
Point wiring using Copper wire without switch. Supplying and wiring adopting loop system in existing PVC Conduit /casing capping using copper PVC insulated multi strand 2x1.5Sqmm copper wire without switch, the other end of the wires shall be terminated with sufficient loose length in a wood/PVC round block. complete for each outlet.( 4/9) - II. Point wiring using class B Materialsc) Long point above 6Mtr up to 10Mtr from tapping point to out let via switch box Z/:†
Z
:B30ÛWiring for lighting/power circuit using one of FRLS PVC insulated 1100V grade, multistrand copper wire with low conductor resistance single core in open or concealed system of wiring with specified IS 694:201 2.5 sqmm :ÑZB31ÐSupplying and flush mounting powder coated / galvanized metal box suitable for mounting modular switch plates. The box should be firmly flush mounted after due groove cutting in Brick/Stone/C.C wall 1-2Way 8ZB:ÈZÏ:B32Ž
Supplying and fixing of modular switch & connected accessorieson existing modular switch plate as per IS 3854 and IS 1293. 16A One Way Switch{ZEachB33“
Supplying and fixing of modular switch & connected accessorieson existing modular switch plate as per IS 3854 and IS 1293. 6/16A Universal Socket{ZB34
Supplying of feet -PVC Batten with integrated LED tube LED light fitting 1 x 4ft - 36/40 W with high quality diffuser with Life of 25000 burning hours & 70% lumen maintenance with CRI greater than 80. Power Input: 220-240V@ 50/60Hz & Power factor greater than 0.9 along with CE approved. 2 years Warranty against any manufacturing defect working under standard electrical condition —6ZZ:B35
Fixing all types and all capacities of fluorescent /falseceiling/ spot light/CFL/LED fittings indoor on the wall/ceiling/rafters/girders using 23/0.0076" twintwisted PVC insulated wires, required Nos of round blocks and clamps. On wall/ ceiling / Rafter / Girders.Z:B369Providing and laying Non- Modular bricks in UG cable ductN0sB37¤Demolishing cement concrate manually/ by mechanical means including disposal of material of the appropriate disposal area as per direction of Emgineer-in-cahrage Cum&SCHEDULE-5 COMMERCIAL DEVIATION CSHEET FOR TECHNOCOMMERCIAL OPENING 2Please fill Only in the Light Blue Couloured Cell.‚ Please key in the SlNo.,Section , Clause , Description as given in bid sheets and finally your Statement of Deviation/Variations.uThis Sheet would be opened at the Techno-Commercial Opening. Please refer Vendor Manual attached for further details.I-WR For any further assistance for submitting your bids please call up KPTCL Office.–We agree to provide all original Documents in support of the information provided for verification upon request. (Key in as YES in the space provided)†We understand that the electonic bid submitted by us is a valid offer in accordance with IT Act. (Key in as YES in the space provided)qWe are fully aware of the electronic bid formalities and abide by the same. (Key in as YES in the space provided)qIf you are not deviating from any of the clauses mentioned please key in as 'NO DEVIATION' in the space provided.ö I/we have read each of the Clauses mentioned in INVITATION FOR TENDERS , INSTRUCTION TO TENDERERS , CONDITIONS OF CONTRACT, SPECIAL CONDITIONS OF CONTRACT and COMMERCIAL TERMS AND CONDITIONS and all the sections of Bid documents. :-Èx The following are the commercial Deviations and Variations from and exceptions to the Specifications and documents for –These deviations and variations are exhaustive. Except these deviations, the entire work shall be performed as per your specifications and documents.Sl. NO.SECTION CLAUSE NO. DESC. AS PER SPECIFICATION"STATEMENT OF DEVIATIONS/VARIATIONSSNote : Deviations specified elsewhere in the specification will not be considered.Name of the companyo SCHEDULE-6 : TECHNICAL DEVIATION #SHEET FOR TECHNO-COMMERCIAL OPENINGƒ Please key in the SlNo., Section , Clause , Description as given in Bid sheets and finally your Statement of Deviation/Variations.<This Sheet would be opened at the Techno-Commercial Opening.~ For any further assistance for submitting your bids please call up KPTCL office. Please fill only in the blue coloured cells.TO,yThe following are the Technical Deviations and Variations from and exceptions to the Specifications and documents for ¥ These deviations and variations are exhaustive.Except these deiviations and variations, the entire work shall be performed as per your specification and documents.1KARNATAKA POWER TRANSMISSION CORPORATION LIMITED .SCHEDULE 7(List of special tools and tackles )NList of special tools and tackles the price of which is included in bid price.For equipment Description of item Name of the Company SCHEDULE 8; SHEET FOR TECHNOCOMMERCIAL OPENING -NOTE: 1 ) SHALL BE UPLOADED WITHOUT PRICES IWe have uploaded with our proposal the following additional information. !Brief Description of information Ref. and Page No. Company sealLSCHEDULE - 9 (1 of 5) : QUALIFYING REQUIREMENTS $ SHEET FOR TECHNOCOMMERCIAL OPENING BIDDER'S NAME AND ADDRESS: TO, I* We have submitted bid as individual Bidder. (Key in Individual Bidder )W* We have submitted bid in Consortium with the following Bidders. (Key in Consortium )Name of Consortium Partner0Scope / Participation of each Consortium PartnerGENERAL INFORMATIONgThe Bidder, bidding for this package are requested to complete the information in the following form. Bidder DetailsName of the Firm2Address of Head Office / Registered Office GST no. Telephone'Name of Contact person with Designation#Place of Incorporation/Registration"Year of Incorporation/Registration6Constitution or legal status of Tenderer [Upload copy]#Place of Registration [Upload copy]Principal place of businessrWe are furnishing the following details/documents in support of Qualifying requirement for above mentioned projectSl.No.Indicate Yes/NoIn case of Consortium -VOID(a)KWritten power of attorney of the signatory on the bid to commit the bidder.Uploaded / Not(b)dCertificate of Registration of the Company. Please mention the date of incorporation of the company (c ) ô
Valid Super Grade Electrical Contractor s License issued by the Government of Karnataka as on the date of techno commercial Bid opening. Please mention the date of expiry of the License certificate issued by GOK/ Undertaking to this effect (d)`Self declaration regarding Litigation w.r.t KPTCL contracts over the last five years (refer IFT)(e)Ž
Self declaration for  not being disqualified regarding non-performance in any of the Government utilities in the past five years . (refer IFT)(f)îAn undertaking to source the supply of equipment/ material from KPTCL approve

rs only as per QR for Vendor registration, available in the KPTCL website ie., kptcl.karnataka.gov.in, Link Tender and Procurement-Application for Vendor.(g)rSelf declaration regarding no action against the bidder have been taken by KPTCL in respect of Risk & Cost clause (h)¯Self declaration regarding 'Eligibility clauses in respect of restrictions on procurement from a bidder of a country which shares a land border with India as per Annexure-XVI (i)°Self declaration regarding RESTRICTIONS ON SOURCING OF EQUIPMENTS/MATERIALS BY THE BIDDER FROM A VENDOR OF A COUNTRY WHICH SHARES A LAND BORDER WITH INDIA as per Annexure -XVIIwSection 3 : 1.3 Work performed of similar nature in the last Ten years of Bidder as per Clause No: 3.2 (b) (i) of ITT Project NameName & Address of the EmployerDescription of Work Voltage class/ Number of Sub-Stations/TBs/Length of the Line Contract NumberValue of contract Rs. LakhDate of issue of work orderSpecified period of completionActual date of commissioning <Remarks explaining reasons for delay in commisioning of work3a3b3CName of Bidder#
Note : 1 . The documentary proof of fulfilling the qualifying requirements shall be uploaded along with the bid. The bidder shall upload the P.O,LOI/LOA, DWA, Work done, Performance Certificates issued by the end users not below the rank of Executive/ Divisional Engineer along with the bid.
2. The qualifying experience of the Bidder who is having qualifying experience shall be furnished in the above performa and Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. ‹3. IF this sheet is insufficient for furnishing the qualifying experience of the Bidder then similar sheets shall be seperately uploaded.4 KARNATAKA POWER TRANSMISSION CORPORATION LIMITED LSCHEDULE - 9 (2 of 5) : QUALIFYING REQUIREMENTS Section 3 : 1.5 Information on works for which Tenders have been submitted and works which are yet to be completed as on the date of this Tender of a Bidder,(A) Existing commitments and on-going works:Description of work  Place & State Contract No & Date Name and Address of Employer Value of contract (Rs. Lakh)#Stipulated period of cof Completiong
Value of works remaining to be completed ( Rs.Lakhs) (Attach Certificates from Engineers  in- Charge)!Anticipated date of commissioningEx-WorksGSTTotal(Ex-works+GST)7a7b7c=7a+7b3
Note:Attach Certificates from Engineers  in- Charge+B)Works for which Tenders already submittedDescription of workPlace & State Name and Address of Employer$Estimated value of works (Rs. Lakh) Stipulated period of Completion Date when decision is expectedRemarks if any Ex-works4a4b4c=4a+4bNote:ii) The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be countersigned by the Employer in charge, not below the rank of an Executive Engineer or equivalent. OR The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be verified and certified by Chartered Accountant/ Cost Auditor. However, the Bidder has to upload the PO/Work Award copies for existing commitments and on-going works ®
ii) A self-declaration is to be uploaded by the bidder stating that "the information with regard to assessed available tender capacity (Works on Hand) furnished are correct .äiii. Bidders shall furnish Certificate from Chartered Accountants for split details of Ex-works values and GST of Contract values of the works in the prescribed format as at Clause No. 1.5 of Section-3: Qualification Information1SCHEDULE - 9 (3 of 5) : QUALIFYING REQUIREMENTS ¸Following is the list of major supplied subsation equipments/accessories which are type tested and designed, manufactured by us in accordance with internationally recognised standards.!Item rating, type and DesignationCustomer Date of OrderDate of SupplyDate of Commissioning>Ref. of Cusomer's certificate of successful operation enclosed@Ref. of layout & Customer's certificae for successful commission–Note: Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. . 1SCHEDULE - 9 (4 of 5) : QUALIFYING REQUIREMENTS ToH

Section 3 : 1.7 Reports on the financial standing of the tenderer, such as Profit and Loss Statements and Auditor s reports in the preceeding last five years, Audited Financial statements i.e Balance sheets, P&L statements, Turnover certificates duly certified by chartered Accountant as documentary evidence shall be uploaded.SLNo. ParticularsYearBidderConsortium Member - VOID Mention Year!Turnover excluding GST (in Rs.) <GST Amount (in case GST is included in Turnover) (in Rs.)!Turnover including GST (in Rs.) Names of the constituent Firm(Annual turn over for the last Five yearsYear(1)2020-21Year(2)2021-22Year(3)2022-23Year(4)2023-24Year(5)2024-25CLiquid Assets / Credit availability or access to evidence of assetskWhether Audited Balance sheets and Profit & Loss statement are enclosed for the last Five Years ? (yes/No)DWhether Bankers certificate enclosed for credit facilities? (Yes/No). . . 1SCHEDULE - 9 (5 of 5) : QUALIFYING REQUIREMENTS éThe information to be filled in by the Tenderer hereunder will be used for purposes of computing Tender capacity as provided for in Clause 3 of the Instructions to Tenderers. This information will not be incorporated in the Contract.7Constitution or legal status of Tenderer [Upload copy]†
Section - 3: 1.2 Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last Five years (in Rs. Lakhs)  ‚
Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last five years (in Rs. Lakhs) of Bidder zFinancial Year KPTCL worksNon KPTCL works"Total value of works in Rs. Lakh>Note: Attach relevant Certificate/s from Chartered Accountant.Section 3: 1.9 Name, address, telephone number & e-mail id of the Tenderers' bankers who may provide references if contacted by the Employer:FName, address, telephone number & e-mail id of the Tenderers' bankers MSection 3: 1.12 Information on litigations in which the Tenderer is involved:Other Party(ies)EmployerDetails of DisputeAmount involved Remarks showing Present Status:SCHEDULE-10 (1 of 3) Details of Tools and Plants availableDFollowing are the details of the Tools and Plants available with us.MakePresent Location / ProjectRemarks (if any)8SCHEDULE 10 (2 of 3) Details of Technical staff employed#SHEET FOR TECHNOCOMMERCIAL OPENING ËSection 3: 1.8 Qualification and experience of the key technical and management personnel in permanent employment with the tenderer and those that are proposed to be deployed on this contract, if awardedName of the employee/Branch (Degree/Diploma)Year of Passing )Since when employed in erection division Past ExperienceSCHEDULE 10 (3 of 3 )TWe propose the following deployment of manpower for the substation and Line package.Category&MONTHS AFTER PLACEMENT OF AWARD LETTERProject managerSr. Project Manager Supervisor T

杩牵獥漠⁦桴⁥牴湡晳牯敭⁲畦湲獩敨⁤祢甠⁳湵敤⁲桴⁥畔湲敫⁹慐正条⁥牡⁥畇牡湡整摥‮敗映牵桴牥搠捥慬敲琠慨⁴椠桴⁥癥湥⁴景愠祮搠晥捩敩据敩⁳湩洠敥楴杮琠敨朠慵慲瑮敥⁳湩爠灥捥⁴景琠敨挠慨慲瑣牥獩楴獣洠湥楴湯摥戠汥睯愠⁳獥慴汢獩敨⁤晡整⁲潣摮捵楴杮琠敨映捡潴祲琠獥ⱴ礠畯洠祡愠⁴潹牵搠獩牣瑥潩Ɱ敲敪瑣漠⁲捡散瑰琠敨攠畱灩敭瑮愠瑦牥愠獳獥楳杮琠敨氠煩極慤整⁤慤慭敧⁳獡猠数楣楦摥椠敲敬慶瑮挠慬獵⁥景䈠摩䐠捯浵湥⹴ 煅極浰湥⁴%䜀慵慲瑮敥⁤潌獳獥愠⁴慲整⁤畯灴瑵䬨⥗5䴀硡丠潌摡氠獯⁳瑡爠瑡摥瘠汯慴敧愠摮爠瑡摥映敲畱湥祣M䴀硡䰠慯⁤潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡MȈ䴀硡䤠′⁒潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡™H 慍⁸畁楸楬牡⁹潬獳愠⁴慲整⁤潶瑬条⁥湡⁤牦煥敵据⁹潦⁲潐敷⁲牔湡晳牯敭⑲〲噍ⱁㄠ〱㌯ⴳㄱ噫倠睯牥吠慲獮潦浲牥—一瑯㩥椨 敒敦⁲敔档楮慣灓捥晩捩瑡潩獮ਠ††††⠠楩吩敨氠獯⁳畱瑯摥猠慨汬戠⁥潣獮獩整瑮椠捓敨畤敬ㄠ‴湡⁤呇獐䐨卒漩⁦倠睯牥吠慲獮潦浲牥 †††††1䬀牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整⁤h匀䡃䑅䱕ⵅ㔱††††††††††††††††††††††††††††††††††††††††††††††༠䥌呓传⁆䕖䑎剏ᡓ䥂䑄剅⁓䅎䕍䄠䑎䄠䑄䕒卓䔀啑偉䕍呎 䅍䕔䥒䱁一䵁⁅䙏吠䕈嘠久佄ࡒ䕖䑎剏ㄠ †嘠久佄⁒ਲ†䕖䑎剏㌠ 䕖䑎剏㐠0倀睯牥吠慲獮潦浲牥㈊䴰䅖‬ㄱ⼰㌳ㄭ欱⁖牔湡晳牯敭᭲䙓‶楃捲極⁴牂慥敫獲਺㐱欵བ啓䝒⁅剁䕒呓剅㍓䌠湯牴汯☠删汥祡倠湡汥⁳ 敒慬⁹…牐瑯捥楴湯倠乁䱅♓瑓瑡潩 煅極浰湥⁴畓灰牯⁴瑳畲瑣牵獥䄀千⁒佃䑎䍕佔੒慅瑲⁨楷敲匀汯摩䌠牯⁥湉畳慬潴⁲䐀獩⁣湉畳慬潴⁲瑓楲杮⹳湉畳慬潴⁲慈摲慷敲䌠慬灭⁳†…潐敷⁲潣湮捥潴獲 䰀䅔⁃䅐䕎ቌ⸱欱⁖佐䕗⁒䅃䱂卅䈀呁䕔奒䈀呁䕔奒䌠䅈䝒剅䌀乏剔䱏䌠䉁䕌ནㄱ噋匠楷捴杨慥൲ㄱ噫唠⁇䅃䱂ᡅ䥆䕒䘠䝉呈义⁇充䥕䵐久協"䤀汬浵湩瑡潩煅極浰湥獴⼠䘠硩畴敲୳潔敷⁲慐瑲ᅳ潔敷⁲捁散獳牯敩ᑳ湉畳慬潴⁲慈摲圠牡獥䌀湯畤瑣牯䄠捣獥潳楲獥䔀牡桴圠物⁥捁散獳牯敩䁳潎整㨠䄠祮传桴牥䴠瑡牥慩獬渠浡⁥…瑩⁳敶摮牯⁳牡⁥潴戠⁥湥整敲⹤6 䍓䕈啄䕌ㄭ‶㨠†低䐠噅䅉䥔乏䌠剅䥔䥆䅃䕔⠠乁䕎啘䕒䤭䔩低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄╄楗桴爠晥牥湥散琠畯⁲楂⁤牐灯獯污丠ٯ慤整⁤昀牯†稠敗栠牥扥⁹潣普物桴瑡眠⁥慨敶爠慥⁤桴⁥牰癯獩潩獮漠⁦桴⁥潣瑮慲瑣‬桴⁥瑳灩汵瑡潩景琠敨敳挠慬獵⁥牡⁥捡散瑰扡敬琠獵‬@愀摮眠⁥慨敶渠瑯琠歡湥愠祮搠癥慩楴湯眠慨獴敯敶⁲潴琠敨敳挠慬獵獥̺⥡̠⥢̠⥣̠⥤̠⥥̠⥦䄠汃畡敳丠⹯ㄠ‰景匠捥楴湯㔭匠数楣污䌠湯楤楴湯⁳景䌠湯牴捡⁴匨䍃 ̠⥧Ƞ⥨ä圀⁥畦瑲敨⁲潣普物桴瑡愠祮搠癥慩楴湯琠桴⁥扡癯⁥汣畡敳⁳瑡匠⹉潎‮愨 潴⠠⥨映畯摮愠祮桷牥⁥湩漠牵戠摩瀠潲潰慳ⱬ椠灭楬楣⁴牯攠灸楬楣ⱴ猠慨汬猠慴摮甠据湯楤楴湯污祬眠瑩摨慲湷‬楷桴畯⁴湡⁹潣瑳椠灭楬慣楴湯眠慨獴敯敶⁲潴䬠呐䱃ਮࠀ
匠䡃䑅䱕ⵅ㜱††但䵒䘠剏䈠䑉匠䍅剕呉⽙䵅⁄䄨乎塅剕ⵅ䥉਩吨敢猠慴灭摥漠獒㌮〰⴯丠湯䨭摵捩慩瑳浡⁰慰数⁲湩愠捣牯慤据⁥楷桴䬠呐䱃䌠物畣慬⁲潎‮偋䍔⽌䵇⽔䥃䥖⁌䈨⤷㌯⼵〲㐲䴭乁䝁剅䔠呓呁⁅䔨ㄭ㘰㤹⤲搠瑡摥〠⸲㌰㈮㈰⤴8 ĺ一呏㩅匠䡃䑅䱕⁅啄奌匠䝉䕎⁄奂吠䕈䄠呕佈䥒䕚⁄䕐卒乏匠䅈䱌䈠⁅偕佌䑁䑅䄠䑎匠久⁔䱁乏⁇䥗䡔传䥒䥇䅎⁌䅂䭎䜠䅕䅒呎䕅䄠䑎传䥒䥇䅎⁌䑄⠠佔䅗䑒⁓䥂⁄啇剁乁䕔⁅ 佔䌠䥈䙅䜠久剅䱁䴠乁䝁剅⠠䕔䡃Ⱙ偋䍔⁌䅂䝎䱁剏⁅体䄠⁓佔删䅅䡃䄠呆剅吠䕈䰠十⁔啓䵂卉䥓乏䐠呁⁅…乏传⁒䕂但䕒吠䕈䐠呁⁅…䥔䕍传⁆偏久义⁇䕔䡃低䌠䵏䕍䍒䅉⁌䥂卄ܮ敒⁦潎ሮ慂歮䜠慵慲瑮敥丠⹯ 䐀慥⁲楓獲娬††††††††††††††䤠捡潣摲湡散眠瑩⁨湉楶慴楴湯琠楂⁤湵敤⁲潹牵猠数楣楦慣楴湯䴀猯栀癡湩⁧瑩⁳敒楧瑳牥摥⼠༠效摡传晦捩⁥瑡☠栨牥楥慮瑦牥挠污敬⁤桴⁥䈧摩敤❲ 楷桳!琀慰瑲捩灩瑡⁥湩琠敨猠楡⁤楂⁤牯(愀摮礠畯‬獡愠猠数楣污映癡畯⁲慨敶愠牧敥䩤潴愠捣灥⁴湡椠牲癥捯扡敬愠摮甠据湯楤楴湯污戠湡畧牡湡整⁥潦⁲湡愠潭湵⁴景 瘀污摩甠⁰潴䈠湯戠桥污⁦景䈠摩敤⁲湩氠敩⁵景琠敨䈠摩搠灥獯瑩爠煥極敲⁤潴戠⁥慭敤l戀⁹桴⁥楂摤牥愠⁳⁡潣摮瑩潩牰摥捥湥⁴潦⁲慰瑲捩灩瑡潩湩琠敨猠楡⁤楂Ɽ湩愠摤瑩潩潴琠敨䐠浥湡⁤牤晡⁴潎ਮ††慤整⁤
⸀眀⁥桴ݥ慂歮愠ᩴ慨楶杮漠牵䠠慥⁤景楦散愠⁴q⠀潬慣摡牤獥⥳朠慵慲瑮敥愠摮甠摮牥慴敫琠慰⁹浩敭楤瑡汥⁹湯搠浥湡⁤祢䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩੮ 琀敨愠潭湵⁴景⠀湩映杩牵獥愠摮眠牯獤섩楷桴畯⁴湡⁹敲敳癲瑡潩Ɱ瀠潲整瑳‬敤畭⁲湡⁤敲潣牵敳‮湁⁹畳档搠浥湡⁤慭敤戠⁹慳摩怠睏敮❲猠慨汬戠⁥潣据畬楳敶愠摮戠湩楤杮漠獵椠牲獥数瑣癩⁥景愠祮搠獩異整漠⁲楤晦牥湥散爠楡敳⁤祢琠敨䈠摩敤⹲伊桔獩䜠慵慲瑮敥猠慨汬戠⁥物敲潶慣汢⁥湡⁤桳污敲慭湩瘠污摩甠⁰潴愠摮椠据畬楤杮༊†††††††ꅀ晉愠祮映牵桴牥†硥整獮潩景琠楨⁳畧牡湡整⁥獩爠煥極敲Ɽ琠敨猠浡⁥桳污敢攠瑸湥敤⁤潴猠捵⁨敲畱物摥瀠牥潩⁤渨瑯攠捸敥楤杮漠敮礠慥⥲漠敲散癩湩⁧椠獮牴捵楴湯⁳ਊ牦浯䴠猯†)漀桷獯⁥敢慨晬琠楨⁳畧牡湡整⁥獩椠獳敵⹤吀楨⁳畇牡湡整⁥慨⁳敢湥椠獳敵⁤獵湩⁧䙓卍倠慬晴牯湡⁤桴⁥敲畱獩瑩⁥潣浭湵捩瑡潩湩琠楨⁳敲慧摲栠獡戠敥潦睲牡敤⁤潴琠敨䈠湥晥捩慩祲䈠湡⹫a䤀楷湴獥⁳桷牥潥⁦桴⁥慂歮‬桴潲杵⁨瑩⁳畡桴牯獩摥漠晦捩牥‬慨⁳敳⁴瑩⁳慨摮愠摮猠慴灭漠桴獩ਠ †††††慤⁹景̠瑡ࠠ楗湴獥⁳ 匀杩慮畴敲Ԡ慎敭ጠ晏楦楣污䄠摤敲獳獥ᱳ敄楳湧瑡潩楷桴䈠湡瑓浡⹰&䄀瑴牯敮⁹獡瀠牥倠睯牥漠⁦䄠瑴牯敮⁹潎మ†††䐠瑡⁥Đ一瑯⁥›⤱䈠瑯⁨桴⁥䈠湡畇牡湡整⁥湡⁤敄慭摮䐠慲瑦猠慨汬戠⁥捳湡敮⁤湡⁤灵潬摡摥愠潬杮眠瑩⁨汅捥牴湯捩猠敨瑥⹳††††††††††††††† ††††⤲吠楨⁳慤整猠慨汬戠⁥潆瑲⁹楆敶⠠㔴 慤獹愠瑦牥琠敨氠獡⁴慤整映牯眠楨档琠敨戠摩椠⁳慶楬⹤†††††††††††††††䄠††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整㽤䍓䕈啄䕌ㄭ‸†倠佒但䵒⁁传⁆䕌呔剅传⁆乕䕄呒䭁义升⠠乁䕎啘䕒嘭㨩吨敢攠數畣整⁤湯丠湯䨭摵捩慩慰数⁲景†敒畱獩瑩噥污敵 刀晥圠⸱††††⩉圯⩥栠癡⁥敲摡愠摮攠慸業敮⁤桴⁥潦汬睯湩⁧楢⁤潤畣敭瑮⁳爠汥瑡湩⁧潴†桴⁥ᐊ昨汵捓灯⁥景圠牯⥫愀 潎楴散䤠癮楩湴⁧敔摮牥ĉ戀⤀ 䌀漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀 挀漀渀琀愀椀渀椀渀最 猀攀挀琀椀漀渀 ✀䤀渀瘀椀琀愀琀椀漀渀 昀漀爀 吀攀渀搀攀爀猀ᤀⰠ ✀䤀渀猀琀爀甀挀琀椀漀渀猀 琀漀 吀攀渀搀攀爀攀爀猀ᤀⰠ ᠀䌠漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀ᤀ†愀渀搀 䌀漀渀琀爀愀挀琀 䐀愀琀愀⸀ ⸀਀㜀⥣†灓捥慩潃摮瑩潩獮漠⁦潃瑮慲瑣愠潬杮眠瑩⁨湁敮畸敲ഠ†††††潴༠⥤䐠慲楷杮⁳潎ᬮ⥥吠捥湨捩污匠数楣楦慣楴湯㭳ࠁ′‮†††⁉ 敗栠牥扥⁹畳浢瑩漠牵䈠摩愠摮甠摮牥慴敫琠敫灥漠牵䈠摩嘠污摩映牯愠瀠牥潩⁤景传敮䠠湵牤摥愠摮䔠杩瑨⁹慤獹⠠㠱‰慤獹 牦浯琠敨䰠獡⁴慤整漠⁦楢⁤畳浢獩楳湯愠⁳潮楴楦摥⠠楥桴牥漠楲楧慮牯攠瑸湥敤⥤‮䤠⼪敗‪敨敲祢映牵桴牥甠摮牥慴敫琠慨⁴畤楲杮猠楡⁤数楲摯䤠圯⁥桳污潮⁴慶祲愯瑬牥漠⁲敲潶敫洠⽹畯⁲楂⹤ऊ਀퀀Ԁ᐀
桔獩甠摮牥慴楫杮椠⁳湩挠湯楳敤慲楴湯漠⁦偋䍔⁌条敲楥杮琠灯湥洠⽹漠牵䈠摩愠摮挠湯楳敤⁲湡⁤癥污慵整琠敨猠浡⁥潦⁲桴⁥異灲獯⁥景愠慷摲漠⁦潗歲椠整浲⁳景瀠潲楶楳湯⁳景挠慬獵⁥湥楴汴摥∠睁牡⁤景䌠湯瑳畲瑣•挧⹬潮‮㘲漠⁦敓瑣潩呉⁔湡⁤挠⹬潮‮㠱漠⁦䍓⁃景†桴⁥楂⁤潄畣敭瑮⹳ ††匠潨汵⁤桴獩戠摩戠⁥捡散瑰摥‬䤠⼪敗‪污潳愠牧敥琠扡摩⁥祢愠摮映汵楦污桴⁥整浲ⱳ挠湯楤楴湯⁳景瀠潲楶楳湯漠⁦桴⁥扡癯⁥敭瑮潩敮⁤楢⹤ 匀杩慮畴敲愠潬杮眠瑩⁨敓污漠⁦潃䄮䐨汵⁹畁桴牯獩摥琠楳湧琠敨吠湥敤⁲湯䈠桥污⁦景琠敨䌠湯牴捡潴⹲ԩ䅎䕍ఠ䕄䥓乇呁佉⁎0一䵁⁅䙏吠䕈䌠䵏䅐奎†††††⠠湩䈠潬正䰠瑥整獲ȩ†圀呉䕎卓 匀䝉䅎啔䕒ᜠ慄整愠摮倠獯慴摁牤獥ѳ䅄䕔吀汥来慲桰捩䄠摤敲獳一䵁⁅乁⁄䑁剄卅൓敔敬桰湯⁥潎म敔敬⁸潎䜮†††††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整彤䍓䕈啄䕌ㄭ‹佃华剏䥔䵕䄠則䕅䕍呎传⁎低⁎啊䥄䥃䱁匠䅔偍倠偁剅传⁆獒㔮〰⴯䄨乎塅剕⁅堭䥉⥉ⴠ嘠䥏䙄低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄⹄!䌀乏体呒啉⁍䝁䕒䵅久⁔䵁乏升⁔⽍⁳䘀牯䈠摩匠数楣楦慣楴湯丠⹯3伀⁆䅋乒呁䭁⁁佐䕗⁒剔乁䵓卉䥓乏䌠剏佐䅒䥔乏䰠䵉呉䑅4 ††††桔獩挠湯潳瑲畩条敲浥湥⁴硥捥瑵摥漠桴獩Р搠祡!䴀湯桴漠⁦睔桴畯慳摮吠敷瑮⁹潆牵 愀潭杮瑳䴠猯⠠⁡潣灭湡⁹湩潣灲牯瑡摥甠摮牥琠敨氠睡⁳景-⠀潃湵牴⥹愠摮栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡x⠀敨敲湩晡整⁲慣汬摥琠敨∠敌摡䌠浯慰祮•桷捩⁨硥牰獥楳湯猠慨汬椠据畬敤椠獴猠捵散獳牯⁳攬數畣潴獲愠摮瀠牥業瑴摥愠獳杩獮Ⱙ†⽍⁳††††††††††††††⠀敨敲湩晡整⁲慣汬摥琠敨∠潃獮楴畴湥⁴潃灭湡≹眠楨档攠灸敲獳潩獮猠慨汬椠据畬敤椠獴猠捵散獳牯ⱳ硥捥瑵牯⁳湡⁤数浲瑩整⁤獡楳湧⥳†n 潦⁲桴⁥異灲獯⁥景洠歡湩⁧⁡楢⁤湡⁤湥整楲杮椠瑮⁡潣瑮慲瑣⠠湉挠獡⁥景愠慷摲 条楡獮⁴桴⁥灳捥晩捩瑡潩潮̮潆ၲ䅎䕍传⁆䡔⁅佗䭒ǵ昀牯䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩瑌⹤栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡†態敶楲䈠慨慶‬慂杮污牯⁥㘵‰〰‹‬態湲瑡歡⁡⠠敨敲湩晡整⁲慣汬摥琠敨∠睏敮≲⸩吠敨氠慥敤⁲景琠敨挠湯潳瑲畩

shall abide by the general terms and conditions specified by the Purchaser. WHEREAS the Owner invited bids as per the above mentioned specifications for the design, manufacture, supply and erection, testing and commissioning of Equipments/Materials stipulated in the bidding documents under subject package ë
AND WHEREAS Section-I ( Volume-1: Clause No. 11:- Qualifying Requirement), forming part of the bidding documents, stipulates that a consortium meeting the requirements of Section-I, ( Invitation of Bid) applicable may bid, provided the Consortium fulfills all other requirements of specification and in such a case, the Bid shall be signed by the members so as to legally bind the members and who will be jointly and severally liable to perform the Contract and all obligations hereunder.õThe above clause further states that the consortium agreement shall be attached to the bid and the contract performance guarantee will be as per the format enclosed with the bidding document without any restriction or liability for either party.DAND WHEREAS the bid has been submitted to the Owner vide proposal NodatedÃby Lead Company based on the Constituent agreement between all the consortium under these presents and the bid in accordance with the requirements of Specifications (Qualification Requirements).3NOW THEREFORE THIS UNDERTAKING WITNESSETH AS UNDER:‚In consideration of the above premises and agreements all the partners to this consortium members do hereby now agree as follows:œ In Consideration of the award of the Contract by the Owner to the Consortium members, we , the members to the consortium agreement do hereby agree that M/s6
shall act as Lead Company and further declare and confirm that we shall jointly and severally be bound up to the Owner for the successful performance of the contract and shall be fully responsible for the design, manufacture, supply and successful performance of the equipments in accordance with the Contract.Z
In case of any breach of the said contract by the Lead company or other constituent of the Consortium agreement, the Lead company do hereby agree to be fully responsible for the successful performance of the contract and to carryout all the obligations and responsibilities under the contract in accordance with the requirements of the Contract' Further, if the Owner suffers any loss or damage on account of any breach in the contract or any shortfall in the performance of the equipment in meeting the performance guaranteed as per the specification in terms of the contract, the Lead company of these presents undertake to promptly make good such loss or damages caused to the Owner, on its demand without any demur. It shall not be necessary or obligatory for the Owner to proceed against Lead Partner to these presents before proceeding against or dealing with the other Partner (s).“
The Financial liability of the members of the consortium agreement to the Owner, with respect to any of the claims arising out of performance or non-performance of the obligations set forth in the said agreement, read in conjunction with the relevant conditions of the contract shall, however not be limited in any way so as to restrict or limit the liabilities of any of the members of the agreement.HIt is expressly understood and agreed between the members to this consortium agreement that the responsibilities and obligations of each of the partners shall be as delineated hereunder (To be incorporated suitably by the member to this agreement). However, each member of the consortium will be severally and jointly responsible for the faithful performance of the contract. It is further agreed by the member that the above sharing of responsibilities and obligations shall not in any way be a limitation of joint and several responsibilities of the members under this contract. +Name of the Lead Bidder/Consortium Partner.Scope of the work/Participation^We further declare ourselves bound to execute our scope of work/participation as stated above;ÉThis Consortium agreement shall be constructed and interpreted in accordance with the laws of India and the courts of Bangalore shall have the exclusive jurisdiction in all matters arising there under.ø
 In case of an award of a Contract, we the Consortium members do hereby agree that we shall be jointly & severally responsible for the works respectively executed and Lead company shall furnishing a contract performance security from a bank in favor of the PURCHASER in the forms acceptable to purchaser for value of Five percent (5%) of the total Contract Price plus additional security for unbalanced tenders in accordance with Clause 25.5 & 29 of ITT and Clause 43 of the CC (Conditions of Contract).>
÷

It is further agreed that the Consortium agreement shall be irrevocable and shall form an integral part of the contract, and shall continue to be enforceable till the owner discharges the same. It shall be effective from the date first mentioned above for all purposes and intents. ÖIN WITNESS WHEREOF the partners to the Consortium have through their authorized representatives executed these presents and affixed Common seals of their companies, on the day, month and year first mentioned above.for Lead Company (Signature),(Signature of the authorized representative)(Name in Block Letters)(Name) (Designation)Common Seal of the Company ( For Constituent 1),SCHEDULE-20 POWER OF ATTORNEY (ANNEXURE-XI)POWER OF ATTORNEY¢(To be stamped on Rs.500/- Non Judicial stamp paper in accordance with KPTCL Circular No. KPTCL/GMT/CIVIL (B7)/35/2024-MANAGER ESTATE (E-106992) dated 02.03.2024)'KNOW ALL MEN BY THESE PRESENTS that we a Company incorporated under the laws of 2and having its Registered Office / Head Office at G"Manufacturer / Bidder" which expression shall unless repugnant to the PContext or meanig thereof, include its successors, administrators and assigns) acting through Mr%its constitute, nominate and appoint )a Company incorporated under the laws of ,and having its Registered / Head Office at Gas its duly constituted lawful Attorney (hereinafter called "Attorney"P or "Authorized Representative") to exercise all or any of the powers for and onE behalf of the "Manufacturer / Bidder" in regard to Specification No.Package'the bids for which have been invited by2(Address "Owner") to undertake the following acts:i.|To submit proposal and participate in the aforesaid Bid Specification of the Owner on behalf of the "Manufacturer / Bidder".ii.ØTo negotiate with the "Owner" the terms and conditions including price for award of the contract pursuant to the aforesaid Bid and to sign the contract with the "Owner" for and on behalf of the Manufacturer / Bidder.iii.\To receive accept and execute the contract for and on behalf of the "Manufacturer / Bidder".iv.@To do any other act or submit any document related to the above.=It is expressly understood that the Power of Attorney shall remain valid, binding and irrecoverable till submission of the Contract performance guarantee in terms of the Contract. The "Manufacturer / Bidder" hereby agrees and undertakes to ratify and confirm all the whatsoever the said "Attorney" / "Authorised Representative" quotes in the Bid, negotiates and signs the contract with the "Owner" and / or purports to act on behalf of the "Manufacturer / Bidder" by virtue of this Power of Attorney and the same shall bind the "Manufacturer / Bidder" as if done by itself.Q IN WITNESS WHEREOF THE "Manufacturer / Bidder" has executed these presents at on this day ofunder 5the Common Seal of the Manufacturer company / Bidder.%Specimen Signature of Attorney Holder(Name & Designation)For and on behalf of,Common Seal of the above Manufacturer/Bidder-Has been affixed thereto in the presence of : WITNESSES : OccupationGBid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026ØReplacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-59Bid Security/ EMD : Bids are accompanied by Bid Security (EMD) for Rs.2.00Lakhs.We have enclosed a Bid Security through e-Payment mode for a sum of Rs..........Lakhs and remaining amount of Rs.........Lakhs ( above Rs.10 Lakhs) in the form of Bank Guarantee in original and two copies of the original valid for a period of 225 days from the Last date of bid submission as notified (either original or extended), and liable to be forfeited in accordance with Bid Documents. (Mode of Payment towards EMD is as detailed in CLAUSE NO. 13 of ITT & Clause No. 5 of NIT) œD Pœp ‡ˆœ— ©œÁ èœG
`J
œK
O
œ

rs only as per QR for Vendor registration, available in the KPTCL website ie., kptcl.karnataka.gov.in, Link Tender and Procurement-Application for Vendor.(g)rSelf declaration regarding no action against the bidder have been taken by KPTCL in respect of Risk & Cost clause (h)¯Self declaration regarding 'Eligibility clauses in respect of restrictions on procurement from a bidder of a country which shares a land border with India as per Annexure-XVI (i)°Self declaration regarding RESTRICTIONS ON SOURCING OF EQUIPMENTS/MATERIALS BY THE BIDDER FROM A VENDOR OF A COUNTRY WHICH SHARES A LAND BORDER WITH INDIA as per Annexure -XVIIwSection 3 : 1.3 Work performed of similar nature in the last Ten years of Bidder as per Clause No: 3.2 (b) (i) of ITT Project NameName & Address of the EmployerDescription of Work Voltage class/ Number of Sub-Stations/TBs/Length of the Line Contract NumberValue of contract Rs. LakhDate of issue of work orderSpecified period of completionActual date of commissioning <Remarks explaining reasons for delay in commisioning of work3a3b3CName of Bidder#
Note : 1 . The documentary proof of fulfilling the qualifying requirements shall be uploaded along with the bid. The bidder shall upload the P.O,LOI/LOA, DWA, Work done, Performance Certificates issued by the end users not below the rank of Executive/ Divisional Engineer along with the bid.
2. The qualifying experience of the Bidder who is having qualifying experience shall be furnished in the above performa and Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. ‹3. IF this sheet is insufficient for furnishing the qualifying experience of the Bidder then similar sheets shall be seperately uploaded.4 KARNATAKA POWER TRANSMISSION CORPORATION LIMITED LSCHEDULE - 9 (2 of 5) : QUALIFYING REQUIREMENTS Section 3 : 1.5 Information on works for which Tenders have been submitted and works which are yet to be completed as on the date of this Tender of a Bidder,(A) Existing commitments and on-going works:Description of work  Place & State Contract No & Date Name and Address of Employer Value of contract (Rs. Lakh)#Stipulated period of cof Completiong
Value of works remaining to be completed ( Rs.Lakhs) (Attach Certificates from Engineers  in- Charge)!Anticipated date of commissioningEx-WorksGSTTotal(Ex-works+GST)7a7b7c=7a+7b3
Note:Attach Certificates from Engineers  in- Charge+B)Works for which Tenders already submittedDescription of workPlace & State Name and Address of Employer$Estimated value of works (Rs. Lakh) Stipulated period of Completion Date when decision is expectedRemarks if any Ex-works4a4b4c=4a+4bNote:ii) The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be countersigned by the Employer in charge, not below the rank of an Executive Engineer or equivalent. OR The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be verified and certified by Chartered Accountant/ Cost Auditor. However, the Bidder has to upload the PO/Work Award copies for existing commitments and on-going works ®
ii) A self-declaration is to be uploaded by the bidder stating that "the information with regard to assessed available tender capacity (Works on Hand) furnished are correct .äiii. Bidders shall furnish Certificate from Chartered Accountants for split details of Ex-works values and GST of Contract values of the works in the prescribed format as at Clause No. 1.5 of Section-3: Qualification Information1SCHEDULE - 9 (3 of 5) : QUALIFYING REQUIREMENTS ¸Following is the list of major supplied subsation equipments/accessories which are type tested and designed, manufactured by us in accordance with internationally recognised standards.!Item rating, type and DesignationCustomer Date of OrderDate of SupplyDate of Commissioning>Ref. of Cusomer's certificate of successful operation enclosed@Ref. of layout & Customer's certificae for successful commission–Note: Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. . 1SCHEDULE - 9 (4 of 5) : QUALIFYING REQUIREMENTS ToH

Section 3 : 1.7 Reports on the financial standing of the tenderer, such as Profit and Loss Statements and Auditor s reports in the preceeding last five years, Audited Financial statements i.e Balance sheets, P&L statements, Turnover certificates duly certified by chartered Accountant as documentary evidence shall be uploaded.SLNo. ParticularsYearBidderConsortium Member - VOID Mention Year!Turnover excluding GST (in Rs.) <GST Amount (in case GST is included in Turnover) (in Rs.)!Turnover including GST (in Rs.) Names of the constituent Firm(Annual turn over for the last Five yearsYear(1)2020-21Year(2)2021-22Year(3)2022-23Year(4)2023-24Year(5)2024-25CLiquid Assets / Credit availability or access to evidence of assetskWhether Audited Balance sheets and Profit & Loss statement are enclosed for the last Five Years ? (yes/No)DWhether Bankers certificate enclosed for credit facilities? (Yes/No). . . 1SCHEDULE - 9 (5 of 5) : QUALIFYING REQUIREMENTS éThe information to be filled in by the Tenderer hereunder will be used for purposes of computing Tender capacity as provided for in Clause 3 of the Instructions to Tenderers. This information will not be incorporated in the Contract.7Constitution or legal status of Tenderer [Upload copy]†
Section - 3: 1.2 Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last Five years (in Rs. Lakhs)  ‚
Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last five years (in Rs. Lakhs) of Bidder zFinancial Year KPTCL worksNon KPTCL works"Total value of works in Rs. Lakh>Note: Attach relevant Certificate/s from Chartered Accountant.Section 3: 1.9 Name, address, telephone number & e-mail id of the Tenderers' bankers who may provide references if contacted by the Employer:FName, address, telephone number & e-mail id of the Tenderers' bankers MSection 3: 1.12 Information on litigations in which the Tenderer is involved:Other Party(ies)EmployerDetails of DisputeAmount involved Remarks showing Present Status:SCHEDULE-10 (1 of 3) Details of Tools and Plants availableDFollowing are the details of the Tools and Plants available with us.MakePresent Location / ProjectRemarks (if any)8SCHEDULE 10 (2 of 3) Details of Technical staff employed#SHEET FOR TECHNOCOMMERCIAL OPENING ËSection 3: 1.8 Qualification and experience of the key technical and management personnel in permanent employment with the tenderer and those that are proposed to be deployed on this contract, if awardedName of the employee/Branch (Degree/Diploma)Year of Passing )Since when employed in erection division Past ExperienceSCHEDULE 10 (3 of 3 )TWe propose the following deployment of manpower for the substation and Line package.Category&MONTHS AFTER PLACEMENT OF AWARD LETTERProject managerSr. Project Manager Supervisor T

杩牵獥漠⁦桴⁥牴湡晳牯敭⁲畦湲獩敨⁤祢甠⁳湵敤⁲桴⁥畔湲敫⁹慐正条⁥牡⁥畇牡湡整摥‮敗映牵桴牥搠捥慬敲琠慨⁴椠桴⁥癥湥⁴景愠祮搠晥捩敩据敩⁳湩洠敥楴杮琠敨朠慵慲瑮敥⁳湩爠灥捥⁴景琠敨挠慨慲瑣牥獩楴獣洠湥楴湯摥戠汥睯愠⁳獥慴汢獩敨⁤晡整⁲潣摮捵楴杮琠敨映捡潴祲琠獥ⱴ礠畯洠祡愠⁴潹牵搠獩牣瑥潩Ɱ敲敪瑣漠⁲捡散瑰琠敨攠畱灩敭瑮愠瑦牥愠獳獥楳杮琠敨氠煩極慤整⁤慤慭敧⁳獡猠数楣楦摥椠敲敬慶瑮挠慬獵⁥景䈠摩䐠捯浵湥⹴ 煅極浰湥⁴%䜀慵慲瑮敥⁤潌獳獥愠⁴慲整⁤畯灴瑵䬨⥗5䴀硡丠潌摡氠獯⁳瑡爠瑡摥瘠汯慴敧愠摮爠瑡摥映敲畱湥祣M䴀硡䰠慯⁤潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡MȈ䴀硡䤠′⁒潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡™H 慍⁸畁楸楬牡⁹潬獳愠⁴慲整⁤潶瑬条⁥湡⁤牦煥敵据⁹潦⁲潐敷⁲牔湡晳牯敭⑲〲噍ⱁㄠ〱㌯ⴳㄱ噫倠睯牥吠慲獮潦浲牥—一瑯㩥椨 敒敦⁲敔档楮慣灓捥晩捩瑡潩獮ਠ††††⠠楩吩敨氠獯⁳畱瑯摥猠慨汬戠⁥潣獮獩整瑮椠捓敨畤敬ㄠ‴湡⁤呇獐䐨卒漩⁦倠睯牥吠慲獮潦浲牥 †††††1䬀牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整⁤h匀䡃䑅䱕ⵅ㔱††††††††††††††††††††††††††††††††††††††††††††††༠䥌呓传⁆䕖䑎剏ᡓ䥂䑄剅⁓䅎䕍䄠䑎䄠䑄䕒卓䔀啑偉䕍呎 䅍䕔䥒䱁一䵁⁅䙏吠䕈嘠久佄ࡒ䕖䑎剏ㄠ †嘠久佄⁒ਲ†䕖䑎剏㌠ 䕖䑎剏㐠0倀睯牥吠慲獮潦浲牥㈊䴰䅖‬ㄱ⼰㌳ㄭ欱⁖牔湡晳牯敭᭲䙓‶楃捲極⁴牂慥敫獲਺㐱欵བ啓䝒⁅剁䕒呓剅㍓䌠湯牴汯☠删汥祡倠湡汥⁳ 敒慬⁹…牐瑯捥楴湯倠乁䱅♓瑓瑡潩 煅極浰湥⁴畓灰牯⁴瑳畲瑣牵獥䄀千⁒佃䑎䍕佔੒慅瑲⁨楷敲匀汯摩䌠牯⁥湉畳慬潴⁲䐀獩⁣湉畳慬潴⁲瑓楲杮⹳湉畳慬潴⁲慈摲慷敲䌠慬灭⁳†…潐敷⁲潣湮捥潴獲 䰀䅔⁃䅐䕎ቌ⸱欱⁖佐䕗⁒䅃䱂卅䈀呁䕔奒䈀呁䕔奒䌠䅈䝒剅䌀乏剔䱏䌠䉁䕌ནㄱ噋匠楷捴杨慥൲ㄱ噫唠⁇䅃䱂ᡅ䥆䕒䘠䝉呈义⁇充䥕䵐久協"䤀汬浵湩瑡潩煅極浰湥獴⼠䘠硩畴敲୳潔敷⁲慐瑲ᅳ潔敷⁲捁散獳牯敩ᑳ湉畳慬潴⁲慈摲圠牡獥䌀湯畤瑣牯䄠捣獥潳楲獥䔀牡桴圠物⁥捁散獳牯敩䁳潎整㨠䄠祮传桴牥䴠瑡牥慩獬渠浡⁥…瑩⁳敶摮牯⁳牡⁥潴戠⁥湥整敲⹤6 䍓䕈啄䕌ㄭ‶㨠†低䐠噅䅉䥔乏䌠剅䥔䥆䅃䕔⠠乁䕎啘䕒䤭䔩低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄╄楗桴爠晥牥湥散琠畯⁲楂⁤牐灯獯污丠ٯ慤整⁤昀牯†稠敗栠牥扥⁹潣普物桴瑡眠⁥慨敶爠慥⁤桴⁥牰癯獩潩獮漠⁦桴⁥潣瑮慲瑣‬桴⁥瑳灩汵瑡潩景琠敨敳挠慬獵⁥牡⁥捡散瑰扡敬琠獵‬@愀摮眠⁥慨敶渠瑯琠歡湥愠祮搠癥慩楴湯眠慨獴敯敶⁲潴琠敨敳挠慬獵獥̺⥡̠⥢̠⥣̠⥤̠⥥̠⥦䄠汃畡敳丠⹯ㄠ‰景匠捥楴湯㔭匠数楣污䌠湯楤楴湯⁳景䌠湯牴捡⁴匨䍃 ̠⥧Ƞ⥨ä圀⁥畦瑲敨⁲潣普物桴瑡愠祮搠癥慩楴湯琠桴⁥扡癯⁥汣畡敳⁳瑡匠⹉潎‮愨 潴⠠⥨映畯摮愠祮桷牥⁥湩漠牵戠摩瀠潲潰慳ⱬ椠灭楬楣⁴牯攠灸楬楣ⱴ猠慨汬猠慴摮甠据湯楤楴湯污祬眠瑩摨慲湷‬楷桴畯⁴湡⁹潣瑳椠灭楬慣楴湯眠慨獴敯敶⁲潴䬠呐䱃ਮࠀ
匠䡃䑅䱕ⵅ㜱††但䵒䘠剏䈠䑉匠䍅剕呉⽙䵅⁄䄨乎塅剕ⵅ䥉਩吨敢猠慴灭摥漠獒㌮〰⴯丠湯䨭摵捩慩瑳浡⁰慰数⁲湩愠捣牯慤据⁥楷桴䬠呐䱃䌠物畣慬⁲潎‮偋䍔⽌䵇⽔䥃䥖⁌䈨⤷㌯⼵〲㐲䴭乁䝁剅䔠呓呁⁅䔨ㄭ㘰㤹⤲搠瑡摥〠⸲㌰㈮㈰⤴8 ĺ一呏㩅匠䡃䑅䱕⁅啄奌匠䝉䕎⁄奂吠䕈䄠呕佈䥒䕚⁄䕐卒乏匠䅈䱌䈠⁅偕佌䑁䑅䄠䑎匠久⁔䱁乏⁇䥗䡔传䥒䥇䅎⁌䅂䭎䜠䅕䅒呎䕅䄠䑎传䥒䥇䅎⁌䑄⠠佔䅗䑒⁓䥂⁄啇剁乁䕔⁅ 佔䌠䥈䙅䜠久剅䱁䴠乁䝁剅⠠䕔䡃Ⱙ偋䍔⁌䅂䝎䱁剏⁅体䄠⁓佔删䅅䡃䄠呆剅吠䕈䰠十⁔啓䵂卉䥓乏䐠呁⁅…乏传⁒䕂但䕒吠䕈䐠呁⁅…䥔䕍传⁆偏久义⁇䕔䡃低䌠䵏䕍䍒䅉⁌䥂卄ܮ敒⁦潎ሮ慂歮䜠慵慲瑮敥丠⹯ 䐀慥⁲楓獲娬††††††††††††††䤠捡潣摲湡散眠瑩⁨湉楶慴楴湯琠楂⁤湵敤⁲潹牵猠数楣楦慣楴湯䴀猯栀癡湩⁧瑩⁳敒楧瑳牥摥⼠༠效摡传晦捩⁥瑡☠栨牥楥慮瑦牥挠污敬⁤桴⁥䈧摩敤❲ 楷桳!琀慰瑲捩灩瑡⁥湩琠敨猠楡⁤楂⁤牯(愀摮礠畯‬獡愠猠数楣污映癡畯⁲慨敶愠牧敥䩤潴愠捣灥⁴湡椠牲癥捯扡敬愠摮甠据湯楤楴湯污戠湡畧牡湡整⁥潦⁲湡愠潭湵⁴景 瘀污摩甠⁰潴䈠湯戠桥污⁦景䈠摩敤⁲湩氠敩⁵景琠敨䈠摩搠灥獯瑩爠煥極敲⁤潴戠⁥慭敤l戀⁹桴⁥楂摤牥愠⁳⁡潣摮瑩潩牰摥捥湥⁴潦⁲慰瑲捩灩瑡潩湩琠敨猠楡⁤楂Ɽ湩愠摤瑩潩潴琠敨䐠浥湡⁤牤晡⁴潎ਮ††慤整⁤
⸀眀⁥桴ݥ慂歮愠ᩴ慨楶杮漠牵䠠慥⁤景楦散愠⁴q⠀潬慣摡牤獥⥳朠慵慲瑮敥愠摮甠摮牥慴敫琠慰⁹浩敭楤瑡汥⁹湯搠浥湡⁤祢䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩੮ 琀敨愠潭湵⁴景⠀湩映杩牵獥愠摮眠牯獤섩楷桴畯⁴湡⁹敲敳癲瑡潩Ɱ瀠潲整瑳‬敤畭⁲湡⁤敲潣牵敳‮湁⁹畳档搠浥湡⁤慭敤戠⁹慳摩怠睏敮❲猠慨汬戠⁥潣据畬楳敶愠摮戠湩楤杮漠獵椠牲獥数瑣癩⁥景愠祮搠獩異整漠⁲楤晦牥湥散爠楡敳⁤祢琠敨䈠摩敤⹲伊桔獩䜠慵慲瑮敥猠慨汬戠⁥物敲潶慣汢⁥湡⁤桳污敲慭湩瘠污摩甠⁰潴愠摮椠据畬楤杮༊†††††††ꅀ晉愠祮映牵桴牥†硥整獮潩景琠楨⁳畧牡湡整⁥獩爠煥極敲Ɽ琠敨猠浡⁥桳污敢攠瑸湥敤⁤潴猠捵⁨敲畱物摥瀠牥潩⁤渨瑯攠捸敥楤杮漠敮礠慥⥲漠敲散癩湩⁧椠獮牴捵楴湯⁳ਊ牦浯䴠猯†)漀桷獯⁥敢慨晬琠楨⁳畧牡湡整⁥獩椠獳敵⹤吀楨⁳畇牡湡整⁥慨⁳敢湥椠獳敵⁤獵湩⁧䙓卍倠慬晴牯湡⁤桴⁥敲畱獩瑩⁥潣浭湵捩瑡潩湩琠楨⁳敲慧摲栠獡戠敥潦睲牡敤⁤潴琠敨䈠湥晥捩慩祲䈠湡⹫a䤀楷湴獥⁳桷牥潥⁦桴⁥慂歮‬桴潲杵⁨瑩⁳畡桴牯獩摥漠晦捩牥‬慨⁳敳⁴瑩⁳慨摮愠摮猠慴灭漠桴獩ਠ †††††慤⁹景̠瑡ࠠ楗湴獥⁳ 匀杩慮畴敲Ԡ慎敭ጠ晏楦楣污䄠摤敲獳獥ᱳ敄楳湧瑡潩楷桴䈠湡瑓浡⹰&䄀瑴牯敮⁹獡瀠牥倠睯牥漠⁦䄠瑴牯敮⁹潎మ†††䐠瑡⁥Đ一瑯⁥›⤱䈠瑯⁨桴⁥䈠湡畇牡湡整⁥湡⁤敄慭摮䐠慲瑦猠慨汬戠⁥捳湡敮⁤湡⁤灵潬摡摥愠潬杮眠瑩⁨汅捥牴湯捩猠敨瑥⹳††††††††††††††† ††††⤲吠楨⁳慤整猠慨汬戠⁥潆瑲⁹楆敶⠠㔴 慤獹愠瑦牥琠敨氠獡⁴慤整映牯眠楨档琠敨戠摩椠⁳慶楬⹤†††††††††††††††䄠††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整㽤䍓䕈啄䕌ㄭ‸†倠佒但䵒⁁传⁆䕌呔剅传⁆乕䕄呒䭁义升⠠乁䕎啘䕒嘭㨩吨敢攠數畣整⁤湯丠湯䨭摵捩慩慰数⁲景†敒畱獩瑩噥污敵 刀晥圠⸱††††⩉圯⩥栠癡⁥敲摡愠摮攠慸業敮⁤桴⁥潦汬睯湩⁧楢⁤潤畣敭瑮⁳爠汥瑡湩⁧潴†桴⁥ᐊ昨汵捓灯⁥景圠牯⥫愀 潎楴散䤠癮楩湴⁧敔摮牥ĉ戀⤀ 䌀漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀 挀漀渀琀愀椀渀椀渀最 猀攀挀琀椀漀渀 ✀䤀渀瘀椀琀愀琀椀漀渀 昀漀爀 吀攀渀搀攀爀猀ᤀⰠ ✀䤀渀猀琀爀甀挀琀椀漀渀猀 琀漀 吀攀渀搀攀爀攀爀猀ᤀⰠ ᠀䌠漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀ᤀ†愀渀搀 䌀漀渀琀爀愀挀琀 䐀愀琀愀⸀ ⸀਀㜀⥣†灓捥慩潃摮瑩潩獮漠⁦潃瑮慲瑣愠潬杮眠瑩⁨湁敮畸敲ഠ†††††潴༠⥤䐠慲楷杮⁳潎ᬮ⥥吠捥湨捩污匠数楣楦慣楴湯㭳ࠁ′‮†††⁉ 敗栠牥扥⁹畳浢瑩漠牵䈠摩愠摮甠摮牥慴敫琠敫灥漠牵䈠摩嘠污摩映牯愠瀠牥潩⁤景传敮䠠湵牤摥愠摮䔠杩瑨⁹慤獹⠠㠱‰慤獹 牦浯琠敨䰠獡⁴慤整漠⁦楢⁤畳浢獩楳湯愠⁳潮楴楦摥⠠楥桴牥漠楲楧慮牯攠瑸湥敤⥤‮䤠⼪敗‪敨敲祢映牵桴牥甠摮牥慴敫琠慨⁴畤楲杮猠楡⁤数楲摯䤠圯⁥桳污潮⁴慶祲愯瑬牥漠⁲敲潶敫洠⽹畯⁲楂⹤ऊ਀퀀Ԁ᐀
桔獩甠摮牥慴楫杮椠⁳湩挠湯楳敤慲楴湯漠⁦偋䍔⁌条敲楥杮琠灯湥洠⽹漠牵䈠摩愠摮挠湯楳敤⁲湡⁤癥污慵整琠敨猠浡⁥潦⁲桴⁥異灲獯⁥景愠慷摲漠⁦潗歲椠整浲⁳景瀠潲楶楳湯⁳景挠慬獵⁥湥楴汴摥∠睁牡⁤景䌠湯瑳畲瑣•挧⹬潮‮㘲漠⁦敓瑣潩呉⁔湡⁤挠⹬潮‮㠱漠⁦䍓⁃景†桴⁥楂⁤潄畣敭瑮⹳ ††匠潨汵⁤桴獩戠摩戠⁥捡散瑰摥‬䤠⼪敗‪污潳愠牧敥琠扡摩⁥祢愠摮映汵楦污桴⁥整浲ⱳ挠湯楤楴湯⁳景瀠潲楶楳湯漠⁦桴⁥扡癯⁥敭瑮潩敮⁤楢⹤ 匀杩慮畴敲愠潬杮眠瑩⁨敓污漠⁦潃䄮䐨汵⁹畁桴牯獩摥琠楳湧琠敨吠湥敤⁲湯䈠桥污⁦景琠敨䌠湯牴捡潴⹲ԩ䅎䕍ఠ䕄䥓乇呁佉⁎0一䵁⁅䙏吠䕈䌠䵏䅐奎†††††⠠湩䈠潬正䰠瑥整獲ȩ†圀呉䕎卓 匀䝉䅎啔䕒ᜠ慄整愠摮倠獯慴摁牤獥ѳ䅄䕔吀汥来慲桰捩䄠摤敲獳一䵁⁅乁⁄䑁剄卅൓敔敬桰湯⁥潎म敔敬⁸潎䜮†††††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整彤䍓䕈啄䕌ㄭ‹佃华剏䥔䵕䄠則䕅䕍呎传⁎低⁎啊䥄䥃䱁匠䅔偍倠偁剅传⁆獒㔮〰⴯䄨乎塅剕⁅堭䥉⥉ⴠ嘠䥏䙄低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄⹄!䌀乏体呒啉⁍䝁䕒䵅久⁔䵁乏升⁔⽍⁳䘀牯䈠摩匠数楣楦慣楴湯丠⹯3伀⁆䅋乒呁䭁⁁佐䕗⁒剔乁䵓卉䥓乏䌠剏佐䅒䥔乏䰠䵉呉䑅4 ††††桔獩挠湯潳瑲畩条敲浥湥⁴硥捥瑵摥漠桴獩Р搠祡!䴀湯桴漠⁦睔桴畯慳摮吠敷瑮⁹潆牵 愀潭杮瑳䴠猯⠠⁡潣灭湡⁹湩潣灲牯瑡摥甠摮牥琠敨氠睡⁳景-⠀潃湵牴⥹愠摮栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡x⠀敨敲湩晡整⁲慣汬摥琠敨∠敌摡䌠浯慰祮•桷捩⁨硥牰獥楳湯猠慨汬椠据畬敤椠獴猠捵散獳牯⁳攬數畣潴獲愠摮瀠牥業瑴摥愠獳杩獮Ⱙ†⽍⁳††††††††††††††⠀敨敲湩晡整⁲慣汬摥琠敨∠潃獮楴畴湥⁴潃灭湡≹眠楨档攠灸敲獳潩獮猠慨汬椠据畬敤椠獴猠捵散獳牯ⱳ硥捥瑵牯⁳湡⁤数浲瑩整⁤獡楳湧⥳†n 潦⁲桴⁥異灲獯⁥景洠歡湩⁧⁡楢⁤湡⁤湥整楲杮椠瑮⁡潣瑮慲瑣⠠湉挠獡⁥景愠慷摲 条楡獮⁴桴⁥灳捥晩捩瑡潩潮̮潆ၲ䅎䕍传⁆䡔⁅佗䭒ǵ昀牯䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩瑌⹤栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡†態敶楲䈠慨慶‬慂杮污牯⁥㘵‰〰‹‬態湲瑡歡⁡⠠敨敲湩晡整⁲慣汬摥琠敨∠睏敮≲⸩吠敨氠慥敤⁲景琠敨挠湯潳瑲畩

shall abide by the general terms and conditions specified by the Purchaser. WHEREAS the Owner invited bids as per the above mentioned specifications for the design, manufacture, supply and erection, testing and commissioning of Equipments/Materials stipulated in the bidding documents under subject package ë
AND WHEREAS Section-I ( Volume-1: Clause No. 11:- Qualifying Requirement), forming part of the bidding documents, stipulates that a consortium meeting the requirements of Section-I, ( Invitation of Bid) applicable may bid, provided the Consortium fulfills all other requirements of specification and in such a case, the Bid shall be signed by the members so as to legally bind the members and who will be jointly and severally liable to perform the Contract and all obligations hereunder.õThe above clause further states that the consortium agreement shall be attached to the bid and the contract performance guarantee will be as per the format enclosed with the bidding document without any restriction or liability for either party.DAND WHEREAS the bid has been submitted to the Owner vide proposal NodatedÃby Lead Company based on the Constituent agreement between all the consortium under these presents and the bid in accordance with the requirements of Specifications (Qualification Requirements).3NOW THEREFORE THIS UNDERTAKING WITNESSETH AS UNDER:‚In consideration of the above premises and agreements all the partners to this consortium members do hereby now agree as follows:œ In Consideration of the award of the Contract by the Owner to the Consortium members, we , the members to the consortium agreement do hereby agree that M/s6
shall act as Lead Company and further declare and confirm that we shall jointly and severally be bound up to the Owner for the successful performance of the contract and shall be fully responsible for the design, manufacture, supply and successful performance of the equipments in accordance with the Contract.Z
In case of any breach of the said contract by the Lead company or other constituent of the Consortium agreement, the Lead company do hereby agree to be fully responsible for the successful performance of the contract and to carryout all the obligations and responsibilities under the contract in accordance with the requirements of the Contract' Further, if the Owner suffers any loss or damage on account of any breach in the contract or any shortfall in the performance of the equipment in meeting the performance guaranteed as per the specification in terms of the contract, the Lead company of these presents undertake to promptly make good such loss or damages caused to the Owner, on its demand without any demur. It shall not be necessary or obligatory for the Owner to proceed against Lead Partner to these presents before proceeding against or dealing with the other Partner (s).“
The Financial liability of the members of the consortium agreement to the Owner, with respect to any of the claims arising out of performance or non-performance of the obligations set forth in the said agreement, read in conjunction with the relevant conditions of the contract shall, however not be limited in any way so as to restrict or limit the liabilities of any of the members of the agreement.HIt is expressly understood and agreed between the members to this consortium agreement that the responsibilities and obligations of each of the partners shall be as delineated hereunder (To be incorporated suitably by the member to this agreement). However, each member of the consortium will be severally and jointly responsible for the faithful performance of the contract. It is further agreed by the member that the above sharing of responsibilities and obligations shall not in any way be a limitation of joint and several responsibilities of the members under this contract. +Name of the Lead Bidder/Consortium Partner.Scope of the work/Participation^We further declare ourselves bound to execute our scope of work/participation as stated above;ÉThis Consortium agreement shall be constructed and interpreted in accordance with the laws of India and the courts of Bangalore shall have the exclusive jurisdiction in all matters arising there under.ø
 In case of an award of a Contract, we the Consortium members do hereby agree that we shall be jointly & severally responsible for the works respectively executed and Lead company shall furnishing a contract performance security from a bank in favor of the PURCHASER in the forms acceptable to purchaser for value of Five percent (5%) of the total Contract Price plus additional security for unbalanced tenders in accordance with Clause 25.5 & 29 of ITT and Clause 43 of the CC (Conditions of Contract).>
÷

It is further agreed that the Consortium agreement shall be irrevocable and shall form an integral part of the contract, and shall continue to be enforceable till the owner discharges the same. It shall be effective from the date first mentioned above for all purposes and intents. ÖIN WITNESS WHEREOF the partners to the Consortium have through their authorized representatives executed these presents and affixed Common seals of their companies, on the day, month and year first mentioned above.for Lead Company (Signature),(Signature of the authorized representative)(Name in Block Letters)(Name) (Designation)Common Seal of the Company ( For Constituent 1),SCHEDULE-20 POWER OF ATTORNEY (ANNEXURE-XI)POWER OF ATTORNEY¢(To be stamped on Rs.500/- Non Judicial stamp paper in accordance with KPTCL Circular No. KPTCL/GMT/CIVIL (B7)/35/2024-MANAGER ESTATE (E-106992) dated 02.03.2024)'KNOW ALL MEN BY THESE PRESENTS that we a Company incorporated under the laws of 2and having its Registered Office / Head Office at G"Manufacturer / Bidder" which expression shall unless repugnant to the PContext or meanig thereof, include its successors, administrators and assigns) acting through Mr%its constitute, nominate and appoint )a Company incorporated under the laws of ,and having its Registered / Head Office at Gas its duly constituted lawful Attorney (hereinafter called "Attorney"P or "Authorized Representative") to exercise all or any of the powers for and onE behalf of the "Manufacturer / Bidder" in regard to Specification No.Package'the bids for which have been invited by2(Address "Owner") to undertake the following acts:i.|To submit proposal and participate in the aforesaid Bid Specification of the Owner on behalf of the "Manufacturer / Bidder".ii.ØTo negotiate with the "Owner" the terms and conditions including price for award of the contract pursuant to the aforesaid Bid and to sign the contract with the "Owner" for and on behalf of the Manufacturer / Bidder.iii.\To receive accept and execute the contract for and on behalf of the "Manufacturer / Bidder".iv.@To do any other act or submit any document related to the above.=It is expressly understood that the Power of Attorney shall remain valid, binding and irrecoverable till submission of the Contract performance guarantee in terms of the Contract. The "Manufacturer / Bidder" hereby agrees and undertakes to ratify and confirm all the whatsoever the said "Attorney" / "Authorised Representative" quotes in the Bid, negotiates and signs the contract with the "Owner" and / or purports to act on behalf of the "Manufacturer / Bidder" by virtue of this Power of Attorney and the same shall bind the "Manufacturer / Bidder" as if done by itself.Q IN WITNESS WHEREOF THE "Manufacturer / Bidder" has executed these presents at on this day ofunder 5the Common Seal of the Manufacturer company / Bidder.%Specimen Signature of Attorney Holder(Name & Designation)For and on behalf of,Common Seal of the above Manufacturer/Bidder-Has been affixed thereto in the presence of : WITNESSES : OccupationGBid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026ØReplacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-59Bid Security/ EMD : Bids are accompanied by Bid Security (EMD) for Rs.2.00Lakhs.We have enclosed a Bid Security through e-Payment mode for a sum of Rs..........Lakhs and remaining amount of Rs.........Lakhs ( above Rs.10 Lakhs) in the form of Bank Guarantee in original and two copies of the original valid for a period of 225 days from the Last date of bid submission as notified (either original or extended), and liable to be forfeited in accordance with Bid Documents. (Mode of Payment towards EMD is as detailed in CLAUSE NO. 13 of ITT & Clause No. 5 of NIT) œD Pœp ‡ˆœ— ©œÁ èœG
`J
œK
O
œ

rs only as per QR for Vendor registration, available in the KPTCL website ie., kptcl.karnataka.gov.in, Link Tender and Procurement-Application for Vendor.(g)rSelf declaration regarding no action against the bidder have been taken by KPTCL in respect of Risk & Cost clause (h)¯Self declaration regarding 'Eligibility clauses in respect of restrictions on procurement from a bidder of a country which shares a land border with India as per Annexure-XVI (i)°Self declaration regarding RESTRICTIONS ON SOURCING OF EQUIPMENTS/MATERIALS BY THE BIDDER FROM A VENDOR OF A COUNTRY WHICH SHARES A LAND BORDER WITH INDIA as per Annexure -XVIIwSection 3 : 1.3 Work performed of similar nature in the last Ten years of Bidder as per Clause No: 3.2 (b) (i) of ITT Project NameName & Address of the EmployerDescription of Work Voltage class/ Number of Sub-Stations/TBs/Length of the Line Contract NumberValue of contract Rs. LakhDate of issue of work orderSpecified period of completionActual date of commissioning <Remarks explaining reasons for delay in commisioning of work3a3b3CName of Bidder#
Note : 1 . The documentary proof of fulfilling the qualifying requirements shall be uploaded along with the bid. The bidder shall upload the P.O,LOI/LOA, DWA, Work done, Performance Certificates issued by the end users not below the rank of Executive/ Divisional Engineer along with the bid.
2. The qualifying experience of the Bidder who is having qualifying experience shall be furnished in the above performa and Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. ‹3. IF this sheet is insufficient for furnishing the qualifying experience of the Bidder then similar sheets shall be seperately uploaded.4 KARNATAKA POWER TRANSMISSION CORPORATION LIMITED LSCHEDULE - 9 (2 of 5) : QUALIFYING REQUIREMENTS Section 3 : 1.5 Information on works for which Tenders have been submitted and works which are yet to be completed as on the date of this Tender of a Bidder,(A) Existing commitments and on-going works:Description of work  Place & State Contract No & Date Name and Address of Employer Value of contract (Rs. Lakh)#Stipulated period of cof Completiong
Value of works remaining to be completed ( Rs.Lakhs) (Attach Certificates from Engineers  in- Charge)!Anticipated date of commissioningEx-WorksGSTTotal(Ex-works+GST)7a7b7c=7a+7b3
Note:Attach Certificates from Engineers  in- Charge+B)Works for which Tenders already submittedDescription of workPlace & State Name and Address of Employer$Estimated value of works (Rs. Lakh) Stipulated period of Completion Date when decision is expectedRemarks if any Ex-works4a4b4c=4a+4bNote:ii) The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be countersigned by the Employer in charge, not below the rank of an Executive Engineer or equivalent. OR The statements showing the value of existing commitments and on-going works as well as the stipulated period of completion remaining for each of the works listed should be verified and certified by Chartered Accountant/ Cost Auditor. However, the Bidder has to upload the PO/Work Award copies for existing commitments and on-going works ®
ii) A self-declaration is to be uploaded by the bidder stating that "the information with regard to assessed available tender capacity (Works on Hand) furnished are correct .äiii. Bidders shall furnish Certificate from Chartered Accountants for split details of Ex-works values and GST of Contract values of the works in the prescribed format as at Clause No. 1.5 of Section-3: Qualification Information1SCHEDULE - 9 (3 of 5) : QUALIFYING REQUIREMENTS ¸Following is the list of major supplied subsation equipments/accessories which are type tested and designed, manufactured by us in accordance with internationally recognised standards.!Item rating, type and DesignationCustomer Date of OrderDate of SupplyDate of Commissioning>Ref. of Cusomer's certificate of successful operation enclosed@Ref. of layout & Customer's certificae for successful commission–Note: Documentary Proof in support of above shall be uploaded in the form of certificates issued by authorized officers of concerned organisations. . 1SCHEDULE - 9 (4 of 5) : QUALIFYING REQUIREMENTS ToH

Section 3 : 1.7 Reports on the financial standing of the tenderer, such as Profit and Loss Statements and Auditor s reports in the preceeding last five years, Audited Financial statements i.e Balance sheets, P&L statements, Turnover certificates duly certified by chartered Accountant as documentary evidence shall be uploaded.SLNo. ParticularsYearBidderConsortium Member - VOID Mention Year!Turnover excluding GST (in Rs.) <GST Amount (in case GST is included in Turnover) (in Rs.)!Turnover including GST (in Rs.) Names of the constituent Firm(Annual turn over for the last Five yearsYear(1)2020-21Year(2)2021-22Year(3)2022-23Year(4)2023-24Year(5)2024-25CLiquid Assets / Credit availability or access to evidence of assetskWhether Audited Balance sheets and Profit & Loss statement are enclosed for the last Five Years ? (yes/No)DWhether Bankers certificate enclosed for credit facilities? (Yes/No). . . 1SCHEDULE - 9 (5 of 5) : QUALIFYING REQUIREMENTS éThe information to be filled in by the Tenderer hereunder will be used for purposes of computing Tender capacity as provided for in Clause 3 of the Instructions to Tenderers. This information will not be incorporated in the Contract.7Constitution or legal status of Tenderer [Upload copy]†
Section - 3: 1.2 Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last Five years (in Rs. Lakhs)  ‚
Total value of works executed (KPTCL & NON KPTCL works) and payments received in the last five years (in Rs. Lakhs) of Bidder zFinancial Year KPTCL worksNon KPTCL works"Total value of works in Rs. Lakh>Note: Attach relevant Certificate/s from Chartered Accountant.Section 3: 1.9 Name, address, telephone number & e-mail id of the Tenderers' bankers who may provide references if contacted by the Employer:FName, address, telephone number & e-mail id of the Tenderers' bankers MSection 3: 1.12 Information on litigations in which the Tenderer is involved:Other Party(ies)EmployerDetails of DisputeAmount involved Remarks showing Present Status:SCHEDULE-10 (1 of 3) Details of Tools and Plants availableDFollowing are the details of the Tools and Plants available with us.MakePresent Location / ProjectRemarks (if any)8SCHEDULE 10 (2 of 3) Details of Technical staff employed#SHEET FOR TECHNOCOMMERCIAL OPENING ËSection 3: 1.8 Qualification and experience of the key technical and management personnel in permanent employment with the tenderer and those that are proposed to be deployed on this contract, if awardedName of the employee/Branch (Degree/Diploma)Year of Passing )Since when employed in erection division Past ExperienceSCHEDULE 10 (3 of 3 )TWe propose the following deployment of manpower for the substation and Line package.Category&MONTHS AFTER PLACEMENT OF AWARD LETTERProject managerSr. Project Manager Supervisor T

杩牵獥漠⁦桴⁥牴湡晳牯敭⁲畦湲獩敨⁤祢甠⁳湵敤⁲桴⁥畔湲敫⁹慐正条⁥牡⁥畇牡湡整摥‮敗映牵桴牥搠捥慬敲琠慨⁴椠桴⁥癥湥⁴景愠祮搠晥捩敩据敩⁳湩洠敥楴杮琠敨朠慵慲瑮敥⁳湩爠灥捥⁴景琠敨挠慨慲瑣牥獩楴獣洠湥楴湯摥戠汥睯愠⁳獥慴汢獩敨⁤晡整⁲潣摮捵楴杮琠敨映捡潴祲琠獥ⱴ礠畯洠祡愠⁴潹牵搠獩牣瑥潩Ɱ敲敪瑣漠⁲捡散瑰琠敨攠畱灩敭瑮愠瑦牥愠獳獥楳杮琠敨氠煩極慤整⁤慤慭敧⁳獡猠数楣楦摥椠敲敬慶瑮挠慬獵⁥景䈠摩䐠捯浵湥⹴ 煅極浰湥⁴%䜀慵慲瑮敥⁤潌獳獥愠⁴慲整⁤畯灴瑵䬨⥗5䴀硡丠潌摡氠獯⁳瑡爠瑡摥瘠汯慴敧愠摮爠瑡摥映敲畱湥祣M䴀硡䰠慯⁤潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡MȈ䴀硡䤠′⁒潬獳愠⁴慲整⁤畣牲湥⁴湡⁤牦煥敵据⁹湡⁤瑡㜠‵敤⁧⁃瑡瀠楲据灩污琠灡™H 慍⁸畁楸楬牡⁹潬獳愠⁴慲整⁤潶瑬条⁥湡⁤牦煥敵据⁹潦⁲潐敷⁲牔湡晳牯敭⑲〲噍ⱁㄠ〱㌯ⴳㄱ噫倠睯牥吠慲獮潦浲牥—一瑯㩥椨 敒敦⁲敔档楮慣灓捥晩捩瑡潩獮ਠ††††⠠楩吩敨氠獯⁳畱瑯摥猠慨汬戠⁥潣獮獩整瑮椠捓敨畤敬ㄠ‴湡⁤呇獐䐨卒漩⁦倠睯牥吠慲獮潦浲牥 †††††1䬀牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整⁤h匀䡃䑅䱕ⵅ㔱††††††††††††††††††††††††††††††††††††††††††††††༠䥌呓传⁆䕖䑎剏ᡓ䥂䑄剅⁓䅎䕍䄠䑎䄠䑄䕒卓䔀啑偉䕍呎 䅍䕔䥒䱁一䵁⁅䙏吠䕈嘠久佄ࡒ䕖䑎剏ㄠ †嘠久佄⁒ਲ†䕖䑎剏㌠ 䕖䑎剏㐠0倀睯牥吠慲獮潦浲牥㈊䴰䅖‬ㄱ⼰㌳ㄭ欱⁖牔湡晳牯敭᭲䙓‶楃捲極⁴牂慥敫獲਺㐱欵བ啓䝒⁅剁䕒呓剅㍓䌠湯牴汯☠删汥祡倠湡汥⁳ 敒慬⁹…牐瑯捥楴湯倠乁䱅♓瑓瑡潩 煅極浰湥⁴畓灰牯⁴瑳畲瑣牵獥䄀千⁒佃䑎䍕佔੒慅瑲⁨楷敲匀汯摩䌠牯⁥湉畳慬潴⁲䐀獩⁣湉畳慬潴⁲瑓楲杮⹳湉畳慬潴⁲慈摲慷敲䌠慬灭⁳†…潐敷⁲潣湮捥潴獲 䰀䅔⁃䅐䕎ቌ⸱欱⁖佐䕗⁒䅃䱂卅䈀呁䕔奒䈀呁䕔奒䌠䅈䝒剅䌀乏剔䱏䌠䉁䕌ནㄱ噋匠楷捴杨慥൲ㄱ噫唠⁇䅃䱂ᡅ䥆䕒䘠䝉呈义⁇充䥕䵐久協"䤀汬浵湩瑡潩煅極浰湥獴⼠䘠硩畴敲୳潔敷⁲慐瑲ᅳ潔敷⁲捁散獳牯敩ᑳ湉畳慬潴⁲慈摲圠牡獥䌀湯畤瑣牯䄠捣獥潳楲獥䔀牡桴圠物⁥捁散獳牯敩䁳潎整㨠䄠祮传桴牥䴠瑡牥慩獬渠浡⁥…瑩⁳敶摮牯⁳牡⁥潴戠⁥湥整敲⹤6 䍓䕈啄䕌ㄭ‶㨠†低䐠噅䅉䥔乏䌠剅䥔䥆䅃䕔⠠乁䕎啘䕒䤭䔩低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄╄楗桴爠晥牥湥散琠畯⁲楂⁤牐灯獯污丠ٯ慤整⁤昀牯†稠敗栠牥扥⁹潣普物桴瑡眠⁥慨敶爠慥⁤桴⁥牰癯獩潩獮漠⁦桴⁥潣瑮慲瑣‬桴⁥瑳灩汵瑡潩景琠敨敳挠慬獵⁥牡⁥捡散瑰扡敬琠獵‬@愀摮眠⁥慨敶渠瑯琠歡湥愠祮搠癥慩楴湯眠慨獴敯敶⁲潴琠敨敳挠慬獵獥̺⥡̠⥢̠⥣̠⥤̠⥥̠⥦䄠汃畡敳丠⹯ㄠ‰景匠捥楴湯㔭匠数楣污䌠湯楤楴湯⁳景䌠湯牴捡⁴匨䍃 ̠⥧Ƞ⥨ä圀⁥畦瑲敨⁲潣普物桴瑡愠祮搠癥慩楴湯琠桴⁥扡癯⁥汣畡敳⁳瑡匠⹉潎‮愨 潴⠠⥨映畯摮愠祮桷牥⁥湩漠牵戠摩瀠潲潰慳ⱬ椠灭楬楣⁴牯攠灸楬楣ⱴ猠慨汬猠慴摮甠据湯楤楴湯污祬眠瑩摨慲湷‬楷桴畯⁴湡⁹潣瑳椠灭楬慣楴湯眠慨獴敯敶⁲潴䬠呐䱃ਮࠀ
匠䡃䑅䱕ⵅ㜱††但䵒䘠剏䈠䑉匠䍅剕呉⽙䵅⁄䄨乎塅剕ⵅ䥉਩吨敢猠慴灭摥漠獒㌮〰⴯丠湯䨭摵捩慩瑳浡⁰慰数⁲湩愠捣牯慤据⁥楷桴䬠呐䱃䌠物畣慬⁲潎‮偋䍔⽌䵇⽔䥃䥖⁌䈨⤷㌯⼵〲㐲䴭乁䝁剅䔠呓呁⁅䔨ㄭ㘰㤹⤲搠瑡摥〠⸲㌰㈮㈰⤴8 ĺ一呏㩅匠䡃䑅䱕⁅啄奌匠䝉䕎⁄奂吠䕈䄠呕佈䥒䕚⁄䕐卒乏匠䅈䱌䈠⁅偕佌䑁䑅䄠䑎匠久⁔䱁乏⁇䥗䡔传䥒䥇䅎⁌䅂䭎䜠䅕䅒呎䕅䄠䑎传䥒䥇䅎⁌䑄⠠佔䅗䑒⁓䥂⁄啇剁乁䕔⁅ 佔䌠䥈䙅䜠久剅䱁䴠乁䝁剅⠠䕔䡃Ⱙ偋䍔⁌䅂䝎䱁剏⁅体䄠⁓佔删䅅䡃䄠呆剅吠䕈䰠十⁔啓䵂卉䥓乏䐠呁⁅…乏传⁒䕂但䕒吠䕈䐠呁⁅…䥔䕍传⁆偏久义⁇䕔䡃低䌠䵏䕍䍒䅉⁌䥂卄ܮ敒⁦潎ሮ慂歮䜠慵慲瑮敥丠⹯ 䐀慥⁲楓獲娬††††††††††††††䤠捡潣摲湡散眠瑩⁨湉楶慴楴湯琠楂⁤湵敤⁲潹牵猠数楣楦慣楴湯䴀猯栀癡湩⁧瑩⁳敒楧瑳牥摥⼠༠效摡传晦捩⁥瑡☠栨牥楥慮瑦牥挠污敬⁤桴⁥䈧摩敤❲ 楷桳!琀慰瑲捩灩瑡⁥湩琠敨猠楡⁤楂⁤牯(愀摮礠畯‬獡愠猠数楣污映癡畯⁲慨敶愠牧敥䩤潴愠捣灥⁴湡椠牲癥捯扡敬愠摮甠据湯楤楴湯污戠湡畧牡湡整⁥潦⁲湡愠潭湵⁴景 瘀污摩甠⁰潴䈠湯戠桥污⁦景䈠摩敤⁲湩氠敩⁵景琠敨䈠摩搠灥獯瑩爠煥極敲⁤潴戠⁥慭敤l戀⁹桴⁥楂摤牥愠⁳⁡潣摮瑩潩牰摥捥湥⁴潦⁲慰瑲捩灩瑡潩湩琠敨猠楡⁤楂Ɽ湩愠摤瑩潩潴琠敨䐠浥湡⁤牤晡⁴潎ਮ††慤整⁤
⸀眀⁥桴ݥ慂歮愠ᩴ慨楶杮漠牵䠠慥⁤景楦散愠⁴q⠀潬慣摡牤獥⥳朠慵慲瑮敥愠摮甠摮牥慴敫琠慰⁹浩敭楤瑡汥⁹湯搠浥湡⁤祢䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩੮ 琀敨愠潭湵⁴景⠀湩映杩牵獥愠摮眠牯獤섩楷桴畯⁴湡⁹敲敳癲瑡潩Ɱ瀠潲整瑳‬敤畭⁲湡⁤敲潣牵敳‮湁⁹畳档搠浥湡⁤慭敤戠⁹慳摩怠睏敮❲猠慨汬戠⁥潣据畬楳敶愠摮戠湩楤杮漠獵椠牲獥数瑣癩⁥景愠祮搠獩異整漠⁲楤晦牥湥散爠楡敳⁤祢琠敨䈠摩敤⹲伊桔獩䜠慵慲瑮敥猠慨汬戠⁥物敲潶慣汢⁥湡⁤桳污敲慭湩瘠污摩甠⁰潴愠摮椠据畬楤杮༊†††††††ꅀ晉愠祮映牵桴牥†硥整獮潩景琠楨⁳畧牡湡整⁥獩爠煥極敲Ɽ琠敨猠浡⁥桳污敢攠瑸湥敤⁤潴猠捵⁨敲畱物摥瀠牥潩⁤渨瑯攠捸敥楤杮漠敮礠慥⥲漠敲散癩湩⁧椠獮牴捵楴湯⁳ਊ牦浯䴠猯†)漀桷獯⁥敢慨晬琠楨⁳畧牡湡整⁥獩椠獳敵⹤吀楨⁳畇牡湡整⁥慨⁳敢湥椠獳敵⁤獵湩⁧䙓卍倠慬晴牯湡⁤桴⁥敲畱獩瑩⁥潣浭湵捩瑡潩湩琠楨⁳敲慧摲栠獡戠敥潦睲牡敤⁤潴琠敨䈠湥晥捩慩祲䈠湡⹫a䤀楷湴獥⁳桷牥潥⁦桴⁥慂歮‬桴潲杵⁨瑩⁳畡桴牯獩摥漠晦捩牥‬慨⁳敳⁴瑩⁳慨摮愠摮猠慴灭漠桴獩ਠ †††††慤⁹景̠瑡ࠠ楗湴獥⁳ 匀杩慮畴敲Ԡ慎敭ጠ晏楦楣污䄠摤敲獳獥ᱳ敄楳湧瑡潩楷桴䈠湡瑓浡⹰&䄀瑴牯敮⁹獡瀠牥倠睯牥漠⁦䄠瑴牯敮⁹潎మ†††䐠瑡⁥Đ一瑯⁥›⤱䈠瑯⁨桴⁥䈠湡畇牡湡整⁥湡⁤敄慭摮䐠慲瑦猠慨汬戠⁥捳湡敮⁤湡⁤灵潬摡摥愠潬杮眠瑩⁨汅捥牴湯捩猠敨瑥⹳††††††††††††††† ††††⤲吠楨⁳慤整猠慨汬戠⁥潆瑲⁹楆敶⠠㔴 慤獹愠瑦牥琠敨氠獡⁴慤整映牯眠楨档琠敨戠摩椠⁳慶楬⹤†††††††††††††††䄠††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整㽤䍓䕈啄䕌ㄭ‸†倠佒但䵒⁁传⁆䕌呔剅传⁆乕䕄呒䭁义升⠠乁䕎啘䕒嘭㨩吨敢攠數畣整⁤湯丠湯䨭摵捩慩慰数⁲景†敒畱獩瑩噥污敵 刀晥圠⸱††††⩉圯⩥栠癡⁥敲摡愠摮攠慸業敮⁤桴⁥潦汬睯湩⁧楢⁤潤畣敭瑮⁳爠汥瑡湩⁧潴†桴⁥ᐊ昨汵捓灯⁥景圠牯⥫愀 潎楴散䤠癮楩湴⁧敔摮牥ĉ戀⤀ 䌀漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀 挀漀渀琀愀椀渀椀渀最 猀攀挀琀椀漀渀 ✀䤀渀瘀椀琀愀琀椀漀渀 昀漀爀 吀攀渀搀攀爀猀ᤀⰠ ✀䤀渀猀琀爀甀挀琀椀漀渀猀 琀漀 吀攀渀搀攀爀攀爀猀ᤀⰠ ᠀䌠漀渀搀椀琀椀漀渀猀 漀昀 䌀漀渀琀爀愀挀琀ᤀ†愀渀搀 䌀漀渀琀爀愀挀琀 䐀愀琀愀⸀ ⸀਀㜀⥣†灓捥慩潃摮瑩潩獮漠⁦潃瑮慲瑣愠潬杮眠瑩⁨湁敮畸敲ഠ†††††潴༠⥤䐠慲楷杮⁳潎ᬮ⥥吠捥湨捩污匠数楣楦慣楴湯㭳ࠁ′‮†††⁉ 敗栠牥扥⁹畳浢瑩漠牵䈠摩愠摮甠摮牥慴敫琠敫灥漠牵䈠摩嘠污摩映牯愠瀠牥潩⁤景传敮䠠湵牤摥愠摮䔠杩瑨⁹慤獹⠠㠱‰慤獹 牦浯琠敨䰠獡⁴慤整漠⁦楢⁤畳浢獩楳湯愠⁳潮楴楦摥⠠楥桴牥漠楲楧慮牯攠瑸湥敤⥤‮䤠⼪敗‪敨敲祢映牵桴牥甠摮牥慴敫琠慨⁴畤楲杮猠楡⁤数楲摯䤠圯⁥桳污潮⁴慶祲愯瑬牥漠⁲敲潶敫洠⽹畯⁲楂⹤ऊ਀퀀Ԁ᐀
桔獩甠摮牥慴楫杮椠⁳湩挠湯楳敤慲楴湯漠⁦偋䍔⁌条敲楥杮琠灯湥洠⽹漠牵䈠摩愠摮挠湯楳敤⁲湡⁤癥污慵整琠敨猠浡⁥潦⁲桴⁥異灲獯⁥景愠慷摲漠⁦潗歲椠整浲⁳景瀠潲楶楳湯⁳景挠慬獵⁥湥楴汴摥∠睁牡⁤景䌠湯瑳畲瑣•挧⹬潮‮㘲漠⁦敓瑣潩呉⁔湡⁤挠⹬潮‮㠱漠⁦䍓⁃景†桴⁥楂⁤潄畣敭瑮⹳ ††匠潨汵⁤桴獩戠摩戠⁥捡散瑰摥‬䤠⼪敗‪污潳愠牧敥琠扡摩⁥祢愠摮映汵楦污桴⁥整浲ⱳ挠湯楤楴湯⁳景瀠潲楶楳湯漠⁦桴⁥扡癯⁥敭瑮潩敮⁤楢⹤ 匀杩慮畴敲愠潬杮眠瑩⁨敓污漠⁦潃䄮䐨汵⁹畁桴牯獩摥琠楳湧琠敨吠湥敤⁲湯䈠桥污⁦景琠敨䌠湯牴捡潴⹲ԩ䅎䕍ఠ䕄䥓乇呁佉⁎0一䵁⁅䙏吠䕈䌠䵏䅐奎†††††⠠湩䈠潬正䰠瑥整獲ȩ†圀呉䕎卓 匀䝉䅎啔䕒ᜠ慄整愠摮倠獯慴摁牤獥ѳ䅄䕔吀汥来慲桰捩䄠摤敲獳一䵁⁅乁⁄䑁剄卅൓敔敬桰湯⁥潎म敔敬⁸潎䜮†††††††††††䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩楌業整彤䍓䕈啄䕌ㄭ‹佃华剏䥔䵕䄠則䕅䕍呎传⁎低⁎啊䥄䥃䱁匠䅔偍倠偁剅传⁆獒㔮〰⴯䄨乎塅剕⁅堭䥉⥉ⴠ嘠䥏䙄低䕔›䍓䕈啄䕌䐠䱕⁙䥓乇䑅䈠⁙䡔⁅啁䡔剏婉䑅倠剅体⁎䡓䱁⁌䕂唠䱐䅏䕄⹄!䌀乏体呒啉⁍䝁䕒䵅久⁔䵁乏升⁔⽍⁳䘀牯䈠摩匠数楣楦慣楴湯丠⹯3伀⁆䅋乒呁䭁⁁佐䕗⁒剔乁䵓卉䥓乏䌠剏佐䅒䥔乏䰠䵉呉䑅4 ††††桔獩挠湯潳瑲畩条敲浥湥⁴硥捥瑵摥漠桴獩Р搠祡!䴀湯桴漠⁦睔桴畯慳摮吠敷瑮⁹潆牵 愀潭杮瑳䴠猯⠠⁡潣灭湡⁹湩潣灲牯瑡摥甠摮牥琠敨氠睡⁳景-⠀潃湵牴⥹愠摮栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡x⠀敨敲湩晡整⁲慣汬摥琠敨∠敌摡䌠浯慰祮•桷捩⁨硥牰獥楳湯猠慨汬椠据畬敤椠獴猠捵散獳牯⁳攬數畣潴獲愠摮瀠牥業瑴摥愠獳杩獮Ⱙ†⽍⁳††††††††††††††⠀敨敲湩晡整⁲慣汬摥琠敨∠潃獮楴畴湥⁴潃灭湡≹眠楨档攠灸敲獳潩獮猠慨汬椠据畬敤椠獴猠捵散獳牯ⱳ硥捥瑵牯⁳湡⁤数浲瑩整⁤獡楳湧⥳†n 潦⁲桴⁥異灲獯⁥景洠歡湩⁧⁡楢⁤湡⁤湥整楲杮椠瑮⁡潣瑮慲瑣⠠湉挠獡⁥景愠慷摲 条楡獮⁴桴⁥灳捥晩捩瑡潩潮̮潆ၲ䅎䕍传⁆䡔⁅佗䭒ǵ昀牯䬠牡慮慴慫倠睯牥吠慲獮業獳潩潃灲牯瑡潩瑌⹤栠癡湩⁧瑩⁳敲楧瑳牥摥漠晦捩⁥瑡†態敶楲䈠慨慶‬慂杮污牯⁥㘵‰〰‹‬態湲瑡歡⁡⠠敨敲湩晡整⁲慣汬摥琠敨∠睏敮≲⸩吠敨氠慥敤⁲景琠敨挠湯潳瑲畩

shall abide by the general terms and conditions specified by the Purchaser. WHEREAS the Owner invited bids as per the above mentioned specifications for the design, manufacture, supply and erection, testing and commissioning of Equipments/Materials stipulated in the bidding documents under subject package ë
AND WHEREAS Section-I ( Volume-1: Clause No. 11:- Qualifying Requirement), forming part of the bidding documents, stipulates that a consortium meeting the requirements of Section-I, ( Invitation of Bid) applicable may bid, provided the Consortium fulfills all other requirements of specification and in such a case, the Bid shall be signed by the members so as to legally bind the members and who will be jointly and severally liable to perform the Contract and all obligations hereunder.õThe above clause further states that the consortium agreement shall be attached to the bid and the contract performance guarantee will be as per the format enclosed with the bidding document without any restriction or liability for either party.DAND WHEREAS the bid has been submitted to the Owner vide proposal NodatedÃby Lead Company based on the Constituent agreement between all the consortium under these presents and the bid in accordance with the requirements of Specifications (Qualification Requirements).3NOW THEREFORE THIS UNDERTAKING WITNESSETH AS UNDER:‚In consideration of the above premises and agreements all the partners to this consortium members do hereby now agree as follows:œ In Consideration of the award of the Contract by the Owner to the Consortium members, we , the members to the consortium agreement do hereby agree that M/s6
shall act as Lead Company and further declare and confirm that we shall jointly and severally be bound up to the Owner for the successful performance of the contract and shall be fully responsible for the design, manufacture, supply and successful performance of the equipments in accordance with the Contract.Z
In case of any breach of the said contract by the Lead company or other constituent of the Consortium agreement, the Lead company do hereby agree to be fully responsible for the successful performance of the contract and to carryout all the obligations and responsibilities under the contract in accordance with the requirements of the Contract' Further, if the Owner suffers any loss or damage on account of any breach in the contract or any shortfall in the performance of the equipment in meeting the performance guaranteed as per the specification in terms of the contract, the Lead company of these presents undertake to promptly make good such loss or damages caused to the Owner, on its demand without any demur. It shall not be necessary or obligatory for the Owner to proceed against Lead Partner to these presents before proceeding against or dealing with the other Partner (s).“
The Financial liability of the members of the consortium agreement to the Owner, with respect to any of the claims arising out of performance or non-performance of the obligations set forth in the said agreement, read in conjunction with the relevant conditions of the contract shall, however not be limited in any way so as to restrict or limit the liabilities of any of the members of the agreement.HIt is expressly understood and agreed between the members to this consortium agreement that the responsibilities and obligations of each of the partners shall be as delineated hereunder (To be incorporated suitably by the member to this agreement). However, each member of the consortium will be severally and jointly responsible for the faithful performance of the contract. It is further agreed by the member that the above sharing of responsibilities and obligations shall not in any way be a limitation of joint and several responsibilities of the members under this contract. +Name of the Lead Bidder/Consortium Partner.Scope of the work/Participation^We further declare ourselves bound to execute our scope of work/participation as stated above;ÉThis Consortium agreement shall be constructed and interpreted in accordance with the laws of India and the courts of Bangalore shall have the exclusive jurisdiction in all matters arising there under.ø
 In case of an award of a Contract, we the Consortium members do hereby agree that we shall be jointly & severally responsible for the works respectively executed and Lead company shall furnishing a contract performance security from a bank in favor of the PURCHASER in the forms acceptable to purchaser for value of Five percent (5%) of the total Contract Price plus additional security for unbalanced tenders in accordance with Clause 25.5 & 29 of ITT and Clause 43 of the CC (Conditions of Contract).>
÷

It is further agreed that the Consortium agreement shall be irrevocable and shall form an integral part of the contract, and shall continue to be enforceable till the owner discharges the same. It shall be effective from the date first mentioned above for all purposes and intents. ÖIN WITNESS WHEREOF the partners to the Consortium have through their authorized representatives executed these presents and affixed Common seals of their companies, on the day, month and year first mentioned above.for Lead Company (Signature),(Signature of the authorized representative)(Name in Block Letters)(Name) (Designation)Common Seal of the Company ( For Constituent 1),SCHEDULE-20 POWER OF ATTORNEY (ANNEXURE-XI)POWER OF ATTORNEY¢(To be stamped on Rs.500/- Non Judicial stamp paper in accordance with KPTCL Circular No. KPTCL/GMT/CIVIL (B7)/35/2024-MANAGER ESTATE (E-106992) dated 02.03.2024)'KNOW ALL MEN BY THESE PRESENTS that we a Company incorporated under the laws of 2and having its Registered Office / Head Office at G"Manufacturer / Bidder" which expression shall unless repugnant to the PContext or meanig thereof, include its successors, administrators and assigns) acting through Mr%its constitute, nominate and appoint )a Company incorporated under the laws of ,and having its Registered / Head Office at Gas its duly constituted lawful Attorney (hereinafter called "Attorney"P or "Authorized Representative") to exercise all or any of the powers for and onE behalf of the "Manufacturer / Bidder" in regard to Specification No.Package'the bids for which have been invited by2(Address "Owner") to undertake the following acts:i.|To submit proposal and participate in the aforesaid Bid Specification of the Owner on behalf of the "Manufacturer / Bidder".ii.ØTo negotiate with the "Owner" the terms and conditions including price for award of the contract pursuant to the aforesaid Bid and to sign the contract with the "Owner" for and on behalf of the Manufacturer / Bidder.iii.\To receive accept and execute the contract for and on behalf of the "Manufacturer / Bidder".iv.@To do any other act or submit any document related to the above.=It is expressly understood that the Power of Attorney shall remain valid, binding and irrecoverable till submission of the Contract performance guarantee in terms of the Contract. The "Manufacturer / Bidder" hereby agrees and undertakes to ratify and confirm all the whatsoever the said "Attorney" / "Authorised Representative" quotes in the Bid, negotiates and signs the contract with the "Owner" and / or purports to act on behalf of the "Manufacturer / Bidder" by virtue of this Power of Attorney and the same shall bind the "Manufacturer / Bidder" as if done by itself.Q IN WITNESS WHEREOF THE "Manufacturer / Bidder" has executed these presents at on this day ofunder 5the Common Seal of the Manufacturer company / Bidder.%Specimen Signature of Attorney Holder(Name & Designation)For and on behalf of,Common Seal of the above Manufacturer/Bidder-Has been affixed thereto in the presence of : WITNESSES : OccupationGBid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026ØReplacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-59Bid Security/ EMD : Bids are accompanied by Bid Security (EMD) for Rs.2.00Lakhs.We have enclosed a Bid Security through e-Payment mode for a sum of Rs..........Lakhs and remaining amount of Rs.........Lakhs ( above Rs.10 Lakhs) in the form of Bank Guarantee in original and two copies of the original valid for a period of 225 days from the Last date of bid submission as notified (either original or extended), and liable to be forfeited in accordance with Bid Documents. (Mode of Payment towards EMD is as detailed in CLAUSE NO. 13 of ITT & Clause No. 5 of NIT) œD Pœp ‡ˆœ— ©œÁ èœG
`J
œK
O
œ

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

10 Defects Liability Period/Guarantee

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Karnataka Power Transmission Corporation Limited

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Karnataka Power Transmission Corporation Limited

SHEET FOR TECHNO COMMERCIAL OPENING (Unpriced)

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

KARNATAKA POWER TRANSMISSION CORPORATION LIMITED

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Place Designation

KARNATAKA POWER TRANSMISSION CORPORATION LIMITED

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Place Designation

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. : To,

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

(* Fill-up whichever is applicable)

Place Designation

Name of the Company

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bidder's Name & Address alongwith GSTIN no. :

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Place Designation

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Printed Name

Karnataka Power Transmission Corporation Limited

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

The Chief Engineer Electy, Transmission (Operations) Zone, KPTCL, Kalaburagi

Place Designation

Name of the Company

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Terms of payment Clause No. 37 of Section-5,Conditions of Contract (CC) and Clause No.8 of Special Conditions of Contrac (SCC)

EMD/Bid Security Clause No. 6, Section :1, Invitation for Tenders (IFT) and Clause No. 13, Section :2, Instruction to Tenderer (ITT)

Contract Performance Guarantee Clause No. 29 of Section:2, Instruction to Tenderers (ITT).

Penalty for delay Clause No. 41 of Section-5 : Conditions of Contract (CC).

Price Basis/ Price adjustment Clause No. 40 of Section-5 :Conditions of Contract (CC).

Defects Liability Period/Guarantee

Work Schedule Clause No.17 of Section:5 Conditions of Contract (CC)

Taxes and Duties Clause No. 11.11 of Section-2: Instruction to Tenderers (ITT).

Place Designation

Name of the Company

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Karnataka Power Transmission Corporation Limited

Bid Enquiry No: KPTCL/2026-27/ SS/Sirigeri Cross CALL-5 Dtd: 06.08.2026

Replacement of existing 2x10MVA, 110/11kV by 2x20MVA, 110/11kV Power Transformer and providing additional MCVCB switchgear at 110kV Sirigeri Cross S/s in Siruguppa Tq., Ballari Dist. on Partial Turnkey Basis. CALL-5