Renovation and Miscellaneous Civil Works for the Existing Shed of Stator Bar at Main Store, GSECL, GTPS

1. SECTION-A:

 ACKNOWLEDGEMENT OF TENDER FEE /EMD.

 TENDER NOTICE.

2. SECTION-B:

 DECLARATION FORM CUM UNDER TAKING TO BE

SIGNED BY BIDDER

 RTGS DETAILS OF BIDDER

 PROJECT SYNOPSIS

 SCOPE OF WORK AND SITE CONDITION

 SPECIAL NOTE FOR PRE-QUALIFICATION

 GENERAL INSTRUCTION TO THE TENDERER

3. SECTION-C:

 GENERAL CONDITIONS OF CONTRACT

4. SECTION-D:

 TERMS AND CONTRACT FOR WORKS

 GENERAL SAFETY RULES & LIST OF SAFETY

5. SECTION-E :

 PERFORMA FOR BANK GUARANTEE

 INTEGRITY PACT

 CERTIFICATE – A

 ANNEXURE – I (DETAILS OF BANK FOR

SOLVEANCY & BG)

6. SECTION-F:

 SPECIAL CONDITIONS FOR USE OF CEMENT

 APPROVED NAME OF MANUFACTURERS OF

STEEL / CEMENT

 GENERAL GUIDELINES RELEVANT TO I.S.

7. SECTION-G:

 GENERAL SPECIFICATIONS

 TECHNICAL SPECIFICATION

 DETAIL SPECIFICATION

8. SECTION-H:

 SCHEDULE-B

 Safe Maintenance Procedure

EW- 341 PUR-F-006 RFQ-

 ACKNOWLEDGEMENT OF TENDER FEE /EMD

 TENDER NOTICE

EW- 341 PUR-F-006 RFQ-

GUJARAT STATE ELECTRICITY CORPORATION LIMITED

Gandhinagar Thermal Power Station, Gandhinagar, India–382041.

Ph. 91-79-23215663Fax: 91-79-23217673, e-mail:

[email protected] Website: www.gsecl.in

CIN:U40100GJ1993SGCO19988

ACKNOWLEDGMENT

E- Tender for the

Renovation and Miscellaneous Civil Works for the Existing Shed of Stator Bar at

Main Store, GSECL, GTPS.

TENDER FEE PAID VIDE DEMAND DRAFT NO. _________________________________

DATED___________________________ RS. __________________________________

EARNEST MONEY DEPOSIT PAID VIDE D.D. NO.

_______________________________ DATED ____________________ RS.

1. The undersigned reserves the right to reject any or all tenders without

assigning any reasons thereof.

2. The Tender fee will be accepted in form of Demand Draft and Earnest Money

Deposit will be accepted in form of Demand Draft or Bank Guarantee of any bank as

prescribe in ANNEXURE- I drawn in favour of “GUJARAT STATE ELECTRICITY

CORPORATION LTD.” payable at Gandhinagar TPS

For & On behalf of GSECL

CHIEF ENGINEER (Gen)

SIGNATURE OF CONTRACTOR GSECL: GTPS

EW- 341 PUR-F-006 RFQ-

GUJARAT STATE ELECTRICITY CORPORATION LIMITED

Gandhinagar Thermal Power Station, Gandhinagar, India–382041.

Ph. 91-79-23215663Fax: 91-79-23217673, e-mail:

[email protected] Website: www.gsecl.in

CIN:U40100GJ1993SGCO19988

Tender Notice No: GSECL/___/ __/ For Civil works

CE [Generation], Gandhinagar, TPS invites “On-line Tenders” (e-tendering) for the work of Renovation

and Miscellaneous Civil Works for the Existing Shed of Stator Bar at Main Store, GSECL, GTPS.Tender

Papers & Specifications may be down loaded from Web site https://gsecl.nprocure.com(For view,

down load and on line submission) and GUVNL / GSECL web sites www.gsecl.in (For view

only).All tender documents are to be upload (Notarized / self-attested copies of original – as specified in

tender document) through online only (mandatory) on (n) procure portal excluding Tender fee and EMD

Tender fee and EMD are to be submitted physically by Registered Post A.D. or Speed Post addressed

to: CHIEF ENGINEER (GENERATION), GUJARAT STATE ELECTRICITY CORPORATION LTD,

THERMAL POWER STATION, GANDHINAGAR-382041, GUJARAT. “NO COURIER SERVICE OR

HAND DELIVERY” will be accepted.

Tender Estimated Cost E.M.D.

EW- Renovation and Rs. 6 (Six) Rs. 1500+

341 Miscellaneous 1665390.65 Calendar = Rs. 1770/- Rs.49962.00

Civil Works for Rupees Months from (One Thousand (Forty nine

the Existing Sixteen Lakh the date of Seven Hundred thousand nine

Shed of Stator Sixty Five written order Seventy hundred sixty

Bar at Main Thousand to commence Rupees Only two rupees

Store, GSECL, Three the work. (Non Only)

GTPS. Hundred Refundable)

Ninety and

Sixty Five

paisa only

180 Days [From the opening of

1 Validity of Tender

Technical Bid].

Last Date for Online tender / offer submission through

2 As per Tender Notice

(n)Procure only up to 18:00 Hrs(This is Mandatory)

Last Date for physical receipt of cover for DD / Bank Guarantee /

3 Online payment reference for Tender Fee and EMD only up to As per Tender Notice

15:00 Hrs Through RPAD or Speed Post Only

Date of opening of online Technical Bid, all relevant documents

submitted through online process, Cover for Tender fee and

4 As per Tender Notice

EMD at 15:30 Hrs (Online technical bid will be opened for

Bidders who have submitted Cover for Tender Fee and EMD)

Tentative date of on-line opening of price bid (if possible) at Party has to be in touch with

15.30 hrs. website www.nprocure.com and

also with e-mail sent by above

For & On behalf of GSECL

CHIEF ENGINEER (Gen)

SIGNATURE OF CONTRACTOR GSECL: GTPS

EW- 341 PUR-F-006 RFQ-

1) Required documents mentioned in tender documents must be uploaded in n-procure

online only. No physical documents are to be submitted except tender fee and EMD

cover. Price Bid shall not be submitted in Hard copy.

2) Demand Draft for Tender Fee and EMD (Original) cover only to submit through

RPAD/Speed post only.

All such documents should be strictly uploaded in N-procure only expect Tender

Fee and EMD details cover. Otherwise the offer will not be considered and no any

further communication in the matter will be entertained.

3) In case any deviation is found in Data / Details / Documents uploaded on N-procure

online offer (e-tendering) documents then such tender will not be considered and no

any further communication in the matter will be entertained. Tenders must be un-

conditional. Conditional Tenders will be rejected.

4) Further bidders are requested to submit Technical Bid documents and price – bid

i.e. Schedule-B on line only and not to submit the Technical bid and price bid in

physical form expect Tender Fee and EMD details cover. This is mandatory. If

Technical bid document and price bid is submitted in physical form expect Tender

Fee and EMD details cover, same will not be opened and only on-line

Uploaded/submitted Technical bid document and price will be considered for

evaluation. The bidder is requested not to upload/submit the by online

(n)procure while bid submission on in (n)procure tender document, condition

of the contract, specification & other relevant documents, except documents

as stated here above. Instead of the same, the bidder shall upload on (n) procure

scan copy of the duly Notarized Undertaking as stated below declaration form on

the stamp paper of Rs. 300/-. However, bidder may download tender document

& preserve with them in Hard Copy for their future reference. Later on, L1

bidder shall be asked to collect the tender documents from the tender inviting

authorities for the purpose of contract agreement execution and place their

signature with seal of the company.

5) It is mandatory for all the bidders to submit their tender documents viz. on-line (e-

tendering) and uploading on (n) procure in scheduled time. Tender documents

submitted in physical form will not be accepted and considered expect Tender Fee

and EMD details cover. Also, all bidders shall submit required Physical documents

as stated in Tender Notice

6) GSECL reserves the rights to reject any OR all tenders without assigning any

reasons thereof.

EW- 341 PUR-F-006 RFQ-

7) Tender Notice Number & name of the work shall be clearly written on the covers of

containing the Tender Fee and EMD.

8) Technical / Price Bids will be opened on the day and time indicated in the tender

notice by an Officer nominated by the Purchaser in the presence of such of the

bidders who wish to be present. Any technical questions, information and

clarifications that may be required pertaining to this tender should be referred to the

CHIEF ENGINEER (GEN.) Gandhinagar TPS. Also during pre-bid meeting (if

arranged) the same may please be discussed

 The exemption in payment of Tender Fee & EMD shall be given to the,

1. Micro & small-scale enterprises which participate directly in tendering process

for the product which they are manufacturing / service which they are

providing and have Udyam registration for items / service under procurement.

2. Startups which participate directly in tendering process for the product which

they are manufacturing / service which they are providing and recognised by

DPIIT under the Start-up India Program and has obtained Udyam registration.

3. Organization which has registration certificate for the manufacturing product

of the tender, from Gujarat Khadi Gramodyog Board or Khadi and Village

Industries Commission(K.V.I.C)or Commissioner of Cottage Industries.

4. Board/Corporations/PSUs of the Central/State Government for their own

manufactured items.

5. State Government recognized organizations like(i) organizations for blinds,

dumb and deaf, disabled, mentally disabled persons;(ii)women's self-help

group recognized by Gujarat Livelihood Promotion Company; which

participate directly in tendering process for the product which they are

manufacturing / service which /they are providing

For & On behalf of GSECL

CHIEF ENGINEER (Gen)

SIGNATURE OF CONTRACTOR GSECL: GTPS

EW- 341 PUR-F-006 RFQ-

 DECLARATION FORM CUM UNDER TAKING

TO BE SIGNED BY BIDDER

 RTGS DETAILS OF BIDDER

 PROJECT SYNOPSIS

 SCOPE OF WORK AND SITE CONDITION

 SPECIAL NOTE FOR PRE-QUALIFICATION

 GENERAL INSTRUCTION TO THE BIDDER

EW- 341 PUR-F-006 RFQ-

(To be uploaded on (n) procure online process duly notarized on Rs. 300/- Non –

Judicial Stamp Paper)

DECLARATION FORM

Bar at Main Store, GSECL, GTPS.

Tender No/ RFQ No:

1. I/We hereby declare that I/We have carefully studied the entire tender placed on the

WEB site and conditions of contract, specifications and other documents of this work

mentioned in the tender and abide by the same. Also, I/We hereby agree to execute

the same accordingly.

2. I/We hereby abide to execute the contract agreement by downloading the copies of

the conditions of contract, specifications and other documents of this work of

and the same will be acceptable to me/us.

3. I/We hereby accept and confirm that any dispute on this regard shall not be

4. I/We hereby declare that I/We have visited the work site and fully acquainted

myself/ourselves with the local situations regarding materials, labour and other

factors pertaining to the work before submitting the tender.

5. I/We hereby confirm that our offer is Un-conditional and without any technical &

commercial deviations.

6. Should this tender be accepted, I /We hereby agree to abide by to fulfill all the terms-

conditions and provision of the Tender and Contract for Works as applicable and

default thereof, to forfeit and to pay to the Gujarat State Electricity Corporation

Limited the sums of money due.

7. The full value of the “Earnest Money Deposit” paid herewith should be absolutely

forfeited to the Corporation, should I/ we do not execute / commence the work after

issuance of date of commencement by GSECL.

8. If, I fail to submit all required documents with application or tender copy ( in each

tender ) then my tender will be cancelled, which is binding to me.

9. If, full or part work will be given to me, it will be accepted to me with same terms, rate

& conditions.

EW- 341 PUR-F-006 RFQ-

10. I, ______ proprietor / owner / partner / Authorized Agent of M/s. ______ do hereby

also declare and undertake as under:

a) That in capacity of independent contractor for M/s. ______ (Sub-Contractor of

M/s. ______ ) worked as contractor at GSECL, ___________Thermal Power Station

for the nature of work of ______ against work Order No. ______ Dt. ______., I have

complied with the provisions of all laws as applicable. I have paid the wages for the

month/s of my contractual period which is / are not less than the minimum rates as

applicable, to all my employee/s and no other dues are payable to my employee/s.

b) That I have covered all the eligible employee/s under the Employees’

Provident Funds and Miscellaneous Provisions Act, 1952 and deposited the

contributions under my PF Code No. ______, place: ______ for the month/s of my

contractual period and as such no amount towards contribution whatever is payable.

c) I further declare and undertake that in case any liability pertaining to any of my

worker, labour, employee/s is/are to be discharged by the principle employer i.e.

Gujarat State Electricity corporation Limited, ___________Thermal Power Station

due to my lapse, I undertake to reimburse the same or the principle employer is

authorized to deduct the same from my dues as payable.

d) I further declare and undertake the legal consequences which may arise in

future under the said work order awarded, and I bond myself to resolve the same at

the risk and cost of M/s. ______.

authorized signatory of M/s

______________________________________________ here by certify that M/s

_________________________________________________ and their proprietor /

any partner / any directors of the firm is not stop deal and / or banned for business

dealing and / or black listed by GUVNL and / or their any subsidiary company viz.

GSECL / GETCO / DGVCL / MGVCL / UGVCL / PGVCL as well as Government

and / or Semi Government company / department.

Seal & Signature of the Bidder

Phone / Mobile/ Fax No. & Company’s Seal

EW- 341 PUR-F-006 RFQ-

E- Tender for the work of Renovation and Miscellaneous Civil Works for the Existing

Shed of Stator Bar at Main Store, GSECL, GTPS.

RTGS DETAIL OF BIDDER

Following RTGS details shall be submitted by agency along with the tender for direct deposit of

payment to the beneficiary account. Bidder has to submit the details as under:

1 Name of Bidder :-

2 Address for correspondence :-

3 E-Mail ID :-

4 Phone / Mobile No. :-

5 Name of Beneficiary :-

6 Bank Account Number of :-

beneficiary

7 Name of Bank of beneficiary :-

8 Name of Bank, branch & address :-

9 Type of account :-

10 Bank Code :-

11 RTGS Code :-

12 IFSC Code :-

EW- 341 PUR-F-006 RFQ-

Project Synopsis and Data

1) Location :- Gandhinagar Thermal power station

2) Purchaser :- GUJARAT STATE ELECTRICITY CORPORATION

3) Engineer :- Chief Engineer(Gen)

4) Site of Project :- Gandhinagar,Gujarat State

5) Nearest town :- Gandhinagar

6) Nearest Railway Station :- Gandhinagar Capital(Ahmedabad is situated at a

distance of about 30.00Km)

7) Nearest Port :-

8) Nearest Air Port :- Ahmedabad-20Km(Approx)

9) Access Road :-

10) Site Elevation from MSL :- RL 81.5 M(floor level)

11) Meteorological Data

 Ambient Air temperature

1] Highest monthly mean of daily Max. :- 35 C

Temperature ( In C)

2] Maximum dry bulb :- 45 C

Temperature ( In C)

3] Minimum dry bulb :- 8.6 C

Temperature ( In C)

 Rainfall

1] Average annual rainfall :- 1000 to 1200mm

2] For 01 hour ( In mm) :- 75 to 100mm

3] For 24 hour ( In mm) :- 250mm

 Wind velocity

1] Maximum wind velocity :-

(In m/sec)

2] Wind direction – N,NE & SW :-

3] For 24 hour ( In mm) :-

 Relative Humidity

1] Annual mean humidity ( In %) :- 50 to 60%

2] Maximum humidity (In %) :- 98%

3] Minimum humidity (In %) :- 2%

4] Type of Atmosphere :- Dry

12) DESIGN DATA

 Seismic Data :-

 Zone :- Zone-III as per IS 1893-1975

 Intensity :-

 Ambient temperature :-

 Other Data :-

EW- 341 PUR-F-006 RFQ-

SCOPE OF WORK AND SITE CONDITIONS

The main scope of the work is to carryout Renovation and Miscellaneous Civil Works for

the Existing Shed of Stator Bar at Main Store, GSECL, GTPS.

Under the scope of this tender the agency has to carry out the subject work, various works as

per all items of Schedule B and as per detail technical specifications items. The quantities taken

under individual items are very tentative. However, the agency has to carry out the works as

per the Company’s requirements (Anywhere in PH Area).

The agency has to carry out the works as per item & specifications of the tender by providing

all materials of best quality and of standard manufactures as the samples approved by EIC and

providing best workmanship through expert manpower.

The agency has to carry out the works as per the priority & schedule given by EIC time to time

even in on or off working hours of the office. The agency will take complete care and will not

damage any other structure in premises of company.

The agency has to carry out all the works by taking all due cares of safety, security norms, with

all risks including scaffolding, strutting, shoring, etc up to any height irrespective of quantum

of the work.

Contractor has to make arrangement for workable site condition with the co operation of

departments of company and agencies, all necessary arrangement to get work permit is to be

made by contractor. Day to day cleaning is required after completion of job. The removed

materials and any other unwanted materials are to be transported and taken away as

instructed by E.I.C.

All safety measures shall be taken by the contractor with his own cost.

The scope of work to be carried out by the Contractor shall also include Clearance of the site,

Disposal of debris, excavated material etc,

The major works involvement generally mentioned as here under:

 Demolition of RCC work, Plaster, roof sheet including ridges, hips, valleys, etc

 Brick work, Plaster, RCC work with TMT bar

 Steel work, welded in built up sections framed work including cutting, hoisting,

fixing….

 Providing and fixing colour coated 0.5 mm (TCT) thick Galvalume sheet of approved

colour….

 Providing ridges or hips 600 mm overall in plain G.I. sheet class-3 fixed with G.I.J. or

L Hooks and nuts….

 Painting work...

 Execution of any item of GoG SoR / GEB SOR / Approved Rate Analysis/Approved

P.O.,W.O. / C.O. Circular etc….

SIGNATURE OF CONTRACTOR CHIEF ENGINEER (Gen)

GSECL, GANDHINAGAR TPS

EW- 341 PUR-F-006 RFQ-

Registration in VMS System

Additional Note: Vendor gets to register in VMS System through vms.guvnl.com. For

registration following documents are required and mail to [email protected] and

[email protected]. After registration vendor have to upload the invoice in the VMS

system for smooth functioning of payment.

Documents required for Registration:

(1) PAN Copy

(2) GST Certificate Copy

(3) Email ID

(4) Full Name of Vendor

EW- 341 PUR-F-006 RFQ-

SPECIAL NOTE FOR PRE-QUALIFICATION

Bar at Main Store, GSECL, GTPS.

The tender documents are of two separate bids i.e. technical and price bids. Bidder is

requested to submit the technical bid with the following credentials for post-

qualification.

1. Bidder should produce evidence of having experience of successfully completed

similar works as defined hereunder, carried out in Central & State Government / Semi-

Government / GSECL / GETCO / DGVCL / MGVCL / UGVCL/PGVCL during the last

seven years ending last day of the month previous to the one in which tender is invited.

Bidder should submit self-attested copies of documentary evidence, preferably photo

copies of work completion certificate, certificate regarding works on hand progressing

satisfactorily along with certificate of amount of work done, work order with Schedule-B,

etc. from the respective department. The amount of completed works should be either

of the following:-

a. Three similar completed works each costing not less than the amount equal to Rs.

b. Two similar completed works each costing not less than the amount equal to Rs.

c. One similar completed works each costing not less than the amount equal to Rs.

2. Similar work means:- General Civil construction / maintenance works.

3. Contractor has to submit satisfactory work completion certificate of the client.

Experience certificate of work executed with private firm shall not be accepted.

Experience as a joint venture or sub-contractor is not allowed and price bid of such

bidders will be rejected.

4. EMD: To pay EMD in form of DD OR in form of B.G. given by bank as described in

the Annexure – I.

5. Tender Fee: The tender fee shall be accompanied in the form of DD.

6. Separate employee’s Provident Fund code number towards registration of firm with

Regional P.F. Commissioner.

7. The Last three-year Audited Annual Accounts, Positive Net worth certificate, and

Average Annual Turnover certificate certified by charted accountant as Per

Qualification Requirement.

8. Financial qualification criteria:

1) The Average Annual Turnover of the bidder, shall not be less than Rs.

during the preceding three (3) financial years as one date of Techno-Commercial

bid opening.

2) Net worth of bidder shall not be less than 100% of the bidder’s paid up share capital

as on the last day of the preceding financial year. In case the Bidder meets the

requirement of Net worth based on the strength of its Subsidiary (ies) and/or

Holding company and/or Subsidiaries of its Holding Companies wherever

applicable, the Net worth of the Bidder and its Subsidiary (ies) and/or Holding

EW- 341 PUR-F-006 RFQ-

company and/or Subsidiary (ies) of the Holding Company, in combined manner

should not be less than 100% of their total paid up share capital. However

individually, their Net worth should not be less than 75% of their respective paid

share capitals.

Net worth in combined manner shall be calculated as follows:

Net worth (combined )= (x1+x2+X3)/(y1+y2+y3) X 100, where x1,x2, x3 are

individual net worth which shall not be less than 75 % of the respective paid up

share capitals and y1, y2, y3 are individual paid up share capitals.

3) In case the bidder is not able to furnish its audited financial statements on stand-

alone entity basis, the unaudited unconsolidated financial statements of the

bidder can be considered acceptable provided the bidder further furnishes the

following documents for substantiation of its qualification.

 Copies of the unaudited unconsolidated financial statements of the bidder along

with copies of the Audited consolidated financial statements of its Holding

 A Certificate from the CEO/CFO of the Holding Company, stating that the

unaudited unconsolidated financial statements form part of the Consolidated

Annual Report of the company.

4) In cases where audited results for the last preceding financial year as on the date

of techno-commercial bid opening are not available, the financial results certified

by a practicing Chartered Accountant shall be considered acceptable. In case,

Bidder is not able to submit the Certificate from practicing Chartered Accountant

certifying its financial parameters, the audited results of three consecutive

financial years preceding the last financial year shall be considered for evaluating

the financial parameters. Further, a Certificate would be required from the

CEO/CFO, stating that the Financial results of the Company are under audit as

on the date of Techno-commercial bid opening and the Certificate from the

practicing Chartered Accountant certifying the financial parameters is not

available.

5) The bidder must submit Average Annual Turnover and Net worth Certificate in

support of Financial QR, duly certified and verified for authenticity from

Independent Statutory Auditor of their company / Practicing Charted Accountant/

C.A. Firms / TPIA (Third-Party Inspection Agency ) empaneled approved by

GSECL, along with copy of Annual Audited Accounts of last three years.

9. Attested copy of relevant document duly signed and sealed on each and every page

shall be uploaded on (n)procure online process only.

10. Attested copy of GST registration certificate issued by appropriate authority.

11. Bidder shall have to submit the PAN card No for Income Tax with documentary

12. Details of the partnership deed.

13. Copy of the updated valid labor contract license from the appropriate authorities and

updated workman group insurance policy covering labor engaged.

14. If the agency is working at GTPS and its civil work/ works is/are in progress having

poor performance /progress of ongoing work, as decided by C.E. (Gen), GTPS; then

the agency may be considered for technically disqualification.

15. TPI Applicable for Works tender having estimated cost up to Rs 1.00 Crore (without

EW- 341 PUR-F-006 RFQ-

16. Declaration form in original duly notarized on stamp paper of Rs. 300/- (As referred

in Tender Notice) to be uploaded on (n)procure online process

17. Bidder has to submit their valid ESIC registration certificate. In cases where the

bidder is required to engage Workers/Employees who are not covered under the

ESIC Scheme, the bidder shall mandatorily submit a valid Employees'

Compensation Insurance Policy covering such Workers/Employees, in accordance

with the applicable statutory provisions.

The above documents will be analyzed and after satisfaction, the price bid will be

opened. GSECL may verify the documents, experience certificates from authority who

have issued such certificates / details.

On opening of Technical Bid, if any required attested documents are missing in

in absence of these documents sufficient competition is not possible, in that case to

post to bidder/bidders to submit the missing required documents within stipulated time

limit and failing which bidder/bidders will be declared technically disqualified for not

submitting the required documents along with technical bids without any further notice.

However, document will be considered valid only if it is for the period of last day of

month previous to the one in which tenders are invited.

For & On behalf of GSECL

CHIEF ENGINEER (Gen)

GSECL: GTPS

SIGNATURE OF CONTRACTOR

EW- 341 PUR-F-006 RFQ-

GENERAL INSTRUCTIONS TO THE BIDDERS

1. SUBMISSIOIN OF TENDER

The tender should be uploaded/ submitted online on n-procure process.

Technical bid cover:- This cover shall contain all relevant attested qualifying documents as

prescribed in tender notice along with tender fee & EMD. Bidder shall have submit Tender Fee and

EMD cover only, All other require document to be upload on online (n)procure process only

Note: - If attested copies of qualifying documents stated as prescribed in tender notice are

not found in on-line Technical bid, but same should be submitted by mail during scrutiny will

be treated as final to consider the bid for pre-qualification. Any missing documents, if

required will be asked from the bidder as mentioned in this tender elsewhere. If party has not

submitted tender in online is liable to be ignored.

Technical Bid

“Please note that the Notarized / self-attested copies of original required documents should

be invariably uploaded in n-procure portal before due date and time in pdf form (Scanned

copy). This is mandatory. No physical documents are required to be submitted except tender

fee and EMD.

Price bid:-

The price bid shall have to be submitted online only. The percentage rates and price shall be written

both in words, and figures and the units in words. In case of any ambiguity or mistakes, the unit

rates and prices written in words shall be considered as final.

Offered rate shall include cost of all Materials, wastage of material , Labours for all leads and lifts,

Supervision, setting out works, Machinery and equipment with its mobilization / demobilization,

transportation charges, Clearing of the site both prior to commencement and after completion of

work. Consumables such as, but not limited to petrol, oil, diesel, lubricants, drill bits, pipes, ropes

etc. Construction facilities such as scaffolding, tarpaulins, wind break, etc., Overheads / profits of

Contractor for due performance of the work under this contract.

Applicability of goods and service tax:-

1) The tenders shall be evaluated on firm price and cost with GST and cess as applicable unless

otherwise mentioned in the tender documents.

2) IF the supplier/contractor have opted for the composition scheme of GST, the same must be clearly

specified with valid declaration and certificate from department. In the event of withdrawal/ cessation

of the supplier from composition scheme during the tenure of the contract, the rate(i. e. price)

mentioned in the price bid shall be final and any additional GST will have to be borne by the

tenderer himself, In no case additional amount towards GST or otherwise will be paid/reimbursed to

supplier/contractor.

3) The bidder shall have to inform their GST no. of the registered place(s) where from the bidder

intends to supply the goods/services, meaning there by the bidder has to supply the goods/services

from the relevant declared/ registered place(s) of supply only.

4) The bidder shall not include GST in their quoted rates; but the bidder has to separately indicate the

GST rate, amount in the price bid schedule.

5) In-case Govt notification comes for change in GST , the same will be applicable.

6) Bidder should indicate GST no.( copy of GST registration to be enclosed) and PAN NO. (copy of

PAN to be enclosed) Tenders submitted without GSTIN No by the firms, the offer will be rejected

without entering into further correspondence.

Further information required, if any, can be had from the office of the Chief Engineer, GSECL,

GTPS. But it must be clearly noted that the tenders must be received complete in every respect

by the due date and time.

i. The bidder must clearly quote rates in figure as well as in words. In case of any discrepancy,

whatever written in words shall prevail.

ii. No deviation in terms & conditions, Schedule-B and technical specifications will be entertained.

Any ignorance for this shall not relieve the contractor from his contractual liability arising as per

tender documents and conditions contained in it.

iii. The bidders are required to quote only firm prices. No variation will be accepted on price/ raw

materials/ finished products or on any other cause.

iv. The bidders should note that the completion of above mentioned works in all respect in

EW- 341 PUR-F-006 RFQ-

accordance with the time limit given is very important and should be strictly adhered to. The work

is to be completed in time limit from the date of issue of written order to commence the work by

the Chief Engineer (Gen.), GSECL, Gandhinagar TPS.

v. The bids should be valid for a minimum period of 180 Days from the date of opening of technical

bid. During this period tenderer shall not be allowed to withdraw their tender and if withdrawn, the

Earnest Money Deposit submitted with the tender will be forfeited.

vi. The works covered under these specification shall be carried-out and governed by “Tender and

contract for Works” booklet appended herewith except where conditions specified in this

specifications.

vii. The successful bidder shall have to enter in to an agreement for contract as per G.S.E.C.L rules

on a stamp paper of Rs.300/- and necessary stamp duty charge shall be borne by the

contractor/consultant.

viii. The complete specification comprises of the following.

Bill of Quantities (Schedule-B), instructions to the bidders, Tender specifications and scope of

work, Tender and contract for Works booklet, General Conditions, Instructions to bidder &

Technical specifications. All these sections are complimentary to each other. The particulars and

requirements contained herein shall cover the execution of the works covered under these

specifications.

ix. The tenderer must visit the site of works and see for himself the site conditions regarding

availability of approach road during all seasons and other matters affecting the above works

before submitting the tender.

x. The submission of tender by a contractor implies that he has read these instructions the conditions

of contract etc. and has himself aware of the scope and specifications of the work to be done and

of conditions and local conditions and other factors bearings on the execution of the works.

GSECL will not therefore after acceptance of contractor's rate pay any extra charge for any other

reason; in case the contractor is found later on to have misjudged the site condition.

xi. GSECL’s authorized officers who accepts tender, shall have the right of rejecting all or any of the

tenders and will not be bound to accept the lowest offer nor to assign any reason whatsoever for

the rejection of any tender or all tenders.

xii. Bidders shall provide evidence of their continued eligibility to the satisfaction of the owner.

xiii. Bidders shall not be listed under a declaration of ineligibility for corrupt or fraudulent Practices

issued by the Govt., the list of black listed Contractors announced by GSECL (erstwhile GEB)

Govt. of Gujarat or its Public Sector undertakings or the contractors who are under stop dealing in

GUVNL and /or their any subsidiary company viz. GETCO/MGVCL/UGVCL/PGVCL/DGVCL.

xiv.The bid, and in case of a successful bid, the Form of Contract Agreement, shall be signed with

the name of Firm / company which will be legally binding on all partners / parties.

xv.If the application is made by an individual, it shall be signed by the individual above his full

typed written name and current address.

xvi.If the application is made by a proprietary firm. It shall be signed by the proprietor above his full

typed written name and the full name of his firm with its current address.

xvii.If the application is made by a partnership firm, it shall be signed by all the partners of the firm

above their full type written names and current addresses or alternatively by partner holding

power of attorney for the firm in which case a certified copy of the power of attorney shall

accompany the application. A certified copy of the partnership deed, full names and current

addresses of all the partners of the firm shall also accompany the application.

xviii. If the application is made by a limited company or a Corporation, it shall be signed by the

authorized person holding power of attorney for signing application in which case a certified copy

of the power of attorney shall accompany the application. Such Limited company or

Corporation may be required to furnish satisfactory evidence of its existence before the pre-

qualification evaluation. They should also furnish Articles of Memorandum of Association. If the

application is made by group of companies, it shall be signed by the authorized person. The

authority letter shall be accompanied with the application.

1. SECURITY DEPOSIT

It should be mandatory to submit security deposit as per cl no.7 of Section C (i.e General

condition of contract).

2. MAINTENANCE:

i] The contractor shall be responsible to make good and remedy at his own expense any

defect which may develop or may be noticed before the period mentioned hereunder

EW- 341 PUR-F-006 RFQ-

from the certified date of completion. The same shall be attended within 15 days of

receipt of the notice. In the case of failure on the part of the contractor, the Engineer-in-

charge may rectify or remove or re-execute the work at the risk & cost of the contractor.

The Engineer-in-charge shall be entitled to appropriate the whole or any part of the

amount of security deposit towards the expenses, if any, incurred by him in rectification,

removal or re-execution. The defects liability period shall be as under,

a) For all works costing more than Rs. 50,000 and up to Rs. 1 crore (amount put to

tender), the period shall be 06 months from the certified date of completion OR one

monsoon, whichever is later.

For the purpose of deciding monsoon period, the 30th September may be treated as the

last date.

3. TIME LIMIT FOR WORK:

The scheduled time limit for the completion of work shall be 6 (Six) Calendar months from the

date of issue of letter to commence the work. However extension in time limit will be granted by

GSECL for the genuine reasons only as per terms of the contracts.

4. TERMS OF PAYMENTS:

Contractor shall be paid RA bill after observing GSECL’s general procedure and

submission of bill by the agency. Also, 75% payment shall be made immediately within a

week period on receipt of recorded bill by Account Section without checking of detail bill

and compliance of queries & statutory requirement. However, remaining balance 25%

amount shall be released only after through checking of detail bill and compliance of

various quarries, statutory compliance etc. The above payment term is applicable to all the

bills of general civil works & ARC/BRC works, provided the bills are recorded regularly and

submitted to Account Section within Ninety [90] days. If the contractor fails to submit the

bills regularly in such a way so that the same cannot be recorded and submitted to account

section within Sixty [60] days, ad-hoc payment as stated above, may not be released and

payment will be released as per GSECL’s general procedure. The period of Sixty [60] days

shall be considered from the date of receipt of last R.A. Bill by Account Section.

5. METHOD OF PAYMENT:

a. The payment for the work done will be made by running bills every month after taking

joint measurement within 30 days.

b. Final bill will be paid within reasonable time after settlement of material account by you

and after recording of joint measurement.

6. VERIFICATION OF BID DOCUMENTS SUBMITTED BY BIDDER THROUGH THIRD

PARTY INSPECTION (TPI) AGENCIES FOR ESTIMATED COST UP TO RS. 1.0 CR.

(WITHOUT TAX):

All bidders shall submit the details/documents in support of Technical Qualification

Requirements duly certified and verified for authenticity from Specified Third-Party

inspection Agency (TPIA) or Statutory Auditor of their Company or Practicing CA,/CA Firm

along with a certificate regarding verification of authenticity of documents as per the format

placed at Annexur-1. All the documents submitted by the bidder in support of the meeting

Technical QR only shall be digitally signed by the Specified Third Party inspection Agency

(TPIA) or Statutory Auditor of their Company or Practicing CA/CA Firm.

The verification and certification of authenticity of documents is acceptable from any of the

following TPIAs:

1. M/s Competent lnspectorate and Consultants Pvt. Ltd, Hyderabad, India.

2. M/s Gulf Lloyds industrial Service India Pvt. Ltd.-Ahmedabad.

3. M/s International Certifications Services.

4. M/s lntertek India Pvt. Ltd.

5. M/s SGS India Pvt. Ltd.

EW- 341 PUR-F-006 RFQ-

6. M/s Moody international (India) Pvt. Ltd.

7. M/s TUV SUD South Asia (P) Ltd.

8. M/s TUV Rheinland (India) Pvt. Ltd.

9. M/s Bureau Veritas (India) Pvt. Ltd.

10. M/s. Hertz inspection & Services Pvt. Ltd.

11. M/s. IRCLASS Systems and Solutions Pvt. Ltd.

Bidders shall be responsible for getting their documents/ credentials verified & certified by

the Specified Third-Party Inspection Agency (TPIA) or Statutory Auditor of their Company

or Practicing CA/CA Firm in support of Technical QR. All the costs pertaining to third party

verification and certification (including those by statutory auditors) shall be borne by the

Bidder. GSECL shall have no liability (financial or Otherwise) towards the same and shall

not be liable for any claim/ dispute between the bidder and the Specified Third-Party

inspection Agency (TPIA) or Statutory Auditor of their Company or Practicing CA/CA Firm

The following website may be referred for contact details of above TPIAs:

http://nabcb.qci.org.in//accreditation/reg_bod_inspection_bodies.php.

Annexure-1

Undertaking from Third Party inspection Agency/Statutory Auditor or Practicing CA/CA Firm

(On letter head digitally signed by a person duly authorized to Sign on behalf of the firm)

Ref: Date:

Power Station ……………….

Subject: Authentication of veracity of documents submitted by M/s ........ in support of

Meeting the Qualifying Requirements

Ref: Tender no. …………………..

Name of the Package/ Tender: ………………………………………

M/s. ……………… (hereinafter called Bidder) having Registered office at …………………… intend

to participate in above referred tender of GSECL.

The tender condition stipulates that the bidder shall submit supporting Documents pertaining to

Qualifying Requirement duly verified and certified by Third-Party Inspection Agency (TPIA) or

Statutory Auditor of their Company or Practicing CA/CA Firm as per the list mentioned in the bidding

documents.

In this regard, it is hereby confirmed that we have examined the following documents, which are

also attached with this letter. The same has been verified from the Original Documents and / or

Client for authenticity.

We hereby confirm that the following documents are found to be genuine and authentic.

1. Doc ref. no. ……….. Dated …….. (Name of Documents)

2. Doc ref. no. ……….. Dated …….. (Name of Documents)

All the aforesaid documents have been digitally signed by us as a certificate of authenticity.

We further confirm that we neither have any vested interest in aforesaid tender nor have any conflict

of interest in respect of above tender.

EW- 341 PUR-F-006 RFQ-

This certificate is issued at the request of M/s ………………. (Bidder) for the purpose of participating

in the subject tender/s

Thanking you,

7. ASSIGNMENT:

The rights and liabilities of the contractor shall not be assigned or transferred by them without the

consent in writing of the GSECL to any other person, firm or organization.

1. The successful Bidder, on receipt of letter of intent will submit within a week's time his

planning / programme of works, for scrutiny of the GSECL in a Bar Chart format, clearly indicating

GSECL's inputs also. Contractor will plan his works such that simultaneous work should progress

in such a way that entire job is completed in scheduled time limit on all the fronts released by

2. The successful bidder will have to depute his authorized representative to attend progress

review meetings to be held at GSECL, Gandhinagar TPS without any extra cost.

3. The Contractor will be responsible for complying with all rules and regulations and labour

laws applicable to him and the GSECL will not be responsible for any lapses committed by them. If

there is any claim from any Government authority pertaining to the contract, the same amount will

be deducted from the Contractor's bill.

4. The time limit for completion of work is stipulated as in the tender will be adhered to.

5. The Contractor's rates should be firm and no variation clause is to be quoted by the

Contractor and GSECL will not accept the same, during contractual period including extended time

limit if any.

8. BIDDER TO STUDY, ANALYSE & CONSIDER:

a) The information given in this specification is in good faith and meant to serve as a

guide to the Bidder. It is, therefore, imperative that Bidder shall obtain and examine for himself all

the data, information and particulars required for the satisfactory execution of the work under this

tender. The submission of a bid by Bidder implies that he has fully read the specifications, bid

drawings, instruction to the bidder along with Contract Document and Conditions of Contract,

applicable labour laws, safety norms etc., and has made himself aware of the scope and the

specifications for the work to be performed and local conditions and other features which have a

bearing on the cost and execution of the work. This specification is intended as a general

description of quality envisaged for materials and workmanship and of the finished work. It is not

intended to cover minute details. The work shall be executed in accordance with the best modern

practice and to the complete satisfaction of the Purchaser. Special techniques approved by the

Purchaser shall be used if and where found necessary. This specification shall have precedence if

anything contrary to this is stated elsewhere in the contract documents. The Purchaser’s decision

shall be final and binding on the contractor on any issue arising out of such discrepancies.

b) Inspection of site by bidder:

Before submission of his bid, Bidder shall inspect the site, examine and obtain all information

required and satisfy himself regarding matters such as:

 weather characteristics,

 Location of site and access, right of way, means of communication & mode of Transport to site,

 The type and number of equipment and facilities required

 The quantity of various items of the work.

 The availability and rates of material.

 Labours condition.

 Local working conditions, obstructions and hindrances that may arise etc.

 Power house, which is under running conditions.

 Required GSECL’s security checks.

 All materials brought to site only after making entries in security register at Control gate

c) These factors are likely to affect the satisfactory completion of work and or cost thereof. The

submission of a bid by the Bidder will be construed as evidence that such an examination

was made and any later claims/ disputes in regard to rates quoted shall not be entertained

or considered by the GSECL.

d) The site visit shall be done by the bidder on his own responsibility and all liabilities including

cash, arising out of the site visit shall be at the bidder’s account.

e) Contractor’s scope of work shall also include making all necessary arrangements for access

EW- 341 PUR-F-006 RFQ-

to work sites, stores and site offices etc. from the nearest approach road to facilitate

transportation of man power, machinery and equipment duly considering the existing site

conditions. No extra claims / costs will be entertained by GSECL.

f) The bidder shall carefully study the work to be carried out & consider all the factors & shall

take into account &consider all the factors such as lead, lift haulage of materials, sequence

of construction, etc. & shall allow for all such information / data in the rates quoted.

g) The GSECL will not pay any extra charges or rate for any reason in case the contractor

claims, after acceptance of contract to have misjudged the site condition. Ignorance of the

intents and contents of the specification document and site conditions shall not be accepted

by the Owner as basis for any claims for compensation.

h) BIDDER shall inspect the site, examine and obtain all information required and satisfy

himself regarding matters such as sub-surface conditions, water records, access to site,

communication, transport, right of way, the type and number of equipment and facilities

required for the satisfactory completion of work, the quantity of various items of the work, the

availability and rates of material, local working conditions, uncertainties of weather,

obstructions and hindrances that may arise etc. which may affect the work or cost thereof,

before submission of his bid. Ignorance of site conditions shall not be accepted by the

ENGINEER IN CHARGE as basis for any claim for compensation.

i) The rates quoted by BIDDER shall be based on his own knowledge and judgment of the

conditions and hazards involved and shall not be based on any representations of the

Engineer in Charge. No claim on this account shall be admitted by the GSECL.

j) The bidders shall submit on online in n-procure with their offer without any deviations in

general terms and conditions of the contract or in technical specifications.

k) Tenders received after the time and date specified in the tender notice will not be accepted.

Once the offer is submitted by bidder before due date of submission, the bidder shall not be

allowed to submit revised/ additional/ modified offer even before due date and time of

submission of tender. However, if the date of issue and/or submission of tender are

extended by the Corporation due to any reason, the bidder may submit if their wishes the

revised/additional/modified offer before extended due date and time of submission.

l) The Corporation reserves the right to accept any tender irrespective of whether it is lowest or

not or to reject all the tenders without assigning any reasons thereof. Tenders deferring from

the technical specifications or the method of bidding in a radical manner may also be

m) The bidder shall be presumed to have carefully examined the drawings, conditions &

specifications of work & to have fully acquainted themselves with all details of the site

conditions, locations, materials, geological & weather characteristics, labour conditions & in

general all the necessary information and data etc. pertaining to and need for the work.

n) This specification is intended as a general description of quality envisaged for materials and

workmanship and of the finished work. It is not intended to cover minute details. The work

shall be executed in accordance with the best modern practice and to the complete

satisfaction of the Purchaser. Special techniques approved by the Purchaser shall be used if

and where found necessary. This specification shall have precedence if anything contrary to

this is stated elsewhere in the contract documents. The Purchaser’s decision shall be final

and binding on the contractor on any issue arising out of such discrepancies.

o) Each bidder shall also submit a 'Declaration' to the effect that the tenderer is an engineering

construction firm or an association of firm or firm which has successfully carried out large

works of this nature and has adequate organization and experienced personnel to handle

this type and magnitude of work. Information should also be given regarding the constitution

of the firm; it’s authorized, subscribed & paid up capital, the date & place of registration, the

place of business, the names of the directors and other relevant information.

p) It is the intent of the ENGINEER IN CHARGE to incorporate these specification documents

in the final ‘Contract’. BIDDERS are required to review these documents and clearly state in

their proposals their acceptance of the same.

q) Each page of the bid document including the bid drawings shall be signed, stamped and

dated in ink by the BIDDER as a token of having examined the same. Any correction in

price and the rates entered in the Schedule of Price shall also be signed and dated by the

BIDDER in ink, before submitting the bid. Non-compliance with this condition will make the

bid liable for rejection.

r) All safety measures as required to be adopted as per the Statutory Regulations and the

Safety Rules of the Plant shall be strictly followed by the Contractor during the execution of

the Contract. The Contractor shall set up a suitable safety organization of his own in this

EW- 341 PUR-F-006 RFQ-

s) In connection with the execution of the Contract, the Contractor shall comply with all

applicable statutory Rules & Regulations including employment of labours at site.

t) The Contractor shall carry out any and all such works, as may be required, for civil work to

be completed in all respect as per the Contract Specification.

u) If the GSECL Engineer-in-Charge is not satisfied with the progress of work at site, he shall

direct the Contractor to depute more numbers of supervisory personnel/workers to meet the

completion schedules as per the Contract. Upon receiving such direction, Contractor shall

deploy additional personnel within 7 days without any extra cost.

v) The GSECL may during the progress of work, order the removal of part or whole of the work

executed, found not in accordance with the specifications/ instructions. No extra claims shall

be entertained for re-executing or altering of such work.

9. SAFETY MEASURES:

The contractor shall ensure the safety of workers, material and structure including existing

structures during execution of the contract. Safety measures shall be followed during

operations of equipments/machinery being used. No separate payment shall be made for

the safety measures and the quoted rates shall include the cost for all safety measures .

10. COMPLETENESS:

Any technical services as set forth here in above and which might not have been specifically

mentioned in this Contract relating to the work or in the specifications and which are not

expressly excluded therefore but which are necessary for the performance in accordance

with the specifications as an integral part of the painting and misc. Civil works shall be

rendered by the Contractor without any extra cost.

11. TOTAL RESPONSIBILITY

The Contractor shall be solely responsible for the entire technical works / services

irrespective of works / services have been made /rendered by him.

12. PAYMENT TO THE LABOURES:

(a) Contractor has to pay the CPF as well as salary to his skilled/unskilled manpower by

cheque A/c payee only, as per minimum wages & prevailing applicable rules on or

before 7th day of next month.

(b) Contractor has to produce challan of PF with list of employees.

(c) Contractor shall have to make payment to his labours in presence of Personal Officer

(Estt.) GSECL, Gandhinagar TPS.

13. CONTRACT AGGREMENT ON ACCEPTANCE:

 The successful contractor will have to sign an agreement as per the Gujarat State

Electricity Corporation Ltd.'s rules on stamped paper and the necessary stamp duty

charges shall be borne by the contractor.

 On acceptance of the tender the name (s) of the accredited representative (s) of the

tenderer who would be responsible for taking instructions from the Engineers of the

GSECL shall be communicated to Chief Engineer (Gen.) Gandhinagar Power Station,

Gujarat State Electricity Corporation Limited.

14. Unsatisfactory progress of the work:

If the work is found not progressing as per the requirement or found not satisfactory then

GSECL will take such action to get the work done through the other agency at agency’s risk

and cost with 15% supervision charges and same will be recovered from agency.

15. The EMD will be returned promptly to the unsuccessful bidder except that of L1, L2 & L3 till

the successful contractor pays the Security Deposit as mentioned in tender document or

after the expiry of the validity of the offer, whichever is earlier.

The EMD will be returned to the successful tenderer after he furnishes the Security Deposit

for the tender work. If he fails to furnish the SD, his EMD shall be forfeited and the tenderer

will not be allowed to participate in the tenders invited by this office for a period of ONE

Year in respective Power Station.

The EMD in form of Bank Guarantee shall be valid for Ten Months from the date of

submission of the tender.

16. Effect and validity of Bid: The submission of bid with these documents and specification

shall constitute an agreement that bidder shall have no cause of action or claim against the

GSECL for rejection of his bid. The GSECL shall always be at liberty to reject or accept, split

any bid or bids at its sole discretion and any action will not be called into question and the

bidder shall have no claim in that regards against the GSECL.

17. Stop Deal / Banned for business dealing / Blacklisting :-

 Has submitted fake, false or forged documents/certificates

EW- 341 PUR-F-006 RFQ-

 Has revised/ withdrawn price bid after opening of Techno-commercial bid, until and unless

it is sought for,

 Has tempered with the stipulated tendering procedure.

 Has refused to accept Letter of Acceptance / Purchase order / Work Order after the same

is issued by the company within the validity period and as per agreed terms and

conditions,

 Has committed breach of contract or has failed to perform a contract or has abandoned

the contract,

 Has failed to provide suitable expertise for the work as per pre-scheduled program.

 Has failed to submit all the necessary tests reports / documents within time scheduled / as

per company’s time limit, as mentioned in the LOA, if the Letter of Acceptance (LOA) is

placed subject to submission of type reports / documents to the firm.

 Has indulged in construction and erection of defective works.

 Has supplied inferior quality / defective materials and refused to replace with stipulated

time frame, as specified by the company,

 Has substituted materials in lieu of materials supplied by the company or has not returned

or has short returned or has unauthorisely disposed of materials / documents / drawings /

tools or plants or equipment supplied by the Company,

 Has involved in malpractices such as bribery, corruption, fraud, canvassing and pilferage,

 Has unauthorisely obtained official company information or copies of documents, in

relation to the Tender / Contract.

 Has failed to follow the stipulated mode of communication, if specified by the tendering

authority / Purchaser.

 Has parted with, leaked or provided confidential / proprietary information of the company

given to the firm only for its use (in discharge of its obligations against an order) to any

third party without prior consent of the Company,

 Any other ground for which in the opinion of the Company makes it undesirable to deal

with the Firm

 In case the state Government directs the Company to place a firm in stop dealing / banned

for business dealing / blacklisting.

18. Conflict of Interest among Bidders / Agents

A bidder shall not have conflict of interest with other bidders for particular quoted

item. Such conflict of interest can lead to anti-competitive practices to the detriment

of Procuring Entity's interests. The bidder found to have a conflict of interest shall

be disqualified. A bidder may be considered to have a conflict of interest with one

or more parties in this bidding process for particular quoted item, if:

a) They have proprietor/partner(s)/Director(s)in common; or

b) They receive or have received any direct or indirect

subsidy/financial stake from any of them; or

c) They have the same legal representative/agent for purposes of this bid; or

d) they have relationship with each other, directly or through common third parties,

that puts them in a position to have access to information about or influence on

the bid of another bidder, or

e) bidder participates in more than one bid in this bidding process. Participation by a

bidder in more than one Bid will result in the disqualification of all bids in which

the parties are involved. However, this does not limit the inclusion of the

components/ sub-assembly/ assemblies from one bidding manufacturer in more

than one bid.

f) In cases of agents quoting in offshore procurements, on behalf of their principal

manufacturers, one agent cannot represent two manufacturers or quote on their

behalf in a particular tender enquiry. One manufacturer can also authorise only

one agent/ dealer. There can be only one bid from the following:

EW- 341 PUR-F-006 RFQ-

1. The principal manufacturer directly or through one Indian agent on his behalf;

2. Indian/foreign agent on behalf of onIy one principal.

g) A Bidder or any of its affiliates participated as a consultant in the preparation of

the design or technical specifications of the contract that is the subject of the Bid;

h) in case of a holding company having more than one independently manufacturing

units, or more than one unit having common business ownership/ management,

only one unit should quote. Similar restrictions would apply to closely related

sister companies. Bidders must proactively declare such sister/common

business/ management units in same/ similar line of business.

i) Bidder shall not act in contravention/violation to the provisions of competition act,

as amended from time to time.

Every bidder should, at the time of submission of bid, give a declaration, that bidder

shall not have conflict of interest with other bidders for particular quoted item, as

For & On behalf of GSECL

CHIEF ENGINEER (Gen)

GSECL: GTPS

SIGNATURE OF CONTRACTOR

EW- 341 PUR-F-006 RFQ-

SECTION-C:

 GENERAL CONDITIONS OF CONTRACT

EW- 341 PUR-F-006 RFQ-

GENERAL CONDITIONS OF CONTRACT

1. DEFINITIONS :

(a) The Contract means the documents forming the tender and acceptance thereof, together

with the documents referred to therein or individual work order in the case of term

contract, including these conditions, schedules and/or additional conditions attached to

the form of tender or individual works, order, rate schedule, the specifications and the

drawings and all these documents, as applicable, taken together shall be deemed to form

the contract.

(b) The “Tender Document” means the form of tender, the applicable schedules and/or

additional conditions and the specifications and/or drawing as issued to the contractors

for the purpose of preparing tender.

(c) The expression “Works” or “Work” when used in the condition of contract shall, unless

there be something in the subject or context repugnant to such construction means, the

works or the work contracted to be executed under or in virtue of the contract whether

original or altered.

(d) The “Contractor” means the individual or firm or Corporation, whether incorporated or not,

undertaking the words and shall include his or its legal personal representatives,

successors and permitted assignees.

(e) “Corporation” means The Gujarat State Electricity Corporation Ltd. and the “Accepting

Officer” means the Officer who is authorized to sign and signs the contract on behalf of

the “Corporation”.

(f) The letter “EE” means Executive Engineer who in the case of measurement and lump

sum contract, direct the contract and the letters “SE” means Superintending Engineer and

“GM” means General Manager who administers and in the case of the term contracts,

directs the contract.

(g) The “Engineer-in-charge” means all officers of the Corporation appointed by the General

Manager to supervise the works or part of the works.

(h) “Approved” and “Directed” means the approval or direction of the Chief Engineer (Gen),

Gandhinagar TPS to Superintending Engineer or the person deputed by him for the

particular purpose.

(i) “BS.” means “British Standards” as issued by the British Standards Institution. “A.S.”

means the “American Standards” as issued by the American Standards Institution, and

“I.S.” means the “Indian Standards” as issued by the Indian Standards Institution.

Wherever the above-mentioned abbreviations are referred to, in the specifications and/or

work orders, they mean the addition with all amendments current at the date of issue of

tender document of work orders.

(j) In the case of measurement and terms of contract “Specifications” mean those contained

in Gujarat State Electricity Corporation Ltd. scheduled together with any amendments etc.

embodied in the tender documents. “Drawing” refers to those incorporating the tender

documents and/or any work orders referred therein.

(k) The “Contract Sum” means the sum accepted or the sum calculated in accordance with

the prices accepted in the tender and/or the contract rate as payable to the contractor for

the full and entire executing and completion of works.

(l) “The date for completion” is the date or dates of completion of the work or any part of the

works set out or ascertained in accordance with the individual work orders and the tender

documents or any subsequent agreed amendments thereto.

2. CONTRACTOR TO INFORM HIMSELF FULLY:

A. Notwithstanding anything contained to the contrary in the specifications or tenders in

subsequent exchange of correspondence, the conditions of contract shall be binding on

the Contractor and any change or variation expressed or implied, however made in the

said conditions, shall not be valid or operative unless expressly sanctioned by the

Corporation. The Contractor shall be deemed to have fully informed himself and to have

special knowledge of the provisions of the conditions of the Contract herein contained.

B. The contractor shall be deemed to have carefully examined the work and site conditions,

the general conditions, the special conditions, specifications, schedules and drawing

and shall be deemed to have visited the site of the works and to have fully informed

himself regarding the local conditions.

EW- 341 PUR-F-006 RFQ-

C. If there shall have any doubt as to the meaning of any portion of these general

conditions or special conditions of the scope of work of the specifications or any other

matter concerning the contract, he shall in good time before submitting his tender, send

for the particulars thereof and submit them to the Engineer-in-charge in writing in order

that such doubt may be removed.

3. CONTRACT DRAWING AND SPECIFICATIONS:

 The contractor will be entitled to receive one set of agreement along with one certified

copy of accepted tender.

 The drawings which form part of these specifications show the work to be done in as

much detail as is possible at the present stage. They will be supplemented by such

additional detailed drawings as may be necessary as the work progresses. The contractor

shall perform the work on these features and in accordance with these additional or

revised drawings as the case may be and at the applicable rates as per the contract.

 The contractor shall check all drawings carefully and shall bring to the notice to the

Engineer-in-charge immediately of any errors or omissions discovered. The contractor

shall not take advantages of errors or omissions of any kind in the drawings supplied.

4. INPUTS BY GSECL:

The electric power supply and connection for construction / work purpose shall be given at

one mutually agreed point at work site free of cost by the GSECL. Further extension for

construction site as well as bore well site for using construction water will have to be

carried out by the contractor as per requirement at their cost. The necessary electric

charges will be paid by the contractor as per rates prevailing from time to time in the

respective DISCOM.

1. If there are any surplus quarters available after meeting the requirement of GSECL's staff,

then GSECL will consider allotment of quarters on rent as per GSECL's rule.

2. The contractor will have to make their own arrangement of water for construction

work as well as for their labourers at his own cost. If possible, water for construction

purpose only at one point as decided by EIC and recovery for water charges shall

be affected at the 2 % of the item of which water is used or by quantity measured by

meter reading of water meter installed by contractor, rate of water supply will be

charged at prevailing purchase rates of GSECL, for water supplied by GSECL is

used as certified by EIC. In case of agency is installing bore well and pumps at his

cost, after completion of work agency will hand over the bore well in good condition

with pumps to the GSECL.

5. DATA TO BE FURNISHED BY CONTRACTOR:

 The contractor shall submit to the Executive Engineer for approval within one week of the

date of contract, a layout plan of construction plant and equipment for the execution

of work which the contractor proposes to adopt at site.

 Prior to commencement of work, the contractor shall submit to the Executive Engineer

for approval, plans in triplicate showing the location of Major plant shop and storage

buildings, storage yards, offices, contractor's power house including its services and

housing facilities which he proposes to put up at site and also indicate the programme of

 The successful bidder on receipt of letter of intent will submit within a week's time his

planning/programme of works for scrutiny of GSECL in a PERT/Bar chart format, clearly

indicating GSECL inputs also.

 Contractor will plan his works such that on all the fronts released by GSECL,

simultaneous work should progress in such a way that entire job is completed in

scheduled time limit.

 No change in the approved layout shall be carried out without specific written approval of

the Executive Engineer.

6. ERRORS, OMISSIONS AND DISCREPANCIES:

In all cases of errors, omissions, doubts or discrepancies in the dimensions, or

discrepancies in the drawings and items of work in specification, reference shall be

made to the Executive Engineer whose elucidation and elaboration shall be considered

as authoritative. The contractor shall be held responsible for any error that may occur in

the work thorough lack of such reference and precautions.

7. SECURITY DEPOSIT:

EW- 341 PUR-F-006 RFQ-

SECURITY DEPOSIT: In tender process for L1 bidder (lowest bidder)

security deposit will be charged as per table below:

Category of the Unit Security Deposit

Works up to Rs. 5 Works More than Rs.

Lakh Lakh

Enterprise or Exempted 3% of Order Value

Organization which

are exempted from

paying Tender Fee &

For all other 5% of Order Value 5% of Order Value

Enterprises

bidder) is not willing to pay SD in advance, either EMD may be converted to SD or

SD may be deducted from 1st or subsequent invoices/RA bills with consent from the

bidder. However, PO/LOA should be placed before commencement of work, except

in some emergency cases where special approval must be obtained from the

Executive Director (Gen.) at Corporate Office.

After issue of Work order and Date of commencement, if successful bidder failed to start the

work then, RPAD notice will be issued to the successful bidder mentioning that on failing to

start the work within next 07 days from the date of issue of RPAD Notice the EMD will be

forfeited and he will not be allowed to participate in the tenders invited from Gandhinagar

TPS office for the period of One year.

The security deposit of the contract value shall be released on finalization of final bill /

successful completion of the work.

All damages, costs, charges, expenses and other sums which may be or may become

due or payable by the contractor to the Corporation under the terms of the contract, may

be deducted from the cash in the proceeds of sale of the securities/bank guarantee so

deposited (which the officer or person to whom the same may be endorsed as aforesaid

is hereby authorized to sell/to encase for that purpose) or from the interest of any such

securities or from any sums due or which may become due to the contractor by the

Corporation or from the whole or the balance unpaid as aforesaid of the encase

securities so deposited being repaid or transferred and returned as the case may be, to

the contractor on finalization of final bill OR after 06 (six) months of successful

completion of the work, whichever later OR on furnishing of the Performance Bond

amounting to 5% of contract value against the defect liability period as mentioned in this

document elsewhere.

If entire security deposit is paid in approved form of Bank Guarantee should be remain

valid during the contractual period and such bank Guarantee should not be reduced on

the basis of the work actually done.

8. USE OF LAND:

The land required for office, godowns and for labour camp if not available with GSECL,

then the contractor has to arrange the same at his cost. GSECL will give the land only if

the spare land is available with the following conditions.

The contractor shall be permitted to use for the bonafide purpose of execution of this

contract free of cost. The contractor shall be permitted to use for the bonafide purpose

of execution of this contract free of cost.

1. Site required for the construction of the work.

2. Required approach road. The contractor shall make their own arrangements for the

necessary approach, road, for transport of their materials and be responsible for the

compensation on account of damage to crop etc. and shall till completion of work.

3. He will be charged the rent at the annual rate of rupees one hundred per every acre

or part thereof, for the construction of temporary hutments and his store yard.

However area required for such purpose may be clearly indicated in this offer.

 All areas of operation, including those for his staff and labour colonies handed over to

the contractor shall be cleared and handed over back in good condition to the

EW- 341 PUR-F-006 RFQ-

Engineer except areas under works as per this contract or those for which specific

approval has been obtained from the Engineer. The contractor shall make good to the

satisfaction of the Engineer any damage or alternation made to areas which he has

to hand over back or to other property land handed over to him for purpose of this

Temporary structures may be erected by the contractor for storage sheds, offices,

residence etc. for noncommercial use on the land, handed over to him at his own

expense and with the permission of the Engineer. These structures shall comply with

the regulation that may be in force and/or specified by the Engineer with regard,

thereto. In any circumstances for constructing temporary structures for contractor's

use, GSECL's free supply materials shall not be used. If it is found that GSECL's free

supply materials are used for other than approved project drawings work, same will be

recovered at

penalized rate.

The contractor shall preserve all existing vegetation such as trees on or adjacent to the

sites which do not interfere with the construction as determined by the Engineer.

The contractors shall take all possible precautions in felling trees authorized for

removal to avoid any unnecessary damage to vegetation and trees not to be felled

and to structures under construction, or to workmen, and shall be responsible for any

damage if it occurs in such operations

 All produce from cutting of trees; grass etc. shall be the property of GSECL and shall

be stocked at the place specified by the Engineer. No claim shall be made for such

cutting and stacking of trees or grass etc. by the contractor

 The contractors shall not unnecessarily or for use as fuel, cut any trees brush wood,

grass or other vegetation nor shall set fire there to without the written permission of

the Engineer. When such permission is given, the contractor shall take necessary

measures to prevent damage or to prevent fire spreading to surrounding property, and

shall be responsible for any such damage, if cause.

 The land shall as herein before mentioned be handed back to Engineer in Charge

immediately after the completion of the work under this contract. Also no land shall

be held by the contractor longer than the Engineer shall deem necessary and the

contractor shall, on due notice by the Engineer, vacate and return the land which the

Engineer may certify as no longer required by the contractor for purpose of the work.

9. START OF WORK:

The contractor shall not enter upon or commence any portion of work except with the

written authority or instructions of the Executive Engineer or his subordinate in charge of

the work, failing such the contractor shall have no claim to ask for measurement or

payment for work and shall be responsible for any claims or damages that may arise

due to such unauthorized commencement or entry.

10. COMPENSATION FOR THE DELAY:

The time allowed for carrying out the work as entered in the tender shall be strictly

observed by the contractor and shall be reckoned from the date on which the order to

commence work is given to the contractor. The work shall throughout the stipulated

period of contract be proceeded with all due diligence (time being deemed to be the

essence of contract) and for delay, the contractor shall pay compensation, an amount

equal to ½ (half) percent per one week for the contract amount or part thereof, including

taxes & duties ( i.e. End cost of contract amount including taxes & duties) and maximum

up to 10 % of the order value, including taxes & duties ( i.e. End cost of contract amount

including taxes & duties) or such smaller amount as per the decision of the Competent

Authority of the GSECL The penalty will be invariably deducted from the bills of the

contractor and no refund will be given unless the competent authority approves the

reduction. The reasons for delay, attributable to GSECL as well as to party will be

brought out clearly while putting the proposal for waiver/reduction in penalty.

11. ACTION WHEN WHOLE OF SECURITY DEPOSIT IS FORFEITED:

In any case in which under any clause or clauses of this contract the contractor shall

have tendered himself to pay compensation amounting to the whole of his security

deposit (whether paid one sum) or in the case of abandonment for the work owing to

serious illness or death of the contractor or any other cause, the Executive Engineer on

behalf of the Corporation, shall have powers to adopt (a) below and any of the following

courses under (b) and (c) as he may deem best suited to the interest of the Corporation.

(a) To rescind the contract (for which rescission notice of 10 days) in writing to the

contractor under the hand of the Executive Engineer shall be conclusive evidence and in

EW- 341 PUR-F-006 RFQ-

that case the security deposit of the contractor shall stand forfeited and absolutely at the

disposal of the Corporation. To employ labour paid by the Corporation, to supply

materials, to carry out the works or any part of the work debiting the contractor with the

cost of the labour and the price of the materials (as to the correctness of which cost and

price, the certificate of the Executive Engineer shall be final and conclusive against the

contractor) and crediting him with value of the work done in all respects in the same

manner and at the same rates as if it had been carried out by the Contractor under the

terms of this contract and in that case the certificate of the Executive Engineer as to the

value of the work shall be final and conclusive against the contractor.

(b) To order that the work of the contractor be measured up and to take such part thereof,

as shall be unexecuted, out of his hands and to give it to another contractor to complete,

in which case, any expenses, which may be incurred in excess of the sum, which would

have been paid to the original contractor, if the whole work would have been executed

by him (as to the amount of which excess expenses, the certificate in writing of the

Engineer-in-charge shall be final, conclusive and shall be borne and shall be paid by the

original contractors and shall be deducted from any money due to him by the

Corporation under the contract or otherwise from his security deposit of his proceeds

sale thereof or a sufficient part thereof.

(c) In the event of the above courses being adopted by the Executive Engineer, the

contractor shall have no claim to compensation for any loss sustained by him by reason

of his having purchased or procured any materials or entered into any engagements or

made any advances on account of or with a view to the execution of the work or the

performance of the contract. And in case the contract shall be rescinded under the

provision aforesaid, the contractor shall not be entitled to recovery or be paid any sum

for any works thereof actually performed by him under this contract unless and until the

Executive Engineer shall have certified in writing the performance of such work and the

amount payable to him in respect thereof and he only be entitled to be paid the amount

so certified.

12. NOTICE UNDER UNSATISFACTORY PROGRESS:

If the progress of a particular portion of the work is unsatisfactory, and also if as per the

opinion/observation of the Executive Engineer (whose decision shall be final) in charge

that the general progress of work is not satisfactory, then Executive Engineer in charge

shall be entitled to take action under clause 11 (c) after giving the contractor ten days’

notice in writing and the contractor will have no claim for compensation for any loss

sustained by him owing to such action.

13. ACTION IN THE CASE OF DEFAULT BY THE CONTRACTOR :

In any case in which any of the powers conferred upon the Executive Engineer by

Clauses 11 and 12 hereof shall have exercisable and the same shall not have been

exercised, the non-exercised thereof shall not constitute a waiver of any of the

conditions hereof and such powers shall not withstanding be exercisable in any further

case of default by the contractor of which, by any clauses hereof, he is declared liable to

pay compensation amounting to the whole of his security deposit and liability of the

contractor for past and future compensation shall remain unaffected in the event of the

Executive Engineer taking action under sub-clause (a) or (c) of Clause 11, he may if he

so desires, take possession of all or any tools, plants, materials, and stores in so upon

the work or the site thereof belonging to the contractor, or procured by him and intended

to be used for the execution of the work of any part thereof paying for allowing for the

same in account at the contract rates, or in the case of a contract rates not being

applicable of current market rates to be certified by the Executive Engineer whose

certificate thereof shall be final. In the alternative, the Executive Engineer may by notice

in writing to contractor or his clerk of works, foreman or other authorized agent, require

him to remove such tools, plant, materials or stores from the premises within a time to

be specified in such requisition, the decision to the contractor failing to comply with any

such requisition, the decision of the Executive Engineer as to the expense of any such

removal and the amount of the proceed and expense of any such sale, be final and

conclusive against the contractor

14. EXTENSION OF TIME LIMIT

If the contractor shall desire an extension of the time limit for completion of the work on

the ground of his having been unavoidably hindered in its execution or on any other

ground, he shall apply in writing to the Executive Engineer and the Executive Engineer

may, if in his opinion there are reasonable grounds for granting extension, recommend

EW- 341 PUR-F-006 RFQ-

such extension as he may think necessary or proper. The decision of the competent

authority in this regard shall be final, and binding to the contractor. Any delay attributed

to Corporation, shall be thus compensated only by way of extending the limit.

15. COMPLETION CERTIFICATE

On completion of the work, the Contractor shall be furnished with Completion Certificate

by the Executive Engineer. No such certificate shall be given nor shall be the work

considered to be completed until works are taken over and/or duly tested and put to

operation as the case may be, nor until the work shall have been measured by the

Engineer-in-Charge or where the measurement have been taken by his subordinates

until they have received the approval of the Executive Engineer the said measurement

being binding and conclusive against the contractor.

16. EFFECT OF THE CERTIFICATE :

No payment shall be made for any work estimated to cost less than Rs.1,000 till after

the whole of said work shall have been completed and a certificate of completion given.

But in the case of works estimated to cost more than Rs.1,000, contractor shall on

submitting a monthly bill thereof, be entitled to receive payments. Proportionate to the

part of the work then approved and passed by the Engineer-in-Charge, whose certificate

of such approval and a passing of the sum so payable shall be final and conclusive

against the contract. All such intermediate payment shall be regarded as payment by

way of advance against the final payment only and not as payments for work actually

done or completed and shall not preclude the Engineer-in-charge from requiring bad,

unsound, imperfect or unskillful work to be removed and taken away and reconstructed

or re-erected nor shall any such payment be considered as admission of the due

performance of the contract or any part thereof in any respect of the occurring of the

claim nor shall conclude, determine or effect in any way the powers of the Engineer-in-

Charge as to the final settlement and adjustment of the accounts otherwise or in any

other way, vary or affect the contract. The final bill shall be submitted by the contractor

within one month of the date fixed for completion of work; otherwise the certificate of the

Engineer-in-charge of the measurement and of total amount payable for the work shall

Engineer-in-charge of the measurement and of total amount payable for the work shall

be final and binding on all parties.

17. PAYMENT TO CONTRACTORS :

The rates for several items of works estimated to cost more than Rs.1, 000 agreed to

within shall be valid only when the item concerned is accepted, having been completed

full, in accordance with the sanctioned specification. In case, where the items of the

work, are not accepted, as so completed, the Engineer-in-charge, may make payment

on account of such items at such reduced rates, as he may consider reasonable in the

preparation of final or running accounts bills and it will be binding to the contractor.

18. BILLS :

The Bill Shall be submitted by the contactor each month on or before the date fixed by

the Engineer-in-charge, for all works, executed in the previous month and the Engineer-

in-charge shall take or cause to be taken the requisite measurement for the purpose or

having the same verified and the claim so far as it is admissible, shall be adjusted, if

possible, within Fifteen days from the presentation of the bills. If the contractor does not

submit the bill, within the time fixed, as aforesaid, the Engineer-in-charge may depute a

subordinate to measure up the said work in the presence of the contractor or his duly

authorized agent, whose counter signature in the measurement shall be sufficient

warrant and the Engineer-in-charge may prepare a bill from such list which shall be

binding on the contractor in all respects. In case if contractor/ representative does not

remain present on specified date for taking measurement than EIC may take the

measurement one sided and the same shall be binding to the contractor irrespective

whether he has signed or not.

19. SUPPLY OF MATERIALS TO CONTRACTOR [APPLICABLE ONLY WHERE

MATERIAL IS TO BE SUPPLIED BY CORPORATION AS MENTIONED IN

SCHEDULE A ]

If the specification of the estimated work provides for use of any special description of

material to be supplied from the Corporation’s stores or if it is required that the

contractor shall use certain stores to be provided by the Engineer-in-charge, (such

material and stores and the prices to be charged thereof as hereinafter mentioned being

so far as practicable for the convenience of contractor but not so as in any way to

control, the meaning or effect of this contract specified in the schedule or memorandum

hereto annexed). The contractors shall be supplied with such materials and stores as

EW- 341 PUR-F-006 RFQ-

may be required from time to time be used by him for the purpose of the contract only

and the value of the full quantity of materials and stores so supplied shall be set off or

deducted from any sum due or thereafter to become due to the contractor, under the

contract or otherwise or from the security deposit or the proceeds of sale thereof if the

deposit is held in government securities the same or a sufficient portion thereof, shall be

sold for the purpose. All materials supplied to the contractor shall remain the absolute

property of the Corporation and shall on account be removed from the site of work and

shall at all times be open to inspection by the Engineer-in-charge. Any such materials

unused and in perfectly good condition at time of completion or determination of the

contract shall be returned to the Corporation’s store if the Engineer-in-charge so

requires by notice in writing given under his hand but the contractor shall not be entitled

to return any such materials except with such consent and he shall have no claim for

compensation on account of any such materials supplied to him as aforesaid but

remaining unused by him or for any wastage in or damaged thereto. The contractor

shall be responsible for the loss, destruction or deterioration of the materials, stores or

articles supplied to him by the Corporation even if such loss, destruction or deterioration

has occurred under any circumstances whatsoever beyond his control as if the

materials, stores or articles so supplied were his property.

20. WORKS TO BE EXECUTED IN ACCORDANCE WITH SPECIFICATIONS, DRAWING,

ORDERS ETC.

The contractor shall execute the whole and every part of work in the most substantial

and workman like manner and both as regarding materials and in every other respect in

strict accordance with the specification. The contractor shall also confirm exactly, fully

and faithfully to the designs, drawings and instructions in writing relating to the work

signed by the Engineer-in-charge and lodged in his office and to which the contractor

shall be entitled to have access for the purpose of inspection at such office, or on the

site of the work during office hours and the contractor shall, if he so requires, be entitled

at his own expense to make or cause to be made copies of the specification and of all

such designs, drawings and instructions as aforesaid.

21. ALTERATIONS IN SPECIFICATIONS AND DESIGNS NOT TO INVALIDATE

The Executive Engineer shall have powers to make any alterations, or additions to the

original specification, designs and instructions that may appear to him to be necessary

or advisable during the progress of the work and the contractor shall be bound to carry

out the work in accordance with any instruction in this connection which may be given to

him in writing, signed by the Engineer-in-charge and such alterations shall not invalidate

the contract. Any additional work which the contractor may be directed to do in the

manner above specified as part of the work shall be carried out by the contractor on

same conditions in all respect on which he agreed to do the main works and at the

same rates as are specified in the tender for the main work.

Where, however, the work is to be executed according to the designs, drawings and the

specifications recommended by the contractor and accepted by the competent authority,

the alteration above referred to shall be within the scope of such designs, drawings and

specifications appended to the tender.

22. RATES FOR WORKS NOT ENTERED IN ESTIMATE OR SCHEDULE OF RATE OF

THE CORPORATION

If the additional and altered work includes any class of work for which no rate is

specified in this contract, then such class of work shall be carried out at the rates

entered in the Schedule of Rates of the Corporation or at the rate mutually agreed upon

between the Executive Engineer and the Contractor, whichever are lower. If the

additional or altered work for which no rate is entered in the Schedule of Rates of the

Division is ordered to be carried out before the rates agreed upon then the contractor

within seven days of date of receipt by him of the order to carry out the work should

inform the Executive Engineer for the rate which it is his intention to charge for such

class of work and if the Executive Engineer does not agree to this rate, he shall be

noticed in writing, be at liberty to cancel his order to carry out such class of work and

arrange to carry it out in such manner as he may consider advisable provided always

that if the rates shall have been determined as lastly herein before mentioned then in

such case he shall only be entitled to be paid in respect of the work carried out or

expenditure incurred by him prior to the date of the determination of the rate as

EW- 341 PUR-F-006 RFQ-

aforesaid according to such rate or rates as shall be fixed by the Executive Engineer in

the event of disputes, the decision of the General Manager of the Corporation will be

23. EXTENSION OF TIME LIMIT IN CONSEQUENCE OF ADDITION OR ALTERATION

The time limit for the work shall be extended in the proportion that the increase in its

cost occasioned by alterations or additions bears to the cost of the original contract work

and the certificate of the Engineer-in-charge as to such proportions shall be conclusive.

24. NO COMPENSATION FOR ALTERATION IN OR RESTRICTION OF WORK TO BE

CARRIED OUT

If at any time, after the execution of the contract documents, the Engineer-in-charge

shall, for any reason whatsoever, requires the whole or any part of the work, as

specified in the tender, to be stopped for any period or shall not require the whole or

part of the work to be carried out at all or to be carried out by the contractor, he shall

give notice in writing of the fact to the contractor who shall thereupon suspend or stop

the work totally or partially as the case may be in any such case, except as provided

here under. The contractor shall have no claim to any payment or compensation

whatsoever on account of any loss in profit or advantage which he might have derived

from the execution, of the work in full but which he did not so derive in consequence of

the full amount of work not having been carried out or on account of any loss that he

may be put to on account of materials purchased or agree to be purchased or for

unemployment of labour recruited by him. He shall not also have any claim for

compensation by reason of any alterations having been made in the original

specification, drawings, designs and instructions which may involve any curtailment of

the work as originally contemplated. Where, however, materials have already been

purchased or agreed to be purchased by the contractor before receipt by him of said

notice, the Executive Engineer provided they are not in excess or requirement and are

of approved quality and/or shall be compensated for the loss, if any, that he may put to

in respect of materials agreed to be purchased by him. The amount of such

compensation to be determined by the Executive Engineer, whose decision shall be

final. If the contractor suffers any loss on account of his having to pay, his labour

charges during the period, during which the stoppage of work has been ordered under

this clause the contractor shall on application be entitled to such compensation on

account of labour charges as the Executive Engineer whose decision shall be final, may

consider reasonable provided that the contractor shall not be entitled to any

compensation on account of labour charges if, in the opinion of the Executive Engineer,

the labour could have been employed by the contractor elsewhere for the whole or part

of the period during which the stoppage of the work has been ordered as aforesaid.

25. NO CLAIM FOR COMPENSATION ON ACCOUNT OF LOSS DUE TO DELAY IN

SUPPLY OF MATERIALS BY CORPORATION

The contractor shall not be entitled to claim any compensation from Corporation for the

loss suffered by him on account of delay by Corporation in the supply of materials

entered in Schedule A where such delay is caused by:

 Difficulties relating to supply of railway wagons.

 Force Majeure

 Act of God

Any other reasonable cause beyond the control of Corporation, including shortage of

materials to be supplied by the Corporation and difficulties in time by reaching at the site

of any materials equipment.

In the case of such delay in the supply of materials, Corporation shall grant such

extension of time for the completion of the works as shall appear to the Executive

Engineer to be reasonable in accordance with the circumstances of the case. The

decision of the Executive Engineer as to the extension of time shall be accepted as final

by the contractor.

26. TIME LIMIT FOR COMPENSATION CLAIMS

Under no circumstances, whatsoever, shall the contractor be entitled to any

compensation from Corporation on any account unless the contractor has claimed in

writing to the Executive Engineer within one month of the cause thereof.

27. ACTION AND COMPENSATION PAYABLE IN CASE OF BAD WORK

If at any time, before the security deposit is refunded to the contractor, it shall appear to

the Executive Engineer or his subordinate in charge of the work that any work has been

executed with unsound, imperfect or unskillful workmanship or with materials of inferior

EW- 341 PUR-F-006 RFQ-

quality or that any materials or articles provided by him for the execution of the work are

unsound or of inferior quality to that contract for or are otherwise not in accordance with

the contract, it shall be lawful for Engineer-in-charge to intimate this fact in writing to the

contractor and then notwithstanding the fact that the work, materials, or articles

complained of, may have been inadvertently passed, certified and paid for, the

contractor shall be bound forthwith to rectify or remove and reconstruct the work so

specified in whole or any part, as the case may require or if so required shall remove the

materials or articles so specified and provided other suitable materials or articles at his

own charge and cost, and in the event of his failing to do so within a period to be

specified by the Engineer-in-charge in the written intimation aforesaid the contractor

shall be liable to pay compensation at the rate of one percent on the amount of the

estimate for every day not exceeding ten days during which the failure so continues and

in the event of any such failure as aforesaid, the Engineer-in-charge may rectify or

remove or re-execute the work or remove and replace the materials or articles

complained of, as the case may be, at the risk and expense in all respects of contractor

should the Engineer-in-charge consider that any such inferior work or materials as

described above may be accepted, or made use of, it shall be within his discretion to

accept the same as such reduced rates as he may fix thereof.

Provided that in the case of any work of which visible check is not possible if the

Engineer-in-charge or his subordinate in charge of the work feels that such work has

been executed with unsound, imperfect or unskillful workmanship or with materials of

inferior quality, he shall take sample tests at random, cost of which shall have to be

borne by the contractor and if after taking such test part of such work is found to be

defective in any respect or to have been executed with materials of inferior quality then

the contractor shall pay for the whole work such amount as may be fixed by the office of

the Engineer-in-charge on the basis of the lowest quality of work found by him in such

sample tests.

28. WORK TO BE OPENED TO INSPECTION, CONTRACTOR OR RESPONSIBLE

AGENT TO BE PRESENT.

All works under execution or in pursuance of the contract shall at all times be open to

the inspection and supervision of the Executive Engineer and his subordinate and

contractor shall at all times, during the usual working hours and at all other times at

which reasonable

notice of the intention of the Executive Engineer or his subordinate to visit the works

shall have been given to the contractor, during which period either he should be present

to receive order and instruction, or have a responsible agent duly authorized agent shall

be considered to have the same force and effect as if they had been given to the

contractor himself.

29. NOTICE TO BE GIVEN BEFORE WORK IS COVERED UP

The contractor shall give not less than five days’ notice in writing to the Executive

Engineer or his subordinate in charge of the work, before covering up or otherwise

placing beyond the reach of measurement of any work, in order that the same may be

measured and correct dimensions thereof, taken before the same is so covered up or

placed beyond the reach of measurement and shall not be covered up or placed beyond

the reach of measurement and work without the consent in writing of Executive

Engineer or his Subordinate in charge of work. If any work shall be covered up or placed

beyond the reach without such notice having been given or consent obtained, the same

shall be uncovered at the contractor’s expense and in default thereof no payment or

allowance shall be made for such work or for the materials with which the same was

30. CONTRACTOR’S LIABILITIES

The contractor shall supply, at his own cost, all materials (except such special materials,

if any as may be supplied from the Corporation stored in accordance with the contract).

Plant, tools, appliances, implements, ladders, cordage, tackle, scaffolding and any

temporary works which may be required for the proper execution of the work, in the

original, altered or substituted form and whether included in the specification and other

document forming part of the contract or referred to in these conditions or not and which

may be necessary for the purpose of satisfying and complying with the requirements of

the Engineer-in-charge as to any matter on which under these conditions, he is entitled

to be satisfied or which he is entitled to require together with carriage thereof to and

EW- 341 PUR-F-006 RFQ-

from the work. The contractor shall also supply without any charge the requisite number

of persons of setting out works and counting, weighting and assisting in the

measurement of examination at the time and from time to time of the work or materials,

failing this the same may be provided by the Engineer-in-charge at the expenses of the

contractor and the expenses may be deducted from any money due to the contractor

under the contract or from his security deposit or the proceeds of sale thereof or of a

sufficient portion thereof, the contractor shall provide all necessary fencing and light

required to protect the public from accident and shall also be bound to bear expenses of

defense of every suit, action or other legal proceedings of law that may be brought by

any person for injury sustained. Owing to neglecting of the above precautions and to

pay any damage and cost which may be awarded in such suit, action or proceedings to

any such person or which may with the consent of the contractor be paid in comprising

any claim by any such person.

31. CONTRACTOR LIABLE FOR ALL DAMAGE

Compensation for all damage done intentionally or unintentionally by contractor’s

laborer, whether in or beyond the limit of Corporation’s property, shall be estimated by the

Executive Engineer or such other office as he may appoint and the estimates of the

Executive Engineer, subject to the decision of the Superintending Engineer, on appeal,

shall be final and the contractor shall be bound to pay the amount of the assessed

compensation demand, failing which, the same will be recovered from the contractor as

damages or deducted by the Engineer-in-charge from any sums that may be due to or

become due from Corporation to the contractor under this contract or otherwise.

The contactor shall bear the expenses of defending any action or other legal proceeding

that may be brought by any person for injury sustained by him owing to negligence of

precautions for prevent the spread of fire and he shall also pay any damage and cost

that may be awarded by the court, if in consequence

32. RESCISSION OF CONTRACT AND FORFEITURE OF DEPOSIT

The contractor shall not assign or sublet, without the written approval of the Engineer-in-

charge and if the contractor assign, or sublet his contract, or attempt to do so or become

insolvent or commence any proceedings to be adjudicated as insolvent or make any

composition with creditors, attempt to do so, the Engineer-in-charge may, by notice in

writing rescind the contract. Also, if any bribe, gratuity, gift, loan, perquisite, reward or

advantage pecuniary or otherwise shall either directly or indirectly be given, promised or

offered by the contractor or any of his servants, or agents, or any person to the employee

of the Corporation in any way relating to his office or indirectly interested in the contract,

the Executive Engineer may, by ten days’ notice in writing, rescind the contract. In the

event of a contract being rescinded the security deposit of the contractor shall there upon

stand forfeited and be absolutely at the disposal of the Corporation and the same

consequences shall ensure as if the contract has been rescinded under Clause

thereof and in addition the contractor shall not be entitled to recover or be paid for any

work thereof actually performed under the contract.

33. COMPENSATION

All sums payable by a contractor by way of compensation under any of these conditions

shall be considered as a reasonable compensation to be applied to the use of

Corporation without reference to the actual loss or damage sustained and whether any

damage has not been sustained.

34. CHANGE IN THE CONSTITUTION OF FIRM TO BE NOTIFIED

In case of tender by partners of a Firm, any change in constitution of firm shall be

forthwith notified by the contractor to the Executive Engineer for his information.

35. WORKS UNDER DIRECTION OF SUPERINTENDING ENGINEER

All works to be executed under the contract shall be executed under the direction and

subject to the approval of Superintending Engineer /Engineer-in-charge for the time being

who shall be entitled to direct at what point or points and in what manner they are to be

commenced and from time to time to be carried on.

36. DECISION OF SUPERINTENDING ENGINEER TO BE FINAL

Except where otherwise specified in contract and subject to the power delegated to him

by Corporation under the Corporation’s rules, then in force, the decision of the

Superintending Engineer/EIC for the time being shall be final, conclusive and binding on

all the specifications, designs, drawings and instructions herein before mentioned and as

to the quality of workmanship or material used on or as to any other question, claim, right

matter or thing whatsoever in any way arising out of or relating to the contract, designs,

EW- 341 PUR-F-006 RFQ-

drawings, specifications, estimates, instructions, orders or these conditions or otherwise

concerning, the works or the execution or failure to execute the same, whether arising

during the progress of the work or after the completion or abandonment thereof.

37. Dispute Resolution Mechanism: For works contracts and composite Contracts, the

arbitration mechanism shall be governed by the Gujarat Public Works Contracts

Disputes Arbitration Tribunal Act, 1992 as per below details.

sub clause 37(1) Amicable Settlement : Any dispute, difference, controversy or claim

between the Parties arising out of or relating to this contract with reference to the

construction, interpretation, breach, termination or validity thereof (hereinafter referred

as "the Dispute") shall, upon the written request of either Party be referred to the

authorized representatives of the Disputing Parties for resolution. The authorized

representatives shall promptly meet and attempt to negotiate in good faith a resolution

of the Dispute within thirty days of the service of the request.

sub clause 37(2) Arbitration : If the Parties fail to amicably resolve the disputes or

differences or contrary claims as indicated herewith in sub clause (1) of Clause

arising under or in connection with the present works contracts, whether pertaining to

works contracts alone or works and procurement both, the same shall be referred to

arbitration under the Gujarat Public Works Contracts Disputes Arbitration Tribunal Act,

38. STORES TO BE OBTAINED FROM CORPORATION [APPLICABLE ONLY WHERE

MATERIAL IS TO BE SUPPLIED BY CORPORATION AS MENTIONED IN

SCHEDULE A]

The contractor shall obtain from the Corporation stores, such articles as are mentioned

in schedule “A” which may be required for the work or any part of the work or in making

up any articles required therefore or in connection therewith, unless he has obtained

permission in writing from the Executive Engineer or obtained such stores and articles

from elsewhere. The value of such stores and articles as may be supplied to the

contractor by the Engineer-in-charge will be debited to the contractor in his account at

the rate shown in the schedule “A” attached to the contract and if they are not entered in

said Schedule, they shall be debited to him at cost price which for the purpose of this

contract shall include cost of carriage and all other expenses whatsoever which may

have to be incurred in obtaining delivery of the same at the stores aforesaid and further

overhead charges 15%.

The Contractor shall be responsible for the loss, destruction or deterioration of the

materials, stores or articles supplied to him by the Corporation, even if such loss,

destruction or deterioration has occurred under any circumstances whatsoever beyond

his control as if the materials, stores or articles so supplied were his property. The

contractor shall be responsible for returning the residual materials after completion of

the contract and it fails to return, the balance materials supplied to him by the

Corporation, the cost of the residual materials will be recovered from the contractor at

the market rate or stock issue rate whichever be higher at the time of materials account

39. LUMP SUMS IN ESTIMATE

When the estimate on which tender is made, includes lump sums in respect of parts of

the works the contractor shall be entitled to payment in respect of the items of works

involved or the part of the work in question at the same rates as are payable under this

contract or such items or if the part of work in question is not in the opinion of the

Engineer-in-charge capable of measurement the Engineer-in-charge may at his

discretion pay the lump sum amount entered in the estimate and the certificate in writing

of the Engineer shall be final and conclusive against the contractor with regard to any

sum or sums payable to him under the provision of this clause.

40. LUMP SUM TENDERS

Whenever lump sum tenders have been invited for buildings or other structures of the

same type, design, the contractor shall submit his bill stated in Clause No. 18 and the

Engineer-in-charge not below the rank of work, Executive Engineer shall certify by

general measurement or by other method considered suitable to him, the value of work

done and the contractor shall be paid monthly a sum equal to 90% of the total value the

work so certified, since the last payment, after deducting a part or whole of the secured

advance if not already paid for the materials utilized on the works. An additional secured

EW- 341 PUR-F-006 RFQ-

advance for any fresh materials utilized on the works. An additional secured advance for

any fresh materials brought on site will also be paid if certified by the officer not below

the rank of Executive Engineer. After the work is completed final bill would be paid on

the certification of officer not below the rank of Executive Engineer, that the work, is

done according to drawing and specifications attached to the tender. If any additions

and alterations have been carried out, detailed measurement in respect thereof shall be

recorded and extra payment or deductions are regulated as per item rates quoted by the

contractor while submitting the tender and if there are any items in the additions and

alterations for which the contractor has not quoted a rate, the payment shall be as per

Clause 39 above

41. ACTION WHERE NO SPECIFICATION

In the case of any class of work for which there is no such specification as is mentioned,

such work shall be carried out in accordance with the PWD and in the event of there

being no PWD specification, the work shall be carried out in all respects in accordance

with the instructions and requirements of the Engineer-in-charge of the Corporation etc.

42. NO CLAIM FOR VARIATION IN QUANTITIES OR WORK

Quantities shown in the tender are approximate and no claim shall be entertained for

quantities of work actually executed, being either more or less up to any extent than

those entered in the tender or less than those entered in the tender or estimate.

43. NO CLAIM FOR COMPENSATION FOR DELAY IN STARTING WORK

No compensation shall be allowed for any delay caused into starting of work on account

of acquisition of land and in the case of clearance for works or any delay in according

sanction to estimates.

44. NO CLAIM FOR COMPENSATION FOR DELAY IN EXECUTION OF WORK

No compensation shall be allowed for any delays in execution of the work on account of

water standing in borrow pits or compartment. The rates are inclusive for hard or

cracked soil, excavation in mud, sub-soil water or water standing in borrow pits and no

claim for any extra rate shall be entertained unless otherwise expressly specified and

mentioned in the tender.

45. EMPLOYMENT OF TECHNICAL PERSONS:

The contractor shall keep one full time qualified Civil Engineer at the site, who shall be

fully authorized to receive and comply with such instructions, as given by the Executive

Engineer. The contractor shall intimate the name of such Engineer with his qualifications

and experience. The Executive Engineer shall have the right to demand the removal of

any technical personnel, skilled or unskilled workmen, who in his opinion are considered

to cause bad workmanship in the execution of works or to cause indiscipline.

46. T erm s and C ondition s re g ardin g L abour L aw s

During the entire period of the contract, the Contractor and his Sub-Contractors shall at all

times comply with all applicable labour laws, rules, regulations, notifications, and bye-laws

issued by the Central Government, State Government, or Local Authorities. This includes all

existing laws as well as any amendments or new notifications that may come into force

during the contract period.

The Contractor and his Sub-Contractors shall, at all times abide by the following

Acts/Statutes related to Human Resources:

1. Factories Act, 1948;

2. Contract Labour (Regulation & Abolition) Act, 1970;

3. EPF & MP Act, 1952;

4. Building & Other Construction Workers (Regulation of Employment & Conditions of

Service) Act, 1996;

5. ESI Act, 1948;

6. Minimum Wages Act, 1948;

7. Payment of Wages Act, 1936;

8. Payment of Bonus Act, 1965;

9. Payment of Gratuity Act, 1972;

10. Workmen’s Compensation Act, 1923;

11. ID Act, 1947;

12. Maternity Benefit Act, 1961;

13. Inter-State Migrant Workmen (Regulation of Employment & Conditions of Service) Act,

14. The Building And Other Construction Workers' Welfare Cess Act,

EW- 341 PUR-F-006 RFQ-

17. The Carriage by Road Act,

The above list is only indicative and not exhaustive. The Contractor shall remain fully

responsible for ensuring compliance with all other applicable labour and welfare

legislations, rules, and regulations in force during the contract.

The following are some of the major responsibilities of the contractor, in addition to other

obligations prescribed under various labour laws, rules, and regulations issued by statutory

authorities such as the State Government or Government of India from time to time, which

the contractor shall strictly comply with during the execution of the contract.

1) T he F a c torie s A c t,

T he contractor s hould not deploy worker below the age of 18 year s and above

60 year s for the awarded work.

E arn L eave s hall be paid to their bonafide contract workers a s per the

provi s ions of the F actorie s Act,

Payment of Earned Leave should be made monthly together with wages for better

compliance of law. The contractor s hall maintain E arn L eave R egi s ter in F orm No.

19 a s per the provis ions of the s aid Act and s ubmit the s ame on demand.

All the written regi ster s , Performa etc. shall be maintained up to date and kept

ready for ins pection at any time or submitted on-time to the concerned

authorities a s per applicability of the Acts by contractor.

2) T he C ontra c t L abour ( R eg ulation and Abolition) A c t,

T he C ontractor / Agency s hall have to obtain the L abour L icen s e under

C ontract L abour (R egulation & Abolition) Act from the appropriate

authorities before commencement of work. T he contractor shall maintain a valid

labour licens e under the C ontract L abour (Regulation and Abolition) Act for

employing nece ss ary man power to be required by contractor.

T he contractor should not be allowed to engage fifty (50) or more contract

labourers without initiating to obtain the labour licens e under the C ontract Labour

Act. (the s aid number i.e., fifty (50) or more includes S upervi s or and other

3) Minimum Wa g e s A c t,

Contractor shall have to make the payment of wages to the Contract Labours engaged by

them, on or before 7th of every month through nearest Nationalized Bank compulsory,

preferably situated in the premises of TPS area in case of all works contract. The

Contractor shall supply copy of Bank Statement duly stamped by the Concerned Bank as

well as debited entry of amount displayed in the contractors’ own bank account as token of

proof towards payment of Wages through CLIM/prevailing system at relevant time. Apart

from Payment of wages through Bank, Contractors shall have to make all other payments

like Advances, Bonus, Leave Encashment etc. to their labours through bank only and cash

payment/entry will not be allowed.

Wages rates for contract laborers are applicable as per the terms and conditions of the

license. The contractor shall have to pay wages to workers as notified by the Government

of Gujarat from time to time.

EW- 341 PUR-F-006 RFQ-

Any default to pay the minimum wages to the engaged workers and deprived of their right

to minimum wages payment on or before 7th of each month shall be dealt as per the

provision of labour laws. Recurrence of the same may lead to cancellation of awarded

4) T he Provident F und and Mi sc ellaneou s P rovi s ion s A c t,

T he contractor mus t po ss e ss separate P . F . code on the name of the F irm /

Agency / Company its elf for the subject work.

It s hould be ens ured that all the contract labours engaged by contractor are

covered under the provident fund s cheme and employee’s pens ion scheme

and their contribution mu s t be remitted regularly to the concerned R P F C . T he

photocopies of challan along with E C R in thi s regards should be submitted

regularly to the Us er Department to enable their onward billing clearance.

T he contractor s hall submit along with hi s bill (month wi se) statement

regarding deductions agains t employees’ provident fund and family

pension s cheme in res pect of each concerned employee. Provident fund and

family pens ion s cheme at the rate of 12 % of wage s (or at the rate s made

applicable by the Government time to time). T he contractor’s contribution

and hi s workers contribution towards provident fund and family pension

scheme s hall deposited by the contractor with concerned PF Authorities.

5) Wo r km en ’ s C omp en sation & E m p l o y e r ’ s L i a b i l i t y Ins ur anc e .

T he contractors s hall have to obtain E mployee C ompens ation P olicy under

the E mployee s C ompens ation Act before starting the work. E mployee

C ompens ation Ins urance shall be obtained for all the workers engaged for the

execution of awarded contract. If any of the work i s sub-letted, the contractor

shall ens ure that the sub-contractor take and provide workmen's compensation

and E mployer' s liability insurance for the labours engaged. C ontractor i s liable to

pay compens ation in ca s e of accidental injury aris ing out of and in the cours e

of employment a s per the s aid Act and s hall bear medical expen s es due to on

duty accident.

6) T he Payment of Gratuity A c t,

For better compliance, contractor shall pay amount of gratuity on a monthly basis along

with the payment of wages, calculated on a pro-rata basis per month, which is equivalent

to 15 days’ wages for each completed year of service for every worker. (* applicable

to A R C / B R C work s c ontra c t only)

7) T he Payment of B onu s A c t,

E very worker s hall be entitled to be paid by the contractor in an accounting year,

bonus, in accordance with the provis ions of thi s Act, F or better com pliance, the

contractor should pay bonus amount on a m onthly basis along with wages

calculated on a pro-rata basis per month. C ontractor ha s to submit the paid bonus

details of it s worker in F orm No. C a s per the provis ions of the s aid Act a s and

when required by the G ovt. Authority a s well a s by G S E C L .

8) T he Maternity Benefit A c t,

Contractor shall ens ure that entitled female worker should provide

Maternity L eave and other benefits a s per the provision of the s aid Act.

EW- 341 PUR-F-006 RFQ-

9) T he B uildin g and other C on s tru c tion Workers’ A c t,

F or any construction work, fall under the definition of S ection 2(1)(d),

happening outside / inside the F actory premis e s the s aid act will be

applicable and the contractor or it s sub-contractor s hall be liable to comply with

the provis ions framed there under.

10) The contractor shall give preference to existing or local contract workers for

engagement in the awarded contract and shall issue appointment orders to

each and every workers individually at the time of their engagement during the

period of contract and terminate the same at the end of the each contract.

Follow the mentioned proc edure at eac h milestone for the ex ec ution of

work s c ontrac t.

11) On C ommenc ement of C ontrac tual Work

1. Before starting the work, the contractor may contact L abour Welfare

Officer / Industrial R elations Officer for all formalities related to labour law

compliance before commencement of the contract and onward Labour

L aw compliance thereof, s o that later no dispute will aris e in res pect of

compliance of labour laws .

2. It i s the res ponsibility of the contractor to ens ure that contractor’s

employees maintain strict dis cipline a s regards security, methods of s afe

working etc, and not to caus e any hindrance to smooth running of power

station or in execution of duties by G S E C L staff. Any laps e in this regard will

be viewed s erious ly and if laps e found, contract i s liable to be terminated. If

any of contractor’s staff i s found unsuitable or not behaving properly,

the contractor s hall have to remove s uch worker from the work-s ite on

demand by EIC. To maintain harmonious industrial relations amongs t

contract labours i s s olely the res ponsibility of contractor. Any breach of the

s ame will be viewed s erious ly.

3. A digital system developed at the request of the agencies working at the

premises of GSECL, is to facilitate them for easy, efficient, effective

management of data, gate passes, attendances, medical records, Police

Verification documents etc related to their employees / workers deployed for

various works and services against work order of GSECL.

4. On receipt of LOA and before commencement of work, authorized

representatives of the agency shall login in the CLIMS online portal /

prevailing system at relevant time and apply for registration of their

employees / workers uploading all information with required documents in

digital form. Upon completion of due verifications, clearance by EIC and HR

departments, contracting agency will obtain gate passes. GSECL will only

consider documents like wage sheet duly accepted and signed by individual

workers, as per the engagement/deployment duration/hours of individual

worker duly certified by the agency, being the employer, for the purpose of

payment of bills and HR clearances.

Agency shall be solely responsible for maintaining accurate and up-to-date

data of their workers in the portal/ prevailing system at relevant time. All

statutory compliances under prevailing laws shall remain the responsibility of

the contracting agency. The agency shall indemnify GSECL against any

liabilities arising from non-compliance of legal provisions or inaccuracies in

EW- 341 PUR-F-006 RFQ-

the data maintained by them in the digital portal of CLIMS/prevailing system

at relevant time.

5. T he C ontractor who intends to engage labours more than the specified limit

under law, then nece ss ary - F orm No. V under the C ontract Labour ( R & A)

Act, 1970 or F orm No. VI under the Interstate Migrant worker (employment

regulation) Act 1979 a s applicable i s to be obtained for the purpos e of

obtaining L abour L icens e from the L icens ing Authority.

6. It s hall be the duty of the C ontractor or hi s S upervis or to ens ure Bio-Metric

punching and reporting at the location of work.

7. T he contractor shall employ adequate number of experienced staff at s ite

for daily s upervis ion and for maintaining of various regis ter s and records

required under the L abour law s and contracts. No payment for s uch

s upervision s hall be admissible.

8. T he gate pa ss e s obtained for any specific work order will be valid for that

specific work order only and contractor s hould not divert the man power for

any other work order. If any work or part thereof i s desired/required

to sublet, the contractor s hall obtain the necess ary permiss ion of EIC in

black and white well in advance which i s mandatory for considering the

statutory documents of agency other than the agency who awarded work

12) During C ontra c tual Work under the pro g re ss:

1. All C ontractor s s hall have to make the payment of wage s to the C ontract

L abour s engaged by them, on or before 7th of every month through

Nearest Nationalized B ank compulsory, preferably situated in the

premis e s of p o w e r s t a t i o n area. T he C ontractor s hall s upply

copy of B ank S tatement duly stamped by the Concerned B ank a s a

token of proof towards payment of Wages through CLIMS / prevailing system at

relevant time.

2. All C ontractor s ha s to comply & maintain statutory documents / regi s ter s under

the provision of labour law s & E P F Act.

3. In cas e the contractor having more than one contract in the s ame T P S , the

contractor shall have to obtain work order wis e separate G ate P a ss e s

and s ubmit the s ame with the documents of statutory compliance that too work

order wi s e every month to the Us er Department to enable their onward billing

clearance.

(13) CONTRACTOR TO INDEMNIFY THE GSECL REGARDING

LABOUR LAWS

T he contractor shall indemnify and keep indemnified the G S E C L , and every

member, officer and employees of the G S E C L , al s o Engineer-in-charge and hi s

staff agains t all actions, proceedings, claims , demands, co s t s and expens e s

whatsoever arising out of or in connection with the matter referred in above claus e s

and elsewhere and against all actions , claims demands, cos t and expens e s which

may be made again st the G S E C L by any workman/ employee s of contractor or any

s ub - contractor and or from any liability any wis e to any workman/employees of the

contractor or sub-contractor under any laws , rules or regulation having in force of law

including but not limited to claims against the owner under employee compens ation

Act, 1923. T he E mployee’s Provident F und Act.1952, and/or the contract labour

(Abolition and R egulation) Act,

EW- 341 PUR-F-006 RFQ-

T he G S E C L s hall not be liable for or in res pect of or in consequence of any accident

or injury to any workmen or other pers on in the employment of the contractor or hi s sub-

contractor, and the contractor s hall indemnify and keep indemnified the G S E C L

agains t all s uch damage and compensation and against all claims, demands

proceedings co s ts , charges and expens e s whatsoever in res pect of or in relation thereto.

T he contractor shall at hi s own expens e / ris k and cos t to comply with all the labour law s

a s above- m e n t i o n e d and keep the G . S . E . C . L . indemnified in res pect thereof.

G S E C L : shall be entitled / empowered to deduct directly from the bills, the amount to be

paid to engaged bonafide contract worker s or the contract workers engaged by Sub-

contractor; any s um or s um s payable by main contractor / sub-contractor and which

s um /s um s the Corporation i s required to pay in capacity of Principal Employer on

account of the default

of contractor in res pect of all liabilities incurred out of non-compliance regarding any

provi sions of L abour L aw s and s ame amount s hall be recovered from the pending

due s of the contractor with 15 % administrative charges .

Any other rules and regulation, conditions, circulars etc., that are in force at pres ent and

that may be framed by the G S E C L from time to time in connection with contracts will

be binding and acceptable to contractor.

T he above are s ome of the major liabilities of the contractor in addition to other liabilities

pres cribed under the various labour law s in force from time to time from S tatutory

Authorities like S tate Government / Government of India, which the contractor s hall have

to comply with.

The contractor shall provide the name of authorized representative, as provided to other

statutory Government authorities and will be notified to Engineer In-Charge time to time.

14) Submission of Statutory documents to ensure the compliances:

The contractor shall upload statutory documents, work order-wise, under Labour Laws and EPF

in CLIMS / prevailing system at relevant time.

Required documents shall be u p l o a d e d by the contractor in existing portal /prevailing

system at relevant time invariably each month to Engineer In-Charge for onward process

and smooth clearance by HR Department.

List of documents required for gatepasses of contract w orkers

through clims /prevailing system

Sr. No. Description of documents attached

Copy of Work Order

2 Copy of P. F. Code No.

Insurance Policy as per subject of work order under the Workmen Compensation

4 Contract agreements/ subletting work contract documents with approval copy

Copy of Id proof of Aadhar card or Election voting card or driving license or Passport

6 Copy of Police Verification in respect of each contract workers

15. The contractor whose work order value is above Rs. 5 lacs shall have to submit

“Declaration cum Indemnity Bond” on Rs. 300/- Non-Judicial stamp paper in prescribed

Performa (Annexure- “B”) with Agreement and Indemnity Bond before the commencement of

the contract.

EW- 341 PUR-F-006 RFQ-

Annexure- “ B ”

D EC L A R A T I O N C U M IND E MNI TY B OND

(On Rs.300/ - Non J udi c ial S tamp P aper duly notaris ed)

T HI S D ECL A R A T IO N C UM IND E MNI TY B OND made at ------------------------- (mention

loc ation) by M/S. ------------------------- having its R eg. office at-------------------------------------

-----------------(hereinafter referred to a s “ C ontrac tor” which expre ssion shall unle ss

it be repugnant to the context or meaning thereof, be deemed to mean and include their

respective a ss ign s , successors , executors, subcontractors and / or adminis trators) of the

ON E P A R T in favour of

M/S G ujarat S tate E lec tri c ity C orporation L imited having its power S tation at

… … … … … . . T h e r m a l Power Station (hereinafter referred to a s the “ C ompany” ),

which express ion s hall unle ss it be repugnant to the context or meaning thereof be

deemed to mean and include it s a ss ign s , s ucce ss or s ) of the O T H ER P A R T .

W H E R E A S the C O M P A N Y ha s entered into a contract with the Contractor for the work of”-

-----------------------------------------------------------‘’ under order No: ------------------------- dated--------

-----------------“hereinafter called the “Contract”);

AND W H E R E A S it i s one of the ess ential conditions of the Contract that the Contractor

s hall comply with all the provis ions of the L abour & Industrial L aw s , a s may be

applicable from time to time for the discharge and completion of the works and

completion of the Works and S ervice s covered under s aid Contract L abour ( R & A) Act

1970,C hild L abour (Prohibition and Regulation) Act 1986, The E mployee s Provident

F und s & Mis cellaneous Provi s ion s Act,1952,Employees S tate Insurance Act

Minimum Wages Act,1948,Payment of B onu s Act,1965,Payment of Wages Act,1936,

E mployee s C ompens ation Act.1923, F actories Act,1948 and other Labour L aw s , R ule s

Notifications and C ode s which are at pres ent applicable to the contractor and which may

be applicable during the tenure of the contract (hereinafter referred a s the ‘L aw s ’).

AND W H E RE A S the Contractor ha s agreed to execute thi s Declaration cum Indemnity

B ond to thi s effect and ha s agreed to indemnify and C ompany, it’s Directors, Officers and

employees and repres entatives indemnified and hold harmless against all third party

claims, charges ,penalties, fines , expens e s ,lo ss e s , damages co s ts , s uits or any other

levy agains t the Company and/or the management due to the failure of the C ontractor

to obs erve or follow all applicable law s.

NOW T HI S D EE D WI T N E SS E T H A S UND ER

1. T he C ontractor hereby declares that all acts , deeds, actions, activities, conduct and laps e,

delays, mi s deeds , faults, breaches, inactions etc done by hi s a ss ign s , s ucce ss or s

executors, subcontractor and / or adminis trator s shall be construed to be have been

done by the contractor and he alone s hall be liable for s uch acts, inactions etc.

2. In consideration of the C ompany awarding the C ontract to the C ontractor subject

to the condition of execution of thi s Declaration cum Indemnity bond, the Contractor

EW- 341 PUR-F-006 RFQ-

declares and repres ents to the C ompany that the Contractor ha s obtained all

Statutory regis trations, Certificate s , licen s es and approvals required under the

L aw s enabling the Contractor to execute the Contract in a legal and lawful

3. That in the event of any liability arising out of non-compliance of any ‘Laws’ of the land by the

Contractor in connection with the Performance of the contract, the Contractor shall bear

all the resultant liability (ies) whatsoever, if any and that the company , its Directors, Officers and

employees, representatives, shall not be liable for any such liability(ies). The Contractor undertakes

to indemnify and keep the C ompany and it s Directors, Officers and employees,

representatives indemnifies, defend and hold harmle ss , agains t all lo ss e s , cos ts

damage s, claims, penalties, interest, expens e s , demands, fines , legal liability,

cau s e s of action, injury to per s ons , s uit s etc., which may be suffered, incurred,

undergone and / s us tained by the C ompany including the C o s t s and expens e s that

may be incurred in defending any s uch liability(ies) claim(S), Proceeding ( S )

etc. that maybe made or taken or taken or aris e on the s ame by any

P er s on, body, authority, government, judicial / quas i - judicial authority due to

the failure or non-compliance of any s uch laws and rules there

under (including any amendments in acts , law s, s tatute s & rules there under) of

whatsoever kind and nature aris ing out of or in any way connected with,

whether or not s uch acts or omi ss ion s are actual or alleged, active or pass ive

with regard to the discharge of the s aid Contract.

4. T he Contractor further declares that in cas e of any s uit / claim / right /

damage s / compens ation / fine / levy / charges / expens es / lo ss e s / penalties /

co s t s rais ed by the third party, including contract labour s engaged by the

contractor, he s hall join s uch proceedings in s uch Suit/Court/Tribunal/Authority and

effectively defend the same.

5. T he Contractor hereby agree and undertakes to make good any lo ss

damage, claims, s uits , demands , decrees, expen s es that the C ompany may

suffer to the fulles t satisfaction of the C ompany and if the Contractor fails to

make good the s ame then the C ompany s hall have the right to recover the

s ame from and or any other lo ss s ustained, without any restriction or

limitation, together with any other incidental expens es , co s ts , and all incidental logistic

expens es etc that may be suffered by the Company from the Contractor and the

Contractor hereby further confirms and declares that thi s Declaration cum

Indemnity B ond i s irrevocable and s hall be final and binding on him, his heirs,

executors, adminis trator s, legal representatives, s ucce ss or s , subcontractors and

a ss ign s , wherever the context applies . any claims, demands, shall be adjusted

agains t any amount due and payable to the Contractor and the C ompany

s hall have the right to withhold any amounts due and payable to the

Contractor, till the settlement of s uch claim s, di s putes to the C ontractor towards

dis charge of s uch claim s, obligations etc.

6. T hi s Declaration cum indemnity bond s hall be in accordance with the laws of India

and any dis pute between the parties with regard to thi s Declaration cum Indemnity

B ond s hall be resolved through the dispute resolution proce ss mentioned in the

General C onditions of the Contract ( G CC ).

EW- 341 PUR-F-006 RFQ-

IN W I T N E S S W H ERE O F , the s aid C ontractor ha s hereunto s et their hand the day and

year firs t hereinabove written.

S I G N E D S E A L E D AND D E L I V E RE D B y the within named “C ON TR A CT O R”

(Authorized Signatory)

R ubber S tamp of Firm/C ompany

Full Name:

Designation:

In pres en c e of Witne ss

Name & Addre ss of Witne ss S i g nature

1. Full Name :

Residential Address:

Contact No. :

2. Full Name :

Residential Address:

Contact No

On Non-Judicial Stamp Paper of Rs.

To be submitted with NOTORIZED at the time of final bill

UNDERTAKING FOR LABOUR LAW COMPLIANCES

I, Proprietor / Owner / Partner / Authorized Agent of

M/s. do hereby declare and undertake as under

1. That in capacity of independent contractor for M/s.

(Sub-Contractor of M/s. ) worked as

Contractor at GSECL, GTPS Thermal Power Station for the nature of work of

against Work Order

No. Dt. ., I have

complied with the provisions of all laws as applicable. I have paid the wages for the month/s

EW- 341 PUR-F-006 RFQ-

of my contractual period which is/are not less than the minimum rates as applicable, to all my

employee/s and no other dues are payable to my employee/s.

2. That I have covered all the eligible employee/s under the Employees’ Provident Funds and

Miscellaneous Provisions Act, 1952 and deposited the contributions under my P.F. Code No.

Place: for the month/s of my contractual

period and as such no amount towards contributions whatever is payable.

3. I further declare and undertake that in case any liability pertaining to any of my worker,

labour, employee/s is/are to be discharged by the Principal Employer i.e. Gujarat State

Electricity Corporation Limited, GTPS due to my lapse, I undertake to reimburse the same or

the Principal Employer is authorized to deduct the same from my dues as payable.

4. I further declare and undertake the legal consequences which may arise in future under the

said work awarded, and I bound myself to resolve the same at the risk and cost of M/s.

EW- 341 PUR-F-006 RFQ-

EW- 341 PUR-F-006 RFQ-

EW- 341 PUR-F-006 RFQ-

47. MATTERS RELATED TO EXECUTION OF WORK:

a) Work shall commence from the date given in letter to commence the work by EIC at

site. The Contractor shall make all necessary arrangements at site to mobilize labour,

operators, divers and materials and maintain necessary number of machinery and

equipment, barge, pontoons etc., to guarantee the agreed rate of progress of work as

per schedule.

b) A detailed work schedule showing how he proposes to carry out the work, specifically

mentioning time periods as well as date of commencement and completion of each

activity and such approved schedules must be strictly adhered to by the

CONTRACTOR. After the owner has agreed with the schedule, the Contractor shall

prepare detailed program of each work front/activity breaking it down giving daily

quantifiable/measure of progress. The schedules are to be reviewed periodically with

the OWNER / ENGINEER to ensure that the completion date will be met or to institute

corrective steps (at no extra cost to the ENGINEER) to adhere to the completion

dates. The OWNER reserves the right to revise the schedule at his discretion in order

to keep up to the completion date and to suit the project requirement and such

alterations shall not entitle the CONTRACTOR to any extra payment.

c) A work schedule with PERT / Bar Chart for carrying out the work in prescribed time

limit mentioning date of commencement, activity to be carried with its time period,

starting & finishing event for each activity, completion of total project in critical path

etc, shall be jointly fixed and approved by the GSECL. Such approved schedules must

be strictly adhered by the Contractor.

d) After the GSECL has agreed with the schedule, the Contractor shall prepare detailed

program of each work front / activity breaking it down to daily quantifiable measure of

progress. The schedules are to be reviewed periodically with the Owner / E.I.C to

ensure that the completion date will be met or to institute corrective steps (at no extra

cost to the GSECL) to adhere to the completion dates. The Owner reserves the right

to revise the schedule at his discretion in order to keep up to the completion date and

to suit the project requirement and such alterations shall not entitle the Contractor to

any extra payment.

e) The GSECL reserves the right to delete any item of schedule-B for which contractor

shall not have any right to claim on this account.

f) One permanent reference bench mark and a reference base line shall be given for lay

out of work, which shall be maintained without disturbance by the CONTRACTOR

during the tenure of the contract. CONTRACTOR shall establish local bench marks

as directed by the ENGINEER IN CHARGE.

g) The contract or any part thereof shall not be subject to change without the written

permission of the Chief Engineer (Gen.) GSECL, GANDHINAGAR TPS or his

authorized representatives.

h) During the execution of the work if it is found that the work is not progressing as per

the scheduled program approved by the GSECL & planned by the contractor, due to

the reasons attributable to the contractor, suitable action shall be taken as per

Clauses in this tender elsewhere & other relevant clauses appearing in the section of

“Terms & condition of tender & works contract, Legal conditions of works contract” of

tender document. And the GSECL may also take such action as it may deem fit to

ensure that the work is completed in time at Risk and Cost of the contractor.

i) Contractor shall attend meetings at EIC's office at site or any other place as fixed by

the EIC, as and when required for review, discussion, coordination etc. Attending

these meetings shall be obligatory on the part of the Contractor, at no cost to the

j) The Contractor shall take all requisite & necessary care to observe that no damage is

caused to the existing, pumps, existing works, service road, or any other structure etc.

For any damage to the existing structures of the GSECL, the Contractor shall be held

responsible and he will have to rectify the damage immediately up to the satisfaction

of Engineer in Charge, at his own cost.

k) The work shall be completed within the period stipulated in the contract. & site

clearance arranged according to the progress of work at site. Therefore, the

contractor has to organize & coordinate the work to suit these circumstantial

conditions. In the event of any delay due to the above or due to any other reason not

attributable to the contractor, reasonable extension in completing the work may be

given at the discretion and as decided by the GSECL but no compensation or idle

charges will be payable to the contractor on this account or any site conditions under

EW- 341 PUR-F-006 RFQ-

any circumstances.

l) No idle charges shall be entertained by GSECL for any site condition or any

circumstances. The corporation will not pay any type of advances including

mobilization advance

48. RECOVERIES:

a) In case of any damage to equipment / machinery or structure / building of GSECL or

any public property due to negligence of contractor or any other reasons attributed to

contractor, the decision of E.I.C. regarding the amount of recovery shall be final.

b) If the contractor fails to execute the work as per direction of E.I.C. within the time

frame given, the GSECL shall get the work done through any other contractor at the

risk and cost of the contractor and the cost of execution of such work along with 15%

overhead charges shall be deducted from contractor’s monthly bill over and above

recovery as per rules.

c) Recoveries due from the contractor, up to the end of the month previous to the one

in which the bill is prepared shall be made from bills approved for payment every

month or at other periods when the bills are prepared, for the various items in the

following order of priorities and extents.

d) Deduction on account of security deposit in full together with shortage, if any, to be

made good.

e) Penalty in full, if levied.

f) Expenditure, if any, incurred by the Corporation on Contractor’s behalf in labour or

materials in full.

g) Charges for services such as water and power supply etc. in full.

h) Charge on account of supply of materials like cement and steel in case of shortages

found in balance or excess consumption than specified.

i) Hire charges for Corporation or Government machinery if any.

j) Recoveries of advance and secured payment or payments for preliminary work in full

or the installment due if and as the same as may have been allowed.

k) Rent recovery on account of allotting quarters on rent as per Corporation’s rules.

l) Income tax and sales tax in full as per Government rules.

m) Outstanding recoveries in respect of other contracts awarded by the Corporation if

n) Other recoveries. (If any)

49. WORK TO BE EXECUTED TO THE SATISFACTION OF THE ENGINEER -IN-

The contractor shall proceed with the work with diligence and expedition and the

whole of the work herein specified as well as the mode of execution shall be

under the supervision and direction and shall be carried on to the entire satisfaction

of the Engineer-in-charge, who shall have full power to order the contractor to

alter, enlarge or diminish the form, dimensions, positions, or quantities of any of the

work or to make use of material and workman-ship of different descriptions and

qualities from this herein specified.

The whole of the works, together with any temporary works, associated therewith,

shall be carried on in the most substantial proper and mannered workman like

manner, with the best materials and workmanship and to the entire satisfaction of

the Engineer-in-charge and in such order of time as he may direct. The contractor

shall attend to and execute without delay all orders and instruction which may from

time to time be issued by the Engineer-in-charge.

50. MATERIALS WORKMANSHIP etc.:

The work shall be executed in thoroughly substantial manner with material and

workmanship of best quality and strictly in accordance with the specifications and

with the drawings, or with such other drawings or written instruction as may from time

to time be furnished to the contractor, in accordance with terms of this contract and

shall be completed in every respect with all materials and workmanship implied and

necessary according to the fair interpretation and meaning of the same and should

there be any discrepancy between the drawings and specifications or any difference

or disputes as to the dimensions to be worked to or the quality of the materials to be

used, or the mode of doing periodical quantity of the work to be executed or with

respect to any subject arising out of this contract, the decision of the Engineer-in-

charge shall be final and binding on all parties. Rejected material shall be so disposed

off as to obviate any possibility of their use on works. The place, method and period of

disposal shall be as directed by the Engineer-in-charge.

51. SAMPLES OF DESCRIPTIVE DATE:

EW- 341 PUR-F-006 RFQ-

Samples of descriptive date, requiring approval, shall be submitted by contractor to

the Engineer-in-charge in good time before the use of such material for inspection and

permission of testing if required. The samples shall be properly marked to show the

name of the material, manufacture, place of origin, and place where to be used

etc. Failure of any sample to pass specified tests will be sufficient cause for the

refusal to consider any further sample from the same source.

52. FENCING AND LIGHTING AND VENTILATION

Except as herein after provided, the contractor shall unless otherwise specified, be

responsible for the proper fencing, guarding, lighting and taking of the necessary

safety measures for all works comprised in the contract and or the proper provision of

temporary roadway, footways, guards fences, caution notices etc. as far as the

same may be rendered necessary by reasons for the work for the accommodation

and protection of workman foot passenger or other traffic and of the owners and

occupiers of adjacent property and of the public and shall remain responsible

for any accidents that may occur on account of his failure to take proper and

timely precautions.

All the arrangements made for fencing, lighting and ventilation shall be maintained

by the contractor throughout the tendency of the contract till physical taking over

of the work by the department.

53. LIABILITY FOR DAMAGE TO WORKS OR PLANTS

 The contractor shall during, the progress of the work, properly cover up and protect

the work, and plant, and materials placed at his disposal or acquired for him by

the Corporation, from injury by exposure to the weather, or any cause what so ever

and shall take every reasonable proper timely and useful precaution against accident

or injury to the same from any cause and shall be and remain answerable and liable

for all accidents, or injuries thereto which until the same be or be deemed to be, taken

over by the Corporation, may arise or be occasioned by the acts or omissions of the

contractor or his workmen of sub-contractors, and all losses and damages to the

works or such plant or material arising from such accidents or injuries as aforesaid

shall be made good in the most complete and substantial manner by and at the sole

cost of the contractor and to the reasonable satisfaction of the Engineer-in-charge. If

the contractor fails to make good such losses & damages within the time given by the

Engineer-in-charge, the Corporation shall be at liberty to recover the amount fixed by

the Engineer-in-charge for such losses or damages or any part thereof by deducting it

from any sum due by the Corporation to the contractor under this contract or otherwise.

 Further the contractor shall, at all time, protect and preserve all materials, plant and

equipment that he may himself have procured for the execution of the work. All

reasonable requests of the Engineer-in-charge to enclose or especially protect any of

the above shall be expeditiously compiled with.

 If the Engineer-in-charge considers that the work or materials or plant is not sufficiently

protected by the contractor, he shall be entitled to arrange for such protection at his

unfettered discretion and recover the cost thereof from the contractor.

 Until the work shall be or be deemed to be taken, over as aforesaid, the contractor

shall also be liable for and shall be deemed to have indemnified the Corporation in

respect of all damage or injury to any person or any property of the Corporation or of

others, occasioned by the negligence of the contractor or his workmen, or his sub-

contractor, or by defective design, work or materials.

54. EXPLOSIVE PROCUREMENT AND STORAGE (IF APPLICABLE)

i) Explosives, petrol, oils, fuels and other inflammable materials shall be stored strictly in

accordance with the rule of the Explosive Department.

ii) The contractor shall at his own expense construct and maintain, proper magazines

which are required for the storage of explosive and arrange for proper storage facilities

for oils, fuels etc. for use in connection with the work.

iii) The contractor shall at his own expense obtain such license or licenses as may be

necessary for strong and using explosives, oils, fuels etc. The department shall not take

any responsibility whatsoever in connection with the storage or use of explosives on the

site, or any accident or occurrence whatsoever in connection therewith. All operation of

the contractor in which or for which Explosives are employed shall be at risk of

contractor and upon his own responsibility.

55. MATERIALS TOOLS AND PLANT BROUGHT ON THE SITE OF WORK

All materials, tools and tackle of the contractor brought to and delivered upon the site

for the purpose of the work shall from the time of their being so brought shall be

EW- 341 PUR-F-006 RFQ-

deemed to be the property of the Corporation in its possession to be used for the

purpose of the work and for that purpose only and shall not on any account be

removed or taken away by the contractor or any other person without the written

permission of the Engineer-in-charge but the contractor shall nevertheless be solely

liable and responsible for and loss destruction thereof or damage thereto. The

Corporation shall have a lien on such materials, tools and tackle for any sum of sums

which may at any time prior to the completion of the works be due or owing to the

Corporation by the contractor, under in respect of and dispose of any such materials,

tools and tackle in such manner as the Corporation may think fit and to apply the

proceeding in or towards the satisfaction of such sum or sums so due or owing as

aforesaid but subject to such lien and power of sale and disposal such surplus

materials, tools and tackle shall belong to the contractor and may be removed and

disposed off by him as he may think fit.

56. ACCESS TO SITE AND WORK ON SITE

The Engineer-in-charge or his authorized representative may if he consider fit from

time to time enter upon any lands which may be in the possession of the

contractor under this contract, for the purpose of executing any work not included

in this contract and may execute such work not included in this contract by agents,

or by other contractors at his option and the contractor shall in accordance with the

requirements of the Engineer-in-charge, afford all reasonable facilities for execution

of the works including occupation of lands by structure or otherwise for any other

contractor employed by the Corporation and his workmen or for the workmen of the

Corporation who may be employed in the execution on or near the site of the work

not included in the contractor’s any contract in connection with or ancillary to the

works and in default, the contractor shall be liable to the Corporation for any delay or

expense incurred by reason of such default. Provided always that if the exercise of

those power shall cause any damage to the contractor he may within fifteen days of

such damage arising make a statement of the same to the Engineer-in-charge who

shall from time to time assess the value in his Judgment of such damage and the

Corporation shall from time to time shall pay to the contractor the amounts (if any

accepted as justified) by the Engineer-in-charge. The contractor shall not however, on

account of any such modified, new or extra work executed by or for the same of the

Corporation be entitled to claim relief from the obligation to execute other works.

57. INSPECTION OF WORKS

The Engineer-in-charge or his duly authorized agent shall have at all time full power

to inspect the works, wherever in progress, either on the site, on the contractor's

premises or at the premises wherever situated, of any firm or Corporation where work

in connection with this contract may be in hand.

Further, the contractor shall not allow, without written authorization permit entry on

site of work, any person except authorized agents of the Corporation of the Engineer-

in-charge or the contractor's staff and labour directly engaged on and in connection

with the work.

The contractor shall, during working hours, maintain supervisors having sufficient

training and experience to supervise the various items and operations of the work and

the said supervisors shall remain present during the inspections of the Engineer-in-

charge. All orders and directions given to such supervisors or other staff of the

contractor shall be deemed to have been given to contractor. Further the Engineer-in-

charge may be due notice, desire a higher ranking members of the supervisory staff

of the contractor to be present on any specified inspection and the contractor shall

comply with such direction.

58. CLEANING UP

 The contractor shall at all times keep the construction area and his power house and

storage areas free from accumulation of waste, or rejected materials.

 Prior to the completion of the work the contractor shall remove all rubbish from and

about the premises, and all tools, scaffolding, equipment and materials which are not

part of permanent structure. The premise will be left in a manner fully satisfactory to the

Engineer-in-charge, thereafter only the completion certificate will be issued.

59. CONTRACTOR TO KEEP INVENTORY OF MATERIALS etc.

The contractor shall prepare and maintain an inventory of all materials temporary

rolling stock, plant purchased or hired for use of employment or for any of the

purposed for this contract and such inventory or a copy thereof shall at all times be

EW- 341 PUR-F-006 RFQ-

available for inspection by the Engineer-in-charge. A complete and up to date copy

of the inventory shall be submitted to the Engineer-in-charge in the beginning and

once a year; thereafter changes in the interim period, if any shall be communicated

on every three months.

60. CONTRACTOR TO RESTORE PLANT

Upon completion of the work, the contractor shall deliver to the Corporation, all

appliances, materials, and plants which may have been loaned or hired to him by

the Corporation and make good all damages which may have occurred to them,

except such as shall be caused by fair wear and tear in execution of the works.

61. PROGRESS SCHEDULE

i) The contractor shall furnish, within one week unless extended by the Engineer of the

order to start the work, a progress schedule in quadruplicate indicating the date of

start the weekly progress expected to be achieved and the anticipated completion

date of each major items of work to be done by him, also indicating dates of

procurement and setting up of materials, plant and machinery. The schedule should

be such as is practicable of achievement towards completion of the whole work in the

time limit and of the particular items on due dates specified in the contract and shall

have the approval of the Engineer. Further, the dates for the progress as in this

schedule shall be kept up-to-date. In case it is subsequently found necessary to alter

this schedule, the contractor shall submit in good time a revised schedule

incorporating necessary modifications proposed and get the same approved by the

Engineer. No revised schedule shall be operative within such acceptance in writing.

Detailed schedules for each week showing the progress proposed to achieve shall

be submitted to the Engineer and got approved. The Engineer is further empowered

to ask for more detailed schedule or schedules any week by week, for any items or

items, and the contractor shall supply the same as and when asked for.

ii) The Engineer shall have, at all times the right without in any way vitiating this contract,

or forming grounds for any claim to alter the order of the works or any part thereof and

the contractor shall after receiving such direction proceed in the order directed. The

contractors shall also revise the progress schedule accordingly and submit four copies

of the revised schedule to the Engineer within seven days of the Engineer's direction

to alter the order of works.

iii)The contractor shall furnish sufficient plant equipment and labour and shall work such

hours and shifts as may be necessary to maintain the progress on the work as per the

approved progress schedule. The working and shift hours shall comply with all

GSECL's regulations in force and shall be such as may be approved by the Engineer.

They shall not be varied without the prior approval of the Engineer.

iv)The contractor shall from time to time as may be required by the Engineer, furnish the

Engineer, with a statement in writing of the arrangement he proposes to adopt for the

execution of this contract and the Engineer may if he considers, necessary at any time

advise alteration in the same, which the contractor shall adopt on notice thereof.

v) The progress schedules shall be in the form of progress charts, forms, statement

and/or reports as may be approved by the Engineer. Further, the contractor shall

submit four copies showing the progress of work in forms and charts etc. at

periodicals intervals as may be specified by the Engineer.

62. DATE OF COMPLETION

The contractor shall supply, erect, equip and construct the whole of the works and

hand over them to the Corporation on or before the date specified in the tender

document including "Special Conditions" and save as herein provided, in no

circumstances whatever shall extend or alter the date for the completion of works.

Provided always that if in the opinion of the Engineer-in-charge the completion of

the works shall be delayed by any change of original design or by the order of

the Engineer-in-charge, of any altered, modified substituted or additional works or

materials omitted or by strikes, lock outs or stoppages of labour, or revolution, riots,

civil or political disturbance or by causes directly due to war or by the contractor not

being given possession of the site or any part there-of or by the Corporation taking

possession of and using the site or any part thereof or the works or any part thereof,

whether any nonperformance of work under the powers herein contained or

otherwise or by any nonperformance of work or non-supply of materials to be

performed or supplied by the Corporation or by the contractor not receiving any

orders, drawings, instructions or directions in time or by the suspensions of the

EW- 341 PUR-F-006 RFQ-

works or by fire, flood exceptionally bad weather tempest, storm, or by from

unforeseen circumstances (and whether the same shall be due to any act or

omission of the Corporation or its agents or those in their respective service or not)

the Engineer-in-charge may, if in his unfettered discretion, he thinks fit either

forthwith or at any later time and from time to time not withstanding that the

prescribed or extended time for completion has expired or that the work have been

completed, by writing under his hand, extend the time for the completion of the

works to such date as he shall appoint. Provided always that unless the contractor

makes a written application to the Engineer-in-charge within one month of the

cause of delay and unless the time is extended by the Engineer-in-charge, the

prescribed time shall not be extended notwithstanding delays from the aforesaid

foregoing or any other causes of whatsoever kind.

63. SUBLETTING OF CONTRACT

There will be generally no objection on the component parts for the work, being given

over to responsible sub-contractors but Corporation shall under no

circumstances recognize these sub-contractors and the responsibility of executing

the work in the accordance with the conditions of contract will entirely rest on

the main contracts. The main contractors will therefore always have the very

responsible member, preferably a technical hand present on the works with power

to sign all work orders issued on the site of work and to take requisite actions in

the interest of very efficient execution of work. However, the subletting of the

contract can be made only with the prior approval of the competent authority of the

Corporation.

64. OTHERCONTRACTS FOR THE WORK SUSPENSION STOPPAGEOR

CURTAILMENTS OF WORK

If during the tendency of the contract the Engineer-in-charge shall for any reasons

(which shall be unquestioned) whatsoever require the whole or any part of the

work as specified in the contract to be suspended for any period or shall not

require the whole or any part of the work as specified in the contract to be carried

out at all by the contractor, he shall give notice in writing of the fact to the

contractor who shall thereupon suspend or stop the work totally or partially as the

case may be. In any, case, except as provided hereunder, the contractor shall

have no claim to any payment or compensation whatsoever on account of any profit

or advantage which he might have derived from the execution of the work in full but

which he did not so derive in consequence of the full amount of the work not

having being carried out, or on account of any loss that he may be put to on account

of materials purchased or agreed to be purchased or for unemployment of labour

recruited by him. He shall not also have any claim for compensation by reason of

any alterations having been made in the original specifications, drawings, designs

and instruction which may involve any curtailment of the work as originally

contemplated. Where, however, materials have already been purchased or agreed

to be purchased by the contractor, before receipt by him of the aforesaid notice,

the contractor shall be paid for such materials at the rate determined by the

Engineer-in-charge, provided they would have been useful for the work curtailed

or stopped are not in excess of requirements, are of approved quality and cannot

be used on other contract works or otherwise by the contractor and/or shall be

compensated for the loss if any, that he may be put to, in respect of materials

agreed to be purchased by him, the amount of such compensation to be determined

by the Engineer-in-charge, whose decision shall be final.

The Engineer-in-charge may grant extension of time for the execution of any item or

items of work affected by such suspension of work. The decision for the Engineer-in-

charge, regarding the granting of extension and the period thereof shall be final. The

Engineer-in-charge may order the contractor to suspend any work on account of bad

weather; rain or storm and such other adverse climate conditions and the contractor

shall comply with the same.

The contractor shall not be entitled to an compensation for such suspension of work,

concrete lining at the junctions of the different works under different contract shall be

done with particular care regarding forms, construction joints, interconnecting

reinforcement etc. If any and the joint planning of such work shall be with prior

approval of the Engineer-in-charge.

65. OTHER CONTRACTORS

EW- 341 PUR-F-006 RFQ-

Apart from this work, the other works connected with the power house will be

simultaneous going on either departmentally or through agencies inside or outside

the power house. Each contractor or agency shall co-operate with others to the

fullest extent and shall allow to each other every facility and co-ordination for

execution of their works simultaneously and satisfactorily, during their action of

machinery or execution of any other co-ordination works of the power house, the

contractor will have to work only at places as directed by the Engineer-in-charge.

He will have some time to suspend his work partially or totally in the interest of the

work at large.

In such cases and at such time, he will be informed from time to time and directed by

the Engineer-in-charge where to work. He may also be required to remove the

scaffolding or to erect the scaffolding and shuttering in such a manner as to be of little

obstruction and inconvenience for erection of machinery. In such cases he shall not

be given any compensation on account of reduction or stoppage or labour force or

removal and reinstatement of scaffolding shuttering etc. It will be seen that contractor

is not put to unnecessary inconvenience.

In the matter of dumps, haul, roads, drainage, diversion and the like, each contractor

shall take into consideration the needs and requirements of the other constructors, if

any working in the vicinity. Further no contractor shall take or cause to be taken

any stops or action that may cause disruption, discontent or disturbance to the

work, labour of arrangements etc. or other contractors in the neighboring project

localities.

Any action, by any contractor, which the Engineer-in-charge in his unquestioned

discretion may consider as infringement of the above code, would be considered as

a breach of the contract conditions and the Engineer-in-charge may take such action

as he may deem fit against the contractor and the action taken shall be considered

as final and binding.

66. SPEED OF WORK

The contractor shall at all times maintain the speed of work to confirm to the latest

operative progress schedule but the Engineer-in-charge may at any time with

sufficient notice in writing direct the contractor to slow down any part or the whole of

the work for any reason (which shall not be question whatsoever, and the contractor

shall comply with such orders of the Engineer-in-charge. The compliance of such

orders shall not entitle the contractor to any claim or compensation.

67. CONTRACT DOCUMENT AND MATTERS TO BE TREATED AS

All documents, correspondence, decisions and other matter concerning the contract

shall be considered as of confident and restricted nature by the contractor and he

shall not divulge or allow access there to any unauthorized persons of any kind.

68. ACCESS TO THE CONTRACTOR'S BOOK

Whenever it is considered necessary by the Engineer-in-charge to ascertain the

actual cost for execution of any particular item of work of supply of plant or material

shall direct the contractor to produce the relevant documents such as pay rolls

records of personnel, invoices of materials and any other data relevant to the item

or necessary to determine its cost etc. and the contractor to the aforesaid items in

the mode and manner that may be specified.

69. INTEREST ON MONEY DUE TO THE CONTRACTOR

The contractors shall not be entitled to get interest on any amount either of their bills

or arrears whatsoever because of delay in payment by the Corporation. Similarly they

shall not be entitled for any interest on amount of bank guarantees given by them.

Non-payment of interest by the Corporation therefore, shall not cause breach of

70. MEASUREMENTS TO BE PROVISIONAL AND SUBJECT TO CORRECTION

Every measurements for running payment on account of work, done or supplies

made, shall be subject to adjustment or final measurements. In case of disagreement

between such intermediate and final measurements, the latter shall prevail. All works

EW- 341 PUR-F-006 RFQ-

shall be measured, met by standard measure and according to rules and custom and

usual in the use in Gujarat State Electricity Corporation Ltd., and no proposal to adopt

alternative method will be accepted, the Executive Engineer’s decision as to what is

“the usual method in use in the Gujarat State Electricity Corporation Ltd.” shall be

71. BREACH ON PART OF CORPORATION NOT TO ANNUAL CONTRACT

No breach or non-observance on the part of the Corporation of any of the

agreements contained herein, shall annul this contract or discharge the contractor

from the observance and performance thereof, or of any part thereof, but on

application by the contractor and in the unfettered discretion of the Engineer-in-

charge an extension of time may be given to the contractor in respect of such

breach or non-observance by the Corporation.

72. PROFORMA RETURNS

The contractor shall maintain Performa, charts and details regarding machinery

equipment materials, labour personnel and other matters as may be specified by the

Engineer-in-charge. He shall further, submit returns of Performa and details as

may be specified by the Engineer-in-charge from time to time.

73. LOCAL LAWS

All local laws in force at the time of entering into the contract and those enacted

thereafter shall be binding on the contractor and he shall abide by the same.

All import duties, sales tax and other local taxes shall be borne by the contractor

and they shall be deemed to have been covered by this quoted tender rate

74. WORKS IN SHIFT DUTY

Works shall be planned in shift duties, if possible in three shifts, depending on

emergency of the work with prior approval of Eng. - in- charge. 0n Sunday or any

other holidays work shall be continued in order to maintain progress with prior

permission of Eng.-in -charge. Such works shall not form any grounds for complaint,

compensation or extension of time limit.

If on the other hand, the Engineer-in-charge directs that the work shall be

proceeded with on days and during hours which are not permissible under this

contract, the contractor shall proceed with the work as directed without in any way

vitiating this contract or forming any grounds for compensation of claim.

The contractor shall in his dealing with labour, atall times, during the period of this

contract, have due regard to local festivals and religious and other customs.

A working day shall consist of two shifts each of eight hours, a working day shall

constitute any day on which in the opinion of the Engineer-in-charge, work can be

carried out in one or more shifts.

Final payment to the contractor shall not be made until the contractor shall deliver to

the purchaser or receipts in full in lieu thereof, and in either case, an affidavit that so

far he has knowledge or information the releases and receipts include all the labour

and material for which in lien could be filed. If any lien remains unsatisfied after all

payments are made, the contractor shall refund to the purchaser all moneys that the

latter may be compelled to pay in discharging such a lien, including all costs and a

reasonable attorney's.

76. MISCELLANEOUS:

1. In case of conflict / discrepancies among clauses of different specifications given in

this document, the stringent specification shall be followed and under such

circumstances, the decision of the EIC shall be final and binding to the Contractor

2. The Notice inviting tender, general instruction to bidders and all other documents of

this tender shall form part of the contract

3. No receipt for any payment alleged to have been made by a Contractor in regard to

any matter relating to tender of the contract shall be valid and binding on the

Corporation unless it is signed by the Engineer-in-Charge.

4. As per provisions of Income Tax Act, Corporation shall deduct Income Tax at the

applicable rate.

EW- 341 PUR-F-006 RFQ-

5. Agency has to note that the extension of Time limit/excess saving in the works if

required to approve, than it shall be processed as per the provision of DoP and will

take time for process the same.

6. The contract is inclusive of the cost of materials required to complete the work in

7. It will be absolutely incumbent on the contractors to have on the site of work only

such of the materials as have been duly passed by the Engineer-in-charge. Materials

that have been rejected must on no account be allowed to remain on the site, and in

spite of written order to do so, any such rejected materials is on the site beyond a

period of 48 hours’ notice, the Engineer-in-charge shall have the right to remove it, at

the risk and cost of the contractors and even to destroy it.

8. It must be distinctly understood that conditions of contract and of claims in respect of

extra work, will not be allowed unless the works to which they relate is clearly without

the spirit and meaning of the specifications or unless such works are ordered in

writing by the Engineer-in-charge and claimed for in specified manner.

9. Contractor will be asked to present the sample of materials, and the approved

samples will be preserved at the site of work, and no change in the approved sample

will be allowed, without the written permission of the Engineer-in-charge.

10. The department reserves the right to make any change in the design and the plans of

the works. The contractor shall be bound to carry them out at the rates tendered. No

claim or compensation will be allowed on this account.

11. The contractor shall keep instruction book on site, for taking site instructions from

time to time. This book shall be made available on site whenever asked for.

12. Above construction equipment brought to site shall be allowed to be taken out only

after the work for which it has been brought is over. The equipment shall be taken out

only with the specific permission in writing from the E.I.C. Only the equipment

required for the work and in fit condition shall be brought to the site. The Contractor

shall ensure that proper documentation is followed at entry gate of GSECL's

premises for such items which shall be carried back by Contractor after completion of

13. The Contractor shall provide all temporary ladders, scaffolding materials, platforms,

supports and other necessary facilities required for trimming & cutting of trees. The

Contractor shall provide sufficient, strong and safe staging so as to ensure safety of

the laborers.