Repairing of Patch work with Milling At Existing Bridges carriageway in Bridge Project of Ahmedabad municipal Corporation.(A.R.C.)

Name of work :- Repairing of Patch work with Milling At Existing Bridges

carriageway in Bridge Project of Ahmedabad municipal Corporation.(A.R.C.)

SR.NO. PARTICULARS

1.A Notice inviting e-Tender

1.B Schedule of Bidding process

1.C Tender Declaration Form

SECTION – I SPECIAL CONDITIONS OF CONTRACT

SECTION – II INSTRUCTIONS TO BIDDERS

SECTION - III GENERAL CONDITIONS OF CONTRACT

SECTION – IV TECHNICAL SPECIFICATIONS

SECTION – VI QUALIFIACATION INFORMATION

Signature of Bidder Page

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

Notice inviting e-Tender

Municipal Commissioner of A.M.C. invites percentage rate sealed tenders from interested

contractors for the following work at Diff.Location of locations of Existing Bridge within the limit of

1 Name of work Repairing of Patch work with Milling At Existing Bridges

carriageway in Bridge Project of Ahmedabad municipal

Corporation.(A.R.C.)

2 Estimated Cost

3 Tender fee Rs.3600.00 (Demand Draft in favour of Municipal Commissioner,

(Non refundable) Ahmedabad)

4 Time Limit 12 Months (Excluding Monsoon)

5 Download of Tender Complete bid documents can be downloaded with effect from

Documents Dt.26/05/2026 from the website www.nprocure.com.

6 Required registration Register “B” class in Govt. R&B/CPWD/AMC or equivalent

register with any other state Govt. or institutions. Bidder who is

not registered in A.M.C., shall have to register in same class in

A.M.C. before claiming 1st R.A. Bill.

A Joint Venture Joint Venture is not allowed.

7 Preliminary prequalification Average annual financial turnover during the last 3 years, ending 31st

criteria of bidding firm March of the previous financial year, should be at least 30% of the

(detailed criterias are given in estimate put to tender i.e. Rs.59,99,822.00 for this work.

the Bid Document) Experience of work of similar nature during last 10 years (in lakhs)

Single work of 80 % of Estimate put to tender OR

Two works of 50 % of Estimate Put to Tender OR

Three works of 40 % of Estimate put to tender

8 Solvency certificate Solvency certificate issued and valid in current year for an amount

equal to 20% of the Estimate put to tender.

9 Earnest Money Deposit (Bid Rs.1,99,994.00/- (Demand Draft / pay order / Bank Guarantee in

security) favour of Municipal Commissioner, Ahmedabad is to be submitted as

(1 % of Estimate put to prescribed.

tender) Bank Guarantee shall be from approved list of AMC of banks and the

issuing branch of bank guarantee shall be of Ahmedabad city only and

it should be valid for 120 days.

E.M.D. shall be submitted physically on/before Date: 17/06/2026 up to

10 Submission of EMD and In separate sealed cover each for EMD and Tender Fee & EMD should

Tender Fees Submitted physically on 17/06/2026 up to 15:00 hrs. along with tender

documents as described in the invitation of tender should be

submitted to Assistant Manager (Projects), 2 nd floor Ahmedabad

Municipal Corporation, Sardar Patel Bhavan, Danapith.Bid submitted

without bid security & tender fee shall be treated as non responsive

and shall be summarily rejected.

11 Pre -Bid Meeting 02/06/2026 Time: 16:00 Hours,

Office of Additional City Engineer (Bridge project), Amdavad Municipal

Corporation, 4th Floor, B-Block, Old building, Sardar Patel Bhavan,

Danapith, Amdavad– 380

12 Mode of sending the Tender The whole tender shall be submitted by two mode.

Documents (1) Whole tender shall be submitted only on www.nprocure.com

website before Date:- 16/06/2026 before 18:00 hrs.

(2) Tender Fee, EMD, technical bid and other relevant PQ Documents

as per check list given in tender shall be submitted physically in

two copies (Original & duplicate) in sealed envelope on or before

Dt.17/06/2026 up to 15:00 hrs.

13 Last date of online submission Date: 16/06/2026 before 18:00 hrs.

Signature of Bidder Page

Ahmedabad Municipal Corporation

14 Submission of Price Bid The Price bid shall be submitted online only.

It shall not be submitted Physically.

15 Opening of Technical bid 17/06/2026 Up to 16:00 Hrs

16 Tender validity period 180 days from the last date of submission of Tender.

17 Security Deposit 5 % of Contract Value to be submitted in the form of Bank Guarantee.

Bank Guarantee shall be from approved list of AMC of banks and the

issuing branch of bank guarantee shall be of Ahmedabad &

Gandhinagar City only. After the Completion of Work, the Security

Deposit shall be converted into Performance Guarantee which shall be

5 % of Final Bill Amount including Price Variation. The Security Deposit

shall be released only after submission of Performance Bank

19 Deductions from Running Bills

a. Retention Money 2 % amount of each Running Bill shall be deducted as a Retention

Money. Such retention money shall be released in the final bill of the

b. Labour welfare cess 1% Labour welfare cess as per the Act, 1996 (non refundable) shall be

deducted from each running bill.

20 Defect liability period 36 months from the date of completion. The date of completion is as

mentioned in the completion certificate issued by Authority.

21 Performance Bank Guarantee The contractor shall have to submit a performance bank guarantee @

% amount of work done in the form of Bank Guarantee after final bill in

replace of defefect liability period. After the Completion of Work, the

Security Deposit shall be converted into Performance Guarantee which

shall be 5 % of Final Bill Amount including Price Variation The same

shall be released after completion of Defect Liability Period and after

deductions of performance based recovery if any & remarks of final

audit from Audit Department of AMC.

22 Liquidated damaged If the Contractor fails to complete the works within the original or

extended time limit, the contractor shall pay penalty of 10% of amount

of actual remaining work, The amount of work for which the scope of

contractor is reduced shall not be considered for the calculation of

Liquidated Damages. Conditions mentioned in the AMC Finance

Department Circular No. 9 Dt 18-05-2012 and Circular No. 18 Dt. 04-07-

2012 and circular no. 53 dated 20-11-2014 and latest Circulars shall be

(1) Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the

rights to reject any or all the tenders without assigning any reasons thereof.

(2) The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In

case authorized signatory holding Power of Attorney and Digital Signatory are not the

same, the bid shall be considered non-responsive.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

SCHEDULE OF BIDDING PROCESS

Sr. No. Event Description Date

1 Sale of Bid Documents 26/05/2026

2 Last date of online submission 16/06/2026 Up to 18:00 Hrs

3 Last date of physical submission 17/06/2026 Up to 15:00 Hrs

02/06/2026 Time: 16:00 Hours,

Office of Additional City Engineer

(Bridge project), Amdavad Municipal

4 Pre bid meeting

Corporation, 4th Floor, B-Block, Old

building, Sardar Patel Bhavan, Danapith,

5 Opening of Technical Bid 17/06/2026 Up to 16:00 Hrs

6 Opening Of Price Bid To be intimated later

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

TENDER DECLARATION FORM

Additional City Engineer

Amdavad Municipal Corporation

Name of Work: Repairing of Patch work with Milling At Existing Bridges carriageway in

Bridge Project of Ahmedabad municipal Corporation.(A.R.C.)

I/We the undersigned have carefully gone through and clearly understood the Tender documents of

above mentioned project comprising of Notice Inviting tenders, Articles of Agreement, Scope of work,

Definition of terms, notes Instructions/Information to Bidder, Condition of Contract, special condition of

contract, Appendices, Specifications, Bill of Quantities, Statements (1 to 6) furnished by AHMEDABAD

MUNICIPAL CORPORATION.

I/We do hereby offer to execute and complete the whole of the work within the time specified all in

accordance with the specification, designs, drawing and instruction in writing referred to in the said document

and with such materials as mentioned for, at the respective rates which I/we have quoted in the Price Bid or at

such other rates as maybe fixed under the provisions of these conditions.

In the event of this tender being accepted I/We agree to enter into an agreement and when required,

execute the contract, according to your form 1 of agreement as or in default where of I/we bound

myself/ourselves to forfeit the "Earnest Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided by AMC

from the date of receipt of letter of acceptance, you will forfeit the earnest money paid by me/us and take

necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for the sum as

mentioned in NIT, the full value of which is to be absolutely forfeited to the Employer If I/We fail to commence

the work specified. Otherwise the Employer shall retain the said sum, as on account of such Security Deposit as

provided for in the aforesaid documents.

I/We agree not to employ sub-contractors other than those that may be approved in accordance with

conditions in the aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any tender,

which are received. I / We also understand & agree that Municipal Commissioner Reserves the right to allot

number of tenders to successful bidders at his sole discretion in case if I / We am/are lowest in more than one

I/We am/are bound to execute the job if the work order is issued within 180 days from the date of

opening of the tender.

I am bound to execute the work by maintaining all Quality aspects/parameters mentioned in the

tender terms and conditions. I am also bound to submit all supporting Genuine Original documents as and

when asked and if any discrepancy found in such documents as well as in the executed Work with respect to

Quality/Quantity at any stage of work or even after completion of work, it will be solely my Responsibility. I am

bound to prove originality of all documents submitted by me and if any Documents found false/fake then

Municipal Commissioner/AMC has right to take any action/penalty/punishment against me.

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality and/or the

construction of road is found to be of an inferior quality under this contract than in such case Municipal

Commissioner/AMC has right to debar/ blacklist permanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi duties, Royalty on

material (i.e. Aggregate, Sand etc.) And any other taxes prevailing and from time to time on such items on

which the same are leviable and the rates quoted by me/us are inclusive of the same.

Yours faithfully

Seal and Sign of Contractor

Signature of Bidder Page

Ahmedabad Municipal Corporation

SPECIAL CONDITION OF CONTRACT

1. This contract envisages repairs to Potholes/heavy patchwork work within limit of

Ahmedabad Municipal corporation Bidders shall execute the work in the co ordination with

Bridge Project engineering staff.

2. The traffic permission, arrangement of lights reflectors, cones, reflective jackets, protection

of working site from regular moving traffic i.e. barricading etc if required will be

responsibility of the bidder.

3. Methodology of road distresses repairs shall be:

1. The potholes/heavy patchwork shall be clearly marked in Regular Geometrical shape

as directed before milling the existing surface.

2. Then remove existing damage surface remove by milling machine up to 75 mm and

disposal of milled material to an approved dumping yard (within 12 km lead) and

then balance loose debris in the potholes/heavy patch work any road distress shall

be blowered off using high volume blower of the milling surface. Removal and

disposal shall be the responsibility of the contractor without any extra cost.

3. The Tack Coat (Cationic bitumen emulsion RS1 grade complying with IS-8887) shall

be sprayed uniformly at the rate of 0.25-0.30 kg/sqm. It shall be applied by a

selfpropelled or towed bitumen pressure sprayer, equipped for spraying the material

uniformly at a specified rate.

4. Back filling the potholes/heavy patch work with coldmix or hotmix material

(Providing Cold Mix and Hot mix material using 100-120 TPH batch type plant

producing an average minimum-output of 75 tonnes per hour. Using crushed

aggregates of specified grading, premixed with Slow/Medium setting bitumen

Emulsion or tailor made confirming to IS:8887 or as medium curing cut-back

conforming to IS-217 @ 7-10% by weight of mix for coldmix material as per

IRC:SP:100-2014 & MORTH 5th Revision & Bituminous Binder @ min. 5.4 % by weight

of mix for hotmix material as per MORTH Clause 507.) laying by Paver Machine/Hand

laying & compacting with 10MT vibratory Roller/Plate compactor as per

requirement. Paver machine shall be deployed if width of patch exceeds 3 mtrs and

length of patch exceed 20 mtrs

5. Emulsion Painting ( Using with Bitumen Emulsion grade RS 1 @ rate of 5 kg/10 smt

by Mechanical sprayer and spreading the stone dust on prepared surface at the rate

of 0.03 cum/10 smt.) for the finish surface using Bituminious Emulsion to form a

smooth riding surface.

6. Compaction equipment is specified in line with the repair area's requirements. All

edges are rolled first to create a mechanic interlock with the surrounding surface, A

skilled operator assesses the repair area's compaction requirements to complete a

high quality and level repair.

7. The bidder is shall have to repair below mentioned potholes/heavy patchwork within

the limit of A.M.C.

1. Potholes/heavy patchwork

2. Utility Cuts

3. Wheel path rutting

6. Crack sealing

8. Pre surface dressing

10. The sand or dry aggregates shall be spread on the freshly sprayed patch surface of

Signature of Bidder Page

Ahmedabad Municipal Corporation

the required area with the help of pothole patching and overlaying machine before

opening for traffic.

11. The surplus excavated material from the site shall be removed free of cost to the

dumping ground immediately after completion of individual works, as directed. The

necessary tipping charges at the dumping ground, as applicable, shall be borne by the

12. The affected area shall be cleaned, prepared, sealeld, filled, cured and ready for

traffic in one smooth operation.

13. No extra payment will be made for material to prepare firm base for big

potholes/heavy patchwork.This work will be done by contractor at his own cost.

5. Traffic Management:-

1. The contractor shall have to provide adequate number of wardens as per requirement.

2. Traffic signs at the contractor's cost.– Temporary traffic and construction signs are to be

provided during construction and maintenance operations for traffic diversion and

pedestrian safety as approved by the Engineer.

3. If any fatal accidents including fatal occurs due to improper traffic diversion during or after

the work (before clearing the site) shall be completely contractor’s responsibility.

4. The full time services of the Personnel Team of the contractor is mandatory during the

entire period of the project. No Extra cost towards the same will be Paid. The contractor

shall ensure with contractor all risk policy for the work.

5. The color photographs of work sites & works as and when directed by Engineer are to be

taken and submitted at no extra cost.

6. TESTING OF MATERIAL

1. Contractors are required to test at least one complete sample per 1000 Sq.Mt. area of

2. The test of samples of material, used in the work shall be carried out at municipal laboratory

or government approved laboratory as directed by engineer in-charge.

3. The charges for testing of bitumen or bitumen emulsion /hotmix or coldmix/Aggregate shall

be as per the rates in force at the time of testing of all materials.The testing charges shall be

borne by the contractor.

4. The work will be treated as completed only after cleaning the site in all respect, after

completion of the work.

7. Post Performance of Attended Potholes/heavy patchwork.

After repairs to potholes/heavy patchwork till end of Defect Liability Period following

performance criteria shall be observed.

a) Edges should not be damaged/deteriorated.

b) No depression / hump shall be observed.

c) Smoothness of surface shall be ensured.

d) There shall be no raveling on attended surface.

In case of failure of any of above said performance criteria, the work shall be redone by the

contractors at his own cost with the same scrubbed material /asphalt /cold mixes/Aggregate

as applicable. No extra payment will be made for material to prepare firm base for big

potholes/heavy patchwork.This work will be done by contractor own cost.

8. The photographs of the pothole to be repaired shall be taken by contractor @ four stages

and contractor should produce the same to AMC if asked by AMC Engineers in charge.

1) Existing pothole.

2) After cutting of pothole to Regular Geometrical shape.

3) During the execution of the work

4) After laying of the hot bituminous/cold mix material

Signature of Bidder Page

Ahmedabad Municipal Corporation

9. Minimum required Equipments for the work

The contractor should have minimum machinery of its own ownership as mentioned below:

1. Milling Machine of 0.55m OR less 01 No.

2. Sensor Paver – 01 No. 1.5m width or less

3. Vibrator Roller – 01 No.

4. Air Compressor-01 No.

5. Dumper – As per Requirement

9.1 Contractor shall submit the list of above equipments along with indemnity bond with

attachment of ownership like RC book/Purchase invoices for above equipments. If the same

are to be procured on rental basis (expect milling machine), than contractor shall submit the

rental agreement to AMC mentioning that all rental machineries shall be used exclusively for

this tender work of AMC allotted to contractor. The ownership of one milling machine

meters or less must be necessary.

9.2 Contractor shall submit a bond mentioning that he will deploy separate machineries for each

tender allotted to him.

9.3 Contractor shall increase & deploy required number of machineries like Milling machine

Sensor Paver, Rollers,dumpers etc. to complete the work within time limit with quality as per

the Priority given by Ahmedabad Municipal Corporation.

10. Batch Mix Plant & Milling Machine

10.1 Bidder shall have own batch mix plant of minimum 100 to 120 TPH capacity in running and

good/operational condition within the limit of 25 km from the boundary of AMC.

10.2 If the batch mix plant of bidder is situated anywhere in the country and not within the above

mentioned limit, Contractor shall submit a separate Bank Guarantee of Rs. 50 Lacs (Rupees

Fifty Lacs) (Other than EMD) & an undertaking on the Rs. 300 stamp paper that he will shift

& install Batch mix plant within the specified limit of this tender within the 45 days from

date of LOI. The same shall be released after establishment of Batch mix plant within

Days of work order within the limit of 25 km from boundary of AMC.

10.3 Bidder shall submit health certificate of that plant from the Superintending Engineer,

(Mechanical), Road & Building Department, Gujarat at the time of commencement of Batch

10.4 In case of late installation of the batch mix plant, the release of this bank guarantee shall be

As per the sole discretion of Municipal Commissioner AMC.

10.5 Bidder must have own milling machine of 0.55 meters OR less & shall not exceed more than

11. Tax, Duties on Materials

All charge on account of Octroi, excise duties, terminal tax, sales tax, and Govt. duties / tax

etc. on material procured for the works from any source shall be borne by the contractor. No

(P) or "C" or "D" form shall be supplied by AMC for this purpose.

12. Reserved Rights

Municipal Commissioner Reserves right,

(1) To waive any qualifying criteria or information in any tender as a special case and to

reject any or all tenders without assigning any reason thereof.

(2) To increase / decrease the scope of work & also split the tender in two or more

contracts without assigning any reason even after the work is awarded.

(3) To allot number of tenders to successful bidders, in case if any contractor is lowest in

more than one tender.

(4) To collect any required documents after bid opening and also reserves the right for

rejection/acceptance of any tender.

Signature of Bidder Page

Ahmedabad Municipal Corporation

13. Performance Bank Guarantee

1. 5% security deposit, submitted at the time of agreement shall be released after

submission of a performance bank guarantee. The security Deposit shall not be

released if contractor fails to submit Performance Bank Guarantee.

2. AMC reserves right to deduct any amount from this Performance bank guarantee

which is levied from the contractor due to poor performance during defect liability

14. Retention Money

2% amount shall be deducted as retention money from each running bill. This

retention money shall be released along with final bill. AMC reserves right to deduct

any amount to compensate the poor performance of the contractor i.e. poor quality

or abandoned/incomplete work.

15. Laboratory at Plant

The Contractor shall setup a laboratory at plant along with all the calibrated

equipments for testing of asphalt, aggregates, cold mix and Hot Mix material with

the Material Engineer in the Laboratory having experience of not less than 3 years in

Laboratory testing.

1. The samples of materials to be procured shall be got approved by the Engineer

2. All the material required for the work shall be confirming to required standard and

requisite certificate will have to be produced/submitted for that.

3. Testing of all material shall be carried out as per required frequency.

4. All the testing charge for mix design etc if necessary shall be borne By the

5. The patch repair work will be with 6 months guarantee after the date of execution.

6. Contractor shall repair at his cost any patch/potholes/heavy patchwork which ae

found detective during defect liability period. No payment shall be made for such

Seal and Signature of the Bidder Add City Engineer

(Bridge Project)

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 This contract covers the following works ;

Work of pothole/heavy patchwork milling and filling with cold mix/Hot mix material

(Production from Batch mix plant 100-120 TPH only) on all the roads in Ward limit during

Contract Period :- The contractors shall be responsible for Repairs to the potholes/heavy

patchwork/Bad Patches during any season on all the roads in the ward except those roads

which are in the Defect Liability Period of contractors of NORTH Agency/ Any other Agency

and Project Roads as per the specifications and as directed by the Engineer.

1.2 The above is general description of the scope of work & the said work is required to be

executed as per the items under the methodology as submitted by milling & patch work

technology as mentioned in this document and relevant Specifications as updated upto the

date of invitation of the Tender.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined

in this tender.

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-

14. An agency that has been engaged by the Employer to provide consulting services for the

preparation or supervision of the works, and any of its affiliates, shall not be eligible to bid.

3.3 An enterprise / company may only participate in the bidding process if they are legally and

financially autonomous, operate under commercial law and are not a dependent agency of

(i) Bidders shall not be under a declaration of ineligibility for corrupt or fraudulent or

collusive or coercive practices in accordance with ITB clause No.

(ii) Bidder(s) found to have conflict of interest shall be disqualified. For clarification

purposes a conflict of interest is when bidders:

(a) are associated with an agency or any of its affiliates which have been engaged by the

Employer to provide consulting services for the preparation of the design,

specifications, and other documents to be used for the procurement of the

goods/works under these Bidding Documents ;

(b) or submit more than one bid in this bidding process. However, this does not limit the

participation of subcontractors in more than one bid.

3.4 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms

those are blacklisted/ debarred for specified period by AMC, Governement of Gujarat,

Government of India or any other entity controlled by it, would not be eligible to submit the

4.0 Qualification of the Bidder

4.1 Experience of bidder

Signature of Bidder Page

Ahmedabad Municipal Corporation

Experience of having successfully completed similar works pothole/heavy patchwork using

milling machine and filling with cold mix/Hot mix material (Production from Batch mix plant

100-120 TPH only cold mix and hotmix) during last 3 years ending last day of month previous

to the one in which applications are invited should be either of the following..

i. Three similar completed works costing not less than the amount equal to 40% of the

estimate put to tender i.e. Rs.79,99,763 i.e. 40% of the estimate put to tender.

ii. Two similar completed works costing not less than the amount equal to 50% of the

estimate put to tender i.e. Rs.99,99,703 i.e. 50% of the estimate put to tender.

iii. One similar completed works costing not less than the amount equal to 80% of the

estimate put to tender i.e. Rs.1,59,99,525 i.e. 80% of the estimate put to tender.

Similar works mean pothole/heavy patchwork using milling machine and filling with cold

mix/Hot mix material (Production from Batch mix plant 100-120 TPH only both hotmix and

It is to be noted that Certificates from private individual/Private limited company etc for

whom the bidder has worked, shall not be considered. Certificate form only those

organizations/institutions/bodies will be considered which execute work in public view and

maintain verifiable records. As such, organizations/bodies from which the certificate shall be

considered as as are as follows :

 Goverments/Semi Government Departments, PSUs and other Govertment

institutions like ONGC,BPCL, IOCL, HPCL etc.

The certificate from above mentioned organizations/bodies shall be certified by any

Charted Accountant will be considered Only.

(Escalation factor as mentioned below shall be used to bring the value of such completed

works to the level of financial year 2025-26)

Year Financial Year Enhancement Factor

Sub contractors experience and resources shall not be taken into account in determining the

bidder’s compliance with the qualifying criteria.

4.2 Organisation & Management

a. Memorandum of association/ articles of association/ partnership agreement etc.

b. Certificate of class of registration

4.3 Financial Status

4.3.1 Achieved an Average Annual financial turnover (in similar type of works only) during the last

3 years, ending 31st March of the previous financial year should be at least 30% of the

estimated cost put to Tender. It should be duly certified by Chartered Accountant.

4.3.2 Escalation factor as mentioned above shall be used to bring the value of such completed

works to the level of financial year 2020-21.

Signature of Bidder Page

Ahmedabad Municipal Corporation

4.3.3 If company did not exist for the last 5 years, corresponding figure for the year is to be taken

4.3.4 The agency should also produce solvency certificate issued and valid in current year for an

amount equal to 20% of the Estimate put to tender.

4.3.5 Bid Capacity

Bidders who meet the minimum qualification criteria will be qualified only if their available

bid capacity is more than the total bid value. The available bid capacity will be calculated as

Available Bid capacity = (A* N* 2 - B)

A = Maximum value of similar works executed in any one year during the last five years

(escalation factor as specified in this section shall be used to bring/calculate the

maximum value of works to the level of financial year 2020-21) taking into account the

completed as well as works in progress.

N = Number of years prescribed for completion of the works for which bid is invited.

B = Value of existing commitments and on-going works to be completed during the next N

years (period of completion of the works for which bid is invited)

4.4 Sub-Contractors' experience and resources shall not be taken into account in determining the

bidder's compliance with the qualifying criteria.

4.5 Performance of Bidder in AMC Work

If works carried out by the bidder in last three years are found to be inferior quality or if the

bidder is alleged for malpractice in the tenders allotted to him in last three year, then to accept

or reject his tender, shall be sole discretion of Municipal Commissioner, A.M.C. i.e. Municipal

Commissioner is at his sole discretion may accept or reject the tender and the decision of

Municipal Commissioner shall be bound to the bidder.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to

be disqualified if they have,

a. Made misleading or false representations in the forms, statements, affidavits and

attachments submitted in proof of the qualification requirements; and/or

b. Record of poor performance such as abandoning the works, not properly completing

the contract, inordinate delays in completion, litigation history, or financial failures

etc. or debarring from AMC work etc.

c. Tampered the bid document in any manner.

d. Colluded with other prospective bidders for this work to arrive at quoted prices for

the purpose of restricting competition.

e. Indulged in inducement of any official of AMC and/or their consulting engineer and

other advisors in any manner whatsoever.

f. Proposal not submitted in accordance with this tender.

g. During validity of the proposal, or its extended period, if any, the bidder changes his

commercial terms.

h. The bidder qualifies the proposal with his own conditions.

i. Proposal is received after due date and time.

j. Commercial proposal is enclosed with the same envelope as technical proposal

k. The envelope does not show on the outside the reference of bid and thus gets

opened before the due date of opening.

l. The E.M.D. is not deposited in full and in the manner as specified in the clause of

Earnest Money Deposit.

Signature of Bidder Page

Ahmedabad Municipal Corporation

m. The tender is in a language other than English or dose not contains its English

Translation in case of other language adopted for tender preparation.

n. The tender documents received are not duly signed by authorized person.

o. The validity of tender is less than what is stated in the tender.

p. Any of the page or pages of tender is/are removed or replaced.

q. Any condition which affect the cost.

6.0 Cost of Bidding

The bidder shall bear all costs associated with the preparation and submission of his Bid.

Employer will in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and

familiarise himself with the site of Works and its surroundings including source of earth,

water, road aggregates etc. and obtain all information that may be necessary for preparing

the Bid and entering into a contract for construction of the Works. The costs of visiting the

Site shall be at the Bidder's own expense.

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

i. If the quantity stipulated in the tender items varies or the scope of work changes

and thereby total amount of work increases / decreases up to any extent.

and thereby total amount of work increases / decreases up to any extent.

ii. If the works gets delayed / postponed for some administrative / technical decision

iii. If the items stipulated in the tender shall not be executed as per site condition/

requirements. No claim shall be entertained for the same.

iv. No idle charges shall be paid to contractor for machinery and man power if remain

idle and no claim shall be entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any)

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

1. Bill of Quantities

9.2 The bidder is expected to examine carefully all instructions, conditions of contract, contract

data, forms, terms, technical specifications, Schedule B, forms, Annexers in the bid

document. Failure to comply with the requirements of bid documents shall be at the

bidder’s own risk. Bids which are not substantially responsive to the requirements of the bid

documents shall be rejected.

1.0 Clarification of bidding documents :- As mentioned in the clause - 11 of Pre Bid Meeting

11.0 Pre Bid Meeting as mentioned in tender document

Signature of Bidder Page

Ahmedabad Municipal Corporation

12.0 Amendment of Bidding Documents

12.1 Before the deadline for submission of bids, the Employer may modify the bidding documents

by issuing addendum.

12.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on

website www.nprocure.com The prospective bidder shall refer to website to check any

addendum before 48 hours of opening of bids. AMC will not give any advertisement for the

12.3 To give prospective bidders reasonable time in which to take an addendum into account in

preparing their bids, the Employer may, at his desecration, extend as necessary the deadline

for submission of bids.

12.4 Prospective bidders should attach the addendum made for the work & if fails to do so than

also the changes made through such addendum shall be appliacable & bound to the bidder.

C. PREPARATION OF BIDS

13.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

14.0 Documents comprising bid

14.1 The e bid submitted by the bidder shall be in two separate parts.

A. Technical Bid

B. Financial Bid

14.2 To qualify for award of the contract, each bidder must upload the scanned copies of

following documents along with the submission of online bidding:

1. Scanned copy of Tender Fee

2. Scanned Copy of EMD

3. Scanned Copy of Required Registration Certificate Register in Govt. R&B/CPWD/AMC

or equivalent register with any other state Govt. or institutions. Bidder who is not

registered in A.M.C., shall have to register in A.M.C. before claiming 1 st R.A. Bill.

4. Scanned copies of original documents defining the constitution or legal status,

place of registration, and principal place of business

5. Scanned Copy of Solvency Certificate

6. An affidavit on a Stamp Paper, duly attested from the Notary Public, that the

information furnished with the bid documents is correct in all respects.

7. scanned copy of valid written power of attorney of the signatory of the Bid to

commit the Bidder

Failure to submit these certificates/documents shall make the bid non-responsive.

14.3 Though, the scanned copies of above mentioned documents is required to be uploaded

during submission of e-bid on the e-tendering portal of (n) procure, however, following

original documents in physical form in two copies, one marked as “original” and other

marked as “Duplicate”, shall be submitted in a sealed envelope by 15:00 Hrs on the date of

physical submission of bid and addressed to the addressee given in the NIT duly super

scribed “Name of Work, Bid due date and time, Name and address of the bidder”

1. Bid security (EMD)

2. Tender Processing Fee

3. Certificate of in Road Works in PWD in Govt. R&B/CPWD/AMC or equivalent register

with any other state Govt. or institutions. Bidder who is not registered in A.M.C.,

shall have to register in A.M.C. before claiming 1st R.A. Bill.

4. Memorandum of Association/Articles of Association as filed before the Register of

Signature of Bidder Page

Ahmedabad Municipal Corporation

5. Original copy of valid written Power of Attorney of the signatory (whose digital

signature certificate is used during e-tender submission) of the bidder to commit the

bid. This power of Attorney shall not be older than 1 year from the date of last date

of online submission of tender.

6. If the application is made by a firm in partnership, it shall be signed by all the

partners of the firm, above their full names and current addresses or by a partner

holding the power of attorney of the firm by signing of the application in which case

a certified copy of power of attorney shall accompany the application. A certified

copy of the partnership deed, current address of the firm and the full names, and

current address of all the partners of the firm shall also accompany the application.

7. If the application is made by limited company or a limited corporation, it shall be

signed by a duly authorized person holding the power of attorney for signing the

application which case, a certified copy of the power of attorney shall accompany

the application. Such limited company or corporation will be required to furnish

satisfactory evidence of its existence before the contract is awarded.

8. Bidder shall have to submit the power of attorney for the person who will going to

sign the measurement book. In case of employee, If the holder of this power of

Attorney will leave the job, the contractor immediately shall have to submit the

fresh power of Attorney for the newly appointed person.

9. Bidder's financial capability and standing over at least past five years and relevant

10. Income Tax Return of last 3 consecutive financial Years.

11. Bidder's present commitments.

12. The technical ability and qualifications of the bidder. Details of technical personnel

with their qualification & experience as per Statement No.4.

13. A list of the equipment the bidder possessed and that which he proposed to

acquires and use for the purpose related to the work

14. Bank Solvency Certificate.

15. Affidavits duly notarized (as per the format provided in Section III)

16. Notarised copy of experience certificate from concerned department not ranked

below Executive Engineer or equivalent, showing that the Bidder has successfully

completed required numbers of similar work in his own name.

17. Undertakings mentioned in Section III (Qualification Information) of this document.

18. Statements no. 1 to 6 with notarized supporting documents

19. Audited balance sheets for last three years.

20. Any other material / information required to be submitted in accordance with these

Instructions to Bidders (ITB)

15.0 Bid Prices

15.1 The contract shall be for the whole works as described in Bill of Quantity as described in sub-

Clause 1.0 including the schedule-B based on the percentage rate in the Bill of Quantities

submitted by the bidder..

15.2 All duties, taxes, and other levies payable by the contractor under the contract, or for any

other cause shall be included in the rates, prices and total Bid Price submitted by the Bidder,

except otherwise stated in the Bid document. Employer will not compensate the bidder

(contractor) for any change in duties, taxes and other levies payable by the contractor under

the contract and any other reasons.

15.3 The percentage rate and bid price quoted by the bidder shall be fixed up to the completion

of Work and shall not be subject to adjustment on any account, except where expressly

specified, otherwise, in the contract.

16.0 Currencies of Bid and Payment

Signature of Bidder Page

Ahmedabad Municipal Corporation

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in

17.0 Bid Validity

17.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a

shorter period shall be rejected by the Employer as non-responsive.

17.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may

request that the bidders may extend the period of validity for a specified additional period.

The request and the bidders' responses shall be made in writing or by cable. A bidder may

refuse the request without forfeiting his bid security. A bidder agreeing to the request will

not be required or permitted to modify his bid, but will be required to extend the validity of

his bid security for a period of the extension, and in compliance with Clause 36.0 in all

18.0 Earnest Money / Bid Security

18.1 The Bidder shall furnish, a Bid Security of the amount as shown in para 6 of the Table of IFB

as part of his bid, in the form of D.D. or pay order or Bank Guarantee in favour of Municipal

Commissioner, Ahmedabad valid for 60 days.

18.2 The issuing branch of the bank guarantee shall be of Ahmedabad / Gandhinagar City only.

A. Guarantees issued by following banks will be accepted as SD/EMD on permanent basis.

All nationalized Banks

A. Guarantees issued by following banks will be accepted as SD/EMD on permanent

basis. All nationalized Banks B. Guarantees issued by following banks will be accepted as

SD/EMD for the period up to March- 31, 2026. The validity cut-off date in the GR is with

respect to the date of issue of Bank Guarantee irrespective of the date of termination of Bank

1. Commercial Banks :-

2. A U Small Finance Bank

3. Bandhan Bank

4. Barclays Bank

5. City Union Bank

7. DBS Bank India Limited

9. Equitas Small Finance Bank

10. ESAF Small Finance Bank

11. Federal Bank

16. IDFC First Bank

17. Jammu and Kashmir Bank

18. Jana Small Finance Bank

19. Karnataka Bank

20. Karur Vysya Bank

Signature of Bidder Page

Ahmedabad Municipal Corporation

21. Kotak Mahindra Bank

22. South Indian Bank

23. Standard Chartered Bank

24. Tamilnadu Mercantile Bank

25. Utkarsh Small Finance Bank

2. Co-operative and Rural Banks Of Gujarat :-

1. The Ahmedabad Mercantile Co-operative Bank Limited

2. Nutan nagrik Sahakari Bank Limited

3. Rajkot Nagarik Sahakari Bank Limited

4. Saraswat Co-operative Bank

5. SBPP Co-operative Bank

6. SVC Co-operative Bank

7. The Cosmos co-opretive Bank

8. The Gujarat State Co-Operative Bank

9. The Mehsana Urban Co-operative Bank Limited

10. The Surat District Co-operative Bank

11. The Surat Peoples Co-operative Bank

12. The Kalupur Commerical Co-operative Bank Limited

13. The Panchmahal District Co-operative Bank

14. The Baroda District Co-operative Bank

15. Baroda Gujarat Gramin Bank

16. Saurashtra Gramin Bank

Signature of Bidder Page

Ahmedabad Municipal Corporation

18.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as

non-responsive.

18.4 Any bid having bid security for lesser value and shorter validity period shall be treated as

non-responsive.

18.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be

returned as promptly as possible.

(b) The bid security of the successful bidder, along with second and third lowest central

tenders, will be returned when the successful bidder has furnished the required

security deposit and signed the agreement.

18.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the

Agreement and furnished the required security deposit.

18.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) Sign the Agreement; or

(ii) Furnish the required security deposit.

(iii) commence the work after signing the agreement within 15 days

18.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the

bank guarantee shall be of Ahmedabad City only.

18.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp

papers of requisite value in accordance with the stamp Act applicable to that particular state

of Indian Union, where executed.

18.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly

indicate in (block letters) his name, designation, Power of Attorney No. / Signing Power No.

18.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by

the executing officers and the last page shall be signed in full, indicating the particulars as

aforesaid (sub-para 36.10) under the seal of the Bank.

19.0 Alternative Proposal by Bidders

Bidders shall submit offers that comply with the requirements of the bidding Documents.

Alternatives will not be considered, unless specifically asked for by the Employer.

20.0 Format and Signing of Bid

20.1 The Bidder shall prepare one original copy of the documents comprising the bid as described

in Clause 14.3 of these Instructions to Bidders, bound with the volume containing the

‘Technical Bid in separate parts and clearly marked "ORIGINAL" and "DUPLICATE" as

appropriate. In the event of discrepancy between them, the original shall prevail.

20.2 The original and duplicate of the Bid shall be typed or written in indelible ink and shall be

signed by a person or persons duly authorized to sign on behalf of the Bidder. All pages of

the Bid where entries or amendments have been made shall be initialled by the person or

persons signing the bid.

20.3 Pages of tender documents shall be initialed by the bidder with company’s seal.

20.4 The Bid shall contain no alterations or additions, except those to comply with instructions

issued by the Employer, or as necessary to correct errors made by the bidder, in which case

such corrections shall be initialled by the person or persons signing the bid.

20.5 Sufficiency of bid: The bidder shall be deemed to have satisfied himself as to the correctness

and sufficiency of the bid, all of which shall, cover all his obligations under the contract and

all matters and things necessary for the proper execution and completion of Works and the

remedying of the defects therein.

Signature of Bidder Page

Ahmedabad Municipal Corporation

D. SUBMISSION OF BIDS

21.0 Sealing and Marking of Bids

21.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes

and the three sealed envelopes shall be sealed in an outer envelope. The Bid envelopes

shall be marked as follows:-

1. Tender fee -

2. Bid Security

1. Complete Tender Document with all necessary qualification related documents (in two

Above two envelopes shall be kept in one envelope and it should be marked as “Technical

Bid” and sealed. This Outer envelope should mention the name of firm of bidder, his

address, contact details & name of the work.

21.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- Project

2 nd floor,Sardar patel bhavan,Danapith,

c) Bear the following identification:

Indicate the name and address of the bidder.

21.3 If the outer envelope is not sealed and marked as above, the Employer will assume no

responsibility for the misplacement or premature opening of the bid.

22.0 DEADLINE FOR SUBMISSION OF THE BID

22.1 Complete Bids (including Technical bid and necessary documents) must be received by the

Employer at the address specified in bid information not later than the date indicated on the

face sheet of the document. In the event of the specified date for the submission of bids

declared a holiday for the Employer, the Bids will be received up to the appointed time on

the next working day. The Bidder is further required to submit Documents in Physical Form

on or before the Bid Due Date and before the time of submission as specified in NIT, at the

following address:

Assistant Manager- Project

2 nd floor,Sardar patel bhavan,Danapith,

22.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-

tendering portal on account of delay in submission at bidder's end. Bidder shall ensure that

they submit the bid well before the "Due Date & Time of Bid- Submission". AMC shall not be

responsible if bidder is not able to submit the bid on account of failure in network/internet

connection or any other technical reason.

22.3 The Employer may extend the deadline for submission of bids by issuing an amendment in

accordance with Clause 12.0, in which case all rights and obligations of the Employer and the

bidders previously subject to the original deadline will then be subject to the new deadline.

22.4 All bidders are requested to see the website of (n) procure for corrigendum as per clause no.

22.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and

returned unopened to the bidder.

Signature of Bidder Page

Ahmedabad Municipal Corporation

Any Bid received by the Employer after the deadline prescribed in NIT will be returned

unopened to the bidder.

24.0 MODIFICATION & WITHDRAWAL OF BID

24.1 Bid shall not be modified by the bidder after the deadline for submission of bids.

24.2 Withdrawal of a bid during the interval between the deadline for submission of bids and the

expiration of the period of bid validity specified in NIT may result in the forfeiture of the Bid

Security pursuant to Clause -18.

24.3 If during Tender validity period, the bidder withdraws his tender, the tender security

(Earnest Money Deposit) shall be forfeited.

E. BID OPENING & EVALUATION

25.0 BID OPENING

25.1 The Employer will open all the Bids received (except those received late), in the presence of

the Bidders or their representative who choose to attend. In the event of the specified date

of Bid opening being declared a holiday for the Employer, the Bids will be opened at the

appointed time and location on the next working day.

25.2 Bids for which acceptable notice of withdrawal has been submitted pursuant to Clause -

shall not be opened and shall be returned.

25.3 The envelope containing “Technical Bid” shall be opened. The amount, form, and validity of

the bid security furnished with each bid will be announced. If the bid security furnished does

not confirm to the amount and validity period as specified in the NIT, and has not been

furnished as specified, the remaining technical bid will be returned to the bidder terming it

as non-responsive.

25.4 Representatives of the bidders (maximum of two) who choose to attend may attend the

online opening of the bids on the Place, date & time as mentioned above.

The bidders or their representatives who are present shall sign attendance sheet evidencing

their attendance.

25.5 (i) Subject to confirmation of the bid security by the issuing Bank, the bids accompanied

with valid bid security will be taken up for evaluation with respect to the qualification

Information and other information furnished in Part I of the bid pursuant to Clause

(ii) After receipt of confirmation of the bid security, the bidder will be asked in writing

(usually within 7 days of opening of the Technical Bid) to clarify his technical bid, if

necessary, with respect to any rectifiable defects.

(iii) The bidders will respond in not more than 4 working days of issue of the clarification

(iv) On receipt of these clarifications AMC finalise the list of responsive bidders whose

financial bids are eligible for consideration.

25.6 As soon as possible, AMC will finalize the list of responsive bidders whose financial bids are

eligible for consideration. However, to assist in the examination, evaluation of technical bids,

the Employer may at his discretion, ask any bidder for clarification of his bid, and any

additional documents in support of clarification of bid.

25.7 The Employer shall inform the bidders, whose technical bids are found responsive, of the

date, time, and place of opening of the financial bids. The bidders so informed, or their

representative, may attend the meeting of opening of financial bids.

25.8 At the time of opening of “Financial Bid”, the names of the bidders who were found

responsive will be announced. The bids of only these bidders will be opened.

Information relating to the examination, clarification, evaluation, qualification, and

comparison of Bids and recommendations for the award of a contract shall not be disclosed

to Bidders or any other persons not officially concerned with such process until the award to

Signature of Bidder Page

Ahmedabad Municipal Corporation

the Successful Bidder has been announced. Any effort by a Bidder to influence the

Employer's processing of Bids or award decisions may result in the rejection of his Bid.

27.0 CLARIFICATION OF FINANCIAL BID

27.1 To assist in the examination, evaluation, and comparison of Bids, the Employer may, at his

discretion, ask any Bidder for clarification of his Bid, including breakdowns of % above or

below amount put to tender. The request for clarification and the response shall be in

writing or fax or e-mail, but no change in the price or substance of the Bid shall be sought,

27.2 No Bidder shall contact the Employer on any matter relating to his bid from the time of the

bid opening to the time the contract is awarded. If the Bidder wishes to bring additional

information to the notice of the Employer, he should do so in writing.

27.3 Any effort by the Bidder to influence the Employer in the Employer's bid evaluation, bid

comparison or contract award decisions may result in the rejection of the Bidders’ bid.

28.0 EXAMINATION OF BID & DETERMINATION OF RESPONSIVENESS

28.1 Prior to evaluation of bids, the Authority shall determine whether each bid is responsive to

the requirements of the tender or not. Any bid shall be considered responsive only if:

(a) it is received as per format mentioned in the bid documents.

(b) it is received before the Application Due Date including any extension thereof.

(c) it is signed, sealed, bound together in hard cover, and marked as stipulated in

(d) it is accompanied by the Power of Attorney as specified in Clause 14.3.

(e) it contains all the information and documents (complete in all respects) as requested

in this TENDER;

(f) it contains information in formats same as specified in this TENDER;

(g) it contains certificates from its statutory auditors in the formats specified at

Appendix-I of the TENDER for each Eligible Project;

(h) it contains an attested copy of the receipt for payment of Tender fee & E.M.D.;

(i) it does not contain any condition or qualification; and

(k) it is not non-responsive in terms hereof.

A responsive Bid is the one which conforms to all the terms, conditions and specification of

the Bidding documents including time for completion, without material deviation or

reservation. A material deviation or reservation is the one which (a) affects in any substantial

way the scope, quality or performance of the Works; (b) which limits in any substantial way,

the Employer’s rights or the Bidder’s obligations under the Contract, or (c) whose

rectification would affect unfairly the competitive position of other Bidders presenting

responsive Bids.

28.2 If a “Technical Bid” is not substantially responsive, it will be rejected by the Employer, and

may not subsequently be made responsive by correction or withdrawal of the non-

conforming deviation or reservation.

29.0 EVALUATION OF BID

29.1 The Employer will evaluate and compare only the Bids determined to be substantially

responsive in accordance with Clause

29.2 If the Bid of the Successful Bidder is seriously unbalanced in relation to the Engineer's

estimate of the cost of work to be performed under the contract, the Employer may require

the Bidder to produce detailed % quote price analysis for any or all items of the BOQ, to

demonstrate the internal consistency of those prices with the construction methods and

schedule proposed. After evaluation of the % quote price analysis, the Employer may require

that the amount of the Security Deposit set forth in Clause -18 be increased at the expense

of the Successful Bidder to a level sufficient to protect the Employer against financial loss in

the event of default of the Successful Bidder under the Contract.

Signature of Bidder Page

Ahmedabad Municipal Corporation

29.3 A bid which unrealistically % quoted priced low and which cannot be substantiated

satisfactorily by the bidder may be rejected as ‘non-responsive’.

29.4 In comparing tenders, the AMC shall consider factors such as the time of completion,

efficiency, and reliability of construction method proposed, compliance with the

specification, relative quality, the operation, maintenance and replacement cost of structure

and plant and also the qualifying criteria for the evaluation of tender. The price bids of only

those bidders who are pre / post qualified will be opened in the presence of the contractor.

30.0 EMPLOYER’S RIGHT TO ACCEPT OR REJECT ANY OR ALL BIDS

30.1 Notwithstanding anything contained in this Bid, the Authority reserves the right to accept or

reject any Application and to annul the Bidding Process and reject all Applications/ Bids, at

any time without any liability or any obligation for such acceptance, rejection or annulment,

and without assigning any reasons therefore. In the event that the Authority rejects or

annuls all the Bids, it may, in its discretion, invite all eligible Bidders to submit fresh Bids

30.2 The Authority reserves the right to reject any Application and/ or Bid if:

(a) at any time, a material misrepresentation is made or uncovered, or

(b) the Applicant does not provide, within the time specified by the Authority, the

supplemental information sought by the Authority for evaluation of the Application.

If such disqualification/ rejection occur after the Bids have been opened and the

Highest Bidder gets disqualified/ rejected, then the Authority reserves the right to:

(i) invite the remaining Bidders to match the Highest Bidder/ submit their Bids in

accordance with the TENDER; or

(ii) take any such measure as may be deemed fit in the sole discretion of the Authority,

including annulment of the Bidding Process.

33.3 In case it is found during the evaluation or at any time before signing of the agreement or

after its execution and during the period of work, that one or more of the pre-qualification

conditions have not been met by the Applicant, or the Applicant has made material

misrepresentation or has given any materially incorrect or false information, the Applicant

shall be disqualified forthwith if not yet appointed as the Concessionaire either by issue of

the LOA or entering into of the Concession Agreement, and if the Applicant/SPV has already

been issued the LOA or has entered into the Concession Agreement, as the case may be, the

same shall, notwithstanding anything to the contrary contained therein or in this TENDER, be

liable to be terminated, by a communication in writing by the Authority to the Applicant,

without the Authority being liable in any manner whatsoever to the Applicant and without

prejudice to any other right or remedy which the Authority may have under this TENDER, the

Bidding Documents, the Concession Agreement or under applicable law.

30.4 The Authority reserves the right to verify all statements, information and documents

submitted by the Applicant in response to the TENDER. Any such verification or lack of such

verification by the Authority shall not relieve the Applicant of its obligations or liabilities

hereunder nor will it affect any rights of the Authority hereunder.

F. AWARD OF CONTRACT

31.0 AWARD CRITERIA

Subject to Clause 32, the Employer will award the Contract to the Bidder whose Bid has been

(i) to be substantially responsive to the Bidding documents and who has offered the

evaluated Bid Price.

(ii) To be within the available bid capacity adjusted to account for his bid price which is

evaluated the lowest in any of the packages opened earlier than the one under

Signature of Bidder Page

Ahmedabad Municipal Corporation

In no case, the contract shall be awarded to any bidder whose available bid capacity is less

than the evaluated bid price, even if the said bid is the lowestevaluated bid. The contract will

in such case be awarded to the next lowest bidder at his evaluated bid price.

32.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

32.1 The Bidder whose Bid has been accepted will be notified of the award by the Employer prior

to expiration of the Bid validity period by writing, facsimile or e-mail confirmed by registered

letter. This letter (hereinafter and in the Conditions of Contract called the “Letter of

Acceptance” as per format given in Annexure – IV) will state the sum that the Employer will

pay the Contractor in consideration of the execution, completion, and maintenance of the

Works by the Contractor as prescribed by the Contract (hereinafter and in the Contract

called the “Contract Price”).

32.2 The notification of award will constitute the formation of the Contract, subject only to the

furnishing of a Security Deposit in accordance with the provisions of Clause-34.

32.3 The agreement will incorporate all correspondences between the Employer and the

Successful Bidder. It will be signed by the Employer and the Successful Bidder.

33.0 SIGNING OF CONTRACT AGREEMENT

33.1 The Employer and the successful bidder shall enter into a Contract Agreement (the Form of

Agreement is placed at Annexure-V) within 28 days after the successful bidder (hereinafter

called the Contractor) receives the Letter of Acceptance, unless they agree otherwise,

subject to furnishing the performance security as laid down in ITB Clause-34 before signing

the Agreement with the Employer.

33.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly

notify the other Bidders that their Bids have been unsuccessful and release their Earnest

Money Deposit/Bid Security.

34.0 SECURITY DEPOSIT

34.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to

the Employer a security deposit in the form of Bank Guarantee for an amount equivalent to

5% of the Contract Price valid for the period of 45 days after the expiry of defect liability

period of 36 months. Following conditions DLP is not considered for patch work. (1) Patch

work done above drainage break down work repaired work, drainage work or any other

repairing work. (2) Hand laying patch also not consider. Hand laying patch means (a) Paver

movement is not possible. (b) Patch width less than 3m and length of patch less than 20m.

(3) Any patch work damage due to proble of base work settlement.

34.2 The performance security shall be in the form of a Bank Guarantee in the name of the

Employer, from Ahmedabad / Gandhinagar branch of any Banks mentioned in the clause no.

18.2 of this tender documents.

34.3 This security deposit shall be released only after the submission of performance bank

guarantee @ 5% of final bill amount including price variation.

34.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of

Bank guarantee or late renewal of bank guarantee for the number of days delayed for

submission or discontinuity of the bank guarantee.

34.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same

verbatim as per the format. Bank Guarantee shall be submitted on right value of stamp

paper and for correct value of contract.

34.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 34.1 shall

constitute sufficient grounds for cancellation of the award and forfeiture of the Bid Security.

34.6 In case of any contract amendment during execution of the contract enhancing value of the

contract the BG value shall be enhanced accordingly. Validity of BG shall be commercial

terms and conditions of the tender.

Signature of Bidder Page

Ahmedabad Municipal Corporation

34.7 All compensation or other sums of money payable by the Contractor to the Employer under

the terms of this Contract or any other contract or on any other account whatsoever may be

deducted from Security Deposit. Also in the event of the Contractor's Security Deposit being

reduced by reasons of such deductions, as aforesaid, the Contractor shall, within 14 days of

receipt of notice of demand from the Engineer-in-Charge, make good the deficit in Security

34.8 Should there arise any occasion under the Contract due to which the periods of validities of

Bank Guarantees as may have been furnished by the Contractor from time to time, are

required to be extended/renewed, the Contractor shall get the validity periods of such

guarantees extended/renewed, and furnish these to the Engineer-in- Charge one month

before the expiry date of the aforesaid Guarantees originally furnished failing which the

existing Bank Guarantees shall be invoked by the Engineer – in – charge. Also in case of any

deficit in securities on any account as might occur or is noticed, the Contractor shall

forthwith recoup/replace the same with acceptable Security Deposit.

34.10 The Bank Guarantee shall be extended within the expiry dates wherever activities as per

contract are not completed in all respects.

34.9 The Security Deposit less any amount due shall, on demand, be returned to the contractor

after 45 days of expiry of Defects Liability Period. No interest on the amount of Security

Deposit shall be paid to the Contractor at the time of release of Security Deposit as stated

34.10 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at

Employer’s office within 15 days of LOA.

35.0 Advance Payment and Security

The Employer will not provide any advance payment.

36.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final

and binding to the bidder.

37.0 Corrupt or Fraudulent Practices

37.1 The Employer will reject a proposal for award if it determines that the Bidder recommended

for award has engaged in corrupt or fraudulent practices in competing for the contract in

question and will declare the firm ineligible, either indefinitely or for a stated period of time.

37.2 The bidder and their respective officers, employees, agents and advisers shall observe the

highest standard of ethics during the bidding process. Notwithstanding anything to the

contrary contained herein, the Employer may reject any bid without being liable in any

manner whatsoever to the bidder if it determines that the bidder has, directly or indirectly

or through an agent, engaged in corrupt practice, fraudulent practice, coercive practice,

undesirable practice or restrictive practice in the bidding process.

37.3 Without prejudice to the rights of the Employer under Clause 30 hereinabove, if an bidder is

found by the Employer to have directly or indirectly or through an agent, engaged or

indulged in any corrupt practice, fraudulent practice, coercive practice, undesirable practice

or restrictive practice during the bidding process, such bidder shall not be eligible to

participate in any tender issued by the Employer during a period of 2 (two) years from the

date such bidder is found by the Employer to have directly or indirectly or through an agent,

engaged or indulged in any corrupt practice, fraudulent practice, coercive practice,

undesirable practice or restrictive practice, as the case may be.

37.4 For the purposes of this Clause 37, the following terms shall have the meaning hereinafter

respectively assigned to them:

(a) “corrupt practice” means the offering, giving, receiving, or soliciting, directly or

indirectly, of anything of value to influence the actions of any person connected with

the bidding process (for avoidance of doubt, offering of employment to, or

Signature of Bidder Page

Ahmedabad Municipal Corporation

employing, or engaging in any manner whatsoever, directly or indirectly, any official

of the Employer who is or has been associated in any manner, directly or indirectly,

with the bidding process or has dealt with matters concerning the Contract or arising

there from, before or after the execution thereof, at any time prior to the expiry of

one year from the date such official resigns or retires from or otherwise ceases to be

in the service of the Employer, shall be deemed to constitute influencing the actions

of a person connected with the bidding process); engaging in any manner

whatsoever, whether during the bidding process or after the award or after the

execution of the Contract, as the case may be, any person in respect of any matter

relating to the Works, who at any time has been or is a legal, financial or technical

adviser of the Employer in relation to any matter concerning the Works;

(b) “Fraudulent practice” means a misrepresentation or omission of facts or suppression

of facts or disclosure of incomplete facts, in order to influence the bidding process;

(c) “Coercive practice” means impairing or harming or threatening to impair or harm,

directly or indirectly, any person or property to influence any person’s participation

or action in the bidding process;

(d) “undesirable practice” means establishing contact with any person connected with

or employed or engaged by the Employer with the objective of canvassing, lobbying

or in any manner influencing or attempting to influence the bidding process; and

(f) “Restrictive practice” means forming a cartel or arriving at any understanding or

arrangement among bidder with the objective of restricting or manipulating a full

and fair competition in the bidding process.

38.0 POLICY FOR TENDER UNDER CONSIDERATION

Tender shall be termed to be under consideration from the opening of the tender until such

time any official announcement or award is made. While tenders are under consideration,

bidders and their representative or other interested parties are advice to refrain from

contracting by any corporation personnel or representative on matters related to the

tenders under study. The AMC representative if necessary will obtain clarification on tenders

by requesting such information from any or all the bidders, either in writing or through

personal contacts may be necessary. The tender will not be permitted to change the

substance of his tender after tenders have been opened. This includes any post tender price

revision. Non compliance with his provision shall make the tender liable for rejection.

39.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting

from Contractors completed or under execution by him over last five yea` If the details of

Litigation History are hidden by the Bidder and later on it comes to the knowledge of the

Employer, the Bidder shall be disqualified for the proposed work and other appropriate

actions shall be taken against the bidder.

40.0 QUOTING RATES:

40.1 The Tenderer shall quote the rate per unit for all items listed in Schedule B in figures as well

as in words. Thereafter the system will work out the total amount of each item in Column

as in words. Thereafter the system will work out the total amount of each item in Column

No. 7 of Schedule B and sum-up the total at the end of column No.7 on each page and on

last page of Schedule B. After striking the total of all items, he may give rebate if he desires

on the total amount so worked out and thereafter express in the figures, as the net amount

on the total amount so worked out and thereafter express in the figures, as the net amount

of his offer which will termed as “Tendered Amount”.

40.2 Tenderers are normally not permitted to suggest any alteration in the works specified in the

tender form or in the time allowed for carrying out the work or any other conditions of any

sort. However, if it is felt necessary by the tenderer to have any conditions, he shall have to

clearly mention the same in very clear terms in the appropriate section of technical bid. The

tender will have to fill in necessary details online in ‘technical bid’ and ‘price-bid’ separately.

Signature of Bidder Page

Ahmedabad Municipal Corporation

No such tender shall include more than one work but contracts who wish to tender for two

or more works shall submit a separate tender for each work online.

40.3 If price-bid contains any conditions, the same shall be rejected outright.

Seal and Signature of the Bidder Add CityEngineer

Date: AhmedabadMunicipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Definitions

1.1 In the contract (as hereinafter defined) the following words and expressions shall have the

meaning hereby assigned to them, except where the context otherwise requires.

1.2 Terms which are defined in the Contract Data are not also defined in the Conditions of

Contract but keep their defined meanings. Capital initials are used to identify defined terms.

“Commencement Date” means the date on which the Contractor receives from the Engineer

the notice to proceed with works.

“Time for completion” means the time for completing the execution of the works and

passing the tests on completion of the works calculated from the commencement date.

“Contract” means the contract agreement between the Employer and the Contractor to

execute, complete and maintain the work as described in details in various documents listed

in clause 4 of “ The Contract Agreement “.

“Specifications” means the specification of the works included in Contract and/or

modifications/alterations made thereto by Contractor and approved by the Engineer.

“Drawings” means all drawings, calculations, and technical information of a like nature

provided by the Engineer to the Contractor.

“Contract Data” means the documents and other information which comprise the Contract.

“Contractor” means a person / corporate body / registered company / consortium of

companies who's Bid to carry out the Works has been accepted by the Employer and the

legal successors in title to such person / corporate body / registered company / consortium

“Sub contractor” means any person/corporate body/ registered company/ a consortium of

companies to whom a part of the works have been subcontracted with the consent of the

“Contractor's Bid’ means the priced offer to the Employer for the execution of the works

and remedying defects therein in accordance with various terms and conditions set out in

the Contract as accepted by “ Letter of Acceptance.”.

Contract Price means the price stated in the Letter of Acceptance and thereafter as adjusted

in accordance with the provisions of the Contract.

“Retention money” means the aggregate of all money retained by Employer pursuant to

clause 18 of these Special conditions of contract.

“Interim Payment Certificate” means any payment certificate issued by the Engineer other

than the final payment certificate.

“Final Payment Certificate” means the certificate of payment issued by the Engineer

pursuant to clause 40 of these Conditions of Contract.

A day means calendar days; months mean calendar months.

Signature of Bidder Page

Ahmedabad Municipal Corporation

“Defect” means any part of the works not completed in accordance with the Contract.

“Employer” means The Ahmedabad Municipal Corporation and is the party who will employ

the Contractor to carry out the Works.

“Engineer” means the person / organisation appointed by the Employer as named in the

Contract Data or as informed to the contractor in writing for the purposes of the contract.

The Contractor is obliged to accept the Engineer appointed by the Employer.

“Engineer’s Representative” means the person appointed by the Engineer for carrying out

such duties and exercising such authority as delegated to him from time to time by the

Engineer with written intimation to the Employer and the Contractor.

“Equipment” means the Contractor's machinery and vehicles brought temporarily to the

Site to construct the Works.

“Completion Date” means the date arrived at by counting the Contract period (inclusive of

any time extensions granted by the Engineer from time to time) after the commencement

“Plant” means any integral part of the Works, which is to have a mechanical, electrical,

electronic or chemical or biological function.

“Site” means the places provided by the Employer where the works are to be executed and

any other places as may be specifically designated in the contract as forming part of the site.

“Specification” means the Specification of the Works included in the Contract and any

modification or addition made or approved by the Engineer.

“Works” means permanent works and/or temporary works.

"Similar Works" means pothole/heavy patchwork with milling and filling with cold mix/Hot

mix material (Production from Batch mix plant 100-120 TPH only)”

“Permanent works” means the permanent works to be executed in accordance with the

“Temporary Works” are works of every kind in or about the permanent works designed,

constructed, installed, and removed by the Contractor, which are needed for construction or

installation of the Works.

“Cost” means all expenditure on or off site properly accounted and incurred or to be

incurred including all overheads.

“Writing” means all handwritten or typewritten or printed communication including cable,

facsimile, or e mail communication.

1.3 Wherever in the contract provision is made for the giving of notice, consent, approval,

certificate or determination by any person such notice consent, approval, certificate or

determination by any person shall be given in writing unless otherwise specified in the

contract. Any such consent, approval, certificate, or determination shall not be unreasonably

delayed or withheld.

2.0 Interpretation

Signature of Bidder Page

Ahmedabad Municipal Corporation

2.1 In interpreting these Conditions of Contract, singular also means plural, male also means

female or neuter, and the other way around. Headings and marginal notes have no

significance. Words have their normal meaning under the language of the Contract unless

specifically defined. All the notices, consents, approvals, certificates, decisions,

determinations to be given under this contract by all the concerned parties (Employer,

Engineer, and Contractor) shall be given in writing only.

2.2 If sectional completion is specified in the Contract Data, The completion date for each

section of work is arrived at by counting the period of completion assigned for that section

of work from the date of commencement assigned to that section of the work.

2.3 The several documents forming the Contract are to be taken as mutually explanatory to one

another, but in case of ambiguities and/or discrepancies the same shall be explained and

adjusted by the Engineer who shall thereupon issue to the contractor instructions thereon

and in such event unless otherwise provided in the contract, the priority of the documents

forming the Contract shall be as follows:

(1) The notice inviting bids

(2) The Contract Agreement

(3) The instructions to Bidders

(4) The Letter of Acceptance and notice to proceed with the works

(5) The accepted Contractor’s Bid

(6) The Contract Data

(7) The General Conditions of Contract and special conditions of contract

(8) The Technical Specifications

(9) The Drawings

(10) Any other document listed in the Contract Data as forming part of the Contract.

3.0 Language and Law

3.1 The language of the Contract shall be English and the law governing the Contract shall be the

Law as prevailing in India.

3.2 If the Contractor’s authorised representative is not in the opinion of the Engineer, fluent in

English, the Contractor shall have available on site at all times a competent interpreter to

ensure the proper transmission of instructions and information.

4.0 EMPLOYER’S REPRESENTATIVE OR HIS NOMINEE’S DECISIONS

4.1 The persons, duly named in the Contract Data as Employer’s Representative, will decide

contractual matters between the Employer and the Contractor in the role representing the

4.2 Except where otherwise specifically stated, the Engineer-in-Charge as mentioned in the

Contract Data shall be the Employer’s Representative who shall be responsible for

supervising the work being performed by the Contractor and administering the Contract.

4.3 The Employer’s Representative/Engineer-in-Charge may delegate any of the duties and

responsibilities to other people (Employer’s Representative’s nominee / Engineer-in-

Charges’ nominee) after notifying the Contractor and may cancel any such delegation after

notifying the Contractor.

5.0 Communications

5.1 A notice shall be effective only when it is delivered (in terms of the Indian Contract Act).

5.2 All communications from Engineer’s Representative shall have the same effect as though

given by the Engineer. The Engineer shall however retain the authority to disapprove any

work, materials, or Plant in the event of the Engineer’s Representative failing to do so or

revoke the decisions/instructions issued by the Engineer’s Representative.

5.3 All certificates, notices, or instructions to be given to the Contractor by the Employer or the

Engineer under the terms of Contract shall be sent by post, cable, fax, and e-mail to or

Signature of Bidder Page

Ahmedabad Municipal Corporation

placed at the Contractor’s principal place of business or such other address as the Contractor

shall nominate for that purpose.

5.4 Any notice to be given to Employer or to the Engineer under the terms of the Contract shall

be sent by post, cable, fax, or e mail to or left at the respective addresses nominated for that

purpose given in contract data.

5.5 Change of address shall be informed to respective parties well in advance.

6.0 Subcontracting

6.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any

portion of Work without the approval of the Employer’s Representative. Any subcontracting

shall not relieve the Contractor from any contractual obligations or responsibility under the

6.2 The Contractor shall not be required to obtain consent for a subcontract for which the name

of the subcontractor and scope of works activities to be performed by him is already stated

in the contract or supply of material or engagement of labour.

7.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as

referred to in the Bid document to carry out the functions stated in the Schedule or other

personnel approved by the Engineer. The Engineer will approve any proposed replacement

of key personnel only if their qualifications, abilities, and relevant experience are

substantially equal to or better than those of the personnel listed in the Schedule.

7.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof,

for his misconduct or inadequacy of technical skills and experience, who is a member of the

Contractor’s staff or his work force, the Contractor shall ensure that the person leaves the

Site within seven days and has no further connection with the work in the Contract.

7.3 No residential accommodation is allowed at the site of work. The labour huts shall not be

erected on the site of work and contractor shall make his own arrangements to provide such

accommodations as per the rules of the local bodies. He shall make his own arrangements

for housing, stores, field office etc. He shall submit a site layout plan indicating the location

of various site facilities to be created by him at his cost for the execution of work. The Owner

shall in no way be responsible for any delay on this account and no claim on this account

whatsoever shall be entertained. All Basic amenities shall be provided by the Contractor to

Labours as per the prevailing labour Laws.

7.4 Project Manager shall be of a graduate civil engineer having a minimum five years of

experience in similar nature work (potholes/heavy patchwork repair work using Milling with

Pothole/heavy patch work road repair work done). The Project Manager shall always be

available at the site during the actual execution of the work. This is in addition to the

number of graduate engineers (of civil and other disciplines as required) who shall be

appointed by contractor to execute all items of work.

8.0 Employer’s and Contractor's Risks

The Employer carries the risks which this Contract states are Employer’s risks, and the

Contractor carries the risks which this Contract states are Contractor’s risks.

9.0 Employer's Risks

The Employer is responsible for the excepted risks which are in so far as they directly affect

the execution of the Works, the risks of war, hostilities, invasion, act of foreign enemies,

rebellion, revolution, insurrection or military or usurped power, civil war, or riot,

commotion, disorder (unless restricted to the Contractor’s employees), natural disaster and

contamination from any nuclear fuel or nuclear waste or radioactive toxic explosive.

Contractor will execute rectification of damaged portions of work due to such risks and

Signature of Bidder Page

Ahmedabad Municipal Corporation

Employer shall suitably compensate for works in accordance with the terms and conditions

of the contract.

10.0 Contractor’s Risks

10.1 All risks of loss or damage to physical property and of personal injury, death which arise

during and in consequence of the performance of the Contract, are the responsibility of the

Contractor. Contractor shall rectify damages to works, loss of materials, property, plant and

machinery, life etc. at his own costs.

10.2 The contractor shall assume all liability, financial or otherwise in connection with his

contract and shall protect and indemnify the Employer from any and all damages and claims

that may arise on any account. The Contractor shall indemnify the owner against all claims in

respect of patent rights, royalties, damages to adjacent buildings, roads or members of

public in course of execution of work or any other reason whatsoever and shall himself

defend all actions arising from such claims and shall keep the Owner saved harmless and

indemnified in all respect from such actions, costs and expenses. The contractor shall be

liable for any loss or damage to the Works occasioned by him in the course of operations

carried out by him. All such damage (except that arising out of excepted risks defined in

clause 11.1 above) to works will be rectified by contractor at his own cost.

11.0 Care of Works, Insurance & Indemnity

11.1 From commencement to completion of the work as a whole, the Contractor shall take full

responsibility for the care thereof and for taking precautions to prevent loss or damage

except the loss/damage occasioned by Employer’s Risks Clause 9 or Force Majeure Risks

Clause 63, which are not insurable as per hereof. He shall be liable for any damage or loss

that may happen to the works or any part thereof except the loss/damage occasioned by

Employer’s Risks or Force Majeure Risks. Any such loss or damage shall be restored in good

order and condition and in conformity in every respect with the requirements of the

Contract and instructions of the Engineer-in-Charge at Contractor’s cost. The re-doing or

repair of Permanent Works occasioned by Employer’s Risks or Force Majeure Risks which are

not insurable shall be paid by the Employer as per variation order provided such a loss or

damage could not have been foreseen or avoided by a prudent person.

11.2 Neither party to the Contract shall be liable to the other in respect of any loss or damage

which may occur or arise out of "Force Majeure" to the Works or any part thereof or to any

material or Plant at Site but not incorporated in the Works or to any person or anything or

material whatsoever of either party and the either party shall bear losses and damages in

respect of their manpower and materials. As such liability of either parties shall include

claims/compensation of the third party also.

11.3 Provided, however, in an eventuality as mentioned in sub-clause 11.1 & 11.2 above, the

following provisions shall also have effect:

(a) The Contractor shall, as may be directed in writing by the Engineer-in-Charge

proceed with the erection and completion of the works under and in accordance

with the Contract; and

(b) The Contractor shall, as may be directed in writing by the Engineer-in-Charge, re-

execute the works lost or damaged, remove from the Site any debris and so much of

the works as shall have been damaged. The cost of such re- execution of the works

shall be ascertained in the same manner as for deviations and this shall be paid

separately to the Contractor.

11.4 Provided always that the Contractor shall, at his own cost, repair and make good so much of

the loss or damage as has been by any failure on his part to perform his obligations under

the Contract or not taking precautions to prevent loss or damage or minimize the amount of

such loss or damage.

11.5 The Contractor shall indemnify and keep indemnified the Employer against all losses and

claims for death, injuries or damage to any person or any property whatsoever which may

Signature of Bidder Page

Ahmedabad Municipal Corporation

arise out of or in consequence of the construction and maintenance of works during the

Time for Completion and also against all claims, demands, proceedings, damages, costs,

charges and expenses whatsoever in respect of or in relation thereto, and such liabilities

shall include claims/compensations of the third party. Provided the same is attributable to

the contractor.

11.6 The Employer shall not be liable for in respect of any damages or compensation payable to

any workman or other person in the employment of the Contractor or any subcontractor,

other than death or injury resulting from any act or default of the Employer, his agents or

servants. The Contractor shall indemnify and keep indemnified the Employer against all such

damages and compensation, other than those for which the Employer is liable as aforesaid,

and against all claims, proceedings, damages costs, charges and expenses whatsoever in

respect thereof or in relation thereto.

12.0 Site Investigation Reports

13.0 Queries about the Contract Data and Contract agreement

13.1 The Employer / Engineer in Charge will clarify queries on the Contract Data. These

clarifications shall form a part of the Contract and shall be binding on both the Employer and

the Contractor.

13.2 The Contractor shall enter into and execute the contract agreement to be prepared at the

cost of the Employer in the form given in the instructions to bidde`

14.0 Contractor to Construct the Works

14.1 The Contractor shall with due care and diligence design (to the extent as provided for in the

contract), execute and complete the works and remedy the defects if any in accordance with

the provisions of the contract, detailed design and drawing for permanent works shall be

made available by AMC.

14.2 Contractor shall provide all superintendence, labour, materials, plant, contractor’s

equipments, and all other things as may be required to design, execute, complete, and

maintain during defects liability period the works. (Refer clause 14.1 above).

14.3 Any defect, error, omission, fault shall be immediately brought to the notice of the Engineer

in Charge before or during the execution of the works.

14.4 The Contractor shall take full responsibility for the adequacy, stability, safety of all site

operations and methods of construction. Contractor shall not be responsible for the design

and specifications of the Permanent Works not designed by him.

14.5 The Contractor shall be responsible for:

1. The accurate setting out of the Works in relation to original lines, levels, and points of

reference given and getting the same approved from the Engineer in Charge.

2. The correctness of all positions, levels, dimensions and alignment of all parts of the

3. The provision of all necessary instruments, appliances, and labour in connection with the

foregoing responsibilities.

4. Contractor shall rectify all errors during execution of works at his cost except for the

errors that occur due to supply of incorrect drawings or instructions by the Engineer.

14.6 The checking and approval by the Engineer of any alignments, levels and setting out shall not

relieve the Contractor of his responsibility for accuracy thereof.

14.7 The Contractor shall provide and maintain a site office with toilet facility for the Engineer

and his staffs for the complete duration of the contract at no cost to the Employer.

15.0 The Works to Be Completed by the Intended Completion Date

Signature of Bidder Page

Ahmedabad Municipal Corporation

15.1 The Contractor may commence execution of the Works on the commencement date and

shall carry out the Works in accordance with the programme submitted by the Contractor, as

updated with the approval of the Engineer in Charge, and complete them by the Completion

15.2 The Employer shall in no way be responsible for either any delay in getting electric and/or

water connections for carrying out the work and no claim whatsoever on this account shall

be entertained from the contractor. Also contingency arrangement of standby water &

electric supply shall be made by the contractor for smooth progress of the work on account

of power failure or disconnection for any reason whatsoever it may be. No claim of any kind

whatsoever shall be entertained on this account from the contractor. Nothing extra shall be

payable on this account.

15.3 The Contractor shall provide necessary superintendence matching with working hou`

Contractor cannot claim for any extra payment in case there is no work front available due

15.4 The Contractor shall afford every facility for and every assistance in obtaining the right to

access for the Engineer in Charge or any of his representative at all reasonable times to the

site or plant and to all workshops, places where materials or plant are being manufactured,

fabricated or prepared. If materials, plant or parts of works are manufactured, fabricated or

prepared in places not belonging to the contractor, the contractor shall organise necessary

permissions from the owners of such facilities for the Engineer to inspect such where

materials or plant.

15.5 Suspension of work

The Contractor shall, on the instructions of the Engineer, suspend the progress of the works

or part thereof for such time and in such manner as the Engineer may consider necessary

and shall, during such suspension, properly protect and secure the works or any part thereof

so far as is necessary in the opinion of the Engineer in Charge. Unless such a suspension is:

i. otherwise provided in the contract,

ii. necessary by reason of some default or breach of contract by the Contractor or for

which he is responsible,

iii. necessary by reason of climatic conditions on site or

iv. necessary for the proper execution of the work or for safety of the works or any part

Following sub clause shall apply.

15.6 Effect of suspension.

With reference to clause 15.5 the Engineer shall after due consultations with the Employer

and the Contractor determine

a. The time effect of such suspension on the contract period and

b. The cost effect of such suspension on the Contract Price.

and shall notify the Contractor with a copy to the Employer.

16.1 The Contractor shall have full regard throughout execution, completion and defects liability

period to following safety aspects and shall take all necessary steps to ensure that danger to

safety is avoided all the time in respect of,

a. Safety of the works

b. Safety of the Contractor’s employees and all the persons directly or indirectly engaged

by him for the works

c. Safety of all the employees including persons working on other contracts of Employer at

the same site of the Employer and Engineers employees engaged at work site.

d. Any authorised third party persons on the site.

e. Contractor’s plant and equipment

16.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning

signs, barricading, and cones; when and where necessary, or required by Engineer in Charge

Signature of Bidder Page

Ahmedabad Municipal Corporation

or by any duly constituted authority for the protection of the works or for the safety and

convenience of the public or other.

16.3 The Contractor shall take all reasonable steps to protect the environment on and off the site

and avoid damage or nuisance to persons or property of the public and others arising as a

consequence of his method of operation.

16.4 The Contractor shall maintain in good condition all work throughout execution, completion,

and defects liability period. The contractor shall be responsible for and to make good all

injuries, damages and repairs, rendered necessary by fire, rain, traffic, floods or other

16.5 All the scaffolding work, wherever required for the execution of work, shall be provided by

the contractor. Nothing extra shall be payable on this account. It shall be provided strictly

with double scaffolding system with all the accessories etc. with adjustable suitable working

platforms to access the areas, with ease for working and inspection. It shall be designed to

take all incidental loads. It should cater to the safety features for workmen. It shall be

ensured that no damage is caused to any structure due to scaffolding.

16.6 All temporary warning/ caution boards display such as “Construction Work in progress”,

“Keep Away", “No parking”, “Speed limit”, Diversion”, etc. shall be provided and displayed

during day as well as night time by the contractor, wherever required and as directed by the

Engineer. A signboard with project description, Name of client Project, etc. should be

displayed at proper locations as directed by the Engineer at no extra cost.

16.7 Arrangement of temporary water and electricity and telephone connection required, by him,

shall be made by the Contractor at his own cost and also necessary permissions directly from

relevant Owners shall be obtained by him under intimation to the Owner. Also all initial and

running charges and security deposit, if any in this regard shall be borne by him. The

Contractor shall abide by all the rules/ bye laws applicable in this regard and he shall be

solely responsible for any penalty on account of violation of any of the rules and byelaws in

16.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the

same shall be completely contractor’s responsibility. All the losses due to such accidents and

expenses of legal matters shall be borne by contractor.

16.9 The Contractor shall be responsible for maintenance and watch and ward of the complete

installation and shall also be responsible for any pilferage, theft, damage, penalty etc. in this

regard. The Contractor shall indemnify the Owner against any claim arising out of pilferage /

theft, damage, penalty etc. whatsoever on this account. Security deposit for the work shall

be released only after the clearance is obtained from the local authorities from whom

temporary electric/ water I telephone connection have been obtained by the contractor.

16.10 The Contractor shall depute Site Engineer & skilled workers as required for the work.

Necessary protective and safety equipments shall be provided to them by the Contractor at

his own cost and used at site.

17.0 Security & Traffic Arrangements

17.1 In event of any restriction being imposed by the Security Staff of Owner, Ahmedabad

Municipal Corporation, Government or any other local governing body having control over

the project, on the working or movement of labour, materials, the Contractor shall strictly

follow all such restrictions or instructions issued regarding the same and nothing extra shall

be payable to the Contractor on account of such restrictions or instructions. In case of loss of

time on this account if any, shall have to be made up by generating additional resources etc.

17.2 General security restrictions are given as under:

i. The movement of trucks and vehicles shall be regulated in accordance with rules and

regulations as approved by competent authorities.

ii. The Contractor shall inform in advance, if required, the truck registration numbers

ownership of the trucks, names, and addresses of the drivers for necessary action by

Signature of Bidder Page

Ahmedabad Municipal Corporation

the security agency.

iii. As and when there will be security requirements, certain additional restrictions can

be imposed as per the requirement of the situation.

iv. No claim whatsoever will be entertained by the Owner on account of any restriction

that can be imposed as per the requirement of the situation.

17.3 No inflammable materials including P.O.L. shall be allowed to be stored in huge quantity at

site. However, reasonable quantity may be permitted for storage, subject to the compliance

of all rules & instructions issued by the relevant authorities and as per the direction of

Engineer -in- Charge in this regard.

17.4 Contractor shall be fully responsible for any person’s injury or death which arises during and

in consequence of the performance of the contract. Employer, Engineer, Engineer’s

representative shall not be responsible for the same.

18.0 Discoveries

Anything of geological or archaeological or other interest or articles of value or antiquity

discovered on the Site shall be the absolute property of the Employer. The Contractor is to

notify the Engineer of such discoveries and carry out the Engineer's instructions for dealing

with them without damages, thefts etc. In carrying out the Engineers instructions to dealing

with such articles if the Contractor incurs extra costs or suffers delays, the Engineer shall

determine after due consultation with the Employer and the Contractor amounts of such

costs and extension of time in accordance with the corresponding clauses of the contract.

19.0 Possession of the Site

19.1 The Contractor shall commence the work as soon as is reasonably possible on receipt of the

“Commencement of Work Notice” from the Engineer.

19.2 The Employer shall give possession of part / parts of the Site to the Contractor from time to

19.3 Access to site shall also be provided by the Employer to the Contractor in order and manner

as set out in the contract to enable the Contractor to commence and proceed with the

works in accordance with his construction programme and method of construction.

19.4 The site of work shall be always kept clean. The excavated material shall be disposed off as

directed by the Engineer, from the premises and all necessary permissions in this regard

from the local bodies shall be obtained by the contractor. The rubbish, construction debris

etc. shall not be allowed to be collected at site or to be disposed into any public place. The

work shall be carried out in such a way that the area is kept clean and tidy without causing

any nuisance. Nothing extra shall be payable on this account.

20.0 Access to the Site

The Contractor shall allow the Engineer and any person authorized by the Engineer access to

the Site, to any place where work in connection with the Contract is being carried out or is

intended to be carried out and to any place where materials or plant are being

manufactured / fabricated / assembled for the works.

21.0 Instructions

The Contractor shall, unless it is legally or physically impossible, execute and complete the

works and remedy defects therein in strict accordance with the contract to the satisfaction

of the Engineer. The Contractor shall comply and adhere to the Engineer’s instructions on

any matter, whether mentioned in the contract or not, concerning the works. The

Contractor shall take instructions only from the Engineer (or his delegates).

22.0 Settlement of Disputes:

Signature of Bidder Page

Ahmedabad Municipal Corporation

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final

and binding to the Bidder.

23.0 Avoidance to damage of roads.

The Contractor shall ensure that no damage to roads and bridges on the route to the sites

occurs due to him or his subcontractor’s traffic. He shall ensure minimum possible hindrance

to the traffic movements on public roads and bridges due to his materials, plant, temporary

works etc. No materials shall be stacked on public roads and thoroughfares. The

damaged/dug/excavated road shall be reinstating during construction within a period of

days on completion of activity to its original condition.

24.0 Transport of Contractor’s equipment

The Contractor shall specifically notify the Employer and the Engineer in case he plans to

transport materials, equipment, plant etc. which might induce such loads on roads and

bridges en route to site for which the roads and bridges are not designed. In every such case

the Contractor shall carry out all such strengthening works as may be necessary to ensure

the safety of the roads/ bridges. All such works should be approved by the Engineer in

writing. The Contractor, despite the strengthening measures and written approval by the

Engineer, shall be responsible for the safety of the roads and bridges as well as his own

plant, materials and equipments.

25.0 Opportunities and Facilities for other Contractors Opportunities:

25.1 The Contractor shall afford all reasonable opportunities to,

a. any other contractor and his workmen engaged by the Employer

b. the Workmen of the Employer

c. Workmen of any other agency permitted by the Employer to work in or around the site

25.2 Facilities:

d. Make available any roads or ways for the maintenance of which the Contractor is

e. Permit the use of any temporary works or Contractors Equipment on site. (to be charged

wherever applicable).

f. Provide any other services of whatsoever nature (to be chargeable wherever applicable.)

26.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage

rubbish, excess materials, temporary works no longer required will be removed from site

27.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials,

rubbish, temporary works of every kind, except those Contractors equipment, surplus

materials, rubbish, temporary works that may be required by him during the Defects Liability

period and leave the site clean and in a workmanlike condition to the satisfaction of the

Engineer on issue of the Taking Over Certificate.

Signature of Bidder Page

Ahmedabad Municipal Corporation

B. TIME CONTROL

28.1 The Contractor should plan the work to be executed round the clock without violating labour

and environmental control norms specified by the governing bodies (National, State and

local) without disturbing and stopping normal traffic.

28.2 Within the time stated in the Contract Data the Contractor shall submit to the Engineer for

his consent a Programme showing the general methods of construction, arrangements,

order, and timing and sequence for all the activities including traffic diversion, resource

schedules including material, manpower and machinery and equipment scheduling monthly

cash flow forecast and any other details the Engineer may require.

28.3 If at any time it should appear to the Engineer that the actual progress of works does not

confirm to the programme to which consent has been given as per clause 28.2 above, the

Contractor shall produce, at the request of the Engineer, a revised programme showing

modifications to the programme consented to under clause 28.2 above necessary to ensure

completion of works within the Time for Completion.

28.4 If the Contractor fails to submit such a revised programme, the Engineer may withhold the

amount stated in the Contract Data from the next payment certificate and continue to

withhold this amount in all future payments until the date on which the revised Program is

28.5 The Engineer's consent to the Program shall not relieve the Contractor from his duties and

responsibilities under the contract.

28.6 The Engineer shall monitor the rate of progress of work. In case the Engineer finds that the

rate of progress of work is too slow to comply with the Time for completion, he shall notify

the Contractor who shall thereupon take necessary steps to expedite progress. No extra

payments on account of such actions shall be due to the Contractor.

29.0 Time for completion and Extension of the Intended Completion Date

29.1 The whole of the works, and if applicable any section of the works required to be completed

within a particular time as stated in the Contract data, shall be completed within the

stipulated time for the whole of the works or the Section (as the case may be) calculated

from the Commencement Date, or such extended time as may be allowed under following

29.2 The Engineer shall, after due consultation with the Employer and Contractor, determine the

amount of extension of time for completion to which the Contractor becomes fairly entitled

in the event of

i. Amount and nature of extra work

ii. Any cause of delay referred to in these conditions

iii. Exceptionally adverse climatic conditions

iv. Any delay, impediment or prevention by the Employer

v. Other special circumstances which may occur, other than through a default or breach of

contract by the contractor

The Engineer shall notify the Contractor about all such extension of time with a copy to the

29.3 The Engineer shall however not be bound to make any determination unless the Contractor

a. has notified the Engineer within 28 days of occurrence of event

b. has furnished detailed particulars of the extension of time arising out of such an event

within 28 days of the issue of notice of occurrence of the event.

30.0 Delays Ordered by the Engineer

The Engineer may instruct the Contractor to delay the start or progress of any activity within

the Works. These delays shall be suitably compensated for time in accordance with the

Signature of Bidder Page

Ahmedabad Municipal Corporation

provisions of the Contract and no compensation for cost shall be payable to the contractor

on this account.

31.0 Management Meetings

31.1 Either the Engineer or the Contractor may require the other to attend a management

meeting. The business of a management meeting shall be to review the plans for remaining

work and to deal with matters raised in accordance with the early warning procedure.

31.2 The Engineer shall record the business of management meetings and is to provide copies of

his record to those attending the meeting and to the Employer. The responsibility of the

parties for actions to be taken is to be decided by the Engineer either at the management

meeting or after the management meeting and stated in writing to all who attended the

32.0 Early Warning

32.1 The Contractor is to warn the Engineer at the earliest opportunity of specific likely future

events or circumstances that may adversely affect the quality of the work, increase the

Contract Price, or delay the execution of works. The Engineer may require the Contractor to

provide an estimate of the expected effect of the future event or circumstance on the

Contract Price and Completion Date. The estimate is to be provided by the Contractor as

soon as reasonably possible.

32.2 The Contractor shall cooperate with the Engineer in making and considering proposals for

how the effect of such an event or circumstance can be avoided or reduced by anyone

involved in the work and in carrying out any resulting instruction of the Engineer.

C. QUALITY CONTROL

33.0 Identifying Defects

33.1 The Employer’s Representative or his nominee, either themselves or through Employer’s

authorized Quality surveillance personnel, shall check the quality of Contractor’s Works

including design, procurement, manufacture, fabrication, construction, erection, testing and

commissioning activities, commensurate with Employer’s QA (Quality Assurance) program

stated in the Contract and notify the Contractor of any Defects that are found. Such checking

whether carried out at Site or at any other place of work shall not affect the Contractor’s

responsibilities.

33.2 The Employer’s Representative or his nominee or Employer’s authorized quality surveillance

engineer may instruct the Contractor to search for a Defect at any stage of an activity and to

uncover and test any work that the Employer’s Representative or his nominee considers may

33.3 The Contractor shall establish the Quality Control/Quality Assurance Systems and facilities

and shall at all time provide to the Employer reports about such checks and inspections.

a. If the Engineer instructs the contractor to carry out a test not specified in the

specification to check whether any work has any defect or not, contractor shall perform

the same and submit the results to the Engineer at his own cost.

b. The contractor has to carry out the testes of all items as per the criteria mentioned in 5th

Revision of MoRTH / IS CODE / IRC as mentioned in the specifications.

35.0 Correction of Defects during Defects liability period

a. The Engineer shall give notice to the contractor of any defects before the end of the

defects Liability Period, which begins at completion and is defined in the contract data.

b. Every time notice of a defect is given, the contractor shall correct the notified defect

within the period of time specified by the Engineer’s notice.

Signature of Bidder Page

Ahmedabad Municipal Corporation

36.0 Uncorrected Defects during Defects liability period

36.1 If the Contractor does not rectify or correct a defect within the time specified in the

engineer’s notice, the engineer will assess the cost of having the defect corrected, and the

contractor will bear the costs of such defective work as well as all works carried out over

such defective work until the defect is removed to the satisfaction of the Engineer. The cost

of such defective work will be recovered from the bank guarantee submitted against

performance for defect liability period.

36.2 Only the defects liability certificate referred to in following clause shall be deemed to

constitute the approval of the works.

36.3 Defects Liability Certificate: The Defects liability certificate shall be given by the Engineer in

Charge to the Employer, with a copy to the Contractor, within 28 days of the expiry of the

Defects Liability Period. The Contract shall remain incomplete until issue of the Defects

Liability Certificate.

36.4 The defects Liability Certificate shall mention clearly that the Contractor has completed his

obligations to execute and complete the works and remedy defects therein to the

satisfaction of the Engineer.

36.5 Unfulfilled obligations: Despite issuance of the Defects Liability Certificate, the contract

between the Employer and the Contractor shall remain in force in respect of unperformed

obligations incurred under the provisions of the Contract prior to the issue of the Defects

Liability Certificate.

Manual for maintenance during defect liability period is attached as Annexure-X

D. COST CONTROL

37.0 Bill of Quantities

a. The schedule-B shall contain Memorandum showing items for the construction,

installation, testing, and commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be

paid only quantities calculated after taking measurements of executed work. The rate

stated in the schedule B for each item of work shall apply. The works shall be measured

by the Contractor jointly with the authorised representative of the Engineer and all

particulars required by the representative of the Engineer shall be supplied by the

c. The work shall be measured net. No allowance for general or local custom, working

space etc. is to be made.

38.0 Variations

39.0 Extra Items

39.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows

in the same order of priority.

a) Variations in the quantities of work in schedule of quantities shall not vitiate the

b) The contractor shall be bound to execute extra items of work as directed by the

Engineer-in-charge.

c) Contract unit rates for individual items shall apply to varied quantities where there is a

quantity variation.

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

39.2 If any extra item crops up during the progress of work the same shall be carried out by the

Contractor and he shall be paid at the rate fixed by Employer which shall be fixed as lowest

Signature of Bidder Page

Ahmedabad Municipal Corporation

of the rates derived by rate analysis based on the following three methods. , the priority of

the documents forming the Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2015-16,

the rate of extra item shall be that rate and premium (above or below) quoted by

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and

equipment, the cost of all temporary and incidental works, the overheads and the

Contractors profit.

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs,

the cost of use of all plant, machinery, and equipment, the cost of all temporary and

incidental works.

39.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall

be taken at 10 % of the final rate derived.

39.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in

his opinion appropriate and shall notify the Contractor accordingly with a copy to the

39.5 The Engineer shall determine provisional rates and prices to enable on account payments to

be included in the Interim Payment Certificates, until rates and prices are agreed as final by

the Employer, the Contractor, and the Engineer.

39.6 The Contractor shall not be entitled to additional payment for costs, which could have been

avoided by giving early warning.

40.0 Payment Certificates

40.1 The Contractor shall submit to the Engineer a monthly statement after the end of each

calendar month in hard copies and soft copy on CDs each signed by the Contractors

authorised Representative in such form as the Engineer may prescribe from time to time.

The Monthly Statement shall state

 The amount to which the Contractor is entitled.

 The value of the permanent works executed.

 Other sums such as secured advance payments, day works payments, price escalation

payments, and mobilisation advance.

 Any other sums to which the Contractor may consider himself entitled.

40.2 The Engineer shall check the Contractor's monthly statement within 14 days and certify for

payment vide an Interim Payment Certificate the amount to be paid to the Contractor after

taking into account any credit or debit for the month a) in respect of materials for the works

in the relevant amounts and b) under various conditions set forth in these Conditions of

Contract and stated in brief in the Contract Data.

40.3 The value of work executed shall be determined, based on measurements by the Engineer.

40.4 The value of work executed shall comprise the value of the quantities of the items in the Bill

of Quantities completed.

40.5 The value of work executed shall also include the valuation of Variations and Compensation

40.6 The Engineer / Employer may exclude any item certified in a previous certificate or reduce

the proportion of any item previously certified in any certificate in the light of later

40.7 The final bill shall be submitted by the contractor within one month of the actual date of

completion of the work; otherwise the Engineers certificate of the measurement and of the

total amount payable for work accordingly shall be final and payment made accordingly

total amount payable for work accordingly shall be final and payment made accordingly

within a period of sixty days as far as possible.

40.8 No payment shall be recommended by the Engineer through Interim Payment Certificate

until he is fully satisfied that

Signature of Bidder Page

Ahmedabad Municipal Corporation

 All premiums towards the various insurance policies taken by the Contractor in

accordance with these General Conditions of Contract are paid.

 Contractor has obtained the labour licences and PF code numbers for site staffs and

41.1 Payments shall be adjusted for deductions for advance payments, retention, other

recoveries in terms of the contract and taxes at source, as applicable under the law. The

Employer shall pay the Contractor the amounts certified by the Engineer.

41.2 If an amount certified is increased in a later date certificate due to corrections in previous

certificates or as a result of an award from disputes review experts, Contractor shall be paid

such amount only. The Contractor shall not be paid any interest upon such delayed

41.3 Items of the work for which no rate or price has been entered in will not be paid for by the

Employer and shall be deemed covered by other rates and prices in the Contract.

41.4 All payments shall be made in Ahmedabad.

42.0 Taxes and duties

42.1 The rates are inclusive of all the prevailing taxes and duties of the NORTH, State and Local

Governing bodies prevailing on the date of award of the contract. The Contractor will have

to pay all such taxes and duties for the performance of this Contract. The Employer will

deduct from the Contractor’s monthly and other payments all taxes and duties, which he is

bound to recover in accordance with the applicable law.

42.2 The Contractor shall keep himself fully informed of all acts and laws of the NORTH & State

and local Governing bodies, all orders, decrees of bodies, tribunals having any jurisdiction or

authority which in any manner affect those engaged or employed, and anything related to

carrying out the work. All the bye-laws lay down by AMC/AUDA and any other local bodies

while executing the work shall be adhered to. All taxes of local bodies shall be borne by the

contractor. The Contractor shall arrange to give all notices required by any authority and to

pay to such authority all the fees that may have to be paid for the material, plants,

equipments etc. The Contractor shall also adhere to all traffic restrictions notified by the

local authorities. He shall protect and indemnify the Owner and its officials & employees

against any claim or liability arising out of violations of any such laws, ordinances, orders,

decree, whether by himself or by his employees or his authorised representatives. Nothing

extra shall be payable on these accounts.

43.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-

1831-M(3) dt. 9/12/05 issued by G.O.G. 1 % cess tax (non-refundable) shall be deducted

from every bills which shall be deposited to Govt. Labour Department for Labour welfare

44.0 Currencies

All payments shall be made in Indian Rupees.

45.0 Advance Payment

No Advance Payment shall be made.

46.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the

Start Date and the end of the Defects Correction periods shall be remedied by the

Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or

Signature of Bidder Page

Ahmedabad Municipal Corporation

E. FINISHING THE CONTRACT

47.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works

and the Engineer will do so upon deciding that the Work is completed.

48.0 Taking Over

48.1 When the whole work have been substantially completed and have satisfactorily passed all

tests on completion prescribed by the contract, the Contractor may give a notice to that

effect to the Engineer in charge, with a copy to the Employer, accompanied by a written

undertaking to finish with due expedition any outstanding work during the Defects Liability

Period. Such notice and undertaking shall be deemed as a request by the contractor to the

Engineer to issue a Taking over Certificate in respect of the works. The Engineer shall, within

21 days of the delivery of such a notice, either issue to the Contractor with a copy to the

Employer, a Taking over Certificate, stating the date on which, in his opinion, the work were

substantially completed in accordance with the Contract, or give instructions in writing to

the Contractor, specifying all the work which, in the Engineer’s opinion, is required to be

done by the Contractor before the issue of such certificate. The Engineer shall also notify the

Contractor of any defects in the works affecting substantial completion that may appear

after the instruction and before completion of the works specified therein. The Contractor

shall be entitled to receive such taking over certificate within 21 days of completion, to the

satisfaction of the Engineer, of the Works so specified and remedying any defects so

o Taking over of sections or parts:

48.2 Similarly, in accordance with the procedure set out in the sub clause 48.1, the Contractor

may request and the Engineer shall issue a Taking over certificate in respect of:

1. Any section in respect of which a separate Time for Completion is provided in the

2. Any substantial part of the permanent works, which has been both completed to the

satisfaction of the Engineer and, otherwise than provided for in the contract, occupied

or used by the Employer, or

3. Any part of the permanent works, which the Employer has elected to occupy or use prior

4. The Contractor shall be deemed to have undertaken to complete with due expedition

any outstanding work in that part of Permanent Works during the Defects Liability

49.0 Surfaces requiring reinstatement:

Any ground or surface requiring reinstatement at the time of issue of Taking over Certificate

for the whole of the works shall be reinstated by the Contractor without any extra costs

even of the Engineer has issued a Taking over Certificate in respect of section or part work

wherein is included such ground or surface requiring reinstatement.

50.0 Defects Liability Period

50.1 “Defects Liability Period” as stated in the contract data means the period calculated from:

The date of completion of the work certified by the Engineer in accordance with Clause

and its sub clauses of these conditions of contract.

50.2 Completion of outstanding work and remedying defects:

a. The contractor shall complete the outstanding work with due diligence. All such work as

listed by the Engineer at the time of issue of “Taking over Certificate “and also.

Signature of Bidder Page

Ahmedabad Municipal Corporation

b. The contractor shall execute all such work of amendment, reconstruction and remedying

defects, shrinkages or other faults as the Engineer may, during the defects liability

period or within 14 days of its expiration, as a result of an inspection made by or on

behalf of the Engineer, prior to its expiration, instruct the contractor to execute.

50.3 Costs of all works referred to in clause 50.2 above shall be borne by the contractor.

50.4 During the Defect Liability period, it shall appear to the Engineer-in-charge or his

subordinates that any work has been executed with unsound, imperfect, or unskilful

workmanship or with materials of inferior quality; or that any materials or articles provided

by him for the execution of the work are unsound, or of a inferior quality, or other- wise not

in accordance with the contract, it shall be lawful for the Engineer-in-charge to intimate this

fact in writing to the contractor and the contractor shall be bound forthwith to rectify, or

remove and reconstruct the work so specified in whole or in part as the case may be.

50.5 Failing which within a period to be specified by the Engineer-in-charge in the written

intimation aforesaid, the contractor shall be liable to pay compensation at the rate of one

percent on the amount of the tender for every day not exceeding ten days, in the event of

any such failure as aforesaid the Engineer-in-charge may rectify or remove and re-execute

the work or remove and replace the materials or articles complained or as the case may be at

the risk and expense in all respects of the contractor.

50.6 Engineer-in-charge consider that any such inferior work or materials as described above may

be accepted or made use of it; shall be within his discretion to accept the same at such

reduced rates along with the appropriate penalty as the Municipal Commissioner may deem

51.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after

receipt by him of a Notice to this effect from the Engineer/Employer after signing

the agreement or

2. To proceed with the works, or any section thereof, within 28 days after received

3. Has failed to comply with a notice issued or an instruction issued within 28 days

after having received.

4. Abandons the works or otherwise plainly demonstrates the intention not to

continue performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written

permission of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or

administration order made against him, compounds with his creditors, or carries on

business under receive, trustee or manager for the benefit of his creditors, or if any

act is done or event occurs which (under applicable Laws) has a similar effect to any

of these acts of event.

51.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to

the contractor, terminate the contract and expel the contractor from the site. However, in

the case of sub-paragraphs (h), the Employer may be notice terminate the contract

51.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the

Employer, under the contract or otherwise.

Signature of Bidder Page

Ahmedabad Municipal Corporation

51.4 After termination, the Employer may complete the works and/or arrange for any other

entities to do so. The Employer and these entities may then use any goods, contractor’s

documents and other design documents made by or on behalf of the contractor.

51.5 The Employer or the Contractor may terminate the Contract if the other party causes a

fundamental breach of the Contract.

51.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the

current Program and the stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for

a reconstruction or amalgamation;

(c) The contractor fails to fulfil requirements stated in clause 9.0;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental

breach of Contract and the Contractor fails to correct it within a reasonable period of

time determined by the Engineer;

(e) the Contractor does not maintain a security which is required;

(f) the Contractor has delayed the completion of works by the number of days for which

the maximum amount of liquidated damages becomes payable as defined in the

(g) if the Contractor, in the judgement of the Employer has engaged in corrupt or

fraudulent practices in competing for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving,

receiving or soliciting of anything of value to influence the action of a public official in

the procurement process or in contract execution. “Fraudulent practice” means a

misrepresentation of facts in order to influence a procurement process or the execution

of a contract to the detriment of the Borrower, and includes collusive practice among

Bidders (prior to or after bid submission) designed to establish bid prices at artificial

non-competitive levels and to deprive the Borrower of the benefits of free and open

51.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a

cause other than those listed above, the Engineer shall decide whether the breach is

fundamental or not.

51.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

51.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe

and secure and leave the Site as soon as reasonably possible and handover the site to the

Employer including all materials and plant and equipment existing there upon.

52 Payment upon Termination

52.1 If the Contract is terminated because of a fundamental breach of Contract by the Contractor,

the Engineer shall issue a certificate for the value of the work done less advance payments

received up to the date of the issue of the certificate, less other recoveries due in terms of

the contract, less taxes due to be deducted at source as per applicable law and less the

percentage to apply to the work not completed as indicated in the Contract Data. Additional

Liquidated Damages shall not apply. If the total amount due to the Employer exceeds any

Liquidated Damages shall not apply. If the total amount due to the Employer exceeds any

payment due to the Contractor the difference shall be a debt payable to the Employer.

52.1 If the Contract is terminated at the Employer's convenience or because of a fundamental

breach of Contract by the Employer, the Engineer shall issue a certificate for the value of the

work done, the cost of balance material brought by the Contractor and available at site the

reasonable cost of removal of Equipment, repatriation of the Contractor's personnel

employed solely on the Works, and the Contractor's costs of protecting and securing the

Works and less advance payments received up to the date of the certificate, less other

recoveries due in terms of the contract and less taxes due to be deducted at source as per

applicable law.

Signature of Bidder Page

Ahmedabad Municipal Corporation

53 Default of Contractor:

53.1 If the Contractor enters into voluntary or involuntary bankruptcy, liquidation or dissolution

or becomes insolvent, or makes an arrangement with, or assignment in favour of, his

creditors, or agrees to execute the contract under a committee of inspection of his creditors,

or if a receiver, administrator, trustee or liquidator appointed over any substantial part of his

assets, or if, under any law or regulations relating to reorganisation, arrangement or

readjustment of debts, proceedings are commenced against the Contractor or resolution

passed in connection with dissolution or liquidation or if any steps are taken to enforce any

security interest over a substantial part of the Contractor’s assets, or if any act is done, or

event occurs with respect to the Contractor or his assets which, under any applicable law

has a substantially similar effect to any of the foregoing acts or events, or if the Contractor

has contravened the sub clause regarding assignment and subletting or has an execution

levied on his goods, or if the Engineer certifies to the Employer with a copy to the

Contractor, that, in his opinion, the Contractor:

a. has repudiated the Contract,

b. without reasonable excuse has failed

i. to commence the Works in accordance with sub clause 17.1 or

ii. to proceed with the Works, or any section thereof, within 28 days after receiving

notice pursuant to sub clause 29.3 and 29.4,

iii. to comply with a notice issued pursuant to sub clause 37 within 28 days after having

received it, or an instruction issued pursuant to sub clause 38 despite previous

warning from the Engineer, in writing, is otherwise persistently or flagrantly

neglecting to comply with any of his obligations under the contract or,

iv. has contravened sub clause regarding sub contracting, then the Employer may, after

giving 14 days notice to the Contractor, enter upon the site and the Works, and

terminate the employment of the Contractor without thereby releasing the

Contractor from any of his obligations or liabilities under the Contract, or affecting

the rights and authorities conferred on the Employer or the Engineer by the

Contract,, and may complete the works, or employ any other contractor to complete

the Works. The Employer or such other contractor may use the Contractor’s

equipment, Temporary Works, or material as he or they may think proper.

53.2 Assignment of benefit of agreement: Unless prohibited by law, the Contractor shall, if so

instructed by the Engineer, within 14 days of such entry and termination referred to in

clause 59.1 above assign to the Employer the benefit of any agreement for the supply of any

goods or materials or services and/or for the execution of any work for the purposes of the

contract, which the Contractor may have entered into.

F. GENERAL DESCRIPTION OF SCOPE OF WORK

54.0 Scope of work, Planning and Site Condition

54.1 The scope of work and explanatory notes given are neither complete nor exhaustive but are

added to assist the Contractor to understand the project. The detail scope is as described in

the Bill of Quantity and specifications. However any item of work required to be carried out

for proper and satisfactory completion of work with the highest standard of workmanship is

deemed to be included in the scope of work whether or not it is specifically included in the

54.2 Standard bench marks of required numbers shall have to be established by contractor

before commencement of the work and connected to the nearest GTS bench mark according

to which, whole work shall be carried out. The Contractor shall establish reference

benchmark at intermediate suitable spots with reference to these benchmarks or as may be

directed. The maintenance of all these BM, till completion shall be the responsibility of the

Signature of Bidder Page

Ahmedabad Municipal Corporation

54.3 The Contractor shall be solely responsible for the true and proper setting out of the

alignments and for the provision of all necessary instruments, at any time during the

execution of the work. In case of any error regarding location, levels, dimensions, or

alignment of any part of the work, the Contractor on being required to rectify such errors as

may be pointed out by the Engineer, shall at his own expense do so, to the satisfaction of

the Engineer. The checking of any setting out of any line or level by the Engineer or his

representative shall not, in any way, relieve the Contractor of his responsibilities for the

correctness thereof. The Contractor shall carefully protect and preserve all benchmarks, site

nails, pegs, reference pillars, and other measures used in setting out of the work.

56.0 Housing, Water Supply and Drainage etc.

56.1 All materials Plant and equipment and workmanship shall be:

a) of the respective kinds described in the contract and in accordance with the Engineers

instructions and

b) Subjected from time to time such tests as the Engineer may require at place of

manufacture, fabrication, or preparation, or on the Site OR at such other place or

places as may be specified in the contract or at all or any of such places.

56.2 All Contractors materials, plant, machinery and equipment shall be deemed to have been

exclusively brought to site for the execution of the works and shall not be removed from site

without the consent of the Engineer.

56.3 Employer shall not be liable for damage to Contractors equipment at any time unless

otherwise expressly stated in the contract.

56.4 The coarse aggregates for concrete works shall be procured from Sevaliya quarries (black

trap chippings) or equivalent confirming to IS 383 and as per MORTH. The suitability of the

same for the required quality, quantity, transport facilities for the same etc. may be

ascertained by the bidder themselves before tendering and rates be quoted accordingly.

Gravel shall not be permitted.

56.5 All samples shall be supplied and tested by the Contractor at his own cost.

56.6 The cost of all tests shall be borne by the Contractor except the tests that are required by

the Engineer are clearly beyond the Contractors obligations of proving the quality and

workmanship standards of all materials, equipment, plants and Works. The Engineer shall

determine the costs and time effects of such tests that are not a part of the Contractors

56.7 The Contractor will have to make his own arrangement for plants, equipments, and

machinery to be used in the execution of this work well in time after award of the contract

and as per work program given by him.

56.8 Contractor shall give Engineer a 24 hours notice for inspection of works or witnessing of test.

The Contractor shall proceed with the works or tests in case the Engineer does not attend.

Such tests and shall be deemed to have been carried out in the presence of the Engineer.

56.9 The Engineer may reject such material, plant, part of the works which are defective and/ or

otherwise not in accordance with the contract and notify the Contractor. The notice shall

state the Engineers objections and reasons. The Contractor shall then promptly rectify the

defect or ensure that rejected materials or plant are not used in the Works. In case the

Contractor wishes to retest such materials, plant or works declared defective by the

Engineer, he has to bear the time, and cost effects of such retests as mutually agreed with

the Employer in consultation with the Engineer.

56.10 The Contractor shall have to make his own arrangement to get the power supply from

concerned electric authority. The costs of electrical charges are to be borne by contractor.

60.0 Labour Employment

Signature of Bidder Page

Ahmedabad Municipal Corporation

60.1 Contractor shall, unless otherwise provided in the Contract, make his own arrangements for

the engagement of all staff and labour, local or other, and their payment, housing, feeding

60.2 Contractor shall furnish the Engineer every week during the progress of the works, classified

weekly returns of the number of the people employed on the work during the week. The

report of skilled and unskilled labour shall be given in the prescribed form if asked by AMC.

60.3 The Contractor shall strictly observe all the requirements laid down in the contract labour

(Regulation and Abolition) Act, 1979 and the contract labour (Regulation and Abolition)

(Gujarat) Rules, 1972 and other acts as amended from time to time so far as applicable from

The Contractor shall pay all royalties for getting construction materials required for the

62.0 Urgent Remedial work:

If, by reason of any accident, or failure, or other event occurring to, in, or in connection with

the Works, or any part thereof, either during the execution of the Works, or during defects

liability period, any remedial or other work is, in the opinion of the Engineer, urgently

necessary for the safety of the Works and the Contractor is unable or unwilling at once to do

such work, the Employer shall be entitled to employ and pay other persons to carry out

such work as the Engineer may consider necessary. If the work or repair so done by the

Employer is work which, in the opinion of the Engineer, the Contractor was liable to do at

his own cost under the Contract, then all costs consequent thereon or incidental thereto

shall, after due consultation with the Employer and the Contractor, be determined by the

Engineer and shall be recoverable by the Employer from the Contractor, and may be

deducted by the Employer from any monies due or to become due to the Contractor and

the Engineer shall notify the Contractor accordingly, with a copy to the Employer. Provided

that the Engineer shall, as soon after the occurrence of emergency as may be reasonably

practicable, notify the Contractor thereof.

63.0 Force Majeure

Neither party shall be to liable to the other for any loss of damage occasioned by or arising

out of acts of god, and in particulars, unprecedented Floods, volcanic eruption earth quake

or other convulsion of nature, and other acts such as but not restricted to general strike,

invasion, the act of foreign countries, hostilities or war like operations before or after

declaration of war, rebellion, military or usurped power which prevent performance of the

contract and which could not have been for seen or avoided by a prudent person.

64.0 Changes in Cost and Legislation

There shall be no addition or deduction from the Contract Price due to changes to any

National or State Statute, Ordinance, Decree, Law, Regulation, or byelaw.

65.0 Compliance with labour regulations:

During continuance of the contract, the Contractor and his sub contractors shall abide at all

times by all existing labour enactment and rules made there under, regulations, notifications

and bye laws of the State or NORTH Government or local authority and any other labour law

(including rules) regulations, bye laws that may be passed or notification that may be issued

under any labour law in future either by the State or NORTH Government or the local

authority. Salient features of some of the major labour laws that are applicable to

construction industry are given below. The Contractor shall keep the Employer indemnified

in case any action is taken against the Employer by the competent authority on account of

contravention of any of the provisions of any Act or rules made there under, regulations or

Signature of Bidder Page

Ahmedabad Municipal Corporation

notifications including amendments. If the Employer is caused to pay or reimburse such

amounts as may be necessary to cause or observe, or for non-observance of the provisions

stipulated in the notifications/bye laws/Acts/Rules/regulations including amendments, if

any, on the part of the Contractor the Nodal Officer or his nominee/Employer shall have the

right to deduct any money due to the Contractor including his amount of performance

security. The Engineer or his nominee shall also have right to recover from the Contractor

any sum required or estimated to be required for making good the loss or damage suffered

by the Employer.

The employees of the Contractor and the Sub-Contractor in no case shall be treated as the

employees of the Employer at any point of time.

66.0 Salient features of some major laws

(a) Workmen Compensation Act 1923:- The Act provides for compensation in case of

injury by accident arising out of and during the course of employment.

b) Payment of Gratuity Act 1972: Gratuity is payable to an employee under the

Act on satisfaction of certain conditions on separation if an employee has completed

years service or more on death at the rate of 15 days wages for every completed year

of service. The Act is applicable to all establishments employing 10 or more

c) Employees P.F and Miscellaneous Provision Act 1952: The Act Provides for monthly

contributions by the employer plus workers @ 12%/8.33%. The benefits payable under

(i) Pension to family pension on retirement or death, as the case may be.

(ii) Deposit linked insurance on the death in harness of the worker.

(iii) Payment of P.F accumulation on retirement/death etc.

d) Maternity Benefit Act 1951:- The Act provides for leave and some other benefits to

workmen/ employees in case of confinement or miscarriage etc.

e) Contract Labour (Regulation & Abolition) Act 1970:- The Act provides for certain

welfare measures to be provided by the Contractor to contract labour and in case the

Contractor fails to provide, the same are required to be provided, by the Principal

Employer by Law. The Principal Employer is required to- take Certificate of

Registration and the Contractor is required to take license from the designated Officer.

The Act is applicable to the establishments or Contractor of Principal Employer if they

employ 20 or more contract labor.

f) Minimum Wages Act 1948: The Employer is supposed to pay not less than the

Minimum Wages fixed by appropriate Government as per provisions of the Act if the

employment is a scheduled employment Construction of Buildings, Roads, Runways

are scheduled employment.

g) Payment of Wages Act 1936:- It lays down as to by what date the wages are to be paid

when it will be paid and what deductions can be made from the wages of the worke`

h) Equal Remuneration Act 1979:- The Act provides for payment of equal wages for work

of equal nature to Male and Female workers and for not making discrimination against

Female employees in the matters of transfers, training and promotions etc.

i) Payment of Bonus Act 1965: The Act is applicable to all establishments employing

or more employees. The Act provides for payments of annual bonus subject to a

minimum of 8.33% of wages and maximum of 20% of wages to employees drawing `

3500/- per month or less. The bonus to be paid to employees getting ` 2500/- per

month or above up to ` 3500/- per month shall be worked out by taking wages as `

2500/- per month only. The Act does not apply to certain establishments. The newly

set-up establishments are exempted for five years in certain circumstances. Some of

the State Governments have reduced the employment size from 20 to 10 for the

purpose of applicability of this Act.

Signature of Bidder Page

Ahmedabad Municipal Corporation

j) Industrial Disputes Act 1947:- The Act lays down the machinery and procedure for

resolution of Industrial disputes, in what situations a strike or lock out becomes illegal

and what are the requirements for laying off or retrenching the employees or closing

down the establishment.

k) Industrial Employment’s (Standing Orders) Act 1946:- It is applicable to all

establishments employing 100 or more workmen (employment size reduced by some

of the States and NORTH Government to 50). The act provides for laying down rules

governing the conditions of employment by the Employer on matters provided in the

Act and get same certified by the designated Authority.

l) Trade Unions Act 1926:- The Act lays down the procedure for registration of trade

union of workmen and employe` The Trade Union registered under the Act has been

given certain immunities from civil and criminal liabilities.

m) Child Labour (Prohibition & Regulation) Act 1986:- The Act prohibits employment of

children below 14 years of age in certain occupations and processes and provides for

regulation of employment of Children in all other occupations and processes.

Employment of Child Labour is prohibited in Building and Construction Industry.

n) Inter-State Migrant workmen’s (Regulation of Employment & Conditions of Service)

The Act is applicable to an establishment which employs 5 or more inter-state migrant

workmen through an intermediary (who has recruited workmen in one state for

employment in the establishment situated in another state). The Inter-State migrant

workmen, in establishment to which this Act becomes applicable, are required to be

provided certain facilities such as housing, medical aid, travelling expenses from home

upon the establishment and back, etc.

o) The Building and Other Construction workers (Regulation of Employment and

Conditions of Service) Act 1996 and the Cess Act of 1996:- All the establishments who

carry on any building or other construction work and employ 10 or more workers are

covered under this Act. All such establishments are required to pay cess at the rate not

exceeding 2% of the cost of construction as may be modified by the Government. The

Employer of the establishment is required to provide safety measures at the Building

or Construction work and other welfare measures, such as Canteens, First-Aid

facilities, Ambulance, Housing accommodations for workers near the work place etc.

The Employer to whom the Act applies has to obtain a registration certificate from the

Registering Officer appointed by the Government.

p) Factories Act 1948:- The Act lays down the procedure for approval at plans before

setting up a factory, health and safety provisions, welfare provisions, working hours,

annual earned leave and rendering information regarding accidents or dangerous

occurrences to designated authorities. It is applicable to premises employing

persons or more with aid of power or 20 more persons without the aid of power

engaged in manufacturing process.

67.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the

same. He shall also be responsible for the correctness of the positions, levels, dimensions,

and alignment of all parts of the structures as per instructions given to him. If at any time any

error shall appear during the progress of any part of the work, the contractor shall at his own

expense rectify such error if called upon to the satisfaction of the Engineer in charge. The

contractor shall be required to construct before starting the works and maintain till the end

of the defect liability period, the temporary bench marks at regular interval preferably at the

interval of 100m. Longitudinally all along the stretch as per the design as approved by

Engineer in Charge. The Contractor shall not be paid extra for constructing and maintaining

the temporary bench marks.

Signature of Bidder Page

Ahmedabad Municipal Corporation

68.0 Overpayment & Underpayment

68.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or

under this Contract against the contractor the same may be deducted by the Municipal

Corporation from any sum then due or which at any time thereafter may become due to the

contractor under this contract and failing that under any other contract with the Municipal

Corporation or from any sum due to the contractor with the Municipal Corporation (which

may be available with Municipal Corporation), or from his retention money, or he shall pay

the claim on demand. The Municipal Corporation reserves the right to carry out post

payment audit and technical examination of the final bill including all supporting vouchers,

abstracts, etc.

68.2 The Municipal Corporation further reserves the right to enforce recovery of any over

payment when detected notwithstanding the fact that the amount of the final bill may be

included by the Contractor.

68.3 If as a result of such audit and technical examination any over payment is discovered in

respect of any work done by the Contractor or alleged to have been done by him under the

contract, it shall be recovered by the Municipal Corporation from the contractor by way of all

the means prescribed above or if any under payment is discovered by the Municipal

Corporation, any amount due to the contractor under this contract or under payment may be

adjusted against any amount then due or which may at any time thereafter become due

before payment is made to the contractor from him to the Municipal Corporation on any

other contract account whatsoever.

If, at any time, there should be evidence of any lien or claim for which owner might have

become liable and which is chargeable to the contractor, the owner shall have the right to

retain out of any payment then due or thereafter to become due an amount sufficient to

completely indemnify the owner against such lien or claim or if such lien or claim be valid the

owner may be or become due and payable to the contractor. If any lien or claims remaining,

unsettled after all payments are made, the contractor shall refund or pay to the owner all

money that the latter may be compelled to pay in discharging such lien or claim including all

cost and reasonable expenses.

70.0 Setting out work

71.0 Materials obtain from dismantling

72.0 Abnormal rates

73.0 Action and compensation in case of bad workmanship

If it shall appear to the Engineer-in-charge that any work has been executed with materials of

inferior description, or quality or are unsound or with unsound imperfect or unskilled

workmanship or otherwise not in accordance with the contractor shall, no demand in writing

from Engineer-in-charge or his authorized representative specifying the work, materials or

articles companied of, not withstanding that the same may have been inadvertently passed,

certified and paid for forth with rectify or remove and reconstruct the work, specified and in

the event of failure to do so within a period to be specified by Engineer- in-charge in his

aforesaid demand, contractor shall be liable to pay compensation as directed by Engineer.

while his failure to do so continue and in the case of any such failure the Engineer-in- charge

may on expiry of the notice period rectify and remove and re-execute the work or remove

Signature of Bidder Page

Ahmedabad Municipal Corporation

and replace with other at the risk and cost of the Contractor. The decision of the Engineer-in-

charge as to any question arising under this clause shall be final and conclusive

75.0 Drawings and Photographs of the Works

75.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No

separate payment will be made to the contractor for this. . The contractor shall have to

submit the same in hard copy as well as soft copy as and when demanded by the AMC.

75.2 No photograph of the works or any part thereof or plant employed thereon, except those

permitted under clause 59.1, shall be taken, or permitted to be taken by the Contractor or

by any of his employees or any employees of his sub-Contractors without the prior approval

of the Engineer in writing. No photographs/ videography shall be published or otherwise

circulated without the approval of the Engineer in writing.

Seal and Signature of the Bidder Add city Engineer

Date: Bridge Project

Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

TECHNICAL SPECIFICATIONS

DETAILS OF MANUFACTURERS

RECOMMENDED PROCEDURE:

1. With Milling Pothole repairing:-

Step – 1:- The potholes/heavy patchwork or any heavy patchwork shall be clearly marked in Regular

Geometrical shape as directed before milling the existing surface.

Step – 2 :-Existing damaged surface shall be removed by milling machine up to 100 mm and disposal

of milled material to appropriate location. The scope of disposal milled material shall be responbility

Steo – 3:- Balance loose debris in the potholes/heavy patch work area of any road distress shall be

blowered off using high volume blower on the milling surface.

Step – 4 :- The Tack Coat (Cationic bitumen emulsion RS1 grade complying with IS-8887) uniformly

shall be sprayed at the rate of 0.25-0.30 kg/sqm. It shall be applied by a selfpropelled or towed

bitumen pressure sprayer, equipped for spraying the material uniformly at a specified rate at no

Step – 5 :- Back filling the potholes/heavy patch work with coldmix or hotmix material (Providing

Cold Mix / Hot mix material using 100-120 TPH batch type plant producing an average minimum-

output of 75 tonnes per hour. Using crushed aggregates of specified grading, premixed with

Slow/Medium setting bitumen Emulsion or tailor made confirming to IS:8887 or as medium curing

cut-back conforming to IS-217@ 7-10% by weight of mix for coldmix material as per IRC:SP:100-2014

& MORTH 5th Revision & Bituminous Binder @ min. 5.4 % by weight of mix for hotmix material as per

MORTH Clause 507.) laying by Paver Machine/Hand laying & compacting with 10MT vibratory

Roller/Plate compactor as per requirement. Paver machine shall be deployed if width of patch

exceeds 3 mtrs and length of patch exceed 20 mtrs

Step – 6 :- Emulsion Painting ( Using with Bitumen Emulsion grade RS 1 @ rate of 5 kg/10 smt by

Mechanical sprayer and spreading the stone dust on prepared surface at the rate of 0.03 cum/10

smt.) for the finish surface using Bituminious Emulsion to form a smooth riding surface.

The operation of the milling machine shall be controlled by levelling beam and automatic sensors unless

otherwise approved by the Engineer In Charge.

The nominated depth(s) of cut of the milling machine shall be as directed by the Engineer In Charge. The

cut shall be automatically controlled, with the control set such that the maximum difference in levels

between adjacent runs shall not exceed 5mm. The average depth of cut measured across the cut from

the adjacent surfaces to the top of the milled surface and at intervals along the work shall not vary by

more than 5mm from the specified thickness.

When milling near access chambers or other similar structures the milling machine shall be operated as

close as possible to the structure without causing damage to it. The remaining asphalt and base course

shall be removed by hand or other method approved by the Engineer In Charge. A ramp using asphalt

Signature of Bidder Page

Ahmedabad Municipal Corporation

shall be formed and compacted around the structure. The ramp shall have a minimum taper length of

1.0m for each 50mm thickness

Longitudinal and transverse ramps, used to tie the milled surface into the existing road levels, shall have a

minimum taper length of 1m for each 50mm variation in levels or part thereof. Where the speed limit

exceeds 60km/h, transverse ramps shall have a taper length of 2.5m for each 50mm.

Milling operation all loose material shall be removed from the road pavement, gully pits and median

areas. The pavement shall be swept and the site left in a clean and tidy state to the satisfaction of the

Engineer In Charge. All cold milled material shall be removed from the site and transported to stockpile

site(s) or otherwise removed from the site to the satisfaction of the Engineer In Charge.

Any material not removed by the milling machine adjacent to concrete medians,kerb and gutter or

drainage structures such as pit grates shall be removed by hand or other means approved by the

Engineer In Charge. When necessary for traffic safety, or when directed by the Engineer In Charge, milled

material or asphalt ramps shall be placed by the Contractor. The Contractor shall liaise with the relevant

Authorities for all underground utility services within the site of the works.

At the end of the day’s work, or whenever the milled pavement is left un attended and reopened to

traffic, the work shall be arranged so that no longitudinal or transverse edges of milled asphalt and base

course, which can affect traffic, are left unattended. Prior to reopening the milled pavement to

unrestricted use by traffic and at the end of the day's work, the final milled lane shall be bevelled such

that the maximum lip between the milled run and the un milled run does not exceed 10mm. When

bevelling is not possible, the fall off in levels shall be ramped with milled material.

Signature of Bidder Page

Ahmedabad Municipal Corporation

Mode of Payment:-

The Payment to the Contractor will be on the per Sq. Mt. Basis. The Surface area of the Pothole/Bad

patch to be repaired will be measured. No extra payment will be made for material to prepare firm

base for big potholes/heavy patchwork. This work will be done by contractor own cost.

General Technical Specification:-

1. In the specifications “as directed” / “approved shall be taken to means “'directed” /

“approved” by the Engineer-in-charge.

2. Wherever a reference to any Indian Standard appears in the specifications, it shall be taken

to mean as a reference to the latest edition of the same in force on the date of agreement.

3. In “Mode of Measurement “in the specification wherever a dispute arises in the absence of

specific mention of a particular point or aspect, the provisions on these particular points or

aspects in the relevant Indian Standards shall be referred to.

4. All measurements and computations, unless otherwise specified, shall be carried out

nearest to the following limits:

(i) Length, width and depth (height) 0.01 meter.

(ii) Areas 0.01 Sq. Mt.

(iii) Cubic Contents 0.01 Cu. Mt.

5. In recording dimensions of work, the sequence of length, width, and height (depth) or

thickness shall be followed.

6. The distance which constitutes lead shall be determined along the shortest practical route

and note necessarily the route actually taken. The decision of the Engineer-in- charge

in this regard shall be taken as final.

7. Where no lead is specific, it shall mean “all leads".

8. Definite particulars covered in the items of work, though not mentioned or included in it

specifications shall be deemed to be included therein.

9. Reference to specifications of Materials as made in the detailed specification of the items

of works is in the form of a designation containing them number of the specification

of the Materials and prefix ‘RS’ e.g. "RS-1"

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

QUALIFICATION INFORMATION

1. The information to be filled in by the Bidder in these statements & supporting documents

submitted in physical form will be used for the purpose of pre qualification as provided in

Clause 4 of the Instructions to Bidder.

2. All statements given here under shall be submitted by bidders on their original letterpads

only with stamp of firm of bidder and sign of the bidder.

3. Photocopy of any statements shall not be considered as valid document.

4. Information / Details to be submitted by the Bidders in the Performa mentioned under

Statement no 1 to 6. All the documents submitted in the support of these statements shall

be duly attested and certified true copy.

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO. –

EQUIPMENTS PROPOSED TO BE DEPLOYES BY THE APPLICANT FOR USE ON THE ROAD WORK.

(Contractor has to submit these details only for the Machineries and Equipments that he intends to

provide for this work.)

Sr. Name of Equipment on hand

No. equipment Total Requirement Equipment to be procured

No. of Kind Capaci No. Year of Name No. Capacity Through

units and ty of Manu. & of of Purchase/

for the make each present owner each Lease

project conditio

1 Batch mix plant

(mini. Capacity

including Filler

unit preferable

filter (mention

manufacture and

The Bidder should

be the owner of

certificate from

Mechanical, Road

department's at

2. Sensor/Mechanic

Nos.)1.5m width

Signature of Bidder Page

Ahmedabad Municipal Corporation

3. Milling Machine

0.55m OR Less (1

4. Vibratory Rollers

5. Plate compactor

6. Bitumen Sprayer

7. Air compressor-

8. Dumpers(as per

9. Tanker 1 nos

10 Level Instrument

The bidder must attached certified copies of the documentary evidence in support of his owning /

leased of the above equipments. In case the bidder proposes to hire or take the above equipment on

lease, he should, along with the lease agreement, attach the proof of ownership of these

equipments with the company/ entity from whom the equipments are proposed to be hired on lease

. Any conditional evidence of deployment of above equipment or inadequate proof as required for

any of the equipment shall make the bid non-responsive and financial bid shall not be opened.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO. –2/A

WORK DONE AS PRIME CONTRACTOR OF A SIMILIAR NATURE DURING LAST THREE YEARS

Sr. Name of the Name Value of Date of Stipulated Actual date Remarks explaining

No. project of the issue of date of of reasons for delay &

Employ contract work completio completion work Completed

Note: Attach certificate(s) from the Employer (to be given by an officer at the rank of Executive

Engineer or equivalent & also supply original or certified copy in physical form envelop)

Seal and Signature of the Bidder Add city Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO. – 2/B

EXISTING COMMITMENTS AND ON-GOING WORKS

(works for which bids have been submitted and accepted and works which are yet to be completed

as on the date 7 days before the last date for bid submission)

Description Name & Date Value of Stipulated Value of Escalation Escalated Anticipated

of works Address of Contract Period of works* factor value of date of

of work (Rs Cr) Completion remaining remaining completion

Employer order to be work

completed during

(Rs Cr) completion

Note: (1) Attach work order copy or certificate(s) from the Engineer(s)-in-Charge of the rank

of Executive Engineer or equivalent & also supply original or certified copy of

certificate in physical form envelop.

(2) Details showing in this statement shall be utilize to finalize the Bid capacity of the

Seal and Signature of the Bidder Add city Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO. – 2/C

DETAILS OF WORKS FOR WHICH BID SUBMITTED AND ACCEPTED (i.e. where contract sign is

Sr.No. Description Place Name & Date of Value Stipulated Value of work

of works & Address of issue of given period for During

State Employer Letter of In LOA completion completion

Acceptance period of work

(LOA) * for which bids

Note: Attach copy of LOA given by the concern department.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO. –3/A

DETAILS OF ANNUAL TURNOVER OF LAST CONSECUTIVE THREE YEARS

Annual Turnover in

Sr. No. Financial Year

Engineering Project (Rs.)

Average Annual Turn Over

1) Figures filled in the above table should to be taken from audited balance sheets and the

same should be attached herewith in duly certified attested true copy

2) Duly certified attested true copies of the balance sheets are to be attached..

Seal and Signature of the Bidder Add city Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO – 3/B

AVAILABLE BID CAPACITY

(Bidder shall calculate, mention his bid capacity and enclose the supporting calculation)

Value of similar works

executed in Rs. (Crores)

The available bid capacity will be worked out as follows:

Available Bid capacity = (A* N* 2 - B)

A = Maximum value of similar works executed in any one year during the last five years

(escalation factor as specified in this section shall be used to bring/calculate the

maximum value of works to the level of financial year) taking into account the

completed as well as works in progress.

N = Number of years prescribed for completion of the works for which bid is invited.

B = Value of existing commitments and on-going works to be completed during the next N

years (period of completion of the works for which bid is invited)

Seal and Signature of the Bidder Add city Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

LIST OF KEY PERSONNEL TO BE DEPLOYED ON THIS CONTRACT WORK

S.No. Personnel Qualification

1 Site Engineer BE Civil 2 year Exp.

2 Traffic Safety Supervisor Dip. Civil 1 year Exp.

LIST OF KEY PERSONNEL CONTRACTOR HAVE

Sr.No. Details of person

3. Qualifications

4. Experience in Project Related field

5. Other experiences

6. Employment Record.

Sr.No. Period Organization under Status / position in

From - To which work the organization

(1) Separate sheet for each person to be furnished as above.

(2) Minimum of 1 person of each category has to be provided

(3) Qualification of each personal along with full CV shall be submitted as a documentary proof

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

STATEMENT NO.-5

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Value of the Reasons/Details for Remarks showing

Year Name of Project (`) litigation/arbitration Present Status

(1) The bidder shall furnish separate table for individual project.

(2) The above information shall be supported with necessary documents otherwise the same

shall be treat as null and void.

(3) A consistent history of arbitration awards? Judgments against the applicants or any partner

of a joint venture may result in disqualification for proposed work.

(4) If the details of litigation History is hidden by the applicant and later on it comes to

knowledge of the employer the bidder shall be disqualified for the proposed work and other

appropriate actions shall be taken against the bidder.

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

METHOD STATEMENT AND WORK PLAN

The Bidder shall have to provide a brief write up to be enclosed with the “Technical Bids“covering

his approach and methodology to handle the project construction activities including his details

work plan. The brief shall include the following aspects.

Sr. No. Components

2. Construction equipment availability and plan of

Seal and Signature of the Bidder Add City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page

Ahmedabad Municipal Corporation

To be notarized by Notary

1. I/We hereby declared that I/We am/are not partner(s) blacklisted or connected with firm

blacklisted in any states, CPWD / MES / Railways or any Government, Semi-Government or

2. The I / We also hereby certifies that our firm M/s ________________________________has

neither abandon any work in India nor rescinded any contract awarded to us during last five

years prior to the date of this bid.

3. At present I/We am/are registered as approved contractor (s), firms in any state, CPWD /

MES / Railways.

4. We, the partners/owners of this firm, hereby give an undertaking that we are jointly and

severally responsible to meet all the liabilities ever and above the business of this firm and

make good the above financial loss sustained by the Ahmedabad Municipal Corporation as a

result of our abandoning the works entrusted to us.

5. I /We hereby certify that all the statements made in the required attachments are true and

6. The I / We undersigned hereby authorise(s) and request(s) any bank, person, firm or

corporation to furnish pertinent information deemed necessary and requested by the

Department to verify this statement or regarding my (our) competence and general

7. I /We hereby declare that I / We understand and agree that further qualifying information

may be requested, and I / We also agree to furnish any such information at the request of

the AMC within the prescribed time.

8. I / We further declare that my / our near relatives are not working in AMC as an Addl. C.E.,

Dy. C.E., A.C.E., A.E., and T.S. as on today.

(Signed by an Authorized Representative of the Firm)