Wanakbori Thermal Power Station

Subject: Supply and Fixing the Chain Pulley Block with different capacity along with respective

Mono rail at Unit No.4,5.6, WTPS.

Reference No:- WTPS/S/TECH/RFQ- 78420E/EMD-2

HSN With Quantity

Sr. No. Description of materials UOM

CODE Cess If Required

CHAIN PULLEY BLOCK WITH

TRAVELING TROLLEY (MANUAL)

CAPACITY 20 MT, LIFTING HEIGHT

CHAIN PULLEY BLOCK WITH

TRAVELING TROLLEY (MANUAL)

CAPACITY 10 MT, LIFTING HEIGHT

Works (Part – B)

Dismantling of existing 20 Ton Chain

Pulley Block and installation &

3 commissioning of new 20 Ton Chain 9 Job

Pulley Block with Monorail Travelling

Dismantling of existing 10 Ton Chain

Pulley Block and installation &

4 commissioning of new 10 Ton Chain 6 Job

Pulley Block with Monorail Travelling

The overall L1 will be considered as SUPPLY (PART-A) + WORKS (PART-B) = L1 (Total End

Cost) including all Items

 Technical specifications:

1) Item sr. no. 1:- 20 Ton Chain Pulley Block with Monorail Travelling trolley Bidder has to

Supply the material as per following detail technical specification only:-

Make: - INDEF-P SERIES,MORRIS , BEMCO, CHACK, ANKER

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

1. Type of Hoist: Chain Block

2. Capacity: 20 Ton

3. Height of Lift: 10 meter

4. Monorail Beam Size: ISMB-400

5. Design Standard: IS 3832 :

6. Ambient Temperature : 45°C

7. Location : Outdoor Duty Application

8. MH Brake Type : Clutch-Screw Type , Friction Disc Type , Self Actuating

9. Load Chain Dia : 10 mm

10. MH Number of Falls : 4 Nos

11. Main Hoist Hook : C Shank Type

12. Effort Required to Lift Maximum Load : 25 Kilogram - Only one person required to lift the load.

Velocity Ratio:

13. Gear Type : Triple Spur Gear Type

14. Heavy Duty Class : Class II

15. Bearing Type : Plain or Rolling

16. Nominal Size of Chain Link : 6 MM

17. Cross Travel Wheel : 100 mm Dia X 4 nos, 280-300 BHN, Forged Steel (C55Mn75) Single

18. Weight of Chain Block : 180 to 250 Kg

19. Painting: Two Coat of Primer & Two coat of Synthetic Enamel paint

20. Lubrication : System Wheels & Pulleys: Local point type

21. Safety Latch: Spring type Safety latch provided for all Hooks

22. Safety Guard : Safety Guard provided for pulley & all rotating parts like couplings, etc.

23. Design Type Test: Accomplished successfully as per the requirement of IS: 3832 - 2005 (4 times

load - lifted for 5 minutes - Once at the time of design stage)

24. Endurance Type Test: Accomplished successfully as per the requirement of IS: 3832 - 2005 (100

Hrs. running on Block at speed of Hand Chain of 20 Mtr./ Min - Once in Six Months)

25. Tested Overload Capacity: Tested at: 50% Overload

26. Manufactured as per Conformity Of Indian Standard : As per IS 3832 - ISI Certified since

Part Wise Material Specification and make: As per Cl. No.6 of IS

1. Hook (Forged): Smruti Forging, Free Trading, MK Forge, Karachiwala, Equivalent confirming IS

15560-2005 Standard

2. Load Chain Wheel : SG Iron, 400/15 (or) Gr, Gr 500/7 (or) 600/3 or Any type of Raw Material

confirming IS: 1865 Standard

3. Hand Chain Wheel : FG 200/220/260, IS: 210, Pressed Steel - Accurately pocketed, Smooth Hand

Chain Pulling Operation

4. Gears & Pinions : En8 / En9 / En 32B & SAE 8620, Alloy Steel Material, precise machined, gear

hobbed & case hardened - duly annealed. Gears shall be lubricated with a semi-liquid grease

instead of oil, which is less likely to leak, eliminates oil level checks.

5. Geared, Un geared runner- : FG 200/220/260 confirming IS: 210 Standard

6. Bearing, Pillow Block : FAG, SKF, NTN, Equivalent

7. MH, AH Gear Box: Elite MHE Or Equivalent Any Standard Make

8. Coupling : Nu-Teck, Sahara, Flexitech, Alliance, Equivalent

9. Spring Bufffer: Insutec, Radient, SP, Equivalent

Mono rail Travelling Trolley:

1. Type of Trolley : Bidder to furnish the recommended size as per existing Trolley

2. Capacity : 20 Ton

3. Height of Lift: 10 meter

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

4. Monorail Beam Size: ISMB-400

5. Design Standard : IS 3838 ,IS 2429 or Equivalent

6. Ambient Temperature: 45 °C

7. Location: Outdoor Duty Application

8. Radius of curvature (Max): 1500 MM or As per Standard

9. Hand Chain (Dia x Pitch) :19 mm x 6 mm

10. Effort Required to Shift Maximum Load: 35 Kilogram - Only one person required to lift the load.

11. Gear Type :Triple Spur Gear Type

12. Bearing Type :Plain or Rolling

13. Net weight with :10 m lift 260.5 Kg

14. Painting :Two Coat of Primer & Two coat of Synthetic Enamel paint

15. Lubrication System : Wheels & Pulleys: Local point type

16. Safety Latch :Spring type Safety latch provided for all Hooks

17. Safety Guard :Safety Guard provided for pulley & all rotating parts like couplings, etc.

18. Tested Overload Capacity: Tested at: 25% Overload

19. Manufactured as per Conformity Of Indian Standard: IS 3838 ,IS 2429 or Equivalent.

2) Item sr. no. 2:- 10 Ton Chain Pulley Block with Monorail Travelling trolley

Bidder has to Supply the material as per following detail technical specification only:-

Make: - INDEF-P SERIES,MORRIS , BEMCO, CHACK, ANKER.

1 Type of Hoist: Chain Block

2 Capacity :20 Ton

3 Height of Lift :10 meter

4 Monorail Beam Size: ISMB-400

5 Design Standard: IS 3832 :

6 Ambient Temperature: 45 ?C

7 Location :Outdoor Duty Application

8 MH Brake Type: Clutch-Screw Type , Friction Disc Type , Self Actuating

9 Load Chain Dia: 10 mm

10 MH Number of Falls : 4 Nos

11 Main Hoist Hook: C Shank Type

12 Effort Required to Lift Maximum Load : 25 Kilogram - Only one person required to lift the load.

Velocity Ratio:

13 Gear Type: Triple Spur Gear Type

14 Heavy Duty Class : Class II

15 Bearing Type : Plain or Rolling

16 Nominal Size of Chain Link : 6 MM

17 Cross Travel Wheel : 100 mm Dia X 4 nos, 280-300 BHN, Forged Steel (C55Mn75) Single Flange

18 Weight of Chain Block : 180 to 250 Kg

19 Painting : Two Coat of Primer & Two coat of Synthetic Enamel paint

20 Lubrication System : Wheels & Pulleys: Local point type

21 Safety Latch : Spring type Safety latch provided for all Hooks

22 Safety Guard : Safety Guard provided for pulley & all rotating parts like couplings, etc.

23 Design Type Test: Accomplished successfully as per the requirement of IS: 3832 - 2005 (4 times

load - lifted for 5 minutes - Once at the time of design stage)

24 Endurance Type Test: Accomplished successfully as per the requirement of IS: 3832 - 2005 (100

Hrs. running on Block at speed of Hand Chain of 20 Mtr./ Min - Once in Six Months)

25 Tested Overload Capacity : Tested at: 50% Overload

26 Manufactured as per Conformity Of Indian Standard: As per IS 3832 - ISI Certified since

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Part Wise Material Specification and make: As per Cl. No.6 of IS

1 Hook (Forged): Smruti Forging, Free Trading, MK Forge, Karachiwala, Equivalent confirming IS

15560-2005 Standard

2 Load Chain Wheel: SG Iron, 400/15 (or) Gr, Gr 500/7 (or) 600/3 or Any type of Raw Material

confirming IS: 1865 Standard

3 Hand Chain Wheel: FG 200/220/260, IS: 210, Pressed Steel - Accurately pocketed, Smooth Hand

Chain Pulling Operation

4 Gears & Pinions: En8 / En9 / En 32B & SAE 8620, Alloy Steel Material, precise machined, gear

hobbed & case hardened - duly annealed. Gears shall be lubricated with a semi-liquid grease

instead of oil, which is less likely to leak, eliminates oil level checks.

5 Geared, Un geared runner :- FG 200/220/260 confirming IS: 210 Standard

6 Bearing, Pillow Block : FAG, SKF, NTN, Equivalent

7 MH, AH Gear Box : Elite MHE Or Equivalent Any Standard Make

8 Coupling :Nu-Teck, Sahara, Flexitech, Alliance, Equivalent

9 Spring Bufffer: Insutec, Radient, SP, Equivalent

Mono rail Travelling Trolley:

1 Type of Trolley : Bidder has to furnish the recommended size as per existing Trolley

2 Capacity : 10 Ton

3 Height of Lift :10 meter

4 Monorail Beam Size: ISMB 140-210

5 Design Standard: IS 3838 ,IS 2429 or Equivalent

6 Ambient Temperature : 45 °C

7 Location : Outdoor Duty Application

8 Radius of curvature (Max): 1500 MM or As per Standard

9 Hand Chain (Dia x Pitch) : 22.5 mm x 5 mm

10 Effort Required to Shift Maximum Load: 31 Kilogram - Only one person required to lift the load.

11 Gear Type: Triple Spur Gear Type

12 Bearing Type : Plain or Rolling

13 Net weight with 10 m lift : 98.3 Kg

14 Painting : Two Coat of Primer & Two coat of Synthetic Enamel paint

15 Lubrication System : Wheels & Pulleys: Local point type

16 Safety Latch : Spring type Safety latch provided for all Hooks

17 Safety Guard : Safety Guard provided for pulley & all rotating parts like couplings, etc.

18 Tested Overload Capacity :Tested at: 25% Overload

19 Manufactured as per Conformity Of Indian Standard : IS 3838 ,IS 2429 or Equivalent

NOTE: Test certificate to be attached at the time of bid for above Item Sr. No. 01 &

3) Item sr. no. 3:- Dismantling of existing 20 Ton Chain Pulley Block and installation &

commissioning of new 20 Ton Chain Pulley Block with Monorail Travelling trolley

(Work to be carried out as mentioned in Scope of Work)

4) Item sr. no. 4:- Dismantling of existing 10 Ton Chain Pulley Block and installation &

commissioning of new 10 Ton Chain Pulley Block with Monorail Travelling trolley.

(Work to be carried out as mentioned in Scope of Work)

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

 SCOPE OF WORK

1) Bidder shall have to submit the offer make technical specification, catalogue and authorize

dealership/distributer certificate along with technical bid.

2) Dismantling of existing 20 Ton & 10 Ton Chain Pulley Block with Monorail Travelling trolley

and installation & commissioning of new 20 Ton & 10 Ton Chain Pulley Block with Monorail

Travelling trolley charges are inclusive of shifting, handling of respective equipment up to

various site locations from Respective stores/sites will be in the scope of the Contractor.

3) All Chain Pulley Block along with Monorail Travelling Trolley erection charges are inclusive

of shifting, handling of respective equipment up to various site locations from Respective

stores will be in the scope of the Contractor.

4) The material will remain in GSECL‟s custody till the commissioning of system.

5) Before dispatch of the material your engineer should be available for receipt of material and

joint inspection of the material.

6) Any Cutting/ fabrication work, Machining work, scaffolding, welding, drilling, tapping, supply

of plate/channels/angles/and other items required for installation of Chain Pulley Block along

with Monorail Travelling Trolley shall be in the scope of party.

7) Bidder has to Arrange the Welding Machine for welding works and All Lifting Tools and

Machines including Crane, Forklift etc for Lifting, Shifting and Erection-commissioning of the

Chain Pulley Block along with Monorail Travelling Trolley.

8) Any other consumable items like connectors, screws, nut bolts, plate, channel ,Welding

Electrodes, sleeves etc. required for erection, installation of Chain Pulley Block along with

Monorail Travelling Trolley shall be in the scope of party at free of cost. However GSECL

provide the addition Power/Control cable with required size as per system requirement.

9) Any scaffolding Preparation like Cup Lock Type Scaffolding work required, the same will be

in the scope of the Contractor.

10) Any Civil work like digging, hole making, masonry etc. will be in scope of Bidder. The Bidder

has to complete all touch work within or after project including cementing, painting etc.

11) All offered and supplied items should be latest.

12) All supplied items should be compatible for Existing Installed Chain Pulley Block along with

Monorail Travelling Trolley and material should provided with standard make.

13) Contractor has to arrange of his own all types of tools and tackles during the work at the

14) All safety precautions should be taken by you (Bidder/Contractor) while men are working.

15) Contractor shall make his own full proof arrangement of storage of spares/ consumable,

tools tackles during contracts. Contractor has to observe all safety rules to avoid any

accidents to any person. For any accident, injury fatal or non-fatal to any worker/person

during work execution for the compensation Bidder will be held fully responsible in all way.

16) All above items are indicative only. Any Components / Accessories not mentioned in above

but absolutely required for complete functioning of the system must be included in offer by

the bidder and will be in Contractor's scope only without any financial implications to

17) The necessary civil work for installation and commissioning of complete Chain Pulley Block

along with Monorail Travelling Trolley is in the scope of the Contractor.

18) Work covered in this contract document shall generally be as detailed. However, contractor

shall be responsible to complete the work in all respects and in doing so provide/ supply all

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

facilities which may not be covered herein but nevertheless are required to complete the

work envisaged with the exception of only such items as have been specifically excluded

from contractor‟s scope.

19) Party has to submit 3 (Three)-sets of documents containing monitoring details, system

drawings, datasheets, configuration details, troubleshooting manuals, BOM with

item/component detail etc. in hard as well as soft copies.

20) All safety precautions should be taken by party (Bidder/Contractor) while men are working.

GSECL, WTPS shall not be liable for any fatal/non fatal accident occurs to bidder‟s person.

21) Party has to maintain the record for the work done and should obtain the sign of supervisor

immediately and also of EIC.

22) All terms and conditions are applicable of works contract of GSECL

23) The Contractor shall be authorized / Certified from OEM. (Required to attach Certificate).

24) GESCL, need full functional of the system. BOM is indicative only. Any Components not

mentioned in BOM but absolutely required for complete functioning of the system must be

included in offer by the bidder and will be in Contractor‟s scope only.

25) The quoted Chain Pulley Block along with Monorail Travelling trolley must of Standard

approved, single make and proper operation compliant only.

26) Contractor or SI should have PF code and WCC Policy for their employees.

27) Contractor has to visit site to solve the defect in newly installed Chain Pulley Block along

with Monorail Travelling trolley within 48 hours any how & has to change spare free of cost

within Guarantee period.

28) The decision of the CE (C&O) WTPS shall be final in case of any dispute.

 TERMS & CONDITIONS

1. Bidder should be OEM/OES/Authorized Dealer of OEM.

2. Bidder has to Supply the material as per mentioned detail technical specification only.

3. Bidder has to submit 50% overload test certificate for Chain Pulley Block and 25% of

monorail travelling trolley.

4. Bidder has to submit guarantee certificate which shall be valid for 12 months from the date of

commissioning or 18 months from the date of dispatch whichever is earlier.

5. Bidder should have to submit authorized dealership certificate along with technical bid.

6. Payment and guarantee terms will be as per GSECL standard terms and condition.

7. Bidder should have to submit purchase proof from OEM at the time of supply the material.

8. Authorized dealer/OES have to submit the latest authorization certificate along with technical

9. Bidder has to provide the application of the supplied materials to required location at plant on

Free of cost. No extra charges for work of application of fire sealing chemical and fire barrier

mineral wool board system for cable.

10. Bidder has to arrange scaffolding to reach up to the work height at its own cost if applicable.

11. The required necessary Tools and Tackles & all other consumable items for this job to be

arrange by party, no any extra charges given by GSECL. Only available aluminum ladder will

be issued by GSECL free of cost during work.

12. Accommodation shall be providing by GSECL on chargeable basis if available.

13. Bidder have to submit the Gov. approved lab/NABL test certificate as mentioned in Technical

specification along with technical bid and during supply the material otherwise offer may not

14. Bidder should submit detail Technical catalogue & literature for offered item inquired against

the same along with technical Bid. Offered material must be as per Tender technical

specifications only.

15. The supplied material must be exactly as per technical specification.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

16. The cost of various testing of complete Chain Pulley Block along with Monorail Travelling

Trolley should be borne by the contractor.

17. Party shall have to supply the material of latest manufacturing date.

18. Bidder has to submit the Test Certificate and Guarantee/Warrantee Certificate along with

Bulk supply of the Material.

19. Time Limit: Validity of the subjected work will be Eleven (24) Months from the Date of LOI.

20. Bidder has to submit interchangeability certificate along with technical bid.

21. Guarantee: The supplied material must be guaranteed for Period of minimum 12 months

from the date of commissioning or 18 months from the date of dispatch whichever is earlier.

Accordingly undertaking of Original Manufacturer & supplier shall be submitted on company's

letter pad. Any peeling off is observed during these periods; it should be rectified & tested by

supplier on FREE OF COST.

22. Bidder has to Confirm to Provide 10 Years of Spares support.

23. Bidder has to give free replacement guarantee against any damage due to transportation

and manufacturing defect. In case of any defects reported to you, the same should be

replaced / rectified within 15 days at free of cost.

24. Delivery Period: F.O.R. GSECL, MAIN STORE WTPS. P&F, Freight & Insurance charges are

inclusive (to be filled by party during online tender submission)

A) Supply: Bidder has to supply material and application of the work within 04 month from the

date of issue of LOI.

B) Work:-The Time Limit for Subjected work order is 24 months from the date of LOI. After

successful completion of testing of supplied material, commencement of work will be issued

by Engineer-In-charge (EIC). Supplier has to commence work within 15 days of letter of

commencement & completion time of each Job is 21 days for one hoist with monorail.

(A) Supply: all the total delivery period should not exceed as per cl. No-25(A) above, however if

the goods are not delivered in time without any reason beyond your control, penalty at 0.5%

per week or part thereof subject to a maximum of 10% will be levied of total order value for

pending material.

(B) Work: The Time Limit for Subjected work is 20 months after commencement of work .The

work will not completed in time without any reason beyond your control, penalty at 0.5% per

week or part thereof subject to a maximum of 10% will be levied on end cost of uncompleted

portion. (i.e. volume of unutilized portion of bulk supply). Stop gap period may consider by

EIC when unable to carry work due to any reason. Same will be informing by EIC via

Mail/Telephonic.

Overall Time Limit for Subjected work order is 24 months from the date of LOI.

Work Completion Time for each Job is 21 Days, if the work will not completed in time without any

reason beyond your control, penalty at 0.5% per week or part there of subject to a maximum of

10% will be levied on end cost of uncompleted portion.

26. Security Deposit: It shall be mandatory to submit 5 % security deposit within 10 days from

the date of issue of Letter of Intent before order placement. In case when successful bidder

not at all responding within notice period or withdraws his offer then his EMD shall be

forfeited and he will not be allowed to participate in the tenders invited from the same office

for the period of One year for that place from where tender is invited.

27. Performance Bank Guarantee

The performance guarantee amounting to 5 % of the end cost shall be furnished. Bank

guarantee is for satisfactory performance of the materials. The BG which should be valid for

24 months from the date of commissioning The PBG should be for the period and should

have clear one time validity for the full period. PBG for an interim period will not be allowed.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

In case of expiry of PBG before the said period the same should be got extended /renewed

till the completion of said period by you at least one months before the expiry of the validity

failing which GSECL will be at liberty to encash the same without entering in to further

correspondence, formalities etc. in the matter.

28. Agreement: The contractor shall have to execute Agreement on stamp paper of Rs.300/-

and Indemnity bond on stamp paper of Rs.300/- in the prescribed form, before

commencement of the work. The Cost of stamp paper shall be borne by the contractor.

29. Work Experience: Contractor must have the experience of similar nature of works as per

above subject only in any Government/Semi Government/GUVNL and its subsidiary/ State/

Central/Railway/NTPC/BHEL/ PSU during last 07 years and copy of complete work order

with Schedule-A or B of the same must be attached with technical bid.

30. Bidder is requested to visit site before quoting to understand the project, if required.

31. Payment T&C: Bidder has to accept GSECL standard payment terms & conditions

a. 80% FOR Destination Price from the date of receipt of material against TRC within

(Thirty) days on verifying required documents as per A/T conditions, amount of GST and

applicable cess will be kept under retention till submission of documentary proof of payment

of GST or till reflection of payment of GST pertain to respective bill amount in GST Return for

concern Order after due verification and

b. Balance 20% of payment will be release after successfully work completion NOC from user-

32. In case of any defects reported to you, the same should be replaced / rectified within 15 days

at free of cost.

33. Subletting of laborious parts of work i.e. scaffolding, material lifting / shifting, cable cleaning

etc. may be allowed with prior permission. However, the core work of application of cable

surface preparation & insulating coating material application must be executed by the

authorized / qualified persons of successful bidder.

34. The required necessary Tools and Tackles & all other consumable items for this job to be

arrange by party, no any extra charges given by GSECL.

35. Accommodation shall be provided by GSECL on chargeable basis if available.

36. Contractor has to take care of all relevant labour laws, etc and fulfill the requirements

necessary for Acceptance of A/T.

37. All the General Terms and Conditions of the works contract of GSECL are applicable to this

contract and binding to the contractor.

38. No compensation will be paid by GSECL in case of any injury / accident to their staff while

39. Contractor should have to produce P.F. code No. / labour license No. / Income Tax PAN No

with technical bid.

40. Safety Rule:-

[A] In case of injury/accident while working .it shall immediately be reported to safety department

through EIC. the prescribed form no 21 may be obtained from EIC or safety officer. For any

incident occurred but have no injury to any persons should also informed to safety officer as

Near Miss Incident.

[B] Contractor shall have invariably to submit “Fitness Certificate” of the working staff from

qualified doctor having qualification not less than MBBS to the EIC & safety officer before

reporting to the work.

41. In case of any dispute, decision of the Chief Engineer (Gen.) will be final & binding to the

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist: Kheda -388239

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018 Certified Power Plant

Pre-Qualifying Criteria (Prequalification Condition)

1) The Bidder should produce certificate/document as evidence for experience of having

successfully completed similar works/jobs (qualifying criteria for similar works/ job should be

clearly defined) carried out satisfactorily for minimum one year in last seven years period in

government/semi government/ state electricity board/ corporation body/ private limited

company/ public limited company.

2) Details of minimum tools, tackles and equipment in possession relevant to the job.

3) The contractor shall have to attach Copy of PAN number; GST Registration Number to be

submitted which are applicable. Photo copy of valid electrical license (IMP Dep‟t) must be

4) Details of skilled / Semi skilled persons if any presently employed by the contractor for similar

contract going on, elsewhere having sufficient knowledge of similar jobs.

5) Detail of the partnership deed, in case it is partnership firm.

6) Copy of the Receipt for payment of Tender Fee / EMD.

7) Similar works means “Supply and Fixing the Chain Pulley Block with different capacity along

with respective Mono rail at Unit No.4,5.6, WTPS.”

8) Copy of power of attorney in the name of bidder if partnership deed is enclosed & the firm is not

9) Technical deviation should not be considered except mention on deviation page in tender

10) The experience of work carried out by bidder as sub-contractor to the other agency will not be

11) Separate provident fund code number towards registration of your firm with Regional P.F.

12) In case of any dispute, the decision of the Chief engineer (C&O) is final and bound to bidder.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist: Kheda -388239

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018 Certified Power Plant

GENERAL CONDITIONS OF CONTRACT

1. The contractor shall at their own expense make all necessary provision for housing water supply

and sanitary arrangement for their employee as well as for works and shall pay direct to the

authorities concerned all rates and taxes.

2. The contractor shall make their own arrangements for the necessary approach road, for

transport of their materials and be responsible for the Compensation on account of damage to

crop on Corporations‟ property.

3. All the royalty charges octroi other duties will be paid by the contractor and no extra could be

claimed on this account.

4. The organization will supply articles at the place and rates mentioned in schedule „A‟ of Tender

form.In case of the materials issued either through or with the recommendation of this

organization it will be absolutely necessary for the contractor to maintain a correct and honest

record of the daily consumption of the said materials/with inside particular reference to the work

during the day.

The Engineer-in-charge of this department or his authorized agent shall have the right to inspect

and check the stores containing these materials and the account for these materials shall be

presented for inspection whenever asked for by them. Every facility shall be afforded by the

contractors for all these inspections Engineer-in-charge will supply the materials in any quantity

5. Godown of sheds hired or constructed for storage of controlled materials and more/ particularly

of cement shall be such as would prevent the materials from getting damages in any way.

6. It will be absolutely incumbent of the contractors to have on the site of work only such of the

materials as have been dully passed by the Engineer-in-charge Materials that have been

rejected must on no account be allowed to remain on the side and in spite of written order to do

so any such rejected material is on the site beyond a period of 48 hours, notice the Engineer-in-

charge shall have the right to remove it at the risk and cost of the contractor and even destroy it.

7. It must be distinctly understood that the conditions of the contract and of claims in respect of

extra work will not be allowed, unless the works to which they relate is clearly without the spirit

and meaning of the specifications or unless such work are ordered in writing by the Engineer-in-

charge and claimed for in specified manner.

8. On completion of the work, the site shall be cleared by the contractors within the stipulated

period, and ground brought to original state and they shall not be entitled for any extra claim on

9. DAMAGE CAUSES TO WORKS:

The work whether fully constructed or not, and all materials, machinery plant tools, temporary

building and other things connected there shall be at the risk and in the sole charge of the

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

contractor until the works have been delivered, completed to the Engineer- in-charge and

certificate from him to that effect obtained until such delivery the contractor shall at their own cost

take all the precautions reasonably necessary to keep all the aforesaid works materials

machinery, plant, tools, temporary building and other things connected with the work, free from

any loss or damage and in the event to the same or any part there of being lost or damage shall

from with within possible speed, reinstate and make good such loss or damage at contractor‟s

10. Supply of controlled articles will be invariably recommended after the actual requirements have

been carefully scrutinized. In the event of any such materials remaining in surplus in charge of

the contract, on account of some modifications either in the design or changes in construction or

any other reason will be returned to the department.

11. There will be generally no objection on the component parts of the works being given over to

responsible sub contractors but it must be borne in mind that this department would under no

circumstances recognize these sub contractors and responsibility of executing the work in

accordance with the condition of the contract will entirely rest on the main contractors. The main

contractors will therefore always have the very responsible member preferably a technical hand,

present on the works with power to sign all work order issued on the site of work and to take

requisite actions in the interest of very efficient execution of works.

12. With a view to ensure rapid progress on the works purchaser may store at work sites certain

quantities of the materials such as cement etc. and it will be incumbent on the tender to

purchase these materials, at the rates mentioned in schedule „A‟ of tender form for supply of

necessary articles, all necessary help will be tendered but in must be clearly understood that the

purchases does not accepted and responsibility for the delay that may be cause in their supply

on account of circumstances beyond the purchaser‟s control.

13. Contractor will be asked to present the sample of materials and the approved sampled will be

preserved at the site of work and no change in the approved sample will be allowed without the

written permission of the Engineer-in-charge.

14. Contract will have to communicate the name of his authorized agent who shall be presentation

the works and shall be authorized to sign the materials requisitions receive instruction given

verbally, or on the order book on behalf of the contractor.

15. The materials issued to the contractor as per schedule „A‟ of the tender shall not be removed

from the work and all surplus material at the end of the works which is considered serviceable

shall be returned to the organization even the unserviceable material shall be removed only with

the prior permission to the E.E. in writing.

16. The contractor will have to sign the conditions of the contract and execute the agreement, send

the list of previous works executed solvency certificates and pay up the security deposits, failing

to that the tender will be rejected and earnest money deposit will be forfeited. The value of the

stamp paper and stamp duty charges shall be borne by the contactor.

17. The contractor must arrange for all transport of materials weighting of material issued at

department stores and all such cost include in the rates of schedule „B‟.

18. The competent authorities can delete to any items in the schedule „B‟ of the tender order if they

feel that the items is not essential to be executed.

19. A schedule of quantities is included in the tender document it shall definitely understood that the

Corporation does not accept any responsibility for the correctness or complication of this

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

schedule-B. The tender documents shall be written legibly and free from grouser, over written on

conversion of figures correction where unavoidable shall be made by crossing out initialing

dating and rewriting both in figures and in words in case of my discrepancy in figures the price

quoted in words shall prevail.

20. This notice to tenders shall form a part of the contract.

21. The entire work is to be completed within the stipulated time limit from the date of work order.

The contractor will not be eligible for any extra for the idle period of work or waiting period that

may be required to suit other considerations and no claim for compensation on account of such

will be considered. However in case or delay due to circumstances beyond the control contractor

either in date of commencement or due to waiting during construction extension time may be

considered for completion of work.

22. In case contractor is unable to account for full quantity of materials issued to him from the

department stores, recovery will be effected from him at cost rates or market rates prevailing at

the time of issue whichever is higher, plus 15% to cover Corporation‟s departmental supervision

charges for all material unaccounted for.

23. Bill shall be submitted by the contractor monthly on or before the date fixed by the E.E., for all

works executed in the previous months.

24. SUPPLY OF WATER AND ELECTRICITY:

If possible water for construction purpose only may be supplied by the Corporation at one point

as decided by the Engineer & recovery for water charges shall be effected at two percent of cost

of time as executed in which the water supplied by the Corporation is used as certified by the

Engineer in charge Electric supply is required the contractor shall be given Free of cost by

GSECL. (Applicable to CIVIL WORKS only).

25. Should this tender be accepted, I/We have agreed to abide by and full fill all the terms and

provision of „Tender and Contract of works‟ as applicable, and in default thereof, to forfeit and

pay to the Corporation the some of money due.

26. The work will have to be carried out in co ordination with other Agencies on the same site on

account of this in case the contractor has to stop or delay his works for same time he will not

claim anything extra only Corporation may consider to give suitable extension in time limit if

necessary on such account.

27. Any disputes arising out of the contract if not settled mutually, than the same shall be settle by

Gujarat Public Work Arbitration Tribunal act-1992.

28. Following clauses of this section are not applicable to this contract i.e.

The following are the major obligations to be fulfilled by the Contractors as per the Contract

Labor (R&A) Act 1970 and rule mentioned there under:

1. License to be obtained before starting the Work where number of contract laborers in Fifty or

2. Payment to contract laborers has to be made in presence of IRO/LWO. Wages rates for contract

laborers are applicable as per the terms and conditions of the license. The contractor shall have

to pay wages to workers as notified by Government of Gujarat., from time to time

3. Every contractor shall have to maintain the muster roll and wages register in respect of his

contract labor.

4. Every contractor is required to issue employment card, wages slip and attendance card to their

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

5. The contractor has to maintain the register No. 13 containing details of contract labors employed

6. Earned leave register/ card as per the Factories Act. And Rules.

7. Other registers required under Contract Labor Rules and the Factories Act. And Rules.

8. Every contractor shall have to obtain insurance policy in respect of the contract labors engaged

by him to cover them under workmen‟s Compensation Act.

9. To send half yearly return to licensing officer as per Rule 82 (1) as per schedule time.

10. Before starting the work as per the contract awarded to him, he should make arrangement to

enter into the agreement in the prescribed format on the stamp paper as applicable. Before

fulfilling the above requirement the contractor is instructed not to start the work. The

responsibility will be on his head in case he fails.

11. Contractor should posses separate P.F. code on their firm, name otherwise their offer may must

All the contractors are informed to adhere to the rules and regulations applicable to them,

particularly in respect of the laborers engaged by them, the contractor not fulfilling the obligations

will not be allowed or continue with work/ not be held qualified to carry out the work at TA-

Galteshwar Dist. - Kheda Power Station.

It has been directed by our CO that, no new labor contract be entrusted to any agency without

getting prior approval from CO. Further the existing contract, on their expiry, may not be

extended without approval from HO, Vadodara.

In light of the instruction conveyed by HO, it is necessary to check up the following documents of

each and every contractor before awarding the contract to these contractors. For preliminary

checking of valid contractors, the following documents are required to be checked by the

concern DE/EE/SE. On their checking the same and by recommending the number of labors,

gate pass will be issued by the Sr. Security officer. But before awarding and finalizing any

contracts, following information must reach to IRO for his confirmation.

1. The contractor should not allowed to engage fifty or more contract labors without initiating to

obtain the labor license under the Contract Labor Act from the Assistant Commissioner of Labor,

Nadiad (The same number i.e. fifty or more includes Supervisor and other staff).

2. Number of days of the contract should be informed first before allowing the contract to start. The

Contractor also must obtain group insurance under WC Act before starting the work.

3. The contract laborers must be paid minimum wages as per notification issued by competent

authority under the said Act from time to time upon issuance of Circular by Chief Engineer,

WTPS. The above instruction must be followed scrupulously to avoid labour liabilities under

Contract labor Act.

“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTOR

All the contractors working in Gujarat State Electricity Corporation LimitedFactory like

Coal/Lignite/Gas/Hydro/Pumping Station shall have to strictly observe the following Safety

Rules. Concern principle contractors are responsible for informing & observance of these rules

by their supervisors/contract workers as well as the owner/supervisors/ workers of sub-

Contractors engaged, if any, by them for the work contract awarded to them. Prior to

commencement of the work, Contractor shall have to submit a written assurance on their

letterhead to the concerned Sectional Head / Engineer-in-charge that they have thoroughly gone

through these Rules, have educated their employees / workers of their sub contractor and will

strictly observe the said Rules while execution of work under work contract awarded to them.

They will have to indemnify the company for any loss or damage / accident / injury to the

company‟s property / employee or employee of their own in default of non - observing these

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

1. Contractor should issue photo gate pass for their workers from GSECL Factory Manager as per

Gujarat Factories rules, 1963 & details shall be filled up in GSECL gate pass format as per

Aadhar card /Election card id proof & to follow the gate pass issue procedure through concern

department EE & SE, Security Officer, LWO/IRO/DGM, Factory Medical Officer, Safety

Officer/Dy. Safety Officer & Factory Manager.

2. In case of emergency, temporary photo gate pass shall be issued by Security Officer only for

three days with prior permission of Factory Manager only. More than three days, Permanent

photo gate pass procedure shall be completed by contract agency for their contract workers.

3. Certificate of Fitness of employment in hazardous process & operations in form no.33 of Gujarat

Factories rules, 1963 shall be issued by GSECL Factory Medical Officer for all contractor

workers before commencement of work & examination responsibility shall be taken by contractor

as well as concerned Head of Department .Pre-employment & Periodical medical examination of

contractor workers shall be carried out in form no.32 from GSECL Factory Medical Officer after

every six (06) months of contractor with their contractor workers. Contractor shall be fulfilled all

health requirements before commencement of work. After completion of medical examination in

form no.32/33, GSECL Factory Medical Officer shall be signed in contract worker gate pass

procedure format.

4. If work executed outside factory premises, Principle Contractor shall be registered compulsory

under The Building & Other Construction Workers (Regulation of Employment and condition of

service) Act, 1996 and The Gujarat Building & Other Construction Workers (Regulation of

Employment and condition of service) Rules, 2003 before execution the ”building or other

construction work” means the construction, alteration, repairs, maintenance or demolition, of or,

in relation to, buildings, streets, roads, railways, tramways, airfields, irrigation, drainage,

embankment and navigation works, flood control works (including storm water drainage works),

generation, transmission and distribution of power, water works (including channels for

distribution of water), oil and gas installations, electric lines, wireless, radio, television, telephone,

telegraph and overseas communications, dams, canals, reservoirs, watercourses, tunnels,

bridges, viaducts, aqueducts, pipelines, towers, cooling towers, transmission towers and such

other work as may be specified in this behalf by the appropriate Government, by notification but

does not include any building or other construction work to which the provisions of the Factories

Act, 1948 (63 of 1948), or the Mines Act, 1952 (35 of 1952), apply.

5. Contract worker gate pass will issue after completion of safety induction 3D animation movie &

Training record is to be maintained in IMS/OHSAS training format by TK Office/LWO.

6. As per Gate pass format of GSECL, Safety Officer/Dy. Safety Officer shall be checked the issue

PPE to contract workers as per nature of job, Form no.10 of lifting tools and tackles, Driving

license, Electrical contractor license, Electrical trade qualifications, Safety induction training,

SOP, supervisor qualifications etc. After fulfillment of all Safety compliances, Safety Officer/Dy.

Safety Officer shall be signed in Contract worker Gate pass procedure format.

7. Work Contract shall be completed by principle contractor/agency/person who is awarded the

work order. Subletting of contract shall be allowed only if prior approval of Power station chief

before execution of work. Contractor/agency shall be submitted the entire subletting contract

documents with gate pass application through concern department EE & SE, LWO/DGM, Safety

Officer/Dy.Safety Officer & Factory Manager.

8. Under The Conditions Framed Under Rule-45 Of The Indian Electricity Rules, 1956, Valid

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Electrical contractor License shall be submitted to concern electrical department

EE/SE/Electrical Safety Officer/ Safety Officer/Factory Manager at the time of apply gate pass by

agency/Contractor with latest renewal from Chief Electrical Inspector, Gandhinagar- Gujarat.

Electrical License photocopy shall be checked by Concerned HOD of Electrical

Department/Electrical Safety Officer/Dy.Safety Officer/ Safety Officer/Factory Manager.

9. As per nature of job/work, Qualified supervisor (Diploma (Electrical/ Mechanical/Civil/C&I) +

3 years experiences or ITI + 10 years) shall be engaged by contract agency & qualification

certificate with experience certificate shall be submitted to concern EE/SE/LWO/IRO/DGM/

Dy.Safety Officer /Safety Officer/Factory Manager at the time of apply gate pass.

10. As per rule 3 of CEA regulation ,2010: Designating person(s) to operate and carry out the

work on electrical lines and Apparatus, Contract person/worker possesses a certificate of

competency or electrical work permit, issued by the Appropriate Government. That means,

Electrical trade Qualification of contract worker/person like ITI-wireman/ Electrician, Diploma

(Elect), BE/B. TECH (Elect), ME/ M. TECH (Elect) shall be submitted to concern

EE/SE/LWO/IRO/DGM, Dy.Safety Officer/ Safety Officer/Factory Manager at the time of apply

for photo gate pass procedure.

11. As per nature of job/work & during capital overhauling work /Annual overhauling work /24X7

round the clock work/major shut down work, Qualified Safety Officer/Manager/Supervisor

(BE/Diploma (Elect/Mech/Civil) + PDIS-Post Diploma in Industrial Safety) shall be engaged by

contractor during dangerous operations/dangerous works as well as day to day dangerous

activities, safety supervision, tool box talk, Safety awareness programme, SOP preparation with

hazards & its control measures with each step , checking of lifting tools & tackles, hydra mobile

crane, Safety precautions, coordination with Safety Department etc.

12. License of driver shall be submitted with gate pass issue application as per nature of vehicles &

to follow the Motor vehicle Act,1988,the Central Motor Vehicles (Amendment) Rules,2016 as well

as Gujarat Motor Vehicles rules,1989 & driver license shall be checked every day by security

shift in charge before entry in the Factory premises.

13. SOP with JSA (Job Safety Analysis) shall be prepared by contractor through competent person

as per GFR, 1963 or Qualified Safety Officer as per GFR, 1963 with 05 years experiences. SOP

will review & approve by concern JE/DE/EE/SE/Elect. Safety Officer/Dy. Safety Officer /Safety

Officer/Factory Manager before execution of work.

14. It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as per the job

requirement. Do not work without use of required P.P.Es. Contractor is responsible to provide

standard make (ISI/DGMS/CE/EN/ANSI approved) & to checked standard/make in PPE issue

format by concern JE/DE/EE/SE/Safety Officer/Factory Manager. Personal Protective

Equipments / Safety Gadgets suitable to give sufficient protection against hazards involved in

their work / job to their staff, as per the job requirement and insist / enforce their workers to put

on the same while at works.

The ongoing work is liable to be stopped at any time if your contract workers/staffs found working

without P.P.Es. Following is the list of various P.P.Es (as per ISI/DGMS/CE/ EN/ ANSI approved

only) to be used for various works / worksites.

In any work, Contractor shall be issued the minimum 06 nos. of PPEs like Safety Shoes, Safety

Helmet, Safety goggles, Mask & Reusable Ear plug, hand gloves to their workers/supervisor

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

compulsory & it will check by concern section HOD & Dy. Safety Officer /Safety Officer at the

time of gate pass procedure.

Quality of PPE shall be approved from Safety Officer as per Indian Standard and International

Standard before executions of work or at the time of gate pass apply procedure.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

List of safety equipments

Industrial Safety Helmet For protection of head against falling objects or during

fall of person from height. YellowColour helmet is

used for contract worker with agency logo.

Safety Goggles/welding goggles/ For protection of eyes against flying particles / dust,

chemical splash goggles chemical splash, welding spark, arc, flashover etc.

Full Face shield For protection of face against flying particles / dust,

chemical splash, spark, arc, flashover etc.

Reusable Earplug / Ear muffs. For ear / hearing system protection while working in

high noise level area.

Chemical suit/Gas tight suit /Fire For body protection against chemicals, oils, sharp

proximity suit/FR Boiler Suit edged objects, heat, hot objects etc.

Safety Hand Gloves For protection of hands against chemicals, oils, sharp

edged objects, heat, hot metals/objects, electricity etc.

Safety shoes/ Gum Boots with For protection of leg/feet against falling objects, sharp

Oil/Chemical/water/heat/ Electrical edged objects, heat, hot metals/objects, electricity etc..

resistance etc.

Safety Belt(full body hardness with For fall prevention while working at heights or in depth,

double lanyard & shock absorber) / working in vessel or in confined space.

Rope / Life line / Fall arrestor etc.

Dust Mask/Respirator with Protection of respiratory system against dust.

Chemical Cartridge Respirator with Protection against toxic chemical fumes /

full face mask type A2B2E2K2 gases/vapors/dust etc.

Trolley mounted Air line respirators Working in oxygen deficient zone or confine space area

with full face mask

Portable Single gas detector like Working in hazardous storage/process area

Chlorine, Ammonia, Hydrogen, etc

Portable Multi gas Detector Working in oxygen deficient zone & use in entry of

( LEL,O2,CO,H2S,SO2, etc) confine space & Major fire

Automatic voltage detector To check the present voltage or induction voltage of

electrical equipments/ bus/switch gears from 01 (one)

feet distance before starting the any electrical work .

Auto darkening welding helmet (EN The new auto darkening welding helmet combines

379 & EN 175 Level-B) with PAPR as legendary Speed glass quality and auto darkening

per EN 12941:1998, class TH2 and technology with an innovative wide-view grinding visor

AS/NZS 1716 to give welders an all-in-one solution for more

flexibility, precision, and efficiency.

Respiratory System is a combined face and breathing

protection device, for increased comfort and safety in

welding. The unit is equipped with a particle filter

which removes particles from the air. The unit provides

a constant airflow independent of filter combinations

and clogging. The unit can also be equipped with a

gas filter (for example A1B1E1). The unit supplies air

to the head top via the connecting breathing tube. The

airflow creates a slight positive pressure which

together with the sealing to the face prevents particles

and other contaminants from entering the head top.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

15. All PPEs (as per ISI/DGMS/CE/EN/ANSI approved only) Should issued by

party/agency/contractor to their contractor workers as per nature of job and allotment of PPE list

shall be submitted to Safety Officer, Wanakbori on his letter head as per below mentioned format

by Contractor before commencement of work through concerned JE,DE,EE/SE .

Sub: Issue of PEE to Contractor workers

Sub of work Order:

Name of Agency:

Date of Commencement:

Time limit for work order:

Sr Nam De Name Name of IS Make Qt Unit Dat Receivin

. e of sig of PPE :Code of y e of g

N work nat Section no. of PPE issu signatur

o ers ion under PPE e e

16. Shift Security Inspector/Security Officer shall be checked Safety Shoes & Safety Helmet of all

contractor workers at entry gate of Factory Premises & shall entered contractor workers with

Safety Shoes & Safety Helmet with photo ID Gate Pass.

17. Shift Security Inspector/Security Officer shall be checked validity of Gate pass of all contractor

workers on daily basis.

18. During the work execution, one trained & competent supervisor of agency should always remain

present at work site. Concern JE/DE of GSECL shall be supervised the contract work as per

19. Approved NABL laboratory calibration certificates of electrical/mechanical/Civil/C&I/Environment

survey/Chemical etc measuring /testing equipments/instruments which are used during contract

work shall be submitted before starting the work & shall be checked by concern JE/DE/EE before

starting work & it‟s record shall be maintained in concern section.

20. The contractor shall take all the required safety measures prior to commencement of work on

dangerous substances, machineries or area at which cautionary notice is displayed and obtain

“Line Clear” or “Work Permit” through the concern Department / Section JE/DE and shall be

informed to concern section JE/DE for closed/ returned after completion of work.

21. Safety talk/Safety work instructions shall be given to contractor workers by concern JE/DE

regarding hazards of specific work, risk & it‟s control measure (mentioned in HIRA) before

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

starting the job work and records shall be maintained for each & every job works.

22. Display Safety instructions shall be strictly followed by all workers who are working in factory

23. Material Safety Data Sheet (MSDS) of each chemical shall be available with Chief

Chemist/Control room &work related Chemical information shall be taken by contractor &

contractor workers from Concern EE/Chief Chemist before starting of chemical handling work.

24. The contractor shall be checked & securely covered or securely fenced any opened fixed vessel,

sump, tank, pit or opening in ground or in floor which, by reason of its depth, situation,

construction or contents ,is or may be a source of danger before starting the work each & every

days or after interval/recess. Contractor supervisor shall be informed to concerned HOD

regarding any unsafe conditions.

25. Prohibition of smoking, fires, lights, spontaneous ignition substance, matches; fuses, mobile

phone etc are to be strictly followed by all workers who are working in factory premises.

26. Prior to carrying out welding, gas cutting, furnace heating or any other hot work job, remove all

the inflammable material lying at or nearby worksite or cover it properly by suitable protective

covering. Also, special care shall be taken before carrying out such job & see that all possible

contributing factors to set fire shall be removed / vanished prior to commencement of the work.

Advance intimation shall be given to concerned section / fire section to commence the work in

fire prone areas. They should also keep ready all the First Aid Fire Extinguishers / equipments&

fire extinguishing media / material like sand / water buckets or other appropriate equipment at

27. While carrying out work in confined space or inside vessel, obtain necessary “Confined Space /

Vessel Entry Permit” from concerned department prior to commencement of the work.

For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp shall be

used. For taking care of the persons working inside the confined space / vessel, a supervisor /

person capable to keep continuous watch on person(s) working inside, assist them in case of

emergency or arrange to get immediate outside help, shall remain present at entry point. Use full

body safety belt without failed.

While working inside sewage, trench or in-depth, a person to warn outsiders / entrants / passers

etc shall remain available near entry point or the entry point shall be cordoned by a barricaded

tape with a cautionary notice. After completion of the works, all the lids / covers / grills / grits

opened, shall be re-fixed / re-placed in the original position as it were prior to commencement of

the work and leave the work place in safe condition in all respect, so as to prevent accident to

fellow workers.

28. The contractor shall see that he / his persons do not work on or block (by stacking material,

spare parts, tools-tackles, equipments etc), any passages / walkways / gangways / aisles /

staircases / ladders / lifts or any other approaches / roads leading to plans or its auxiliaries, on

which there is traffic movements or possible traffic movements in case of emergency. Such

passages are meant for safe escape in the event of emergency. If it is utmost necessary to carry

out work in such area with blocking of passage, prior permission of Competent Authority or the

Engineer-In-Charge shall be obtained. To demarcate / declare the area as “UNSAFE”, cordon it

using barricading tape & display suitable caution notice or keep a person to restrict / divert the

traffic on this route through other safe passage.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

29. Prior to use power / electrically operated hand tools / equipments / machines / gadgets like

welding machine, hand grinder, hand drill etc, ensure for its safe operation & use it only if it is

found safe to use. Do not use defective, unsafe or improperly maintained equipments.

30. The electrical power supply required to run such equipments shall not be taken directly at their

own but shall be obtained through concerned Electrical Maintenance Departments or their

authorized persons or under their observations / guidance only. The Electrical Section shall

provide temporary electrical connection up to contractor‟s Mains Board on which it is compulsory

to install mains switch, ELCB & fuses of adequate capacity. All such equipments shall invariably

be earthed adequately to prevent electrical shock, sparking, short circuit etc. Power cord to be

used shall be of adequate capacity, without any joint & shall consist of earth wire also. Hence, it

is necessary to use adequate capacity 3-wire power cord for single & 5-wire power cord for three

phase power connections. The plugs, receptacles, pins, holders etc shall be of adequate

capacity & safe to use.

All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting machine,

Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used during work execution

shall be of standard make & bear ISI certification mark on it. The consumables like welding

electrodes, grinding wheels / discs etc which has specific prescribed life span shall not be used

in any case if its expiry date is over.

31. Non-Sparking Non-Magnetic electrical hand tools and tool kits shall be used by Electrical

contractor for safe use in areas where hazardous, flammable, or combustible vapors, liquids,

dusts, or residues may be present in Gas Based power plant and list of tools and tackles shall

be submitted with technical bid. Non-Sparking Non-Magnetic electrical hand tools and tool kits

shall be checked by JE/DE before commencement of Electrical work.

32. Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift, mobile crane,

EOT crane etc) & its attachments (like D-shackles, slings, U-clamps, Eye bolts or any fixtures), it

shall be checked and used only if found safe to use. Also, ensure that these are tested,

examined & certified in form no.10 by Competent Person as per the Factory act-1948 & Gujarat

Factories Rules and its validity do not expire. Further, it shall be fixed properly and firmly prior to

lifting the weight. Valid Test certificate of all Lifting machines used by Contractor to be

submitted to Dy.Safety Officer/ Safety Officer before commencement of work through

concerned EE/SE.

33. Metal Scaffoldings to be used for working at height shall be of adequate size & capacity. Obtain

the work permit when working at height. While climbing on such scaffolding or working on any

structure at height, use of full body safety belt /full body hardness with double lanyard & Fall

arrestor & Helmet is compulsory. It is also necessary to fasten chinstraps of the helmet.

34. Contractor or their employee shall not interfere in day-to-day routine plant activities / works

except the work assigned to them, shall not loiter in the areas other than their work jurisdiction,

as well as shall not temper / operate / touch the machineries/equipments/auxiliaries with which

they are not concerned. Also, the contractor shall strictly instruct their staff for not to sit or take

rest at/near/below running plants, auxiliaries, systems or any place which is risky, hazardous &

prone to accident.

35. The cylinders containing poisonous / toxic or inflammable / explosive gas like Oxygen,

Acetylene, LPG, Hydrogen, Ammonia, Chlorine, CO2etc shall be handled safely taking due care.

To handle / shift such cylinders a special trolley /cage meant for it must be used but in no case it

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

should be rolled.

36. In Gas Based Power station/Hydrogen storage area /Hydro carbon fumes-vapour generated

area, Spark arrestor (as per approved manufacturer of CCOE, Nagpur) shall be provided on

each vehicle by party/agency and it will check by shift security in charge before entry of vehicles

in the factory premises.

37. No women or young person shall be employed or permitted to work in Lead-compound area like

battery room etc. as per schedule VI of GFR

38. No women or young person shall be allowed to clean, lubricate or adjust any part of a prime

mover or of any transmission machinery while the prime mover or transmission machinery is in

motion. Examination or operation of motion machinery shall be made or carried out only by a

specially trained adult male worker wearing tight fitting clothing as per section 22 of factories act

39. In all risky job, before start the work, contractor should obtain General Safety Work Permit

through concerned section from Shift –in-charge well in advance.

40. In case of noticing smoke or fire during their work execution, they shall make immediate efforts to

extinguish / control it and simultaneously inform the Fire Station Mobile No as well as Station Fire

Officer or Emergency Control room no which is displayed at prominent place of factory like Main

Security Gate, All unit control room, Canteen area, Safe Assembly points, Fire Station, All

security gates, Occupational Health Centre.

41. In case of any injury / accident while working, it shall immediately be reported to Safety

Department through concerned Sectional Head / Engineer. The prescribed Form No.

21&ANNEXURE may be obtained from concerned section or Dy.Safety Officer/Safety Officer.

In case of any electrical accident, it shall immediately be reported to Electrical Safety Officer

through concern Sectional Head / Engineer. The prescribed Electrical accident form no. A as

per electricity act-2003 & Form No. 21 & ANNEXURE as per Gujarat Factories rules shall be

filled up by concern department JE/DE with written consent of contractor. The Form may be

obtained from concerned Electrical section or Electrical Safety Officer. Electrical accident

investigation shall be carried out by Electrical Safety Officer with Factory Manager.

After any reportable accident, Contract agency shall be submitted the fitness certificate of injured

person with endorsement of GSECL factory Medical Officer to LWO/Dy.Safety Officer/Safety

Officer/Electrical Safety Officer then after injured person may allow for work.

42. For any incident occurred but have no injury to any persons should also reported as per GSECL

format and informed to Dy.Safety Officer/Safety Officer as Near Miss Incident.

43. Safety penalty shall be imposed against Offences by contract workers: If any contract

worker worked in a factory contravenes any provision of Factories act or any rules or orders

made there under ,imposing any duty or liability on workers, contractor/agency shall be

punishable with fine which mentioned as under.

Sr. Description of penalty Amount

(i) Work without PPEs Rs.300/- per person

(ii) Work without work Safety permit like working at Rs.1000/- per day

height, confine space entry, hot work etc.

(iii) License of driver as per type of vehicles not Rs.750/- per person

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

(iv) Welding work without flashback arrestor/double Rs.1000/- per set

gauge regulator set

(v) Operate Portable power tool without ELCB Rs.1000/-per equipment

(vi) Work without qualified Supervisor as per nature of Rs.1000/-per day

job like mechanical, electrical, civil, C&I, chemical

(vii) Work without SOP & JSA Rs.2000/-per day

(viii) Work without test report of lifting machines / Rs.2000/- per equipment

tackles (like C.P.Bs., Hook chooks, winch, forklift,

mobile crane, EOT crane etc) & its attachments

(like D-shackles, slings, U-clamps, Eye bolts or

any fixtures) in Form No.10 of Gujarat Factories

(ix) Work without Double lynyer Safety belt during Rs.3000/-per person

working at Height work, work without anchoring in

(x) Work without 24 Volt supply in Confine space Rs.3000/-per person

(xi) (a) Grinding machine used without safety guard / Rs. 500/- per equipment / per set

(b) Unsafe welding machine like open body, Knob

without insulation, connection without lug

(c) Damaged welding cables/gas pipelines

(d) Welding work doing without welding blanket

(e) Electrical supply without 3 pin plug/ Industrial

(f) Use of damaged electrical wire for lighting /

(g) Use of lighting lamp without cage

(h) Use of open halogen tube

(i) Use of damaged PPEs/use of non standard

(j) Unsafe lifting and handling of gas cylinders

(k) Cylinder handling without safety cap

(l) Temporary connection without ELCB etc.

During plant visit/supervision of concern JE/DE/EE, SE, Safety Officer/Safety Officer/Electrical

Safety Officer and Factory Manager/Occupier, if they will observed any safety violations as per

CO circular/statutory requirements then they must imposed Safety Penalty through office note

directly against contract workers/ contract agency and Office note process through proper

channel to concern Section head and Account head for recovery purpose. Photograph/CCTV

camera footage is to be put up with penalty note by imposed individual officer.

44. Contractor will damage any fire equipments or property or machinery in factory during execution

of work, total damage cost will be recovered from Contractor RA bill and recovery Office note put

up by concern HOD.

45. All the relevant labour and industrial laws shall also be followed compulsorily.

46. After completion of work, cotton waste, grease, oil, unused material, welding rod pieces, scrap

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

etc. are to be removed by contractor and scrap shall be deposited to scrap yard of Main Store.

47. For performance evaluation of contractor, safety factors of work accident, fire incident & near

miss accident will be considered. Steps can be taken to review the job assignment up to

cancellation for negligence.

48. Over & above these, contractor shall have to follow all the safety requirements /rules &

regulations / norms and legal provisions laid down in various statutes. Particularly the provisions

of The Factories Act-1948 & the Gujarat State Factories Rules-1963 (Amended up to date), The

Electricity Act-2003 & rules, BOCW Act/Rules shall be followed strictly. The contractor shall also

obey the rules / regulations / instructions of the local Competent Authority for safety & health

49. The above rules shall be scrupulously followed and where required, Contractor /contractor

workers may contact to the Dy.Safety Officer/Safety Officer/Electrical Safety Officer in case of

any ambiguity or needs further guidance in this regard.

GENERALCONDITION AT CONTRACT

1. “Contract” means the documents forming tender and the subsequent agreement that may be

2. “Work” or “Works” means the work related to the subject mentioned in tender.

3. Contractor” means a firm or an individual undertaking these works or offers the rates for this

4. The general rules and regulations of the GSECL for tender and contract for works will apply to

the extent of the same and not modified herein. The contractor is deemed to have gone through

and considered to be fully aware of the conditions mentioned therein.

5. Earnest Money Deposit:

Tender should be submitted along with Earnest Money Deposit (EMD), without which tender is

liable to be rejected. The exemption in payment of EMD shall be given under following clauses.

1. Micro & small-scale enterprises which participate directly in tendering process for the

product which they are manufacturing / service which they are providing and have

Udyam registration for items / service under procurement.

2. Start-ups which participate directly in tendering process for the product which they are

manufacturing/ service which they are providing and re-cognized by DPIIT under the

Start-up India Program and has obtained Udyam registration.

3. Organization which has registration certificate for the manufacturing product of the

tender, from Gujarat Khadi Gramodyog Board or Khadi and Village Industries

Commission (K.V.I.C) or Commissioner of Cottage Industries.

4. Board/Corporations/PSUs of the Central/ State Government for their own manufactured

5. State Government recognized organizations like (i) organizations for blinds, dumb and

deaf, disabled, mentally disabled persons; (ii) women's self-help group recognized by

Gujarat Livelihood Promotion Company; which participate directly in tendering process

for the product which they are manufacturing / service which /they are providing.

6. Security Deposit:

It is mandatory to submit security deposit before order placement. Contractor shall have to pay

security deposit of 5% of contract value within 10 days from the date of letter of intent. Such

security deposit will be payable either in D.D./ Bank guarantee. Bank guarantees from

scheduled/ nationalized banks will be acceptable if the amount of security deposit payable

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

exceed Rs 5000/- . The bank guarantee will be excruciated on the standard form prescribe by

the corporation. In case of bank guarantees furnished/ submitted they should have clear one

time validity till the completion of the order in all respects and up to the expiry of the guarantee

period from the date of work completion. Bank guarantee for interim period will not be allowed. If

by any reason the work period is extended than contractor should undertake to renew the bank

guarantee at least one month before the expiry of the validity failing which GSECL will be at

liberty to encash the same.

If the full security amount is not paid immediately after the receipt of the letter of intent,

than the order will not be placed (at the discretion of the GSECL) and without entering to

any correspondence and this will be binding on the tenderer.

If the tenderer fails to pay the security deposit or defaults in execution of the orders place

or if GSECL suffers any financial loss due to this, then GSECL will be liberty to adjust the

amount of others orders of the same firms or by encasing the bank guarantee.

Failure to deposit the S.D. will entail for failure of EMD and the contract shall be treated

as terminated. You shall not be, allow to start the work if, S.D. is not paid. Any loss to the

GSECL due to late start of the work because of the late payment of S.D shall be

contractor‟s liability.

SD will be accepted in form of Bank guarantees issued by ….

[A] Any nationalized bank

[B] Guarantees issued by following banks will be accepted as SD/EMD for the period

up to Dt:31.03.2027. The validity cut-off date In the GR is with respect to the date

of issue of Bank Guarantee irrespective of the date of termination of Bank

A. All Nationalized banks

B. Guarantees issued by following banks will be accepted for the period up to 31-03-2027.The

validity cutoff date in GR is with respect to date of issue of bank Guarantee irrespective of

the date of termination of Bank Guarantee.

1 Axis Bank 23 AU Small Finance Bank

2 Bandhan Bank 24 City Union Bank

3 CSB Bank. 25 DBS Bank India Limited

4 DCB Bank 26 Dhanlaxmi Bank

5 Equitas Small Finance Bank 27 FEDERAL BANK

6 HDFC Bank 28 HSBC Bank

7 ICICI Bank 29 IDBI Bank

8 IDFC First Bank 30 Induslnd Bank

9 Jammu and Kashmir Bank 31 Jana Small Finance Bank

10 Karnataka Bank 32 Karur Vysya Bank

11 Kotak Mahindra Bank 33 RBL Bank

12 South Indian Bank 34 Standard Chartered Bank

13 Tamil nadu Mercantile Bank 35 Ujjivan Small Finance Bank

14 YES Bank 36 Ahmedabad Mercantile CO-op. Bank

15 Nutan Nagrik Sahakari Bank

37 Rajkot Nagrik Sahakari Bank Ltd.

16 Saraswat Co-Operative Bank 38 SBPP Co-Operative Bank Ltd.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

17 SVC Co-Operative Bank Ltd. 39 The Cosmos Co-op bank Ltd.

18 The Gujarat State Co-

40 The Surat District Co-Op. Bank

19 The Surat People‟s Co-Op. The Baroda Central Co-operative

20 The Panchmahal District Co-

42 The Kalupur Commercial Co-op. Bank

The Rajkot Commercial Co- The Banaskantha Mercantile Co-opelative

operative Bank Bank Ltd.

22 Gujarat Gramin Bank

In tender process, for L-1 Bidder Security Deposit will be charged as per table below.

Security Deposit

Category of the Unit Purchase Up-to Rs. 5 Purchase of more than

Lakhs Rs. 5 Lakhs

Enterprises or organizations Exempted 3% of order value

which are Exempted from

paying tender fee & EMD as

per procurement policy

For all other enterprises 5% of order value 5% of order value

7. The security Deposit/ Bank guarantee covering execution of the contract will be released only on

successful execution of contract and on receipt of the “NO Objection Certificate” from the

Engineer In charge of the work.

8. Sublet or transfer of contract without prior written approval of G.S.E.C.L., will be treated, as

breach of contract and it will be punishable by forfeiting the Security Deposit as well as

termination of contract.

9. The G.S.E.C.L. reserves the right to forfeit the S.D. in case of any breach of contract and in case

of disputes the decision of C.E., G.S.E.C.L Wanakbori T.P.S. shall be final and binding and shall

be acceptable to the contractor. If the contractor fails to start the work as stipulated the EMD and

the SD shall be forfeited.

10. The following are the major obligations to be fulfilled by the Contractors as per the Contract

Labor (R&A) Act 1970 and rule mentioned there under:

1 The contractor should not be allowed to engage fifty or more contract labourers

without initiating to obtain the labour license under the Contract Labour Act from the

Assistant Commissioner of Labour Nadiad (the said number i.e., fifty or more includes

Supervisor and other staff.)

2 The contractors shall have to obtain group insurance under Employee‟s

Compensation Act before starting the work.

3 All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized Bank

compulsory, preferably situated in the premises of Wanakbori TPS area in case of ARC

/BRC works Contract. The Contractor shall supply copy of Bank Statement duly stamped by

the Concerned Bank as a token of proof towards payment of Wages to HR Department. In

Case of Non ARC/ BRC works contract, it is also expected the same practice to be adopt

by the contractor.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

4 Payment to contract laborers has to be made through Bank/ Cheque/ RTGS only.

Wages rates for contract laborers are applicable as per the terms and conditions of the

license. The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

5 It should be ensured that all the labours engaged by contractor are covered under

the provident fund scheme and employee‟s pension scheme and their contribution are

remitted regularly to the concerned RPFC. The Xerox copies of challan along with ECR in

this regards should be submitted regularly in G.S.E.C.L. office.

6 In case the contractor having more than one contract in the same TPS, the

contractor shall have to submit contract wise separate list of the workmen to the concerned

7 The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

11. Labour Laws:

The labour laws applicable and amended from time to time have to be followed scrupulously. A

few of them for information are as under:

a) Person below the age of 18 years and above 60 years should not be employed for the work.

b) No female worker shall be employed in the night shift between 7.00 P.M. to 6.00 A.M.

c) The contractor shall maintain a valid labour license under the contract labour (Regulation and

Abolition) Act for employing necessary man power to be required by contractor. In the

absence of such license the contract shall be liable to be terminated without assigning any

reasons thereof.

d) The contractor shall at his own expense comply with all labour laws and keep the G.S.E.C.L.

Indemnified in respect thereof. Some of the major liabilities under various labour and

industrial laws, which the contractor shall have to comply, which are as under:

I) Payment of contribution by way of employee‟s contribution towards provident fund,

family pension scheme, deposit linked insurance scheme, administrative charge etc., at

the rates made applicable from time to time by Govt. of Gujarat /Govt. of India and other

statutory authorities.

II) Payment of deposit in respect of each contract labour at the rate applicable of with the

offices of Commissioner of Labour as per the contract labour (Regulation and Abolition)

III) License fee as prescribed under the contract labour (Regulation and Abolition) Act and

rules framed there under depending upon the number of workmen employed by

IV) Identity cards as prescribed under the factories Act shall be issued to workmen.

VI) Payment of retrenchment compensation, Notice pay and other liabilities as per

Industrial Disputes Act. Any payment to the contractor's employees arising out of any

claim or disputes under the Industrial Dispute Act 1947 or any other labour laws

VI) Payment of compensation in case of accidental injury shall be made as per the WC Act.

VII) If the female workmen are more than 50 numbers engaged then provision of crèches,

shall be complied accordingly.

VIII) Maternity leave as per the provision of the maternity benefit Act.

The above are some of the major liabilities of the contractor in addition to other liabilities

prescribed under the various labour laws in force from time to time from statutory Authorities like

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

State Government / Government of India, which the contractor shall have to comply with.

12. Provident Fund and Family Pension Scheme:

The contractor shall submit along with his bill (month wise) statement regarding deductions

against employees‟ provident fund and family pension scheme in respect of each concerned

employee. Provident fund and family pension scheme at the rate of 12 % of wages (or at the

rates made applicable by the Government time to time). The contractor‟s contribution and his

workers contribution towards provident fund and family pension scheme shall deposited by the

contractor with Regional Provident Fund Commissioner, Ahmedabad. In case if the contractor

deposits the contribution to the Assistant Provident Fund Commission, the zerox copy of challans

and schedule must be submitted in the office. For maintaining the CPF Account of contractor‟s

employees the contractor will have to pay administrative charges as applicable of the

emoluments of the employer of the contractor's every month.

13. Group Insurance Scheme:

The contractor has to take Group Insurance for all workmen engaged by him and copy of the

same shall be produced to Concerned Officer.

14. Paid Leave Facility:

Paid leave facility at the rate of one day for every 20 days worked by the contract, labour shall be

provided the contractor to his workers. It shall be duly verified and approved/certified by the

authorized officer of the GSECL.

15. The contractor shall employ adequate number of experienced staff at site for daily supervision

and for maintaining of various registers and records required under the law and contracts. No

payment for such supervision shall be admissible.

16. Contractor to Indemnify the GSECL:

The contractor shall indemnify and keep indemnified the GSECL, and every member, officer and

employees of the GSECL, also Engineer-in-charge and his staff against all actions, proceedings,

claims, demands, costs and expenses whatsoever arising out of or in connection with the matter

referred in above clauses and elsewhere and against all actions, claims demands, cost and

expenses which may be made against the GSECL by any workman/ employees of contractor or

any sub contractor and or from any liability any wise to any workman/employees of the contractor

or sub-contractor under any laws, rules or regulation having in force of law including but not

limited to claims against the owner under workmen compensation Act, 1923. The Employee‟s

Provident Fund Act.1952, and/or the contract labour (Abolition and Regulation) Act,

The GSECL shall not be liable for or in respect of or in consequence of any accident or injury to

any workmen or other person in the employment of the contractor or his sub-contractor, and the

contractor shall indemnify and keep indemnified the GSECL against all such damage and

compensation and against all claims, demands proceedings costs, charges and expenses

whatsoever in respect of or in relation thereto.

17. Workmen’s Compensation Fund and Employer’s Liability Insurance:

Insurance shall be affected for all the contractor‟s employees engaged in the execution of these

contracts. If any of the work is sublet, the contractor shall required the sub-contractor to provide

workmen's compensation and Employer's liability insurance for the latter's employees unless

such employees are covered under the contractor‟s insurance. It shall be liability of contractor

for employees of his sub-contractor.

18. Any other rules and regulations, conditions, circulars etc. that are in force at present and that

may be framed by the GSECL from time to time in connection with the contract will be binding

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

and acceptable to the contractor.

19. The contractor must possess separate P.F. code for the above subject work.

20. Attendance rolls shall be maintained up to date. All the written registers, Performa etc…shall be

filled up and maintained up to date and kept ready for inspection at any time or submitted in-time

to the concerned authorities as per contract labour etc. Factory Act. etc... By contractor.

21. It is the responsibility of the contractor to ensure that his employees maintain strict discipline as

regards security, methods of safe working etc., and not to cause any hindrance to smooth

running of power station or in execution of duties by GSECL staff. Any lapse in this regard will

be viewed seriously and contract is liable to be terminated. If any of contractor‟s staff is found

unsuitable or not behaving properly, the contractor shall have to remove him from the work-site

on demand by GSECL. The contractor shall have to strictly observe the rules and conditions

specified in the enclosed works contract booklet of the GSECL, which are not modified

hereunder. To keep harmonious Industrial Relations amongst contract labours is the sole

responsibility of the contractor. Any breach of the same will be viewed seriously.

22. Before starting the work, the contractor should contract Industrial Relation Officer/ Labour

Welfare Officer for all formalities and obtaining the gate passes of all contract labourers and for

other formalities.

23. Follow the following procedure at each milestone for the execution of works contract.

(A) On Commencement of Contractual Work:

(1) The Contractors shall have to obtain Photo-Gate-Pass before the commencement of

contractual work awarded. Contractor shall have to apply for the gate passes in triplicate

in a prescribed application form which is to be available from Security Section for the

entry of workmen in the premises.

(2) Such application shall have to be proceed for the approval of Factory Manager. After

obtaining approval of Competent Authority, contractor shall have to prepare the Gate

Passes and obtain the signature of Factory Manager.

(3) If Labours are required to be engaged in Emergency during Public Holiday , Contractors

Can apply for Temporary Gate-Pass for the period of only three days with

recommendation of respective EE/SE and the same shall have to be regularized after

following the procedure of Gate Pass applications on the office working day from HR

Department. It is to note that No Temporary Gate-Pass shall be issued for the work other

than acute emergency to carry out the work in power station premises.

(4) The Contractor shall have to obtain the Group Insurance Policy under the Employee

Compensation Act, 1923 prior to commencement of work.

(5) The Contractor who intend to engaged 50 or More than 50 labours to Carry out the

awarded contractual work then necessary - Form No. V under the Contract Labour (R&

A) Act, 1970 / Form No. VI under the Interstate Migrant worker (employment regulation)

rule 1979 as applicable is to be obtained from HR Department for the purpose of

obtaining Labour License from the Licensing Authority.

(B) During Contractual Work under the progress:

(1) Bill Recording Officer of User department shall have to ensure as to whether contractor

has engaged minimum number of contract workmen per day as per the terms of work

(2) All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized Bank

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

compulsory, preferably situated in the premises of Wanakbori TPS area in case of ARC

/BRC works Contract. The Contractor shall supply copy of Bank Statement duly stamped

by the Concerned Bank as a token of proof towards payment of Wages to HR

Department. In Case of Non ARC/ BRC works contract, it is also advisable the same

practice to be adopted by the contractor.

(3) All Contractors has to comply & maintain statutory documents / registers at site under the

provision of labour laws & EPF Act.

(C) Submission of Statutory documents to ensure the compliances:

The Contractor shall have to submit following statutory documents, work order wise, under the

labour laws and EPF to the recording officer of user department for ensuring the compliances of

provision of labour laws and EPF Act for the respective working period.

 Copy of Attendance register – with name & address of establishment, Name of work and

site (duly signed & stamp by Contractor ) - Form XVI

 Copy of Wage Payment Sheet – with signature of workmen, duly signed & stamped by

Contractor - Form XVII

 Copy of Bank Statement of Wage Payment (duly signed & Stamp by Concern Bank)

 Copy of PF Challan along with ECR Statement

 Copy of Gate Pass Permission ( duly signed by Authorities ) -

 Copy of Work Order ( First Time )

 Copy of Valid W.C. Policy

 Copy of Valid Labour License ( If Applicable in case of More than 50 manpower

Engaged by Contractor for said work )

 Form No. XIII – Register of workers employed by Contractor

 Form –C – copy of Bonus Register

 Form -19 – copy of Leave with wages Register

Prescribed under the Contract Labour (R&A) Act, 1970 Contractor shall specify the Name of

Work, Place of Work and Work order number in Muster Roll- Form No. XVI& Wage Register –

24. Submission of the bill by the contractor:

Bills shall be submitted by the contractor for each month on or before the date fixed by the Site In

charge, for all works, executed in the previous month and the Site In charge shall take or cause

to be taken the requisite measurement for the purpose or having the same verified and the claim

so far as it is admissible, shall be adjusted, if possible, within ten days from the presentation of

the bills. If the contractor does not submit the bill, within the time fixed, as aforesaid, the Site In

charge may depute a subordinate to measure up the said work in the presence of the contractor

or his duly authorized agent, whose counter signature in the measurement list shall be sufficient

warrant and the Site In charge may prepare a bill from such list which shall be binding on the

contractor in all respect. Along with the R.A. Bill, the contractor should submit material Account

wherever applicable, proof of payment of provident fund and other statutory dues, certificate

issued by I.R.O. / L.W.O certifying average number of labour deployed during the month and

total amount of wages and salaries paid to labour. Payment will be made as per actual work

total amount of wages and salaries paid to labour. Payment will be made as per actual work

done only after taking joint measurement and The contractor will be paid 100 % amount of

actual work done on satisfactory completion of job work .Payment will be released within 30 days

from receipt of recorded bill in all respect as per corporation‟s rules. However, amount of GST

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

and applicable cess will be kept under retention till submission of documentary proof of payment

of GST or till reflection of payment of GST pertain to respective bill amount in GST return after

due verification.

25. Income Tax:

Income tax will be deducted at source from each bill as per statutory requirements. The GSECL

will be entitled to deduct directly from the bills to be paid to the contractor any sum or sums

payable by the contractor and which sum/sums the GSECL is required to pay as a principal

employer on account of contractor‟s default in respect of all liabilities referred to in above

 No sales tax, professional tax or any other taxes, cess or levy, excise duty, octroi, royalty

or other duties will be payable by the GSECL against this contract.

 Service tax at the rate prevalent during period of execution of contract and if applicable

will be reimbursed on production of certified copy of registration number and paid Challan

for payment of service tax from time to time.

26. The quantities mentioned in the Schedule-B are approximate only and may vary widely. The

contractor shall be paid for the actual works carried out at the rates quoted by him.

27. The TDS @ 2% as per Sections 57A and 57B GST Act shall be deducted from the contractor‟s

28. Compensation for the Delay:

The time allowed for carrying out the work as entered in the tender shall be strictly observed by

the contractor and shall be reckoned from the date on which the order to commence work is

given to the contractor. The work shall throughout the stipulated period of contract be proceeded

with all due diligence (time being deemed to be the essence of contract) and the contractor shall

pay, as compensation, an amount equal to ½ percent or such smaller amounts, as the

Competent Authority (whose decision in writing shall be final) may decide of the amount of the

contracted cost of whole work as shown by the tender for every day that the work remains un-

commenced or unfinished after the proper dates. Provided always that the total amount of

commenced or unfinished after the proper dates. Provided always that the total amount of

compensation, to be paid under the provisions of the clause, shall not exceed 10 percent of the

contracted cost of the work as shown in tender.

29. Deposit Linked Insurance Scheme:

The contractor shall have to deposit 0.50% (half percent) or the rate applicable from time to time

of the wages in respect of employees who are members of the PF, as the contribution to the

Deposit Linked Insurance Scheme, with the Regional Provident Fund Commissioner,

30. Liability towards Gratuity:

The contractor shall deposit 15 days salary at the rate of last drawn salary for every completed

one year of service for each worker for the liability of gratuity.

31. Minimum Wages Act:

The contractor shall pay prevailing minimum wages as applicable from time to time to the labours

engaged by him as per the minimum wages Act, in presence of the GSECL officer or

representative.

32. E.S.I. Act.:

The contractors shall comply with the provisions of E.S.I. Act wherever applicable as per the

prevailing provisions of the Act and as amended from time to time.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

33. Administrative Charges:

Administrative charges for maintaining Provident Fund account shall be deposited by the

contractor with the Regional Provident Fund Commissioner, Ahmedabad, at the rates applicable.

The contractor shall strictly observe all safety rules and provide safety equipment to the contract

labours as per the Factories Act, 1948, and whatever amendments made from time to time to

avoid any chance of accident. The contractor shall strictly observe all instructions of Safety

Officer and Factory Inspector to avoid any chance of accident.The contractor has to provide

safety articles to his contract labour as per the nature of work they have to perform in the

contract. A certificate in this regard has to be obtained from Safety Officer then the detailed work

order will be issued.

35. Compliance to Security Matters:

The power station being a restricted / prohibited area, all the formalities as required by the

Security and Vigilance staff of GSECL should be complied with, to whom the contractor should

36. Submission of Returns & Maintenance of Records:

The contractor shall submit the returns under the Contract Labour Act, Payment of Bonus Act,

and Payment of Gratuity Act etc. and shall have to maintain all up-to date records/registers in

respect his employees as prescribed under various Labour Laws and produce the same as and

when demanded by GSECL‟s appropriate authorities.

37. Contract agreement & indemnity Bond:

As per Corporation‟s rules, Contractor will have to submit an agreement with the Corporation on

stamp paper of appropriate value Rs.300/- in the prescribed form within one month of receipt of

this A.T. or before starting the work. The cost of the stamp fee shall be borne by you. The tender

This letter and subsequent correspondence shall be deemed to be part of the Contract.

Contractor will have to submit an Indemnity Bond also with the corporation on stamp paper of

appropriate value Rs.300/- in the prescribed form before commencement of the work. The cost of

the stamp fee shall be borne by you.

38. The contractor must be maintaining regular labour record and should be paying all acquired

benefits to labour force and contractor should obtain certificates to this effect from Labour

39. Because of this contract, the GSECL shall not accept any additional labour liabilities than stated

40. The contractor will make arrangements at his own cost to insure all men, materials and

equipment employed for this work. The GSECL will not be responsible for any loss or damage

either to the contractor‟s personnel or his equipment.

41. Dispute, if any, taking place between the contractor and labourers must be intimated to Labour

Welfare Officer, Wanakbori TPS, immediately.

42. The contractor must insure all the labourers before starting the works.

43. Any casualty will also have to be borne by the contractor for the period the contract continues.

44. The contractor shall not engage any sub-contractor without written prior permission of the Chief

Engineer or the authorized officer of the GSECL. In no case the GSECL will be liable in any

manner regarding any liability in respect of any contract labours engage by the sub-contractor

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

and the liability of such contract labours will solely rest with the principal contractor.

45. The GSECL reserves the right to terminate this contract at any time during its currency without

giving notice of termination or any reason thereof.

46. In case of default, the work will be got done through other agency / agencies at the risk and cost

of the original contractor, and the GSECL shall be entitled to recover such expenses from

defaulting contractor by such methods as deemed fit. The contractor shall not, however, be

entitled to terminate the contract or stop works undertaken by him before expiry of the contract

period / extended period due to any reason whatsoever.

47. Under the contract, the contractor should either himself be present at the site or should nominate

persons in writing, who must be available at site and who should be authorized to take decisions

about the works and receive the instructions from Site In charge of the work at any time. In

absence of any responsible man of contractor at the time of any emergency, adhoc decision of

Site In charge will be binding on the contractor.

48. The contractor is bound to execute the work for any item as per the instruction of the Site In

charge. On refusal to do so, the work will be carried out at the risk and cost of contractor by

using the contractor‟s tools and tackles, for which no compensation whatsoever shall be payable

to the contractor.

49. If any immovable articles/tools/equipment will be found stolen from the working place, the

contractor would be held responsible and cost will be recovered from his bill.

50. For any conflict and ambiguity, the decision of the Chief Engineer (C&O) shall be final and

binding on the contractor.

51. DISPUTE RESOLUTION MECHANISM:

(1) Amicable settlement

Any dispute, difference, controversy or claim between the Parties arising out of or relating to

this contract with reference to the construction, interpretation, breach, termination or validity

thereof (hereinafter referred as “the Dispute”) shall, upon the written request of either Party

be referred to the authorized representatives of the Disputing Parties for resolution. The

authorized representatives shall promptly meet and attempt to negotiate in good faith a

resolution of the Dispute within thirty days of the service of the request.

(2) Arbitration

If the Parties fail to amicably resolve the disputes or differences or contrary claims as

indicated herewith in sub clause (1) of this Clause, arising under or in connection with the

present Works Contracts, whether pertaining to works contracts alone or works and

Procurement both, the same shall be referred to arbitration under the Gujarat Public works

Contracts Disputes Arbitration Tribunal Act,1992”

52. “D.G.S. & D. Force Majeure Clause”

“ If, at any time during the continuance of this contract, the performance in whole or in part by

either Contractor of any obligation under this contract shall be prevented or delayed by reason of

any war, hostility, act of the public enemy, civil commotion, sabotage fires, floods, explosion,

epidemics, quarantine restrictions, strikes lockouts or acts of God ( hereinafter referred to as

event)”, then provided notice of the happening of any such event is given by either Contractor to

the other within twenty one days from the date of occurrence there of neither Contractor shall by

reason of such event be entitled to terminate this contract nor shall either Contractor shall have

any claim for damage against the other in respect of such non-performance of delay in

performance, and deliveries under the contract shall be resumed as soon as practicable after

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

such event has come to end or ceased to exist, and the decision of the Managing Director as to

whether the deliveries have been so resumed or not shall be final and conclusive.

Provided further that if the performance in whole or part of any obligation under this contract is

prevented or delayed by reasons of any such event for a period exceeding 60 days, either

Contractor may at its option terminate the contract provided also that if the contract is terminated

under this clause, the Purchaser shall be at liberty to take over from the supplier at a price to be

fixed by the Managing Director of the GSECL, which shall be final, all unused undamaged and

acceptable materials bought out components, and stores in course of manufacture in the

possession of the supplier at the time of such termination or such portion thereof as the

Purchaser may be deem fit excepting such materials, bought out component and stores as the

supplier may with concurrence of the Purchaser elect to retain”.

53. The contractor shall quote rate & also furnish GST, if any, as per Schedule-B. Nothing will be

paid extra as a part of contract unless & until, it is specified in the tender documents by GSECL.

54. The rates quoted shall be firm and valid for 180 days for acceptance from the date of opening.

55. The contractor, if desired, can see the plant and site on any working day and during working

hours with permission of the Chief Engineer.

56. Conditional tender is liable to be rejected withdrawal or insertion of conditions unilaterally after

opening of tenders will not be permitted unless it is so desired by the GSECL.

57. Office correspondence will be carried out in English language, and if at any time to facilitate the

contractor, Gujarati translation may be furnished, if deemed fit. The English version will be the

correct one and the same only will held good for legal matters.

58. The contractor should intimate to the office the name and address of authorized and responsible

representatives, so that our field officers can contact them when required in connection with the

execution of the said works.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Contract Labour Information Management System (CLIMS)

GSECL has developed a Contract Labour Information Management System (CLIMS)- a

comprehensive digital platform designed to manage all activities related to contract labour

transparently and efficiently.

The primary objectives of CLIMS are to save time for both agencies and GSECL personnel, to

ensure full legal and regulatory compliance and to reduce the operational burden on agencies,

allowing them to focus on their core activities. To ensure the successful implementation and

operation of CLIMS, the following guidelines are hereby issued.

l. CLIMS is a web-based system that can be accessed by agencies from any location using a

desktop, laptop, or mobile device.

2. To begin using the system, agencies must register by entering their EPO (E Urja Order)

number. All other necessary details are automatically fetched from the E-Urja system.

3. The issuance of gate passes for contract labour is managed entirely through CLIMS. Agencies

can generate and track gate passes within the system.

4. In order to enable gate pass issuance, agencies are required to input and upload the

necessary details of their contract labourers into the system.

5. Once the required information is submitted, the gate pass approval process is initiated and

managed through the system. The request automatically moves through the predefined workflow

levels. Agencies can monitor the real-time status of their gate pass applications via CLIMS.

6. Upon completion of all required approvals within the system, the gate pass is issued to the

B. Attendance and wages of workers:

1. Once contract workers gate passes are approved in the system, they are required to be

registered in Bio-Metric/Face Reader Punching machines by HR Department.

2. The attendance of all contract workers can be monitored and maintained through CLIMS by

3. Access to data of Bio-Metric is given to agencies. It should be the duty of agencies or his

supervisor to ensure the supply of specified number of manpower and to ensure their Bio-Metric

punching and reporting at the location of work.

4. Attendance register and wage register of the worker will be generated by CLIMS from the login

of agency only.

C. Compliance to various labour laws:

l. All the contractors have to comply various labour laws and they shall submit the attached

Declaration-cum Indemnity Bond before staring of work. This Bond may also be made part of

ensuing tenders/contracts.

2. Contractors shall upload the CLIMS generated previous month attendance sheet, wage register

duly signed by workers, wage bank statement, ECR copy, PF Challan and Remittance slip.

3. The said submitted documents in CLIMS will go to user department, after verification of

completeness of documents, user department will forward it to HR Department for further

verification and approval.

4. If the documents are complete, HR Department will approve in CLIMS and send to Account

Department for further process of bill.

5. If non-compliance is found in submitted documents, it will be returned to user department in

CLIMS with specific remarks and user department will forward it to contractor for compliance. In

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

such cases, 75% of the bills may be released subject to a maximum ceiling of 20% of the contract

values. Such system of payment shall be allowed only for 3 monthly Running Accounts (RA) bills

(Maximum cumulative amount up to 20% of the contract value) of the contractor in a period

contract (AMC) of 12 months or 6 RA bills in a period contract (BMC) of 24 months if there is non-

compliance. All other RA bills and specifically final bill shall not be processed if the previous &

current compliances are not made by contractor. No such relaxation will be granted for non-

periodic, one time or overhauling type contract.

D. Special Case:

In case of work order issued for expert services to PSU or OEM/OES following procedure may be

1. If officers / specialized manpower / expert Engineers from Govt / Semi Govt Companies / PSUs

/ OEM/OES/foreign experts are deployed for short-term, specialized, or ad-hoc technical /

consultancy services (e.g., commissioning, maintenance, consultancy or inspections), concerned

Engineer In-Charge (EIC) shall certify the same

2. The EIC must obtain following documents from the concerned Govt / Semi Govt Companies /

PSUs/OEM/OES etc:

(i) Declaration cum undertaking (As Per Annexure-A) that visiting experts are their regular

employees with documentary proof, and

(ii) Declaration towards compliance of applicable labour laws.

The above documents shall be submitted along with the bill / Invoices by EIC to HR department

for the purpose of HR clearance in lieu of the procedure at Clause -C above.

SIGNATURE OF CONTRACTOR

WITH SEAL & DATE

Chief Engineer (C&O)

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

Declaration –cum-Undertaking

This is to certify and declare that Shri [Employee's Full Name] , son/daughter of [Father's Name], is

a permanent/regular employee of [Company Name], employed in the capacity of [Designation].

His/Her Employee ldentity Card is attached herewith for reference.

It is further declared that his/her Universal Account Number (UAN) under the Employees'

Provident Fund and Miscellaneous Provisions Act, 1952, is IUAN Number] as applicable

We hereby undertake and declare that:

1. We have complied with all applicable provisions of all the labour laws , including but not

limited to the Employees' Provident Fund and Miscellaneous Provisions Act, 1952; the

Employees' State lnsurance Act, 1948; the Payment of Wages Act, 1936; the Payment of

Bonus Act, 1965; the Contract Labour (Regulation and Abolition) Act, 1970; the Minimum

Wages Act, 1948; and other relevant labour and industrial legislations, in respect of Shri

[Employee's Full Name] as applicable to us.

2. We further undertake to produce, as and when required, all statutory records, registers,

Challans , and returns as proof of compliance to the Gujarat State Electricity Corporation

Limited (GSECL) or any other statutory/government authority.

3. We hereby indemnify GSECL in respect of any civil or criminal liability which may arise due

to any non-compliance of the law of the land in respect of our above-mentioned

This Declaration-cum-Undertaking is issued in good faith and to the best of our knowledge and

belief and shall be binding upon us.

Authorised Signatory,

For [Company Name]

[Authorised Signatory Name]

[Seal/Stamp of Company]

[contact Details]

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

SUB: Supply and Fixing the Chain Pulley Block with different capacity along with respective Mono rail at

Unit No.4,5.6, WTPS.

Section: EMD-II (BLR)

JOB Safety Analysis Sheet

Job Step Hazard Control Measures Responsibility

Supply, Electric Shock High  Ensure power supply module Contractor‟s

Dismantling is Off if required

And Fixing the  PPEs must be used as per

work requirement.

different  Use certified calibrated tools &

capacity along tackles for lifting and shifting of

with Chain Pulley Block and

Mono rail at Monorail Trolley.

Unit No.4, (Form No. 10 to be Ensured)

5&6 WTPS. Chain pulley must be in vertical

Inclined load not allowed.

 Ensure over hauling area is

Slips/Trips/Falls

 Job should be done as per

 Due care while Fixing the

Monorail Trolley and Chain

part of body  Skilled men power should be

 Close supervision required.

Exposure to  Use proper PPE during work and in Contractor‟s

noise of running Low high noise areas.

machines Supervisor

NOTE: Required check list should be filled up by contractor at time of work execution.

Prepared by Reviewed by Checked by Approved by

EE(EMD-2) Safety Officer SE(E-I) Factory Manager Chief Engineer(C&O)

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

DECLARATION FORM

ON LETTER HEAD OF SUPPLIER

Subject: Supply and Fixing the Chain Pulley Block with different capacity along with respective Mono

rail at Unit No.4,5.6, WTPS.

Reference No:- WTPS/S/TECH/RFQ- 78420E/EMD-2

1. I/We hereby declare that I/We have carefully & thoroughly studied the entire tender placed on

the website and General terms & conditions, technical specification, PQR and other documents

of the tender mentioned under reference along with the Commercial terms and conditions.

2. I/We hereby confirm and certify that the offer submitted by me/us is strictly in accordance with

the GSECL‟s Tender specifications, Guaranteed Technical Particulars and drawing as

mentioned in the Tender Specifications. There is no commercial or Technical deviation (except

the deviations shown in respective Annexure-12 of Technical Deviations of this tender

document) in the offer from the Board‟s Tender Specification. I undertake to abide by the

GSECL‟s Technical specification / Guaranteed Technical Particulars / Drawing, I undertake to

supply materials strictly as per the GSECL‟s Technical specification / Guaranteed Technical

Particulars / Drawing, even if any technical deviations are mentioned by me. I also undertake

to abide by all commercial conditions of the GSECL, including delivery schedule. I have

submitted all the annexure-1 to 15,form of integrity pact etc along with the technical Bid dully

filled along with all the details”

3. I / We, hereby declare that our Technical Bid is strictly in line with the Tender specifications

(except the deviations shown in Annexure-12 of Technical Deviations of this tender document).

4. I / We also agree that additional conditions / deviations, if any, found in the Commercial terms

& conditions (except the deviations shown in Annexure-12 of Technical Deviations of this

tender document) our offer shall be out rightly rejected without assigning any reason thereof.

5. I/We hereby abide to execute the contract agreement & submitted the same along with the

acceptance of LOI and the same will be acceptable to me/us.

6. I/We hereby accept and confirm that any dispute on this regard shall not be entertained by the

tender inviting authority.

7. The full value of the “Earnest Money Deposit” paid herewith should be absolutely forfeited to

the Corporation, should I/ we do not deposit the specified amount of specified Security Deposit

within 10 Days from receipt of the Letter of Intent.

8. If, I fail to submit all required documents with application or tender copy ( in each tender ) then

my tender will be cancelled, which is binding to me.

authorized signatory of M/s ______________________________________________ here by

proprietor / any partner / any directors of the firm is not stop deal and / or banned for business

dealing and / or black listed by GUVNL and / or their any subsidiary company viz. GSECL /

GETCO / DGVCL / MGVCL / UGVCL / PGVCL as well as Government and / or Semi

Government company / department.

10. We here by confirm that we have not stake in one or more other agencies / bidders who are

participating in same tender and if it is found that the submitted information / declaration are

wrong in the tender / enquiry as stated in tender terms, than we will be disqualified

automatically &it will be accepted to us. EMD / SD will be forfeited. More over if GSECL shall

take stern action including stop dealing with our firms which is also accepted to us

Seal of the Firm Signature of the Tenderer with Designation.

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

[On Company’s Letter Head]

(Require for Price Justification, if Necessary)

(UNDERTAKING IN REGARD TO QUOTED PRICE)

(All Bidders will have to furnish the following undertaking duly filled in, for all the quoted

items/works of the tender along with online Technical Bid)

Ref.: Tender No……………. / Gem Bid. No.

We, the undersigned, hereby declare and undertake that we have not accepted or executed

any Letter of Acceptance (LOA) or Purchase Order (PO) at a unit ex-works price/any work at

rate lower than the rate offered in this tender in any station of GSECL/GUVNL/ & Subsidiaries/

CPSU / SPSU/IPP etc. during the period from six (6) months prior to two (2) months after the

bid submission date of this tender.

We also understand that LOA / Purchase Order placed by any station of GSECL/GUVNL

Subsidiaries/ CPSU/SPSU/IPP etc. on the basis of above undertaking shall not be considered

as „offered‟ price for the tender items in subsequent tender, if it is not within period mentioned

I/We accept above undertaking.

Seal of the Firm Signature of the Tenderer

With Designation

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page

<On the letterhead of the vendor/ payee>

Subject : Declaration for TDS/TCS under the Income Tax Act (IT Act)

Reference : Provisions of S. 206AB/ 206CCA/139AA of the IT Act

This is with reference to the determination of appropriate Tax deduction at source (TDS) or Tax

collected at source (TCS) as per the provisions of the Act i.e. Section 206AB/ 206CCA/139AA of the IT

Act. In relation to the said provision of the Act: I / We, having status of <<mention status i.e.

Individual/Company/ Firm etc.)>>hereby declare and confirm that: -

a) I/We have<<mention PAN>>Permanent Account Number (PAN) under the IT Act.(Copy of

PAN card is enclosed herewith.)

b) I/We have linked / will be linking Aadhar number with PAN as required under section 139AA (2)

read with Rule 114AAA.latest by 30th June

c) I/We have/have not filed income tax returns (ITR) for two previous years immediately prior to

the year in which tax is required to be deducted and for which last date of filing of income tax

return is expired u/s139(1) of the Act.

I/ We am/ are hereby attaching a copy of acknowledgment of ITR filed for any one of previous

two financial years of which due date u/s139(1) is expired, as proof of filing ITR. (Strike out full

sentence if not filed IT returns)

d) The aggregate amount of Tax Deductible at Source (TDS) and Tax Collectible at Source (TCS)

exceed/don‟t exceed Rs. 50,000 or more in each of the two aforesaid previous years in my/our

case (Vendor has to provide the extract of its Form 26AS if copy of ITR is not provided as

e) I/ We shall, indemnify the Company for any consequences arising out of any acts of commission

or omission including incorrect declaration basis which the Company would act upon.

I/We agree that Company shall determine applicability of section 206AB/206CCAof the IT Act

based on the aforesaid declaration/documents filed by me/us and would deduct TDS/TCS

accordingly. The decision of Company shall be final and acceptable to me/us. Strikeout

whichever is not applicable.

Yours faithfully,

< Full Name of Vendor & seal >

BIDDER’S SIGN WITH SEAL

RFQ- 78420E Page