Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing / Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations. and (B) Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous works at GIPCL - SLPP

documents for Technical Bid in Office of Surat Lignite Power Plant (SLPP)

E-Reverse Auction Will be informed by GIPCL to all qualified Bidders

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

1. Amendment / corrigendum of the Tender Document, forms, schedules, etc. may be

done any time by the GIPCL during the period of publication of Tender on the

website. The Bidders are required to visit the website regularly till the last date &

time of Bid submission.

2. GIPCL reserves the right to reject any or all the tenders without assigning any

reason thereof.

3. The Bidders are required to quote the rate strictly as per the terms and conditions

mentioned in the tender document, adhering to technical specifications as well.

4. The Bidders are required to submit their Bids online only through (n)Procure portal

(https://tender.nprocure.com)

5. The EMD, Tender fee & other supporting documents are to be submitted in physical

form only at the following address:-

Gujarat Industries Power Company Limited,

Surat Lignite Power Plant,

At Village: Nani Naroli,

Taluka: Mangrol, Dist.: Surat - 394 112, Gujarat.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

INSTRUCTIONS TO BIDDERS

1. PLANT SYNOPSIS

Gujarat Industries Power Company Limited (GIPCL) (henceforth be named

Company/GIPCL), is a Premier Power Utility in the State of Gujarat with an installed

capacity of 1859.40 MW comprising of various conventional and renewable projects.

GIPCL commissioned its first power project: a 145 MW gas based combined cycle power

plant in 1992 at Vadodara. It expanded its capacity by 165 MW Neptha and Gas based

Combine Cycle Power Plant at Vadodara in

Surat Lignite Power Plant (SLPP) with four units of 125 MW capacities each is located at

Village: Nani Naroli, Taluka: Mangrol, District: Surat in Gujarat. GIPCL has also operating

its own captive Lignite and Lime Stone Mines close to the Power Plant. The Power Plant is

based on Circulating Fluidized Bed Combustion (CFBC) technology for the Boilers, where

Lignite is burnt along with Lime Stone in the Combustor of the Boiler.

It commissioned 5 MW Solar Power Plant on the Vastan Mine dump top adjacent to Surat

Lignite Power Plant in January 2012. Also, GIPCL has commissioned 1MWp Distributed

Solar Power Projects at two locations in Gujarat viz. at Village: Amrol, Dist.: Anand in April,

2016 and at Village Vastan, Taluka Mangrol, and Dist.: 2016. Surat in May 2016. GIPCL

has successfully commissioned a 2 X 40 MW Solar Project in September 2017 as well as

a 75 MW Solar Power Project in June 2019 at Gujarat Solar Park, Village Charanka, Dist.:

Patan. GIPCL has also successfully commissioned 112.4 MW wind farms at different

location of Gujarat. The Company has commissioned the 100 MW Solar Project at the

Raghanesda Solar Park, Banaskantha, Gujarat on August 2021. The Company has also

commissioned 75 MW Solar project at Vastan Lignite Mine, Tal. Mangrol, Dist. Surat,

Gujarat in June 2025. The Company has also developed 2375 MW Renewable Energy

Park at Khavda in the Kutch district of Gujarat in Dec

Surat Lignite Power Plant (SLPP) is accessible by road from Kim and Kosamba, which are

on Mumbai-Ahmadabad highway. From Kosamba, SLPP is around 32 km, out of which

km is part of the National & State Highway and balance 5 km is District Road. From Kim,

SLPP is around 18 km, out of which 13 km is the State Highway and balance 5 km is District

Road. The nearest Broad Gauge Railway Line is at Kim, which is around 21 km from the

SLPP. Surat is approximately 50 km from the SLPP. Location Map for SLPP is as under:

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

The Company intends to award Biennial Rate Contract (BRC) for (A) Disposal of Ash at pre-

designated locations of Mines pit / any other locations and (B) Cleaning of Areas underneath and

surrounding Fly Ash & Bed Ash Silos (Contract Period: 2027-29) at GIPCL-SLPP: 4 x 125 MW

Power Plant and is therefore inviting e-Tenders online on (n)Procure portal

(https://tender.nprocure.com)from experienced & resourceful Contractors.

2. SCOPE OF WORK

2.1 The Scope of Work covers Hiring of Dozer D-80 on Metric Tonne basis for following:

During the monsoon period, festival periods and any other lean periods, Fly Ash / Bed Ash will

be transported to Lignite mines / any other locations for utilization / dumping purpose. As soon

as ash is unloaded at site, it is to be dozed & leveled immediately. The delay in Dozing of

ash will block the approach area for further transportation & unloading at designated

point. So, it is very much essential to keep the dozer in running condition for quick action.

It may be noted that, the Contract will operate as & when required basis which shall mainly

depend upon volume & frequency of rainfall, sale of ash or any other requirement. By any

reason, if Contract is not executed or partly operated, GIPCL shall not be responsible for

any type of idle charges.

2.2 The Scope of Work covers Hiring of Dozer D-80 on Running Hour basis for following:

2.2.1 The compaction of Lignite and Limestone at in-plant, out plant and ELHS stockpile layer

2.2.2 Pushing of Limestone and Lignite at in-plant stockpile, out plant stockpile, ELHS

stockpile and at feeder breaker end.

2.2.3 For lying of conveyor belt and lifting of take up counter weights in Maintenance work

and any other jobs as per the requirement.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

2.3 The Bid submitted by the Bidder not covering the total scope of work and services as

detailed out in the tender document shall be liable for rejection.

2.4 Quantum of job mentioned against all items in the Price bid are indicative only & may vary

as per site requirement & not to be construed as maximum or guaranteed quantity.

The quantities shown in the price bid are approximate quantities for the contract period and

they may vary as per job requirements.

2.5 All the miscellaneous activities pertaining to specific work to be executed for satisfactory

performance is in the scope of Contractor in his quoted rates.

3. GENERAL INSTRUCTIONS

3.1 The Bidders who are interested in participating in the Tender must read and comply with

the instructions and the Terms & Conditions contained in the Tender Document.

3.2 The Bids shall be filled in by the Bidders clearly, neatly and accurately. Any alteration,

erasures or overwriting shall be liable to make the tender invalid unless the same is neatly

carried out and attested over the full signature of Bidder. The decision of the Company

to interpret the information and rates filled in by the Bidder shall be final and binding on

3.3 The Bidders are requested to make themselves fully conversant with the General

Conditions of Contract, Special Conditions of Contract, Technical Specifications, Site

conditions, Safety & Health Aspects and Norms to be observed etc. before submitting

their bids so that no ambiguity arises in these respects subsequent to submission of the

3.4 Before quoting the rates, the Bidder should go through the specifications, scope of work

etc. and get himself fully conversant with them. The Bid should include cost of

mobilization and cost to adhere to all Safety Norms as described in the Tender. No

relaxation or request for revision of quoted / accepted rates shall be entertained

subsequent to the opening of Bid on account of mobilization or Safety costs.

3.5 Splitting of work is not advisable as the purpose of SoR method will not be fulfilled.

3.6 Bidder has to submit all the information as per required Bid document. Failure to furnish

all the information as per required Bid documents or submission of a Bid containing

deviations from the contractual terms and conditions, specifications and requirements,

shall be rejected.

3.7 The Bids shall be submitted within the time frames set out in the Notice Inviting Tender

(‘NIT’) and Bids submitted thereafter shall not be accepted and considered.

3.8 The Tender Document shall not be transferable.

3.9 The Bidders are expected to examine all instructions, forms, terms & specifications in the

Bid documents and to get fully acquainted themselves with all the conditions and matters

which may affect the subject matter of the work/tender or the cost thereof. If any Bidder

finds any discrepancies or omissions in the specifications and documents or any doubt

in true meaning or interpretation of any part, he shall seek necessary clarifications in

writing if required.

3.10 Conditional offers shall not be considered and liable to be rejected.

3.11 The Company reserves the right to extend the deadlines for submission of the Bids by

giving amendments.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

3.12 Bidders may visit site for detailed understanding regarding the “Scope of Work” as per

the Tender document, with due prior intimation in writing pertaining to the said Site visit.

3.13 During evaluation of Bids the Company may, at its discretion ask the Bidder(s) for

clarification of their Bid. The request for clarification and the response shall be in writing

and no change in prices or substance of the Bid shall be sought, offered or permitted.

3.14 The Company reserves the right to amend / modify the Bidding documents at any time

prior to the deadline for submission of Bids, either at its own discretion or in response to

the clarification requested by a prospective Bidder. In such case, the Company may in its

discretion extend the deadline for submission of Bids in order to facilitate the prospective

Bidders for incorporating the effect of the amendment in their Bids.

3.15 The Bidders shall bear all costs and expenses associated with the preparation and

submission of their respective Bids, to attend meetings or conferences, if any, including

any pre award discussion with the successful Bidder, technical and other presentations

etc. and the Company shall not be liable for any expense thereof.

3.16 If the successful Bidder is a joint venture, formed of two or more companies, the Bidder

along with the partners shall accept joint and several responsibilities and liabilities for all

obligations under the Contract.

3.17 Timely and satisfactory completion of the work and strict adherence to the allotted time

frames for jobs shall be the essence of the contract.

3.18 The Company reserves the right to qualify/disqualify any applicant without assigning any

3.19 The Bidder shall be disqualified if any untrue statement or misrepresentation is made in

the Bid forms, attachments and other supporting documents submitted by the Bidder.

It is perquisite and necessary for all interested Bidders to visit the site/plant after downloading

the Tender copy to understand the actual working conditions, compliance related to labour, safety

etc. before submitting their offer. Failing which, any consequential liabilities arising will be to

Bidder’s account. The Bidders shall examine the site of works and its surroundings at his own

responsibility. The Bidders shall collect information that may be necessary for preparing the Bid

and entering into a Contract. All costs and liabilities arising out of the site visit shall be at Bidder’s

The Bidder is deemed to have examined and understood the Tender document, obtained his

own information in all matters whatsoever that might affect the carrying out the works expressly

mentioned or works which may have to be carried out to fulfill his contractual obligations within

the scheduled rates and to have satisfied himself to the sufficiency for his offer.

The submission of Tender by a Contractor implies that he has read these instructions, conditions

of the contract etc. and has himself aware of the Scope, nature of works & specifications of the

works to be done. GIPCL will not, therefore after acceptance of Contractor’s rate, pay any extra

charges for any other reason in case the Contractor is found later on to have misjudged the site

Any error in description or quantity or omission in the contract document shall not vitiate the

contract or release the Contractor from executing the work comprised in the contract according

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

to scope of works, magnitude of the works, requirement of materials, equipment, tools & tackles,

labour, etc. Contractor has to complete the work in accordance with the contract documents

irrespective of any defects, omissions or errors that may be found in the contract documents.

BIDDER shall inspect the site, examine and obtain all information required and satisfy himself

regarding matters such as access to site, communication, transport, working condition including

constraint of work place, confined area, quantum of dusting, running equipment, importance of

work, round the clock working conditions, safety requirements, right of way, high flood level in

River, flow of water during monsoon/dry season in the River/Nullah, the type and number of

equipment and facilities required for the satisfactory completion of work, the quantity of various

items of the work, the availability of local labour, availability and rates of material, local working

conditions, uncertainties of weather, obstructions and hindrances that may arise, etc which may

affect the work or cost thereof, before submission of his Bid. Ignorance of site conditions shall

not be accepted by the GIPCL as basis for any claim for compensation. The submission of a Bid

by the BIDDER will be construed as evidence that such an examination was made. Any later

claims / disputes in regard to rates quoted shall not be entertained or considered by the GIPCL.

The rates quoted by BIDDER shall be based on his own knowledge and judgment of the

conditions and hazards/risk involved and shall not be based on any representations of the

5. ELIGIBILITY CRITERIA

The following criteria shall be adopted for qualifying the Bidders for further proceeding:

5.1 Bidder should possess minimum Three years of experience out of last five years ending

last day of the month previous to the one in which tender is invited in similar nature of

mechanized jobs involving the equipment / machinery such as Dozer of Model: D-80 or

equivalent dozing capacity, and/ or other similar types of HMVs / HCVs and Earth mover

equipments. Bidder shall enclose the proof of the same. Bidder shall submit necessary

evidence for the same like attested copies of work orders along with work completion

certificates from clients. The work completion certificate shall comprise of Order value &

Executed value. Bidders should have executed the work directly. The work executed as

a sub-contractor or subletting agency shall not be taken in to consideration.

Note: For evaluation of the bid, the executed value mentioned in the work completion certificate

will be considered.

5.2 Bidder must Own / Possess minimum One (1) No. Dozer of Model: D - 80 or equivalent

dozing capacity. The relevant copies showing the Ownership / Possession of the said

Dozer shall be submitted along with the Bid.

5.3 Bidder should produce evidence of having experience of successfully completed

similar works as defined hereunder during last five years ending last day of the

month previous to the one in which tender is invited, satisfactory progress of ongoing

works etc. secured from clients along with certified copies of documentary evidence

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

preferably photo copies of work experience. The experience should be either of the

a. One similar completed work each costing not less than the amount equal to

Rs. 16.75 Lac with GST.

b. Two similar completed works each costing not less than the amount equal to

Rs. 11.17 Lac with GST.

c. Three similar completed works each costing not less than the amount equal

to Rs. 8.38 Lac with GST.

Bidder should specifically mention fulfilling of above criteria in his offer along with details of work

orders & work completion certificates issued by clients.

5.4 Tender Fee: The Tender Fee shall be accompanied in form of Demand Draft / RTGS

5.5 EMD: The EMD shall be accompanied in the form of DD/RTGS or Bank Guarantee given

by Bank as described in detail in Clause No. 7 of this Section of Tender Document.

5.6 Bidder should have separate Employees Provident Fund code number towards

registration of firm with RPF commissioner.

5.7 Attested copies of relevant documents duly signed & sealed on each & every page shall

be submitted. The above documents will be analyzed and if found satisfactory, the Price

Bid will be open. GIPCL may verify the documents, experience certificates issued by

concerned authority. After opening of Technical Bid, if any required attested documents

found missing in the Technical Bid submitted by the Bidder, the tender inviting authority

may inform to that Bidder only once by e-mail to submit the missing required documents

within stipulated time limit. If Bidder/Bidders fail to submit within stipulated time, their Bid

will be declared technically disqualified and no further correspondence will be

5.8 Bidder should have average annual turnover of Rs. 8.38 lac with GST during last

three financial years i.e. FY: 2023-24, FY: 2024-25 and FY: 2025-26. Bidder shall

furnish annual audited financial statement duly certified by Chartered Accountant for the

aforesaid three financial years to demonstrate the financial healthiness of the company.

The Balance sheet must be in the name of the company. Any type of MOU for this

purpose will not be entertained.

Note: In case, the annual turnover is less than the statutory guidelines which does not require

audit, the Bidder shall submit the turnover certificate from Chartered Accountant.

5.9 The Bidder has to submit Income Tax Permanent Account Number (PAN) & GST

registration number. Copy of the same shall be submitted.

5.10 The Net worth at the end of the financial year 2025-26 should be positive (+) as per

audited accounts audited by a qualified Chartered Accountant, being a member of the

Institute of Chartered Accountants of India.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

5.11 In case Bidder is a Consortium / joint deed of undertaking of company, the above

requirements/credential of consortium leader / bidder shall be considered unless

otherwise specifically mentioned in the tender.

5.12 If Bidder or its Partner(s) or Director(s) is /are/was in any Litigation(s), Court Case(s) or

Arbitration(s), either completed or under progress during last five (5) years or Black Listed

/ Deregistered / Stopped or banned from dealing in the past by any Govt. of Gujarat

Undertakings / Depts. / Authorities and Govt. of Gujarat supported companies /

undertakings / organizations, Bid of that party will be liable to be rejected. Bidder agrees

and undertakes to accept decision of GIPCL in this regards as final and binding on the

Bidder without any demur and that no further correspondence shall be done in this regard

at any stage. Bidder shall have to submit the “Declaration for Contractual Disputes/

Litigations” as appended in Annexure – G (SECTION – F)

5.13 Bidder shall have to submit the “Declaration-cum-Undertaking for Compliance of Safety

Laws and Regulations” on his company letter head as amended in Annexure-F in Section-

F / Form attached.

• If any Major Violation of any safety law(s) / Rule(s) is / are found during the preceding

Three (3) years, Bid of that party will be liable to be rejected. Bidder agrees and

undertakes to accept decision of GIPCL in this regards as final and binding on the Bidder

without any demur and that no further correspondence shall be done in this regard at any

• If any of the details submitted in the prescribed Annexure / Form to the Bid is/are found

to be false, incorrect at any time in future, then the Contract awarded to that Bidder /

Contractor shall be liable to be terminated forthwith without any notice / correspondence

and Bidder agrees and undertakes to accept decision of GIPCL in this regards as final

and binding on the Bidder without any demur and that no further correspondence shall

be done in this regard at any stage. Further, Performance / Security Deposit will also be

liable to be forfeited. Any dues to GIPCL from the Bidder / Contractor shall be recovered

from the pending bills or any other dues payable to the Bidder / Contractor, if any or

otherwise through any other recourse available under the Laws.

The Bidder shall submit all the evidences, documents, attested copies of Work Orders &

Work completion certificates etc. as a proof with EMD & Tender Fee and also provide the

requisite details ‘Online’ for meeting the pre-qualification requirements. GIPCL will verify

the experience, performance, capability & strength of Bidders, independently for

executing the job. GIPCL may visit the site & consult the owner of the industry/property

where similar job is executed by the Bidder. GIPCL reserves the right to accept / cancel

/ reject any / all Bids without assigning any reason thereof. The Tenders of qualified

Bidder/Bidders shall only be considered for further evaluation.

5.14 Site Visit is mandatory prior to submission of bid to understand the scope of work,

working conditions, site conditions, equipments, tools & tackles, labor deployment,

associated risk, surrounding etc.

6. LANGUAGE OF BID

The Bid prepared by the Bidder, and all correspondence and documents relating to the Bid

exchanged by the Bidder and the Company, shall be written in the English language. Any printed

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

literature furnished by the Bidder, written in another language shall be accompanied by an

English translation for the purpose of interpretation of the Bid.

7. EARNEST MONEY DEPOSIT (EMD) and TENDER FEE

7.1 An EMD of Rs. 48,000/- and Non-refundable Tender fee Rs. 2,950/- inclusive of

applicable GST shall accompany with Bid. Tender fee shall be submitted through

RTGS / online mode of payment only.

7.2 The EMD shall be submitted in the form of DD/irrevocable Bank Guarantee in favor of

“Gujarat Industries Power Company Limited” from all Nationalized Banks or Axis Bank,

ICICI Bank, HDFC Bank, Kotak Mahindra Bank, IndusInd Bank, Federal Bank, Bandhan

Bank, IDBI Bank and Karur Vysya Bank as per Performa of BG enclosed with this tender

document under Section-F (Annexure-C).

Bank for EMD DD Payable at :

1. Bank of Baroda Mosali, Dist: Surat

2. State Bank of India Nani Naroli, Branch Code:

3. Any Nationalized banks Surat

Alternatively, EMD & Tender Fee may also be submitted through RTGS mode of

payment by the bidders as per the details given below:-

1. BANK NAME:- State Bank of India

2. BRANCH:- Nani Naroli

3. IFSC CODE:- SBIN0013423

4. BENEFICIARY NAME: Gujarat Industries Power Company Limited

Also, EMD & Tender fee may be submitted through online payment gateway of company’s

website: www.gipcl.com (online Payment Form) as per detail provided in Section-F

(Annexure-I) herein under.

7.3 In case EMD is paid in the form of BG, the same shall be valid for a period of 180 days

after the due date for submission of the Bid.

7.4 The EMD of the successful Bidder will be returned after payment of Security Deposit

within 21 days from the date of award of contract by successful Bidder.

7.5 The Earnest Money Deposit will be refunded to the unsuccessful BIDDER as soon as the

Tender is finalized and after award of LOI/WO.

7.6 Any bid not accompanied with EMD and Tender fee will be rejected. Tender Fees and

EMD should be submitted in physical form directly to GIPCL as per Clause 7.9.

7.7 No interest shall be payable on EMD.

7.8 The EMD will be forfeited if the BIDDER (i) withdraws his Tender after acceptance or (ii)

withdraws his Tender before the validity date of the tender.

7.9 SCHEDULE OF EMD & TENDER FEES:

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Details/receipts of EMD & Tender fee Address for Submission:

paid by RTGS/online or EMD in

physical form by way of DD/BG (as CGM (THERMAL),

GUJARAT INDUSTRIES POWER CO. LTD.,

applicable) with other documents duly (Surat Lignite Power Plant)

self-attested are to be submitted in Village – Nani Naroli, Taluka – Mangrol

physical form in sealed cover as per District – Surat 394 112, Gujarat

details mentioned in NIT. Bid No. Phone : 02629-261063

shall be mentioned at the top of Fax : (02629) 261073 /

cover/envelope.

8. SUBMISSION OF BIDS

A: MODE OF SUBMISSION

The Bids shall be submitted online on (n)Procure portal (https://tender.nprocure.com) within

the dates specified in the NIT along with the details of Tender Fees, EMD in two parts as under:

(a) Pre-qualification and Techno-commercial Bid without price.

(a) Pre qualification and Techno-commercial Bid without price:

The Tender document duly signed in all pages without price bid along with techno-commercial

deviations, if any, shall accompany the Bid. The following Information shall be provided in the

techno commercial bid:

1. Schedule of deviation (SECTION – F: Annexure E) Technical as well as commercial, if

The following supporting documents shall also be submitted along with EMD & Tender Fee in

1. The Tender Document duly signed in all pages without price bid along with Techno-

commercial deviations, if any.

2. Proof of experience meeting the minimum ‘Eligibility Criteria’ (Clause No. 5 above).

3. Performance certificate issued by clients.

4. Previous Work Order copies.

5. Details of present Work Order (if any).

6. Average Annual Turnover for the last three financial years i.e. FY: 2023-24, FY: 2024-25

and FY: 2025-26, audited annual accounts / financial statements i.e. Profit and Loss

account and Balance Sheet duly certified by a practicing CA will be required.

7. P.F Number and Allotment Letter.

9. GST registration number/certificate copy.

10. Copies of RC Books / Certificate showing Ownership Dozer Model D – 80 or equivalent

as mentioned in ‘Eligibility Criteria’ (Clause No. 5 above).

• To participate in e-Reverse Auction, Bidders have to create e-Auction user Id on https://e-

auction.nprocure.com and it is mandatory to submit the same along with physical

Techno-commercial Bid; so that the Bidder shall be allowed to participate in the e-

Reverse Auction.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

1. Price Bid shall be

submitted online only through (n)Procure portal

(https://tender.nprocure.com) .

Note: Estimate includes cost of all equipment / machinery, manpower, vehicles,

consumables, fuel, tools & tackles, transportation, Safety statutory compliance,

mobilization etc.

2. GST shall be paid extra at actual as per prevailing rates as declared by Central

Government on submission of documentary evidence.

3. Bidder shall have to fill the respective item rate excluding GST.

4. The quantities shown in the Section – E: Schedule of Quantities and Price are

approximate for the Contract Period and may vary as per job requirement.

5. The Bidder shall fill the Bid documents with utmost care in consonance with the

instructions contained in the Bid documents.

B: METHOD OF TENDERING / SIGNATURE ON BIDS

(i) The Bid must contain the postal address like name, residence and place of business of

the person or persons submitting the Bid and must be signed and sealed by the Bidder

with his usual signature. The name of all persons signing the documents shall also be

typed or printed below the signature on each page.

(ii) Bid by a joint venture/partnership firm must be furnished with full names of all partners

and be signed with the partnership name, followed by the signature and designation of

one of the authorized partners or other authorized representative(s). A certified copy of

the power of attorney authorizing such partner or representative shall also be submitted.

(iii) Bids by a Corporation/Company must be signed with the legal name of the

Corporation/Company i.e. by the President/Managing Director/Secretary or other

person or persons authorized to Bid on behalf of such Corporation/Company. A certified

copy of the board resolution/power of attorney authorizing such partner or

representative shall also be submitted.

(iv) The Bidder's name stated on the proposal shall be the exact legal name of the firm.

(v) Erasures or other changes in the Bid Documents shall be initialed by the person signing

(vi) Bids not conforming to the above requirements of signing shall be disqualified.

9. MODIFICATION AND WITHDRAWAL OF BIDS

a. The Bidder may modify or withdraw the bid prior to the deadline prescribed for submission

b. No Bid shall be modified subsequent to the deadline for submission of Bids.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

c. No Bid shall be withdrawn in the interval between the deadline for submission of Bids and

the expiration of the period of bid validity.

10. POLICY FOR BIDS UNDER CONSIDERATION

a. Bid shall be deemed to be under consideration immediately after opening of the Bid and till

official intimation of award / rejection made by the Company to the Bidders.

b. While the Bids are under consideration, Bidders and / or their representative or other

interested parties are advised to refrain from contacting by any means, the Company. The

Engineer, if necessary, will obtain clarifications on the Bids by requesting for such

information from any or all the Bidders, in writing as may be necessary. The Bidder will not

be permitted to change the price or substance of the Bid after the Bid has been opened.

11. EFFECT AND VALIDITY OF THE BID

a. The Bid should be kept valid for acceptance for a period of one hundred and eighty (180)

calendar days from the last date of submission of Bids.

b. The submission of any Bid along with the required documents and specifications shall

constitute an agreement that the Bidder shall have no cause of action or claim, against the

Company for rejection of his Bid. The Company shall always be at liberty to reject or accept

any Bid or Bids at his sole discretion and any action will not be called into question and the

Bidder shall have no claim in that regard against the GIPCL.

12. OPENING OF BIDS

12.1 GIPCL will open the Pre-qualification / Technical Bid / Price Bid, as the case may be,

in presence of Bidder's representatives whenever such a procedure has been specified.

Otherwise the tender will be opened by the authorized officers of GIPCL.

12.2 Preliminary Examination:

12.2.1 The Company will examine the Bids for any computational errors, for sureties

furnished by Bidder, for authentication of documents submitted and completeness of

12.2.2 Arithmetical errors will be rectified on the following basis:

(a) If there is a discrepancy between the unit price and the total price that is obtained by

multiplying the unit price and quantity, the unit price shall prevail and the total price will

be corrected & will be binding to the Bidders.

(b) If there is a discrepancy between the Total Bid Amount and the sum of total prices, the

sum of total prices shall prevail and the Total Bid Amount will be corrected & will be

binding to the Bidders.

13. EVALUATION & COMPARISON OF BIDS

13.1 GIPCL shall evaluate the Bids received and accepted by it to ascertain the lowest

evaluated Bid in conformity with the specifications of the Tender Document.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

13.2 The Technical Bids will be examined for minor matters regarding qualification of bids.

Subsequent to correspondence with the respective bidders, the decision of Tender

Committee will be final.

13.3 All responses to requests for clarifications shall be in writing and shall be presented to

the Company through e-mail or in a sealed envelope on or before the given date

requested by the Company. If the Technical clarifications sought by the Company do not

reach the Company on or before due date, the Bid will be rejected.

13.4 The comparison of all the Bids shall be carried out with reference to the scope of work as

per the technical specification. Any deviation / omission shall be evaluated at highest

quoted price of the deviation / omission quoted by any of the Bidder. In case a separate

price (for omission) is not given by any other Bidder, a reasonable price of the same shall

be taken & the same shall be binding to the Bidders.

13.5 The commercial deviation, if any, shall be loaded to bring all the Bids at par. The loading

shall be carried out at an interest rate of 2% above PLR of SBI.

13.6 A Bid to be substantially responsive shall be one which on evaluation confirms to all the

terms, conditions and specifications of the Bid documents without any material deviation

or reservation.

13.7 For the above referred purpose, a ‘material deviation’ shall be one which:

(a) Affects in any substantial way the Scope, Quality or performance of the

(b) Limits in any substantial way and in a manner inconsistent with the Bid documents,

GIPCL’s right or the Bidder’s obligations, under the contract, or

(c) Rectification of it would affect unfairly the competitive position of other Bidders presenting

substantially responsive Bids.

14. RIGHT OF REJECTION OF TENDERS

14.1 GIPCL reserves the right to accept or reject any Bid or to cancel the Bidding process and

reject all Bids at any time prior to award of Contract, without thereby incurring any liability

to the affected Bidder or Bidders or any obligation to inform the affected Bidder or Bidders

regarding the same.

14.2 Any Tender without EMD and Tender Fee will be treated as non responsive and shall be

rejected at the outset & no further correspondence shall be entertained regarding this.

14.3 GIPCL reserves the right to debar any Bidder from participation in future Bids if such

Bidder has quoted an abnormally low rate in the Bid document/price Bid.

15. AWARD OF CONTRACT

15.1 GIPCL will award the Contract to that Bidder whose quotation has been determined to be

substantially responsive and evaluated as the lowest quotation in conformity with the

requirements of the specifications and documents contained herein, provided further that

the bidder is determined and evaluated to be qualified to perform the contract

satisfactorily.

15.2 The successful bidder shall be intimated of his selection through the Letter of Intent or

Letter of Award/ Work Order which shall be sent to him through e-mail, courier, fax or

registered mail.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

15.3 GIPCL reserves the right to cancel/short close the contract during the contract period by

giving prior notice of one month without assigning any reason.

15.4 GIPCL reserves the right to split the contract quantity between vendors.

16. CONTRACT PERIOD

16.1 The Contract will be for a period of two (2) years and shall commence from the date as

mentioned in the Letter of Intent (LoI) / Work Order which shall be awarded to the

successful Bidder.

16.2 GIPCL reserves the right to extend the Contract Period up to 3 months on the same rates

and terms and conditions without any price escalation and entering into any new contract.

16.3 The said Contract Period can be extended if mutually agreed upon by both the parties up

to one year and in such a case a revised Work Order shall be issued at the same rates

and terms & condition or at negotiated rates acceptable by both parties i.e. the Company

& the Contractor.

17. ASSIGNMENT AND SUB-LETTING:

The contractor shall not directly or indirectly assign or sub-let total / any part of contract to

any other party or agency.

18. CONTRACTOR’S OBLIGATIONS

• DEPLOYMENT OF EQUIPMENT / MACHINERY

(i) The Contractor shall Own / Possess the following Equipments / Machinery for deployment

at site for timely & satisfactorily execution of the works under the Contract:

• Minimum 1 No. Dozer D-80 (Model: D-80 or equivalent)

(ii) The Contractor shall deploy sufficiently skilled Dozer Operators having a valid Driving

License of respective Earth Mover category and HMV / HCV category and along with mobile

(iii) At the time of deploying manpower, the Contractor shall strictly comply all the applicable

labor laws/Acts norms including but not restricted to the age of the workers, women workers

and shall also ensure that a police verification and security check for all the workmen /

labour engaged at the GIPCL site is done and necessary documents regarding the same

shall be submitted to the GIPCL’s authorized representative/officer-in-charge. Any default

in complying with the same or any misrepresentation regarding compliance of the same

shall compel GIPCL to initiate appropriate civil or criminal proceedings regarding the same.

(iv) The Contractor shall also comply with the safety requirements and provide his

workmen/labour with safety equipment like safety shoes, safety helmets, safety shoes

masks, gum boots, a uniform and other necessary PPEs for properly undertaking the

operations involved under this contract. Following are also to be issued:

(v) Contractor shall nominate / authorize person in writing to co-ordinate with GIPCL’s

Engineer and who shall bear overall responsibility for performance of the Contract. Such

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

person shall remain always available at SLPP site. Contractor has to submit the authority

letter and documentary proof for the same.

(vi) The Contractor shall appoint a person who shall co-ordinate with GIPCL’s Engineer In-

charge for daily entrusted job. They have to maintain daily records duly signed for the works

carried out and duly certified by Engineer-In-Charge. The Contractor in co-ordination with

the Engineer-In-Charge shall ensure the availability of adequate manpower / machinery /

equipment to carry out the job satisfactorily on a daily basis. As per the instruction of

Engineer In-Charge they have to allot the work and execute the same in specified time limit.

(vii) During execution of the works, one or more jobs may be required to be done simultaneously

and the Contractor shall mobilize additional resources accordingly.

(viii) During emergency or similar situations the Contractor shall be required to mobilize

resources as per need within the period of four (4) hours as directed by GIPCL. If the

Contractor fails to mobilize sufficient resources to complete the job in time, GIPCL will

execute the job through other agency at the risk and cost of the Contractor with 10%

supervision charges plus applicable GST as per extant GST Laws & the same will be

recovered from the Contractor’s bill.

19. CLARIFICATION OF BIDDING DOCUMENTS

If any Bidder requires any further information or clarification in the Bidding Documents, may

notify the Company before one week of last date of submission of online Bid, in writing or by E-

mail at the GIPCL's mailing address [email protected] as indicated in the 'Invitation to Bids'.

The GIPCL's response (including an explanation of the query) will be sent in writing or by E-mail

to all prospective Bidders who have received the Bidding Documents.

20. TIME SCHEDULE

The basic considerations and the essence of the 'Contract' shall be the strict adherence to the

time schedule for performing the specified 'Works'.

21. UNDERSTANDING AND CLARIFICATION ON DOCUMENTS AND

The Bidder is required to carefully examine the specifications and documents, all the conditions

and matters work wise & cost wise. If any Bidder finds any discrepancies or omissions in the

specifications and documents or is in doubt for any meaning of any part, he shall request in

writing for an interpretation/ clarification to the GIPCL or during Pre-Bid meeting.

All such interpretations and clarifications shall form a part of the Bid documents.

All the payments against the Work Order shall be in Indian currency and payable through cheque

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

23. POINTS TO BE CONSIDERED DURING QUOTING ONLINE PRICE BID

a. The Schedule of Rates (SoR) shall be read in conjunction with Instructions to Bidders,

General Conditions of Contract, Special Conditions of Contract and Technical

specifications.

b. The quantities given in the Schedule of Rates (SoR) are estimated and will be made as per

actual work carried out as per the rates of Work Order.

c. The method of measurement of completed work for payment shall be in accordance with

the method of measurement specified in the Tender document.

d. No separate amount shall be payable for use of auxiliary equipment incidental to or in day

to day operation in the course of fulfillment of contractual obligation of the supplier.

Note: Interested Bidders are requested to submit the online tender at least two days in

advance from the due date set for Online submission of Bid in order to avoid non-

participation in e-Tender due to probable technical problem in (n)Procure portal.

The quantities specified are estimated and for tendering purpose only. Payment will be

made, based on actual work done as certified by Engineer In-charge of GIPCL.

Quantities of individual items may be revised during the course of Contract period based on site

requirement. Contractor shall not be entitled for any compensation on ground of such alteration

in scope of work. GIPCL reserves the right to operate or increase / decrease quantities in each

item or omit any item included in Schedule of Quantity at his discretion. Contractor shall have no

claim, whatsoever, on grounds of loss of anticipated profit etc. on account of the same.

After commencement of the work, GIPCL, for any reason may not require to be carried out the

whole/part of the work as specified in the tender, the Engineer In-charge shall inform the fact for

thereof to the Contractor and the Contractor shall have no claim for any payment or

compensation whatsoever on account of any profit or advantage which he might have derived

from the execution of the work in full but which he did not derive in consequence of the full amount

of the work not having been carried out nor shall he have any claim for compensation by reason

of any change having been made in the original specifications and instructions which shall involve

any curtailment of the work as originally contemplated.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

INSTRUCTIONS TO BIDDERS FOR ONLINE TENDERING &

E-REVERSE AUCTION

SR. DESCRIPTION

Tender documents are available only in electronic format and same can be

01. downloaded from the website https://tender.nprocure.com and It can also be

viewed from Company’s website www.gipcl.com

Price bid should be submitted online through the website

02. https://tender.nprocure.com only. No physical submission of price bid will be

entertained as it should be furnished on-line only

Bidders who wish to participate in online tenders will have to procure / should

have legally valid Digital Certificate (Class III) as per Information Technology

Act-2000, using which they can sign their electronic bids. Bidders can procure

the same from any of the license certifying Authority of India or can contact

(n)code solutions- a division of GNFC Limited, who are licensed Certifying

Authority by Government of India

All bids should be digitally signed. The bidders are required to contact at the

below mentioned address for detailed training on on-line tendering and also for

(n) Code Solutions - A division of GNFC Ltd.

04. 403, GNFC Infotower, S.G Road,

Bodakdev, Ahmedabad – 380054 (Gujarat, India).

E-mail: [email protected], website: https://tender.nprocure.com

Interested bidders are requested to submit the online tender at least two days in advance

from the due date set for on line submission of bid in order to avoid non participation.

E-REVERSE AUCTION:

1 GIPCL reserves the right to conduct E-Reverse auction through (n) Procure platform.

2 E-Reverse auction shall be conducted amongst (a) the lowest 50% eligible bidders

(rounded to the next higher whole number) from the total bids received OR (b) Minimum

three (03) lowest bidders, whichever is higher, shall be invited for participation in e-Reverse

Auction through n-procure platform.

3 Opening Price, Detrimental value and duration for the e-Reverse Auction shall be informed

to the qualified bidders before start of e-Reverse Auction.

4 After e-Reverse Auction process, L1 bidder shall be decided on Lowest Total Contract

Price. i.e. gross total quoted amount with GST.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

5 After e-Reverse Auction process, the original % rate quoted by the final L1 bidder shall be

reduced proportionately on SoR of individual items/packages by total % reduction after e-

reverse auction, keeping GST % rate same as originally quoted by final L1 bidder.

6 To participate in e-Reverse Auction, Bidders have to create e-Auction USER ID on

https://e-auction.nprocure.com and it is mandatory to submit the same along with

physical Techno-commercial Bid; so that the Bidder shall be allowed to participate

in the e-Reverse Auction.

7 In case of any further information regarding online bidding or if a Bidder needs any

assistance in accessing/ submission of online bid/ clarification or if training is required for

participating in online e-reverse bidding, then the Bidder can contact the following office for

assistance or training:

(n) Procure Cell, (n) code solutions-A division of GNFC Ltd.,

403, GNFC Info tower, S.G. Road,

Bodakdev Ahmedabad – 380054 (Gujarat)

Fax: 079-26857321 / 40007533, Email: [email protected]

Bidder may visit https://tender.nprocure.com for information regarding e-tendering

registration process.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

GENERAL CONDITIONS OF CONTRACT

1. CONTRACT SECURITY DEPOSIT/ PERFORMANCE BANK GUARANTEE

As a Contract Security, the successful Bidder, to whom the work is awarded, shall be required to

furnish a Performance Bank Guarantee (PBG) / Contract Security Deposit in favour of Gujarat

Industries Power Company Limited for guarantee amount at Ten percent (10%) of the “Annual

Contract Price excluding GST” from any Nationalized Bank, Axis Bank, ICICI Bank, HDFC

Bank, Kotak Mahindra Bank, IndusInd Bank, RBL Bank, DCB Bank, Federal Bank, Bandhan

Bank, Standard Chartered Bank in the format attached in SECTION-F, and it shall guarantee the

faithful performance of the 'Contract' in accordance with the terms and conditions specified in these

documents and specifications. Contract security deposit shall be submitted strictly within twenty

one days from the date of LoI or work order, whichever is earlier. The guarantee shall be valid up

to retention period of four months from the contract completion date. The Guarantee amount

shall be payable to the Company in Bidder's home currency without any condition whatsoever.

The Performance Bank Guarantee (Security deposit) shall be returned to the Vendor / Contractor

without any interest at the end of the Retention Period after the completion of Contract and on

fulfilling contractual obligations throughout the retention period. However, any delay in

submission of initial SD will result in equivalent late release of entire SD after guarantee period.

2. PENALTY AND RECOVERY:

(i) In case of any damage of equipment/machinery due to negligence of Contractor or any

other reasons attributed to Contractor the decision of Engineer In-charge regarding the

amount of recovery shall be final and binding subject to a maximum of 10% of Contract

value. Recovery will be affected from the monthly bills and security deposit.

(ii) If the Contractor fails to execute the work as per directions of Engineer In-charge within the

time frame given in work order and / or day to day instructions given by Engineer In-charge,

GIPCL shall get the work done by third party at the risk & cost of the Contractor with 10%

additional overhead charges plus applicable GST as per extant GST Laws.

(iii) The ascertainment of the cause of the damage shall be done by Plant head - SLPP and his

decision in this regard shall be final.

(iv) The aforesaid amounts of Penalty and Damages shall be recoverable from the monthly

invoices of the Contractor or the Security deposit. If the amount of damages recoverable

from the Contractor exceeds the total of invoices and/or Security deposit amount, then the

Contractor shall become liable to pay the same to GIPCL and GIPCL shall be entitled to

initiate appropriate proceedings against the Contractor for the same.

(v) Tentative Penalty shall be imposed to Contractor for various instances as follows:

• Non availability of the following equipments / machinery although due intimation in

▪ Dozer D-80 / Un-Satisfactory work: Rs. 5,000 per Day in case of non-availability

• Absence of Dozer operator without approval from Engineer In-charge: Rs. 1000 / day

• Un-safe work execution: Rs. 750 per day per Instance

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

• In-spite of repeated instruction, if found without safety appliances like Safety shoe, Safety

helmet or any other Safety gear which he has to wear considering his job location,

Necessary action shall be taken against that particular workmen like not allowing him in to

plant premises etc. Also, a token amount of Rs. 100/- per day would be deducted as per

the discretion of Engineer In-charge / Safety Officer.

(vi) The maximum total Penalty which shall be deductible considering all above instances shall

be limited to 10% of the Total Contract Value.

3. DEDUCTIONS FROM CONTRACT PRICE

All costs, charges or expenses that GIPCL may have paid, for which, under the Contract the

Contractor is liable, shall be recovered by the GIPCL. The Contractor shall pay all such claims

within 15 days of claim failing which the same shall be deducted from the bills of Contractor.

4. TERMINATION OF CONTRACT BY GIPCL

Contractor shall be responsible to complete the jobs within agreed time schedule and in case

Contractor fail to complete the job, GIPCL shall recover from his bill, Security Deposit and / or

whatsoever for expenses incurred to complete the job with additional 10% overhead charges

plus applicable GST as per extant GST Laws.

In case if contractor’s services are not found satisfactory with respect to mobilization, time bound

completion of work, workmanship & safety (OHSAS policy of GIPCL) then GIPCL has right to

terminate the contract at any time by giving him 15 days advance notice without assigning any

reason and will make the alternate arrangement at the risk & cost of contractor.

GIPCL may terminate the contract after due recoveries of pending jobs / damages after giving

15 days advance notice to the Contractor if any of the following events occur:

i. Contractor is adjudged as insolvent.

ii. Contractor has abandoned the contract.

iii. Contractor fails to proceed with the work with due diligence as per requirements of the

iv. Contractor has neglected or failed persistently to observe or perform any of the acts,

matters or things, which as per the contract are to be observed and performed by the

v. Contractor repetitively violating the safety norms for more than three incidents.

vi. Any major contradiction of applicable labour laws.

vii. Any major deviations from contractual terms and conditions including quality of job.

viii. GIPCL reserves the right to terminate the contract without giving any reason

whatsoever and forfeit the PBG.

5. FAILURE & TERMINATION

If the Contractor after receipt of written notice from the GIPCL / Engineer In-charge requiring

compliance, with such further drawings and/or the GIPCL / Engineer In-charge’s instructions fails

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

within seven days to comply with the same, the GIPCL / Engineer In-charge may employ and

pay other agencies to execute any such work whatsoever as may be necessary to give effect

thereto and all costs incurred in connection therewith shall be recoverable from the Contractor

by the GIPCL on a certificate by the GIPCL / Engineer In-charge as a debt or may be deducted

by him from any money due or to become due to the Contractor.

If the Contractor fails to execute the work or fails to mobilize the resources and equipments as

per directions of GIPCL / Engineer In-charge within the time frame given and/or violating the

GIPCL’s safety rules & regulations, GIPCL / Engineer In-charge shall get the work done by third

party at the risk & cost of the Contractor with additional 10% overhead charges plus applicable

GST as per extant GST Laws and all costs incurred in connection therewith shall be recoverable

from the Contractor by the GIPCL / Engineer In-charge as a debt or may be deducted by him

from any money due or to become due to the CONTRACTOR.

6. SETTLEMENT OF DISPUTES

a. Any disputes or difference of opinion between parties arising out of the contract to the extent

possible shall be settled amicably between the parties. If amicable settlement cannot be

reached all the disputed issues shall be resolved through arbitration before a Sole Arbitrator

appointed by Managing Director, GIPCL according to the provisions of The Arbitration &

Conciliation (Amendment) Act, 2019, as amended from time to time. The place of arbitration

shall be at Vadodara/ Surat or any other place within state of Gujarat.

b. Work under the contract shall be continued by the contractor during arbitration proceedings

unless GIPCL shall order suspension thereof or any part thereof in writing or unless the

matter in such work cannot possibly be continued unless the decision of the Arbitration

proceedings is obtained.

7. INTERPRETATION OF CLAUSE

In case of disputes as regards interpretation of any of the clauses or specification, the decision

of CGM (THERMAL) - GIPCL will be final and binding on the Contractor.

8. EMPLOYEE’S COMPENSATION INSURANCE

Contractor shall take all risk Insurance Policy to cover all his workmen/employees, staff

applicable under the Employee Compensation Act 1923 or any amendment thereof as also

insurance cover for third party liability. The Contractor shall keep the GIPCL indemnified from all

liabilities arising out of his action in pursuance of this contract. The E.C. Policy should be obtained

from Surat Jurisdiction and shall be assigned to GIPCL. E.C. Policy should cover the specified

contract period.

Contractor shall also obtain additional Off-duty coverage insurance policy for all his workers.

9. STATUTORY REQUIREMENTS

A. COMPLIANCE OF LABOUR LAWS

The Contractor shall at his own cost comply with the provision of labour laws, rules, orders and

notifications whether central or state or local as applicable to him or to this contract from time to

time. These Acts/Rules include without limitation of the followings.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

1. Contractor shall be solely responsible and shall fully comply with all the provisions of

all the labor laws applicable such as the Minimum Wages Act, 1948, Contract Labor

(Regulation & Abolition) Act 1970, Factories Act, 1948, Payment of Bonus Act

Employees Provident Fund and Miscellaneous Provision Act 1952, Industrial Dispute

Act 1947, Workmen Compensation Act 1923, Payment of Gratuity 1972, Interstate

Migrant Workmen Act 1979, Equal Remuneration Act with Rules, Order and

Notifications issued/made there under from time to time.

2. All other Acts, Rules/Bye-Laws, Orders, Notifications etc. present of future applicable

to the Contractor from time to time for performing the contract job.

2.1 The Contractor shall provide and be responsible for payment of Wages, Salaries,

Bonus, Social charges, Insurance, Food, Accommodation, Transport, Medical and

Canteen facilities and other statutory privileges and facilities to his personnel as per

law / rules / regulations and orders of the Central Government, State Government,

Local Authorities or other authorities as are in force from time to time. All employees

of the Contractor shall be employee of the Contractor.

2.2 The Contractor shall have a valid license obtained from Licensing Authority under

the Contract Labor (Regulation & Abolition) Act, 1970 at the time of execution of the

contract covering all his employees working at SLPP site and furnish the same

failing which GIPCL may terminate the contract at its sole discretion.

2.3 The Contractor shall at the time of execution of the contract have a EPF Code

Number obtained from the Authorities concerned under the Employees Provident &

Miscellaneous Provisions Act, 1972 and remit contributions in respect of the

employees employed by him at SLPP Site to the P.F office concerned every month

failing which GIPCL will recover from the outstanding payment to the Contractor

from GIPCL.PF code of Gujarat region should be taken.

2.4 The Contractor shall maintain all records/registers required to be maintained by him

under various labor laws mentioned above and produce the same before the

Statutory Authorities whenever required.

2.5 The Contractor shall also submit periodical reports / returns to the various statutory

authorities such as the Contract Labour (Regulation & Abolition) Act-1970,

Employees Provident Fund Act etc. Under intimation to HR&A dept.

2.6 The Contractor shall not pay less than the Minimum Wages notified by the

Government from time to time to his employees of corresponding categories.

2.7 The Contractor shall be responsible for payment of overtime wages to his workmen,

if any, in case they are required to work beyond the prescribed hours under law as

per applicable rates.

2.8 The Contractor shall take Workmen Compensation Insurance Policy for all his

employees working at SLPP. The Contractor shall indemnify the company against

any liability due to any work injury or accident to any of its employees.

2.9 The Contractor shall in the event any of his workmen / employee sustains any injury

or disablement due to an accident arising out of and in the course of his

employment, provide necessary medical treatment and pay compensation as

applicable, required under the Workmen’s Compensation Act,

2.10 If any of the persons engaged by the Contractor misbehave with any of the officials

or the Company or commit any misconduct with regard to the property of the

Company or suffer from any serious communicable disease, the Contractor shall

replace them immediately.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

2.11 The Contractor shall not engage / employ persons below the age of 18 years.

Employment of women shall be strictly according to applicable laws.

2.12 GIPCL will have right to deduct and disburse the claims of the individual / parties

being a principal employer on any account whatsoever in relation to their

employment with the Contractor. The Security deposit will be released to the

Contractor at the end of the contractual tenure subject to an undertaking by the

Contractor that in the event any of his workmen or the heirs of workmen puts up a

claim for recovery of money due to him from the Contractor before the appropriate

authority under the I.D.Act 1947 or under any other labor laws or for compensation

under the Workmen’s Compensation Act, 1923 and the appropriate authority has

given a direction for making payment the Contractor will meet the same or indemnify

GIPCL if in the event GIPCL pays it as Principal Employer.

2.13 The Contractor shall make payment of wages to his employees on fixed date within

the period specified under the applicable Law, in presence of representative of the

company. He will submit a true copy of wage sheet, attendance register and P.F.

remitted challan on monthly basis to HR&A dept. for verification and record.

2.14 The Contractor shall provide Safety items / kits to his employees such as safety

shoes, goggles, ear plugs, hand gloves, safety belts etc., if any, required under the

2.15 The Contractor shall conduct pre-induction and periodic medical checkup of his

workmen as per applicable laws.

2.16 The Contractor shall be solely responsible for any accident caused to his workers

and should adhere to all rules / regulations as per labor laws of Government and

other statutory laws as applicable.

2.17 The Contractor should register himself under the Contract Labour Act, Employee

Compensation Act and PF Act (Code no. to be mentioned) and submit the copy of

registration certificate and should possess the same from the date of

commencement of work, failing which the contract is liable to be cancelled. The

E.C. Policy copy should be submitted to the GIPCL before commencement of the

work and Labor License should be obtained within one week from the date of issue

of form-V. Contractor should apply for Form-V immediately after receipt of LoI. A

copy of Labour License shall be submitted to GIPCL, HR&A Department.

2.18 Contractor shall have to insure his workmen /supervisors etc. under Group

Insurance scheme.

2.19 The Contractor shall be responsible for compliance of all statutory rules, regulation,

act enforced from time framed by the government such as Factory Act, Employee

Compensation Act, payment of ‘Wages Act’, Minimum Wages Act’, Provident Fund

Act, All Labor Laws Act in respect of employees engaged by him for the work

and shall have to maintain necessary records. In case any amount becomes due

to be payable by him to his employees or to the Government under the above rules,

regulation, Acts, GIPCL reserves the right to recover the same from the running bill

of the contract.

2.20 Documentary evidence of deposit of PF paid shall have to be produced by the

Contractor along with the next bill.

2.21 Records as per the provisions of various statutory Acts will have to be maintained

by the Contractor and submitted as and when required.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

2.22 All employees of Contractor should maintain due discipline and respect local

sentiments. GIPCL reserves the right to direct the Contractor to remove any such

person who does not comply with it.

2.23 The list is indicative in nature and not an exhaustive one. Any

amendment/alteration/Notifications or addition to the existing Law or a new statute

shall automatically and immediately become applicable.

2.24 Annual Health Check up- As per Statutory requirement, Contractor has to inform

workmen deployed at site for annual health check up as per schedule prepared by

HR&A department.

B. LEGAL ASPECTS

1. Contractor shall maintain all register required under the Labour Laws and make the

payment as per the Minimum Wages Act to the workers employed by him.

2. Contractor shall obtain requisite license to carry out this contract under the provisions of

Contract Labour Act, 1970 and maintain necessary records and registers under the said

3. Contractor shall submit a copy of each of the registration certificates with respect to

Employees Provident Fund and Employee Compensation Act within one week time, from

the date of award of this contract.

4. Contractor’s employees, agent or sub-agent shall not smoke or light anything within the

premises of the GIPCL and carry match box / lighter or any other explosive and /or

inflammable material inside the plant.

5. Contractor shall abide by all the statutory rules and regulations like P.F., Labour Laws

6. Contractor shall issue an appointment order to each casual workman stating therein the

nature of job to be performed by him and fix time for which the concerned workmen are

likely to be deployed. Contractor shall also issue a temporary identity card specifying the

period for which the workmen has been deployed.

7. Contractor is fully liable for the persons engaged by him for above work; however, GIPCL

reserves the right to deduct any amount legally justified towards any liability not fulfilled.

8. Contractor shall indemnify GIPCL from any liabilities arising out of the employment of the

9. If the Contractor fails to complete the allocated job within specified time frame, GIPCL

shall get the work done by third party at the risk and cost of Contractor.

10. PAYMENT OF WAGES

Contractor shall be responsible for compliance of all statutory rules, regulation, act enforced from

time framed by the government such as Factory Act, Employee Compensation Act, payment of

‘Wages Act’, Minimum Wages Act’, Provident Fund Act, Payment of Bonus Act, Labour Law Act,

maternity benefit act in respect of employees engaged by him for the work and shall have to

maintain necessary records. In case any amount becomes due to be payable by him to his

employees or to the Government under the above rules, regulation, Acts.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

11. ACCIDENT TO WORKMEN

Contractor shall be fully responsible for injury or death of any of your or third party workmen due

to any act omission / indiscretion on your part while undertaking the work and Contractor shall

fully abide by the statutory requirements of the employee's compensation act. GIPCL shall not

be liable for any compensation due to accident, death or injury to any of Contractor’s workmen

or any third party due to negligence, act or omission on your part.

General area lighting will be provided by GIPCL. However work area specific lighting should be

arranged by contractor.

13. NIGHT/SUNDAY/HOLIDAY SHIFT

The Contractor shall depute qualified and adequate resources in Night shift / Sunday / holidays

for any emergency job, which may come up at Night / Sunday / holiday.

14. SAFETY ASPECT

Contractor shall observe all the safety and security rules and regulation of the GIPCL which are

at present in force and which may come into force during the pendency of the contract. Any

violation of any rules and regulations will entail immediate termination of the contract.

When contractor moves his/her lifting tools and tackles to the plant area, required test certificates

as per the Factories Act 1948, as amended from time to time and the state factories rules has to

be submitted to safety Dept. Safety Dept. will check the certificates and if found okay, then only

materials will be allowed to enter inside the plant. Material inward gate pass will be made only

after certification from Safety Dept. Security Dept. will inform to Safety Dept., as & when such

tools and tackles brought at the gate for making entry in the maintenance site.

The contractor has to submit the list of required safety gears along with safety equipments

available with him/her to safety Dept. Safety Dept. will check for quantity and quality of the safety

gears and then allowed permission of work. Poor quality material will not be allowed to take

inside the Plant. If quantity of required safety equipments is not satisfactory, contractor will not

be allowed to carry out the work using such safety gears inside the Plant for the work.

15. GENERAL SAFETY CLAUSES:

1. The Contractor shall observe and comply, with regard to his workmen working at the SLPP

site, the safety norms as per the safety operating standards.

2. The Contractor shall ensure that his workmen are informed and trained regarding the safety

standards to be adopted while operating within the SLPP Plant & Mines premises and the

Contractor shall brief them regarding the same and use of the Personal Protective Equipment

3. The Contractor shall issue safety shoes and safety helmet of IS standard to all his workmen

immediately on execution of the work and the contractor shall ensure that his workmen wears

the protective equipments at all times during the work operation. Following brand of the safety

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

shoes and helmet shall be issued to contract workmen. Contractor shall issue safety shoes

Sr No. Model Company Specifications

01. Tough Hat, HP-TH Sure Safety

02. V-Gard MSA IS : 2925 – 1984, ANSI / ISEA

03. PN 521 –Shelmet Karam

Sr No. Model Company Specificatio

SSTEELE (Strom) – Double

01. Acme Fabrikplast Co.

TRIMAX(Adjacent) – Double

02. Acme Fabrikplast Co.

03. Worktoes Warren Worktoes - Warren Plus

4. Other safety gears like ear plug, dust mask, hand gloves, safety goggles, gum boots, full

body safety uniform and belts, safety net etc. shall be issued and used as per the job

requirements. Safety helmet shall be of YELLOW COLOUR ONLY. Contractor will procure

safety shoes & safety helmet from a reputed company with at least 12 months’ guarantee

and shall produce the guarantee certificate and IS standard certificate to the safety

department. Contractor should purchase safety shoes of reputed brands. Safety shoes will

be issued every year. IS certificate and guarantee certificate must be obtained from the

vendor and submitted to the Safety department. Safety shoes should be heat, water, oil and

chemical resistant, having an anti-slippery sole of 15298- 2002 make.

5. It is the duty of Contractor to ensure that his workmen are wearing required PPEs as per

work requirement. Contractor should ensure that their workers are wearing Safety helmet,

safety shoes, dust mask, goggles, ear plug etc. at all times when they are at work throughout

the contract period. The Contractor has to maintain the PPE issue registers with signature of

6. Contractor will reissue these PPEs in case of damage or misplacement of the same.

Replacement shall be made immediately.

7. The Contractor shall be responsible for providing first aid or emergency medical help and

treatment to his workmen in the event of any accident or injury.

8. If it is observed that Contractor is not issuing required PPEs timely and that of required

quality, GIPCL will issue the required PPEs to contract workers and back charge the same

with 25% overhead charges plus applicable GST as per extant GST Laws incurred by GIPCL.

9. All lifting tools and tackles shall be duly certified by competent person in conformity with the

statutory requirements and certificate in form no. 10 as per rule 60 of Gujarat Factories Rules,

1963 and section 29 of the Factories Act, 1948 shall be submitted every year before using

such tools and tackles. In case of purchase of new lifting tools and tackles, form no. 10 as

per the said rules shall be submitted before they are taken into use. All lifting tools and tackles

shall be of reputed make having International manufacturing standard and shall be

maintained in proper and workable condition.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

10. The Contractor shall nominate one Safety Officer with required qualification for supervising

the daily job/ shutdown jobs for observing and maintaining the safety aspects at site. He is

solely responsible for any safety measures during maintenance work. He has to ensure that

all the workmen working at site are equipped with essential PPE’s and proper safety

arrangement is made at the SLPP site.

11. After mobilization of any tools & tackles to site, which includes chain pulley blocks, D-

shackles, wire ropes, winch machines, Mobile crane, Hydra etc. shall be offered for

inspection with all above statutory test certificate before using at site for any work. They

should use all tools and tackles only after certification by GIPCL representative/safety officer.

12. When working at height, working on ceiling or roof covered with fragile materials, full body

harness safety belt, ladders and crawling boards shall be used to prevent accident. Further,

during working on height, Contractor should arrange proper scaffolding of still pipes, safety

net, full body safety belt, fall arrestor system etc. Advice and instructions of engineer in

charge/ safety in charge shall be strictly complied with in this regard. All necessary safety

precautions shall be taken by the Contractor to prevent accident and personnel injuries while

working on height.

13. Flash back arrestors made of reputed manufacturer shall be provided on cutting torch, on DA

cylinders and on O2 cylinder. Cylinder caps also required for handling the cylinders at the

work at height area. Gas cylinders shall be transferred through gas cylinder trolley only with

cylinder cap and stored up right (vertical) position only. All gas cylinders shall be hydro tested

/ certified as per gas cylinder rules 2004. Gas cylinders shall be stored, handled as per gas

14. All vehicles shall be operated by licensed drivers only. All vehicles’ PUC to be tested as per

Government approved RTO guidelines. All Vehicles must be parked in Parking space

designated by GIPCL. If any vehicle is found inside the plant premises other than the parking

area such vehicles shall be handed over to Security dept. and their entry shall be cancelled

for movement inside the plant premises with immediate effect.

15. All electrical equipment shall be in good condition and free from any defect. Electrical tools

& equipments i.e. welding machine, grinding and drill machine etc. may be checked by the

electrical engineer of the Contractors regularly, every six month at least and report to be

submitted to concerned HOD and safety dept.

16. During hot work, Contractor will use fire curtains like asbestos sheets or fire blankets to

prevent falling and spreading of sparks and hot material on and around the work area.

Contractor will procure and use such items. ELCB / RCCB shall be provided with rating of 9-

30 milli-amperes on welding machine and all portable power tools.

17. The Contractor shall fill – up Incident notification form (S-I), Incident Investigation form (S-II)

and near miss report within time limit as specified in forms, if any accident, Incident, near

miss occurred while working at SLPP site.

18. Major AMC / ARC Contractor (Where the man power strength is more than 50 and above)

should appoint / nominate one qualified safety officer and he shall be responsible for

addressing all the safety related aspects of execution of contract jobs and he will in close co

ordination with safety officer of SLPP and attend all safety related meeting such as safety

committee, on job safety training etc. Where the Contractual man power is less than 50, the

Site In-charge of the Contractor will act as a Safety Officer and he will perform all the duties

of safety officer as mentioned above.

19. No loose connection / joints allowed in electrical cables during performance of any kind of

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

20. Safety shoes to be issued to female employees also.

21. All the vehicles shall be fit as per RTO guidelines and valid fitness certificate is required as

per RTO guidelines.

22. The Contractor’s nominated safety officer shall be imparted regular on-job safety training like

tool-box talk etc. and submit a record of such training in safety dept, respective dept and

23. The Contractor shall comply all the new requirements related with safety as informed by the

HOD / Safety department from time to time.

24. Penalty to be imposed for Violation of safety norms is proposed as follows:-

The Contractor & Contract workmen shall strictly adhere to Safety standards / Guidelines as per

practices. The list provided below is an indicative list to explain the principles behind safety

practice. If the contract workmen fail to comply with safety standards as per category A, B & C

below, penalty shall be levied on the Contractor as per the table mentioned below:

Category Examples / Cases Penalty

PPEs Working without shoes, dust mask,

A Rs. 100 /- per instant.

Related gloves, safety goggles etc.

Failure to adhere to HSE

guidelines/plans, careless attitude in

material handling,

Machine being used with damaged

machine guard, unsafe electrical

work - workout plug top/improper

electrical joints/cables lying on

ground, electrical equipment working • Rs. 500 /- per instant.

without proper earthing, machine

being used without machine guard, • After three incidence, per

Welding machine without ELCB / incidence Rs. 2,500/-

WI RCCB of proper rating, Gas cylinder

Related without test certificate, Cylinder cap, • Continuous unsafe acts will

NRV / Flash back arrester, Cylinder disqualify the Contractor

trolley etc. from further participation in

Unsafe working practices at height tender of/contract with

more than 3 meters. GIPCL.

Working without permit or non-

compliance with permit conditions

like hot work, height work etc. as

applicable, lifting tools and tackles

being used without third party

inspection certificates in form no.

9/10 as per Factory Act – 1948 etc.

• Suspend the entry gate

Breach of safe practices by a pass for one week.

C particular person repeatedly for three

times • After two suspensions his

gate pass will be cancelled.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Penalty so levied against the Contractors and company employees will be used during the

observation of National Safety Day.

The Contractor, workmen following good safety practices in their work area continuously

will be rewarded / honored on National safety day.

16. REJECTION OF WORK:

If, as a result of inspection, examination or testing, the GIPCL’s Representative / Engineer

decides that any materials, work or workmanship is defective or otherwise not in

accordance with the Contract, the GIPCL / Engineer / GIPCL’s Representative may reject

such plant, materials, work or workmanship and shall notify the CONTRACTOR promptly,

stating his reasons. The CONTRACTOR shall then promptly make good the defect and

ensure that the rejected item complies with the Contract. If Contractor failed to rectify the

rejected work or workmanship, GIPCL / Engineer reserves the right to deduct or withhold

amount against rejected work or Workmanship. CONTRACTOR shall not entitle for any

claim or release of hold payment until rectify the defect up to satisfactory of GIPCL. If

Contractor failed to rectify any such defective work or workmanship, GIPCL reserve the

right to rectify at risk and cost of the CONTRACTOR and deducted by the GIPCL from any

amount due, or to become due, to the CONTRACTOR’s dues.

If the GIPCL / Engineer / GIPCL’s Representative requires such materials, work or

workmanship to be retested, the tests shall be repeated under the same terms and

conditions. If such rejection and retesting cause the GIPCL additional costs for the

traveling and lodging costs of GIPCL / Engineer’s personal for attending the retest, such

costs shall be recoverable from the CONTRACTOR by the GIPCL and may be deducted

by the GIPCL from any amount due, or to become due, to the CONTRACTOR.

17. GENERAL TERMS AND CONDITIONS:

a. All tools & tackles, labours, equipments, vehicles, tractors, etc., to execute the

contract are in the scope of the contractor. The contractor should ensure that tools

&equipments are in healthy condition.

b. The decision of the Engineer-in-charge shall be final and binding on the contractor

for defining the terms and condition included in this contract.

c. If the work is not found satisfactory, Engineer-in-charge reserves the right to take

suitable action.

d. Contractor shall depute full time independent experienced site-in-charge /

independent site supervisor / s at site. They shall co-ordinate with GIPCL engineer

and shall bear overall responsibility of contract including joint certification, billing etc.

Such person shall function from site office of contractor at SLPP.

e. Contractor shall also nominate one safety supervisor at site and shall submit

nomination of safety supervisor in writing before commencement of contract. Safety

supervisor shall arrange small safety talk on every day morning or whenever required

with all workers working under this contract. He shall coordinate with concern

department’s Engineer-in-charge on daily basis and report daily observations, tool-

box talk records etc. The work shall not be allowed without deploying safety

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

supervisor and a penalty equal to Rs.1,000/- per day absent of safety supervisor shall

be levied from Contractor.

f. Contractor shall strictly follow the existing work permit system of the GIPCL and any

future revisions.

g. The contractor has to take EC insurance policy for their workmen. The contractor has

to submit labour license (if applicable) and PF account number to the Engineer-in-

charge before start the work.

h. The contractor has to do the job timely. GIPCL shall not compromise in delay. In case

of delay of work without any valid reason, the GIPCL reserves the rights to carry out

the work by deploying other agencies at the risk & cost of contractor with additional

10% overhead charges plus applicable GST as per extant GST Laws.

i. Contractor shall mobilize the resources as per need within the period of twenty four

hours. If the contractor fails to mobilize sufficient resources to complete the job in

time, GIPCL will execute the job through other agency at the risk and cost of the

contractor with additional 10% overhead charges plus applicable GST as per extant

j. Contractor should mobilize all resources for efficient & smooth execution of contract

within seven to fifteen days from the date of issue of Letter of Intent/Work Order.

k. The prices / item rates quoted (based on quoted % above/equal or below SoR) shall

remain firm till completion of the contract and any agreed extensions thereafter and

shall not be subject to any price escalation including idle charges for labour,

machinery, overhead expenses etc… due to any reason whatsoever. However

Diesel price variation will be applicable as mentioned in the clause no 2 of Section

D. No price escalation / idle charges shall be entertained due to delay in work on

unavailability of work front, non-issue of work permit, holding of work permit for any

reason, unavailability of contractor’s supervisor, unavailability of contractor’s safety

supervisor, violation of safety rules, unsafe act by any of contractor’s worker,

negligence & ignorance of safety & quality instructions of GIPCL Engineer-in-charge

or any other reason whatsoever.

l. Contractor must fulfill all the safety regulations and to take safety measures to avoid

hazards. Contractor shall arrange all standard adequate healthy safety PPEs like but

not limited to approved quality safety shoes & safety helmets, standard dust masks,

safety goggles, safety hand gloves, etc… as required and shall use exclusively under

this contract for all the time during working at specified locations failing which, the

Engineer-in-charge may hold the work and will take necessary action including

penalty as decided. If the contractor repeatedly violates safety rules / regulations

(more than three successive incidents), Engineer-in-charge may take necessary

action against the contractor, including appropriate financial penalty and / or

termination of contract.

m. One or more jobs may be required to be done simultaneously and contractor shall

mobilize additional resources accordingly.

n. Timely completion of all jobs and works shall be the essence of this Contract.

Contractor should closely monitor each activities and complete the jobs as per the

time given by and under the supervision of the Engineer-In-charge and shall ensure

that sufficient manpower is deployed for the same.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

o. The contractor has to complete the works as per the planning schedule and their

respective supervisor has to interact with Engineer-In-Charge for PTW (Permit to

work), work instruction, Return of permit.

p. The contractor has to submit daily reports showing work carried out with details of

available manpower, equipments / vehicles (tractors) etc.

q. Any job other than the listed jobs in work order shall be executed by the contractor

on instruction from GIPCL and payment shall be made to the contractor on respective

item rate only.

r. The Government of India has enacted the Micro, Small and Medium Enterprises

Development Act, 2006 (the “Act”) and the Act has come into force from October

2006. The Bidder shall confirm whether your organization is registered under the

Micro, Small and Medium Enterprises Development Act, 2006, as amended from

time to time. If your organization is registered under the Act, please specify the

category i.e., Micro Enterprise, Small Enterprise or Medium Enterprise under which

it is registered and kindly attach a copy of your registration certificate.

s. The Bidder shall provide details of registration along with copy of the registration

certificate issued by the District Industries Centre/Department of Industries, etc of the

respective State Government. It is to be noted that large scale industries and trading

firms have been excluded from the purview of the Act.

t. GIPCL is an ISO 9001, ISO 14001, ISO 45001 & ISO 50001 (EnMS) certified

company and GIPCL gives extreme importance to maintain these global standards.

Contractor shall be required to fulfill the requirements of above standards while

working with GIPCL especially for controlling fugitive emission of ash (fly and Bed)

during dozing / leveling / compacting of Ash / Lignite / Limestone activities. Contractor

should ensure that his workmen/labour work in accordance with them.

u. GIPCL shall impart safety training to the Dozer operator/s in phased manner,

considering their working in mines area, and relevant safety aspects / use of safety

PPEs pertaining to it. Contractor shall instruct the operator/s for attending these

training sessions, as and when informed by GIPCL’s Engineer In-charge.

18. CONTRACTOR’S SUPERVISION

The Contractor shall, during the whole time the work is in progress, employ a qualified manpower

/ operator with adequate experience in handing of jobs of this nature and with the prior approval

of the GIPCL / Engineer In-charge. Such manpower / operator shall be constantly in attendance

at the site during working hours. During Contractor’s Supervisor’s absence during working hours,

if unavoidable, and also beyond working hours, when it may be necessary to give directions,

orders may be given by the GIPCL’s Engineer In-charge and shall be received and obeyed by

the Contractor’s superintendent who may have charge of the particular part of the work in

reference to which orders are given. If requested to do so, the Engineer / GIPCL shall confirm

such orders in writing. Any directions, instructions or notices given by the Engineer / GIPCL to

him, shall be deemed to have been given to the Contractor. The representative of the Contractor

shall have all necessary powers to receive materials from the GIPCL, issue valid receipts for the

same, engage labour or purchase materials and proceed with the work as required for speedy

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

None of the Contractor’s Superintendents, Supervisors or labour should be withdrawn from the

work without due notice being given to the GIPCL’s Engineer In-charge; further no such

withdrawals shall be made if in the opinion of the GIPCL’s Engineer In-charge such withdrawals

will jeopardize the required pace of progress / successful completion of the work.

The Contractor shall employ in or about execution of the work only such persons as area careful,

skilled and experienced in their respective trades, and the GIPCL shall be at liberty to object to

and require the Contractor to remove any person employed by the Contractor in or about

execution of works who in the opinion of the Engineer misconducts himself or is incompetent or

negligent in the proper performance of his duties and all such persons shall not again be

employed upon the works without the prior permission of the GIPCL.

Neither the Contractor nor the Engineer shall hire or employ any employee of any other party

except by mutual consent.

19. CONTRACTOR TO REMOVE ALL OFFENSIVE MATTER IMMEDIATELY AND CLEAN-

All loose materials, wastage, packing materials, empty paint drums, cut pieces or other

matter of an offensive nature shall not be deposited on the surface, but shall at once be

carted away by the CONTRACTOR to some pit or place provided by him away from the

site of work and approved by local authorities.

As a part of the work included in this contract, the CONTRACTOR shall completely

remove and satisfactorily dispose of all temporary works & remove scaffolding materials

to the extent directed. He shall tear down and dispose of all temporary works, shall

remove or grade, to the extent directed, all plant and equipment, shall satisfactorily

dispose off all rubbish resulting from the operations under this contract and shall do all

work necessary to restore the territory embraced within the site of his operations to at

least as good order and conditions as at the beginning of the work under this contract.

20. FACILITIES TO BE PROVIDED BY GIPCL

A. The Company shall provide the following facilities to the Contractor at the site:

a. Electricity & water at nearest available one point. Further distribution to be done by

contractor at their cost.

b. Quarter / room & food for supervisors / engineers on chargeable basis in GIPCL’s

township at discretion of GIPCL if available. Food on chargeable basis at GIPCL’s

Industrial Canteen as available. If not available, contractor to make his own

arrangement for lodging and boarding locally or as appropriate at his cost.

c. Workshop facility as available at site only. However contractor may visit the workshop

to ensure the existing facility. For the facilities other than available, contractor has to

carry out the job outside at their own cost.

d. First aid facilities as available on chargeable basis. If not available contractor to make

his own arrangement for the same locally or as appropriate at his cost.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Apart from the above, no other facilities shall be provided by GIPCL.

B. GIPCL shall also conduct an orientation program appraising the workmen regarding the

safety norms and measures to be observed during work operations at the plant site.

21. WORK MEASUREMENT / CERTIFICATION

On daily basis, the Contractor shall take the certification form GIPCL Engineer In-charge

regarding daily work carried out in line with the tender and as per GIPCL engineer instructions.

This daily certification of measurement of work shall be the basis of processing your monthly bill.

For Package (A) of Tender, the weighment of the Ash disposed / dumped at specified locations

of Mines pit on day to day basis shall be the basis for the Operation of Dozer. The Contractor

shall have to doze / level / compact the dumped Ash on day to day basis. The certification for

Dozer operation shall be based on the complete dozing of the previously dumped Ash at location

directed by Engineer in-charg (Ash dump-yard) after physical verification for proper leveling /

compacting before the said certification. The weighment at AHS Weigh Bridge shall be treated

as actual quantity of Ash disposed / dumped. If Weigh-bridge is out of order, the average weight

derived by previous record or the decision taken by the Engineer In-charge in this regard, shall

be considered as the quantity of Ash dumped in the mines pit for dozing and

dozing/compacting/Leveling of the same shall be considered for work certification. For Package

(B), the actual measured (and certified by Engineer In-charge) Dozer Run Hours shall be

considered for work measurement / certification.

22. PUBLIC HOLIDAYS

The Contractor shall be responsible for giving benefit to all his employees, employed in

whatsoever capacity, Nine (9) Public / Paid holidays and the same shall be notified in advance

and due communication thereof shall be made to the Management.

23. FORCE MAJEURE

The performance of the obligations herein contemplated may be suspended without incurring the

penalty in the event of the subsistence of Force Majeure conditions.

If a Force Majeure situation arises, the affected Party shall promptly notify the other Party in

writing of such conditions and the performance shall be suspended as per mutual agreement.

For the purposes of this clause, ‘Force Majeure’ means an event beyond the control of the Party

and not foreseeable by the Party and shall include events of floods, explosions, riots, wars,

hurricane, epidemics, any other Act of God, quarantine restrictions, terrorism, government

actions and provided always that such acts result in the impossibility of the further performance

of the contract.

The Contractor shall indemnify and keep harmless GIPCL from and against all actions,

proceedings, claims, demands, losses, costs, damages and expenses whatsoever which may

be brought against or suffered by GIPCL which it may sustain, pay or incur as a result of or in

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

connection with the performance/ purported performance / non-performance of the contract by

the Contractor.

In case, in any litigation pertaining to labour employed through Contractor if any direction or order

is issued by court at any point of time the Contractor shall comply with and implement such

direction or order whether passed at the time of award of contract or during the pendency of

contract. Further, the Contractor shall indemnify the GIPCL against all consequences arising and

affecting GIPCL owing to the compliance of the orders by the Contractor.

25. GOVERNING LAW AND JURISDICTION

This tender document and contract shall be governed by the laws of India and the Courts at Surat

shall have jurisdiction regarding the same.

26. Where any portion of the General Condition of Contract is repugnant to or at variance with

any provisions of the Special Condition of Contract, then unless a different intention

appears, the provision of the Special Conditions of Contract shall prevail to the extent of

such repugnancy of variance.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

SPECIAL CONDITIONS OF CONTRACT

1. DETAILED SCOPE OF WORK:

(1A) Package - A: Dozing / Compacting / Leveling of Ash and other works at pre-

designated locations of Mines pit:

GIPCL Power plant generates Fly Ash & Bed Ash which is suitable for manufacturing bricks,

paving blocks, hollow blocks, etc. The nearby local land losers / brick manufacturers lift entire

quantity of ash from power plant for their use. These local customers do not lift ash completely /

partially When there is less demand of ash based product in the market or heavy rainfall or during

festival times such as Diwali, Holi etc. So it is disposed at pre-designated locations of mines

area. The Scope of Work here shall be to Doze / Compact and Level the disposed quantity of

Ash at pre-designated locations of Lignite mines pit on day to day basis, as and when required.

The estimated quantity of Ash which may be required to be disposed and hence subsequently

dozed/compacted/leveled at mines during the proposed Contract period shall be as per the

Section E – Schedule of Quantities and Price. This quantity may increase or decrease, which

shall depend upon the frequency & volume of rainfall. If there is intermittent rain fall & volume of

rain is less, the estimated disposal quantity may be very less.

The Scope of Work shall cover Hiring of Dozer D-80 or of equivalent capacity on Metric Tonne

(MT) basis for following:

▪ During the monsoon period and any other lean period during the Contract period at any time,

Fly Ash / Bed Ash will be transported to Lignite mines for dumping purpose. As soon as Ash

is unloaded at site, it is to be dozed & leveled immediately.

▪ Arrangement of water hose and spraying of water for compacting the dozed ash, as and

when required or as instructed by Engineer-in-charge.

▪ The delay in Dozing of ash will block the approach area for further Transportation & Unloading

at designated point. So, it is very much essential to keep the dozer in running condition for

▪ It may be noted that, the Contract will operate as & when required basis. However

Contractor has to ensure 365 days availability of Dozer along with operator.

1. The weighment for the actual Ash disposed / dumped at the below specified locations of

Mines pit shall be done at GIPCL’s AHS Weigh-bridge.

2. If at any point, the Weigh Bridge is found in-operative or out of order, average weight

transported of previous one month will be considered for billing purpose.

3. Followings are the pre-designated locations of Lignite Mines pit / any other locations where

Contractor shall have to execute the work :

(i) at a one way distance of 0 km to < 3 km from Fly Ash Silos – 3 & 4;

(ii) at a one way distance of > 3 km to < 6 km from Fly Ash Silos – 3 & 4;

(iii) at a one way distance of > 6 km to < 9 km from Fly Ash Silos – 3 & 4;

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

(iv) at a one way distance of > 9 km to < 12 km from Fly Ash Silos – 3 &

4. The total estimated quantity of Ash to be dozed/compacted/leveled, during the Contract, shall

be as specified in Section – E. The quantity of ash may vary depending on the performance

of the plant, volume of Rain fall, the off take of Ash by the local land losers / brick

manufacturers etc. Company shall allow brick manufacturers to lift the ash, as much quantity

as they can lift. So in case if Contract is not executed or partly operated, GIPCL shall

not be responsible for any type of idle charge.

(1B) Package-B: Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction

at in-plant and ELHS stock pile area & other miscellaneous works:

The Scope of Work shall cover Hiring of Dozer D-80 or equivalent capacity on Running Hour

basis for following:

➢ The compaction of lignite / limestone at in-plant, out plant and ELHS stockpile layer wise.

➢ Pushing of Lignite and Limestone at in-plant stockpile, out plant stockpile, ELHS stockpile

and at feeder breaker end.

➢ For lying of conveyor belt and lifting of take up counter weights in Maintenance work and any

other jobs as per the requirement.

Note: Considering the case of Dozer break-down and parallel work requirement for

Package A and Package B, and parallel work to be carried out at different locations of

Mines pit, Contractor may have to arrange additional Dozer (model D-80 or equivalent

dozing capacity), at GIPCL–SLPP site, without any cost implication to GIPCL.

Followings shall form the part of Scope of Work for both Package - A and Package – B for

the Contractor:

1. The Dozer of model D-80 / equivalent equipment deployed at Site shall be equipped with an

Hour Meter for measurement of the Running Hours for the Operation of Dozer. Further, the

Dozers shall be retained at Site till the completion of work assigned by Engineer In-charge,

on day to day basis.

2. In normal day, Contractor shall keep Dozer from 8:30 am to 5:30 pm. However in case of

urgency, Contractor shall make the Dozer available in one hour notice other than above time,

if required so.

3. Contractor shall mobilize the replacement for all the vehicles deployed by him at site,

immediately on any breakdown of the respective equipment / machinery.

4. The mobilization of Dozer between intermediate locations of Mines, where the Dozing of Ash

shall have to be carried out as per the Scope of Work of Contract, or the mobilization of Dozer

from any AHS locations to LLHS locations and vice versa shall not be payable to the

Contractor and shall be in Contractors’ scope. The Contractor may consider tentatively

12 Nos. of such mobilization of Dozer per Annum (approx. 4 hours of Dozer running

per to & fro mobilization) for execution of inter-departmental scope of work (between

Package – A and Package – B)

5. While executing the contract, if any legal situation, local litigations, etc. arises, it will be the

responsibility of Contractor to manage amicably without any financial burden to GIPCL.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

6. During execution of contract, Contractor shall follow all the safety norms, legal / statutory

compliances, etc. as applicable time to time.

7. Contractor has to designate a person as a supervisor to look after and coordinate the daily

activities. The supervisor shall report to concerned Engineer In-charge of GIPCL and get the

job certified on daily basis. The daily reports duly certified by GIPCL Engineer In-charge shall

be submitted along with the monthly bill and the payment shall be made on the basis of the

8. Mobilization period: Initial mobilization period from the Date of Award of Contract shall

seven (7) days. If the Contractor fails to mobilize sufficient resources to complete the job in

time, GIPCL may execute the job through other agency at the risk and cost of the contractor.

9. All statutory requirements applicable for working in Power Plant and Mines area shall be

adhered to and followed.

10. On completion of work, the Contractor shall promptly demobilize from the site and leave the

place in a manner as directed by the OWNER / Engineer In-charge, including cleaning of the

11. Contractor shall report to Ash Handling department for Package-A. pertaining to any issue

regarding the Dozing of Ash at pre-designated locations of Mines pit and LLHS department

for Package-B pertaining to any issue regarding the Dozing of Lignite/Coal and other works

12. No damages to GIPCL property or any public property shall be admissible.

13. All tools and plants and consumables shall be in the scope of contractor.

14. Contactor has to provide mobile phone to its dozer operator for ease of communication while

working in mines area.

1.1 SPECIFIC REQUIREMENT

Contractor shall submit copies of the following documents immediately on Award of Contract:

❖ Suitable / Valid Driving licenses for Dozer Operators (suitable Earth mover category).

❖ R.C. book of Vehicles deployed at site.

❖ Valid Insurance coverage of Vehicles deployed at site.

❖ Valid Fitness certificates, if applicable, of Dozer(s)

❖ Valid P.U.C, if applicable, of Dozer(s).

❖ Vocational Training certificate issued under VT rule

❖ Medical of Driver/ Dumper Operator - as per Mine Rule

• Under - performance of work:

The daily operating hours may be from 07.00 am to 09:00 pm in critical times. Contractor shall

have to doze / compact / level the dumped Ash or push / lift / compact Lignite, as and when

required, as directed by Engineer In-charge, by 9:00 pm of the respective day. If the Contractor

shall not be able to achieve the above, as per requirement, by 9.00 pm of the particular day, and

especially for Package – (A), if Ash dumping shall be hampered, it will be considered as Under

performance and GIPCL shall be free to deploy any other party to get the work done at the risk

and cost of Contractor. In case of such urgency, Contractor shall be prepared with the

required resources for the Dozing / compacting / leveling of up to 1,500 to 2,000 MT of Ash

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

If Contractor Under performs as above for more than five (5) times in a Fortnight period,

GIPCL reserves the authority to terminate the Contract immediately and forfeit the

Security deposit of the Contractor.

1.2 FAILURE DURING EMERGENCY

During any emergencies, Contractor shall have to carry out the work by deploying additional

required resources within four (4) hours of intimation, failing to which GIPCL reserves the right

to carry out this work by engaging any other party at the risk and cost of Contractor. The

expenditure occurred due to such situations, the Contractor will be held responsible & the same

will be recovered from the Contractor’s monthly bill / any other pending bills along with 10%

Overhead charges plus applicable GST as per extant GST Laws. For repetitive failure of such

work for more than two incidents, GIPCL reserve the right to terminate the entire contract by

forfeiting all pending dues, Security Deposit, after giving 15 days notice to the Contractor & this

will be binding to the Contractor.

1.3 TO REMEDY DEFECTIVE WORK

If the work or any portion thereof shall be damaged in any way excepting by the acts of the

GIPCL, or if defects not readily detected by proper inspection shall develop before the final

completion and acceptance of the whole work, the Contractor shall forthwith make good, without

compensation, such damage or defects in a manner satisfactory to the Engineer In-charge /

GIPCL. In no case shall defective or imperfect work be retained even if Contractor followed all

technical specifications. GIPCL will not compromise for quality of materials, works &

The Contractor shall remain liable under the provisions of this clause notwithstanding the passing

by the GIPCL of any certificate, final or otherwise or the passing of any accounts.

2. DIESEL PRICE VARIATION

Diesel price variation will be applicable only if diesel price increase or decrease more than 5%

over the base price of diesel.

i) Base price will be the average of last 30 days diesel price at nearest PSU outlet (Nani

Naroli) from plant from the date of publication of tender.

ii) For calculation of diesel price variation, Monthly average diesel price for the claimed

billing period ( generally 21st to 20th ) will be considered.

iii) Diesel price variation will be applicable only on 60% component of respective items

mentioned in the Section-E of tender.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Effect of change in diesel price on SoR will be calculated as shown in below table. Diesel rate

considered here for calculation is indicative only.

Calculation for increase of Diesel price for item as mentioned in Sr. No. A

1 SoR rate Rs / Ton

2 Base Price of Diesel Rs/Lit

3 Monthly Average Price of Diesel Rs/Lit

4 Difference in Diesel Price (3-2) Rs/Lit

5 Change in Diesel Price (4/2*100) %

Change in Diesel Price which is not applicable as per tender

7 Change in Diesel Price which is applicable (5-6) %

8 Variable Component Specified in Tender %

9 Rise in SoR (1*7*8/10000) Rs / Ton

10 New SoR Rate after increase of diesel price (1+9) Rs / Ton

Calculation for decrease of Diesel price for Fly Ash Dozing item Sr. No. A of

1 SoR rate Rs / Ton

2 Base Price of Diesel Rs/Lit

3 Monthly Average Price of Diesel Rs/Lit

4 Difference in Diesel Price (3-2) Rs/Lit -10

5 Change in Diesel Price (4/2*100) % -10.20

Change in Diesel Price which is not applicable as per tender

7 Change in Diesel Price which is applicable (5-6) % -5.20

8 Variable Component Specified in Tender %

9 Rise in SoR (1*7*8/10000) Rs / Ton -0.50

10 New SoR Rate after decrease of diesel price (1+9) Rs / Ton

Calculation for increase of Diesel price for item as mentioned in Sr. No. B

1 SoR rate Rs / Hr

2 Base Price of Diesel Rs/Lit

3 Monthly Average Price of Diesel Rs/Lit

4 Difference in Diesel Price (3-2) Rs/Lit

5 Change in Diesel Price (4/2*100) %

Change in Diesel Price which is not applicable as per tender

7 Change in Diesel Price which is applicable (5-6) %

8 Variable Component Specified in Tender %

9 Rise in SoR (1*7*8/10000) Rs / Hr

10 New SoR Rate after increase of diesel price (1+9) Rs / Hr

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Calculation for decrease of Diesel price for item as mentioned in Sr. No. B

1 SoR rate Rs / Hr

2 Base Price of Diesel Rs/Lit

3 Monthly Average Price of Diesel Rs/Lit

4 Difference in Diesel Price (3-2) Rs/Lit -10

5 Change in Diesel Price (4/2*100) % -10.20

Change in Diesel Price which is not applicable as per tender

7 Change in Diesel Price which is applicable (5-6) % -5.20

8 Variable Component Specified in Tender %

9 Rise in SoR (1*7*8/10000) Rs / Hr -56.20

10 New SoR Rate after decrease of diesel price (1+9) Rs / Hr

3. PRICE & RATES

The rates quoted by the Bidder in the online Price Bid shall be inclusive of cost of all labour,

supervision, cost of safety supervisor, shifting, transportation, loading, unloading, fuel

,equipment, all tools & tackles, safety equipments & PPEs, Royalties, Rents, GST, Stamp Duties,

Central or State Government or Local body or Municipal Taxes or Duties, Turn over Tax, Work

Contract Tax and / or any other duty / tax levied by the Central, State Government or other Public

bodies etc... and such other costs that are not specifically mentioned herein but will be incurred

by the Contractor for the satisfactory and timely completion of the work. The quoted rates shall

be deemed to include for everything mentioned in the specification, all leads & lifts, Contractor’s

overheads & profits for due performance of the work under this contract and such other costs

that are not specifically mentioned herein but will be incurred by the Contractor for the satisfactory

and timely completion of the work. The rates shall also include cost for mobilization /

demobilization of manpower, equipments, materials, etc.

The quoted rates by the Contractor shall be firm throughout the Contract period and also during

extension, if required and shall not be subject to any escalation in prices, idle charges for

equipment / machinery, labour, overhead expenses etc. However Diesel price variation will be

applicable as mentioned in the clause no 2 of Section D. No idle charges shall be paid due to

any reason whatsoever and due to delay in work by Contractor or due to non-availability of work

front by GIPCL or any reason whatsoever.

The price / rate quoted by Contractor shall be considering mobilization of all required manpower,

tools & tackles, materials, equipment for timely and satisfactory completion of all Scope of work.

The value and/or quantum of work may be increased or decreased depending upon day to day

requirement. However, item rates remains unchanged (except change due to Diesel price

variation) and the payment shall be made as per the actual quantity executed as informed &

certified by GIPCL representatives.

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

3.1 TERMS OF PAYMENT

A. Conditions of Payment:

The Contractor shall raise the running Invoices in duplicate every month in respect of the work

performed or completed during the month along with the documents as hereinafter provided. On

receipt of the invoice complete in all respects and with all the said documents, the payment in

respect of the same shall be made within 21 days of such receipt of a complete invoice as per

the following terms of payment:

(i) 100% of monthly RA bill along with 100% taxes shall be released against the work

executed duly certified by GIPCL, Income Tax (IT) will be deducted at source from

monthly RA bills as per the rules in force.

(ii) Security deposit at 10% of Annual Contract value excluding GST shall be submitted as

per Clause no.: 1 of SECTION - C. Security deposit will be returned to the Contractor

without any interest after retention period of three months from actual contract completion

date as certified by Engineer-in-charge as per Clause no.: 1 of SECTION - C.

(iii) GST shall be paid along with bills after fulfillment of following terms:

(a) Submission of copy of registration certificate issued by GST Authority (to be

furnished only once).

(b) Citing the GST Registration no. And the date of Issue of Registration certificate on

(c) Claim of GST amount with percentage (%) separately shown on the invoices.

(d) The Contractor shall be required to submit the proof of payment of GST in previous

month/quarter, as may be applicable as & when demanded by

GIPCL/Owner/company.

(e) The Bidder shall inform the Owner in the event of its registration certificate is

cancelled or discontinued for whatsoever reason.

(f) The vendor shall also mention on their invoice the HSN/SAC code as applicable

under the GST laws under which GST is levied and a self certified authentic third

party evidence (www.cbic-gst.gov.in) shall be adduced, one time, to that effect by

(iv) At the time of submission of the first monthly RA Bill, the Contractor shall submit a

certificate from Engineer In-charge regarding availability of required equipments

machineries with due healthiness, other required vehicles etc at site. The Contractor shall

also furnish the checklist as per Annexure enclosed with the SECTION - F of tender

document along with the RA Bill of respective month.

(v) The Contractor shall submit his Final Bill within a period of four months of the expiration

or earlier termination of the contract or any extensions that may be granted by GIPCL to

the Contractor. GIPCL shall not entertain any bill for any work item after expiration of

period of four months.

(vi) The Contractor shall include all his claims in the Final Bill submitted by him and

accordingly the final bill submitted by the Contractor shall be deemed to be inclusive of

all and whatsoever the claims that the Contractor may have from GIPCL. The Contractor

shall not be entitled to claim any amounts which are not mentioned in the Final Bill and

the Contractor shall be deemed to have waived any claims not mentioned in the Final Bill

and shall not be entitled to recover the same from GIPCL subsequent to the submission

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

of the Final Bill on any account and GIPCL shall stand absolved of all its liabilities in

respect of any such claims not raised by the Contractor in his Final Bill.

B. Validity and Uniformity of Rates

The rates shall be firm and valid for the period of two years of the Contract Period and shall

remain unaltered during Contract Period. However Diesel price variation will be applicable as

mentioned in the clause no 2 of Section D.

3.2 SUBMISSION OF TECHNICAL DOCUMENTS TO THE ENGINEER IN-CHARGE:

Contractor shall submit following documents to the Engineer In-charge for verification purpose

• Measurement sheets along with record duly signed by authorized representative of

Contractor and GIPCL Engineer.

The bill will not be entertained without submission of relevant documents.

3.3 SUBMISSION OF STATUTORY COMPLIANCES WITH PERIODICAL /

MONTHLY RA BILL(S)/FINAL RA BILL:

Contractor shall submit one time or regularly, as applicable, the following documents alongwith

the periodical/monthly RA bill/Final RA bill.:

(i) Notarized Indemnity Bond as per standard Performa, in case of Final bill.

(ii) No claim - No arbitration certificate as per Performa at Annexure-C in Section-F,, after the

final bill amount is certified by GIPCL for payment and the same is made known to the

contractor by GIPCL & accepted by the contractor.

Bill submitted without any of the above documents shall not be processed for payment.

3.4 MOBILIZATION DURING EXECUTION OF WORK

a. Initial mobilization: After issue of LOI/ Work order, contractor has to mobilize all resources

within 7 days at site. Subsequently the contractor shall mobilize resources at site as per

need within period of four (4) hours as directed by GIPCL.

b. Contractor shall provide required separate & independent site supervisors who will be

responsible for supervision and execution of job in specified time with respect to quality,

specifications, site preparations, safety, co ordination with GIPCL, joint measurements, etc.

The supervisors shall coordinate with the Engineer In-charge of GIPCL for proper execution

c. The resources required for execution of above jobs will vary from time to time, hence

Contractor shall mobilize the resources accordingly.

d. Contractor shall provide accommodation for the persons deployed by him for the work at his

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

3.5 QUANTITY OF WORK

The estimated quantities of work required to be carried out by the Contractor are as given in the

Section - E (Schedule of Quantities and Price). Estimated Quantities shall vary according to the

exigencies of work at site. However, the rates quoted by Bidder shall remain firm irrespective of

any variation in estimated quantities. Contractors shall engage required nos. of workmen /

machinery / equipment along with required tools & tackles as per work load and emergency

situations throughout the contract period to perform his contractual duties.

In case, contract quantity / amount exhausted before completion of contract period, GIPCL

reserve the rights to increase the quantities or contract amount for successful completion of entire

contract period. Contractor shall responsible to complete the particular job up to entire

satisfaction of Engineer In-charge. The item rates remain firm & unchanged (except change due

to Diesel price variation) till completion of the contract and any agreed extensions thereafter and

shall not be subject to any escalation, idle charges for labour, machinery, overhead expenses

etc. for any reason whatsoever. However Diesel price variation will be applicable as mentioned

in the clause no 2 of Section D. The quantum of work of individual item may be up to any extent

depending upon requirement. Under this contract, Contractor has to execute all work as per the

Plant requirement.

3.6 GENERAL CONDITIONS OF CONTRACT

General Conditions of Contract (Section-C) and detail specification prepared by the company will

be applicable for this contract. The same is enclosed herewith. Bidders are advised to go through

Where any portion of the General Conditions of Contract is repugnant to or at variance with any

provisions of the Special Conditions of Contract, then unless a different intention appears, the

provision of the Special Conditions of Contract shall prevail to the extent of such repugnancy of

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

SCHEDULE OF QUANTITIES AND PRICE

Biennial Rate Contract (BRC) for Hiring of Dozer (model D-80 or equivalent) for

(A) Dozing / Compacting / Leveling of Ash at pre-designated locations of Mines

pit / any other locations, and (B) Pushing / Lifting of Lignite, Limestone, Lignite

stock pile compaction at In-plant and ELHS stock pile area & other miscellaneous

works at Surat Lignite Power Plant – 4 x 125 MW, Unit # 1 to 4 (Contract Period:

Brief Total Biennial SoR

Scope of UoM Biennial amount (G)

No. Description (g)

Work Qty (excl. GST)

A. Hiring of Dozer of model D-80 or equivalent capacity for dozing / compacting /

leveling of Ash and other works at pre-designated locations of Mines pit / any

(model D-80 Rate

or excluding Will be derived

1 equivalent) MT 1,00,000 GST to be after filling of

for dozing / quoted by rate by bidder

leveling / bidder

B. Hiring of Dozer of model D-80 or equivalent capacity for Pushing / Lifting of

Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile

area & other miscellaneous works

excluding Will be derived

equivalent) detailed in Running

2 1,000 GST to be after filling of

for pushing / section - Hours

quoted by rate by bidder

lifting / D above.

Will be derived

Total Contract Value for two (2) years

after filling of

(excluding GST)

Will be derived

Total Contract Value for two (2) years

after filling of

(including GST)

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

LIST OF ANNEXURES & FORMS

CHECKLIST FOR PASSING THE BILLS

For the month of :

1) Work Order / P.O. No. & :

2) Nature of work :

3) Duration of Work Order : From to

4) Maxi. No. of manpower per day : M F Total

deployed in the month.

5) Details of Labour License : Valid up to for

6) Details of E.C Policy : Valid up to for

7) Documents attached for verification : Wage & Attendance Sheets.

for the previous month. Yes/No

P.F Challan Yes/No

8) Documents attached for verification : Bonus Payment Register

(in case of Final Bill) Yes/No

: Leave wage register Yes/No

9) Security Deposit / Retention Money : Yes / No if yes, Rs.

Date: Signature of Contractor

with official stamp

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

PROFORMA FOR CONTRACT SECURITY-CUM-PERFORMANCE GUARANTEE BY

SELLER / CONTRACTOR

(To be executed on non-judicial stamped paper of approximate value)

1. WHEREAS Gujarat Industries Power Company Limited having its office at PO: RANOLI, Dist.

Vadodara – 391 350, Gujarat State, India (hereinafter referred to as “The Company/Owner”

w h i c h expressions shall unless repugnant to the subject or context includes its legal

representatives, successors and assigns) has entered into a contract with M/s.

………………………………../ has placed a purchase order on

M/s………………………….(hereinafter referred to as “Contractor(s)/ Seller(s)” which

expression shall unless repugnant to the subject or context includes their legal

representatives, successors and assigns ) for …………………………….on the terms and

conditions as set out inter alia, in the Company‟s contract No./ P.O.No.…………..date

…………and various documents forming part thereof hereinafter referred to as the “said

contract” which expression include all amendments, modifications and/ or variations thereto

and where as the Contractor(s)/ Seller(s) has agreed for due execution of the entire contract

and guarantees its performance including any parts executed through any other agencies/

subcontractors AND WHEREAS one of the conditions of the “said contract” is that

“contractor(s)/seller(s) shall furnish to the owner a Bank Guarantee from a bank for ….%

(……….percent) of the total value of the “said contract” against due and faithful performance

of the “said contract” including performance guarantee obligations of the

contractor(s)/seller(s) for execution/ supplies made under the “said contract.”

2. We …………………………….Bank having its branch office at ……….……..do hereby agree

and undertake to pay the amount due and payable under this guarantee without any demur

merely on a demand from the Company stating that in the opinion of the Company, which is

final & binding, the amount claimed is due by reason of default made by the Contractor(s)/

Seller(s) in performing any of the terms & conditions of the said Contract including defect

liability obligations, in fulfilling the performance guarantee obligation or loss or damage

caused to or would be caused to or suffered by the Company by reason of any breach by the

said Contractor (s)/ Seller(s) of any of the terms & conditions of the contract. Any such

demand made on the Bank by the owner shall be conclusive as regards the amount due and

payable by the Bank under this guarantee. However our liability under this guarantee shall be

restricted to Rs. ……(Rupees………………………only).

3. We undertake to pay to the Company any money so demanded not withstanding any dispute

or disputes raised by the contractor(s)/ Seller(s) in any suit or proceeding pending before any

office, court or tribunal relating thereto our liability under this present guarantee being absolute

and unequivocal. The payment so made by us under this bond shall be a valid discharge of

our liability for payment there under. Our liability to pay is not dependent or conditional on the

owner proceeding against the Contractor(s)/ Seller(s).

4. The guarantee herein contained shall not be determined or affected or suspended by the

liquidation or winding up, dissolution or change of constitution or insolvency of the said

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit / any other locations and (B)

Pushing / Lifting of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other

miscellaneous works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

Contractor(s)/ Seller(s) but shall in all respect and for all purposes be binding and operative

until payment of all money due or liabilities under the said contract(s)/ Order(s) are fulfilled.

5. The Bank further unconditionally agrees with Gujarat Industries Power Company Limited

(GIPCL) that Gujarat Industries Power Company Limited (GIPCL) shall be at liberty, without

the Bank’s consent and without affecting in any manner the Bank’s obligation under this

Guarantee, from time to time, to:

a. Vary and / or modify any of the terms and conditions of the Agreement.

b. Extend and / or postpone the time for performance of the obligations of the Contractor

under the Agreement.

c. Forbear or enforce any of the rights exercisable by Gujarat Industries Power Company

Limited (GIPCL) against the Contractor under the terms and conditions of the Agreement.

6. This guarantee shall be in addition to and not in substitution or in derogation of any other

security held by Gujarat Industries Power Company Limited (GIPCL) to secure the

performance of the obligations of the Contractor under the Agreement.

7. No action, event or condition, which by any Applicable Law should operate to discharge the

Bank from liability hereunder, shall have any effect and the Bank hereby waives any right it

may have to apply such law, so that in all respects its liability hereunder shall be irrevocable

and, except as stated herein, unconditional in all respects.

8. This guarantee will remain valid up ____________________ days or ______________

whichever is earlier. The Bank undertakes not to revoke this guarantee during its currency

without previous consent of the OWNER/PURCHASER and further agrees that if this

guarantee is extended for a period as mutually agreed between bidder & owner/purchaser,

the guarantee shall be valid for a period so extended provided that a written request for such

extension is received before the expiry of validity of guarantee.

9. We ……………Bank further agree with the Company that the company shall have the fullest

liberty without our consent and without affecting in any manner our obligations hereunder to

vary any of the terms and conditions of the said Contract(s)/ Order(s) or to extend the time of

performance by the said Contractor(s) Seller(s) from time to time or to postpone for any time

or from time to time any of the powers exercisable by the Company against the said

Contractor(s)/ Seller(s) and to forbear or enforce any of the terms and conditions relating to

the said Contract(s)/ Order(s) and we shall not be relieved from our liability by reason of any

such variation, or extension being granted to the said Contractor (s) / Seller(s) or for any

forbearance, act or omission on the part of the Company or any indulgence by the Company

to the said Contractor(s)/ Seller(s) or by any such matter or thing whatsoever which under the

law relating to sureties would, but for this provision, have affect of so relieving us.

10. Notwithstanding anything contained herein before, our liability shall not exceed

Rs…………….(Rupees…………only) and shall remain in force till..……..Unless a demand or

claim under this Guarantee is made on us within three months from the date of expiry we shall

be discharged from all the liabilities under this guarantee.

Corporate Seal of the Bank Signature of duly Authorized person

By its constitutional Attorney On behalf of the Bank

With Seal & Signature code

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

PROFORMA FOR BANK GUARANTEE FOR EARNEST MONEY DEPOSIT

(To be executed on non-judicial stamped paper of appropriate value)

1. WHEREAS M/s.Gujarat Industries Power Company Limited having its

Corporate Office at PO: R A N O L I , Dist.Vadodara – 391 350, Gujarat State,

India (hereinafter called “The Company Owner” which expression shall

unless repugnant to the subject or context includes its legal representatives,

successors and assigns) has issued tender paper vide its Tender

---------- (hereinafter called “the said tender”) to M/s.

……………………………(hereinafter called the said Tenderer(s)” which

expression shall unless repugnant to the subject or context includes their legal

representatives, successors and assigns and as per terms and conditions of

the said tender, the tenderer shall submit a Bank Guarantee for

Rs.………. (Rupees……………..only) towards earnest money in lieu of cash.

2. We ……………………………..Bank having its branch office at

……… do hereby undertake to pay the amount due and payable under this

guarantee without any demur, merely on a demand from the Company stating

that in the opinion of the company which is final and binding, the amount

claimed is due because of any withdrawal of the tender or any material

alteration to the tender after the opening of the tender by way of any loss or

damage caused to or would be caused or suffered by the Company by reason

of any breach by the said tenderer(s) of any of the terms and conditions

contained in the said tender or failure to accept the letter of Intent

Agreement or that the amount covered under this Guarantee is forfeited.

Any such demand made on the Bank by the owner shall be conclusive as regards

the amount due and payable by the Bank under this guarantee, However, our

liability under this guarantee shall be restricted to an amount not exceeding

Rs………………..(Rupees………………..only).

3. We undertake to pay to the Company any money so demanded

notwithstanding any dispute or disputes raised by the tenderer (s) in any

suit or proceeding pending before any office, court or tribunal relating thereto

our liability under this present guarantee being absolute and unequivocal. The

payment so made by us under this bond shall be a valid discharge of our liability

for payment there under. Our liability to pay is not dependent or conditional

on the owner proceeding against the tenderer.

4. The guarantee herein contained shall not be determined or affected or

suspended by the liquidation or winding up, dissolution or change of

constitution or insolvency of the said tenderer(s) but shall in all respect and for all

purposes be binding and operative until payment of all money due or liabilities

under the said contract(s)/ Order(s) are fulfilled.

5. The Bank further unconditionally agrees with Gujarat Industries Power Company

Limited (GIPCL) that Gujarat Industries Power Company Limited (GIPCL) shall be

at liberty, without the Bank’s consent and without affecting in any manner the Bank’s

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

obligation under this Guarantee, from time to time, to:

a. Vary and / or modify any of the terms and conditions of the Agreement.

b. Extend and / or postpone the time for performance of the obligations of the

Contractor under the Agreement.

c. Forbear or enforce any of the rights exercisable by Gujarat Industries Power

Company Limited (GIPCL) against the Contractor under the terms and conditions of

6. This guarantee shall be in addition to and not in substitution or in derogation of any

other security held by Gujarat Industries Power Company Limited (GIPCL) to secure

the performance of the obligations of the Contractor under the Agreement.

7. No action, event or condition, which by any Applicable Law should operate to

discharge the Bank from liability hereunder, shall have any effect and the Bank

hereby waives any right it may have to apply such law, so that in all respects its liability

hereunder shall be irrevocable and, except as stated herein, unconditional in all

8. We ……………..Bank Ltd. further agree that the guarantee herein contained shall

remain in full force and effect during the period that would be taken for the

finalization of the said tender and that it shall continue to be enforceable till the said

tender is finally decided and order placed on the successful tenderer(s) and

or till all the dues of the company under or by virtue of the said tender have been

fully paid and its claims satisfied or discharged or till a duly authorized officer of the

company certifies that the terms and conditions of the said tender have been fully

and properly carried out by the said tenderer (s) and accordingly discharges the

9. That t h e O wn e r Company will have full liberty without reference to us and without

affecting this guarantee to postpone for any time or from time to time the exercise

of any of the power of the owner under the tender.

10. Notwithstanding anything contained herein before, our liability shall not exceed

Rs…………………. (Rupees…………………………only) and shall remain in force

till…………….. (Date to be filled up shall be 180 days from the date of submission

Bank Corporate Seal of

the Bank By its

constitutional Attorney

Signature of duly Authorized person

On behalf of the Bank

W ith Seal & Signature code

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

4.0 ANNEXURE – D

PROFORMA CERTIFICATE

(No claim, No arbitration)

Chief General Manager (Thermal)

Gujarat Industries Power Company Limited,

Surat Lignite Power Plant,

Village: Nani Naroli, Ta. Mangrol,

Dist. Surat – 394112 (Gujarat).

We hereby confirm with free consent as under:-

1. The measurements certified in final bill are full and final. We accept all the certified

measurements and no claim related to the measurement is left.

2. The payment certified in that or above referred LoI / contract is full and final. We accept

this, and no claim related to payment is left.

3. The rates of the LoI / contract and its amendments are firm till completion of contract and

extension period. We shall not claim any escalation against these rates.

4. Along with the contract referred, the ARBITRATION CLAUSE also perishes i.e. we will not

resort to arbitration.

5. No extra items are left to be settled.

6. We do not have any claims against any item related to the LoI than those items certified

7. We are accepting the recoveries or hold amount from our bills, if any, made by GIPCL

against non compliance or as decided by GIPCL within terms & conditions of contract.

8. We have paid royalties, taxes for all the materials procured by us, for carrying out the

works for above LoI and we indemnify GIPCL from any liability arising thereof.

9. In case of any disputes arising in future related to payment of royalties, all liabilities of

settlement of dispute and its payment if any, will be borne by us.

10. We have paid wages to all the workmen who were deployed by us for carrying out above

referred work as per prevailing Minimum wages act. We have also fulfilled all requirements

of the P.F. Act. We have maintained all records necessary as per the statutory

requirements. We hereby indemnify GIPCL from any disputes arising in future related to

payment of labours, Provident Fund, etc. and confirm that all liabilities of settlements of

disputes and their payment is our responsibility.

The above confirmation will come into effect as soon as payment from final bill after due

recoveries will be received by us.

Signature, Stamp and date

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

5.0 ANNEXURE – E

Schedule of Deviation from Technical Specification and Commercial Terms and

All the deviations from the terms & conditions of contract shall be filled by BIDDER

clause by clause in this schedule.

Sr. No SECTION TENDER DEVIATION

The bidder here by certifies that the above mentioned are the only deviations from OWNER’s

Tender enquiry. The bidder further confirms that in the events any other data and information

presented in the BIDDER’s proposal and accompanying documents are at variance with

specific requirements laid out in the OWNER’s Tender Document, then the latter shall govern

and will be binding on the BIDDER for quoted price.

SIGNATURE …………………

DESIGNATION ……………..

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

6.0 ANNEXURE – F

Declaration cum Undertaking for Safety Laws and Regulations Compliance

(To be submitted on Company’s Letter Head)

I ______________________ on behalf of ………Name of Party/Company………..hereby

confirm, agree and undertake that all the Statutory and Safety Laws and Regulations of the

applicable Authority/ies shall be strictly followed for all types of works at the site during the period

of the Contract, if awarded to me.

Signed and Stamped by the

Authorized Signatory of the Bidder

Declaration for Contractual Litigations

(To be submitted on Company’s Letter Head)

Please Tick (√) whichever is correct option

I ______________________ on behalf of ………Name of Party/Company………..hereby confirm

that I /We have

a. Not invoked legal recourse e.g. litigation against any Govt, of Gujarat Undertakings

/ Depts. / Authorities and Govt. of Gujarat supported companies / undertakings /

organizations for the last three ( 03) years. There are no ongoing/pending legal

matter(s) with any of the Govt. of Gujarat Undertakings / GoG supported

Companies, including GIPCL.

Please Tick ( )

b. Invoked legal recourse e.g. litigation against any Govt, of Gujarat Undertakings

/Depts. / Authorities and Govt. of Gujarat supported companies / undertakings

/organizations for the last three (03) years.

Please Tick ( )

If “b” is applicable, please submit the details for the same.

The above is true, as on date, to the best of my knowledge. Any breach/ false statement in this

regard shall amount to disqualification of the Bid being submitted herein.

Signed and Stamped by the

Authorized Signatory of the Bidder

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

PARTICULARS OF THE BIDDER

Sr. No. Particulars Please provide information here.

1. Name of Bidder

2. a. Registered Office Address:

b. Address for Correspondence:

3. Contact Details:

Contact Person Name

Telephone No. :

Year of establishment

COMPANY SEAL SIGNATURE …………………

DESIGNATION ……………..

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

PROCEDURE FOR MAKING ONLINE PAYMENT OF EMD/SD/TENDER FEE

1. For making online payment, first go to the website: www.gipcl.com

2. Then, click on the caption/link as can see like:

“Click here for Making Online Payment of EMD/SD, Advance for Ash, DM water

(The link is visible as horizontal highlighted below Tenders - News & Update Section. Can be

seen in below screenshot)

3. After clicking the link the new page will open. On this page, No need to enter User Name

and Password. Directly click on “Payment Form” given below the sign in option.

4. After clicking the “Payment Form”, the vendor has to enter the details asked which will be

self explanatory. It is desired that all the information may be filled correctly so that the

payment made can be tracked.

If the some required fields are not known/available, vendor may write “Not Available” and then

proceed. E.g. some information like Party code is not available to vendor or GST No. not

available with vendor.

Optional Note: Although mentioned as above can be proceeded with “Not available”, It will

be appreciated that regular vendors may obtain the party code from Materials Dept. or

Concerned Person, so that the vendor can be identified. The same party code may be used

for future transactions also.

After entering the details, click on SUBMIT Button.

5. The vendor/Party will be redirected to Payment Gateway. By selecting the desired payment

mode, payment can be made:

6. After making the payment, the receipt will be generated which has to be shared with

Concerned Person of GIPCL.

Important Note: Please note that for making online payment through the above gateway, the

charges* as below will be applicable, which has to be borne by Vendor/Party making the

Payment Mode Charges

Net Banking Rs.9 + GST

Credit Card 0.75% + GST

International 3.00% + GST

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

10.0 ANNEXURE-J

CERTIFICATE OF COMPLIANCE BY CONTRACTOR

(To be submitted with each monthly bill on letter head along with labour compliance records)

of.........................to.......................... at Gujarat Industries Power Company Limited –

Surat Lignite Power Plant, Nani Naroli. I undertake to be bound by all the provisions of

the Contract Labour (Regulation & Abolition) Act 1970 and the Contract Labour

(Regulation & Abolition) Rules 1972, The Employees’ Provident Funds and

Miscellaneous Provisions Act 1952, Minimum Wages Act 1948, Payment of Wages Act

1936 and Payment of Bonus Act 1965 and all other applicable labour laws in so far as

the provisions are applicable to me in respect of the employment of contract labour by

Authorized Signature with Stamp

Place: Nani Naroli

Tender Document for Biennial Rate Contract for Hiring of Dozer of D-80 Model or equivalent for: (A) Dozing /

Compacting / Leveling of Ash and other works at pre-designated locations of Mines pit and (B) Pushing / Lifting

of Lignite, Limestone, Lignite stock pile compaction at in-plant and ELHS stock pile area & other miscellaneous

works at GIPCL - SLPP [Tender Ref. No. SLPP/AHS/BRC/Dozer/2027-29]

11.0 ANNEXURE – K

GUJARAT INDUSTRIES POWER COMPANY LIMITED

PO : RANOLI, DIST : BARODA –

Reference PO No. Date:

Integrity Pact No.: Contract Period:

To create an environment where Business Confidence is built through best business practices

and is fostered in an atmosphere of trust and respect between providers of goods and services

and their users for the benefit of stakeholder, society and the nation.

GIPCL’S COMMITMENT PARTY’S COMMITMENT

Not to bring pressure / recommendation

To maintain the highest ethical standards in

from outside GIPCL to influence its

business and professions

Not to use intimidation, threat, inducement

To ensure maximum transparency to the

or pressure of any kind on GIPCL or any

satisfaction of all stakeholders.

of it's employees.

To fulfill the terms of agreement / contract To be prompt and reasonable in fulfilling

and to consider objectively the viewpoints of the contract, agreement and legal

other stakeholders. obligations.

To ensure regular and timely release of To provide goods and / or services timely

payments for works done/services provided as per agreed quality and specifications.

To ensure that no improper demand is made To maintain the general discipline in our

by employees or by anyone on our behalf. dealings and transactions.

To give maximum possible assistance to all

the Vendors / Suppliers / Service Provider To be truthful and honest in furnishing

and others to enable them to complete the information.

Not to divulge to others any information,

To provide all necessary information to

business details about GIPCL made

suppliers /contractors relating to contract /

available during the course of business

job to facilitate them to complete the

relationship without the written consent of

contract / job successfully in time.

To ensure that no hurdles are caused to Not to enter into cartel / understanding

vendors / suppliers / contractors in whether formal or informal so as to

execution of agreement / contract / work. influence the price.

Seal & Signature Seal & Signature

(GIPCL’s Authorized signatory) (Party’s Authorized signatory)

Designation : Designation: