Work of replacement / repairing / fabrication of Single / Double / Fourfold expansion bellows of air/flue gas in Unit 3, 4 & 5 at GTPS during AOH/COH.

Date of opening of online Technical Bid, all

relevant documents submitted through online

process, Cover for Tender fee and EMD at 15:30

As per Tender Notice

Hrs (Online technical bid will be opened for

Bidders who have submitted Cover for Tender Fee

Tentative date of on-line opening of price bid (if Party has to be in touch with

possible) at 15.30 hrs. website

https://tender.nprocure.com

and also with e-mail sent by

EW- 313 PUR-F-006 RFQ-

Important Notes to Bidders:

(1) All the online Annexure and price bid, other tender documents (As per PQC)

must be submitted/attached through online form only. Bidder has to upload

scanned copies of original documents (Notarized / self-attested copies of original –

as specified in tender document) with bid. No physical documents to be submitted

(2) Payment of Tender Fee /Earnest Money Deposit (EMD):

All the bidders will be required to pay Tender Fee & EMD as mentioned in the

Tender Document either in Demand Draft, Pay Order or Bank Guarantee (only for

EMD) in favour of Gujarat State Electricity Corporation Limited payable at

Gandhinagar, Gujarat. The scanned copy of original document shall have to be

uploaded online with the bid and RPAD or Speed Post only addressed to The Chief

Engineer (G), Gujarat State Electricity Corporation Limited, Thermal Power

Station, Gandhinagar-382041.

(3) Being three part Bid, bidder shall have to submit their tender in three stages i.e.

PRILIMINARY STAGE (EMD Details- scan copy(online) & Original document- Hard

Copy submission), TECHNICAL STAGE (on line submission only) and COMMERCIAL

STAGE (on line submission only).

 First preliminary stage will be opened and if the documents submitted by bidder

towards payment of Tender Fee & EMD are found ok, then only Technical Bid will

be opened (On-line). Tenders submitted without Tender Fee & EMD by the firms,

will be rejected without entering into further correspondence. Submission of

required documents for exemption of EMD is mandatory.

 The exemption in payment of EMD shall be given to the,

1. Micro & small-scale enterprises which participate directly in tendering

process for the product which they are manufacturing / service which they

are providing and have Udyam registration for items / service under

2. Start-ups which participate directly in tendering process for the product

which they are manufacturing/service which they are providing and re-

cognized by DPIIT under the Start-up India Program and has obtained Udyam

3. Organization which has registration certificate for the manufacturing product

of the tender, from Gujarat Khadi Gramodyog Board or Khadi and Village

Industries Commission(K.V.I.C)or Commissioner of Cottage Industries.

4. Board/Corporations/PSUs of the Central/State Government for their own

manufactured items.

5. State Government recognized organizations like(i) organizations for blinds,

dumb and deaf, disabled, mentally disabled persons;(ii)women's self-help

group recognized by Gujarat Livelihood Promotion Company; which

participate directly in tendering process for the product which they are

manufacturing / service which /they are providing.

6. OEM and service providers rendering services directly or by its own and

having annual turnover of INR 500 Crore or more

7. Sellers/Service Providers holding BIS license for the Primary Product Category

whose credentials are validated through BIS database

1. Micro & Small Enterprises (MSEs) who participates directly in the tendering

process as Manufacturers or Service Providers, and holds a valid Udyam

Registration, are eligible for exemption from payment of Earnest Money

EW- 313 PUR-F-006 RFQ-

2. Agencies registered under Udyam in the capacity of Traders, Re-sellers, or

similar categories (i.e. other than Manufacturers/Service Providers) are not

eligible for EMD exemption.

3. Migration period for Reclassification of MSMEs: - ln case of an upward change

in terms of investment in plant and machinery or equipment or turnover or

both, and consequent re-classification, an enterprise shall continue to avail of

all non-tax benefits of the category (micro or small or medium) it was in before

the re-classification, for a period of three years from the date of such upward

 Vendor Registration with GSECL is not compulsory for submitting this tender.

(4) If any Bank Guarantee submitted against EMD/security deposit/PBG, same should

be valid one year from the date of expiry of BG. Bank Guarantee should be

confirmed through Structured Financial Messaging system (SFMS). SFMS allows

intra/interbank message transfer system of banking. Our bank details are as under.

ACCOUNT NAME GSECL

BANK NAME & BRANCH BOB, SECTOR-21, GANDHINAGAR

IFSC CODE BARB0GANDHI

(5) The tender received after time and date specified in the tender notice will not

be accepted. Once the offer Submitted by the Contractor before due date of

submission, the Contractor will not be allowed to submit revised/

additional/Modified/other after opening of bid. Any alterations/ modification to

the bids received after submission of offer shall not be considered unless carried for

by the Corporation in negotiation.

(6) Any deviation found in Data / Details / Documents between on line offer (e-

tendering) and physically submitted documents (Tender document fee, Technical

offer of the bidder) offer of the same bidder will not be considered and no any further

communication in the matter will be entertained.

Further bidders are requested to submit price – bid (Part-II) on-line only and not to

submit the price bid in physical form. This is mandatory. If price bid is submitted in

physical form, same will not be opened and only on-line submitted price bid will be

considered for evaluation. Further if the quantity quoted differs in the any of the

technical bid forms and in price bid forms, it is discretion of CE Committee –GSECL

to consider the quoted quantity.

(7) PLEASE MENTION:

(a) EPF Code No.: _________________ (The contractor shall have to submit in online

the attested copy of EPF code certificate issued by RPFC without fail otherwise

tender will not be considered )

(c) GSTIN Registration No. : _____________________________________ ( For Works &

(8) In case short submission of documents with bid and / or clarification if any required

from the bidder, The required details / documents may be asked from bidder.

(9) It shall be sole responsibility of the bidder that the uploaded scanned documents (in

PDF form) Remain legible and should not be password protected

(10) Tender will be evaluated on basis of Data / Details / Documents submitted by

online form only.

(11) It is mandatory for all the bidders to upload their tender documents by on line only

(E-tendering) in scheduled time. No documents shall be considered physically

which are mentioned for on-line submission only.

EW- 313 PUR-F-006 RFQ-

(12) The bidders are required to fill up all the online annexure / forms and shall be

uploaded invariably. This is intended for transparency and speedy evaluation of the

bids. Instead of simply confirming / attached in bid / refer physical offer, the Bidder

shall fill in the particulars against appropriate place in respect of each line

appearing in each online annexure. Wherever required, bidder shall invariably have

to upload supporting authentic documents in the online bid. (In the absence of

required details in the online annexure, the purchaser has every right to evaluate

the bids accordingly and bidder cannot raise any objection against any point during

(13) Bidders are requested to remain in touch with the web-site for any amendment /

corrigendum or extension of due date etc

(14) EMD Fee Demand Draft with different purchaser or agency shall not be accepted.

Tender without EMD shall be rejected.

(15) The GSECL reserves the right to award the work to one or more bidders, considering

their technical and financial capacity OR to reject any or all tenders or accept any

tender without assigning any reason thereof.

(16) Once the offer Submitted by the Contractor before due date of submission, the

Contractor will not be allowed to submit revised/ additional/Modified/other after

opening of bid. Any alterations/ modification to the bids received after submission of

offer shall not be considered unless carried for by the Corporation in negotiation

(17) GSECL reserves the rights to reject any OR all tenders without assigning any

reasons thereof.

(18) Vendor get to register in VMS System through vms.guvnl.com. For registration

following documents are required and mail to [email protected] and

[email protected]. After registration vendor have to upload the invoice in the VMS

system for smooth functioning of payment.

Documents required for Registration:

(2) GST Certificate Copy

(4) Full Name of Vendor

Site : vms.guvnl.com

Username : PAN (PAN number)

Password : MyInvoice@123

Chief Engineer (G)

GSECL: Gandhinagar TPS

Dated seal & signature of

Bidder/Contractor

EW- 313 PUR-F-006 RFQ-

BIDS FOR WORKS GENERAL CONDITONS

The tenderers should thoroughly read all the following clauses before submitting their

 online tender with Tender Fee & EMD Fee cover will be opened as per tender notice

date and time. and if the documents towards payment of Tender Fee & EMD are

found OK then only, offer of the bidder will be considered for further evaluation.

 EMD will be forfeited (i) if the tender, which it covers, is withdrawn during the validity

of the offer and (ii) the Tenderer fails to furnish / deposit the security deposit.

 “It shall be mandatory to submit security deposit within 10 days from the date of

issue of Letter of Intent before order placement. In case when successful bidder not at

all responding within notice period or withdraws his offer then his EMD shall be

forfeited and he will not be allowed to participate in the tenders invited from the same

office for the period of One year for that place from where tender is invited.”

1. TECHNICAL BID: (Online only not by physically)

1.1) The technical bid comprises scope and nature of works and quantity of works/jobs,

drawings (Refer Schedule-B), required technical qualification for execution of the

works/job etc. for which price are to be quoted. Also, all the technical details of the

stores/materials offered in accordance with the Corporation scope of work,

specification guaranteed technical particulars and conditions, etc

The supplier/contractor should mention separate HSN/SAC code and rate of GST

and cess as applicable for each item of goods/services. If no specifically mentioned

then company will have option to take the prices as exclusive of taxes and duties at

maximum higher slab rates for the evaluation of tenders.

1.2) The Technical Bid shall be opened as per Tender Notice (If possible).Please note that

the required documents should be invariably submitted in online only. If party has

not submitted tender in online is liable to be ignored.

1.3) Contractor has to submit all required documentary evidences thereof to qualify for

acceptance of their technical bid. The acquisition of the tender documents by any

party will not automatically qualify the party as to its capability to execute such or

similar orders. The Corporation shall assess the capability of the party at the time of

evaluation of the technical bids.

1.4) The submission of the offer by any contractor does not mean that the bidder is

qualified for execution of the works. After opening of the online technical bids, the

competent authority will evaluate on the basis of technical qualification criteria. If

contractor’s bid does not meet the technical qualification criteria, then his technical

bid will be ignored. Decision taken by the CE(G),GTPS will be binding to all in this

2.1) The price bid comprises Schedule-B, in which the tenderer has to offer their rates in

accordance with the technical specification specified in technical bid with all

commercial terms and condition. The Price Bid must be submitted strictly as per

Schedule-B and shall be submitted online only, not by physically.

Incomplete bids and amendments and additions to bids after opening of the bids will

be ignored out rightly.

The price bid of those who are techno-commercially qualified shall be opened. After

technical bid is opened, for modification, if any, all shall be given equal chance.

2.2) Price bids of technically acceptable tenders shall be opened after analyzed &scrutiny

of the technical bid.

2.3) The ‘TECHNICAL” and ‘PRICE” Bids shall contain adequate cross-reference wherever

necessary to ensure clear and proper co-relation of the two bids without ambiguities

whatsoever. Any technical questions information and clarifications that may be

required pertaining to this Tender should be referred to the Chief Engineer (Gen),

Gandhinagar, TPS-382041 reserves the right to reject any OR all tenders without

assigning any reasons thereof.

EW- 313 PUR-F-006 RFQ-

2.4) Bidders have to quote their rates online only as per GSECL’s given format of price

2.5) The offered prices to be indicated in online mode of tender in the format given (i.e.

Schedule-B) the price bid submitted in physical mode shall not be considered.

CONDITIONS FOR PRICE BID

a) For Works & Supply GST rate will be paid with the applicable GST rules.

b) For Supply Portion Only:-“Party shall have to quote their rates in Schedule “B” of

price bid only along with commercial terms and conditions. The details of applicable

GST, service charges, packing & forwarding charges, freight, insurance, F.O.R. etc.

The supplier/contractor should mention separate HSN/SAC code and rate of GST

and cess as applicable for each item of goods/services. If no specifically mentioned

then company will have option to take the prices as exclusive of taxes and duties at

maximum higher slab rates for the evaluation of tenders.

It is mandatory to indicate GST NO in annexure 10a of tech. bid otherwise if no

specifically mentioned then company will have option to take the prices as exclusive

of taxes and duties at maximum higher slab rates for the evaluation of tenders.

3. Applicability of Goods and Service Tax (GST):-

(a) The tenders shall be evaluated on firm price and cost with GST and cess as

applicable unless otherwise mentioned in the tender documents.

(b) If the supplier/contractor have opted for the composition scheme of GST, the

same must be clearly specified with valid declaration and certificate from

department. In the event of withdrawal/ cessation of the supplier from composition

scheme during the tenure of the contract, the rate(i. e. price) mentioned in the price

bid shall be final and any additional GST will have to be borne by the tenderer

himself, In no case additional amount towards GST or otherwise will be

paid/reimbursed to supplier/contractor.

(c) The bidder shall have to inform their GST no. of the registered place(s) where from

the bidder intends to supply the goods/services, meaning there by the bidder has to

supply the goods/services from the relevant declared/ registered place(s) of supply

(d) The bidder shall not include GST in their quoted rates; but the bidder has to

separately indicate the GST rate, amount in the price bid schedule.

(e) In-case Govt notification comes for change in GST , the same will be applicable.

(f) Bidder should indicate GST no.( copy of GST registration to be enclosed) and PAN

NO. (copy of PAN to be enclosed) Tenders submitted without GSTIN No by the

firms, the offer will be rejected without entering into further correspondence.

Chief Engineer (G)

GSECL: Gandhinagar TPS

Dated seal & signature of

Bidder/Contractor

EW- 313 PUR-F-006 RFQ-

Other Terms & Conditions

1. Contractor shall indemnify GSECL against for any injury and/or damage that may

be caused in his man or material. Moreover, the contractor shall be fully responsible

for any damage caused to the Corporation’s properties done by his man/materials

while executing the work. The Corporation will be entitled to recover the damage

from the party’s bill.

2. At any time if GSECL feels that progress of work is unsatisfactory and work force of

contractor is inadequate, other agencies/ departmental personnel will be put in

parallel for expediting the work. Amount so incurred will be recovered from the

contractor’s bill. In this case decision of the Engineer-in-charge shall be final and

binding to the contractor.

3. At any stage of the contract period, if the contractor fails to complete the job or his

work is not found satisfactory the same will be got done at his cost and risk and

additional expenditure incurred by the Corporation will be recovered from him by

giving one week's notice.

4. To sublet or transfer of contract without prior written approval of Corporation shall

be treated as breach of contract and it shall be punishable by forfeiting the S.D. as

well as termination of contract.

5. The Corporation reserves the right to forfeit the S.D. in case of any breach of

contract and in case of disputes. The decision of Chief Engineer (Gen), TPS

GANDHINAGAR shall be final, binding & acceptable to the Contractor. If contractor

fails to start the Work as Stipulated, the E.M.D. & S.D. Shall be forfeited.

6. Conditional tender will not be accepted. Withdrawal of tender condition

unilaterally by you before or after opening of tender will not be permitted.

7. The contractor has to carry out the required work strictly according to guidance

given by the Corporation's responsible officer.

8. The Corporation reserves the right whether the materials to be accepted, or not.

Only specified and scheduled materials are to be examined by Corporation's officer

and then if suitable will be accepted by the Corporation.

9. The contractor shall submit his bill in triplicate to the CE(G), GSECL, TPS,

Gandhinagar which will be paid after the certificate regarding correct receipt of the

materials in good condition.

10. The rates should be quoted without any condition. The rates be written in words and

7figures legibly.

11. Revision of prices or any commercial terms affecting the price after opening of

technical bids shall not be considered and will be ignored.

12. The contractor shall have to execute an agreement with the Corporation on a non

judicial stamp paper, the cost of which will have to be borne by the contractor and

will have to sign the contract and tender booklet of the Corporation.

13. SECURITY DEPOSIT: In tender process for L1 bidder(lowest bidder) security

deposit will be charged as per table below:

Category of the Unit Security Deposit

Works up to Rs. 5 Works More than Rs.

Enterprise or Exempted 3% of Order Value

Organization which are

exempted from paying

For all other Enterprises 5% of Order Value 5% of Order Value

Note: Security Deposit will be collected from the successful tenderer at the rates

mentioned above. This may be recovered by deduction through running bills of the

contractors and / or by treating the Earnest Money Deposit (Bid Security) paid at the time

of submission of the tender.

EW- 313 PUR-F-006 RFQ-

14. The Bank Guarantees will be executed on the standard form prescribed by the

corporation. In case of the Bank Guarantees furnished / submitted, they should

have clear one time validity till the completion of the order in all respects and up to

the expiry of Guarantee period from the date of the work completion. Bank

Guarantee for Interim period will not be allowed. If by any reasons the work period is

extended then contractor should undertake to renew the Bank Guarantee at least

one month before the expiry of the validity failing which GSECL will be at liberty to

encash the same.

“It shall be mandatory to submit security deposit as per above table within

days from the date of issue of Letter of Intent before order placement. In case

when successful bidder not at all responding within notice period or withdraws

his offer then his EMD shall be forfeited and he will not be allowed to

participate in the tenders invited from the same office for the period of One

year for that place from where tender is invited.”

If the Tenderer fails to pay the Security Deposit or defaults in execution

of the orders placed or if GSECL suffers any financial loss due to this, then

GSECL will be at liberty to adjust the amount from other orders of the same

firm or by encashing the Bank Guarantee.

All the costs of the stamp papers, other than required for payment is to be

made through SIDBI / ICICI by Board, are to be borne by you as per the Govt. of

India’s latest guidelines.

15. VALIDITES OF THE OFFERS:

The offers will have to be kept valid for a period of 180 days from the date of

opening of technical bids. In case of finalization of the tender is likely to be delayed,

the tenderers will be asked to extend the same without change in the prices or

any terms and conditions of the offer. If any change is made, original or during

the extended validity period, the offers will be liable for outright rejection without

entering into further correspondence in this regard and no reference will also be

16. If successful contractor fails to pay the required security deposit and does not come

forward to execute the work, the full value of EMD will be forfeited by the

17. Any terms and conditions mutually agreed to writing shall be for a part of the

18. Payment will be made as per GSECL’s rule.

19. The authorized officer/person of the Corporation will have the liberty to check the

material and work etc.

20. Regarding the quality and acceptance of the jobs the authorized officer's decision

will be binding and final and no dispute on this account will be entertained.

21. General terms and conditions of the Corporation for works contract will be made

applicable for this work also.

22. No material for the said work will be supplied by the GSECL except specified in

schedule thereof.

23. WORK COMPLETION PERIOD: The Tenderers will have to confirm work

completion period as specified in this tender. Delay in execution of order on

account of any other reason will be subject to penalty.

24. PBG (Applicable / Not Applicable) : “The supplier/contractor/party (i.e. tenderee)

has to give Bank Guarantee with validity period of additional 01 (one) month i.e.

more than actual Guarantee/Warranty period of 6/12/18/24/36/48/60 months

(depending upon product) to safeguard Company’s interest in case of any eventuality

happening on the last day of the Guarantee/Warrantee period after office hours of

the Bank or Bank holidays.”

25. PENALTY FOR LATE EXECUTION OF WORK: Any delay that may take place in

supply and / or erection, testing and commissioning activities beyond contractual

EW- 313 PUR-F-006 RFQ-

cutoff date / stipulated period in the order shall be subjected to penalty (not

liquidated damages) at the rate of ½% of the contract price / order price per week or

part thereof subject to a maximum of 10% of the total contract value / order value

(i.e. End cost including taxes & GST).

26. Statutory variations:-any statutory increase or decrease on the taxes and duties

subsequent to your offer if it takes place within the original contractual delivery date

will be to the company’s account subject to the claim being supported by

documentary evidence. However if any decrease takes place after the contractual

delivery date the advantage will have to be passed on the company

27. If the work is not done as per specification given by the GSECL in stipulated time in

all respects, the penalty will be levied as per GSECL's rules.

28. The GSECL shall have the right to make any changes, additions / deletions or

modifications in any terms / conditions of the tender and / or specifications as may

be deemed necessary by the GSECL at its sole discretion at any time before the due

date of opening of the tender.

29. Tenderer should furnish a list of orders for similar work executed by them indicating

the name of the party and their order reference to whom they have worked, to be

furnished in Annexure- 6. Failure to do this will result on contractor’s tender being

rejected without any reference.

30. GSECL does not accept the printed conditions of any Tenderer. It will be ignored

without any reference; hence tenderers should withdraw such printed conditions if

31. Tenders will be accepted only on or before due date and time of opening.

32. If technical deviations furnished by the Tenderer are not agreeable to the GSECL,

the offers may be ignored. However it will be solely at GSECL’s discretion to consider

the technical deviations OR not for considering the Tenderer. No correspondences of

the Tenderer after opening of the bid will be entertained in this matter.

33. The contractor will be responsible and liable for any damage to man and materials

during his work.

34. While execution of this job our plant and auxiliaries will be in running conditions.

Hence contractor has to take all precautions for safety etc. Safety belts etc. also to

be used wherever necessary while working.

35. GSECL reserve the right to terminate the contract if quantity shown in Schedule-B

is executed earlier.

36. All the terms and conditions specified in Industrial & safety laws are binding on the

37. Registration certificate under labor contract act will have to be obtained before

execution of contract.

38. The laborers shall be supplied for 8 hours a day, so contractors shall arrange

39. The following List of Annexures and Documents (available in this tender document)

should be invariably submitted along with the tender:

(i) Schedule–“A” Indicating the Description of work & quantities for the tender.

(ii) Schedule–“B” Price Bid to be submitted online ONLY”

(iii) Annexure-“A” - Technical Scope of Work

(iv) Form of Bankers undertaking Performa for E.M.D and S.D.

(v) Annexures – 1 TO

(vi) Certificate – “A”.

(vii) Document of Important Instructions.

All the above documents should be duly filled in, signed & stamped with company’s

seal should be submitted along with the Technical Bid in online only.

40. Please note that any additional conditions / deviations, if any, found in the

Commercial terms & conditions, then the Price Bids of such tenderers will not be

opened and no further correspondences in the matter will be allowed.

EW- 313 PUR-F-006 RFQ-

41. Tenderer should invariably fill up all the details of all the Annexure of this tender

document. This is mandatory. Also all the Annexures should be duly signed by

authorized signatories with their rubber stamp and along with Company’s Rubber

(Round) seal / stamp affixed on each paper.

42. All the tenderers must ensure that all the relevant documents / papers submitted

with the tender should be serially numbered, and properly documented. This must

43. All the above points should be complied by the Tenderers. If not, tenders are likely to

be ignored without making any further reference.

44. If participating bidder/agency have stake in one or more other agencies / bidder

who are participating in same tender and on account of submission of wrong

information / declaration in the tender / enquiry certificate – A, then the bidder will

be declared as disqualified automatically and EMD / SD will be forfeited. Further,

GSECL shall take stern action including stop dealing with their firms’

45. The CE(G),GSECL, Gandhinagar, reserves right to reject/accept any or all tenders

without assigning any reasons thereof and to split up the work between the parties

as the case may be.

46. Relationship of employee: - Every bidder should, at the time of submission of bid,

give a declaration as under.

“If in any bidder company/firm, the interest (i.e. Shareholding in company and share

in partnership firm) of any employee of the tendering Company or his/her relative as

defined in section 2(77) of the Company’s act. 2013 is 10% or more, the tendering

Company will not deal with such company/firm at all.

Tenderer therefore, must specifically disclose this fact in his technical bid. Non-

disclosure of such facts would immediately disqualify the tenderer for further

dealing with the tendering company.”

47. Conflict of interest among Bidders/Agents: A bidder shall not have conflict of

interest with other bidders. Such conflict of interest can lead to anti-competitive

practices to the detriment of Procuring Entity’s interests. The bidder found to have a

conflict of interest shall be disqualified. A bidder may be considered to have a

conflict of interest with one more parties in this bidding process, if:

a) they have proprietor/partner(s)/Director(s) in common; or

b) they receive or have received any direct or indirect subsidy/financial stake from

any of them; or

c) they have the same legal representative/agent for purposes of this bid; or

d) they have relationship with each other, directly or through common third

parties, that puts them in a position to have access to information about or

influence on the of bid of another bidder; or

e) Bidder participates in more than one bid in this bidding process. Participation

by a bidder in more than one Bid will result in the disqualification of all bids in

which the parties are involved. However, this does not limit the inclusion of the

components/sub-assembly/assemblies from one bidding manufacturer in more

f) in cases of agents quoting in offshore procurements, on behalf of their principal

manufacturers, one agent cannot represent two manufacturers or quote on their

behalf in a particular tender enquiry. One manufacturer can also authorize only

one agent/dealer. There can be only one bid from the following:

1. The principal manufacturer directly or through one Indian agent on his

2. Indian/foreign agent on behalf of only one principal.

g) a Bidder or any of its affiliates participated as a consultant in the preparation

of the design or technical specifications of the contract that is the subject of the

h) in case of a holding company having more than one independently

manufacturing units, or more than one unit having common business

EW- 313 PUR-F-006 RFQ-

ownership/management, only one unit should quote. Similar restrictions would

apply to closely related sister companies. Bidders must proactively declare such

sister/common business/ management units in same/similar line of business.

i) Bidder shall not act in contravention/violation to the provisions of

competition act, as amended from time to time. Every bidder should, at the

time of submission of bid, give a declaration, that bidder shall not have

conflict of interest with other bidders, as above

48. All bidders shall submit the details/documents in support of Technical Qualification

Requirements duly certified and verified for authenticity from Specified Third-Party

inspection Agency (TPIA) or Statutory Auditor of their Company or Practicing CA/CA

Firm along with a certificate regarding verification of authenticity of documents as per

the format placed at Annexur-1. All the documents submitted by the bidder in support

of the meeting Technical QR only shall be digitally signed by the Specified Third-Party

inspection Agency (TPIA) or Statutory Auditor of their Company or Practicing CA/CA

The verification and certification of authenticity of documents is acceptable from any of

1. M/s Competent inspectorate and Consultants Pvt. Ltd, Hyderabad, lndia.

2. M/s Gulf Lloyds industrial Service lndia Pvt. Ltd.-Ahmedabad.

3. M/s international Certifications Services.

4. M/s lntertek lndia Pvt. Ltd.

5. M/s SGS lndia Pvt. Ltd.

6. M/s Moody lnternational (lndia) Pvt. Ltd.

7. M/s TUV SUD South Asia (P) Ltd.

8. M/s TUV Rheinland (lndia) Pvt. Ltd.

9. M/s Bureau Veritas (lndia) Pvt. Ltd.

10. Hertz lnspection & Services Pvt. Ltd.

11. IRCLASS Syslems and Solutions Pvt. Ltd.

Verification for authenticity shall not be applicable in following cases.

1: Bidders having proven track record or regular suppliers/contractors (i.e.

2: Past order copies of GSECL as these documents can be verified internally.

Bidders shall be responsible for getting their documents/ credentials verified &

certified by the Specified Third-Party inspection Agency (TPIA) or Statutory Auditor of

their Company or Practicing CA/CA Firm in support of Technical QR. All the costs

pertaining to third party verification and certification (including those by statutory

auditors) shall be borne by the Bidder. GSECL shall have no liability (financial or

otherwise) towards the same and shall not be liable for any claim/ dispute between

the bidder and the Specified Third-Party inspection Agency (TPIA) or Statutory

Auditor of their Company or Practicing CA/CA Firm

Chief Engineer (G)

GSECL: Gandhinagar TPS

I/ We hereby agree for the terms & conditions laid down in Tender.

Contractor's Signature

With Seal & Date

EW- 313 PUR-F-006 RFQ-

Undertaking from Third Party Inspection Agency/Statutory Auditor or Practicing

(On letter head digitally signed by a person duly authorized to Sign on behalf of the firm)

Gandhinagar TPS.

Subject: Authentication of veracity of documents submitted by M/s …….. in support of

Meeting the Qualifying Requirements

Ref : Tender no.: ________________

M/s._______________________________________________(hereinafter called Bidder) having

Registered office at_____________________intend to participate in above referred tender of

The tender condition stipulates that the bidder shall submit supporting Documents

pertaining to Qualifying Requirement duly verified and certified by Third-Party

Inspection Agency (TPIA) or Statutory Auditor of their Company or Practicing CA/CA

Firm as per the list mentioned in the bidding documents.

In this regard, it is hereby confirmed that we have examined the following documents,

which are also attached with this letter. The same has been verified from the Original

Documents and / or Client for authenticity.

We hereby confirm that the following documents are found to be genuine and authentic.

1. Doc ref. no. _________________________ dated______________ (name of Documents)

2. Doc ref. no. _________________________ dated ______________ (name of Documents)

All the aforesaid documents have been digitally signed by us as a certificate of

We further confirm that we neither have any vested interest in aforesaid tender nor have

any conflict of interest in respect of above tender.

This certificate is issued at the request of M/s._____________________________ (Bidder) for

the purpose of participating in the subject tender/s.

EW- 313 PUR-F-006 RFQ-

General Terms & Conditions

1. Contractor shall indemnify GSECL against for any injury and/or damage that may

be caused in his man or material. Moreover, the contractor shall be fully

responsible for any damage caused to the Corporation’s properties done by his

man/materials while executing the work. The Corporation will be entitled to recover

the damage from the party’s bill.

2. At any time if GSECL feels that progress of work is unsatisfactory and work force of

contractor is inadequate, other agencies/ departmental personnel will be put in

parallel for expediting the work. Amount so incurred will be recovered from the

contractor’s bill. In this case decision of the Engineer-in-charge shall be final and

binding to the contractor. At any stage of the contract period, if the contractor fails

to complete the job or his work is not found satisfactory the same will be got done

at his cost and risk and additional expenditure incurred by the Corporation will be

recovered from him by giving one week's notice.

3. Subletting the contract to other agency is not permitted unless and otherwise

approved by the competent authority.

4. The contractor has to carry out the required work strictly according to guidance

given by the Corporation's responsible officer.

5. The Corporation reserves the right whether the materials to be accepted, or not.

Only specified and scheduled materials are to be examined by Corporation's officer

and then if suitable will be accepted by the Corporation.

6. The contractor shall submit his bill in triplicate to the CE(G), GSECL, TPS,

Gandhinagar which will be paid after the certificate regarding correct receipt of the

materials in good condition.

7. Any terms and conditions mutually agreed to writing shall be for a part of the

8. The authorized officer/person of the Corporation will have the liberty to check the

material and work etc.

9. Regarding the quality and acceptance of the jobs the authorized officer's decision

will be binding and final and no dispute on this account will be entertained.

10. General terms and conditions of the Corporation for works contract will be made

applicable for this work also. The booklet is attached herewith.

11. No material for the said work will be supplied by the Corporation except specified in

schedule thereof.

12. Penalty :-If the work is not done as per specification given by the Corporation in

stipulated time in all respects, the penalty will be levied as per Corporation's rules.

Any delay that may take place in supply and / or erection, testing and

commissioning activities beyond contractual cutoff date / stipulated period in the

order shall be subjected to penalty (not liquidated damages) at the rate ½ % of the

contract price / order price per week or part thereof subjected to a maximum of

10% of the total contract value/ order value (i.e. End cost including GST)

13. Statutory variations:-any statutory increase or decrease on the taxes and duties

subsequent to your offer if it takes place within the original contractual delivery

date will be to the company’s account subject to the claim being supported by

documentary evidence. However if any decrease takes place after the contractual

delivery date the advantage will have to be passed on the company.

14. The contractor will be responsible and liable for any damage to man and materials

during his work.

15. While execution of this job our plant and auxiliaries will be in running conditions.

Hence contractor has to take all precautions for safety etc. Safety belts etc. also to

be used wherever necessary while working.

16. Corporation reserve the right to terminate the contract if quantity shown in

Schedule-B is executed earlier.

EW- 313 PUR-F-006 RFQ-

17. All the terms and conditions specified in Industrial & safety laws are binding on the

18. Registration certificate under labor contract act will have to be obtained before

execution of contract

19. The laborers shall be supplied for 8 hours a day, so contractors shall arrange

20. Payment Terms: Party has to accept payment terms as per GSECL rules only i.e. as

per actual work done. NO ADVANCE payment will be allowed. Net Payment will be

released within 30 days after completion of work and submitting their relevant

21. Dispute Resolution Mechanism: For works contracts and composite Contracts, the

arbitration mechanism shall be governed by the Gujarat Public Works Contracts

Disputes Arbitration Tribunal Act, 1992 as per below details.

(1) Amicable Settlement : "Any dispute, difference, controversy or claim between the

parties arising out of or relating to this contract with reference to the

construction, interpretation, breach, termination or validity thereof (herein after

referred as "the Dispute") shall, upon the written request of either party by

referred to the authorized representatives of the Disputing Parties for resolution.

The authorized representatives shall promptly meet and attempt to negotiate in

good faith a resolution of the Dispute within thirty days of the service of the

(2) Arbitration: If the Parties fail to amicably resolve the disputes or differences or

contrary claims as indicated herewith in sub clause (1) of Clause 21 arising under

or in connection with the present works contracts, whether pertaining to works

contracts alone or works and procurement both, the same shall be referred to

arbitration under the Gujarat Public Works Contracts Disputes Arbitration

Tribunal Act, 1992."

22. For procedure for health check-up accordingly bill shall be reimbursed once during

total contract period (for as & when and AOH/COH contract) maximum up to

Rs.1000 or actual cost per worker/ labour /person, whichever is minimum after

verification & recommendation by concern doctor. In case any worker left the work

in between than for replacement Worker Company will not provide any

reimbursement, however it is compulsory to submit new report of replacement

worker for fitness certificate at contractor’s own expense.

23. For Periodic Medical examination, No reimbursement for periodic medical

examination to be given to contract employee for whom GSECL are conducting

Periodic Medical examination at company’s cost at GTPS. If a contractor fails to

undergo periodic medical examination, they have to undergo prescribed

investigation as per hazard analysis from outside, No reimbursement to be given for

these investigations.

Chief Engineer (G)

GSECL: Gandhinagar TPS

I/ We hereby agree for the terms & conditions laid down in Tender.

Contractor's Signature

With Seal & Date

EW- 313 PUR-F-006 RFQ-

BID - QUALIFICATION CRITERIA FOR TECHNICAL BID

Work of replacement / repairing / fabrication of Single / Double / Triple /

Sub: Fourfold expansion bellows of air/flue gas duct in Unit # 3, 4 & 5 at GTPS

during AOH/COH.

Pre-Qualification Criteria (PQC) (To be submitted with Technical Bid):-

The bidders are requested to submit the technical bid with the following credentials

for technically qualifying criteria in soft ONLY.

Technical Bid Qualifying Criteria regarding

1 Evidence of having successfully executed work order or completed

work order of similar type of work carried out satisfactorily at Thermal

Power Stations having Unit of Minimum Capacity of 70 MW for

minimum one year in last seven (07) years period in

GSECL/NTPC/other SEBs/ Corporation / Company having as per

below (a) or (b) or (c)

a) Three similar completed works costing not less than the amount

equal to 8,96,592 of the estimated cost.

b) Two similar completed works costing not less than the amount

equal to 11,20,740 of the estimated cost.

c) One similar completed work costing not less than the amount

equal to 17,93,184 of the estimated cost.

Same / similar works means “various Replacement / Repairing of

Single / Double / Triple / Four Fold expansion bellows of Air/Flue

Gas duct of Plant Capacity 70 MW & above at GSECL or NTPC or

other SEB’s or any private power plant during AOH/COH of last

Note: All bidders shall submit the details/documents in support of

Technical Qualification Requirements duly certified and verified for

authenticity from Specified Third-Party inspection Agency (TPIA) or

Statutory Auditor of their Company or Practicing CA,/CA Firm along

with a certificate regarding verification of authenticity of documents

as per the format placed at Annexur-1. All the documents submitted

by the bidder in support of the meeting Technical QR only shall be

digitally signed by the Specified Third-Party inspection Agency

(TPIA) or Statutory Auditor of their Company or Practicing CA/CA

EW- 313 PUR-F-006 RFQ-

2 Financial qualification criteria:

1) The Average Annual Turnover of the bidder shall not be

less than Rs 6.72 Lakh during the preceding three (3)

financial years as one date of Techno-Commercial bid

2) Net worth of bidder shall not be less than 100% of the

bidder’s paid up share capital as on the last day of the

preceding financial year. In case the Bidder meets the

requirement of Net worth based on the strength of its

Subsidiary(ies) and/or Holding company and/or

Subsidiaries of its Holding Companies wherever

applicable, the Net worth of the Bidder and its Subsidiary

(ies) and/or Holding company and/or Subsidiary (ies) of the

Holding Company, in combined manner should not be less

than 100% of their total paid up share capital. However

individually, their Net worth should not be less than 75% of

their respective paid share capitals.

Net worth in combined manner shall be calculated as

Net worth (combined )= (x1+x2+X3)/(y1+y2+y3) X

where x1,x2, x3 are individual net worth which shall not be

less than 75 % of the respective paid up share capitals

and y1, y2, y3 are individual paid up share capitals.

3) In case the bidder is not able to furnish its audited financial

statements on stand-alone entity basis, the unaudited

unconsolidated financial statements of the bidder can be

considered acceptable provided the bidder further

furnishes the following documents for substantiation of its

 Copies of the unaudited unconsolidated financial

statements of the bidder along with copies of the

Audited consolidated financial statements of its

Holding Company.

 A Certificate from the CEO/CFO of the Holding

Company, stating that the unaudited unconsolidated

financial statements form part of the Consolidated

Annual Report of the company.

4) In cases where audited results for the last preceding

financial year as on the date of techno-commercial bid

opening are not available, the financial results certified by

EW- 313 PUR-F-006 RFQ-

a practicing Chartered Accountant shall be considered

acceptable. In case, Bidder is not able to submit the

Certificate from practicing Chartered Accountant certifying

its financial parameters, the audited results of three

consecutive financial years preceding the last financial

year shall be considered for evaluating the financial

parameters. Further, a Certificate would be required from

the CEO/CFO, stating that the financial results of the

Company are under audit as on the date of Techno-

commercial bid opening and the Certificate from the

practicing Chartered Accountant certifying the financial

parameters is not available.

5) The bidder must submit Average Annual Turnover and Net

worth Certificate in support of Financial QR, duly certified

and verified for authenticity from Independent Statutory

Auditor of their company / Practicing Charted Accountant/

C.A. Firms / TPIA (Third-Party Inspection Agency )

empaneled approved by GSECL along with copy of Annual

Audited Accounts of last three years.

Note for point No.1, 2, 3 &4:

i. Other income shall not be considered for arriving at

annual turnover.

ii. “Holding Company" and “Subsidiary Company” shall have

the meaning ascribed to them as per Companies Act of

India, in vogue.

iii. Net worth means the sum total of the paid up share

capital and free reserves. Free reserve means all

reserves credited out of the profits and share premium

account but does not include reserves credited out of the

revaluation of the assets, write back of depreciation

provision and amalgamation. Further, any debit balance

of Profit and Loss account and miscellaneous expenses

to the extent not adjusted or written off, if any, shall be

reduced from reserves and surplus.

3 Other requirements:

1. List of tools & tackles and technical personnel & name of

2. Details of PF code number from appropriate authority

3. Details of registered partnership deed, in case of partnership

firm and activities of association and memorandum of

EW- 313 PUR-F-006 RFQ-

association, in case of company.

4. The tender shall be opened of only those bidders who have

paid Tender fee & EMD.

5. Conditional tender will not be acceptable. Withdrawal or

insertion of conditions unilaterally after opening of tenders

will not be permitted unless it so desired by the GSECL.

6. Copy of PAN No.

7. Copy of valid GST Reg. No.

8. Copy of contract labour license from the appropriate

authorities duly obtained and renewed for the entire contract

period which is submitted after receipt of LOI if applicable.

9. Copy of group insurance of all contractor labour duly

engaged throughout the contract period which is submitted

after receipt of LOI.

1. The Chief Engineer (Gen.), GSECL, GTPS reserve right to reject any tender or all tenders

without assigning any reason thereof and to split up the work between more than one party as

the case may be.

2. Non-compliance of above criteria the technical bid is liable to be rejected. After

acceptance of the Technical Bid, the Price Bid will be considered for opening.

Chief Engineer (G)

GSECL: Gandhinagar TPS

Dated seal & signature of

Bidder/Contractor

EW- 313 PUR-F-006 RFQ-

Sr. Details Confirmation

No. (Tick √ any one)

1 Annexure – 2 YES / NO

2 Firm’s details as per “Annexure –3” YES / NO

3 Copy of the un-priced schedule (Description and YES / NO

price). “Annexure - 4”.

4 Work Completion Period as per “Annexure- 5” YES / NO

5 Past experience details as per “Annexure-6” YES / NO

6 Performance certificates as per “Annexure-7” YES / NO

7 ANNEXURE – 8 YES / NO

8 ANNEXURE – 9 YES / NO

9 ANNEXURE – 10 YES / NO

10 ANNEXURE – 11 YES / NO

11 ANNEXURE – 12 YES / NO

12 Certificate of Important Instruction & certificate-A YES / NO

13 INTEGRITY PACT YES / NO

14 Schedule-“A” & Annexure-“A” (GSECL’s work/ Scope YES / NO

of work to be carried out by contractor specified duly

signed and with seal of firm.)

I / WE, confirm that following documents are attached with the technical bid of

Signature of the Tenderer

Seal of the Firm

NOTE: ALL THE DOCUMENTS SHOULD BE PROPERLY FILED AND SHOULD BE

GIVEN FLAG MARKING FOR IDENTIFICATION.

EW- 313 PUR-F-006 RFQ-

Subject:. Work of replacement / repairing / fabrication of Single / Double / Triple / Fourfold

expansion bellows of air/flue gas duct in Unit # 3, 4 & 5 at GTPS during AOH/COH.

Reference: Tender No. EW-313

Due on date: / /

In connection with the above subject and reference I/ We confirm the following:

1. I / We, the under signed have read and examined the Scope of Work & requirements

during execution of work in tender mentioned under reference along with the

Commercial terms and conditions.

2. I / We, declare that our Technical Bid is strictly in line with the Tender

specifications/work.

3. Further, I / We also agree that additional conditions / deviations, if any, found in the

Commercial terms & conditions, our offer shall be out rightly rejected without

assigning any reason thereof.

4. We hereby agree for the terms & conditions laid down in Tender.

All the bidders are requested to see and verify the documents of

a) General safety rules / norms” to be observed by the contractors

b) Additional terms and conditions regarding industrial law and other related

matters for the tender documents.

c) General rules and directions for the guidance of contractor booklet of GSECL,

GTPS on our website under heading of “Rules for Works”

And confirm that all the above documents you have verified & certify as below

“I/we hereby has read the above documents and agree for the Safety Rules, Industrial

Laws and Contract Booklet (a, b & c as above) and accordingly submitted my/our

Signature of the Authorized

Representatives of the firm

Seal of the Firm

Name of the Tendering Firm / Agency:

EW- 313 PUR-F-006 RFQ-

DETAILS OF THE FIRM

Tenderer may MANDATORILY fill all the details in this form.

(These details are necessary to create the database of Contractors)

Contractor Name

Within Gujarat / Outside Gujarat /GST

Pvt. Firm / Public Ltd. / State Govt. Under (Indicate the relevant status)

taking / Central Govt. undertaking

Vendor Registration Letter No. & Date

(If registered and Letter issued by Board) -

(If Applicable)

Vendor Registration Fee (If Applicable) Paid / Not Paid (Tick any one, for New

Vendor Registration Date (If Applicable) -

Vendor Registration Validity Period From Date___________ to Date___________

(If Applicable)

P.F NO (Also Physical Document is

required along with the Technical Bid)

PAN NUMBER (Also Physical Document is

required along with the Technical Bid)

Custom No. and Date (If applicable)

Electrical License Type(If Applicable) (Also

Physical Document is required along with

the Technical Bid)

License Validity Period (If Applicable) From Date___________ to Date___________

Account Number of Bidder

Type of Account of Bidder

Branch Name & Address

Contact Number of the Branch

Copy of Cancelled Cheque

COMPANY EMAIL ID FOR

CONFIRMATION OF PAYMENT

Address of Registered Office Factory Works Authorized

Contact person name

City & Pin code

Phone Nos.(Office)

Phone Nos.(Residence)

Web site address

EW- 313 PUR-F-006 RFQ-

UN – PRICED SCHEDULE (COPY WITHOUT PRICES)

DESCRIPTION OF WORK QTY UNIT

Replacement/repairing of Single / Double / Triple / Fourfold Running

1 expansion bellows (joints) /cover bellows at various locations on

air/flue gas duct as per scope of work(1) of Schedule-A

Fabrication of Single fold expansion bellows according to the Running

existing damaged bellows as per scope of work of Schedule-A

and as directed by EIC.

Fabrication of Double fold expansion bellows according to the Running

3 existing damaged bellows as per scope of work of Schedule-A

and as directed by EIC.

Fabrication of Triple fold expansion bellows according to the Running

4 existing damaged bellows as per scope of work of Schedule-A

and as directed by EIC.

Removing & refitting of expansion bellow cover plates in which

5 bellow not replace as per scope of work of Schedule-A and as

directed by EIC.

Fabrication of frame, channel etc. for erection / strengthening of

6 expansion bellow as per scope of work of SCHEDULE-A and as 10 MT

per inst. Of EIC.

Removal of existing rubber cover made from conveyer belt fixed Running

7 on outer surfaces of expansion bellow by bolting as per scope of

work of Schedule-A.

Erection of Temporary Approach scaffolding from available Firm Running

8 platform/Ground as per specification and Height of scaffolding for

Expansion bellow work at Higher Elevation.

EW- 313 PUR-F-006 RFQ-

Work Completion Period

EW- 313 PUR-F-006 RFQ-

DETAILS OF THE EXPERIENCE FOR SIMILAR TYPE OF WORK AS PER TENDER’S

PRE-QUALIFICATION CRITERIA.

Party should submit below executed detailed work order physically along with the

Technical Bid. This is mandatory.

Sr. NAME ORDER DESCRIPTION ORDER ORDER STATUS, IF REMARKS

No OF REFERENCE OF WORK AMOUNT FULLY ORDER

WORK No. & DATE EXECUTED. UNDER

YES/NO EXECUTION

A GUJARAT STATE ELECTRICITY CORPORATION LTD /SISTER COMPANY.

B OTHER STATE ELECTRICITY BOARD

C OTHER ORGANISATION.

EW- 313 PUR-F-006 RFQ-

LIST OF PERFORMANCE CERTIFICATES SUBMITTED WITH THE TECHNICAL BID.

Party should submit below executed work performance certificate physically along

with the Technical Bid.

Sr. No. Name of the Authority by Reference No. & Details of Works

whom certificate is issued date

EW- 313 PUR-F-006 RFQ-

ANNEXURE – 8 ( for Works )

Bidder must fill up below details & should place at the top of the Technical Bid.

1 PRICES: [FIRM ONLY]

(Please Specify YES / NO.)

2 TAX: [IN PERCENTAGE] ( GST )

3 The Last three-year Audited Annual Accounts, Positive

Net worth certificate, and Average Annual Turnover

certificate certified by charted accountant as Per

Qualification Requirement

4 Please quote your GST Registration No. (Also Physical

Document is required along with the Technical Bid)

5 Please quote your PF Registration No. & Date. (Also

Physical Document is required along with the Technical

6 PENALTY TERMS AGREED :

(Please Specify YES / NO.)

7 SECURITY TERMS AGREED:

(Please Specify YES / NO.)

8 DETAILS OF EMD PAYMENT (as applicable as below)

a) DD No & Date & Name of Bank

b) B.G. No. & Date & name of Bank

c) Cash details

9 Completion of Works

(Please Specify YES / NO.)

10 VALIDITY OF THE OFFER AGREED:

(Please Specify YES / NO.)

11 PAYMENT TERMS AGREED:

(Please Specify YES / NO.)

12 WORK OFFERED AS PER SCHEDULE-B: (YES/NO)

13 TELEPHONE NOS. & FAX NO:

14 Authorized person of the firm :

15 Name of the proprietor, partners, directors [as the case

may be], along with address, telephone, fax no. etc.

16 If Vendor Registration is Done:(If Applicable)

(Please submit copy of Vendor Registration approval -

letter in the EMD cover).

EW- 313 PUR-F-006 RFQ-

TECHNICAL DEVIATIONS IF ANY TO BE FURNISHED IN THIS ANNEXURE ONLY AND

TO BE SUBMITTED WITH TECHNICAL BID.

EW- 313 PUR-F-006 RFQ-

(UNDERTAKING IN REGARD TO QUOTED PRICE)

(Bidder should not quote their prices in this page)

Sub: Undertaking in regard to quoted prices.

All bidders will have to furnish the following undertaking duly filled in, signed and

“This is to certify that we have not worked for the subjected tender viz.…………………. to

other SEBs / Power Utilities with this tender details of GSECL at lower % price than the

% prices quoted in this tender by us for the same item during last Six (6) Months.”

The prices quoted by us for the same item to other SEBs during the last six (6) months

are given below:

Signature of the Tenderer

Seal of the Firm

EW- 313 PUR-F-006 RFQ-

ANNEXURE-10A (For Supply)

Vendor must fill up below details & should place at the top of the Technical Bid.

1. PRICES:[FIRMONLY]

(Please Specify YES/NO.)

2. Rates offered FOR:__________________

3. GST :[INPERCENTAGE]

(Please Specify IN/EXCLUSIVE/EXEMPTED)

Please quote your GST Registration No. &Date

Please specify GST NO

4. In case of GST(SGST,CGST OR IGST)please specify place

of Manufacturer unit from where material is to be supplied

5. PENALT YTERMS AGREED:

(Please Specify YES/NO.)

6. SECURITYTERMSAGREED:

(Please Specify YES/NO.)

7. P.G TERMS AGREED (Wherever applicable):

(P.G.-Performance Guarantee)(Please Specify YES/NO.)

8. DETAILS OF EMD PAYMENT

(Please Specify DD/BG/Pay order/ Valid SSI/Valid NSIC

No./Valid UDYAM/Valid KVIC/Valid MSME

9. DELIVERY TERMS AGREED:

(Please Specify YES/NO.)

10. VALIDITY OF THE OFFER AGREED:180 Days from the

date of opening of Technical Bid

11. PAYMENT TERMS AGREED: 80% against T.R.C. within

30days & balance 20% within 45 days

12. ITEMS OFFERED:

13. TELEPHONE NOS. & FAX NO:

14. Authorized person of the firm:

15. Name of the proprietor ,partners, directors [As the case

may be], along with address, telephone, fax no. e-Mail ID

Signature of Tenderer Company’s roundseal

EW- 313 PUR-F-006 RFQ-

(UNDERTAKING IN REGARD TO STOP DEAL / BANNED FOR BUSINESS DEALING /

BLACK LIST THEREOF).

Sub: Undertaking in regard to Stop Deal / Banned for Business dealing / Black List

Ref: Tender No.:

M/S. ______________________________________ here by certify that M/S

__________________________________________ and their proprietor / any partner / any

directors of the firm is not stop deal and/or banned for business dealing and/or black

listed by GUVNL and/or their any subsidiary company viz.

GSECL/GETCO/DGVCL/MGVCL/UGVCL/PGVCL.

(Confirmed / not confirmed)

Contractor’s Signature

With Seal & Date

EW- 313 PUR-F-006 RFQ-

Bidders must furnish the scan copy of below details along with technical Bid.

(1) A copy of order on hand.

(2) Detail order copies submitted as per Annexure-6.

(3) Performance Certificate if any.

(4) Documentary Proof for Partnership of proprietor, Partners, Directors (as the case

may be), along with Address, Telephone No, Fax No. etc. if any.

(5) The Last three-year Audited Annual Accounts, Positive Net worth certificate, and

Average Annual Turnover certificate certified by charted accountant as Per

Qualification Requirement.

(6) A copy of Goods and Service Tax Registration document along with valid Registration

Number as per Annexure –

(7) A copy of PF Registration document along with valid Registration Number as per

(8) A valid B.G. against EMD or DD for the payment of EMD as per Annexure-8.

IMPORTANT INSTRUCTIONS

1. The Tenderer should clearly give certificate along with the Technical Bid:

“This is to confirm and certify that the offer submitted by me is strictly in accordance

with the GSECL’s Work Tender specifications and as per Technical detail work/

drawing as mentioned in the Tender Specifications. There is no commercial or

Technical deviation in the offer from the Corporation’s Tender Specification. I

undertake to abide by the GSECL’s tender description and Particulars. I undertake to

complete work strictly as per the GSECL’s Technical specification/ Scope of work/

Guaranteed Technical Particulars / Drawing, even if any technical deviations are

mentioned by me. I also undertake to abide by all commercial conditions of the GSECL,

including work completion schedule.”

(Signature of the Tenderer)

1. Any offer without above certificate will not be considered and the tender will be out

rightly ignored in the absence of above certificate.

2. After opening of the Tender, if it is found that the offer given by the Tenderer is not

according to the GSECL’s specifications, Guaranteed Technical Specifications/

Scope of work, Drawing and commercial terms and conditions and false certificate

is given by the Tenderer, then GSECL will not deal with the firm for the present

Tender. It is, therefore requested that the Tenderer should take care in giving their

offer and submission of documents.

3. The conditional tenders will not be accepted.

EW- 313 PUR-F-006 RFQ-

[On Company's Letter Head]

(Required for price justification, if necessary)

(UNDERTAKING IN REGARD TO QUOTED PRICE)

(All bidders will have to furnish the following undertaking duly filled in, for all the

quoted items/works of the tender along with online Technical Bid)

Ref.: Tender No: / Bid. No.:

We, the undersigned, hereby declare and undertake that we have not accepted or

executed any Letter of Acceptance (LOA) or Purchase Order (PO) at a unit ex-works

price/any work at rate lower than the rate offered in this tender in any station of

GSECL/GUVNL & Subsidiaries/CPSU/SPSU/IPP etc. during the period from six (6)

months prior to two (2) months after the bid submission date of this tender.

We also understand that LOA / Purchase Order placed by any station of

GSECL/GUVNL Subsidiaries/CPSU/SPSU/IPP etc. on the basis of above

undertaking shall not be considered as ‘offered’ price for the tender items in

subsequent tender, if it is not within period mentioned above

I/ We accept above undertaking.

EW- 313 PUR-F-006 RFQ-

Gujarat State Electricity Corporation Ltd.

Thermal Power Station, GANDHINAGAR

(On Firm’s Letter Head)

ON FIRM’S LETTER HEAD:-

of M/s. __________________________________ hereby certified that M/s.

______________________________________is not related with other firms who have submitted

tenders for the same work under this inquiry / tender and the interest (i.e.

Shareholding in company and share in partnership firm) of any employee of the tendering

Company or my/our relative as defined in section 2(77) of the Company’s act. 2013 is

10% or more, the tendering Company will not deal with such company/firm at all.

Also I /We declare that, I/We have not conflict of interest with other bidders, as

Conflict of interest among Bidders/Agents

A bidder shall not have conflict of interest with other bidders. Such conflict of

interest can lead to anti-competitive practices to the detriment of Procuring

Entity’s interests. The bidder found to have a conflict of interest shall be

disqualified. A bidder may be considered to have a conflict of interest with one

more parties in this bidding process, if :

a) they have proprietor/partner(s)/Director(s) in common; or

b) they receive or have received any direct or indirect subsidy/financial stake

from any of them; or

c) they have the same legal representative/agent for purposes of this bid; or

d) they have relationship with each other, directly or through common third

parties, that puts them in a position to have access to information about or

influence on the of bid of another bidder; or

e) Bidder participates in more than one bid in this bidding process.

Participation by a bidder in more than one Bid will result in the

disqualification of all bids in which the parties are involved. However, this

does not limit the inclusion of the components/sub-assembly/assemblies

from one bidding manufacturer in more than one bid.

f) in cases of agents quoting in offshore procurements, on behalf of their

principal manufacturers, one agent cannot represent two manufacturers or

quote on their behalf in a particular tender enquiry. One manufacturer can

also authorize only one agent/dealer. There can be only one bid from the

1. The principal manufacturer directly or through one Indian agent on his

2. Indian/foreign agent on behalf of only one principal.

EW- 313 PUR-F-006 RFQ-

g) a Bidder or any of its affiliates participated as a consultant in the

preparation of the design or technical specifications of the contract that is

the subject of the Bid;

h) in case of a holding company having more than one independently

manufacturing units, or more than one unit having common business

ownership/management, only one unit should quote. Similar restrictions

would apply to closely related sister companies. Bidders must proactively

declare such sister/common business/management units in same/similar

line of business.

i) Bidder shall not act in contravention/violation to the provisions of

competition act, as amended from time to time.

SIGNATURE OF THE TENDERER

WITH DESIGNATION.

SEAL OF THE FIRM:

EW- 313 PUR-F-006 RFQ-

GUJARAT STATE ELECTRICITY CORPORATION LIMITED, BARODA Date:

To, create an environment where Business Confidence is built through Best Business

Practices and in fostered in an atmosphere of trust and respect between providers of goods

and services and their users for the ultimate benefit of society and the nation.

GSECL’S COMMITMENT PARTY’S COMMITMENT

■ To maintain the highest ethical ■ Not to bring pressure

standards in business and recommendations from outside GSECL

professions. to influence its decision.

■ Ensure maximum transparency ■ Not to use intimidation, threat

to the satisfaction of inducement or pressure of any kind on

stakeholders. GSECL or any of it’s employees under

any circumstances.

■ To ensure to fulfill the terms of ■ To be prompt and reasonable in

agreement / contract and to fulfilling the contract, agreement, legal

consider objectively the viewpoint obligations.

■ To ensure regular and timely ■ To provide goods and/or services

release of payments on due dates timely as per agreed quality and

for work done. specifications at minimum cost to

■ To ensure that no improper ■ To abide by the general discipline to be

demand is made by employees or maintained in our dealings.

by anyone on our behalf.

■ To give maximum possible ■ To be true and honest in furnishing

assistance to all the Vendors / information.

Suppliers/ Service Provider and

other to enable them to complete

the contract in time.

■ To provide all information to ■ Not to divulge any information,

suppliers/contractors relating to business details available during the

contract/job which facilitate him course of business relationship to

to complete the contract/job others without the written consent of

successfully in time. GSECL.

■ To ensure minimum hurdles to ■ Not to enter into carter/syndicate/

vendors/suppliers/contractors in understanding whether formal/non-

completion of agreement/ formal so as to influence the price.

contract/ work order.

Seal & Signature Seal & Signature

(GSECL’s Authorized Signatory) (Party’s Authorized Person)

EW- 313 PUR-F-006 RFQ-

GUJARAT STATE ELECTRICITY CORPORATION LIMITED.

TPS: GANDHINAGAR.

Work of replacement / repairing / fabrication of Single / Double / Triple /

Sub: Fourfold expansion bellows of air/flue gas duct in Unit # 3, 4 & 5 at GTPS

during AOH/COH.

1. Replacement/repairing of Single / Double / Triple / Fourfold expansion bellows

(joints) /cover bellows at various locations on air/flue gas duct as per scope of

work(1) of Schedule-A

(a) Cutting and, removal of single/double/triple/four fold expansion bellows/cover bellows at

various locations of air/flue gas duct:

 Opening the manhole doors of duct where bellow replacement/repair is to be done.

 Preparation of necessary temporary scaffolding at elevated location of various flue

gas duct, PA duct & SA duct with their own scaffolding material if required.

 Locking the respective duct by means of welding of channel/ beam before cutting the

eroded expansion joint to maintain the original width of joints.

 Cutting the eroded expansion joints (Single, double & triple fold) by means of gas

cutting; removing the same form respective duct and crediting the scrap in main

store as per instruction of EIC.

 The scope of work also includes removal of insulation cladding and insulation materials

required to uncover and cutting of respective damaged/eroded expansion joints.

Quantity of work shall be considered on actual cutting length of expansion joint.

(b) Erection, alignment & welding of single/double/triple/four fold expansion joints:

 Cleaning the edges of respective duct at which new expansion joints to be erected

 Edge preparation of respective duct by means of grinding;

 Transportation of required size of new expansion joints from main store to site including

means of transportation at their own cost; safely shifting of new expansion joints or pieces

of expansion joints (in case of big expansion joints) from site to respective location where

it is to be erected without any damage;

 Placement and alignment of new expansion joints with corner either in single piece or in

more than one piece in respective position and seal welding the same with suitable size of

welding electrode of ISI brand confirming to AWS-6013 [which is recommended by

EIC] series only; Any rectification required in matching the gap of cut portion of

respective duct & width of new expansion joints shall have to be carried out;

 Removing the lock of new expansion joints to release the load on it;

 Removing and cutting of temporary locking of respective duct;

 Removing of scaffolding, closing the manhole doors.

 Welding should be free from any kind of welding defect. Welding shall have to be rectified

if any defect noticed;

 Cleaning of surrounding area by disposing off the debris, scrap materials including

insulation and cladding etc;

 Attending the leakages if any noticed during charging the duct with gas and air.

 Quantity of work shall be considered on actual length of welding joint of installed

expansion joint.

 Required lifting tackles (i.e. chain pulley block, wire & pulleys etc.) shall have to be

arranged by the contractor at their own cost.

 If work done is less than 5 running meter/bellow than minimum rate of 5 running

EW- 313 PUR-F-006 RFQ-

meter/bellow will be given. For works more than 5 meter, payment will be done for actual

measurement of work carried our & measurement will be taken jointly.

1. Priority will be given to replace the existing corroded/eroded bellow with New bellow as

per availability with GSECL and as per instruction of EIC. If new Bellow is not available,

then only repair of the bellow will be undertaken, with prefabricated patches by the party.

2. In case of replacement of cover bellow only, for such work 80% payment will be made.

(2) Fabrication of single/double/triple/ four fold expansion joints :

 Issuing required thickness and quantity of HR sheet from main store;

 Transportation of required materials from main store to site including means of

transportation at their own cost;

 Fabrication of Single/Double/Triple/Four fold expansion joints identical to the existing

installed expansion joint in single pieces or in pieces with corner as per requirement and

instruction of EIC from HR sheet of required thickness by forming in die and press.

Care shall have to be taken to match the contour of fold throughout length.

 Fabrication of plain flange and welding the same with the edge of fabricated expansion

joints to facilitate the installation of same in duct.

 Welding should be free from any kind of welding defect. Welding shall have to be rectified

if any defect noticed.

 After fabrication of expansion joints same shall have to be painted with red oxide.

Purchase & application of Red oxide is in the scope of party, no extra amount will be

given to party for purchase of the same.

 Surrounding area is to be cleaned.

 All the scrap / balance material shall have to be credited to main store.

(3) Removing & refitting of expansion bellow cover plates in which bellow not replace

as per scope of work of Schedule-A and as directed by EIC:

(UOM: running meter=running meter of length of welding irrespective of width of cover

(a) Cutting and removal of cover plates.

 Cutting the eroded cover plates installed and welded on Single/Double/Triple/Four fold

expansion joints by means of gas cutting/grinding etc.

 Removal of cover plates from the ducts and lowering down on the ground.

 Crediting the scrap of removed cover plate to Main store as per instruction of EIC.

(b) Fabrication & installation of cover plate on expansion joints:

 Issuing of MS plates (i.e. 5mm/6mm/etc) from main store/sub store/scrapyard,

transportation of same from main store to site including transportation means,

fabrication of cover plate of required width by cutting and grinding the edges of same,

shifting the seal cover plate from site to the location of installation by means of lifting

tackles, removing of eroded seal cover plate, installation and providing of new

fabricated cover plate on expansion joints from inside, welding of cover plate from

one side only as per instruction of EIC & other side should be free for accommodating

of expansion, crediting of scrap and any surplus materials to main store.

 The welding should be free from any kind of welding defect. Welding shall have to be

rectified if any defect noticed. For the inspection of existing bellow, cover plate shall be

removed and if the condition of plate is good, then it shall be reused otherwise new plate

shall be fabricated and provided.

EW- 313 PUR-F-006 RFQ-

 Kerosene test is to be arranged by the party for any leakage in welding and defective

welding is to be rectified free of cost by the party. Welding is to be done by tested

/certified welder only.

 The expansion bellow cover plate is to be removed for inspection, repairing of

expansion bellow.

 The cover plate is to be removed by cutting its welding with duct. If removed cover

plate is in good condition same is to be refitted by preparing its edge by grinding. If

required, new cover plate of required size is to be fabricated from plate issued by

GSECL by cutting, grinding etc.

 The work also includes fabrication of cover plate by welding two pieces, if required, to

minimize wastage of steel material. The cover plate must be welded at one edge so

as to facilitate its expansion in the direction of flue gas flow.

 The cover plate welding with duct wall should not be less than 4.0 mm or equal to

thickness of cover plate whichever is less.

(4) Fabrication of frame, channel etc. For strengthening of expansion bellows:

 Shifting/lifting of materials like plates, angles, channels, pipes, etc of suitable size

from main store/departmental store and stack near work area as per instruction

and intimation (irrespective of stopping of boiler) given by EIC. Transportation in

contractor scope.

 Fabrication is to be carried out from structural steel thick as per dimensions taken

at site. While fabrication, the corner piece from 10-mm plate is to be

provided for expansion bellow strengthening. If required, party has to repair /

replace expansion bellow frames.

(5) Removal of existing rubber cover made from conveyer belt fixed on outer surfaces

of expansion bellow:

 At present rubber covers made from conveyer belts are provided on outer

periphery of expansion bellows which are fixed by bolting. This covers are required

to be removed from bellows where replacement/repairing are to be done.

 Required scaffolding is to be made by the contractor.

 Bolts and plates will be required to cut by welding/cut rods.

 Belt covers are to be removed from its location and lowered down to ground floor

 After completion of work, removed belt covers and scraps shall be submitted to

 Required transportation for crediting the scrap shall be arranged by the contractor

at their own cost. Every tools-tackles & consumables and required to complete the

work are to be arranged by the contractor.

(6) Erection of Temporary approach scaffolding:

 The scope of work includes Erection & Dismantling of temporary approach

Scaffolding when the height of lower most edge of area to Expansion below

Repair is more than 3.0 meter from firm platform / ground/ permanent structure

from where approach platform is erected. Subsequent to this, if any further

scaffolding is required to carry out Expansion bellow Repair then separate

payment will not be released.

 The temporary approach platform to be erected must be of size of 2.5 mtr X

mtr or equivalent area or part of it (as per site requirement) at top of approach

scaffolding. The payment against this scope of work will be released based on

actual height of such scaffolding up to lower most edge of area firm platform /

ground/ permanent structure from where approach platform is erected. The

EW- 313 PUR-F-006 RFQ-

scaffolding measurement calculated 2.5 mtr x 2.5 mtr and height 1 mtr then it is

taken 1 mtr as running meter and subsequent.

 If available, the scaffolding materials will be provided by GSECL free of cost on

returnable However, contractor has to arrange steel binding wire & any of

required consumable material for Erection of scaffolding.

 To & fro Transportation of scaffolding materials from BMD sub store to work site /

location is in contractor’s scope

TECHNICAL TERMS AND CONDITIONS:

(1) For each items of Schedule-B, description mentioned in scope of work is indicative

only, it is not limited to it but any other related work required for completing the job will

be considered as scope of work.

(2) To conduct survey of different expansion bellows of bowl mill individual ducts, hot air

PA header, cold air PA fan & FD fan ducts, Air-preheater inlet & outlet ducts up to ID

fan exit which are required to be replace/repair. The fabrication is to be started for the

damaged expansion bellow as instructed by GSECL Engineer-in-charge well in

advance prior to commencement of AOH/COH.

(3) Contractor shall fabricate bellow based on survey conducted and as directed by EIC

well in advance prior to commencement of AOH/COH.

(4) If contractor fabricates bellows more than length decided by survey, NO payment

shall be made for this extra length of fabrication.

(5) Fabrication is to be carried out from @ 2.50/3.15 mm plate as per dimensions taken at

site. While fabrication, the corner piece from 10-mm plate is to be provided for

expansion bellow strengthening. If required, party has to repair/replace expansion

bellows frames.

(6) Full welding of the bellows corner as well as with main ducting is to be carried out.

Kerosene test is to be given for welding and repair.

(7) For erection of expansion bellow at site, party has to remove existing bellow and

same is to be credited to store. Temporary scaffolding, supports, lugs structures are

to be prepared by the contractor at his own cost. The same is to be removed

completely after work is completed.

(8) The contractor has to arrange scaffolding to carry out the Expansion below work. The

Scaffolding required to carry out the Works shall be arranged by the Contractor at

their Own Cost. The scaffolding material will be provided by GSECL free of cost if

available. Scaffolding consumables like steel binding wire is to be arranged by

contractor at his own cost. The scaffolding required to approach to work area (i.e.

approach scaffolding) is also to be arranged by contractor. The approach scaffolding

up to height of 3.0 mtr from ground / permanent platform / structure shall be arranged

by the Contractor at their Own Cost.

(9) Party has to submit detail report for material issued and used with location & detail

measurement to Engineer-In-charge. Measurement is to be taken jointly in presence

of GSECL supervisor or engineer-in-charge. The final bill will be prepared based on

final measurement sheet dully accepted &signed by party and our supervisor

(10) Before taking written permission of excess work of C.A. if party carries out excess

work, payment will not be made for excess work carried out.

(11) Electrical connection and energy consumption will be given Free of charges. The

lighting is to be arranged by the party. The GSECL shall make arrangement for

providing power supply to the contractor for working their equipments, tools etc. as

and when required as decided Locations/points by Engineer in Charge. ICTP switches

and ELCBs has to be arranged by the contractor. Further distributions shall be at the

EW- 313 PUR-F-006 RFQ-

cost of contractor. Floods for Lighting will be arranged by GSECL as and where

required. However, contractor has to arrange 100/24 Watts bulbs at their cost.

(12) The scope of works includes carting of materials form the GSECL Main Store/Sub

Store as the case may be if applicable and as directed by GSECL Engineer for which

no extra payment shall be made for transportation.

(13) All types of consumables like cotton waste, cloth, kerosene, diesel, rust removal

chemical, lapping paste, emery papers, paint, cutting gas, general purpose welding

rods, cut rod, personal protective equipments(PPE) like helmets, safety belts,

goggles, dust masks, Scaffolding material etc. will be arranged by party at their cost.

(14) Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift,

mobile crane, EOT crane etc) & its attachments (like D-shackles, slings, U-clamps,

Eye bolts or any fixtures), it shall be checked and used only if found safe to use. Also,

ensure that these are tested, examined & certified in form no 9/10 by Competent

Authority Person as per the Factory act-1948 and its validity not expired. Further, it

shall be fixed properly and firmly prior to lifting the weight.

(15) The contractor shall take all the required safety measures prior to commencement of

work on dangerous substances, machineries or area at which cautionary notice is

displayed and obtain `Line Clear` or `Work Permit` through the concerned Department

GENERAL TERMS AND CONDITIONS:

1) Contractor shall have to clean the area and remove the fouling material, cotton waste

& scrap in all respect in the area in which work is executed and get it certified through

the engineer in charge looking after the job.

2) Contractor will have to keep authorized and well experienced supervisor round the

clock at site for supervising the work and coordinating with other agencies and

GSECL. If it is observed that work is carried out under GSECL supervision in

absence of contractor’s supervisor, penalty of Rs. 500/- per day will be

3) In case party fails to clean the area and clear the site within five days after

completion of work, same will be carried out at the risk and cost of the party.

4) After re-commissioning of equipment/system, if any problems arise for the works

carried out, it shall have to be set right by the contractor without any extra charges to

the GSECL. Contractor should attend any defect contributory to their faulty

workmanship during the trial run, and up to the Period of 03 Months from re-

commissioning of equipment/system/unit, without any extra charges to the GSECL. If

a rectification is not carried out in time as instructed by Engineer in Charge, the same

shall be carried out by GSECL by engaging GSECL staff or any other agency and

cost of which will be recovered including supervision charges from the contractor’s bill

as per Company’s Rules.

5) GUARANTEE PERIOD:

The party shall have to give performance guarantee 5 % of execution of work

for their poor workmanship for a period of 03 months from the date of

completion of work.

6) The payment will be done for actual work done only.

7) All general Terms & Conditions as per Corporation’s standard format applicable to this

8) Mobilization period:

04 days time shall be allowed from the date of receipt of telegraphic / fax letter / letter

/ Mail for mobilization and mobilization of contractor’s men, material etc. at works site

before 2 days of AOH / COH.

EW- 313 PUR-F-006 RFQ-

9) Work Completion Period:

The period for completion of work shall be 21 days / 25 days / 30 days and Schedule

of AOH/COH days will intimate to party by this office, respectively excluding the

mobilization period of 04 days. All the necessary items of schedule “B” as directed by

EIC. Party have to complete work within stipulated AOH days as intimated by this

10) TIME LIMIT:

The contract period is of 18 months from the date of commencement of work. GSECL

reserves the right to extend this contract as per GSECL norms with same rate, terms &

conditions & it’s binding to the party.

11) PENALTY FOR DELAY:

If the work is not done as per specification given by the corporation in stipulated time

in all respects, the penalty will be levied as per corporation rules. Any delay that may

take place in supply and / or erection, testing and commissioning activities beyond

contractual cutoff date / stipulated period in the order shall be subjected to penalty (not

liquidated damages) at the rate ½% of the contract price / order price per week or part

thereof subject to a maximum of 10% of the total contract value / order value (i.e. End

cost including taxes & duties.)

(1) If party fail to attends the daily AOH meeting then penalty will be impose Rs. 300/-

(2) During AOH GSECL will arrange the special meeting and if party fail to attends the

meeting, then penalty will be impose Rs. 500/- per incident.

(3) The contractor is responsible to keep the work area cleaned daily. If the contractor

fails to keep the work area clean on daily basis than GSECL GTPS will impose

penalty Rs. 500/- per incident after 3 times notice.

(4) If party has fail to submit daily work progress report in hard/soft copy in morning

before 9:00am then penalty will be impose Rs. 100/- per incident.

12) Party shall have to remove all the scrap and deposit the same to main stores as per

instructions of EIC. In addition to this the party has to totally clean the work area

immediately on completion of work or else Rs.5000/- or part thereof (as decided by the

competent authority i.e Chief Engineer; GTPS) shall be deducted towards penalty from

the party’s Bill submitted for payment.

13) DISPUTE: In case of any dispute, the decision of the Chief Engineer of respective

power station will be final and binding on the contractor.

14) GSECL RIGHT TO ACCEPT DOCUMENTS: The GSECL reserved the right to award

full item or part thereof or reject any item or all the items on the tender without

assigning any reasons thereof which is considered advantage to the GSECL. No sales

tax will be paid for this work.

15) The contractor has to adhere safety practices against hazardous and unsafe working

conditions and shall comply with the safety rules in force from time to time of GSECL,

Gandhinagar TPS. The contractor has to arrange for 24 V Transformers/battery to

men to be utilized as safe equipments while carrying out the work Inside of

equipments /at higher elevation.

16) During execution of work, if any fatal/ non-fatal accident or occurrence happens,

Corporation shall not responsible for any kind of legal liabilities and workmen

compensation; only the contractual party is responsible for legal compliance and any

compensation thereof.

17) All accidents / incident to be reported immediately to C.E. (G) and safety officer.

18) In case of any injury / accident while working, it shall immediately be reported to

Safety Department through concerned Sectional Head / Engineer. The prescribed

Form No.21 may be obtained from concern section or Safety Officer. For any incident

EW- 313 PUR-F-006 RFQ-

occurred but have no injury to any persons should also informed to safety officer as

Near Miss Incident.

19) In all risky job, before start the work contractor should obtained General Safety Work

Permit through concerned section from safety dept in well advance.

20) For performance evaluation of contractor safety factors of work accident, fire incident

& near miss accident will be considered. Steps can be taken to review the job

assignment up to cancellation for negligence.

21) Flash back arrestor to be fixed in each welding / cutting gas cylinders sets. The above

rules shall be scrupulously followed and where required, they may contact the Safety

Officer in case of any ambiguity or needs further guidance in this regard.

22) The subjected work shall have to be carried out during AOH/COH as per the

company’s outage schedule. Any change in proposed outage schedule shall be

binding to the contractor, for which no extra Payment shall be given.

23) Party has to furnish the documents for insurance of Workmen, labours license and

other account section formalities before starting the Works, failing to which Contractor

shall not be allowed to commence the Work.

24) All the work shall be carried out as per the instruction of GSECL Engineer-in-charge or

his representatives. GSECL Engineer’s decision regarding the correctness of the work

and method of working shall be final and binding to the contractor.

25) The GSECL shall not be liable in any manner whatsoever, to the contractor or his

worker in respect of any losses damaged suffered while working in the powerhouse

premises. The whole responsibility shall be of the contractor.

26) As per C.O circular No. GSECL/Medical/PME/O1 DTD.16.07.2019 i.e. for procedure

for health check-up accordingly bill shall be reimbursed once during total contract

period (for as & when and AOH/COH contract) maximum up to Rs.1000 or actual cost

per worker/ labour / person, whichever is minimum after verification & recommendation

by concern doctor. In case any worker left the work in between than for replacement

Worker Company will not provide any reimbursement, however it is compulsory to

submit new report of replacement worker for fitness certificate at contractor’s own

Chief Engineer (Gen)

Signature of contractor

EW- 313 PUR-F-006 RFQ-

ON STAMP PAPER OF Rs.300/-]

EMD BANK GUARANTEE FORMAT

FOR TENDER NO.__________

GUJARAT STATE ELECTRICITY CORPORATION LIMITED

WHEREAS M/s. __________________________________________(Name and Address of the

Firm/company) having their registered Office at

________________________________(Address of the Firm’s registered Office) (hereinafter

called the “Tenderer”) wish to participate in the Tender No._______________ for

_________work (Supply / Erection / Supply & Erection Work, etc.) of ______________________

(Name of the Material/equipment / work) for Gujarat State Electricity Corporation Limited

(hereinafter called the “Beneficiary”) and WHEREAS a Bank Guarantee for

Rs._____________ (Amount of Bank Guarantee towards EMD) valid till ____________ (mention

here date of validity of this Guarantee which will be Six months from the date of submission

of bid of the tender) which is required to be submitted by the Tenderer along with the

We,_____________________________________________(Name of the Bank & address of the

Branch giving the Bank Guarantee) having our registered Office at

_____________________ (Address of Bank’s registered Office) hereby give this Bank

Guarantee No. _________________ dated ____________ and hereby agree unequivocally

and unconditionally to pay immediately on demand in writing from Beneficiary

Gujarat State Electricity Corporation Limited or any Officer authorized by it in this

behalf any amount up to and not exceeding Rs.____________(Amount of E.M.D.),

Gujarat State Electricity Corporation Limited on behalf of the Tenderer.

We, ____________________________________________ (Name of the Bank) also agree that

withdrawal of the Tender/Bid/EOI or part thereof by the Tenderer within its validity or

Non submission of Performance Guarantee towards execution/supply period by the

Tenderer within 15 days from the date of issue of Letter of Acceptance by the Gujarat

State Electricity Corporation Limited would constitute a default on the part of the

Tenderer and that this Bank Guarantee is liable to be invoked & encashed within its

validity by the Beneficiary in case of any occurrence of a default on the part of the Tenderer

and that the encashed amount is liable to be forfeited by the Beneficiary.

This agreement shall be valid and binding on this Bank up to and inclusive of

_______________ (mention here the date of validity of Bank Guarantee) and shall not be

terminable by notice or by Guarantor for change in the constitution of the Bank or the

Firm of Tenderer or by any reason whatsoever and our liability hereunder shall not be

impaired or discharged by any extension of time or variations or alterations made,

given, conceded with or without our knowledge or consent by or between the

Tenderer and the Gujarat State Electricity Corporation Limited.

Notwithstanding anything contrary contained in any law for the time being in force or

banking practice, this Guarantee shall not be assignable, transferable by the Beneficiary

(i.e. GSECL) Notice or invocation by any person such as assignee, transferee or agent of

beneficiary shall not be entertained by the Bank. Any invocation of the Guarantee can be

made only by the beneficiary directly.”

NOTWITHSTANDING anything contained hereinbefore our liability under this

Guarantee is restricted to Rs.__________(Amount of EMD) (Rupees

__________________________________) (in words). Our Guarantee shall remain in force till

EW- 313 PUR-F-006 RFQ-

_____________ (Date of validity of the Guarantee). Unless demands or claims under this

Bank Guarantee are made to us in writing on or before ___________ (Date of validity of the

Bank Guarantee), all rights of Beneficiary under this Bank Guarantee shall be forfeited

and we shall be released and discharged from all liabilities there under.

Please Mention here Complete Postal Signature of the Bank’s

Address of the Bank with Branch Code, Authorised Signatory with

Telephone and Fax Nos Official Round seal

NAME OF DESIGNATED BANKS : As per Annexure – I

EW- 313 PUR-F-006 RFQ-

(ON STAMP PAPER OF Rs.300/-)

FORM OF BANKER’S UNDERTAKING

(For Performance Guarantees (PBG) towards execution/supply period ( Security

Deposit ) as per Commercial Terms & Conditions of Tender)

We, __________________________________________________(name of the Bank and Address of

the Branch giving the Bank Guarantee) having our registered Office at

registered office) hereby give this Bank Guarantee No.

unequivocally and unconditionally to pay immediately on demand in writing from

the Gujarat State Electricity Corporation Limited, or any Officer authorized by

it in this behalf any amount up to and not exceeding Rs. _____________ (Amount of

Performance Guarantee towards execution/supply period ) Rupees

said Gujarat State Electricity Corporation Limited on behalf of

contract for the supply / works specified below :

This agreement shall be valid and binding on this Bank up to and inclusive

of___________________(Date of validity of the Bank Guarantee) and shall not be

terminable by notice or by change in the constitution of the Bank or the firm of

Contractors / Suppliers or by any other reason whatsoever and our liability

hereunder shall not be impaired or discharged by any extension of time or

variations or alterations made, given conceded or agreed, with or without our

knowledge or consent, by or between parties to the said within written contract.

“Notwithstanding anything contrary contained in any law for the time being in force or

banking practice, this Guarantee shall not be assignable, transferable by the beneficiary

(i.e. GSECL). Notice or invocation by any person such as assignee, transferee or agent of

beneficiary shall not be entertained by the Bank. Any invocation of the Guarantee can be

made only by the beneficiary directly.”

“NOT WITHSTANDING” anything contained herein before, our liability under this

guarantee is restricted to Rs._______________(Rupees

___________________________________________only). Our guarantee shall remain in force

until _______________ (date of validity of the Bank Guarantee).Unless demands or

claims under this Bank Guarantee are made to us in writing on or before _____________

(Date of validity of the Bank Guarantee), all rights of Beneficiary under this Bank

Guarantee shall be forfeited and we shall be released and discharged from all liabilities

Please mention here complete Signature of the Bank’s authorized

Postal Address of the Bank with signatory with Official Round Seal.

Branch Code, Telephone and Fax

NAME OF DESIGNATED BANKS : As per Annexure - I

EW- 313 PUR-F-006 RFQ-

(ON STAMP PAPER OF Rs.300/-)

FORM OF BANKER’S UNDERTAKING

(For Performance Guarantees (PBG) towards Guarantee/Warranty period as per

Commercial Terms & Conditions of Tender)

We, __________________________________________________(name of the Bank and Address of

the Branch giving the Bank Guarantee) having our registered Office at

registered office) hereby give this Bank Guarantee No.

unequivocally and unconditionally to pay immediately on demand in writing from

the Gujarat State Electricity Corporation Limited, or any Officer authorized by

it in this behalf any amount up to and not exceeding Rs. _____________ (Amount of

Performance Guarantee towards Guarantee/Warranty period ) Rupees

Gujarat State Electricity Corporation Limited on behalf of

contract for the supply / works specified below :

This agreement shall be valid and binding on this Bank up to and inclusive

of___________________(Date of validity of the Bank Guarantee) and shall not be

terminable by notice or by change in the constitution of the Bank or the firm of

Contractors / Suppliers or by any other reason whatsoever and our liability

hereunder shall not be impaired or discharged by any extension of time or

variations or alterations made, given conceded or agreed, with or without our

knowledge or consent, by or between parties to the said within written contract.

“Notwithstanding anything contrary contained in any law for the time being in force or

banking practice, this Guarantee shall not be assignable, transferable by the beneficiary

(i.e. GSECL). Notice or invocation by any person such as assignee, transferee or agent of

beneficiary shall not be entertained by the Bank. Any invocation of the Guarantee can be

made only by the beneficiary directly.”

“NOT WITHSTANDING” anything contained herein before, our liability under this

guarantee is restricted to Rs._______________(Rupees

___________________________________________only). Our guarantee shall remain in force

until _______________ (date of validity of the Bank Guarantee).Unless demands or

claims under this Bank Guarantee are made to us in writing on or before _____________

(Date of validity of the Bank Guarantee), all rights of Beneficiary under this Bank

Guarantee shall be forfeited and we shall be released and discharged from all liabilities

Please mention here complete Signature of the Bank’s authorized

Postal Address of the Bank with signatory with Official Round Seal.

Branch Code, Telephone and Fax

NAME OF DESIGNATED BANKS : As per Annexure – I.

EW- 313 PUR-F-006 RFQ-

(ON STAMP PAPER OF Rs.300/-)

FORM OF BANKER’S UNDERTAKING

(Combined Performance Guarantees (PBG) towards Execution/Supply period and

Guarantee/Warranty period as per Commercial Terms & Conditions of Tender)

We, __________________________________________________(name of the Bank and Address of

the Branch giving the Bank Guarantee) having our registered Office at

registered office) hereby give this Bank Guarantee No.

unequivocally and unconditionally to pay immediately on demand in writing from

the Gujarat State Electricity Corporation Limited, or any Officer authorized by

it in this behalf any amount up to and not exceeding Rs. _____________ (Amount of

Combined Performance Guarantees (PBG) towards Execution/Supply period and

Guarantee/Warranty period) Rupees

Gujarat State Electricity Corporation Limited on behalf of

contract for the supply / works specified below :

This agreement shall be valid and binding on this Bank up to and inclusive

of___________________(Date of validity of the Bank Guarantee) and shall not be

terminable by notice or by change in the constitution of the Bank or the firm of

Contractors / Suppliers or by any other reason whatsoever and our liability

hereunder shall not be impaired or discharged by any extension of time or

variations or alterations made, given conceded or agreed, with or without our

knowledge or consent, by or between parties to the said within written contract.

“Notwithstanding anything contrary contained in any law for the time being in force or

banking practice, this Guarantee shall not be assignable, transferable by the beneficiary

(i.e. GSECL). Notice or invocation by any person such as assignee, transferee or agent of

beneficiary shall not be entertained by the Bank. Any invocation of the Guarantee can be

made only by the beneficiary directly.”

“NOT WITHSTANDING” anything contained herein before, our liability under this

guarantee is restricted to Rs._______________(Rupees

___________________________________________only). Our guarantee shall remain in force

until _______________ (date of validity of the Bank Guarantee).Unless demands or

claims under this Bank Guarantee are made to us in writing on or before _____________

(Date of validity of the Bank Guarantee), all rights of Beneficiary under this Bank

Guarantee shall be forfeited and we shall be released and discharged from all liabilities

Please mention here complete Signature of the Bank’s authorized

Postal Address of the Bank with signatory with Official Round Seal.

Branch Code, Telephone and Fax

NAME OF DESIGNATED BANKS : As per Annexure - I.

EW- 313 PUR-F-006 RFQ-

Financial Department, GR.No. FD/MSM/e-file/4/2025/2712/DMO Dtd. 01/04/2026

[ To be revised as per GoG notification issued from time to time.]

List of Banks Notified by GSECL

(A) Guarantees issued by following banks will be accepted as SD/EMD on permanent

 All Nationalized Banks.

(B) Guarantees issued by following Banks will be accepted as SD/EMD for period up

to March 31, 2027. The validity cut-off date in the GR is with respect to date of

issue of Bank Guarantee irrespective of date of termination of Bank Guarantee.

Name of Banks Name of Banks

1 AXIS Bank 23 A U Small Finance Bank

2 Bandhan Bank 24 City Union Bank

3 CSB Bank 25 DBS Bank India Limited

4 DCB Bank 26 Dhanlaxmi Bank

5 Equitas Small Finance Bank 27 Federal Bank

6 HDFC Bank 28 HSBC Bank

7 ICICI Bank 29 IDBI Bank

8 IDFC First Bank 30 Induslnd Bank

9 Jammu and Kashmir Bank 31 Jana Small Finance Bank

10 Karnataka Bank 32 Karur Vysya Bank

11 Kotak Mahindra Bank 33 RBL Bank

12 South Indian Bank 34 Standard Charter Bank

13 Tamilnad Mercantile Bank 35 Ujjivan Small Finance Bank

14 YES Bank 36 Ahmedabad Mercantile Co-

15 Nutan Nagrik Sahakari Bank 37 Rajkot Nagrik Sahakari Bank

16 Sarswat Co-Operative Bank 38 SBPP Co-operative Bank Ltd.

17 SVC Co-Operative Bank Ltd. 39 The Cosmos Co-op Bank Ltd.

18 The Gujarat State Co- 40 The Surat District Co-operative

Operative Bank Bank

19 The Surat Peoples Co- 41 The Baroda Central Co-operative

operative Bank Ltd. Bank

20 The Panchmahal District Co- 42 The Kalupur Commercial Co-

operative Bank operative Bank

21 The Rajkot Commercial Co- 43 The Banaskantha Mercantile Co-

operative Bank Limited Operative Bank Ltd.

22 Gujarat Gramin Bank

EW- 313 PUR-F-006 RFQ-

GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTOR

All the contractors working in Gujarat State Electricity Corporation Limited Factory

like Coal/Lignite/Gas/Hydro/Pumping Station shall have to strictly observe the

following Safety Rules. Concern principle contractors are responsible for informing &

observance of these rules by their supervisors/contract workers as well as the

owner/supervisors/ workers of sub-Contractors engaged, if any, by them for the work

contract awarded to them. Prior to commencement of the work, Contractor shall have to

submit a written assurance on their letterhead to the concerned Sectional Head /

Engineer-in-charge that they have thoroughly gone through these Rules, have educated

their employees / workers of their sub contractor and will strictly observe the said Rules

while execution of work under work contract awarded to them. They will have to indemnify

the company for any loss or damage / accident / injury to the company’s property /

employee or employee of their own in default of non - observing these rules.

(01) Contractor should issue photo gate pass for their workers from GSECL Factory

Manager as per Gujarat Factories rules, 1963 & details shall be filled up in GSECL

gate pass format as per Aadhar card /Election card id proof & to follow the gate pass

issue procedure through concern department EE & SE, Security Officer,

LWO/IRO/DGM, Factory Medical Officer, Safety Officer/Dy. Safety Officer & Factory

(02) In case of emergency, temporary photo gate pass shall be issued by Security Officer

only for three days with prior permission of Factory Manager only. More than three

days, Permanent photo gate pass procedure shall be completed by contract agency for

their contract workers.

(03) Certificate of Fitness of employment in hazardous process & operations in form no.33

of Gujarat Factories rules, 1963 shall be issued by GSECL Factory Medical Officer for

all contractor workers before commencement of work & examination responsibility

shall be taken by contractor as well as concerned Head of Department .Pre-

employment & Periodical medical examination of contractor workers shall be carried

out in form no.32 from GSECL Factory Medical Officer after every six (06) months of

contractor with their contractor workers. Contractor shall be fulfilled all health

requirements before commencement of work. After completion of medical examination

in form no.32/33, GSECL Factory Medical Officer shall be signed in contract worker

gate pass procedure format.

(04) If work executed outside factory premises, Principle Contractor shall be registered

compulsory under The Building & Other Construction Workers (Regulation of

Employment and condition of service) Act, 1996 and The Gujarat Building & Other

Construction Workers (Regulation of Employment and condition of service) Rules,

2003 before execution the ”building or other construction work” means the

construction, alteration, repairs, maintenance or demolition, of or, in relation to,

buildings, streets, roads, railways, tramways, airfields, irrigation, drainage,

embankment and navigation works, flood control works (including storm water

drainage works), generation, transmission and distribution of power, water works

(including channels for distribution of water), oil and gas installations, electric lines,

wireless, radio, television, telephone, telegraph and overseas communications, dams,

canals, reservoirs, watercourses, tunnels, bridges, viaducts, aqueducts, pipelines,

towers, cooling towers, transmission towers and such other work as may be specified

in this behalf by the appropriate Government, by notification but does not include

any building or other construction work to which the provisions of the Factories Act,

1948 (63 of 1948), or the Mines Act, 1952 (35 of 1952), apply.

(05) Contract worker gate pass will issue after completion of safety induction 3D

animation movie & Training record is to be maintained in IMS/OHSAS training

format by TK Office/LWO.

EW- 313 PUR-F-006 RFQ-

(06) As per Gate pass format of GSECL, Safety Officer/Dy. Safety Officer shall be checked

the issue PPE to contract workers as per nature of job, Form no.10 of lifting tools and

tackles, Driving license, Electrical contractor license, Electrical trade qualifications,

Safety induction training, SOP, supervisor qualifications etc. After fulfillment of all

Safety compliances, Safety Officer/Dy. Safety Officer shall be signed in Contract

worker Gate pass procedure format.

(07) Work Contract shall be completed by principle contractor/agency/person who is

awarded the work order. Subletting of contract shall be allowed only if prior approval

of Power station chief before execution of work. Contractor/agency shall be submitted

the entire subletting contract documents with gate pass application through concern

department EE & SE, LWO/DGM, Safety Officer/Dy.Safety Officer & Factory

(08) Under The Conditions Framed Under Rule-45 Of The Indian Electricity Rules,

Valid Electrical contractor License shall be submitted to concern electrical

department EE/SE/Electrical Safety Officer/ Safety Officer/Factory Manager at the

time of apply gate pass by agency/party with latest renewal from Chief Electrical

Inspector, Gandhinagar- Gujarat. Electrical License photocopy shall be checked by

Concerned HOD of Electrical Department/Electrical Safety Officer/Dy.Safety Officer/

Safety Officer/Factory Manager.

(09) As per nature of job/work, Qualified supervisor (Diploma (Electrical/

Mechanical/Civil/C&I) + 3 years experiences or ITI + 10 years) shall be engaged by

contract agency & qualification certificate with experience certificate shall be

submitted to concern EE/SE/LWO/IRO/DGM/ Dy. Safety Officer /Safety

Officer/Factory Manager at the time of apply gate pass.

(10) As per rule 3 of CEA regulation ,2010: Designating person(s) to operate and carry

out the work on electrical lines and Apparatus, Contract person/worker possesses

a certificate of competency or electrical work permit, issued by the Appropriate

Government. That means, Electrical trade Qualification of contract worker/person

like ITI-wireman/ Electrician, Diploma (Elect), BE/B. TECH (Elect), ME/ M. TECH

(Elect) shall be submitted to concern EE/SE/LWO/IRO/DGM, Dy.Safety Officer/

Safety Officer/Factory Manager at the time of apply for photo gate pass procedure.

(11) As per nature of job/work & during capital overhauling work /Annual overhauling

work /24X7 round the clock work/major shut down work, Qualified Safety

Officer/Manager/Supervisor (BE/Diploma (Elect/Mech/Civil) + PDIS-Post Diploma in

Industrial Safety) shall be engaged by contractor during dangerous

operations/dangerous works as well as day to day dangerous activities, safety

supervision, tool box talk, Safety awareness programme, SOP preparation with

hazards & its control measures with each step , checking of lifting tools & tackles,

hydra mobile crane, Safety precautions, coordination with Safety Department etc.

(12) License of driver shall be submitted with gate pass issue application as per nature of

vehicles & to follow the Motor vehicle Act,1988,the Central Motor Vehicles

(Amendment) Rules,2016 as well as Gujarat Motor Vehicles rules,1989 & driver

license shall be checked every day by security shift in charge before entry in the

Factory premises.

(13) SOP with JSA (Job Safety Analysis) shall be prepared by contractor through

competent person as per GFR, 1963 or Qualified Safety Officer as per GFR, 1963 with

05 years experiences. SOP will review & approve by concern JE/DE/EE/SE/Elect.

Safety Officer/Dy. Safety Officer /Safety Officer/Factory Manager before execution of

(14) It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as

per the job requirement. Do not work without use of required P.P.Es. Contractor is

responsible to provide standard make (ISI/DGMS/CE/EN/ANSI approved) & to

checked standard/make in PPE issue format by concern JE/DE/EE/SE/Safety

Officer/Factory Manager. Personal Protective Equipments / Safety Gadgets suitable to

give sufficient protection against hazards involved in their work / job to their staff, as

EW- 313 PUR-F-006 RFQ-

per the job requirement and insist / enforce their workers to put on the same while at

The ongoing work is liable to be stopped at any time if your contract workers/staffs

found working without P.P.Es. Following is the list of various P.P.Es (as per

ISI/DGMS/CE/ EN/ ANSI approved only) to be used for various works / worksites.

In any work, Contractor shall be issued the minimum 06 nos. of PPEs like Safety

Shoes, Safety Helmet, Safety goggles, Mask & Reusable Ear plug, hand gloves to their

workers/supervisor compulsory & it will check by concern section HOD & Dy. Safety

Officer /Safety Officer at the time of gate pass procedure.

Quality of PPE shall be approved from Safety Officer as per Indian Standard and

International Standard before executions of work or at the time of gate pass apply

List of safety equipments

Industrial Safety Helmet For protection of head against falling objects or

during fall of person from height. Yellow Colour

helmet is used for contract worker with agency

Safety Goggles/welding For protection of eyes against flying particles / dust,

goggles/ chemical splash chemical splash, welding spark, arc, flashover etc.

Full Face shield For protection of face against flying particles / dust,

chemical splash, spark, arc, flashover etc.

Reusable Earplug / Ear For ear / hearing system protection while working in

muffs. high noise level area.

Chemical suit/Gas tight suit For body protection against chemicals, oils, sharp

/Fire proximity suit/FR edged objects, heat, hot objects etc.

Safety Hand Gloves For protection of hands against chemicals, oils,

sharp edged objects, heat, hot metals/objects,

electricity etc.

Safety shoes/ Gum Boots For protection of leg/feet against falling objects,

with sharp edged objects, heat, hot metals/objects,

Oil/Chemical/water/heat/ electricity etc..

Electrical resistance etc.

Safety Belt(full body For fall prevention while working at heights or in

hardness with double depth, working in vessel or in confined space.

lanyard & shock absorber) /

Rope / Life line / Fall

Dust Mask/Respirator with Protection of respiratory system against dust.

Chemical Cartridge Protection against toxic chemical fumes /

Respirator with full face gases/vapors/dust etc.

mask type A2B2E2K2

Trolley mounted Air line Working in oxygen deficient zone or confine space

respirators with full face area

Portable Single gas detector Working in hazardous storage/process area

like Chlorine, Ammonia,

Portable Multi gas Detector Working in oxygen deficient zone & use in entry of

( LEL,O2,CO,H2S,SO2, etc) confine space & Major fire

EW- 313 PUR-F-006 RFQ-

Automatic voltage detector To check the present voltage or induction voltage of

electrical equipments/ bus/switch gears from

(one) feet distance before starting the any electrical

Auto darkening welding The new auto darkening welding helmet combines

helmet (EN 379 & EN 175 legendary Speed glass quality and auto darkening

Level-B) with PAPR as per technology with an innovative wide-view grinding

EN 12941:1998, class TH2 visor to give welders an all-in-one solution for more

and AS/NZS 1716 flexibility, precision, and efficiency.

Respiratory System is a combined face and breathing

protection device, for increased comfort and safety in

welding. The unit is equipped with a particle filter

which removes particles from the air. The unit

provides a constant airflow independent of filter

combinations and clogging. The unit can also be

equipped with a gas filter (for example A1B1E1). The

unit supplies air to the head top via the connecting

breathing tube. The airflow creates a slight positive

pressure which together with the sealing to the face

prevents particles and other contaminants from

entering the head top.

(15) All PPEs (as per ISI/DGMS/CE/EN/ANSI approved only) Should issued by

party/agency/contractor to their contractor workers as per nature of job and

allotment of PPE list shall be submitted to Safety Officer, Dhuvaran on his letter head

as per below mentioned format by Contractor before commencement of work through

concerned JE,DE,EE/SE .

Sub: Issue of PEE to Contractor workers

Sub of work Order:

Name of Agency:

Date of Commencement:

Time limit for work order:

Sr. Name Desi Name of Name of PPE IS Make Qt Unit Date Rec

no. of gnati Section :Code of PPE y of eivi

worke on under no. of issue ng

rs work PPE sign

Reusable Ear Pair

Safety Shoes Pair

(16) Shift Security Inspector/Security Officer shall be checked Safety Shoes & Safety

Helmet of all contractor workers at entry gate of Factory Premises & shall entered

contractor workers with Safety Shoes & Safety Helmet with photo ID Gate Pass.

(17) Shift Security Inspector/Security Officer shall be checked validity of Gate pass of all

contractor workers on daily basis.

(18) During the work execution, one trained & competent supervisor of agency should

always remain present at work site. Concern JE/DE of GSECL shall be supervised the

contract work as per SOP .

EW- 313 PUR-F-006 RFQ-

(19) Approved NABL laboratory calibration certificates of electrical/mechanical/Civil/

C&I/Environment survey/Chemical etc measuring /testing equipments/instruments

which are used during contract work shall be submitted before starting the work &

shall be checked by concern JE/DE/EE before starting work & it’s record shall be

maintained in concern section.

(20) The contractor shall take all the required safety measures prior to commencement of

work on dangerous substances, machineries or area at which cautionary notice is

displayed and obtain “Line Clear” or “Work Permit” through the concern Department

/ Section JE/DE and shall be informed to concern section JE/DE for closed/

returned after completion of work.

(21) Safety talk/Safety work instructions shall be given to contractor workers by concern

JE/DE regarding hazards of specific work, risk & it’s control measure (mentioned in

HIRA) before starting the job work and records shall be maintained for each & every

(22) Display Safety instructions shall be strictly followed by all workers who are working in

factory premises.

(23) Material Safety Data Sheet (MSDS) of each chemical shall be available with Chief

Chemist/Control room & work related Chemical information shall be taken by

contractor & contractor workers from Concern EE/Chief Chemist before starting of

chemical handling work.

(24) The contractor shall be checked & securely covered or securely fenced any opened

fixed vessel, sump, tank, pit or opening in ground or in floor which, by reason of its

depth, situation, construction or contents ,is or may be a source of danger before

starting the work each & every days or after interval/recess. Contractor supervisor

shall be informed to concerned HOD regarding any unsafe conditions.

(25) Prohibition of smoking, fires, lights, spontaneous ignition substance, matches; fuses,

mobile phone etc are to be strictly followed by all workers who are working in factory

(26) Prior to carrying out welding, gas cutting, furnace heating or any other hot work job,

remove all the inflammable material lying at or nearby worksite or cover it properly by

suitable protective covering. Also, special care shall be taken before carrying out such

job & see that all possible contributing factors to set fire shall be removed / vanished

prior to commencement of the work. Advance intimation shall be given to concerned

section / fire section to commence the work in fire prone areas. They should also

keep ready all the First Aid Fire Extinguishers / equipments & fire extinguishing

media / material like sand / water buckets or other appropriate equipment at such

(27) While carrying out work in confined space or inside vessel, obtain necessary

“Confined Space / Vessel Entry Permit” from concerned department prior to

commencement of the work.

For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp

shall be used. For taking care of the persons working inside the confined space /

vessel, a supervisor / person capable to keep continuous watch on person(s) working

inside, assist them in case of emergency or arrange to get immediate outside help,

shall remain present at entry point. Use full body safety belt without failed.

While working inside sewage, trench or in-depth, a person to warn outsiders /

entrants / passers etc shall remain available near entry point or the entry point shall

be cordoned by a barricaded tape with a cautionary notice. After completion of the

works, all the lids / covers / grills / grits opened, shall be re-fixed / re-placed in the

original position as it were prior to commencement of the work and leave the work

place in safe condition in all respect, so as to prevent accident to fellow workers.

(28) The contractor shall see that he / his persons do not work on or block (by stacking

material, spare parts, tools-tackles, equipments etc), any passages / walkways /

gangways / aisles / staircases / ladders / lifts or any other approaches / roads

leading to plans or its auxiliaries, on which there is traffic movements or possible

EW- 313 PUR-F-006 RFQ-

traffic movements in case of emergency. Such passages are meant for safe escape in

the event of emergency. If it is utmost necessary to carry out work in such area with

blocking of passage, prior permission of Competent Authority or the Engineer-In-

Charge shall be obtained. To demarcate / declare the area as “UNSAFE”, cordon it

using barricading tape & display suitable caution notice or keep a person to restrict /

divert the traffic on this route through other safe passage.

(29) The contractor shall see that he / his persons do not work on or block (by stacking

material, spare parts, tools-tackles, equipments etc), any passages / walkways /

gangways / aisles / staircases / ladders / lifts or any other approaches / roads

leading to plans or its auxiliaries, on which there is traffic movements or possible

traffic movements in case of emergency. Such passages are meant for safe escape in

the event of emergency. If it is utmost necessary to carry out work in such area with

blocking of passage, prior permission of Competent Authority or the Engineer-In-

Charge shall be obtained. To demarcate / declare the area as “UNSAFE”, cordon it

using barricading tape & display suitable caution notice or keep a person to restrict /

divert the traffic on this route through other safe passage.

(30) Prior to use power / electrically operated hand tools / equipments / machines /

gadgets like welding machine, hand grinder, hand drill etc, ensure for its safe

operation & use it only if it is found safe to use. Do not use defective, unsafe or

improperly maintained equipments.

The electrical power supply required to run such equipments shall not be taken

directly at their own but shall be obtained through concerned Electrical Maintenance

Departments or their authorized persons or under their observations / guidance only.

The Electrical Section shall provide temporary electrical connection up to contractor’s

Mains Board on which it is compulsory to install mains switch, ELCB & fuses of

adequate capacity. All such equipments shall invariably be earthed adequately to

prevent electrical shock, sparking, short circuit etc. Power cord to be used shall be of

adequate capacity, without any joint & shall consist of earth wire also. Hence, it is

necessary to use adequate capacity 3-wire power cord for single & 5-wire power cord

for three phase power connections. The plugs, receptacles, pins, holders etc shall be

of adequate capacity & safe to use.

All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting

machine, Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used

during work execution shall be of standard make & bear ISI certification mark on it.

The consumables like welding electrodes, grinding wheels / discs etc which has

specific prescribed life span shall not be used in any case if its expiry date is over.

(31) Non-Sparking Non-Magnetic electrical hand tools and tool kits shall be used by

Electrical contractor for safe use in areas where hazardous, flammable, or

combustible vapors, liquids, dusts, or residues may be present in Gas Based power

plant and list of tools and tackles shall be submitted with technical bid. Non-Sparking

Non-Magnetic electrical hand tools and tool kits shall be checked by JE/DE before

commencement of Electrical work.

(32) Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift,

mobile crane, EOT crane etc) & its attachments (like D-shackles, slings, U-clamps,

Eye bolts or any fixtures), it shall be checked and used only if found safe to use. Also,

ensure that these are tested, examined & certified in form no.10 by Competent Person

as per the Factory act-1948 & Gujarat Factories Rules and its validity do not expire.

Further, it shall be fixed properly and firmly prior to lifting the weight. Valid Test

certificate of all Lifting machines used by Contractor to be submitted to

Dy.Safety Officer/ Safety Officer before commencement of work through

concerned EE/SE.

(33) Metal Scaffoldings to be used for working at height shall be of adequate size &

capacity. Obtain the work permit when working at height. While climbing on such

scaffolding or working on any structure at height, use of full body safety belt /full

EW- 313 PUR-F-006 RFQ-

body hardness with double lanyard & Fall arrestor & Helmet is compulsory. It is also

necessary to fasten chinstraps of the helmet.

(34) Contractor or their employee shall not interfere in day-to-day routine plant activities /

works except the work assigned to them, shall not loiter in the areas other than their

work jurisdiction, as well as shall not temper / operate / touch the

machineries/equipments/auxiliaries with which they are not concerned. Also, the

contractor shall strictly instruct their staff for not to sit or take rest at/near/below

running plants, auxiliaries, systems or any place which is risky, hazardous & prone

(35) The cylinders containing poisonous / toxic or inflammable / explosive gas like

Oxygen, Acetylene, LPG, Hydrogen, Ammonia, Chlorine, CO 2 etc shall be handled

safely taking due care. To handle / shift such cylinders a special trolley /cage meant

for it must be used but in no case it should be rolled.

(36) In Gas Based Power station/Hydrogen storage area /Hydro carbon fumes-vapour

generated area, Spark arrestor (as per approved manufacturer of CCOE, Nagpur) shall

be provided on each vehicle by party/agency and it will check by shift security in

charge before entry of vehicles in the factory premises.

(37) No women or young person shall be employed or permitted to work in Lead-

compound area like battery room etc. as per schedule VI of GFR

(38) No women or young person shall be allowed to clean, lubricate or adjust any part of a

prime mover or of any transmission machinery while the prime mover or transmission

machinery is in motion. Examination or operation of motion machinery shall be made

or carried out only by a specially trained adult male worker wearing tight fitting

clothing as per section 22 of factories act

(39) In all risky job, before start the work, contractor should obtain General Safety Work

Permit through concerned section from Shift –in-charge well in advance.

(40) In case of noticing smoke or fire during their work execution, they shall make

immediate efforts to extinguish / control it and simultaneously inform the Fire

Station Mobile No as well as Station Fire Officer or Emergency Control room no which

is displayed at prominent place of factory like Main Security Gate, All unit control

room, Canteen area, Safe Assembly points, Fire Station, All security gates,

Occupational Health Centre.

(41) In case of any injury / accident while working, it shall immediately be reported to

Safety Department through concerned Sectional Head / Engineer. The prescribed

Form No. 21 & ANNEXURE may be obtained from concerned section or Dy.Safety

Officer/Safety Officer.

In case of any electrical accident, it shall immediately be reported to Electrical Safety

Officer through concern Sectional Head / Engineer. The prescribed Electrical

accident form no. A as per electricity act-2003 & Form No. 21 & ANNEXURE as

per Gujarat Factories rules shall be filled up by concern department JE/DE with

written consent of contractor. The Form may be obtained from concerned Electrical

section or Electrical Safety Officer. Electrical accident investigation shall be carried

out by Electrical Safety Officer with Factory Manager.

After any reportable accident, Contract agency shall be submitted the fitness

certificate of injured person with endorsement of GSECL factory Medical Officer to

LWO/Dy.Safety Officer/Safety Officer/Electrical Safety Officer then after injured

person may allow for work.

(42) For any incident occurred but have no injury to any persons should also reported as

per GSECL format and informed to Dy.Safety Officer/Safety Officer as Near Miss

(43) Safety penalty shall be imposed against Offences by contract workers: If any

contract worker worked in a factory contravenes any provision of Factories act or any

rules or orders made there under ,imposing any duty or liability on workers,

contractor/agency shall be punishable with fine which mentioned as under.

EW- 313 PUR-F-006 RFQ-

Sr. Description of penalty Amount

(i) Work without PPEs Rs.300/- per person

(ii) Work without work Safety permit like working at Rs.1000/- per day

height, confine space entry, hot work etc.

(iii) License of driver as per type of vehicles not Rs.750/- per person

(iv) Welding work without flashback arrestor/double Rs.1000/- per set

gauge regulator set

(v) Operate Portable power tool without ELCB Rs.1000/-per

(vi) Work without qualified Supervisor as per nature Rs.1000/-per day

of job like mechanical, electrical, civil, C&I,

(vii) Work without SOP & JSA Rs.2000/-per day

(viii) Work without test report of lifting machines / Rs.2000/- per

tackles (like C.P.Bs., Hook chooks, winch, forklift, equipment

mobile crane, EOT crane etc) & its attachments

(like D-shackles, slings, U-clamps, Eye bolts or

any fixtures) in Form No.10 of Gujarat Factories

(ix) Work without Double lynyer Safety belt during Rs.3000/-per person

working at Height work, work without anchoring

in hook/line line

(x) Work without 24 Volt supply in Confine space Rs.3000/-per person

(xi) (a) Grinding machine used without safety Rs.500/-per

guard/machine guard equipment / per set

(b) unsafe welding machine like open body, Knob

without insulation, connection without lug

(c) damaged welding cables/gas pipelines

(d) welding work doing without welding blanket,

(e) electrical supply without 3 pin plug/Industrial

(f) use of damaged electrical wire for lighting/

(g) use of lighting lamp without cage,

(h) use of open halogen tube,

(i) use of damaged PPEs/use of non Standard

(j) Unsafe lifting and handling of gas cylinders

(k) Cylinder handling without safety cap

(l) Temporary connection without ELCB, etc.

During plant visit/supervision of concern JE/DE/EE, SE, Safety Officer/Dy.Safety

Officer, Electrical Safety Officer, Factory Manager, If they will observed any safety

violations as per CO circular/statutory requirements then they must impose Safety

Penalty through office note directly against contract workers/ contract agency and

Office Note process through proper channel to concern Sectional head and Account

head for recovery purpose. Photograph/CCTV footage is to be put up with penalty note

by imposing officer.”

(44) Party will damage any fire equipments or property or machinery in factory during

execution of work, total damage cost will be recovered from party RA bill and recovery

Office note put up by concern HOD.

EW- 313 PUR-F-006 RFQ-

(45) All the relevant labour and industrial laws shall also be followed compulsorily.

(46) After completion of work, cotton waste, grease, oil, unused material, welding rod

pieces, scrap etc. are to be removed by contractor and scrap shall be deposited to

scrap yard of Main Store.

(47) For performance evaluation of contractor, safety factors of work accident, fire incident

& near miss accident will be considered. Steps can be taken to review the job

assignment up to cancellation for negligence.

(48) Over & above these, contractor shall have to follow all the safety requirements /rules

& regulations / norms and legal provisions laid down in various statutes. Particularly

the provisions of The Factories Act-1948 & the Gujarat State Factories Rules-1963

(Amended up to date), The Electricity Act-2003 & rules, BOCW Act/Rules shall be

followed strictly. The contractor shall also obey the rules / regulations / instructions

of the local Competent Authority for safety & health requirements.

(49) The above rules shall be scrupulously followed and where required, Contractor

/contractor workers may contact to the Dy.Safety Officer/Safety Officer/Electrical

Safety Officer in case of any ambiguity or needs further guidance in this regard.

Chief Engineer (G)

GSECL: Gandhinagar TPS

Dated seal & signature of

Bidder/Contractor

EW- 313 PUR-F-006 RFQ-

Terms and Conditions regarding Labour Laws

During the entire period of the contract, the Contractor and his SubContractor shall at all

times comply with all applicable labour laws, rules, regulations, notifications, and bye-laws

issued by the Central Government, State Government, or Local Authorities. This includes

all existing laws as well as any amendments or new notifications that may come into force

during the contract period.

The Contractor and his Sub-Contractors shall, at all times abide by the following

Act/statutes related to Human Resources:

1. Factories Act, 1948;

2. Contract Labour (Regulation & Abolition) Act, 1970;

3. EPF & MP Act, 1952;

4. Building & Other Construction Workers (Regulation of Employment & Conditions of

Service) Act, 1996;

5. ESI Act, 1948;

6. Minimum Wages Act, 1948;

7. Payment of Wages Act, 1936;

8. Payment of Bonus Act, 1965;

9. Payment of Gratuity Act, 1972;

10. Workmen's Compensation Act, 1923;

12. Maternity Benefit Act, 1961;

13. Inter-State Migrant Workmen (Regulation of Employment & Conditions of Service)

14. The Building And Other Construction Workers' Welfare Cess Act, 1996;

15. The Carriage by Road Act,

The above list is only indicative and not exhaustive. The Contractor shall remain fully

responsible for ensuring compliance with all other applicable labour and welfare

legislations, rules, and regulations in force during the contract.

The following are some of the major responsibilities of the contractor, in addition to other

obligations prescribed under various labour laws, rules, and regulations issued by

statutory authorities such as the State Government or Government of India from time to

time, which the contractor shall strictly comply with during the execution of the contract.

1) The Factories Act,

The contactor should not deploy worker below the age of 18 years and above 60 years

for the awarded work.

Earn Leave shall be paid to their bonafide contract workers as per the provisions of

the Factories Act,

Payment of Earned Leave should be made monthly together with wages for better

compliance of law. The contactor shall maintain Earn Leave Register in Form No.

as per the provisions of the said Act and submit the same on demand.

All the written registers, Performa etc. shall be maintained up to date and kept ready

for inspection at any time or submitted on-time to the concerned authorities as per

applicability of the Acts by cotractor.

2) The Contract Labour (Regulation and Abolition) Act,

The Contractor / Agency shall have to obtain the Labour License under Contract

Labour (Regulation & Abolition) Act from the appropriate authorities before

commencement of work. The contractor tor shall maintain a valid labour license

under the Contract Labour (Regulation and Abolition) Act for employing necessary

man power to be required by contractor.

EW- 313 PUR-F-006 RFQ-

The contractor should not be allowed to engage fifty (50) or more contract labourers

without initiating to obtain the labour license under the Contract Labour Act. (the

said number i.e., fifty (50) or more includes Supervisor and other staff).

3) Minimum Wages Act,

Contractor shall have to make the payment of wages to the Contract Labours engaged

by them, on or before 7th of every month through nearest Nationalized Bank

compulsory, preferably situated in the premises of TPS area in case of all works

contract. The Contractor shall supply copy of Bank Statement duly stamped by the

Concerned Bank as well as debited entry of amount displayed in the contractors' own

bank account as token of proof towards payment of Wages through CLIM/prevailing

system at relevant time. Apart from Payment of wages through Bank, Contractors

shall have to make all other payments like Advances, Bonus, Leave Encashment etc.

to their labours through bank only and cash payment entry will not be allowed.

Wages rates for contract laborers are applicable as per the terms and conditions of

the license. The contractor shall have to pay wages to workers as notified by the

Government of Gujarat from time to time.

Any default to pay the minimum wages to the engaged workers and deprived of their

right to minimum wages payment on or before 7th of each month shall be dealt as per

the provision of labour laws. Recurrence of the same may lead to cancellation of

awarded contract.

4) The Provident Fund and Miscellaneous Provisions Act,

The contractor must possess separate P.F. code on the name of the Firm /Agency

/Company itself for the subject work.

It should be ensured that all the contract labours engaged by contractor are covered

under the provident fund scheme and employee's pension scheme and their

contribution must be remitted regularly to the concerned RPFC. The photocopies of

challan along with ECR in this regards should be submitted regularly to the User

Department to enable their onward billing clearance.

The contractor shall submit along with his bill (month wise) statement regarding

deductions against employees' provident fund and family pension scheme in respect

of each concerned employee' Provident fund and family pension scheme at the rate of

12 %o of wages (or at the rates made applicable by the Government time to time). The

contractor's contribution and his workers contribution towards provident fund and

family pension scheme shall deposited by the contractor with concerned PF

5) Workmen's Compensation & Employer's Liability Insurance.

The contractors shall have to obtain Employee Compensation Policy under the

Employees Compensation Act before starting the work. Employee Compensation

Insurance shall be obtained for all the workers engaged for the execution of awarded

contract. If any of the work is sub-letted the contractor shall ensure that the sub-

contractor take and provide workmen's compensation and Employer's liability

insurance for the labours engaged. Contractor is liable to pay compensation in case of

accidental injury arising out of and in the course of employment as per the said Act

and shall bear medical expenses due to on duty accident.

6) The Payment of Gratuity Act,

For better compliance, contractor shall pay amount of gratuity on a monthly basis

along with the payment of wages, calculated on a pro-rata basis per month, which is

equivalent to 15 days' wages for each completed year of service for every worker. (*

applicable to ARC / BRC works contract only)

7) The Payment of Bonus Act,

Every worker shall be entitled to be paid by the contactor in an accounting year,

bonus, in accordance with the provisions of this Act, For better compliance, the

contractor should pay bonus amount on a monthly basis along with wages calculated

on a pro-rata basis per month. Contactor has to submit the paid bonus details of its

EW- 313 PUR-F-006 RFQ-

worker in Form No. C as per the provisions of the said Act as and when required by

the Govt. Authority as well as by GSECL.

8) The Maternity Benefit Act,

Contractor shall ensure that entitled female worker should provide Maternity Leave

and other benefits as per the provision of the said Act.

9) The Building and other Construction Workers' Act,

For any construction work, fall under the definition of Section 2(1) d), happening

outside / inside the Factory premises the said act will be applicable and the contactor

or its sub-contactor shall be liable to comply with the provisions framed there under.

10) The contractor shall give preference to existing or local contract workers for

engagement in the awarded contract and shall issue appointment orders to each and

every workers individually at the time of their engagement during the period of

contract and terminate the same at the end of the each contract.

Follow the mentioned procedure for each milestone for the execution of works

11) On Commencement of Contractual Work

1. Before starting the work, the contractor may contact Labour Welfare Officer /

Industrial Relations Officer for all formalities related to labour law compliance

before commencement of the contract and onward Labour Law compliance

thereof,, so that later no dispute will arise in respect of compliance of labour laws.

2. It is the responsibility of the contractor to ensure that contactor’s employees

maintain strict discipline as regards security, methods of safe working etc., and

not to cause any hindrance to smooth running of power station or in execution of

duties by GSECL staff Any lapse in this regard will be viewed seriously and if

lapse found, contact is liable to be terminated. If any of contractor's staff is found

unsuitable or not behaving properly, the contractor shall have to remove such

worker from the work-site on demand by EIC. To maintain harmonious industrial

relations amongst contact labours is solely the responsibility of contractor. Any

breach of the same will be viewed seriously.

3. A digital system developed at the request of the agencies working at the premises

of GSECL, is to facilitate them for easy, efficient, effective management of data,

gate passes, attendances, medical records, Police Verification documents etc.

related to their employees / workers deployed for various works and services

against work order of GSECL.

4. On receipt of LOA and before commencement of work, authorized representatives

of the agency shall login in the CLIMS online portal / prevailing system at

relevant time and apply for registration of their employees / workers uploading all

information with required documents in digital form. Upon completion of due

verifications, clearance by EIC and HR departments, contracting agency will

obtain gate passes. GSECL will only consider documents like wage sheet duly

accepted and signed by individual workers, as per the engagement/deployment

duration/hours of individual worker duly certified by the agency, being the

employer, for the purpose of payment of bills and HR clearances.

Agency shall be solely responsible for maintaining accurate and upto-date data of

their workers in the portal/ prevailing system at relevant time. All statutory

compliances under prevailing laws shall remain the responsibility of the

contracting agency. The agency shall indemnify/ GSECL against any liabilities

arising from non-compliance of legal provisions or inaccuracies in the data

maintained by them in the digital portal of CLlMS/prevailing system at relevant

5. The Contractor who intends to engage labours more than the specified limit under

law, then necessary - Form No. V under the Contract Labour (R & A) Act, 1970 or

Form No. VI under the Interstate Migrant worker (employment regulation) Act

1979 as applicable is to be obtained for the purpose of obtaining Labour License

from the Licensing Authority.

EW- 313 PUR-F-006 RFQ-

6. It shall be the duty of the Contractor or his Supervisor to ensure Bio-Metric

punching and reporting at the location of work.

7. The contractor shall employ adequate number of experienced staff at site for daily

supervision and for maintaining of various registers and records required under

the Labour laws and contracts. No payment for such supervision shall be

8. The gate passes obtained for any specific work order will be valid for that specific

work order only and contractor should not divert the man power for any other

work order. If any work or part thereof is desired/required to sublet, the contactor

shall obtain the necessary permission of EIC in black and white well in advance

which is mandatory for considering the statutory documents of agency other than

the agency who awarded work order.

12) During Contractual Work under the progress:

1. All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized

Bank compulsory, preferably situated in the premises of power station area. The

Contractor shall supply copy of Bank Statement duly stamped by the Concerned

Bank as a token of proof towards payment of Wages through CLIMS / prevailing

system at relevant time.

2. All Contractors has to comply & maintain statutory documents / registers under

the provision of labour laws & EPF Act.

3. In case the contractor having more than one contract in the same TPS, the

contractor shall have to obtain work order wise separate Gate Passes and submit

the same with the documents of statutory compliance that too work order wise

every month to the User Department to enable their onward billing clearance.

13) CONTRACTORTO II\TDEMNIFY THE GSECL REGARDING LABOUR LAWS

The contractor shall indemnify and keep indemnified the GSECL, and every member,

officer and employees of the GSECL, also Engineer-in-charge and his staff against all

actions, proceedings, claims, demands, costs and expenses whatsoever arising out of

or in connection with the matter referred in above clauses and elsewhere and against

all actions, claims demands, cost and expenses which may be made against the

GSECL by any workman/ employees of contractor or any sub-contractor and or from

any liability any wise to any workman/employees of the contractor or sub-contractor

under any laws, rules or regulation having in force of law including but not limited to

claims against the owner under employee compensation Act, 1923. The Employee's

Provident Fund Act.l952, and/or the contract labour (Abolition and Regulation) Act,

The GSECL shall not be liable for or in respect of or in consequence of any accident or

injury to any workmen or other person in the employment of the contractor or his

sub-contractor, and the contractor shall indemnify and keep indemnified the GSECL

against all such damage and compensation and against all claims, demands

proceedings costs, charges and expenses whatsoever in respect of or in relation

The contractor shall at his own expense / risk and cost to comply with all the labour

laws as above-mentioned and keep the G.S.E.C.L. indemnified in respect thereof.

GSECL : shall be entitled /empowered to deduct directly from the bills, the amount to

be paid to engaged bonafide contract workers or the contract workers engaged by

Sub-contractor any sum or sums payable by main contractor / sub-contractor and

which sum/sums the Corporation is required to pay in capacity of Principal Employer

on account of the default of contractor in respect of all liabilities incurred out of non-

compliance regarding any provisions of Labour Laws and same amount shall be

recovered from the pending dues of the contractor with 15% administrative charges.

EW- 313 PUR-F-006 RFQ-

Any other rules and regulation, conditions, circulars etc., that are in force at present

and that may be famed by the G S E C L from time to time in connection with

contracts will be binding and acceptable to contractor. The above are some of the

major liabilities of the contractor in addition to other liabilities prescribed under the

various labour laws in force from time to time from Statutory Authorities like State

Government / Government of India, which the contractor shall have to comply with.

The contractor shall provide the name of authorized representative, as provided to

other statutory Government authorities and will be notified to Engineer In-Charge

14) Submission of Statutory documents to ensure the compliances:

The contractor shall upload statutory documents, work order-wise, under Labour

Laws and EPF in CLIMS / prevailing system at relevant time. Required documents

shall be uploaded by the contractor in existing portal /prevailing system at relevant

time invariably each month to Engineer In-Charge for onward process and smooth

clearance by HR Department.

List of documents required for gate passes of contract workers through clims /

prevailing System.

Sr. Description of documents attached

1 Copy of Work Order

2 Copy of P. F. Code No.

3 insurance Policy as per subject of work order under the Workmen

Compensation Act,

4 Contract agreements/ subletting work contract documents with

5 Copy of Id proof of Aadhar card or Election voting card or driving

license or Passport only

6 Copy of Police Verification in respect of each contract workers

16. The contractor whose work order value is above Rs. 5 lacs shall have to submit

‘Declaration cum Indemnity Bond’ on Rs. 300/- Non-Judicial stamp paper in

prescribed Performa (Annexure- ‘B’) with Agreement and Indemnity Bond before the

commencement of the contract.

EW- 313 PUR-F-006 RFQ-

DECLARATION CUM INDEMNITY BOND

(On Rs.300/- Non Judicial Stamp Paper duly notarised)

THIS DECLARATION CUM INDEMNITY BOND made at_____________________

(mention location) by M/S. ________________________________________________ having its

Reg. office at___________________________(hereinafter referred to as “Contractor” which

expression Shall unless it be repugnant to the context or meaning thereof, be deemed to

mean and include their respective assigns, successor, executors, subcontractors and/or

administrators) of the ONE PART in favour of M/S Gujarat State Electricity Corporation

Limited having its power Station at Gandhinagar Thermal Power Station (hereinafter

referred to as the “Company”), which expression shall unless it be repugnant to the

context or meaning thereof be deemed to mean and include its assigns, successors) of the

WHEREAS the COMPANY has entered into a contract with the Contractor for the work of

_____________________________________dated_____________“hereinafter called the “Contract”);

AND WHEREAS it is one of the essential conditions of the Contract that the Contractor

shall comply with all the provisions of the Labour& Industrial Laws, as may be applicable

from time to time for the discharge and completion of the works and completion of the

Works and Services covered under said Contract Labour (R & A) Act 1970, Child Labour

(Prohibition and Regulation) Act 1986, The Employees Provident Funds & Miscellaneous

Provisions Act, 1952, Employees State Insurance Act 1948, Minimum Wages Act,

Payment of Bonus Act, 1965, Payment of Wages Act, 1936, Employees Compensation Act,

1923, Factories Act, 1948 and other Labour Laws, Rules, Notifications and Codes which

are at present applicable to the contractor and which may be applicable during the tenure

of the contract (hereinafter referred as the ‘Laws’).

AND WHEREAS the Contractor has agreed to execute this Declaration cum Indemnity

Bond to this effect and has agreed to indemnify and Company, it’s Directors, Officers and

employees and representatives indemnified and hold harmless against all third party

claims, charges, penalties, fines, expenses, losses, damages costs, suits or any other levy

against the Company and/or the management due to the failure of the Contractor to

observe or follow all applicable laws.

NOW THIS DEED WITNESSETH AS UNDER:

1. The Contractor hereby declares that all acts, deeds, actions, activities, conduct and

lapse, delays, misdeeds, faults, breaches, inactions etc done by his assigns,

successors, executors, subcontractor and/ or administrators shall be construed to be

have been done by the contractor and he alone shall be liable for such acts, inactions

2. In consideration of the Company awarding the Contract to the Contractor subject to

the condition of execution of this Declaration cum Indemnity bond, the Contractor

declares and represents to the Company that the Contractor has obtained all Statutory

registrations, Certificates, licenses and approvals required under the Laws enabling the

Contractor to execute the Contract in a legal and lawful manner.

3. That in the event of any liability arising out of failure to observe or non-compliance of

any such „Laws‟ by the Contractor in connection with the Performance of the contract,

the Contractor shall bear all the resultant whatsoever liability(ies), if any arising out

thereof and that the company, its Directors, Officers and employees, representatives,

shall not be liable for any such liability(ies). The Contractor agrees to indemnify and

EW- 313 PUR-F-006 RFQ-

keep the Company and its Directors, Officers and employees, representatives

indemnifies, defend and hold harmless, against all losses, costs, damages, claims,

penalties, interest, expenses, demands, fines, legal liability, causes of action, injury to

persons, suits etc., which may be suffered, incurred, undergone and / sustained by the

Company including the Costs and expenses that may be incurred in defending any

such liability(ies) claim(S), Proceeding (S) etc. that maybe made or taken or taken or

arise on the same by any Person, body, authority, government, judicial / quasi -

judicial authority due to the failure or non-compliance of any such laws and rules

there under (including any amendments in acts, laws, statutes & rules there under) of

whatsoever kind and nature arising out of or in any way connected with, whether or

not such acts or omissions are actual or alleged, active or passive with regard to the

discharge of the said Contract.

4. The Contractor further declares that in case of any suit / claim / right / damages /

compensation / fine / levy / charges / expenses / losses / penalties / costs raised by

the third party, including contract labours engaged by the contractor, he shall join

such proceedings in such Suit/Court/Tribunal/Authority and effectively defend the

5. The Contractor hereby agree and undertakes to make good any loss, damage, claims,

suits, demands, decrees, expenses that the Company may suffer to the fullest

satisfaction of the Company and if the Contractor fails to make good the same then the

Company shall have the right to recover the same and or any other loss sustained,

without any restriction or limitation, together with any other incidental expenses,

costs, and all incidental logistic expenses etc that may be suffered by the Company

from the Contractor and the Contractor hereby further confirms and declares that this

Declaration cum Indemnity Bond is irrevocable and shall be final and binding on it /

him heirs, executors, administrators, legal representatives, successors, subcontractors

and assigns, wherever the context applies. any claims, demands, shall be adjusted

against any amount due and payable to the Contractor and the Company shall have

the right to withhold any amounts due and payable to the Contractor, till the

settlement of such claims, disputes to the Contractor towards discharge of such

claims, obligations etc.

6. This Declaration cum indemnity bond shall be in accordance with the laws of India and

any dispute between the parties with regard to this Declaration cum Indemnity Bond

shall be resolved through the dispute resolution process mentioned in the General

Conditions of the Contract (GCC).

IN WITNESS WHEREOF, the said Contractor has hereunto set their hand the day and year

first hereinabove written.

SIGNED SEALED AND DELIVERED By the within named “CONTRACTOR”

(Authorised Signatory)

Rubber Stamp of Firm/Company

EW- 313 PUR-F-006 RFQ-

In presence of Witness

Name & Address of Witness Signature

Residential Address:

Residential Address:

EW- 313 PUR-F-006 RFQ-

GUJARAT STATE ELECTIRICITY CORPORATION LTD., GANDHINAGAR

TENDER & CONTRACT FOR WORKS

GENERAL RULES AND DIRECTIONS FORTHE GUIDANCE OF CONTRACTOR

Notwithstanding anything contained to the contrary in the specification or tenders in

subsequent exchange of correspondence, the conditions of contract shall be binding on

the contractor and any change of variation expressed or implied however made in the said

conditions shall not be however valid or operative unless expressly sanctioned by the

corporation The contractor shall be deemed to have fully informed himself and to have

special knowledge of the provisions of the conditions of contract herein contained.

1. All works proposed to be executed by contract shall be notified in one of the English

and one of the vernacular local daily newspapers stating the work to be carried out as

well as the date for submitting and opening tenders and time allotted for carrying out

the work also the amount of earnest money to be deposited with the tenderer and the

security deposit to be deposited by the successful tenderer.

2. Copies of the specifications, designs drawings, estimated rates. Schedule rates and any

other documents required in connection with work which will be signed by the

Executive Engineer for the purpose; of identification shall be open for inspection by the

contractors at the office of the Executive Engineer during office hours.

3. Where the works are proposed to be executed according to the specification

recommended by a contractor and approved by a competent authority on behalf of the

Gujarat State Electricity Corporation Ltd. Such specification with designs and drawings

shall form part of the accepted tender.

3 The tender and receipts for payments made on the account of any work, when executed

by a firm, should be signed by all the partners except where the contractor are

described in their tender as firm in which case the receipt shall be signed in the name

of firm including the Partners or some other persons; having authority to do so.

5. Any person who submits tender at percentage rate shall fill up the usual form stating

what percentage above or below rates specified he is willing to undertake the work. Only

one rate or such percentage on all the estimated rates or scheduled rates shall be

6. Tenders which propose any alteration in the work specified in the form invitation to

tender or in the time allowed for carrying out the works or which contain any other

conditions of any sort, will be liable to rejection.

7. No single tender shall include more than one work. but contractors who wish to tender,

for two or more works, shall submit a separate tender for each work. Tender shall have

the name and the number of the works of which they pertain be subscribed on the

8. The Executive Engineer or his duly authorized assistant will open tenders in the

presence of any intending contractors who may be present at the time and will enter the

amount of the several tenders in a comparative statement in a suitable form. In the

event of tender being accepted the contractor shall thereupon, for the purpose of

identification, sign copies of the specifications and other documents. In the event of

tender being rejected the officer (Executive Engineer ) shall authorize the paying officer

to refund the amount of the earnest money deposited to the contractor making the

tender on his giving for the return of the money.

9. The officer competent to dispose off the tenders, shall have the right of rejecting all or

any of the tenders without assigning any reasons thereof.

10. No receipt for any payment alleged to have been made by a contractor in regard to any

matter relating to tender of the contract shall be valid and binding on the corporation

unless it is signed by the Executive Engineer.

11. The memorandum of work to be tendered for and the schedule of materials to be

EW- 313 PUR-F-006 RFQ-

supplied by the Gujarat state Electricity corporation Ltd. and their rates shall be filled

in and completed by the office of Executive Engineer before the tender form is issued if

a form issued to an intending tenderer has not been so filled in and uncompleted he

shall request the said office to have this done before he completes and delivers his

12. All work shall be measured, meet by standard measure and according to rules and

custom and usual in the use in the Gujarat state electricity corporation Ltd. and no

proposals to adopt alternative method will be accepted. The Executive Engineer's

decision as to what is the usual method in use in the Gujarat state Electricity

Corporation Ltd. shall be final.

13. Every contractor shall except the registered contractor on the approved list of the

corporation produce along with his tender a solvency certificate from the collector of the

District within which he resides or a bankers Certificate of his financial stability if he

fails to produce such a certificate his tender will not be considered.

14. All correction and addition or pasted slips should be initiated.

15. Tenderer shall be deemed to have full knowledge of all relevant documents site

conditions etc. whether inspected or not by him.

16. Submissions of a tender by a contractor implies he has read the instruction and

conditions of contract and has made himself aware of the scopes and specification of

the work to be done & of the conditions and rates at which stores etc. will be issued to

him and local conditions and other factors bearing on the execution of the work.

17. Under no circumstances shall any contractor be entitled to claim enhanced rates for

any items of contract without prior sanction of the competent authority.

18. These rules and directions shall form part of the contract.

I/We hereby tender for the GUJARAT STATE ELECTRICITY CORP.LTD. (herein referred as

"Corporation") of the work specified in the under written memorandum within the time

specified in Scheduled B (memorandum showing items of work to be carried out) and in

accordance in all respect with the specifications design drawing and instructions in writing

and as per annexed conditions of contract and agree that when the materials for works are

provided by the corporation such materials and rates to be paid for them shall be as

Provided in schedule A hereto.

(a) General description of work.

(b) Estimated cost.

(c) Earnest money.

(d) Security deposit:

(1) Party shall have to pay security deposit(if applicable) in the form of Bank

Guarantee/ Demand Draft in favour of GSECL payable at Gandhinagar within

days of date of issue of Letter of Intent.

(2) Time allowed for the completion of work from date written order to commence. Should

this tender be accepted I/we hereby agree to abide by and fulfill all the terms and

provision of conditions of contractor annexed hereto as applicable and in default thereof

forfeit and pay to the corporation the sums of money mentioned in the said conditions.

Receipt No. date from the GUJARAT STATE ELECTIRICITY CORP. LTD. in

respect of sum of Rs. (The amount to be specified in figure & words,) Is herewith forwarded

representing the earnest money (the full value of which is to be absolutely forfeited to the

CORPORATION l/We not deposit the full amount Deposit of the said conditions/otherwise

the said sum of Rs. Shall be refunded on surrendering the original receipt.

Signature of the Contractor Address of the Contractor

EW- 313 PUR-F-006 RFQ-

Signature of witness Address of Witness

The above tender is hereby accepted by me on behalf of the Gujarat State Electricity

Corporation Ltd.

The Chief Engineer (Gen).

Superintending Engineer

Executive engineer

Or his duly authorized assistant.

EW- 313 PUR-F-006 RFQ-

GUJARAT STATE ELECTIRICITY CORPORATION LTD, GANDHINAGAR

TENDER & CONTRACT FOR WORKS

CONDITIONS OF CONTRACT

(a) The “contract” means the documents forming the tender and acceptance thereof

together with the document referred to therein or individual work order in the case of

term contracts including these conditions schedules and or additional conditions

attached to the form of tender or individual works, order, rate schedule the

specifications and the drawings and all these documents as applicable taken together

shall be deemed to form the contract.

(b) The “Tender Document” means the form of tender the applicable schedules and/or

additional conditions and the specifications and/or drawing as issued on the

contractors for the purpose of preparing tender.

(c) The expression "Works" or 'work when used in the condition of contract shall, unless

there be something in the subject or context repugnant to such construction means

the work or the work contracted to be executed under or in virtue of the contract

whether original or altered.

(d) The "Contractor” means the individual or firm or company. Whether incorporated or

not, undertaking the works and shall include his or its legal personal representatives

successors and permitted assignees.