Water proofing work

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

FINANCIAL INFORMATION

NAME OF THE CONTRACTOR

TURNOVER OF CONTRACTOR /BIDDER FOR LAST FIVE YEARS

Financial Analysis - Details to be furnished duly supported by figures in balance sheet/profit & loss account for the last five financial years duly certified by the Chartered Accountant,as submitted by the Applicant to the Income Tax Department(Copies to be scanned & uploaded).

S. No Financial Year Gross Annual Turnover on Construction Works/ Works Contract (Rs. In Lakhs) Profit/loss(Rs. In Lakhs) Remarks

Financial arrangements for carrying out the proposed work.

Solvency certificate from bankers of the bidder(attached sepearately in FORM-B)

Signature of the Bidder (s)

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

NAME OF THE CONTRACTOR

SOLVENCY CERTIFICATE DETAILS

S. No Type of solvency Name of Bank Solvency Amount in Lakhs Issue Date (dd-mm-yyyy)

Signature of the Bidder (s)

NOTE: This table is meant for data

1 The original bankers certificate should be on letter head of bank as per form-B of the tender document.

2 In case of partnership firm,certificate should include names of all partners as recorded with the bank

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

DETAILS OF ALL WORKS OF SIMILAR NATURE COMPLETED DURING THE LAST SEVEN YEARS AS ON THE BID SUBMISSION DATE

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location Owner of sponsoring organization Cost of work Rupees (in Lakhs) Date of commencement as per contract Stipulated date of completion Actual date of completion Litigation/arbitration case pending/ in progress with details * Name and address/telephone number of officer to whom reference may be made for the work Remarks

* Indicate gross amount claimed and amount awarded by the Arbitrator

Signature of the bidders(s)

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

Projects under Execution or Awarded

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location Owner of sponsoring organization Cost of work rupees in lakhs Date of commencement as per contract (dd-mm-yyyy) Stipulated date of completion (dd-mm-yyyy) Actual date of completion (dd-mm-yyyy) Percentage progress of work. Litigation/arbitration cased pending/ in progress with details * Name and address/telephone number of officer to whom reference may be made Remarks

(i)* Indicate gross amount claimed and amount awarded by the Arbitrator

(ii)Applicant may submit separate form for giving details of work(completed) for each year to fill up the details as above.Separate sheets if any shall be numbered in sequence.

(iii)The scanned copies of the work orders for each work be uploaded.BOQ shall be furnished at a later date on request.

(iv)Certified that the above list of works is complete and no work has been left-out and the information given is correct to my knowledge and belief.

(v)The hard copy of all similar works completed during last seven years as on the previous day of date of submission date shall also be submitted on or before due date.

Signature of the Bidder (s)

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

PERFORMANCE OF WORKS

NAME OF THE CONTRACTOR

S. No. Name of the work/Project and location AGREEMENT N0 Cost of work rupees in lakhs Final completion value in lakhs Date of commencement as per contract (dd-mm-yyyy) Stipulated date of completion (dd-mm-yyyy) Actual date of completion (dd-mm-yyyy) extension of time with or without levy of penality or to be decided Amount of compensation for delay levied amount of reduced rates Perfrmance -to indicate very good/good/fair/poor Remarks

1 quality finance tech prof resources Gen behaviour 10

* Indicate gross amount claimed and amount awarded by the Arbitrator

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

NAME OF THE CONTRACTOR

S. No. Description of the item Details Remarks

1 Contractors name with address

Contact person name

2 Legal status of the bidder (a)An Individual( b)Proprietary firm (c) A firm in partnership (d) A limited company or Corporation-Attach copy of Legal document

3 Names and Titles of directors & Officers with designation to be concerned with this work

4 Designation of Individual authorised to act for the organisation

5 Was the bidder ever required to suspend construction for a period of more than 6 months(If so,give the details)

6 Registration of contractors

Financial Limit

Date of Registration

Address of the issuing authority/to whom TDS is to be remitted

8 GST registration no

Address of Commercial tax office to whom GST deducted to be remitted

9 EPF registration No

10 ESI registration No

11 LIN registration no.

12 Has the bidder or any constituent partner ever abandoned the awarded work before its completion(If so,give the details)

13 Has the bidder or any constituent partner ever been debarred/blacklisted for tendering in any organisation(If so,give the details)

14 Has the bidder or any constituent partner ever been convicted by the court of law(If so,give the details)

15 Field of Civil Engineering Construction the bidder has specialisation and interest

16 Any other information considered necessary but not included above

Signature of the Bidder (s)

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

NAME OF THE CONTRACTOR

DETAILS OF TECHNICAL & ADMINISTRATIVE PERSONNEL TO BE EMPLOYED FOR THIS WORK

S. No. Designation Total Number Required Number available for this work Remarks

Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad NIT NO. AMD/C&ESG/ET-128/2025-26 Dt: 10.03.2026

DETAILS OF CONSTRUCTION PLANT AND EQUIPMENT LIKELY TO BE USED IN CARRYING OUT THE WORK

NAME OF THE CONTRACTOR

S. No. Name of equipment Nos. Capacity or type Age Condition Ownership status Current location Remarks

Presently owned Leased To be purchased Proposed to be hired

Signature of the bidder (s)

Select, Excess (+), Less (-) Less (-)

Tender Inviting Authority: Director, AMD, Hyderabad

Name of Work: Replacement of old water proofing membrane with new membrane on B-block roof and other allied works at AMD Office Complex, Begumpet, Hyderabad

NIT No: AMD/C&ESG/CHEM/ ET-128/2025-26 Date: 10.03.2026

Name of the Bidder/ Bidding Firm / Company :

Sl. No. Item Description Item Code / Make Quantity Units Estimated Rate in Rs. P Addition / Deduction Addition / Deduction Values Currency Convertion against each Item Quoted Currency in INR / Other Currency RATE inclusive of all taxes In Figures To be entered by the Bidder in Rs. P Excise Duty VAT Freight Charges ( Unloading & Stacking) Any Other Taxes/Duties/Levies Other Taxes 2 IIIrd Party i.e DGS&D / RITES etc Inspection Charges @0.34%+Service Tax Less for Cenvat Credit,if any respect of Supplies Under full Excise Duty Category

1 Providing and laying six courses water proofing treatment with bitumen felt over roofs consisting of first, third and fifth courses of blown or / and residual bitumen applied hot at 1.45, 1.20 and 1.70 kg per square metre of area respectively, second and fourth courses of roofing felt type 2 grade I (fibre base self finished bitumen felt) Six and Final course with aluminium paint Two or more coats . Note: the payment for aluminium paint will be made under relevant item. 2000 Sqm Excess(+) Full Conversion INR

2 Supplying and applying bituminous solution primer on roof and / or wall surface at 0.24 litre per sqm. 2000 Sqm Excess(+) Full Conversion INR

3 Painting with aluminium paint Two or more coats on new work of approved brand and manufacture to give an even shade . 2000 Sqm Excess(+) Full Conversion INR

4 Providing, mixing and applying SBR polymer (of approved make) modified Cement mortar of 12 mm average thickness in proportion of 1:4 (1 cement: 4 graded coarse sand with polymer minimum 2% by wt. of cement used) as per specifications and directions of Engineer-in-charge. 200 Sqm Excess(+) Full Conversion INR

5 Providing corrugated G.S. sheet roofing of 0.50 to 080 mm thick with zinc coating not less than 275 gm/m² including vertical / curved surface fixed with polymer coated J or L hooks, bolts and nuts 8 mm diameter with bitumen and G.I. limpet washers or with G.I. limpet washers filled with white lead, including a coat of approved steel primer and two coats of approved paint on overlapping of sheets complete (up to any pitch in horizontal/ vertical or curved surfaces), excluding the cost of purlins, rafters and trusses and including cutting to size and shape wherever required. 50 sqm Excess(+) Full Conversion INR

6 Brick work with common burnt clay F.P.S. (non modular) bricks of class designation 7.5 with Cement mortar 1:4 (1 cement : 4 coarse sand) in uperstructure above plinth level up to floor V level in all shapes and sizes 2.5 Cum Excess(+) Full Conversion INR

7 Painting with synthetic enamel paint of approved brand and manufacture to give an even shade Two or more coats on new work 75 sqm Excess(+) Full Conversion INR

8 Demolishing cement concrete Nominal concrete 1:3:6 or richer mix (i/c equivalent design mix) manually/ by mechanical means including disposal of material within 50 metres lead as per direction of Engineer - in - charge 0.5 Cum Excess(+) Full Conversion INR

9 Dismantling Asbestos Cement sheet roofing including ridges, hips, valleys and gutters etc., and stacking the material within 50 metres lead. 45 Sqm Excess(+) Full Conversion INR

10 Dismantling old plaster or skirting raking out joints and cleaning the surface for plaster including disposal of rubbish to the dumping ground within 50 metres lead 20 sqm Excess(+) Full Conversion INR

11 Removal of old water proofing membrane with bitumen felt over roofs including removal of all loose particles. 1800 Sqm Excess(+) Full Conversion INR

12 Note-1: General Notes 1.On their own interest, contractors are advised to inspect the site with prior permission before quoting their rates. 2. All the samples of materials which are to be used shall be approved by the department in advance. 3. The contractor shall comply with the provision of the Payment of Wages act 4. Rates quoted shall be inclusive of all cost of materials, labour, carriage, taxes, GST, labourcess, wastages etc.. 5. Rates quoted shall be excluding the amount of EPFO and ESIC contributions. EPFO and ESIC contributions are reimbursable on production of valid proof of payment made by the contractor as per CPWD norms.

Total in Figures

Quoted Rate in Figures Select

Please Enable Macros to View BoQ information