Labour work for Hand Laying Patch work at diff. Road in Shahpur

Name of work: - Ntnvwh Jtuzobtk sw>e sw>e søgtyu htuz vh nuLz juEkd&e vuaJfo fhJtlt juch

ftb.(yu.yth.me.)

Tender Invited on Behalf of AMC, Central Zone.

Assistant Manager, Central Zone,

Central Zone Zonal Office”, B – Wing,

Third Floor,Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

Signature of Bidder Page 2 of

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

Notice inviting Tender

Competent authority on behalf of Municipal Commissioner of A.M.C. invites percentage rate sealed

tenders from interested contractors for the following work at different locations within the limit of

Ntnvwh Jtuzobtk sw>e sw>e søgtyu htuz vh nuLz juEkd&e vuaJfo fhJtlt

juch ftb.(yu.yth.me.)

2 Estimated Tender Amount Rs. 1086531.05 (EXCLUDING OF GST) GST WILL BE PAID EXTRA BY

AMC/AUTHORITY AT PREVALLING RATE TO THE CONTRACTOR

3 Tender fee Rs.900.00

(Non refundable) (Demand Draft in favour of Municipal Commissioner, Ahmedabad)

4 Time Limit 12 Months (Excluding Monsoon)

5 Download of Tender Tenders from the website www.nprocure.com or shall be down

Documents loaded mentioned AS PER TENDER NOTICE INVITED

6 Required registration Register “E-2” class having in Road Works in PWD in Govt. R&B /

CPWD / AMC or equivalent register with any other state Govt. or

7 Earnest Money Deposit Rs. 10865.00 (Demand Draft / pay order / Bank Guarantee in favour of

(Bid security) Municipal Commissioner, Ahmedabad is to be submitted as prescribed

(1 % of Estimate put to as below. Demand Draft/Bank Guarantee shall be from approved list of

AMC of banks and the issuing branch of bank guarantee shall be of

Ahmedabad city only and it should be valid for for 180 days. ( As

Per AMC finance Dept . Circular No. 5 Dt. 5/5/2007 & F.D.

Circular No. 29 Dt. 7/8/2010 & attched ANNEXURE - 1 finance

dept.circular No-40 Dt.05/11/2020. E.M.D. shall be submitted

physically along with the Physical Submission when applicable.

8 Submission of EMD and Tender Fee & EMD should Submitted physically along with tender

Tender Fees documents as described in the invitation of tender should be

submitted to Assistant Manager- Central Zone, 3rd Floor, B – Wing,

Sardar Patel Bhavan, Danapith, Ahmedabad-380001.

Bid submitted without bid security & tender fee shall be treated as

non responsive and shall be summarily rejected.

9 Mode of sending the The whole tender shall be submitted by two modes.

Tender Documents • Whole tender shall be submitted only on www.nprocure.com

website as per Schedule mentioned in Notice inviting

• Tender Fee, EMD, technical bid and other relevant PQ Documents

as per check list given in tender shall be submitted physically in

two copies (Original & duplicate) in sealed envelope as per

Schedule mentioned in Notice inviting Tender.

10 Last date of receiving As per Notice inviting Tender / Addendum / Corrigendum.

Tenders. The tenders received after latest schedule date and time will not

be entertained under any circumstances.

11 Submission of Price Bid The Price bid shall be submitted online only. The bidder shall fill

percentage rate on amount of BOQ online only until specified.

Price Bid shall be submitted physically duly signed & seal without

Signature of Bidder Page 1 of

Ahmedabad Municipal Corporation

mentioning quoted rated, else it shall be considered as rejected.

12 Opening of Technical bid As per Notice inviting Tender / Addendum / Corrigendum.

13 Tender validity period 120 days from the last date of submission of Tender.

14 Security Deposit 5 % of Contract Value to be submitted in the form of (Demand Draft /

pay order / Bank Guarantee in favour of Municipal Commissioner,

Ahmedabad. Bank Guarantee shall be from approved list of AMC of

banks as per attched ANNEXURE - 1 finance dept. latest circular.

and the issuing branch of bank guarantee shall be of Ahmedabad City

only. The validity of the Security Deposit shall be up to valid till

days beyond Date of completion of work.

The Security Deposit shall be payable in 10 days (for tenders upto

Rs.10.0 Lacs) or 15 days (for tenders of Rs.10.0 Lacs and above) from

date of receipt of LOI failing which interest @ 4% per annum will be

charged by AMC.

15 Deductions from Running

a. Retention Money 2 % amount of each Running Bill shall be deducted as a Retention

Money. Such retention money shall be released in the final bill of the

b. Labour welfare cess Labour welfare cess as per the Act, 1996 (non refundable) shall be

deducted from each running bill.

16 Defect & Liability Period Not applicable in this case. If applicable than refer condition of

contract attached over rule as per form B-1 published by Government.

17 Compansation for Delay 10 % of the actual balance work after Time limit expired.

• All the circulars which were published by Authorities of AMC time by time will be applicable on

said Tender and bound to bidder with out any condition.

• Conditional tenders will not be accepted in any case. Municipal Commissioner reserves the

rights to reject any or all the tenders without assigning any reasons thereof.

• The authorized signatory holding Power of Attorney shall only be the Digital Signatory. In case

authorized signatory holding Power of Attorney and Digital Signatory are not the same, the bid

shall be considered non-responsive.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 2 of

Ahmedabad Municipal Corporation

(On contractor’s Letter Head / certified with Stamp and Sign with Contact Detail)

TENDER DECLARATION FORM

Additional City Engineer

Ahmedabad Municipal Corporation,

Name of Work:- Ntnvwh Jtuzobtk sw>e sw>e søgtyu htuz vh nuLz juEkd&e vuaJfo fhJtlt juch

ftb.(yu.yth.me.)

I/We the undersigned have carefully gone through and clearly understood the Tender

documents of above mentioned project comprising of Notice Inviting tenders, Articles of Agreement,

Scope of work, Definition of terms, notes Instructions/Information to Bidder, Condition of Contract,

special condition of contract, Appendices, Specifications, Bill of Quantities, furnished by AHMEDABAD

MUNICIPAL CORPORATION.

I/We do hereby offer to execute and complete the whole of the work within the time specified

all in accordance with the specification, designs, drawing and instruction in writing referred to in the

said document and with such materials as mentioned for, at the respective rates which I/we have

quoted in the Price Bid or at such other rates as may be fixed under the provisions of these conditions.

In the event of this tender being accepted I/We agree to enter into an agreement and when

required, execute the contract, according to your form 1 of agreement as or in default where of I/we

bound myself/ourselves to forfeit the "Earnest Money Deposit."

I/We understand that if I/We shall not enter in agreement within fifteen days or as decided by

AMC from the date of receipt of letter of acceptance, you will forfeit the earnest money paid by me/us

and take necessary action as deemed fit.

I/We have enclosed a Demand Draft / Bank Guarantee as an “Earnest Money Deposit", for the

sum as mentioned in NIT, the full value of which is to be absolutely forfeited to the Employer If I/We fail

to commence the work specified. Otherwise the Employer shall retain the said sum, as on account of

such Security Deposit as provided for in the aforesaid documents.

I/We agree not to employ sub-contractors other than those that may be approved in accordance

with conditions in the aforesaid documents.

I/We understand that Municipal Commissioner is not bound to accept the lowest or any tender,

which are received. I / We also understand & agree that Municipal Commissioner Reserves the right to

allot number of tenders to successful bidders at his sole discretion in case if I / We am/are lowest in

more than one tender.

I/We am/are bound to execute the job if the work order is issued within 120 days from the date

of opening of the tender.

I am bound to execute the work by maintaining all Quality aspects/parameters mentioned in the

tender terms and conditions. I am also bound to submit all supporting Genuine Original documents as

and when asked and if any discrepancy found in such documents as well as in the executed Work with

respect to Quality/Quantity at any stage of work or even after completion of work, it will be solely my

Responsibility. I am bound to prove originality of all documents submitted by me and if any Documents

found false/fake then Municipal Commissioner/AMC has right to take any action/penalty/punishment

Signature of Bidder Page 3 of

Ahmedabad Municipal Corporation

I am also bound that if I/we, indulged into any malpractice and/or used any inferior quality

and/or the construction of road is found to be of an inferior quality under this contract than in such case

Municipal Commissioner/AMC has right to debar/ blacklist permanently.

I/We agree to pay the Government income-Tax, GST/Sales-Tax (Central and State), Octroi duties,

Royalty on material (i.e. Aggregate, Sand etc.) And any other taxes prevailing and from time to time on

such items on which the same are leviable and the rates quoted by me/us are inclusive of the same.

Yours faithfully

Seal and Sign of Contractor

Signature of Bidder Page 4 of

Ahmedabad Municipal Corporation

INSTRUCTIONS TO BIDDERS

1. Scope of Bid

1.1 Competent authority on behalf of The Municipal Commissioner, Ahmedabad Municipal

Corporation (referred to as Employer in these documents) invites sealed bids for the

construction of works (as defined in these documents and referred to as “the work”) detailed in

the table given in the Invitation for Bid (hereinafter called as IFB.) from competent bidder. The

bidders may submit bids for the works detailed in the table given in IFB.

2.0 Source of Funds

Ahmedabad Municipal Corporation has arranged the fund for this project.

3.0 Eligible Bidders

3.1 The Invitation for Bids is open to all eligible bidders meeting the eligibility criteria as defined in

3.2 All bidders shall provide Qualification Information and Forms of Bid mentioned in the Clause-14.

An agency that has been engaged by the Employer to provide consulting services for the

preparation or supervision of the works, and any of its affiliates, shall not be eligible to bid.

3.3 Any entity which has been declared as non-performing by NHAI / GoG / AMC or the firms those

are blacklisted/ debarred for specified period by AMC, Governement of Gujarat, Government of

India or any other entity controlled by it, would not be eligible to submit the Bid.

4.0 Qualification of the Bidder

4.1 Requires registration:- Register as per Notice Inviting Tender having in Road Works in PWD in

Govt. R&B / CPWD / AMC or equivalent register with any other state Govt. or institutions.

5.0 DISQUALIFICATION

Even though the bidders meet the above mentioned qualifying criteria, they are subject to be

disqualified if they have,

• Made misleading or false representations in the forms, statements, affidavits and

attachments submitted in proof of the qualification requirements; and/or

• Record of poor performance such as abandoning the works, not properly completing the

contract, inordinate delays in completion, litigation history, or financial failures etc. or

debarring from AMC work etc.

• Tampered the bid document in any manner.

• Colluded with other prospective bidders for this work to arrive at quoted prices for the

purpose of restricting competition.

• Indulged in inducement of any official of AMC and/or their consulting engineer and other

advisors in any manner whatsoever.

• Proposal not submitted in accordance with this tender.

• During validity of the proposal, or its extended period, if any, the bidder changes his

commercial terms.

• The bidder qualifies the proposal with his own conditions.

• Proposal is received after due date and time.

• Commercial proposal is enclosed with the same envelope as technical proposal

• The envelope does not show on the outside the reference of bid and thus gets opened

before the due date of opening.

• The E.M.D. is not deposited in full and in the manner as specified in the clause of

Earnest Money Deposit.

Signature of Bidder Page 5 of

Ahmedabad Municipal Corporation

• The tender is in a language other than English or dose not contains its English

Translation in case of other language adopted for tender preparation.

• The tender documents received are not duly signed by authorized person.

• The validity of tender is less than what is stated in the tender.

• Any of the page or pages of tender is/are removed or replaced.

• Any condition which affect the cost.

• If it is joint venture.

5.1 Debarment / Black listing

Notwithstanding the above, the Employer may debar or blacklist any of the bidder(s) for

their misleading or false representations in the forms statements etc. for the period to be

decided by the Employer.

6.0 Cost of Bidding

The bidder shall bear all costs associated with the preparation and submission of his Bid.

Employer will in no case be responsible and liable for those costs.

The Bidder, at his own cost, responsibility and risk, is encouraged to visit, examine and

familiarize himself with the site of Works and its surroundings including source of earth, water,

road aggregates etc. and obtain all information that may be necessary for preparing the Bid and

entering into a contract for construction of the Works. The costs of visiting the Site shall be at

the Bidder's own expense.

8.0 Bidders shall not have any dispute or claim for any kind of compensation in case of,

• If the quantity stipulated in the tender items varies or the scope of work changes and thereby

total amount of work increases / decreases up to any extent.

total amount of work increases / decreases up to any extent.

• If the works gets delayed / postponed for some administrative / technical decision whatsoever.

• If the items stipulated in the tender shall not be executed as per site condition/ requirements.

No claim shall be entertained for the same.

• No idle charges shall be paid to contractor for machinery and man power if remain idle and no

claim shall be entertained for the same.

B. BIDDING DOCUMENTS

9.0 Content of Bidding Documents

9.1 The set of bidding documents comprises the documents listed below and addendum (if any)

1. Notice inviting e-Tender

2. Special conditions of Contract

3. Instructions to Bidders

4. Qualification Information

5. Conditions of Contract

6. Technical Specifications

7. Forms of Bid

8. Bill of Quantities

• The bidder is expected to examine carefully all instructions, conditions of contract, contract

data, forms, terms, technical specifications, forms, Annexes in the bid document. Failure to

comply with the requirements of bid documents shall be at the bidder’s own risk. Bids which are

not substantially responsive to the requirements of the bid documents shall be rejected.

10.0 Amendment of Bidding Documents

Signature of Bidder Page 6 of

Ahmedabad Municipal Corporation

10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by

issuing addendum.

10.2 Any addendum thus issued shall be part of the bidding documents and shall be placed on

website www.nprocure.com The prospective bidder shall refer to website to check any

addendum before 24 hours of opening of bids. AMC will not give any advertisement for the

10.3 To give prospective bidders reasonable time in which to take an addendum into account in

preparing their bids, the Employer may, at his desecration, extend as necessary the deadline for

submission of bids.

10.4 Prospective bidders should attach the addendum made for the work & if fails to do so than also

the changes made through such addendum shall be applicable & bound to the bidder.

C PREPARATION OF BIDS

11.0 Language of the Bid

All documents relating to the bid shall be in the English language only.

12.0 Documents comprising bid

The e bid submitted by the bidder shall be in two separate parts.

• Technical Bid

• Financial Bid

To qualify for award of the contract, each bidder must submit the following documents along

• Required Registration Certificate

• Other requested documents

• Any other material / information required to be submitted in accordance with these

Instructions to Bidders (ITB)

Failure to submit these certificates/documents shall make the bid non-responsive.

Above original documents in physical form in two copies, one marked as “original” and other

marked as “Duplicate”, shall be submitted in a sealed envelope by 18:00 Hrs on the date of

physical submission of bid and addressed to the addressee given in the NIT duly super scribed

“Name of Work, Bid due date and time, Name and address of the bidder”

13.0 Bid Prices

• The contract shall be for the whole works as described in Bill of Quantity based on the

percentage rate in the Bill of Quantities submitted by the bidder..

• All duties, taxes, and other levies payable by the contractor under the contract, or for any other

cause shall be included in the rates, prices and total Bid Price submitted by the Bidder, except

otherwise stated in the Bid document. Employer will not compensate the bidder (contractor)

for any change in duties, taxes and other levies payable by the contractor under the contract

and any other reasons.

• The percentage rate and bid price quoted by the bidder shall be fixed up to the completion of

Work and shall not be subject to adjustment on any account, except where expressly specified,

otherwise, in the contract.

14.0 Currencies of Bid and Payment

The currency of bid and payment shall be in Indian Rupees. All payments shall be made in Indian

Signature of Bidder Page 7 of

Ahmedabad Municipal Corporation

15.0 Bid Validity

15.1 Bids shall remain valid for 120 days from last date of submission of tender. A bid valid for a

shorter period shall be rejected by the Employer as non-responsive.

15.2 In exceptional circumstances, prior to expiry of the bid validity (120 days), the Employer may

request that the bidders may extend the period of validity for a specified additional period. The

request and the bidders' responses shall be made in writing or by cable. A bidder may refuse the

request without forfeiting his bid security. A bidder agreeing to the request will not be required

or permitted to modify his bid, but will be required to extend the validity of his bid security for a

period of the extension.

16.0 Earnest Money / Bid Security

16.1 The Bidder shall furnish, a Bid Security of the amount as shown in the Table of IFB as part of his

bid, in the form of Demand Draft / pay order / Bank Guarantee in favour of Municipal

Commissioner, Ahmedabad valid for 120 days.

16.2 The issuing branch of the bank guarantee shall be of Ahmedabad City only.

Signature of Bidder Page 8 of

Ahmedabad Municipal Corporation

16.3 Any bid not accompanied by an acceptable Bid Security shall be rejected by the Employer as

non-responsive.

16.4 Any bid having bid security for lesser value and shorter validity period shall be treated as non-

16.5 (a) The bid security of the unsuccessful bidders, except for L1, L2 and L3 bidders will be returned

as promptly as possible.

(b) The bid security of the successful bidder, along with second and third lowest tenders, will be

returned when the successful bidder has furnished the required security deposit and

signed the agreement.

16.6 The Bid Security of the Successful Bidder will be discharged when the bidder has signed the

Agreement and furnished the required security deposit.

16.7 The Bid Security shall be forfeited,

a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;

b) in the case of a successful Bidder, if the Bidder fails within the specified time limit to

(i) sign the Agreement; or

(ii) Furnish the required security deposit.

(iii) commence the work after signing the agreement within 15 days

16.8 No interest shall be paid by the owner on any tender guarantee. The issuing branch of the bank

guarantee shall be of Ahmedabad City only.

16.9 Bank Guarantee for Earnest Money Deposit should be executed on non-judicial Stamp papers of

requisite value in accordance with the stamp Act applicable to that particular state of Indian

Union, where executed.

16.10 The executing officers of the bank Guarantee for Earnest Money Bid Security shall clearly

indicate in (block letters) his name, designation, Power of Attorney No. / Signing Power No. etc.

16.11 Each page of the bank guarantee for Earnest Money Deposit shall be duly signed/initialed by the

executing officers and the last page shall be signed in full, indicating the particulars as aforesaid

under the seal of the Bank.

D. SUBMISSION OF BIDS

17.0 Sealing and Marking of Bids

17.1 The bidder shall submit the Technical Bid only. The Bid shall be sealed in separate envelopes and

the three sealed envelopes shall be sealed in an outer envelope. The Bid envelopes shall be

marked as follows:-

• Complete Tender Document with all necessary qualification related documents (in two

Above two envelopes shall be kept in one envelope and it should be marked as “Technical Bid”

and sealed. This Outer envelope should mention the name of firm of bidder, his address, contact

details & name of the work.

17.2 The inner and outer envelopes

a) Shall be addressed to the Employer at the following address:

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Signature of Bidder Page 9 of

Ahmedabad Municipal Corporation

Danapith, Ahmedabad-380001.

c) Bear the following identification:

Indicate the name and address of the bidder.

• If the outer envelope is not sealed and marked as above, the Employer will assume no

responsibility for the misplacement or premature opening of the bid.

18.0 DEADLINE FOR SUBMISSION OF THE BID

18.1 Complete Bids (including Technical bid and necessary documents) must be received by the

Employer at the address specified in bid information not later than the date indicated on the

face sheet of the document. In the event of the specified date for the submission of bids

declared a holiday for the Employer, the Bids will be received up to the appointed time on the

next working day. The Bidder is further required to submit Documents in Physical Form on or

before the Bid Due Date and before the time of submission as specified in NIT, at the following

Assistant Manager- Central Zone,

3rd Floor, B – Wing, Sardar Patel Bhavan,

Danapith, Ahmedabad-380001.

18.2 AMC assumes no responsibility for inability of a bidder to submit bids through (n) procure e-

tendering portal on account of delay in submission at bidder's end. Bidder shall ensure that they

submit the bid well before the "Due Date & Time of Bid- Submission". AMC shall not be

responsible if bidder is not able to submit the bid on account of failure in network/internet

connection or any other technical reason.

18.3 The Employer may extend the deadline for submission of bids by issuing an amendment in

accordance with respective Clause, in which case all rights and obligations of the Employer and

the bidders previously subject to the original deadline will then be subject to the new deadline.

18.4 All bidders are requested to see the website of (n) procure for amendment / corrigendum if any.

18.5 Any Bid received by the Employer after the deadline prescribed in NIT will be rejected and

returned unopened to the bidder.

Any Bid received by the Employer after the deadline prescribed in NIT will be returned

unopened to the bidder.

20.0 NOTIFICATION OF AWARD & SIGNING OF AGREEMENT

The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to

expiration of the Bid validity period by writing, facsimile or e-mail confirmed by registered letter.

This letter (hereinafter and in the Conditions of Contract called the “Letter of Acceptance” will

state the sum that the Employer will pay the Contractor in consideration of the execution,

completion, and maintenance of the Works by the Contractor as prescribed by the Contract

(hereinafter and in the Contract called the “Contract Price”).

The notification of award will constitute the formation of the Contract, subject only to the

furnishing of a Security Deposit in accordance with the provisions of Clause.

The agreement will incorporate all correspondences between the Employer and the Successful

Bidder. It will be signed by the Employer and the Successful Bidder.

21.0 SIGNING OF CONTRACT AGREEMENT

21.1 The Employer and the successful bidder shall enter into a Contract Agreement within 28 days

after the successful bidder (hereinafter called the Contractor) receives the Letter of Acceptance,

unless they agree otherwise, subject to furnishing the security deposit before signing the

Agreement with the Employer.

Signature of Bidder Page 10 of

Ahmedabad Municipal Corporation

21.2 Upon issue of ‘Letter of Acceptance’ to the successful Bidder, the Employer will promptly notify

the other Bidders that their Bids have been unsuccessful and release their Earnest Money

Deposit / Bid Security.

22.0 SECURITY DEPOSIT

22.1 Within 15 days of receipt of the Letter of Acceptance, the Successful Bidder shall deliver to the

Employer a security deposit in the form of Bank Guarantee for an amount equivalent to 3% of

the Contract Price valid for the period of valid till 90 days beyond Date of completion of work.

The Security Deposit shall be payable in 10 days (for tenders upto Rs.10.0 Lacs) or 15 days (for

tenders of Rs.10.0 Lacs and above)from date of receipt of LOA failing which interest @ 4% per

annum will be charged by AMC.

22.2 The security deposit shall be in the form of a Bank Guarantee in the name of the Employer, from

Ahmedabad branch of any Banks mentioned in the clause no. 16.2 of these tender documents.

22.3 This security deposit shall be released only after the clearance of final bill including pre & post

22.3 Interest @ 4 % per annum shall be deducted from contractor in case of late submission of

security deposit or late renewal of bank guarantee for the number of days delayed for

submission or discontinuity of the bank guarantee.

22.4 Bank Guarantee to be submitted in the prescribed format enclosed and shall be same verbatim

as per the format. Bank Guarantee shall be submitted on right value of stamp paper and for

correct value of contract.

22.5 Failure of the Successful Bidder to comply with the requirements of Sub-Clause 22.1 shall

constitute sufficient grounds for cancellation of the award and forfeiture of the Bid Security.

22.6 In case of any contract amendment during execution of the contract enhancing value of the

contract the BG value shall be enhanced accordingly. Validity of BG shall be commercial terms

and conditions of the tender.

22.7 All compensation or other sums of money payable by the Contractor to the Employer under the

terms of this Contract or any other contract or on any other account whatsoever may be

deducted from Security Deposit. Also in the event of the Contractor's Security Deposit being

reduced by reasons of such deductions, as aforesaid, the Contractor shall, within 14 days of

receipt of notice of demand from the Engineer-in-Charge, make good the deficit in Security

22.8 Should there arise any occasion under the Contract due to which the periods of validities of

Bank Guarantees as may have been furnished by the Contractor from time to time, are required

to be extended/renewed, the Contractor shall get the validity periods of such guarantees

extended/renewed, and furnish these to the Engineer-in- Charge one month before the expiry

date of the aforesaid Guarantees originally furnished failing which the existing Bank Guarantees

shall be invoked by the Engineer – in – charge. Also in case of any deficit in securities on any

account as might occur or is noticed, the Contractor shall forthwith recoup/replace the same

with acceptable Security Deposit.

22.9 The Bank Guarantee shall be extended within the expiry dates wherever activities as per

contract are not completed in all respects.

22.10 The Security Deposit less any amount due shall, on demand, be returned to the contractor after

45 days of completion date / Final Bill paid date which ever is later. No interest on the amount

of Security Deposit shall be paid to the Contractor at the time of release of Security Deposit as

22.11 The successful bidder to whom ‘LOA’ has been issued shall enter into an agreement at

Employer’s office within 15 days of LOA.

Signature of Bidder Page 11 of

Ahmedabad Municipal Corporation

23.0 Advance Payment and Security

The Employer will not provide any advance payment.

24.0 Dispute Review Expert

In case of all the disputes, decision of the Municipal Commissioner, Ahmedabad shall be final

and binding to the bidder.

25.0 LITIGATION HISTORY

The applicant should provide accurate information on litigation and/or arbitration resulting from

Contractors completed or under execution by him over last five years. If the details of Litigation

History are hidden by the Bidder and later on it comes to the knowledge of the Employer, the

Bidder shall be disqualified for the proposed work and other appropriate actions shall be taken

against the bidder.

DETAILS OF COMPLETED / ONGOING LITIGATION / ARBITRATION

Employer Value of the Reasons/Details for Remarks showing

Year Name of Project (Rs.) litigation/arbitration Present Status

 The bidder shall furnish separate table for individual project.

 The above information shall be supported with necessary documents otherwise the same shall

be treat as null and void.

 A consistent history of arbitration awards? Judgments against the applicants or any partner of a

joint venture may result in disqualification for proposed work.

 If the details of litigation History is hidden by the applicant and later on it comes to knowledge

of the employer the bidder shall be disqualified for the proposed work and other appropriate

actions shall be taken against the bidder.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 12 of

Ahmedabad Municipal Corporation

GENERAL CONDITIONS OF CONTRACT

1.0 Liquidated Damages

1.1 If the Contractor fails to complete the works within the original or extended time limit, the

Contractor shall pay penalty of 10% of amount of actual remaining work. The amount of work

for which the scope of contractor is reduced shall not be considered for the calculation of

Liquidated Damages.

1.2 Conditions mentioned in the AMC Finance Department Circular AMC no. 18 Date: 23/05/2017

and all latest Circulars shall be applicable.

2.0 Retention Money

2 % amount of each Running Bill shall be deducted as a Retention Money. Such retention money

shall be released in the final bill of the said work. AMC reserves right to deduct any amount to

compensate the poor performance of the contractor i.e. poor quality or abandoned /

incomplete work.

3.0 Subcontracting

3.1 Except where expressly specified in the Contract, the Contractor shall not subcontract any

portion of Work without the approval of the Employer’s Representative. Any subcontracting

shall not relieve the Contractor from any contractual obligations or responsibility under the

3.2 The Contractor shall not be required to obtain consent for a subcontract for which the name of

the subcontractor and scope of works activities to be performed by him is already stated in the

contract or supply of material or engagement of labour.

4.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as

referred to in the Bid document to carry out the functions stated in the Schedule or other

personnel approved by the Engineer. The Engineer will approve any proposed replacement of

key personnel only if their qualifications, abilities, and relevant experience are substantially

equal to or better than those of the personnel listed in the Schedule.

4.2 If the Engineer asks the Contractor to remove a person, without assigning reasons thereof, for his

misconduct or inadequacy of technical skills and experience, who is a member of the

Contractor’s staff or his work force, the Contractor shall ensure that the person leaves the Site

within seven days and has no further connection with the work in the Contract.

4.3 No residential accommodation is allowed at the site of work. The labour huts shall not be erected

on the site of work and contractor shall make his own arrangements to provide such

accommodations as per the rules of the local bodies. He shall make his own arrangements for

housing, stores, field office etc. He shall submit a site layout plan indicating the location of

various site facilities to be created by him at his cost for the execution of work. The Owner shall

in no way be responsible for any delay on this account and no claim on this account whatsoever

shall be entertained. All Basic amenities shall be provided by the Contractor to Labours as per

the prevailing labour Laws.

5.1 The Contractor shall have full regard throughout execution, completion and defects liability

period to following safety aspects and shall take all necessary steps to ensure that danger to

safety is avoided all the time in respect of,

Safety of the works

Signature of Bidder Page 13 of

Ahmedabad Municipal Corporation

• Safety of the Contractor’s employees and all the persons directly or indirectly engaged

by him for the works

• Safety of all the employees including persons working on other contracts of Employer at

the same site of the Employer and Engineers employees engaged at work site.

• Any authorized third party persons on the site.

• Contractor’s plant and equipment

5.2 The Contractor shall provide and maintain at his costs all lights, guards, fencing, warning signs,

barricading, and cones; when and where necessary, or required by Engineer in Charge or by any

duly constituted authority for the protection of the works or for the safety and convenience of

the public or other.

5.3 The Contractor shall take all reasonable steps to protect the environment on and off the site and

avoid damage or nuisance to persons or property of the public and others arising as a

consequence of his method of operation.

5.4 The Contractor shall maintain in good condition all work throughout execution, completion, and

defects liability period. The contractor shall be responsible for and to make good all injuries,

damages and repairs, rendered necessary by fire, rain, traffic, floods or other causes.

5.5 All the scaffolding work, wherever required for the execution of work, shall be provided by the

contractor. Nothing extra shall be payable on this account. It shall be provided strictly with

double scaffolding system with all the accessories etc. with adjustable suitable working

platforms to access the areas, with ease for working and inspection. It shall be designed to take

all incidental loads. It should cater to the safety features for workmen. It shall be ensured that

no damage is caused to any structure due to scaffolding.

5.6 All temporary warning/ caution boards display shall be provided and displayed during day as

well as night time by the contractor, wherever required and as directed by the Engineer.

5.7 Arrangement of temporary water and electricity and telephone connection required, by him,

shall be made by the Contractor at his own cost and also necessary permissions directly from

relevant Owners shall be obtained by him under intimation to the Owner. Also all initial and

running charges and security deposit, if any in this regard shall be borne by him. The Contractor

shall abide by all the rules/ bye laws applicable in this regard and he shall be solely responsible

for any penalty on account of violation of any of the rules and byelaws in this regard.

5.8 In any case if any fatal accident (major or minor) occurs due to poor safety precautions, the

same shall be completely contractor’s responsibility. All the losses due to such accidents and

expenses of legal matters shall be borne by contractor.

5.9 The Contractor shall be responsible for maintenance and watch and ward of the complete

installation and shall also be responsible for any pilferage, theft, damage, penalty etc. in this

regard. The Contractor shall indemnify the Owner against any claim arising out of pilferage /

theft, damage, penalty etc. whatsoever on this account.

5.10 The Contractor shall depute Site Engineer & skilled workers as required for the work. Necessary

protective and safety equipments shall be provided to them by the Contractor at his own cost

and used at site.

6.0 Contractor to keep site clean:

During the execution of the work, the Contractor shall keep the site clean. All wreckage rubbish,

excess materials, temporary works no longer required will be removed from site immediately.

7.0 Clearance of site on completion:

The Contractor shall clear away and remove all Contractors equipment, surplus materials,

rubbish, temporary works of every kind.

Signature of Bidder Page 14 of

Ahmedabad Municipal Corporation

A. COST CONTROL

8.0 Bill of Quantities

a. The schedule-B shall contain Memorandum showing items for the construction, installation,

testing, and commissioning work to be done by the Contractor.

b. The quantities stated in the schedule B are estimated quantities. The Contractor shall be

paid only quantities calculated after taking measurements of executed work. The rate stated

in the schedule B for each item of work shall apply. The works shall be measured by the

Contractor jointly with the authorized representative of the Engineer and all particulars

required by the representative of the Engineer shall be supplied by the contractor.

c. The work shall be measured net. No allowance for general or local custom, working space

etc. is to be made.

9.1 The Engineer in Charge shall have power to make any variation of form, quality or quantity of

the works or any part thereof that may, in his opinion, be necessary and for that purpose, or if

for any other reason it shall, in his opinion, be appropriate, he shall have the authority to

instruct the Contractor to do and the Contractor shall do any of the following:

 Increase or decrease the quantity of any work up to any extent included in the contract,

 Omit any such work,

 Change the character or quality or kind of any such work,

 Execute additional work of any kind necessary for the completion of the Works or

 Change any specified sequence or timing of construction of any part of work.

9.2 No such variation shall in any way vitiate or invalidate the contract, but the effects, if any, of all

such variations shall be valued in accordance with the following sub clauses. Provided that

where the issue of an instruction to vary the Works is necessitated by some default or breach of

contract by contractor or for which he is responsible, any additional cost attributable to such

default shall be borne by the Contractor.

9.3 The Contractor shall not make any such variation without an instruction of the Engineer. No

instruction is required for quantities varying from those provided for the items in the contract

10.1 The basis for the valuation of variations for addition to the Contract Price shall be as follows in

the same order of priority.

a) Variations in the quantities of work in schedule of quantities shall not vitiate the contract.

b) The contractor shall be bound to execute extra items of work as directed by the Engineer-

c) Contract unit rates for individual items shall apply to varied quantities where there is a

quantity variation.

d) The price variations on extra item will not be given.

e) In case of other non tender items following procedure shall apply.

10.2 If any extra item crops up during the progress of work the same shall be carried out by the

Contractor and he shall be paid at the rate fixed by Employer which shall be fixed as lowest of

the rates derived by rate analysis based on the following three methods. , the priority of the

documents forming the Contract shall be as follows:

(i) If the extra item is included in the S.O.R. of Road & Building Department, Year 2013-14, the

rate of extra item shall be that rate and premium (above or below) quoted by contractor.

(ii) Rate analysis based on prevailing Govt. of Gujarat’s SOR rates.

(iii) Rate analysis based on current market rates. This shall be based on

 The material costs, the labour costs, the cost of use of all plant, machinery and

equipment, the cost of all temporary and incidental works, the overheads and the

Contractors profit.

Signature of Bidder Page 15 of

Ahmedabad Municipal Corporation

 The overheads shall be taken at 5 % of the sum of material costs, the labour costs, the

cost of use of all plant, machinery, and equipment, the cost of all temporary and

incidental works.

10.3 In case of the rate is to be derived from prevailing market rate, the Contractors profit shall be

taken at 10 % of the final rate derived.

10.4 In the event of disagreement, the Engineer in Charge shall fix such rates and prices as are, in his

opinion appropriate and shall notify the Contractor accordingly with a copy to the Employer.

10.5 The Engineer shall determine provisional rates and prices to enable on account payments to be

included in the Interim Payment Certificates, until rates and prices are agreed as final by the

Employer, the Contractor, and the Engineer.

10.6 The Contractor shall not be entitled to additional payment for costs, which could have been

avoided by giving early warning.

11.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in

terms of the contract and taxes at source, as applicable under the law. The Employer shall pay

the Contractor the amounts certified by the Engineer.

11.2 If an amount certified is increased in a later date certificate due to corrections in previous

certificates or as a result of an award from disputes review experts, Contractor shall be paid

such amount only. The Contractor shall not be paid any interest upon such delayed payment.

11.3 Items of the work for which no rate or price has been entered in will not be paid for by the

Employer and shall be deemed covered by other rates and prices in the Contract.

11.4 All payments shall be made in Ahmedabad.

12 Taxes and duties

12.1 The rates are inclusive of all the prevailing taxes and duties of the Central, State and Local

Governing bodies prevailing on the date of award of the contract. The Contractor will have to

pay all such taxes and duties for the performance of this Contract. The Employer will deduct

from the Contractor’s monthly and other payments all taxes and duties, which he is bound to

recover in accordance with the applicable law.

12.2 The Contractor shall keep himself fully informed of all acts and laws of the Central & State and

local Governing bodies, all orders, decrees of bodies, tribunals having any jurisdiction or

authority which in any manner affect those engaged or employed, and anything related to

carrying out the work. All the bye-laws lay down by AMC/AUDA and any other local bodies while

executing the work shall be adhered to. All taxes of local bodies shall be borne by the

contractor. The Contractor shall arrange to give all notices required by any authority and to pay

to such authority all the fees that may have to be paid for the material, plants, equipments etc.

The Contractor shall also adhere to all traffic restrictions notified by the local authorities. He

shall protect and indemnify the Owner and its officials & employees against any claim or liability

arising out of violations of any such laws, ordinances, orders, decree, whether by himself or by

his employees or his authorized representatives. Nothing extra shall be payable on these

13.0 Labour Welfare Cess

As per circular No. GHR/2005/04/CWA/2004/841/M-3 dt. 3/1/05 and G.R. No. CWA/2004-1831-

M(3) dt. 9/12/05 issued by G.O.G. (non-refundable) shall be deducted from every bills which

shall be deposited to Govt. Labour Department for Labour welfare fund.

Signature of Bidder Page 16 of

Ahmedabad Municipal Corporation

14.0 Currencies

All payments shall be made in Indian Rupees.

15.0 Advance Payment

No Advance Payment shall be made.

16.0 Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the Works between the Start

Date and the end of the Defects Correction periods shall be remedied by the Contractor at the

Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.

B. FINISHING THE CONTRACT

17.0 Completion

The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and

the Engineer will do so upon deciding that the Work is completed.

18.0 Termination

18.1 The Employer shall be entitled to terminate the contract if the contractor:

(a) Fails to carry out any obligation under the contract.

(b) Without reasonable excuse fails –

1. To commence the works on site within the period stated in the Appendix to Bid after

receipt by him of a Notice to this effect from the Engineer/Employer after signing the

2. To proceed with the works, or any section thereof, within 28 days after received notice

3. Has failed to comply with a notice issued or an instruction issued within 28 days after

having received.

4. Abandons the works or otherwise plainly demonstrates the intention not to continue

performance of his obligation under the contract.

5. Sub-contracts the works or assigns the contract without the specific prior written

permission of the engineer.

6. Has failed to furnish the required securities or extension thereof in terms of the

7. Becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration

order made against him, compounds with his creditors, or carries on business under

receive, trustee or manager for the benefit of his creditors, or if any act is done or event

occurs which (under applicable Laws) has a similar effect to any of these acts of event.

18.2 In any of these events or circumstances, the Employer may, upon giving 14 days notice to the

contractor, terminate the contract and expel the contractor from the site. However, in the case

of sub-paragraphs (h), the Employer may be notice terminate the contract immediately.

18.3 The Employer’s decision to terminate the contract shall not prejudice any other rights of the

Employer, under the contract or otherwise.

18.4 After termination, the Employer may complete the works and/or arrange for any other entities

to do so. The Employer and these entities may then use any goods, contractor’s documents and

other design documents made by or on behalf of the contractor.

18.5 The Employer or the Contractor may terminate the Contract if the other party causes a

fundamental breach of the Contract.

18.6 Fundamental breaches of Contract include, but shall not be limited to the following:

(a) the Contractor stops work for 14 days when no stoppage of work is shown on the current

Program and the stoppage has not been authorized by the Engineer;

(b) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a

reconstruction or amalgamation;

Signature of Bidder Page 17 of

Ahmedabad Municipal Corporation

(c) The contractor fails to fulfill requirements;

(d) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach

of Contract and the Contractor fails to correct it within a reasonable period of time

determined by the Engineer;

(e) the Contractor does not maintain a security which is required;

(f) the Contractor has delayed the completion of works by the number of days for which the

maximum amount of liquidated damages becomes payable as defined in the Contract data;

(g) if the Contractor, in the judgment of the Employer has engaged in corrupt or fraudulent

practices in competing for or in the executing the Contract.

(h) For the purpose of this paragraph: “corrupt practice” means the offering, giving, receiving or

soliciting of anything of value to influence the action of a public official in the procurement

process or in contract execution. “Fraudulent practice” means a misrepresentation of facts

in order to influence a procurement process or the execution of a contract to the detriment

of the Borrower, and includes collusive practice among Bidders (prior to or after bid

submission) designed to establish bid prices at artificial non-competitive levels and to

deprive the Borrower of the benefits of free and open competition.”

18.7 When either party to the Contract gives notice of a breach of contract to the Engineer for a

cause other than those listed above, the Engineer shall decide whether the breach is

fundamental or not.

18.8 Notwithstanding the above, the Employer may terminate the Contract for convenience.

18.9 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and

secure and leave the Site as soon as reasonably possible and handover the site to the Employer

including all materials and plant and equipment existing there upon.

19.0 Contractor's own responsibility

The contractor is to set out and level the works and will be responsible for the accuracy of the

same. He shall also be responsible for the correctness of the positions, levels, dimensions, and

alignment of all parts of the structures as per instructions given to him. If at any time any error

shall appear during the progress of any part of the work, the contractor shall at his own expense

rectify such error if called upon to the satisfaction of the Engineer in charge.

20.0 Overpayment & Underpayment

20.1 Whenever any claim Fifths payment of a sum to the Municipal Corporation arises out of or

under this Contract against the contractor the same may be deducted by the Municipal

Corporation from any sum then due or which at any time thereafter may become due to the

contractor under this contract and failing that under any other contract with the Municipal

Corporation or from any sum due to the contractor with the Municipal Corporation (which may

be available with Municipal Corporation), or from his retention money, or he shall pay the claim

on demand. The Municipal Corporation reserves the right to carry out post payment audit and

technical examination of the final bill including all supporting vouchers, abstracts, etc.

20.2 The Municipal Corporation further reserves the right to enforce recovery of any over payment

when detected notwithstanding the fact that the amount of the final bill may be included by the

20.3 If as a result of such audit and technical examination any over payment is discovered in respect

of any work done by the Contractor or alleged to have been done by him under the contract, it

shall be recovered by the Municipal Corporation from the contractor by way of all the means

prescribed above or if any under payment is discovered by the Municipal Corporation, any

amount due to the contractor under this contract or under payment may be adjusted against any

amount then due or which may at any time thereafter become due before payment is made to

the contractor from him to the Municipal Corporation on any other contract account

Signature of Bidder Page 18 of

Ahmedabad Municipal Corporation

21.0 Materials obtain from dismantling

If the contractor, in the course of execution of work is called upon to dismantle any part for

reasons other than on account of bad or imperfect work, the materials obtained from

dismantling will be the property of the A.M.C. and will be disposed of as per instruction of

Engineer-in-charge in the best interest of the A.M.C.

22.0 Dispute to be referred to Arbitrator

The disputes relating to this contract, so far as they relate to any of the following matters,

whether such disputes arise during the progress of the work or after the completion or

abandonment thereof, shall be referred an independent Arbitrator appointed by AMC as far

possible in consultation with the agency if it is necessary and such disputes shall be settled in

accordance with the arbitration and conciliation Act.

(i) The rates of payment under clause 5 for any tools, materials and stores, in or upon the

works of the site thereof or belonging to the contractor or procured by him and

intended to be used for execution of the work or any part thereof possession of which

may have been taken by the Engineer-in-charge under the said clause –5.

(ii) The reduction in rates made by the Engineer-in-charge under clause 9 from the items of

works not accepted as completed fully in accordance with the sanctioned specifications.

(iii) The rate of part of payment for any class of work which is included in the additional or

altered work carried out by the contractor in accordance with the instructions of the

Engineer-in-charge under clause 14 and the rates for which is to be determined under

the said clause

(iv) The rates of payment for materials already purchased or agreed to be purchased by the

contractor before receipt of notice given by the Engineer-in-charge under clause

and/or amount of compensation payable to the contractor under the said clause for loss

in respect of such materials.

(v) The amount of compensation which the contractor shall be liable to pay under clause

in the event of this failure to rectify, remove or reconstruct the work within the period

specified in the written intimation or the amount of expenses incurred by the Engineer-

in-charge under the said clause17 in rectifying, removing or re-executing the work or in

removing and replacing the materials or articles complained of.

(vi) The reduction of rates as may be fixed by the Engineer-in-charge under clause 17 for the

inferior work or materials as accepted or made use of.

(vii) The amount of compensation payable by the contractor for damages as estimates and

assessed under clause

(viii) The amount payable to the contractor for the work carried out under clause 33 in

accordance with the instructions and the requirement of the Engineer-in-charge in case

where there are no specifications.

(ix) The awards declared by the arbitrator shall be speaking award giving reasons and

calculations to every item of claims. The decision will have to be implemented by all the

(x) In case of dispute leading to the contractor or Ahmedabad Municipal Corporation

approaching on Court of Law. It shall be within the jurisdiction where the site of work is

The reference to arbitration proceeding under this clause shall not:

i) Entitle the contractor to stop the Affect the right of the Engineer-in-charge under clause 5 to

take possession of all or any tools, plants, materials and stores in or upon the works of site

thereof belonging to the contractor or procured by him and intended to be used for the

execution of the work or any part thereof.

Signature of Bidder Page 19 of

Ahmedabad Municipal Corporation

ii) Preclude the Engineer-in-charge from utilizing the materials purchased by the contractor in

any work or from removing such materials to other places, during the period the work is

stopped or suspended in pursuance, of notice given to the contractor under clause

iii) Progress of the work or the carrying out the additional or altered work in accordance with the

provisions of clause 14 or as the case may be, of clause

23.0 Drawings and Photographs of the Works

23.1 The contractor shall do photography/ videography of the site as and when asked by AMC. No

separate payment will be made to the contractor for this. . The contractor shall have to submit

the same in hard copy as well as soft copy as and when demanded by the AMC.

23.2 No photograph of the works or any part thereof or plant employed thereon, except those

permitted under clause 59.1, shall be taken, or permitted to be taken by the Contractor or by

any of his employees or any employees of his sub-Contractors without the prior approval of the

Engineer in writing. No photographs/ videography shall be published or otherwise circulated

without the approval of the Engineer in writing.

SPECIAL CONDITION OF CONTRACT

The Bidder must fulfill the following criteria for tender:

 Bidder Must Supply Laboure & Machinerys & other Iteam As Per Work Condition.

 If Necessary, Bidder Must have to Supply Multiple Laboure & Machinerys As Per

Daily Requirement On Work Quantity based.

 As Per Tender Criteria Experienced Enginner & Supervisoir Must Have to Present

On Working Site in Daily Based.

 Bidder must supply labours for all days in weeks including Sunday or govt. holidays

or in festival.

 No payment will be given if supplied labour doing only washout or borewell work.

Payment will given for 8 hours-shift of work.

Seal and Signature of the Bidder Additional City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 20 of

Ahmedabad Municipal Corporation

yb>tJt> BGþrlrmvj ftuvtuohuNl

ftb btxuLþk xftJthe >hJt¤wk xuLzh ylu ftuLx[tfx

xuLzh btxule Nh<tu

(1) y:- yt xuLzh su <u Jdolt yb>tJt> BGþrl.ftuvtuohuNl y&Jt fuLî{ y&Jt htsg mhfthle btLg

gt>elt ftuLx[fxhtu Che NfNu. dJobuLxlt btLg ftuLx[tfxhu yb>tJt> BGþrl.ftuvtuohuNlbtk btLg

ftuLx[tfxhtule gt>ebtk hSMxuNl fhtJJtlwk hnuNu.

c:- btLg ©uKelt ftuLx[tfxh <hefu ltuk^Kelwk «btKvºtle MJ «btKe< fhuj lfj xuLzh mt&u

stuzJtle hnuNu.

f:- xuLzhhle jtgft<

ftb sJtc>th xuLzhh <ubs su xuLzhh mwaJuj ftuLx[tfxhle ©uKe ytJ<t ntug <ubs ftb fhJt

mûtb ntug <ublu s ytvJtbtk ytJNu. ftb ytv<t vnujt ftuLx[tfxhu ftb mk<tu»tfthf <ubs

xtRb jebexbtk ÃþY fhJt sYhe mJj<,ylwCJ, ûtb<t ylu VtgltLmegj hemtumo hsw fhJtlt

z:- yb>tJt> Bgwrlrmvj ctuzo XhtJ lk - 3836,<t.25/11/2011 &e b¤uj bkswhe ylwmth <&t

mexe.Rsluh mh¾gwjh,lk -17,<t.09/12/2012 bwsc yb>tJt> Bgwrlrmvj ftuvtuohuNlbtk

ftuLx[t¾xh hSMxuNl Ve, heLgwyj Ve <&t yvd{uzuNl Ve ylu btv>kztu ægtlbtk htFe <u bwsc

ybj fhJtltu hnuNu.

E. xuLzh Ch<t vnujt xuLzhhu mtRx rlheûtK fhe juJwk. xuLzhh ftblt «fth, ngt< hM<t, vtKe

btdo, mkath ylu JvhtNlt ceò hM<tytu&e mk<wÐ ntuJtlwk btle juJtbtk ytJNu. xuLzhhu ftblu

mtRx ylu rcÕzekd(fu su ftb fhJt, ftb ÃþY fhJt <&t ftblt buRxulLm btxu cltJuj

ntug).<ubs xuLzhhu yt mtRxlt ftb btxu, rcÕzekd btxu, gtzo, zevtu btxule søgt vtu<tle he<u

bu¤Je juJtle hnuNu. (xuLzhlwk ftb fhJt, ftb vwhwk fhJt <&t ftblt buRxulLm btxule søgt)

(h) yt ftble mbg bgto>t bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(3) xuLzh Jujezexe rvhegz bubtuhuLzb (ltuxem RLJtRxuz xuLzh) btk sKtJuj «btKu le hnuNu.

(4) xuLzh Ch<e JF<u yluoMxble ChJtle hnuNu.

(5) xuLzh Vtubo

xuLzh Vtubo ylu ylwmwrabtkle >hufu >huf Ftje søgt xuLzh Chlthu Chuje yt mt&u btufjujt >M<tJus

vh< fhJtlt hnuNu.

(6) ftuLx[tfxhtuyu leaule ctc<tu ft¤SÃËJof JtkaJt rJlk<e Au.

(1) ftuR fkvlelu ltbu xuLzh juJtbkt ytÔgwk ntug <tu fkvle J<e xuLzh vh mne fhlth Ôgrf<lu yr^f]<

fh<wk bwFðgthltbwk xuLzh mt&u hsw fhJtlwk hnuNu.

Signature of Bidder Page 21 of

Ahmedabad Municipal Corporation

(2) Bgwrl.ftuvtuohuNllt «Joðbtl rlgbtu ylwmth yluMxble ChJtle hnuNu.ylu xuLzh mt&u

(3) ftuLx[tfxhu RLfbxuût mkckr^< vtl lkch <&t cukf zexuRj ytvJtle hnuNu.

(4) ftuLx[tfxh vtmu ydtWlt ylwCJt ykdult «btKvºttule lfj xuLzh mt&u hsw fhe NfNu.

(5) xuLzh Nh<tu ylu MvuNeVefuNl <&t CtJ vºtflt >huf vtlt ylu rJd<tu vh ftuLx[tfxhu mne

(6) <btb mw^tht, AufAtf ylu Dwkxujt jFtK vh ftuLx[tfxhu xwkfe mne fhJe.

xuLzh Chlthlu sKtJJtbtk ytJu Au fu xuLzh >eM<tJustult jFtKbtk ftuR AufAtf fu VhuVth

fhJt >uuJtNu lrn ylu ytJe ftuR AufAtf fu VuhVth juJtNu lrn, <ultk jFtKbtk ftuR Cwj ntug

<tu <ult vh l Dwkx<t Ftuxt jFtK fu ytkfzt vh Auftu bthelu <ult mtawk jFtK fu ytkfzt MvÐ

Wfju <u he<u jFJt. «ðguf mw^tht vh xwkfe mne fhJe.

(8) y:- xuLzh hsw fh<tk vnujt Ftm fhelu xuLzhbtk >NtoJuj mwaltytulwk vtjl fhJtbtk ytÔgw lrn ntug

<tu xuLzh ybtLg dKJtbkt ytJNu <ule ltuk^ juJt rJlk<e Au. J¤e yt Vtubolwk bwFv]ƒ ylu

ftuLx[tfxhtult btdo>Nol btxu mtbtLg rlgbtu ylu mwaltytu vK ft¤SvwJof JtkaJt rJlk<e Au.

(1) ftuEvK fthK >NtoÔgt rmJtg ftuEvK fu c^t xuLzhtu yMJefthJtltu n¬ yctr^< hnu Au.

(h) xuLzhhu ctujvtuELx vullt c>ju NtneJt¤e vul&e Chujt xuLzhtu ðþkh< s ybtLg dKJtbtk

c:- Wvhle ctc<tu Wvhtk< xuLzh leault mkstudtubtk <h< ybtLg XhJtlu vtºt &Nu.

(1) xuLzh Chlth, rlg< ftb y&Jt ftb btxu bkswh fhuj y&Jt CtJ vºtflt ftuR ftuz y&Jt

vîr< y&Jt rJd<tubtk bwfuj Nh< y&Jt mw^thtbtk ftuR VuhVth mwaJ<t ntug.

(h) xuLzhlwk ftuR vtlwk fu vtlt ftZe ltkÏgwk/ltkÏgt ntug fu c>ÕGþ / c>Õgt ntug.

(3) c^t mw^tht J^tht y&Jt atukxtzuje ftvjeytu Wvh xuLzh Chlthu xwkfe mne l fhe ntug.

(4) xuLzhbtk <ubKu ftuR AufAtf fhe ntug, ylu

(5) xuLzh Chlth y&Jt vuZele ctc<btk >huf Ctde>th y&Jt <u ykdulwk bwFðgthltbwk ^htJlth

Ôgrf< mne l fhu y&Jt xuLzhbt <u btxu htFJtbtk ytJuje søgtbtk mne/mneytu Wvh ftuR

mtûteyu mtF fhe l ntug.

f:- Nh<e xuLzh MJefthJtbtk ytJNu lne.

z:- xuLzh MJefthJw, h> fhJw, ftulu ytvJw ylu fgt CtJ&e ytvJw <u ykdu Bgwrl. frb§h©eltu

rlKog ytFhe hnuNu. ftuR fthKmh stu ftuLx[tfxhlu ftb l ytve Nftg <tu <u ykdu ftuLx[tfxh

ftuRvK «fthltu lwfNtle fu J¤<hltu nff>tJtuu fhe NfNu lrn fu ftg>tfeg ftgoJtne yt ykdu

&R NfNu lrn. xuLzh bkswh &gtltu y&o ftb ytve >uJtLþk Au <uJtu &R NfNu lrn.Nh<e xuLzh

MJefthJtbtk ytJNu lne.

(9) rJmkdr< ylu rnmtc stud:

Signature of Bidder Page 22 of

Ahmedabad Municipal Corporation

nt& ^hJtlt ftbtule ctc< >NtoJ<t CtJ vºtfbtklt sÚ&t ylu hfble ftuRvK

Cwjawf leault rlgbtu ylwmth mhCh fhJtbtk ytJNu.

(1) xuLzh Chlthu >hlt Ftltbtk sKtJuj Nç>tu ylu ytkfzt Jåau ftuR ymkdr<lt fumbtk Nç>tuubtk

sKtJuj hfb btLg htFJtbtk ytJNu.

(2) yufb >h ylu sÚ&tlt Ftuxt dwKtfthlt fthKu ftble ctc<tu >NtoJ<e CtJ vºtflt

Ftltbtk&e hfbbtk Cwj sKtg <tu yufb >h btLg htFJtbkt ytJNu ylu >hlt yt^thu dwKtfth

mw^thJtbkt ytJNu.

(3) yufblt Ftltbtk&e <ubs ytd¤ Fuka<t mhJt¤tle <btb Cwjtu mw^thJtbkt ytJNu.

(4) ctc<tu y&Jt mhJt¤t mtbu vwhu ytkfzu fhuj ftuR vK ctc< ægtlbtk juJtbtk ytJNu lrn.

(10) y:- ftbltu «tud{um mbgbgto>t bwsc fhJtltu hnuNu. yt mbgbgot>t 10 jtF mw^elt ftb btxu

yuj.ytu.ytR. ytÃgt <theF&e 10 r>Jm <&t 10 jtF &e Wvhltk ftb btxu yuj.ytu.ytR. ytÃg

<theF&e 15 r>Jm&e NY &guj dKJtbt ytJNu. <&t <u >hBgtl ftble 5% juFu zevtuÍex Che

fhthvºt fhJtltu hnuNu.

xuLzhbtk ftuLx[t¾xh îtht Chujt CtJ <btb «fthlt su <u «J<o<t mhfthe xuût mrn<lt

CtJ dKJtbtk ytJNu. ylu <ubtk atjw ftb >hBgtl su ftuR VuhVth &Nu <ultu J^thtu awfJJtbtk

c:- mûtb m•tt îtht Yt.10,00,000.00 (>m jtF) mw^elt xuLzhle bkswheltu XhtJ vtzgt ct>

(LOI) ytvJtbtk ytJNu ðgth ct> r>l - 10 btk rm¾gtuhexe zevtuÍex sbt fhtJJtle hnuNu.

rm¾gtuhexe zevtuÍex btuze ChJtlt rfMmtbtk Bgwrl.ftuvtuohuNlbtk «Joðbtl rlgb ylwmth

ftgoJtne fhJtbtk ytJNu.

f:- bkswh &guj xuLzhle mbgbgto>tbtk ftbdehe vqKo l &tg <tu bubtuhuLzb (ltuxem RLJtRxuz

xuLzh) btk sKtJuj «btKu bkswh &guj mbgbgto>t ct>lt FhuFh ctfe ftble hfblt bn•tb

10% juFu (jefJezexe zubuSm) vulÕxe Jmwj fhJtbtk ytJNu.

(11) y:- awfJKe:-

xuLzh Chlthu yu Jt< mbS juJtle hnuNu fu <uKu xtkfujt >h vwhtk &gujt ftb btxult Au ylu <ubtk

bswhe, vtjF, ÃjtLx, >uFhuF, mhJem-ftbdehe, Jes¤e, htugÕxe ylu ytufx[tug Jduhu ykNu

<btb Faoltu <&t sYh sKtg <tu ylu ðgthu ht<vt¤elt ftblu juJt c^t J^thtlt Faoltu

mbtJuN &Nu ylu xtkfujt CtJ fu >h fh<t J^thtle ftuR awfJKe ykdult <ublt ftuR >tJt

ægtlbtk juJtNu lnek ylu xuLzh Chlth Ftuxe hswyt<lu fthKu y&Jt ftuR Ôgrf<yu (vAe<u

ctk^ftb rJCtdltu fboathe ntug fu l ntug) <ublu ytvuje btne<elu yt^thu vtA¤&e ftuR

>tJt> hsw fhJt nf>th hnuNu lnek. <ublw xuLzh ChJt <&t <ubtk sw>t sw>t CtJ ylu >h ChJt

btxu sYhe yuJe <btb btne<e vtu<tlt vûtu l bu¤Je NfJtlu fthKu vtu<u xuLzh hsw fhJtlu je^u

y&Jt <ubtk&e WCt &<t ftuR stuFb fu sJtc>thebtk&e Axfe NfNu lnek. m>h ftbbtk ftuR

vK ò<lt ctk^ftblt bxehegj Wvh CtJ J^thtu ytvJtbtk ytJNu lrnk.

c:- ftuLx[tfxhtulu vubuLx / hlekd cej Bgwrl. frb§h©elt su <u «J<obtl rlgb bwsc fhJtbt

ytJNu. <&t Bgwrl. frb§h©e/mexe Rsluh©e lt su <u JF<ltk mh¾gwjh «btKu

ftbdehe/ybj fhJt rcl Nh<e ckDlf<ot hnuNu.

Signature of Bidder Page 23 of

Ahmedabad Municipal Corporation

f:- ftuLx[t¾xhlt >huf hlekd cejbtk&e ftuLx[t¾xhlu awfJJtle &<e fwj hfb Wvh (xuLzh bwsclwk

vubuLx + yu¾x[t ytRxb) 2 % juFu hexulNl ble ftvJtbtk ytJNu su VtRlj cejbtk vh<

ytvJtbtk ytJNu.

z:- htsg / fuL÷ mhfth©elt JF<tuJF<lt ftg>t bwsc su ftuR hfble fvt< fhJtle &Nu <u

bwsc ftuLx[tfxhlt cejbtk&e fvt< fhJtbt ytJNu.

(12) yu:- fhth mkc^e >M<tJustu fhthlt ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{

ftblu jtdw vzNu.

ce:- xuLzhbtk >NtoJuj ftb mkck^e >M<tJusbtk >NtoJuj rJd<btk rJmkd<<tlt rfMmtbtk leau >NotJuj

¢btlwmth >M<tJusbtk >NtoJj u rJd< d{tng htFJtbkt ytJNu.fhth mkc^e >M<tJustu fhthlt

ydðglt Ctd dKtNu ylu <u mD¤t mne<lt fhth mbd{ ftblu jtdw vzNu.

(yu) yufb ylu f>:-

(2) xuLzh VtuboLþk CtJvºtf

(3) MvuNeVefuNl

z[tu#dbtk f>, ytfth, ytkfzt f>ta Ftuxt ntug <tu btvujt f>, ytfthlu yLþmhÔþk

(2) xuLzh Vtubole yLþMþra-ce

(3) MvuNeVefuNl

Cwj Chujt fu Ftuxt JKollt rfMmtbtk yt mkck^e Wvhefûttyu rJmkd<<t ykdule ltuk^

bwfe yuze.mexe yuLSlegh / zu.BGþrl.frbNlh©ele bkswhe bu¤JJtbtk ytJNu ylu <u bwsc

fhJtbkt ytJuj rlKog ykr<b dKJtbkt ytJNu.

(13) xuLzhhu z[tuRkd fu MvuNeVefuNlbtk hnuje ftuR ûtr< fu Ftbeltu duhjtC juJtle fturNN l fhJe

ylu Rsluh Rlatsuo Ãjtl <&t MvuNeVefuNlle ûtr<ytu mw^thJe <&t <ulwk mtawk y&oDxl

(14) yt Wvhtk< y.Bgw. ftuvtuo. lt slhj ftuLx[tfx fLzeNl vK btLg htFJle hnuNu.

(15) yufe JF<u yuf fh<t J^w søgtytuyu ftb NY fhJtltu Jfo ytuzoh b¤u <tu ftb yuf mt&u s c^u

(16) atjw ftbu mrJom jtRllu lwfNtl l &tg <u he<u ftb fhJtlw hnuNu. stu ftuR mrJom jtRllu

lwfNtl &Nu <tu <ule mkvwKo sJtc>the (òlbtj) ftuLx[tfxhle vtu<tle hnuNu. mtRx Wvh ftb

>hBgtl bswhtu fu sl<tlt ftuR btKmlt òlbtj lu lwfNtl &tg <ule sJtc>the

ftuLx[tfxhle hnuNu. vtujem Vrhgt> &tg <tu <ule sJtc>the vK ftuLxtfxhle hnuNu. CuFz

Dme l vzu <ule sJtc>the vK vtujem Vrhgt>bt ftuLx[tfxhle hnuNu. CuFz Dme l vzu <u btxu

mjtb<elt vdjt (suJt fu >tuhzwk ctk^e bswh Ftztbtk W<thJt, mtuhekd ylu Mx[xekd fhJt

rJduhu) je^t Jdh bsqhlu Ftztbtk W<thNu <tu ftuLx[tfxh s vtujem Vrhgt>bt sJtc>th hnuNu

Signature of Bidder Page 24 of

Ahmedabad Municipal Corporation

ylu Bgwrl.ftuvtuohuNlltu ftuRvK MxtV ytlt btxu sJtc>th hnuNu lrn. ytxjwk mbSlu s

xuLzh ChJwk. bswhtultu rJbtu vK W<thJtu.

(17) bxehegÕm fu ceò xuMxed hevtuxo ftuLx[tfxhu vtu<tlt Fauo ftuvtuohuNl sKtJu <u søgtyu

fhtJJtlt hnuNu. bxehegÕm jtJJt fu jR sJtltu mkvwKo Fao ftuLx[tfxhu CtudJJtltu hnuNu.

(18) M&¤ vrhrM&r< / sYhegt< bwsc ftb fhtJ<t xuLzhlt ytRxblt sÚ&tbtk J^ ^x &tg <tu

rlgb ylwmth <u ykdu ftb fhJt ftuLx[tfxh ck^tgujt Au.

(19) mtRx vh jtJJtbtk ytJuj btj mtbtl hesufx fhJtbt ytJu <tu <whk< r>l 1btk vh< jR

sJtltu hnuNu. yLg&t <ule lwfNtlle sJtc>the ftuLx[tfxhle hnuNu.

(20) ftuLx[tfxhlu su ftuLx[tfx ytvJtbtk ytJu Au. <ubt mhfth©elt «Joðbtl rlgb bwsc

ve.yuV/juch yufx <&t bswhtu <&t MxtVle Jebt vtujeme jElu <ult ftg>tlw vtjl fhJtlwk

hnuNu <&t yt ykdu Bgwrl.ftuvtuohuNl îtht su btne<e btkdJtbtk ytJu <u ytvJtle hnuNu.

bu.BGþrl.frbNlh©elt mh¾âwjh Bþsc sYhe ctknu^he vºtf ytvJtLþk hnuNu.

(21) ftuRvK ftg>tfeg jexeduNl yb>tJt> Nnuhle ftuxobt hnuNu.

(22) btj su <u Mxtumo Wvh y&Jt mtRx Wvh jtuftulu lz<h l &tg <u he<u mwalt bwsc W<thJtltu

<ubs dtuXJJtltu hnuNu.

(23) ftuR vK mhfthe fhJuht ChJtle <btb sJtc>the ftuLx[tfxhle hnuNu.

(24) ftuLx[tfxh îtht xuLzhbt >NtoJuj MveNeVefuNl bwsc MxtLzzo bxehegÕm MvuNeVefuNl bwsc

jtJJtlt hnuNu.<&t xuMxekd fhtJJtlwk hnuNu.<&t y ykdu «Joðbtl Bgwrl.ftuvtuohuNlt rlgbtulw

vtjl fhJtlw hnuNu.

(25) yt xuLzhbtk stu ftuR ytRxb hne dR ntug <tu <u y&Jt M&¤ M&e<e bwsc xuLzhbtk mbtJuN l

ntug <uJe J^thtle ftbdehe fhJtle &tg <uJt rfMmbtk Bgwrl.ftuvtuohuNlt «Joðbtl rlgb

ylwmth J^thtle ytRxblt CtJ lffe fhJtbtk ytJNu ylu <u bwsc awkfJKe fhJtbtk

(26) atjw ftb >hBgtl «tuxufNlle mkvwKo sJtc>the ftuLx[tfxhle hnuNu. subtk vevzt, >tuhzt

Cgmwaf ctuzo, ÃjtMxef vèe, rJ. ftuLx[tfxhu jtJJtlwk ylu mtaJJtlwk hnuNu. ylu ftuRvK

yfMbt< &Nu <tu <ule mkvwKo sJtc>the ftuLx[tfxhle hnuNu.

(27) M&¤ Wvh atjw ftbdehe >hBgtl ftb fhlth ftuLx[tfxhlt bswh / fboathe y&Jt yLg

Ôgrf<lt yfMbt<lt rfMmbtk juch yufx bwsc fhJtle &<e ftgoJtne <&t vtujem

ftgoJtnele sJtc>the ftuLx[tfxhle hnuNu.

(28) stu MxtV mqalt ytvu <u bwsc mwalt vtu&e ftuLx[tfxhu htFJtle hnuNu. <ubtk >hhtus fhuj

ftbdehe <&t yr^ftheytuyu ftb mw^thJt fu «tud{um J^thJtlt ltuk^ fhuj ntug <tu <ulwk

ftuBÃjtgLm ytvJtlwk hnuNu ytJe ltu^lt sJtc l &gu fu <u «btKu M&¤ Wvh ybj l &gu

ftuLx[tfxhlu vulÕxe fhJtle m•ttt yuze.mexe yuLSlehgh©elu hnuNu.

(29) >huf ytRxblt MvuNeVefuNl yb>tJt> Bgwrlrmvj ftuvtuohuNlltk bkswh &guj <&t btLg

htFuj MvuNeVefuNl Nh<tu bwsc hnuNu su ytRxbbtk MvuNeVefuNl l ntug <uJt mkstudtubtk

yuze.mexe.yuLSlegh©eltu rlKog ytFhe hnuNu.Jtuxhekd fhJtbtk lrn ytJu fu >hhtus

Signature of Bidder Page 25 of

Ahmedabad Municipal Corporation

J^thtltu zucheÍ WvtzJtbtk lrn ytJu <tu ftuLx[tfxhlt Fauo ylu sutFbu Jdh ltuxemu Jtuxhekd

fhtJJtbtk <&t zucheÍ WvtzJtbtk ytJNu ylu cejbtk&e hfb ftve juJtbtk ytJNu.

(30) juch JuÕVuh Vkz btxu ntjbtk htsg mhfth©eyu fhuj nwfb bwscle hfb cejbtk&e ftve

(31) atubtmtltu vehegz <t.15 swl &e 14 ytufxtuch Mþ^eltu dKJtbtk ytJNu. yt mbg >hBgtl

ftuLx[tfxh îtht ftbdehe fhe Nftg <ub l ntug <tu <u Bþscle xtEb jebex J^the ytvJtbtk

(32) muÕm xuût / Jux lkch / ve.yuV. ftuz lkch / vtl lkch / S.yum.xe. lkch rJduhu ftuLx[t¾xhu

VhSgt< ytvJtlt hnuNu.

(33) ltbœth ftuxo îtht fhuj nwfb <ubs rlœuo»ttulwk awM<vKu vtjl fhJtlwk hnuNu. subtk z[ulus lu jd<tk

ftb btk ftuRvK mkkstudtubtk bNel ntuj / dxh btk btKmlu W<thJtu lnek <ubs buLgwyj

M¾{uJSkd ykdule btdoœrNoft lwk vtjl fhJwk.

(34) S.yum.xe ftWrLmj îtht lffe fhuj «J<obtl S.yum.xe CtJ bwsc ytvJtbtk ytJNu.

(35) yu.yth.me «fthle ftbdehe ntuR,su <u ftb JtRÍ ftbdehele sÁhegt< bwsc ykœts

cltJe bksqhe btkdJtbtk ytJNu.<ubs su <u ftble hfb bwsc yjd&e Jfo ytuzoh ytvJtbtk

ytJNu <ubs Jfo ytuzohbtk œNtoJuj ftble mbgbgtoœtbtk ftbdehe vqKo fhJtle hnuNu.

yufhthlwk Vtubo

(1) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt xuLzh hsw fh<tk vnujtk buk/ybu M&¤le

bwjtft< je^e Au ylu ftblu jd<t btjmtbtl, bswhe ylu ceS ctc<tulu jd<e

M&trlf vrhrM&r<le ò<-btne<e bu¤Je Au.

(2) nwk/ybu yt&e yufhth fhwk Awk/fheyu Aeyu fu yt ftuLx[tfxhtule Nh<tu rJd<tu ylu xuLzhlu

jd<t >M<tJustu ft¤SvwJof yÇgtm fgtuo Au ylu <u bwsc <ultu ybj fhJt mkb<

ftuLx[tfxhle mne ylu rmfft

Signature of Bidder Page 26 of

Ahmedabad Municipal Corporation

SPECIFICATIONS OF MATERIALS – CIVIL

This section gives detail specifications for mainly used materials, for other materials refer Building

Specifications.

For materials relevant specification of Building Specification shall apply.

TECHNICAL SPECIFICATIONS

NAME OF THE WORK: Ntnvwh Jtuzobtk sw>e sw>e søgtyu htuz vh nuLz juEkd&e vuaJfo fhJtlt juch

ftb.(yu.yth.me.)

Labour charges for hand laying hotmix material DBM/BC on the road surface in line & level incl.

cleaning the surface with air compressor and if require re carting material by JCB at necessary place

of work also rolling with 8 - 10 tonnes vibratory roller and Dust spreading on BC after rolling, rate

also includes re-carting of Hotmix material from place of Work / AMC store to

Location of laying having narrow width like chawls, poles, gamtal roads etc. complete. (AMC

The measurement shall be given on per MT basis

Providing & applying Tack coat with with bitumen imulsion RS1 grade using emulsion pressure

distributerat the rate of 0.20-0.30 kg per sqm on the prepared bituminous surface cleaned with

mechanical broom / air compressor.

The measurement shall be given on per smt. basis

Hiring of Tractor with trolley considering 8 Hrs as working day hours incl.Driver

The measurement shall be given on per shift basis

Hiring of 3-Wheeler carrier (Chhakado/Rickshaw/Chhota Hathi considering 10 hrs as working day

hours inclusive drivers.

The measurement shall be given on per shift basis

Supplying, labour for break down repairing work for activities like excavation, disliting, removing

debris from trench back filling etc. comp. as directed by Eng.in charge.

1) Mazdoor at day /Night

2) Makadam/ supervision at day / Night

Mode of measurement:

The rate shall be for a unit of No Basis.

Providing & Supplying JCB Machine on rental basis in case of emergency situation and

break down type work & also during unavoidable condition as per instructionofengg. incharge , rate

includes all nece. shifting,fuel and operating charges and stacking of useful & non-useful materials

separately up to store.

Signature of Bidder Page 27 of

Ahmedabad Municipal Corporation

The measurement shall be given on per hour basis

Providing, laying, spreading and compacting gradedstone aggregate to wet mix macadam

specificationincluding premixing the Material with water at OMCin mechanical mix plant carriage

ofmixed Materialby tipper to site, laying inuniform layers in subbase/ base course on wellprepared

surface andcompacting withvibratory roller to achieve thedesired density as per MoRTH clause

The provision of MORTH Clause 406 shall apply during construction of Wet Mix Macadam.

The rate shall be for a unit of one Cmt

(a) Extra rate over item of excavation of earth for excavation of asphalt pavement / RCC of

upto 0.20 meter including demolishing the asphalt carpet,metal,soiling/cutting Reinforcement etc.

comp. with stacking the material as directed.(app.rate)

(b) 0.20 meter to 0.30 meter (By Breaker Machine including cost of operator, fuel, & transportaion

(c) 0.30 meter & above (By Breaker Machine including cost of operator, fuel, & transportaion etc

2.1 Extra rate for excavation of asphalt pavement of any thickness including demolishing the

asphalt carpet, metal, soiling etc. complete with stacking the materials as directed. The road

surface of asphalt shall carefully be opened to full width as directed by the Engineer in charge

Asphalt, popada's spouls, metals etc shall be separately deposited in such places as may be

determined by the Engineer-in-charge. In case above materials not being so deposited or being

mixed up with the excavated materials will not be allowed for refilling. The cost of materials shall

be charged from the contractor. The decision of the C.E. shall be final and binding to the

The rate per sq. mt. in this item shall be paid extra addition to the rate for excavation

Mode of measurement: The rate shall be for a unit of Smt Basis.

Supplying Pneumatic Breaker Machine for RCC Slab or Asphalt Demolishing Work on site by using

Operator, fuel, power Supply etc. Complete as Directed. (No payment should be allowed for non

working condition of machinery and for pipe line excavation and M.H. work. Allowed only for break

The measurement shall be given on per hr. basis

Supplying Electric Breaker Machine for RCC Slab or Asphalt Demolishing Work on site by using

Operator, fuel, power Supply etc. Complete as Directed. (No payment should be allowed for non

working condition of machinery and for pipe line excavation and M.H. work. Allowed only for break

down work) ( Based on Previously approved rate by C E sir )

Signature of Bidder Page 28 of

Ahmedabad Municipal Corporation

The measurement shall be given on per hr. basis

Bitumen CuttingLabour charge of cutting in bituminous pavement. Cutting to be done with heavy

duty tandom cutting machine consist of diamond blade. Minimum cutting depth shall be 75 mm from

the finished level. Cutting shall be perfeclty in line. The width and depth of the removal of asphalt

towards kerb stone shall be as per the drawing. Bitumen shall be carefully removed so that the the

cutting edge towards the road should not be disturbed. The work of removal of the asphalt will be

considered in this item as running meter of the cutting done by machine. One cutting line will be

considered per length of the kerb stone.Bitumen and other debris shall be disposed within 10.0 km. as

per the instruction of the engineer in charge. Surroundings shall be cleaned to the satisfaction of the

engineer in charge.

The measurement shall be given on per rmt. Basis

Re-carting of Hotmix material from place of Work/ AMC store to Location of laying havind narrow

width like chawls, poles, gamtal roads using JCB for loading to transorting by tractor trolly including

fuel, driver etc complete as directed.

The measurement shall be given on per MT Basis

Repairing damaged M.H. incl. removing damaged brick and repairing by masonry in C.M. 1:5 and

plaster in C.M. 1:3 and fixing C.I. steps and M.H. and carting the same as directed.

A)………………do………………. Up to 0.15 mt. ( @ Two coarse)

B) ………………do……..………… Up to 0.35 mt. ( @ Four coarse)

C)………………do…………………Up to 0.65 mt. ( @ Seven coarse)

D)………………do…………………Up to 0.90 mt. (@ Ten Coarse )

Repairing damaged I.C./ Raisin removing damaged brick work and repairing by brick masonry

in C.M. 1:5 and plaster in C.M. 1:3 and fixing C.I. steps and existing chamber sheet cover,

removing the debris from chamber and carting the same as directed.

Required level shall be achieved in brick work as specified including plaster, the thickness of joints shall

not exceed 10 mm (3/9”). In no case the frame shall be supported by chips or broken brick or asphalt mix.

All frame of manholes, and chambers etc. shall be kept flush with the general surface of an

asphalt road/concrete pavement. The frame shall be bedded in cement mortar on the brick work with

splayed filler all around.

Water: Gully frames being on the edge of road shall be fixed to the correct road level at its upper end

and the slope should be such it must be about (12 mm) (1/2”) lower than water table.

A concrete pavement should be case around the frames and covers of man-holes, chambers etc.

in case of asphlatic road.

The space around circular frame and covers shall be fully paved with c.c. (1:2:4) as specified and

directed. The pavement shall be at least 8 mm (3”) wider than the outer most edge of the circular frame

no pavement will be made of this pavement under the item of cement concrete.

The space to be paved around hydrant or sluice boxes shall be 1.6 m x 1.5 m (5’ x 5’) in external

measurement and in case if gas siphon or chamber 91 cm x 61 cm (3’ x 2’) the longer dimension being

along the direction of the main.

Signature of Bidder Page 29 of

Ahmedabad Municipal Corporation

In case of rectangular frame cover it shall paved as directed by Engineer with 1:2:4 C.C. No

payment will be made for the pavement should be at least 8 cm (3”) wider than the outer most edge of the

After removing the top portion of the manholes, the proper brick masonry layer with c.m. (1:4)

should be constructed for proper bondage with old masonry and 8 cms thick PCC work (1:2:4) should be

laid on the top of brick layer an up to the bottom of the seat. After fixing the seat the manhole should be

properly leveled with road level.

Filling with cement concrete the spaces around the manholes, chambers, etc. shall be clean

within 48 hours of concreting day.

M/S shall be given on No basis.

Providing F.R.C. MH seat cover incl. carting to the work site etc. comp. Directed. (Based on

rate of central store)

1) F.R.C. Extra Heavy Duty (EHD-35) Manhole Covers & Frames Cover : 728mm ø &

mm thick circular cover,

35.00 MT load design, 100x2mm MS flat allround, 16mm ø plain round bar for lifting the cover

& should be fitted with plastic cups. Frame : 560 mm ø clear opening, outer size-

888x888x175 mm. On the upper periphery of frame 25 x 3 mm wide MS flat should be well

embed in concrete to protect the edges of frame. FRC E.H.D.-35 manhole cover &

frame described as aboveCover Suitable for 50Cm Opening Of MH

2) FRC heavy duty cover size 730 mm. & 90 mm thick circular cover 20 M.T. design load and

frame size 560 mm clear

opening size 890 x 890 x 120 mm.House connection Chamber Light Duty

3) FRC medium duty cover size 670 mm dia & 70 mm thick 10M.T. load design and frame size

560 mm clear opening outer size 780 x 780 x 120 mm

4) FRC medium duty Chamber seat cover (FRC) cover 706 x 556 x 50 mm rectangular cover

frame size 600 x 450 mm clear opening outer size 816 x 666 x 100 mm (MD-10)

5) FRC light duty Chamber seat cover (FRC) cover with

rectangular frame (LD-2.5)

Mode of measurement:-

The rate shall be for a unit of one number basis

I HAVE ALSO GONE THROUGH TECHNICAL SPECIFICATIONS FOR THE ITEMS (AS PER

STANDARD P.W.D. TECHNICAL SPECIFICATION FOR THE ITEMS AND ALSO I HAVE

THE BOOK OF THE SAME) AND AGREE TO ABIDE BY THEM. IN CASE OF WHERE IS NO

TECHNICAL SPECIFICATION FOR THE ANY ITEMS AVAILABLE, SPECIFICATION GIVEN

BY THE ENGINEER-IN-CHARGE SHALL BE FOLLOWED AND FOR THE SAME I AGREE

TO ABIDE BY THEM.

Seal and Signature of the Bidder Addl. City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 30 of

Ahmedabad Municipal Corporation

AHMEDABAD MUNICIPAL CORPORATION

ENGINEERING DEPARTMENT (CENTRAL ZONE)

BILL OF QUANTITY

Sr. Quantity Item Description Rate in Per Amount in

1 400.00 Labour charges for hand laying hotmix material

DBM/BC on the road surface in line & level incl. cleaning

the surface with Air Compressor and if require re carting

material by JCB at necessory place of work also rolling

with 8‐10 Tonnes Vibratory Roller and Dust spreading

on BC after rolling, rate also includes re‐carting of Hotmix

material from place of Work/AMC store to Location of

laying having narrow width like chawls, poles, gamtal

roads etc. complete. (As Per Road Tender) 449.68 MT

2 650.00 Providing and applying Primer Coat with cationic

bitumen emulsion SS1 grade conforming to ASTM

GRADE on prepared surface of wet mix macadam

including clearing of Wet mix macadam surface with air

compressor to remove all loose material other foreign

material. The primer shall be sprayed uniformly at the rate

of 0.70-1.0 kg/sqm. It shall be applied by a self-propelled

or towed bitumen pressure sprayer, equipped for spraying

the material uniformly at a specified rate. No dilution or

heating at site of SS1 bitumen emulsion shall be permitted.

(As Per Road Tender) 40.24 Smt

3 85.00 Hiring of Tractor with trolley considering 8 Hrs. As

working Day hours inclu. Driver (GWSSB SOR-2022-23

Section-2E-Miscellenous Item No.7)

4 85.00 Hiring of 3-Wheeler carrier (Chhakado /Rickshaw /Chhota

Hathi considering 10 hrs as working day hours inclusive

drivers. 1156.76 shift

5 Supplying, labour for excavation of all types of soil at any

depth including excavation of asphalt pavement of any

thickness, demolition of brick work in CM of any

proportion including stacking of serviceable materials and

disposal of unserviceable material etc. comp. as directed.

a 100.00 Mazdoor at day /night (As per min.wages circular of

GOG) 363.30 No.

c 20.00 Makadam/ supervision/Fitter at day / Night 379.46 No.

6 80.00 Providing & Supplying JCB Machine on rental basis in

case of emergency situation and break down type work

& also during unavoidable condition as per instruction of

Engg. In Charge, rate includes all nece. Shifting, fuel

and operating charges and stacking of useful & non-

useful materials separately up to store. (As Per R&B SOR

23-24 Item Code. H016) 711.86 Hour

7 Providing, laying, spreading and compacting graded stone

aggregate to wet mix macadam specification including

premixing the Material with water at OMC in mechanical

mix plant carriage of mixed Material by tipper to site,

laying in uniform layers in sub‐ base / base course on well

Signature of Bidder Page 31 of

Ahmedabad Municipal Corporation

prepared surface and compacting with vibratory roller to

achieve the desired density as per Codal Provision. (As Per

A 85.00 Production & Supply of WMM 1708.13 Cmt

B 85.00 Laying of WMM 31.25 Cmt

8 Extra rate over item of excavation of earth for excavation

of asphalt pavement / RCC of thickness upto 0.20 meter

including demolishing the asphalt carpet, metal, soiling

/cutting Reinforcement etc. comp. with stacking the

material as directed.

450.00 a) upto 0.20 meter thickness (By Manual) 80.00 Smt

200.00 b) 0.20 meter to 0.30 meter (By Breaker Machine

including cost of operator, fuel, & transportaion etc

20.00 c) 0.30 meter & above (By Breaker Machine including

cost of operator, fuel, & transportaion etc complete. 350.00 Smt

9 30.00 Supplying Pneumatic Breaker Machine for RCC Slab or

Asphalt Demolishing Work on site by using Operator, fuel,

power Supply etc. Complete as Directed. (No payment

should be allowed for non working condition of machinery

and for pipe line excavation and M.H. work. Allowed only

for break down work) ( Based on Previously approved rate

by C E sir ) 600.00 Hours

10 30.00 Supplying Electric Breaker Machine for RCC Slab or

Asphalt Demolishing Work on site by using Operator, fuel,

power Supply etc. Complete as Directed. (No payment

should be allowed for non working condition of machinery

and for pipe line excavation and M.H. work. Allowed only

for break down work) ( Based on Previously approved rate

by C E sir ) 1200.00 shift

11 950.00 Bitumen Cutting Labour charge of cutting in bituminous

pavement. Cutting to be done with heavy duty tandom

cutting machine consist of diamond blade. Minimum

cutting depth shall be 75 mm from the finished level.

Cutting shall be perfeclty in line. The width and depth of

the removal of asphalt towards kerb stone shall be as per

the drawing. Bitumen shall be carefully removed so t the

cutting edge towards the road should not be disturbed. The

work of removal of the asphalt will be considered in this

item as running meter of the cutting done by machine. One

cutting line will be considered per length of the kerb stone.

Bitumen and other debris shall be disposed within

km. as per the instruction of the engineer in charge.

Surroundings shall be cleaned to the satisfaction of the

engineer in charge 113.39 Rmt

12 250.00 Re-carting of Hotmix material from place of Work / AMC

store to Location of laying havind narrow width like

chawls, poles, gamtal roads using JCB for loading to

transorting by tractor trolly including fuel, driver etc

complete as directed. 90.00 MT

13 Repairing damaged M.H. and rasing M.H. up to road level

incl. removing damaged brick work and repairing by brick

masonry in C.M. 1:5 and plaster in C.M. 1:3 and fixing

C.I. steps and existing MH sheet cover, removing the

debris from MH and carting the same as directed. (Based

on Drainage SOR 2009-10)

Signature of Bidder Page 32 of

Ahmedabad Municipal Corporation

a 30.00 (A) up to 0.15 mt. (@ Two Coarse) 722.00 No.

b 20.00 (B) up to 0.35mt. (@ Four Coarse) 1144.00 No.

c 10.00 (C) up to 0.65 mt. (@ Seven Coarse) 1769.00 No.

14 5.00 F.R.C. Extra Heavy Duty (EHD-35) Manhole Covers

& Frames Cover : 728mm ø & 100 mm thick circular

cover, 35.00 MT load design, 100x2mm MS flat allround,

16mm ø plain round bar for lifting the cover & should be

fitted with plastic cups. Frame : 560 mm ø clear opening,

outer size- 888x888x175 mm. On the upper periphery of

frame 25 x 3 mm wide MS flat should be well embed in

concrete to protect the edges of frame. FRC E.H.D.-35

manhole cover & frame described as above 1355.00 Set

a 5.00 FRC heavy duty cover size 730 mm. & 90 mm thick

circular cover 20 M.T. design load and frame size 560 mm

clear opening size 890 x 890 x 120 mm.

b 5.00 FRC medium duty cover size 670 mm dia & 70 mm thick

10 M.T. load design and frame size 560 mm clear

opening outer size 780 x 780 x 120 mm

c 5.00 FRC medium duty Chamber seat cover (FRC) cover 706 x

556 x 50 mm rectangular cover frame size 600 x 450 mm

clear opening outer size 816 x 666 x 100 mm (MD-10) 871.00 No.

d 5.00 FRC light duty Chamber seat cover (FRC) cover

with rectangular frame (LD-2.5) 871.00 No.

Seal and Signature of the Bidder Addl. City Engineer

Date: Ahmedabad Municipal Corporation

Signature of Bidder Page 33 of