Wanakbori Thermal Power Station

No. CODE Required

If Any IN %

SUPPLY(PART-A)

CLAMP ON TYPE SPRAY NOZZLE WITH

01 S.S. CAP AND S.S. CLAMP SUITABLE FOR 140 Set

42.5MM OD PVC PIPE.

PVC LOUVERS WITH FIXING FRAME

MADE FROM 10G GI SHEETS CHANNELS Square

WITH PVC LOUVERS HAVING THICKNESS Meter

1.5MM THICKNESS.

6 PASS, 5 BEND PVC ELIMINATOR

HAVING THICKNESS OF 1.2 TO 1.5 MM Square

WITH FIXING FRAME & ANGLE DULLY Meter

HOT DIP GALVANIZED FRAME.

Works (Part – B)

Dismantling & erection of PVC Louvers with

fixing frame

Dismantling & erection of 6 pass, 5 Bend

05 PVC Eliminator with fixing frame including 01 Job

Civil work as per requirement

Note :-For Sr. No. 01 to 05, Overall (L1) offer (i.e. Supply (Part-A) + Work (Part-B)

=L1 (total end cost) will be consider for placement of order.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist:

Kheda -388239 Ph: 91-2699-235522 Fax: 91-2699-235607

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018

Certified Power Plant

Name of Supply and replacement of PVC louvers, Eliminators with fixing frame and

Work other miscellaneous work related to air washery unit#7.

SCHEDULE-A

[A] SUPPLY PART:

 For Item Sr. No. 1:Supply of Clamp on type spray nozzle with S.S. cap and S.S.

clamp suitable for 42.5mm OD PVC pipe.

 For Item Sr. No. 2: Supply of PVC Louvers with Hot Dip Galvanized fixing frame

made from 10G GI Sheets Channels having thickness of 1.5 to 2.0 mm, with suitable

length to accommodate the complete opening area for air inlet at Air washery room of

unit no.07.Party has to supply required fitting accessories having hot dip Galvanized

material i.e. Angle, channels, Nut-Bolts, Tie rod, Fixtures, Supports etc as per site

requirement. Also, Party shall have to calculate required quantity of material as per

site requirement.

Party shall have to supply the PVC louvers, with suitable length to accommodate to

complete opening area for air inlet at Air washery room. Party shall have to calculate

required quantity of material as per site requirement.

 For Item Sr. No. 3: Supply of 6 Pass, 5 Bend PVC Eliminators with Dully Hot Dip

Galvanized fixing frame made from 10G GI Sheets Channels having thickness of

to 2.0 mm, with suitable length to accommodate the complete opening area for air

inlet at Air washery room of unit no.07.Party has to supply required fitting accessories

having hot dip Galvanized material i.e. Angle, channels, Nut-Bolts, Tie rod, Fixtures,

Supports etc as per site requirement. Also, Party shall have to calculate required

quantity of material as per site requirement.

Party shall have to supply the PVC eliminators, with suitable length to accommodate

to complete opening area for air inlet at Air washery room. Party shall have to

calculate required quantity of material as per site requirement.

[B] WORKS PART:

[a] Following major works are in the scope of the contractor for item Sr no: 04 &

(1) Party has to remove the all louvers and eliminators with existing eroded frame of

louvers and eliminators at Air washery unit

(2) Old/removed scrap material shall have to be credited to GSECL main store.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

(3) GSECL will issue materials other than indented item from GSECL stores. Party shall

have to arrange to transport the material from main store to work area.

(4) Party has to arrange the fixing of supplied louvers and eliminators frame. Required

arrangement of scaffolding and civil work are in party scope.

(5) The space between two adjacent louvers should not be more than 90 mm

(6) Party shall have to provide blanks above eliminators about 500 mm with material as

per site requirement and as per the instruction of GSECL EIC.

(7) Contractor shall have to arrange skilled manpower with tools and tackles with

transportation to execute the job after getting clear order from GSECL and shall have

to complete the work within stipulated time period.

(8) The party shall have to visit WTPS site before submitting their offer to understand

exact material requirement and to collect any technical information on any working

(9) Tool-tackles required for subject work like Welding Machine, Oxy-acetylene Cylinder,

Cutting Torch, Press for bending the plates, Grinding Tools, chipping hammer etc.

shall be arranged by the contractor at their own cost only.

(10) Party shall have to arrange red-oxide and followed by black/aluminum paint of Asian

or Burger make paint for painting of any fixing frames as well as all structure steel

work at their own cost.

(11) There should not be any spillage of water though installed eliminators in all 03 air

washery blowers running condition

(12) This is complete job work. Hence any scope of work/materials, which is not

mentioned but required to complete the job at sr no. 04 & 05 are in the scope of

party. No extra charges will be given for the same.

(13) Work Period to execute the entire work at Schedule-B item Sr no: 04 & 05 is

months from the date of work commencement letter / mail issued by WTPS.

[b] Following works are in the scope of the GSECL.

Air, Water and Electricity are provided by GSECL at free of cost form the points

decided by EIC. However, whenever electricity connections are needed by the

contractor, they shall have to mandatorily furnish the complete details of their

equipment in writing (citing work order number), to carry out the tendered work.

[C] Commercial & Other Terms & Conditions:

01.Time Limit: The time limit for the work contract will be 18 Months from the date of

commencement work.

Supply Part: Party has to supply all materials at schedule-B item Sr no: 01,02 & 03 with all

mandatory spares related to item at Sr no:01, 02 & 03 in all respect within 03 months from

date of LOI.

Work Part: Party has to complete removal of existing installed louvers and eliminators and

installation of supplied louvers and eliminators as per scope of work in all respect within

months from the date of commencement letter / Mail issued from WTPS-GSECL.

02.Penalty: If the work is not done as per specification given by the Corporation in stipulated

time in all respects, the penalty will be levied as per Corporation's rules.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

Supply Portion: In all the total delivery Period should not exceed as per above Clause of

Time limit however if the goods are not delivered in time without any reason beyond control,

Penalty at 0.5% Per week or part thereof subject to a maximum of 10% will be levied on end

cost of undelivered material.

Work Portion: Any delay that may take place in work activates beyond contractual cutoff date

/Stiputed period i.e as per above Clause of Time limit in the order shall be subjected to

penalty(not liquidated damage) at the rate 1/2 %of the week contract or part thereof

Subjected to a maximum of 10 %of the value of work portion.(i.e End Cost including taxes &

03.Payment Terms: Party has to accept payment terms as per GSECL rules only i.e. as per

actual work done. NO ADVANCE payment will be allowed.

For Supply: Payment shall be made as per corporation‟s standard only. Payment shall be

made by the Corporation for the material supplied at 80% against TRC within 30 days and

Balance against S.R. Note within 45 days from the date of receipt of material at our site.

For Work: Payment will be made as per actual work done only after taking joint

measurement and the contractor will be Paid 100% amount of actual work done on

satisfactory Completion of job work. Payment will be released within 30 days from receipt of

recorded bill in all aspects .However amount of GST and applicable Cess Will be kept

under retention till Submission of Documentary Proof of Payment of GST or till reflection of

Payment of GST Pertain to respective bill amount in GST Return after due Verification

04.Mobilization: Contractor shall have to mobilize their manpower within IMMEDIATELY after

instruction of EIC. GSECL will complete the work by deputing other agencies if the progress /

quality of works are not found satisfactory at the risk and cost of contractor.

05.AGREEMENT AND INDEMNITY BOND: successful bidder shall have to execute

agreementon stamp paper of Rs 300/- and indemnity bond on stamp paper of Rs 300/- in the

prescribed form before commencement of work. The cost of stamp paper shall be borne by

the contractor.

06.Security Deposit: Security deposit should be paid within 10 days after receipt of LOI i.e.

before placement of order. The successful bidder has to pay an amount @ 5% of the value of

the work order value as security deposit either in case / D.D. / Bank guarantee only.

07.Guarantee period / Warranty Period: The party shall guarantee / warranty for installed

Louvers & Eliminator for 12 months from date of successful installation of work. Any defects

or observation found during Guarantee period / Warranty Period of 12 months, Party shall

have to rectify the same by replacing / repairing at free of cost.

For item sr. no. 01 Party shall have to give Guarantee/Warrantee against manufacturing

defect for the period of 12 months from the date of commissioning or 18 months from the

date of supply whichever is earlier.

08.For Sr. No. 01 to 05, Overall (L1) offer (i.e. Supply (Part-A) + Work (Part-B) =L1 (total end

cost)) will be consider for placement of order.

09.Details of P.F. code No. from the appropriate provident fund authorities and details of P.F.

paid to the employees for last six months. Certificate of separate provident fund account

10.Contractor shall comply with the Factory Acts, Labour Laws and Safety Laws in force and

Amended From time to time.

11.Any other rules and Regulations, Conditions etc. that are in force at present and that may

be Framed by The GSECL from time to time in connection with the Contracts will be binding

and acceptable to the Contractor.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

12.GSECL reserves the right to forfeit the security deposit in case of any breach of contract

and stop dealing with party in future.

13.Party shall have to engage sufficient man power (round the clock also) so that the entire

work is completed in the stipulated time only.

14.Accommodation at GSECL guest house / hostel. Quarters will be provided if available and

on chargeable basis as per GSECL rules.

15.Goods & Service Tax: GST will be paid extra on supply portion whichever applicable.

Party has to submit documentary evidence for the same wherever applicable.GST will be

paid extra on work portion at prevailing rate by GSECL if the same is claimed in the invoice

on production of necessary documents as per government rules. Please quote your Income

Tax PAN No. and Service Tax / GST No. while submitting invoice.

16.Gate pass & medical test related terms:

(A)New photo gate pass procedure for contract workers, following guide line should be

implemented for pre-employment check-up of medical test(form attached) in old contracts &

for new contract and it shall be considered in estimate for as & when & AOH/COH contracts.

1.X-ray chest (PA) view in 14 X 17 inch plate with reporting by qualified Radiologist.

(Maximum Up to Rs. 300/- per worker once during contract period.

2.Pulmonary function test (Maximum up to Rs. 200/- Per worker once during contract period)

3.Eudiometry in Sound proof cabin with reporting by qualified audiologist. (Maximum Up to

Rs. 200/- Per Worker once during contract period).

4.Random blood sugar report, complete Blood count & Urine R/M(Maximum up to Rs. 200/-

per worker once during contract period)

5.Clinical examination & consultation charge for qualified doctor having minimum MBBS with

CIH/AFIH degree for issuing fitness certificate. (Maximum up to Rs. 100/- per worker once

during contract period.

17.If required, party may visit to WTPS for pre-bid meeting, site visit and for discussion

regarding scope of supply / work during office time.

18. Vendor gets to register in VMS System through vms.guvnl.com. For registration following

documents are required. After registration vendor have to upload the invoice in the VMS

system for smooth functioning of payment.

Documents required for VMS Registration:

(1) PAN Copy

(2) GST Certificate Copy

(3) Email ID

(4) Full Name of Vendor

If any query regarding registration please mail to [email protected];

[email protected]; [email protected];[email protected] ; "

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

Gujarat State Electricity Corporation Limited

Wanakbori Thermal Power Station, Ta: Galteshwar, Dist: Kheda -388239

Ph: 91-2699-235522 Fax: 91-2699-235607

Email: [email protected] Web site: www.gsecl.in

CIN: U40100GJ1993SGC019988

AN ISO-9001:2015&14001:2015 OHSMS 45001:2018 Certified Power Plant

GENERAL CONDITIONS OF CONTRACT

1. The contractor shall at their own expense make all necessary provision for housing water supply

and sanitary arrangement for their employee as well as for works and shall pay direct to the

authorities concerned all rates and taxes.

2. The contractor shall make their own arrangements for the necessary approach road, for transport

of their materials and be responsible for the Compensation on account of damage to crop on

Corporations‟ property.

3. All the royalty charges octroi other duties will be paid by the contractor and no extra could be

claimed on this account.

4. The organization will supply articles at the place and rates mentioned in schedule „A‟ of Tender

form.In case of the materials issued either through or with the recommendation of this organization

it will be absolutely necessary for the contractor to maintain a correct and honest record of the

daily consumption of the said materials/with inside particular reference to the work during the day.

The Engineer-in-charge of this department or his authorized agent shall have the right to inspect

and check the stores containing these materials and the account for these materials shall be

presented for inspection whenever asked for by them. Every facility shall be afforded by the

contractors for all these inspections Engineer-in-charge will supply the materials in any quantity as

deemed fit.

5. Godown of sheds hired or constructed for storage of controlled materials and more/ particularly of

cement shall be such as would prevent the materials from getting damages in any way.

6. It will be absolutely incumbent of the contractors to have on the site of work only such of the

materials as have been dully passed by the Engineer-in-charge Materials that have been rejected

must on no account be allowed to remain on the side and in spite of written order to do so any

such rejected material is on the site beyond a period of 48 hours, notice the Engineer-in-charge

shall have the right to remove it at the risk and cost of the contractor and even destroy it.

7. It must be distinctly understood that the conditions of the contract and of claims in respect of extra

work will not be allowed, unless the works to which they relate is clearly without the spirit and

meaning of the specifications or unless such work are ordered in writing by the Engineer-in-charge

and claimed for in specified manner.

8. On completion of the work, the site shall be cleared by the contractors within the stipulated period,

and ground brought to original state and they shall not be entitled for any extra claim on this

9. DAMAGE CAUSES TO WORKS:

The work whether fully constructed or not, and all materials, machinery plant tools, temporary

building and other things connected there shall be at the risk and in the sole charge of the

contractor until the works have been delivered, completed to the Engineer- in-charge and

certificate from him to that effect obtained until such delivery the contractor shall at their own cost

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

take all the precautions reasonably necessary to keep all the aforesaid works materials machinery,

plant, tools, temporary building and other things connected with the work, free from any loss or

damage and in the event to the same or any part there of being lost or damage shall from with

within possible speed, reinstate and make good such loss or damage at contractor‟s own cost.

10. Supply of controlled articles will be invariably recommended after the actual requirements have

been carefully scrutinized. In the event of any such materials remaining in surplus in charge of the

contract, on account of some modifications either in the design or changes in construction or any

other reason will be returned to the department.

11. There will be generally no objection on the component parts of the works being given over to

responsible sub contractors but it must be borne in mind that this department would under no

circumstances recognize these sub contractors and responsibility of executing the work in

accordance with the condition of the contract will entirely rest on the main contractors. The main

contractors will therefore always have the very responsible member preferably a technical hand,

present on the works with power to sign all work order issued on the site of work and to take

requisite actions in the interest of very efficient execution of works.

12. With a view to ensure rapid progress on the works purchaser may store at work sites certain

quantities of the materials such as cement etc. and it will be incumbent on the tender to purchase

these materials, at the rates mentioned in schedule „A‟ of tender form for supply of necessary

articles, all necessary help will be tendered but in must be clearly understood that the purchases

does not accepted and responsibility for the delay that may be cause in their supply on account of

circumstances beyond the purchaser‟s control.

13. Contractor will be asked to present the sample of materials and the approved sampled will be

preserved at the site of work and no change in the approved sample will be allowed without the

written permission of the Engineer-in-charge.

14. Contract will have to communicate the name of his authorized agent who shall be presentation the

works and shall be authorized to sign the materials requisitions receive instruction given verbally,

or on the order book on behalf of the contractor.

15. The materials issued to the contractor as per schedule „A‟ of the tender shall not be removed from

the work and all surplus material at the end of the works which is considered serviceable shall be

returned to the organization even the unserviceable material shall be removed only with the prior

permission to the E.E. in writing.

16. The contractor will have to sign the conditions of the contract and execute the agreement, send

the list of previous works executed solvency certificates and pay up the security deposits, failing to

that the tender will be rejected and earnest money deposit will be forfeited. The value of the stamp

paper and stamp duty charges shall be borne by the contactor.

17. The contractor must arrange for all transport of materials weighting of material issued at

department stores and all such cost include in the rates of schedule „B‟.

18. The competent authorities can delete to any items in the schedule „B‟ of the tender order if they

feel that the items is not essential to be executed.

19. A schedule of quantities is included in the tender document it shall definitely understood that the

Corporation does not accept any responsibility for the correctness or complication of this schedule-

B. The tender documents shall be written legibly and free from grouser, over written on conversion

of figures correction where unavoidable shall be made by crossing out initialing dating and

rewriting both in figures and in words in case of my discrepancy in figures the price quoted in

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

words shall prevail.

20. This notice to tenders shall form a part of the contract.

21. The entire work is to be completed within the stipulated time limit from the date of work order. The

contractor will not be eligible for any extra for the idle period of work or waiting period that may be

required to suit other considerations and no claim for compensation on account of such will be

considered. However in case or delay due to circumstances beyond the control contractor either in

date of commencement or due to waiting during construction extension time may be considered

for completion of work.

22. In case contractor is unable to account for full quantity of materials issued to him from the

department stores, recovery will be effected from him at cost rates or market rates prevailing at the

time of issue whichever is higher, plus 15% to cover Corporation‟s departmental supervision

charges for all material unaccounted for.

23. Bill shall be submitted by the contractor monthly on or before the date fixed by the E.E., for all

works executed in the previous months.

24. SUPPLY OF WATER AND ELECTRICITY:

If possible water for construction purpose only may be supplied by the Corporation at one point as

decided by the Engineer & recovery for water charges shall be effected at two percent of cost of

time as executed in which the water supplied by the Corporation is used as certified by the

Engineer in charge Electric supply is required the contractor shall be given Free of cost by

GSECL. (Applicable to CIVIL WORKS only).

25. Should this tender be accepted, I/We have agreed to abide by and full fill all the terms and

provision of „Tender and Contract of works‟ as applicable, and in default thereof, to forfeit and pay

to the Corporation the some of money due.

26. The work will have to be carried out in co ordination with other Agencies on the same site on

account of this in case the contractor has to stop or delay his works for same time he will not claim

anything extra only Corporation may consider to give suitable extension in time limit if necessary

on such account.

27. Any disputes arising out of the contract if not settled mutually, than the same shall be settle by

Gujarat Public Work Arbitration Tribunal act-1992.

28. Following clauses of this section are not applicable to this contract i.e.

CIRCULAR – I

The following are the major obligations to be fulfilled by the Contractors as per the Contract Labor

(R&A) Act 1970 and rule mentioned there under:

1. License to be obtained before starting the Work where number of contract laborers in Fifty or

2. Payment to contract laborers has to be made in presence of IRO/LWO. Wages rates for contract

laborers are applicable as per the terms and conditions of the license. The contractor shall have to

pay wages to workers as notified by Government of Gujarat., from time to time

3. Every contractor shall have to maintain the muster roll and wages register in respect of his

contract labor.

4. Every contractor is required to issue employment card, wages slip and attendance card to their

5. The contractor has to maintain the register No. 13 containing details of contract labors employed

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

6. Earned leave register/ card as per the Factories Act. And Rules.

7. Other registers required under Contract Labor Rules and the Factories Act. And Rules.

8. Every contractor shall have to obtain insurance policy in respect of the contract labors engaged by

him to cover them under workmen‟s Compensation Act.

9. To send half yearly return to licensing officer as per Rule 82 (1) as per schedule time.

10. Before starting the work as per the contract awarded to him, he should make arrangement to enter

into the agreement in the prescribed format on the stamp paper as applicable. Before fulfilling the

above requirement the contractor is instructed not to start the work. The responsibility will be on

his head in case he fails.

11. Contractor should posses separate P.F. code on their firm, name otherwise their offer may must

be considered.

All the contractors are informed to adhere to the rules and regulations applicable to them,

particularly in respect of the laborers engaged by them, the contractor not fulfilling the obligations

will not be allowed or continue with work/ not be held qualified to carry out the work at TA-

Galteshwar Dist. - Kheda Power Station.

CIRCULAR-2

It has been directed by our CO that, no new labor contract be entrusted to any agency without

getting prior approval from CO. Further the existing contract, on their expiry, may not be extended

without approval from HO, Vadodara.

In light of the instruction conveyed by HO, it is necessary to check up the following documents of

each and every contractor before awarding the contract to these contractors. For preliminary

checking of valid contractors, the following documents are required to be checked by the concern

DE/EE/SE. On their checking the same and by recommending the number of labors, gate pass will

be issued by the Sr. Security officer. But before awarding and finalizing any contracts, following

information must reach to IRO for his confirmation.

1. The contractor should not allowed to engage fifty or more contract labors without initiating to obtain

the labor license under the Contract Labor Act from the Assistant Commissioner of Labor, Nadiad

(The same number i.e. fifty or more includes Supervisor and other staff).

2. Number of days of the contract should be informed first before allowing the contract to start. The

Contractor also must obtain group insurance under WC Act before starting the work.

3. The contract laborers must be paid minimum wages as per notification issued by competent

authority under the said Act from time to time upon issuance of Circular by Chief Engineer, WTPS.

The above instruction must be followed scrupulously to avoid labour liabilities under Contract labor

“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTOR

All the contractors working in Gujarat State Electricity Corporation LimitedFactory like

Coal/Lignite/Gas/Hydro/Pumping Station shall have to strictly observe the following Safety

Rules. Concern principle contractors are responsible for informing & observance of these rules by

their supervisors/contract workers as well as the owner/supervisors/ workers of sub-Contractors

engaged, if any, by them for the work contract awarded to them. Prior to commencement of the

work, Contractor shall have to submit a written assurance on their letterhead to the concerned

Sectional Head / Engineer-in-charge that they have thoroughly gone through these Rules, have

educated their employees / workers of their sub contractor and will strictly observe the said Rules

while execution of work under work contract awarded to them. They will have to indemnify the

company for any loss or damage / accident / injury to the company‟s property / employee or

employee of their own in default of non - observing these rules.

1. Contractor should issue photo gate pass for their workers from GSECL Factory Manager as per

Gujarat Factories rules, 1963 & details shall be filled up in GSECL gate pass format as per Aadhar

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

card /Election card id proof & to follow the gate pass issue procedure through concern department

EE & SE, Security Officer, LWO/IRO/DGM, Factory Medical Officer, Safety Officer/Dy. Safety

Officer & Factory Manager.

2. In case of emergency, temporary photo gate pass shall be issued by Security Officer only for three

days with prior permission of Factory Manager only. More than three days, Permanent photo gate

pass procedure shall be completed by contract agency for their contract workers.

3. Certificate of Fitness of employment in hazardous process & operations in form no.33 of Gujarat

Factories rules, 1963 shall be issued by GSECL Factory Medical Officer for all contractor workers

before commencement of work & examination responsibility shall be taken by contractor as well as

concerned Head of Department .Pre-employment & Periodical medical examination of contractor

workers shall be carried out in form no.32 from GSECL Factory Medical Officer after every six (06)

months of contractor with their contractor workers. Contractor shall be fulfilled all health

requirements before commencement of work. After completion of medical examination in form

no.32/33, GSECL Factory Medical Officer shall be signed in contract worker gate pass procedure

4. If work executed outside factory premises, Principle Contractor shall be registered compulsory

under The Building & Other Construction Workers (Regulation of Employment and condition of

service) Act, 1996 and The Gujarat Building & Other Construction Workers (Regulation of

Employment and condition of service) Rules, 2003 before execution the ”building or other

construction work” means the construction, alteration, repairs, maintenance or demolition, of or, in

relation to, buildings, streets, roads, railways, tramways, airfields, irrigation, drainage,

embankment and navigation works, flood control works (including storm water drainage works),

generation, transmission and distribution of power, water works (including channels for distribution

of water), oil and gas installations, electric lines, wireless, radio, television, telephone, telegraph

and overseas communications, dams, canals, reservoirs, watercourses, tunnels, bridges, viaducts,

aqueducts, pipelines, towers, cooling towers, transmission towers and such other work as may be

specified in this behalf by the appropriate Government, by notification but does not include any

building or other construction work to which the provisions of the Factories Act, 1948 (63 of 1948),

or the Mines Act, 1952 (35 of 1952), apply.

5. Contract worker gate pass will issue after completion of safety induction 3D animation movie &

Training record is to be maintained in IMS/OHSAS training format by TK Office/LWO.

6. As per Gate pass format of GSECL, Safety Officer/Dy. Safety Officer shall be checked the issue

PPE to contract workers as per nature of job, Form no.10 of lifting tools and tackles, Driving

license, Electrical contractor license, Electrical trade qualifications, Safety induction training, SOP,

supervisor qualifications etc. After fulfillment of all Safety compliances, Safety Officer/Dy. Safety

Officer shall be signed in Contract worker Gate pass procedure format.

7. Work Contract shall be completed by principle contractor/agency/person who is awarded the work

order. Subletting of contract shall be allowed only if prior approval of Power station chief before

execution of work. Contractor/agency shall be submitted the entire subletting contract documents

with gate pass application through concern department EE & SE, LWO/DGM, Safety

Officer/Dy.Safety Officer & Factory Manager.

8. Under The Conditions Framed Under Rule-45 Of The Indian Electricity Rules, 1956, Valid

Electrical contractor License shall be submitted to concern electrical department EE/SE/Electrical

Safety Officer/ Safety Officer/Factory Manager at the time of apply gate pass by agency/Contractor

with latest renewal from Chief Electrical Inspector, Gandhinagar- Gujarat. Electrical License

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

photocopy shall be checked by Concerned HOD of Electrical Department/Electrical Safety

Officer/Dy.Safety Officer/ Safety Officer/Factory Manager.

9. As per nature of job/work, Qualified supervisor (Diploma (Electrical/ Mechanical/Civil/C&I) +

years experiences or ITI + 10 years) shall be engaged by contract agency & qualification certificate

with experience certificate shall be submitted to concern EE/SE/LWO/IRO/DGM/ Dy.Safety Officer

/Safety Officer/Factory Manager at the time of apply gate pass.

10. As per rule 3 of CEA regulation ,2010: Designating person(s) to operate and carry out the

work on electrical lines and Apparatus, Contract person/worker possesses a certificate of

competency or electrical work permit, issued by the Appropriate Government. That means,

Electrical trade Qualification of contract worker/person like ITI-wireman/ Electrician, Diploma

(Elect), BE/B. TECH (Elect), ME/ M. TECH (Elect) shall be submitted to concern

EE/SE/LWO/IRO/DGM, Dy.Safety Officer/ Safety Officer/Factory Manager at the time of apply for

photo gate pass procedure.

11. As per nature of job/work & during capital overhauling work /Annual overhauling work /24X7 round

the clock work/major shut down work, Qualified Safety Officer/Manager/Supervisor (BE/Diploma

(Elect/Mech/Civil) + PDIS-Post Diploma in Industrial Safety) shall be engaged by contractor during

dangerous operations/dangerous works as well as day to day dangerous activities, safety

supervision, tool box talk, Safety awareness programme, SOP preparation with hazards & its

control measures with each step , checking of lifting tools & tackles, hydra mobile crane, Safety

precautions, coordination with Safety Department etc.

12. License of driver shall be submitted with gate pass issue application as per nature of vehicles & to

follow the Motor vehicle Act,1988,the Central Motor Vehicles (Amendment) Rules,2016 as well as

Gujarat Motor Vehicles rules,1989 & driver license shall be checked every day by security shift in

charge before entry in the Factory premises.

13. SOP with JSA (Job Safety Analysis) shall be prepared by contractor through competent person as

per GFR, 1963 or Qualified Safety Officer as per GFR, 1963 with 05 years experiences. SOP will

review & approve by concern JE/DE/EE/SE/Elect. Safety Officer/Dy. Safety Officer /Safety

Officer/Factory Manager before execution of work.

14. It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as per the job

requirement. Do not work without use of required P.P.Es. Contractor is responsible to provide

standard make (ISI/DGMS/CE/EN/ANSI approved) & to checked standard/make in PPE issue

format by concern JE/DE/EE/SE/Safety Officer/Factory Manager. Personal Protective Equipments

/ Safety Gadgets suitable to give sufficient protection against hazards involved in their work / job to

their staff, as per the job requirement and insist / enforce their workers to put on the same while at

The ongoing work is liable to be stopped at any time if your contract workers/staffs found working

without P.P.Es. Following is the list of various P.P.Es (as per ISI/DGMS/CE/ EN/ ANSI approved

only) to be used for various works / worksites.

In any work, Contractor shall be issued the minimum 06 nos. of PPEs like Safety Shoes, Safety

Helmet, Safety goggles, Mask & Reusable Ear plug, hand gloves to their workers/supervisor

compulsory & it will check by concern section HOD & Dy. Safety Officer /Safety Officer at the time

of gate pass procedure.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

Quality of PPE shall be approved from Safety Officer as per Indian Standard and International

Standard before executions of work or at the time of gate pass apply procedure.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

List of safety equipments

Industrial Safety Helmet For protection of head against falling objects or during fall

of person from height. YellowColour helmet is used for

contract worker with agency logo.

Safety Goggles/welding goggles/ For protection of eyes against flying particles / dust,

chemical splash goggles chemical splash, welding spark, arc, flashover etc.

Full Face shield For protection of face against flying particles / dust,

chemical splash, spark, arc, flashover etc.

Reusable Earplug / Ear muffs. For ear / hearing system protection while working in high

noise level area.

Chemical suit/Gas tight suit /Fire For body protection against chemicals, oils, sharp edged

proximity suit/FR Boiler Suit objects, heat, hot objects etc.

Safety Hand Gloves For protection of hands against chemicals, oils, sharp

edged objects, heat, hot metals/objects, electricity etc.

Safety shoes/ Gum Boots with For protection of leg/feet against falling objects, sharp

Oil/Chemical/water/heat/ edged objects, heat, hot metals/objects, electricity etc..

Electrical resistance etc.

Safety Belt(full body hardness For fall prevention while working at heights or in depth,

with double lanyard & shock working in vessel or in confined space.

absorber) / Rope / Life line / Fall

arrestor etc.

Dust Mask/Respirator with Protection of respiratory system against dust.

valve(FFP2)

Chemical Cartridge Respirator Protection against toxic chemical fumes /

with full face mask type gases/vapors/dust etc.

Trolley mounted Air line Working in oxygen deficient zone or confine space area

respirators with full face mask

Portable Single gas detector like Working in hazardous storage/process area

Chlorine, Ammonia, Hydrogen,

Portable Multi gas Detector Working in oxygen deficient zone & use in entry of confine

( LEL,O2,CO,H2S,SO2, etc) space & Major fire

Automatic voltage detector To check the present voltage or induction voltage of

electrical equipments/ bus/switch gears from 01 (one) feet

distance before starting the any electrical work .

Auto darkening welding helmet The new auto darkening welding helmet combines

(EN 379 & EN 175 Level-B) with legendary Speed glass quality and auto darkening

PAPR as per EN 12941:1998, technology with an innovative wide-view grinding visor to

class TH2 and AS/NZS 1716 give welders an all-in-one solution for more flexibility,

precision, and efficiency.

Respiratory System is a combined face and breathing

protection device, for increased comfort and safety in

welding. The unit is equipped with a particle filter which

removes particles from the air. The unit provides a

constant airflow independent of filter combinations and

clogging. The unit can also be equipped with a gas filter

(for example A1B1E1). The unit supplies air to the head

top via the connecting breathing tube. The airflow creates

a slight positive pressure which together with the sealing to

BIDDER’S SIGN WITH SEAL the face prevents particles and other contaminants from

RFQ- 77691M entering the head top. Page

15. All PPEs (as per ISI/DGMS/CE/EN/ANSI approved only) Should issued by party/agency/contractor

to their contractor workers as per nature of job and allotment of PPE list shall be submitted to

Safety Officer, Wanakbori on his letter head as per below mentioned format by Contractor before

commencement of work through concerned JE,DE,EE/SE .

Sub: Issue of PEE to Contractor workers

Sub of work Order:

Work order no.

Name of Agency:

Date of Commencement:

Time limit for work order:

Sr Nam De Name Name of IS Make Qt Unit Dat Receivin

. e of sig of PPE :Code of y e of g

N work nat Section no. of PPE issu signatur

o ers ion under PPE e e

Safety Nos

01 Helmet .

Safety Nos

goggles .

Reusable Pair

Dust Mask Nos

Safety Pair

16. Shift Security Inspector/Security Officer shall be checked Safety Shoes & Safety Helmet of all

contractor workers at entry gate of Factory Premises & shall entered contractor workers with

Safety Shoes & Safety Helmet with photo ID Gate Pass.

17. Shift Security Inspector/Security Officer shall be checked validity of Gate pass of all contractor

workers on daily basis.

18. During the work execution, one trained & competent supervisor of agency should always remain

present at work site. Concern JE/DE of GSECL shall be supervised the contract work as per SOP .

19. Approved NABL laboratory calibration certificates of electrical/mechanical/Civil/C&I/Environment

survey/Chemical etc measuring /testing equipments/instruments which are used during contract

work shall be submitted before starting the work & shall be checked by concern JE/DE/EE before

starting work & it‟s record shall be maintained in concern section.

20. The contractor shall take all the required safety measures prior to commencement of work on

dangerous substances, machineries or area at which cautionary notice is displayed and obtain

“Line Clear” or “Work Permit” through the concern Department / Section JE/DE and shall be

informed to concern section JE/DE for closed/ returned after completion of work.

21. Safety talk/Safety work instructions shall be given to contractor workers by concern JE/DE

regarding hazards of specific work, risk & it‟s control measure (mentioned in HIRA) before starting

the job work and records shall be maintained for each & every job works.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

22. Display Safety instructions shall be strictly followed by all workers who are working in factory

23. Material Safety Data Sheet (MSDS) of each chemical shall be available with Chief Chemist/Control

room &work related Chemical information shall be taken by contractor & contractor workers from

Concern EE/Chief Chemist before starting of chemical handling work.

24. The contractor shall be checked & securely covered or securely fenced any opened fixed vessel,

sump, tank, pit or opening in ground or in floor which, by reason of its depth, situation, construction

or contents ,is or may be a source of danger before starting the work each & every days or after

interval/recess. Contractor supervisor shall be informed to concerned HOD regarding any unsafe

conditions.

25. Prohibition of smoking, fires, lights, spontaneous ignition substance, matches; fuses, mobile phone

etc are to be strictly followed by all workers who are working in factory premises.

26. Prior to carrying out welding, gas cutting, furnace heating or any other hot work job, remove all the

inflammable material lying at or nearby worksite or cover it properly by suitable protective covering.

Also, special care shall be taken before carrying out such job & see that all possible contributing

factors to set fire shall be removed / vanished prior to commencement of the work. Advance

intimation shall be given to concerned section / fire section to commence the work in fire prone

areas. They should also keep ready all the First Aid Fire Extinguishers / equipments& fire

extinguishing media / material like sand / water buckets or other appropriate equipment at such

27. While carrying out work in confined space or inside vessel, obtain necessary “Confined Space /

Vessel Entry Permit” from concerned department prior to commencement of the work.

For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp shall be used.

For taking care of the persons working inside the confined space / vessel, a supervisor / person

capable to keep continuous watch on person(s) working inside, assist them in case of emergency

or arrange to get immediate outside help, shall remain present at entry point. Use full body safety

belt without failed.

While working inside sewage, trench or in-depth, a person to warn outsiders / entrants / passers

etc shall remain available near entry point or the entry point shall be cordoned by a barricaded

tape with a cautionary notice. After completion of the works, all the lids / covers / grills / grits

opened, shall be re-fixed / re-placed in the original position as it were prior to commencement of

the work and leave the work place in safe condition in all respect, so as to prevent accident to

fellow workers.

28. The contractor shall see that he / his persons do not work on or block (by stacking material, spare

parts, tools-tackles, equipments etc), any passages / walkways / gangways / aisles / staircases /

ladders / lifts or any other approaches / roads leading to plans or its auxiliaries, on which there is

traffic movements or possible traffic movements in case of emergency. Such passages are meant

for safe escape in the event of emergency. If it is utmost necessary to carry out work in such area

with blocking of passage, prior permission of Competent Authority or the Engineer-In-Charge shall

be obtained. To demarcate / declare the area as “UNSAFE”, cordon it using barricading tape &

display suitable caution notice or keep a person to restrict / divert the traffic on this route through

other safe passage.

29. Prior to use power / electrically operated hand tools / equipments / machines / gadgets like welding

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

machine, hand grinder, hand drill etc, ensure for its safe operation & use it only if it is found safe to

use. Do not use defective, unsafe or improperly maintained equipments.

30. The electrical power supply required to run such equipments shall not be taken directly at their own

but shall be obtained through concerned Electrical Maintenance Departments or their authorized

persons or under their observations / guidance only. The Electrical Section shall provide temporary

electrical connection up to contractor‟s Mains Board on which it is compulsory to install mains

switch, ELCB & fuses of adequate capacity. All such equipments shall invariably be earthed

adequately to prevent electrical shock, sparking, short circuit etc. Power cord to be used shall be of

adequate capacity, without any joint & shall consist of earth wire also. Hence, it is necessary to use

adequate capacity 3-wire power cord for single & 5-wire power cord for three phase power

connections. The plugs, receptacles, pins, holders etc shall be of adequate capacity & safe to use.

All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting machine,

Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used during work execution

shall be of standard make & bear ISI certification mark on it. The consumables like welding

electrodes, grinding wheels / discs etc which has specific prescribed life span shall not be used in

any case if its expiry date is over.

31. Non-Sparking Non-Magnetic electrical hand tools and tool kits shall be used by Electrical

contractor for safe use in areas where hazardous, flammable, or combustible vapors, liquids,

dusts, or residues may be present in Gas Based power plant and list of tools and tackles shall be

submitted with technical bid. Non-Sparking Non-Magnetic electrical hand tools and tool kits shall

be checked by JE/DE before commencement of Electrical work.

32. Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift, mobile crane,

EOT crane etc) & its attachments (like D-shackles, slings, U-clamps, Eye bolts or any fixtures), it

shall be checked and used only if found safe to use. Also, ensure that these are tested, examined

& certified in form no.10 by Competent Person as per the Factory act-1948 & Gujarat Factories

Rules and its validity do not expire. Further, it shall be fixed properly and firmly prior to lifting the

weight. Valid Test certificate of all Lifting machines used by Contractor to be submitted to

Dy.Safety Officer/ Safety Officer before commencement of work through concerned EE/SE.

33. Metal Scaffoldings to be used for working at height shall be of adequate size & capacity. Obtain

the work permit when working at height. While climbing on such scaffolding or working on any

structure at height, use of full body safety belt /full body hardness with double lanyard & Fall

arrestor & Helmet is compulsory. It is also necessary to fasten chinstraps of the helmet.

34. Contractor or their employee shall not interfere in day-to-day routine plant activities / works except

the work assigned to them, shall not loiter in the areas other than their work jurisdiction, as well as

shall not temper / operate / touch the machineries/equipments/auxiliaries with which they are not

concerned. Also, the contractor shall strictly instruct their staff for not to sit or take rest

at/near/below running plants, auxiliaries, systems or any place which is risky, hazardous & prone

to accident.

35. The cylinders containing poisonous / toxic or inflammable / explosive gas like Oxygen, Acetylene,

LPG, Hydrogen, Ammonia, Chlorine, CO2etc shall be handled safely taking due care. To handle /

shift such cylinders a special trolley /cage meant for it must be used but in no case it should be

36. In Gas Based Power station/Hydrogen storage area /Hydro carbon fumes-vapour generated area,

Spark arrestor (as per approved manufacturer of CCOE, Nagpur) shall be provided on each

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

vehicle by party/agency and it will check by shift security in charge before entry of vehicles in the

factory premises.

37. No women or young person shall be employed or permitted to work in Lead-compound area like

battery room etc. as per schedule VI of GFR

38. No women or young person shall be allowed to clean, lubricate or adjust any part of a prime mover

or of any transmission machinery while the prime mover or transmission machinery is in motion.

Examination or operation of motion machinery shall be made or carried out only by a specially

trained adult male worker wearing tight fitting clothing as per section 22 of factories act

39. In all risky job, before start the work, contractor should obtain General Safety Work Permit through

concerned section from Shift –in-charge well in advance.

40. In case of noticing smoke or fire during their work execution, they shall make immediate efforts to

extinguish / control it and simultaneously inform the Fire Station Mobile No as well as Station Fire

Officer or Emergency Control room no which is displayed at prominent place of factory like Main

Security Gate, All unit control room, Canteen area, Safe Assembly points, Fire Station, All security

gates, Occupational Health Centre.

41. In case of any injury / accident while working, it shall immediately be reported to Safety

Department through concerned Sectional Head / Engineer. The prescribed Form No.

21&ANNEXURE may be obtained from concerned section or Dy.Safety Officer/Safety Officer.

In case of any electrical accident, it shall immediately be reported to Electrical Safety Officer

through concern Sectional Head / Engineer. The prescribed Electrical accident form no. A as

per electricity act-2003 & Form No. 21 & ANNEXURE as per Gujarat Factories rules shall be

filled up by concern department JE/DE with written consent of contractor. The Form may be

obtained from concerned Electrical section or Electrical Safety Officer. Electrical accident

investigation shall be carried out by Electrical Safety Officer with Factory Manager.

After any reportable accident, Contract agency shall be submitted the fitness certificate of injured

person with endorsement of GSECL factory Medical Officer to LWO/Dy.Safety Officer/Safety

Officer/Electrical Safety Officer then after injured person may allow for work.

42. For any incident occurred but have no injury to any persons should also reported as per GSECL

format and informed to Dy.Safety Officer/Safety Officer as Near Miss Incident.

43. Safety penalty shall be imposed against Offences by contract workers: If any contract worker

worked in a factory contravenes any provision of Factories act or any rules or orders made there

under ,imposing any duty or liability on workers, contractor/agency shall be punishable with fine

which mentioned as under.

Sr. Description of penalty Amount

(i) Work without PPEs Rs.300/- per person

(ii) Work without work Safety permit like working at Rs.1000/- per day

height, confine space entry, hot work etc.

(iii) License of driver as per type of vehicles not Rs.750/- per person

registered.

(iv) Welding work without flashback arrestor/double Rs.1000/- per set

gauge regulator set

(v) Operate Portable power tool without ELCB Rs.1000/-per equipment

(vi) Work without qualified Supervisor as per nature of Rs.1000/-per day

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

job like mechanical, electrical, civil, C&I, chemical

(vii) Work without SOP & JSA Rs.2000/-per day

(viii) Work without test report of lifting machines / Rs.2000/- per equipment

tackles (like C.P.Bs., Hook chooks, winch, forklift,

mobile crane, EOT crane etc) & its attachments

(like D-shackles, slings, U-clamps, Eye bolts or

any fixtures) in Form No.10 of Gujarat Factories

Rules,1963

(ix) Work without Double lynyer Safety belt during Rs.3000/-per person

working at Height work, work without anchoring in

hook/line line

(x) Work without 24 Volt supply in Confine space Rs.3000/-per person

(xi) (a) Grinding machine used without safety guard / Rs. 500/- per equipment / per set

machine guard

(b) Unsafe welding machine like open body, Knob

without insulation, connection without lug

(c) Damaged welding cables/gas pipelines

(d) Welding work doing without welding blanket

(e) Electrical supply without 3 pin plug/ Industrial

(f) Use of damaged electrical wire for lighting /

equipments

(g) Use of lighting lamp without cage

(h) Use of open halogen tube

(i) Use of damaged PPEs/use of non standard

(j) Unsafe lifting and handling of gas cylinders

(k) Cylinder handling without safety cap

(l) Temporary connection without ELCB etc.

During plant visit/supervision of concern JE/DE/EE, SE, Safety Officer/Safety Officer/Electrical

Safety Officer and Factory Manager/Occupier, if they will observed any safety violations as per CO

circular/statutory requirements then they must imposed Safety Penalty through office note directly

against contract workers/ contract agency and Office note process through proper channel to

concern Section head and Account head for recovery purpose. Photograph/CCTV camera footage

is to be put up with penalty note by imposed individual officer.

44. Contractor will damage any fire equipments or property or machinery in factory during execution of

work, total damage cost will be recovered from Contractor RA bill and recovery Office note put up

by concern HOD.

45. All the relevant labour and industrial laws shall also be followed compulsorily.

46. After completion of work, cotton waste, grease, oil, unused material, welding rod pieces, scrap etc.

are to be removed by contractor and scrap shall be deposited to scrap yard of Main Store.

47. For performance evaluation of contractor, safety factors of work accident, fire incident & near miss

accident will be considered. Steps can be taken to review the job assignment up to cancellation for

negligence.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

48. Over & above these, contractor shall have to follow all the safety requirements /rules & regulations

/ norms and legal provisions laid down in various statutes. Particularly the provisions of The

Factories Act-1948 & the Gujarat State Factories Rules-1963 (Amended up to date), The Electricity

Act-2003 & rules, BOCW Act/Rules shall be followed strictly. The contractor shall also obey the

rules / regulations / instructions of the local Competent Authority for safety & health requirements.

49. The above rules shall be scrupulously followed and where required, Contractor /contractor workers

may contact to the Dy.Safety Officer/Safety Officer/Electrical Safety Officer in case of any

ambiguity or needs further guidance in this regard.

GENERALCONDITION AT CONTRACT

1. “Contract” means the documents forming tender and the subsequent agreement that may be

entered in to.

2. “Work” or “Works” means the work related to the subject mentioned in tender.

3. Contractor” means a firm or an individual undertaking these works or offers the rates for this

4. The general rules and regulations of the GSECL for tender and contract for works will apply to the

extent of the same and not modified herein. The contractor is deemed to have gone through and

considered to be fully aware of the conditions mentioned therein.

5. Earnest Money Deposit:

Tender should be submitted along with Earnest Money Deposit (EMD), without which tender is

liable to be rejected. The exemption in payment of EMD shall be given under following clauses.

1. Micro & small-scale enterprises which participate directly in tendering process for the

product which they are manufacturing / service which they are providing and have Udyam

registration for items / service under procurement.

2. Start-ups which participate directly in tendering process for the product which they are

manufacturing/ service which they are providing and re-cognized by DPIIT under the Start-

up India Program and has obtained Udyam registration.

3. Organization which has registration certificate for the manufacturing product of the tender,

from Gujarat Khadi Gramodyog Board or Khadi and Village Industries Commission

(K.V.I.C) or Commissioner of Cottage Industries.

4. Board/Corporations/PSUs of the Central/ State Government for their own manufactured

5. State Government recognized organizations like (i) organizations for blinds, dumb and

deaf, disabled, mentally disabled persons; (ii) women's self-help group recognized by

Gujarat Livelihood Promotion Company; which participate directly in tendering process for

the product which they are manufacturing / service which /they are providing.

6. Security Deposit:

It is mandatory to submit security deposit before order placement. Contractor shall have to pay

security deposit of 5% of contract value within 10 days from the date of letter of intent. Such

security deposit will be payable either in D.D./ Bank guarantee. Bank guarantees from scheduled/

nationalized banks will be acceptable if the amount of security deposit payable exceed Rs 5000/- .

The bank guarantee will be excruciated on the standard form prescribe by the corporation. In case

of bank guarantees furnished/ submitted they should have clear one time validity till the completion

of the order in all respects and up to the expiry of the guarantee period from the date of work

completion. Bank guarantee for interim period will not be allowed. If by any reason the work period

is extended than contractor should undertake to renew the bank guarantee at least one month

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

before the expiry of the validity failing which GSECL will be at liberty to encash the same.

If the full security amount is not paid immediately after the receipt of the letter of intent, than

the order will not be placed (at the discretion of the GSECL) and without entering to any

correspondence and this will be binding on the tenderer.

If the tenderer fails to pay the security deposit or defaults in execution of the orders place or

if GSECL suffers any financial loss due to this, then GSECL will be liberty to adjust the

amount of others orders of the same firms or by encasing the bank guarantee.

Failure to deposit the S.D. will entail for failure of EMD and the contract shall be treated as

terminated. You shall not be, allow to start the work if, S.D. is not paid. Any loss to the

GSECL due to late start of the work because of the late payment of S.D shall be

contractor‟s liability.

SD will be accepted in form of Bank guarantees issued by ….

[A] Any nationalized bank

[B] Guarantees issued by following banks will be accepted as SD/EMD for the period up

to Dt:31.03.2027. The validity cut-off date In the GR is with respect to the date of

issue of Bank Guarantee irrespective of the date of termination of Bank Guarantee.

A. All Nationalized banks

B. Guarantees issued by following banks will be accepted for the period up to 31-03-2027.The

validity cutoff date in GR is with respect to date of issue of bank Guarantee irrespective of

the date of termination of Bank Guarantee.

1 Axis Bank 23 AU Small Finance Bank

2 Bandhan Bank 24 City Union Bank

3 CSB Bank. 25 DBS Bank India Limited

4 DCB Bank 26 Dhanlaxmi Bank

5 Equitas Small Finance Bank 27 FEDERAL BANK

6 HDFC Bank 28 HSBC Bank

7 ICICI Bank 29 IDBI Bank

8 IDFC First Bank 30 Induslnd Bank

9 Jammu and Kashmir Bank 31 Jana Small Finance Bank

10 Karnataka Bank 32 Karur Vysya Bank

11 Kotak Mahindra Bank 33 RBL Bank

12 South Indian Bank 34 Standard Chartered Bank

13 Tamil nadu Mercantile Bank 35 Ujjivan Small Finance Bank

14 YES Bank 36 Ahmedabad Mercantile CO-op. Bank

15 Nutan Nagrik Sahakari Bank

37 Rajkot Nagrik Sahakari Bank Ltd.

16 Saraswat Co-Operative Bank

38 SBPP Co-Operative Bank Ltd.

17 SVC Co-Operative Bank Ltd. 39 The Cosmos Co-op bank Ltd.

18 The Gujarat State Co-

40 The Surat District Co-Op. Bank

Operative Bank

19 The Surat People‟s Co-Op. The Baroda Central Co-operative

Bank Ltd. Bank

20 The Panchmahal District Co-

42 The Kalupur Commercial Co-op. Bank

Operative Bank

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

The Rajkot Commercial Co- The Banaskantha Mercantile Co-opelative

operative Bank Bank Ltd.

22 Gujarat Gramin Bank

In tender process, for L-1 Bidder Security Deposit will be charged as per table below.

Security Deposit

Category of the Unit Purchase Up-to Rs. 5 Purchase of more than

Lakhs Rs. 5 Lakhs

Enterprises or organizations Exempted 3% of order value

which are Exempted from

paying tender fee & EMD as

per procurement policy

For all other enterprises 5% of order value 5% of order value

7. The security Deposit/ Bank guarantee covering execution of the contract will be released only on

successful execution of contract and on receipt of the “NO Objection Certificate” from the

Engineer In charge of the work.

8. Sublet or transfer of contract without prior written approval of G.S.E.C.L., will be treated, as breach

of contract and it will be punishable by forfeiting the Security Deposit as well as termination of

9. The G.S.E.C.L. reserves the right to forfeit the S.D. in case of any breach of contract and in case

of disputes the decision of C.E., G.S.E.C.L Wanakbori T.P.S. shall be final and binding and shall

be acceptable to the contractor. If the contractor fails to start the work as stipulated the EMD and

the SD shall be forfeited.

10. The following are the major obligations to be fulfilled by the Contractors as per the Contract Labor

(R&A) Act 1970 and rule mentioned there under:

1 The contractor should not be allowed to engage fifty or more contract labourers

without initiating to obtain the labour license under the Contract Labour Act from the

Assistant Commissioner of Labour Nadiad (the said number i.e., fifty or more includes

Supervisor and other staff.)

2 The contractors shall have to obtain group insurance under Employee‟s

Compensation Act before starting the work.

3 All Contractors shall have to make the payment of wages to the Contract Labours

engaged by them, on or before 7th of every month through Nearest Nationalized Bank

compulsory, preferably situated in the premises of Wanakbori TPS area in case of ARC /BRC

works Contract. The Contractor shall supply copy of Bank Statement duly stamped by the

Concerned Bank as a token of proof towards payment of Wages to HR Department. In Case

of Non ARC/ BRC works contract, it is also expected the same practice to be adopt by the

contractor.

4 Payment to contract laborers has to be made through Bank/ Cheque/ RTGS only.

Wages rates for contract laborers are applicable as per the terms and conditions of the

license. The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

5 It should be ensured that all the labours engaged by contractor are covered under

the provident fund scheme and employee‟s pension scheme and their contribution are

remitted regularly to the concerned RPFC. The Xerox copies of challan along with ECR in

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

this regards should be submitted regularly in G.S.E.C.L. office.

6 In case the contractor having more than one contract in the same TPS, the

contractor shall have to submit contract wise separate list of the workmen to the concerned

7 The contractor shall have to pay wages to workers as notified by Government of

Gujarat., from time to time.

11. Labour Laws:

The labour laws applicable and amended from time to time have to be followed scrupulously. A

few of them for information are as under:

a) Person below the age of 18 years and above 60 years should not be employed for the work.

b) No female worker shall be employed in the night shift between 7.00 P.M. to 6.00 A.M.

c) The contractor shall maintain a valid labour license under the contract labour (Regulation and

Abolition) Act for employing necessary man power to be required by contractor. In the absence

of such license the contract shall be liable to be terminated without assigning any reasons

d) The contractor shall at his own expense comply with all labour laws and keep the G.S.E.C.L.

Indemnified in respect thereof. Some of the major liabilities under various labour and industrial

laws, which the contractor shall have to comply, which are as under:

I) Payment of contribution by way of employee‟s contribution towards provident fund, family

pension scheme, deposit linked insurance scheme, administrative charge etc., at the

rates made applicable from time to time by Govt. of Gujarat /Govt. of India and other

statutory authorities.

II) Payment of deposit in respect of each contract labour at the rate applicable of with the

offices of Commissioner of Labour as per the contract labour (Regulation and Abolition)

III) License fee as prescribed under the contract labour (Regulation and Abolition) Act and

rules framed there under depending upon the number of workmen employed by

contractor.

IV) Identity cards as prescribed under the factories Act shall be issued to workmen.

VI) Payment of retrenchment compensation, Notice pay and other liabilities as per Industrial

Disputes Act. Any payment to the contractor's employees arising out of any claim or

disputes under the Industrial Dispute Act 1947 or any other labour laws

VI) Payment of compensation in case of accidental injury shall be made as per the WC Act.

VII) If the female workmen are more than 50 numbers engaged then provision of crèches,

shall be complied accordingly.

VIII) Maternity leave as per the provision of the maternity benefit Act.

The above are some of the major liabilities of the contractor in addition to other liabilities prescribed

under the various labour laws in force from time to time from statutory Authorities like State

Government / Government of India, which the contractor shall have to comply with.

12. Provident Fund and Family Pension Scheme:

The contractor shall submit along with his bill (month wise) statement regarding deductions against

employees‟ provident fund and family pension scheme in respect of each concerned employee.

Provident fund and family pension scheme at the rate of 12 % of wages (or at the rates made

applicable by the Government time to time). The contractor‟s contribution and his workers

contribution towards provident fund and family pension scheme shall deposited by the contractor

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

with Regional Provident Fund Commissioner, Ahmedabad. In case if the contractor deposits the

contribution to the Assistant Provident Fund Commission, the zerox copy of challans and schedule

must be submitted in the office. For maintaining the CPF Account of contractor‟s employees the

contractor will have to pay administrative charges as applicable of the emoluments of the employer

of the contractor's every month.

13. Group Insurance Scheme:

The contractor has to take Group Insurance for all workmen engaged by him and copy of the same

shall be produced to Concerned Officer.

14. Paid Leave Facility:

Paid leave facility at the rate of one day for every 20 days worked by the contract, labour shall be

provided the contractor to his workers. It shall be duly verified and approved/certified by the

authorized officer of the GSECL.

15. The contractor shall employ adequate number of experienced staff at site for daily supervision and

for maintaining of various registers and records required under the law and contracts. No payment

for such supervision shall be admissible.

16. Contractor to Indemnify the GSECL:

The contractor shall indemnify and keep indemnified the GSECL, and every member, officer and

employees of the GSECL, also Engineer-in-charge and his staff against all actions, proceedings,

claims, demands, costs and expenses whatsoever arising out of or in connection with the matter

referred in above clauses and elsewhere and against all actions, claims demands, cost and

expenses which may be made against the GSECL by any workman/ employees of contractor or

any sub contractor and or from any liability any wise to any workman/employees of the contractor

or sub-contractor under any laws, rules or regulation having in force of law including but not limited

to claims against the owner under workmen compensation Act, 1923. The Employee‟s Provident

Fund Act.1952, and/or the contract labour (Abolition and Regulation) Act,

The GSECL shall not be liable for or in respect of or in consequence of any accident or injury to

any workmen or other person in the employment of the contractor or his sub-contractor, and the

contractor shall indemnify and keep indemnified the GSECL against all such damage and

compensation and against all claims, demands proceedings costs, charges and expenses

whatsoever in respect of or in relation thereto.

17. Workmen’s Compensation Fund and Employer’s Liability Insurance:

Insurance shall be affected for all the contractor‟s employees engaged in the execution of these

contracts. If any of the work is sublet, the contractor shall required the sub-contractor to provide

workmen's compensation and Employer's liability insurance for the latter's employees unless

such employees are covered under the contractor‟s insurance. It shall be liability of contractor

for employees of his sub-contractor.

18. Any other rules and regulations, conditions, circulars etc. that are in force at present and that may

be framed by the GSECL from time to time in connection with the contract will be binding and

acceptable to the contractor.

19. The contractor must possess separate P.F. code for the above subject work.

20. Attendance rolls shall be maintained up to date. All the written registers, Performa etc…shall be

filled up and maintained up to date and kept ready for inspection at any time or submitted in-time to

the concerned authorities as per contract labour etc. Factory Act. etc... By contractor.

21. It is the responsibility of the contractor to ensure that his employees maintain strict discipline as

regards security, methods of safe working etc., and not to cause any hindrance to smooth running

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

of power station or in execution of duties by GSECL staff. Any lapse in this regard will be viewed

seriously and contract is liable to be terminated. If any of contractor‟s staff is found unsuitable or

not behaving properly, the contractor shall have to remove him from the work-site on demand by

GSECL. The contractor shall have to strictly observe the rules and conditions specified in the

enclosed works contract booklet of the GSECL, which are not modified hereunder. To keep

harmonious Industrial Relations amongst contract labours is the sole responsibility of the

contractor. Any breach of the same will be viewed seriously.

22. Before starting the work, the contractor should contract Industrial Relation Officer/ Labour Welfare

Officer for all formalities and obtaining the gate passes of all contract labourers and for other

formalities.

23. Follow the following procedure at each milestone for the execution of works contract.

(A) On Commencement of Contractual Work:

(1) The Contractors shall have to obtain Photo-Gate-Pass before the commencement of

contractual work awarded. Contractor shall have to apply for the gate passes in triplicate in

a prescribed application form which is to be available from Security Section for the entry of

workmen in the premises.

(2) Such application shall have to be proceed for the approval of Factory Manager. After

obtaining approval of Competent Authority, contractor shall have to prepare the Gate

Passes and obtain the signature of Factory Manager.

(3) If Labours are required to be engaged in Emergency during Public Holiday , Contractors

Can apply for Temporary Gate-Pass for the period of only three days with recommendation

of respective EE/SE and the same shall have to be regularized after following the

procedure of Gate Pass applications on the office working day from HR Department. It is to

note that No Temporary Gate-Pass shall be issued for the work other than acute

emergency to carry out the work in power station premises.

(4) The Contractor shall have to obtain the Group Insurance Policy under the Employee

Compensation Act, 1923 prior to commencement of work.

(5) The Contractor who intend to engaged 50 or More than 50 labours to Carry out the

awarded contractual work then necessary - Form No. V under the Contract Labour (R& A)

Act, 1970 / Form No. VI under the Interstate Migrant worker (employment regulation) rule

1979 as applicable is to be obtained from HR Department for the purpose of obtaining

Labour License from the Licensing Authority.

(B) During Contractual Work under the progress:

(1) Bill Recording Officer of User department shall have to ensure as to whether contractor

has engaged minimum number of contract workmen per day as per the terms of work

(2) All Contractors shall have to make the payment of wages to the Contract Labours engaged

by them, on or before 7th of every month through Nearest Nationalized Bank compulsory,

preferably situated in the premises of Wanakbori TPS area in case of ARC /BRC works

Contract. The Contractor shall supply copy of Bank Statement duly stamped by the

Concerned Bank as a token of proof towards payment of Wages to HR Department. In

Case of Non ARC/ BRC works contract, it is also advisable the same practice to be

adopted by the contractor.

(3) All Contractors has to comply & maintain statutory documents / registers at site under the

provision of labour laws & EPF Act.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

(C) Submission of Statutory documents to ensure the compliances:

The Contractor shall have to submit following statutory documents, work order wise, under the

labour laws and EPF to the recording officer of user department for ensuring the compliances of

provision of labour laws and EPF Act for the respective working period.

site (duly signed & stamp by Contractor ) - Form XVI

 Copy of Wage Payment Sheet – with signature of workmen, duly signed & stamped by

Contractor - Form XVII

 Copy of Bank Statement of Wage Payment (duly signed & Stamp by Concern Bank)

 Copy of PF Challan along with ECR Statement

 Copy of Gate Pass Permission ( duly signed by Authorities ) -

 Copy of Work Order ( First Time )

 Copy of Valid W.C. Policy

 Copy of Valid Labour License ( If Applicable in case of More than 50 manpower Engaged

by Contractor for said work )

 Form No. XIII – Register of workers employed by Contractor

 Form –C – copy of Bonus Register

 Form -19 – copy of Leave with wages Register

Place of Work and Work order number in Muster Roll- Form No. XVI& Wage Register – Form No

24. Submission of the bill by the contractor:

Bills shall be submitted by the contractor for each month on or before the date fixed by the Site In

charge, for all works, executed in the previous month and the Site In charge shall take or cause to

be taken the requisite measurement for the purpose or having the same verified and the claim so

far as it is admissible, shall be adjusted, if possible, within ten days from the presentation of the

bills. If the contractor does not submit the bill, within the time fixed, as aforesaid, the Site In charge

may depute a subordinate to measure up the said work in the presence of the contractor or his

duly authorized agent, whose counter signature in the measurement list shall be sufficient warrant

and the Site In charge may prepare a bill from such list which shall be binding on the contractor in

all respect. Along with the R.A. Bill, the contractor should submit material Account wherever

applicable, proof of payment of provident fund and other statutory dues, certificate issued by I.R.O.

/ L.W.O certifying average number of labour deployed during the month and total amount of wages

/ L.W.O certifying average number of labour deployed during the month and total amount of wages

and salaries paid to labour. Payment will be made as per actual work done only after taking joint

measurement and The contractor will be paid 100 % amount of actual work done on satisfactory

completion of job work .Payment will be released within 30 days from receipt of recorded bill in all

respect as per corporation‟s rules. However, amount of GST and applicable cess will be kept under

retention till submission of documentary proof of payment of GST or till reflection of payment of

GST pertain to respective bill amount in GST return after due verification.

25. Income Tax:

Income tax will be deducted at source from each bill as per statutory requirements. The GSECL

will be entitled to deduct directly from the bills to be paid to the contractor any sum or sums

payable by the contractor and which sum/sums the GSECL is required to pay as a principal

employer on account of contractor‟s default in respect of all liabilities referred to in above clauses.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

 No sales tax, professional tax or any other taxes, cess or levy, excise duty, octroi, royalty or

other duties will be payable by the GSECL against this contract.

 Service tax at the rate prevalent during period of execution of contract and if applicable will

be reimbursed on production of certified copy of registration number and paid Challan for

payment of service tax from time to time.

26. The quantities mentioned in the Schedule-B are approximate only and may vary widely. The

contractor shall be paid for the actual works carried out at the rates quoted by him.

27. The TDS @ 2% as per Sections 57A and 57B GST Act shall be deducted from the contractor‟s

28. Compensation for the Delay:

The time allowed for carrying out the work as entered in the tender shall be strictly observed by the

contractor and shall be reckoned from the date on which the order to commence work is given to

the contractor. The work shall throughout the stipulated period of contract be proceeded with all

due diligence (time being deemed to be the essence of contract) and the contractor shall pay, as

compensation, an amount equal to ½ percent or such smaller amounts, as the Competent

Authority (whose decision in writing shall be final) may decide of the amount of the contracted cost

of whole work as shown by the tender for every day that the work remains un-commenced or

unfinished after the proper dates. Provided always that the total amount of compensation, to be

unfinished after the proper dates. Provided always that the total amount of compensation, to be

paid under the provisions of the clause, shall not exceed 10 percent of the contracted cost of the

work as shown in tender.

29. Deposit Linked Insurance Scheme:

The contractor shall have to deposit 0.50% (half percent) or the rate applicable from time to time of

the wages in respect of employees who are members of the PF, as the contribution to the Deposit

Linked Insurance Scheme, with the Regional Provident Fund Commissioner, Ahmedabad.

30. Liability towards Gratuity:

The contractor shall deposit 15 days salary at the rate of last drawn salary for every completed one

year of service for each worker for the liability of gratuity.

31. Minimum Wages Act:

The contractor shall pay prevailing minimum wages as applicable from time to time to the labours

engaged by him as per the minimum wages Act, in presence of the GSECL officer or

representative.

32. E.S.I. Act.:

The contractors shall comply with the provisions of E.S.I. Act wherever applicable as per the

prevailing provisions of the Act and as amended from time to time.

33. Administrative Charges:

Administrative charges for maintaining Provident Fund account shall be deposited by the

contractor with the Regional Provident Fund Commissioner, Ahmedabad, at the rates applicable.

34. Safety:

The contractor shall strictly observe all safety rules and provide safety equipment to the contract

labours as per the Factories Act, 1948, and whatever amendments made from time to time to avoid

any chance of accident. The contractor shall strictly observe all instructions of Safety Officer and

Factory Inspector to avoid any chance of accident.The contractor has to provide safety articles to

his contract labour as per the nature of work they have to perform in the contract. A certificate in

this regard has to be obtained from Safety Officer then the detailed work order will be issued.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

35. Compliance to Security Matters:

The power station being a restricted / prohibited area, all the formalities as required by the Security

and Vigilance staff of GSECL should be complied with, to whom the contractor should contact.

36. Submission of Returns & Maintenance of Records:

The contractor shall submit the returns under the Contract Labour Act, Payment of Bonus Act, and

Payment of Gratuity Act etc. and shall have to maintain all up-to date records/registers in respect

his employees as prescribed under various Labour Laws and produce the same as and when

demanded by GSECL‟s appropriate authorities.

37. Contract agreement & indemnity Bond:

As per Corporation‟s rules, Contractor will have to submit an agreement with the Corporation on

stamp paper of appropriate value Rs.300/- in the prescribed form within one month of receipt of

this A.T. or before starting the work. The cost of the stamp fee shall be borne by you. The tender

with the specification, price schedule, drawing and the contract booklet are to be signed by you.

This letter and subsequent correspondence shall be deemed to be part of the Contract.

Contractor will have to submit an Indemnity Bond also with the corporation on stamp paper of

appropriate value Rs.300/- in the prescribed form before commencement of the work. The cost of

the stamp fee shall be borne by you.

38. The contractor must be maintaining regular labour record and should be paying all acquired

benefits to labour force and contractor should obtain certificates to this effect from Labour

Commissioner.

39. Because of this contract, the GSECL shall not accept any additional labour liabilities than stated

40. The contractor will make arrangements at his own cost to insure all men, materials and equipment

employed for this work. The GSECL will not be responsible for any loss or damage either to the

contractor‟s personnel or his equipment.

41. Dispute, if any, taking place between the contractor and labourers must be intimated to Labour

Welfare Officer, Wanakbori TPS, immediately.

42. The contractor must insure all the labourers before starting the works.

43. Any casualty will also have to be borne by the contractor for the period the contract continues.

44. The contractor shall not engage any sub-contractor without written prior permission of the Chief

Engineer or the authorized officer of the GSECL. In no case the GSECL will be liable in any

manner regarding any liability in respect of any contract labours engage by the sub-contractor and

the liability of such contract labours will solely rest with the principal contractor.

45. The GSECL reserves the right to terminate this contract at any time during its currency without

giving notice of termination or any reason thereof.

46. In case of default, the work will be got done through other agency / agencies at the risk and cost of

the original contractor, and the GSECL shall be entitled to recover such expenses from defaulting

contractor by such methods as deemed fit. The contractor shall not, however, be entitled to

terminate the contract or stop works undertaken by him before expiry of the contract period /

extended period due to any reason whatsoever.

47. Under the contract, the contractor should either himself be present at the site or should nominate

persons in writing, who must be available at site and who should be authorized to take decisions

about the works and receive the instructions from Site In charge of the work at any time. In

absence of any responsible man of contractor at the time of any emergency, adhoc decision of Site

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

In charge will be binding on the contractor.

48. The contractor is bound to execute the work for any item as per the instruction of the Site In

charge. On refusal to do so, the work will be carried out at the risk and cost of contractor by using

the contractor‟s tools and tackles, for which no compensation whatsoever shall be payable to the

contractor.

49. If any immovable articles/tools/equipment will be found stolen from the working place, the

contractor would be held responsible and cost will be recovered from his bill.

50. For any conflict and ambiguity, the decision of the Chief Engineer (C&O) shall be final and binding

on the contractor.

51. DISPUTE RESOLUTION MECHANISM:

(1) Amicable settlement

Any dispute, difference, controversy or claim between the Parties arising out of or relating to

this contract with reference to the construction, interpretation, breach, termination or validity

thereof (hereinafter referred as “the Dispute”) shall, upon the written request of either Party be

referred to the authorized representatives of the Disputing Parties for resolution. The

authorized representatives shall promptly meet and attempt to negotiate in good faith a

resolution of the Dispute within thirty days of the service of the request.

(2) Arbitration

If the Parties fail to amicably resolve the disputes or differences or contrary claims as indicated

herewith in sub clause (1) of this Clause, arising under or in connection with the present Works

Contracts, whether pertaining to works contracts alone or works and Procurement both, the

same shall be referred to arbitration under the Gujarat Public works Contracts Disputes

Arbitration Tribunal Act,1992”

52. “D.G.S. & D. Force Majeure Clause”

“ If, at any time during the continuance of this contract, the performance in whole or in part by

either Contractor of any obligation under this contract shall be prevented or delayed by reason of

any war, hostility, act of the public enemy, civil commotion, sabotage fires, floods, explosion,

epidemics, quarantine restrictions, strikes lockouts or acts of God ( hereinafter referred to as

event)”, then provided notice of the happening of any such event is given by either Contractor to

the other within twenty one days from the date of occurrence there of neither Contractor shall by

any claim for damage against the other in respect of such non-performance of delay in

performance, and deliveries under the contract shall be resumed as soon as practicable after such

event has come to end or ceased to exist, and the decision of the Managing Director as to whether

the deliveries have been so resumed or not shall be final and conclusive.

Provided further that if the performance in whole or part of any obligation under this contract is

prevented or delayed by reasons of any such event for a period exceeding 60 days, either

Contractor may at its option terminate the contract provided also that if the contract is terminated

under this clause, the Purchaser shall be at liberty to take over from the supplier at a price to be

fixed by the Managing Director of the GSECL, which shall be final, all unused undamaged and

acceptable materials bought out components, and stores in course of manufacture in the

possession of the supplier at the time of such termination or such portion thereof as the Purchaser

may be deem fit excepting such materials, bought out component and stores as the supplier may

with concurrence of the Purchaser elect to retain”.

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

53. The contractor shall quote rate & also furnish GST, if any, as per Schedule-B. Nothing will be paid

extra as a part of contract unless & until, it is specified in the tender documents by GSECL.

54. The rates quoted shall be firm and valid for 180 days for acceptance from the date of opening.

55. The contractor, if desired, can see the plant and site on any working day and during working hours

with permission of the Chief Engineer.

56. Conditional tender is liable to be rejected withdrawal or insertion of conditions unilaterally after

opening of tenders will not be permitted unless it is so desired by the GSECL.

57. Office correspondence will be carried out in English language, and if at any time to facilitate the

contractor, Gujarati translation may be furnished, if deemed fit. The English version will be the

correct one and the same only will held good for legal matters.

58. The contractor should intimate to the office the name and address of authorized and responsible

representatives, so that our field officers can contact them when required in connection with the

execution of the said works.

Contract Labour Information Management System (CLIMS)

GSECL has developed a Contract Labour Information Management System (CLIMS)- a

comprehensive digital platform designed to manage all activities related to contract labour

transparently and efficiently.

The primary objectives of CLIMS are to save time for both agencies and GSECL personnel, to ensure

full legal and regulatory compliance and to reduce the operational burden on agencies, allowing them

to focus on their core activities. To ensure the successful implementation and operation of CLIMS, the

following guidelines are hereby issued.

A. Gate Pass:

l. CLIMS is a web-based system that can be accessed by agencies from any location using a desktop,

laptop, or mobile device.

2. To begin using the system, agencies must register by entering their EPO (E Urja Order) number. All

other necessary details are automatically fetched from the E-Urja system.

3. The issuance of gate passes for contract labour is managed entirely through CLIMS. Agencies can

generate and track gate passes within the system.

4. In order to enable gate pass issuance, agencies are required to input and upload the necessary

details of their contract labourers into the system.

5. Once the required information is submitted, the gate pass approval process is initiated and managed

through the system. The request automatically moves through the predefined workflow levels.

Agencies can monitor the real-time status of their gate pass applications via CLIMS.

6. Upon completion of all required approvals within the system, the gate pass is issued to the agency.

B. Attendance and wages of workers:

1. Once contract workers gate passes are approved in the system, they are required to be registered in

Bio-Metric/Face Reader Punching machines by HR Department.

2. The attendance of all contract workers can be monitored and maintained through CLIMS by

contractors.

3. Access to data of Bio-Metric is given to agencies. It should be the duty of agencies or his supervisor

to ensure the supply of specified number of manpower and to ensure their Bio-Metric punching and

reporting at the location of work.

4. Attendance register and wage register of the worker will be generated by CLIMS from the login of

agency only.

C. Compliance to various labour laws:

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

l. All the contractors have to comply various labour laws and they shall submit the attached

Declaration-cum Indemnity Bond before staring of work. This Bond may also be made part of ensuing

tenders/contracts.

2. Contractors shall upload the CLIMS generated previous month attendance sheet, wage register duly

signed by workers, wage bank statement, ECR copy, PF Challan and Remittance slip.

3. The said submitted documents in CLIMS will go to user department, after verification of

completeness of documents, user department will forward it to HR Department for further verification

and approval.

4. If the documents are complete, HR Department will approve in CLIMS and send to Account

Department for further process of bill.

5. If non-compliance is found in submitted documents, it will be returned to user department in CLIMS

with specific remarks and user department will forward it to contractor for compliance. In such cases,

75% of the bills may be released subject to a maximum ceiling of 20% of the contract values. Such

system of payment shall be allowed only for 3 monthly Running Accounts (RA) bills (Maximum

cumulative amount up to 20% of the contract value) of the contractor in a period contract (AMC) of

months or 6 RA bills in a period contract (BMC) of 24 months if there is non-compliance. All other RA

bills and specifically final bill shall not be processed if the previous & current compliances are not made

by contractor. No such relaxation will be granted for non-periodic, one time or overhauling type

D. Special Case:

In case of work order issued for expert services to PSU or OEM/OES following procedure may be

1. If officers / specialized manpower / expert Engineers from Govt / Semi Govt Companies / PSUs /

OEM/OES/foreign experts are deployed for short-term, specialized, or ad-hoc technical / consultancy

services (e.g., commissioning, maintenance, consultancy or inspections), concerned Engineer In-

Charge (EIC) shall certify the same

2. The EIC must obtain following documents from the concerned Govt / Semi Govt Companies /

PSUs/OEM/OES etc:

(i) Declaration cum undertaking (As Per Annexure-A) that visiting experts are their regular employees

with documentary proof, and

(ii) Declaration towards compliance of applicable labour laws.

The above documents shall be submitted along with the bill / Invoices by EIC to HR department for the

purpose of HR clearance in lieu of the procedure at Clause -C above.

SIGNATURE OF CONTRACTOR

WITH SEAL & DATE

Chief Engineer (C&O)

GSECL, WTPS

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

Annexure A

Declaration –cum-Undertaking

This is to certify and declare that Shri [Employee's Full Name] , son/daughter of [Father's Name], is

a permanent/regular employee of [Company Name], employed in the capacity of [Designation].

His/Her Employee ldentity Card is attached herewith for reference.

It is further declared that his/her Universal Account Number (UAN) under the Employees'

Provident Fund and Miscellaneous Provisions Act, 1952, is IUAN Number] as applicable

We hereby undertake and declare that:

1. We have complied with all applicable provisions of all the labour laws , including but not

limited to the Employees' Provident Fund and Miscellaneous Provisions Act, 1952; the

Employees' State lnsurance Act, 1948; the Payment of Wages Act, 1936; the Payment of

Bonus Act, 1965; the Contract Labour (Regulation and Abolition) Act, 1970; the Minimum

Wages Act, 1948; and other relevant labour and industrial legislations, in respect of Shri

[Employee's Full Name] as applicable to us.

2. We further undertake to produce, as and when required, all statutory records, registers,

Challans , and returns as proof of compliance to the Gujarat State Electricity Corporation

Limited (GSECL) or any other statutory/government authority.

3. We hereby indemnify GSECL in respect of any civil or criminal liability which may arise due

to any non-compliance of the law of the land in respect of our above-mentioned

This Declaration-cum-Undertaking is issued in good faith and to the best of our knowledge and

belief and shall be binding upon us.

Authorised Signatory,

For [Company Name]

[Authorised Signatory Name]

IDesignation]

[Seal/Stamp of Company]

[contact Details]

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

JSA for:Supply and replacement of PVC louvers, Eliminators with fixing frame and other

miscellaneous work related to air washery unit#7.

Job Step Hazard Risk Level Control Measures Responsibility

Supply and Fall of object High  Area barricaded. Contractor‟s

replacement of from height  Helmet must be used Supervisor

PVC louvers, by all personal in

Eliminators barricading area.

with fixing  Close supervision

other Failure of lifting High  Crane / Hydra must

miscellaneous tools / tackles be operated by

work related to operator

air washery  Confirm crane/hydra

unit#7. to be used as per load

of vehicles.

 Form no 10 must

available for lifting

machine is to be

Fall of object & High  Area barricaded.

person in the  Area should be

sump sufficient illuminated

Fall of personnel High  Work to done as per

& material from checklist of work at

working area height.

Fire High  Proper housekeeping to

be ensured before &

after work start &

completion.

 HOT work must be

taken when work

carried out.

 Area should be

barricaded.

Prepared by Checked by Reviewed by Approved by

(EE) (safety Factory Chief

(JE/DE) Officer) Manager Engineer

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

DECLARATION FORM

ON LETTER HEAD OF SUPPLIER

Subject: Supply and replacement of PVC louvers, Eliminators with fixing frame and other

miscellaneous work related to air washery unit#7.

Reference No:- WTPS/S/TECH/RFQ- 77691M/TMD-3

1. I/We hereby declare that I/We have carefully & thoroughly studied the entire tender placed on

the website and General terms & conditions, technical specification, PQR and other

documents of the tender mentioned under reference along with the Commercial terms and

conditions.

2. I/We hereby confirm and certify that the offer submitted by me/us is strictly in accordance with

the GSECL‟s Tender specifications, Guaranteed Technical Particulars and drawing as

mentioned in the Tender Specifications. There is no commercial or Technical deviation

(except the deviations shown in respective Annexure-12 of Technical Deviations of this

tender document) in the offer from the Board‟s Tender Specification. I undertake to abide by

the GSECL‟s Technical specification / Guaranteed Technical Particulars / Drawing, I

undertake to supply materials strictly as per the GSECL‟s Technical specification /

Guaranteed Technical Particulars / Drawing, even if any technical deviations are mentioned

by me. I also undertake to abide by all commercial conditions of the GSECL, including

delivery schedule. I have submitted all the annexure-1 to 15,form of integrity pact etc along

with the technical Bid dully filled along with all the details”

3. I / We, hereby declare that our Technical Bid is strictly in line with the Tender specifications

(except the deviations shown in Annexure-12 of Technical Deviations of this tender

document).

4. I / We also agree that additional conditions / deviations, if any, found in the Commercial

terms & conditions (except the deviations shown in Annexure-12 of Technical Deviations of

this tender document) our offer shall be out rightly rejected without assigning any reason

5. I/We hereby abide to execute the contract agreement & submitted the same along with the

acceptance of LOI and the same will be acceptable to me/us.

6. I/We hereby accept and confirm that any dispute on this regard shall not be entertained by

7. The full value of the “Earnest Money Deposit” paid herewith should be absolutely forfeited to

the Corporation, should I/ we do not deposit the specified amount of specified Security

Deposit within 10 Days from receipt of the Letter of Intent.

8. If, I fail to submit all required documents with application or tender copy ( in each tender )

then my tender will be cancelled, which is binding to me.

authorized signatory of M/s ______________________________________________ here

by certify that M/s _________________________________________________ and their

proprietor / any partner / any directors of the firm is not stop deal and / or banned for business

dealing and / or black listed by GUVNL and / or their any subsidiary company viz. GSECL /

GETCO / DGVCL / MGVCL / UGVCL / PGVCL as well as Government and / or Semi

Government company / department.

10. We here by confirm that we have not stake in one or more other agencies / bidders who are

participating in same tender and if it is found that the submitted information / declaration are

wrong in the tender / enquiry as stated in tender terms, than we will be disqualified

automatically &it will be accepted to us. EMD / SD will be forfeited. More over if GSECL shall

take stern action including stop dealing with our firms which is also accepted to us

Seal of the Firm Signature of the Tenderer with Designation.

Place: Date:

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

[On Company’s Letter Head]

Annexure –

(Require for Price Justification, if Necessary)

(UNDERTAKING IN REGARD TO QUOTED PRICE)

(All Bidders will have to furnish the following undertaking duly filled in, for all the quoted

items/works of the tender along with online Technical Bid)

Ref.: Tender No……………. / Gem Bid. No.

We, the undersigned, hereby declare and undertake that we have not accepted or executed

any Letter of Acceptance (LOA) or Purchase Order (PO) at a unit ex-works price/any work at

rate lower than the rate offered in this tender in any station of GSECL/GUVNL/ &

Subsidiaries/ CPSU / SPSU/IPP etc. during the period from six (6) months prior to two (2)

months after the bid submission date of this tender.

We also understand that LOA / Purchase Order placed by any station of GSECL/GUVNL

Subsidiaries/ CPSU/SPSU/IPP etc. on the basis of above undertaking shall not be

considered as „offered‟ price for the tender items in subsequent tender, if it is not within

period mentioned above.

I/We accept above undertaking.

Seal of the Firm Signature of the Tenderer

With Designation

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page

<On the letterhead of the vendor/ payee>

To, Date : __________

Subject : Declaration for TDS/TCS under the Income Tax Act (IT Act)

Reference : Provisions of S. 206AB/ 206CCA/139AA of the IT Act

Dear Sirs,

This is with reference to the determination of appropriate Tax deduction at source (TDS) or Tax

collected at source (TCS) as per the provisions of the Act i.e. Section 206AB/ 206CCA/139AA of the

IT Act. In relation to the said provision of the Act: I / We, having status of <<mention status i.e.

Individual/Company/ Firm etc.)>>hereby declare and confirm that: -

a) I/We have<<mention PAN>>Permanent Account Number (PAN) under the IT Act.(Copy of

PAN card is enclosed herewith.)

b) I/We have linked / will be linking Aadhar number with PAN as required under section 139AA

(2) read with Rule 114AAA.latest by 30th June

c) I/We have/have not filed income tax returns (ITR) for two previous years immediately prior to

the year in which tax is required to be deducted and for which last date of filing of income tax

return is expired u/s139(1) of the Act.

I/ We am/ are hereby attaching a copy of acknowledgment of ITR filed for any one of previous

two financial years of which due date u/s139(1) is expired, as proof of filing ITR. (Strike out full

sentence if not filed IT returns)

d) The aggregate amount of Tax Deductible at Source (TDS) and Tax Collectible at Source

(TCS) exceed/don‟t exceed Rs. 50,000 or more in each of the two aforesaid previous years in

my/our case (Vendor has to provide the extract of its Form 26AS if copy of ITR is not provided

e) I/ We shall, indemnify the Company for any consequences arising out of any acts of

commission or omission including incorrect declaration basis which the Company would act

I/We agree that Company shall determine applicability of section 206AB/206CCAof the IT Act

based on the aforesaid declaration/documents filed by me/us and would deduct TDS/TCS

accordingly. The decision of Company shall be final and acceptable to me/us. Strikeout

whichever is not applicable.

Thanking you,

Yours faithfully,

<<Signature>>

< Full Name of Vendor & seal >

BIDDER’S SIGN WITH SEAL

RFQ- 77691M Page