BID DOCUMENTS FOR DESIGN, CONSTRUCTION, ERECTION, TESTING AND COMMISSIONING OF 53 MLD SEWAGE TREATMENT PLANT AT KANAKPUR KANSAD FOR NEWLY ADDED AREA OF NEW SOUTH ZONE, SURAT MUNICIPAL CORPORATION. (INCLUDING 10 YEAR OF OPERATION AND MAINTENANCE)

Name of Work: - Tender Document for

‘DESIGN, CONSTRUCTION, ERECTION, TESTING

AND COMMISSIONING OF 53 MLD SEWAGE

TREATMENT PLANT AT KANAKPUR KANSAD

FOR NEWLY ADDED AREA OF NEW SOUTH

ZONE, SURAT MUNICIPAL CORPORATION.

(INCLUDING 10 YEAR OF OPERATION AND

MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

Web Site: https://tender.nprocure.com

(SURAT MUNICIPAL CORPORATION)

Name of Work: BID DOCUMENTS FOR " DESIGN, CONSTRUCTION,

ERECTION, TESTING AND COMMISSIONING OF 53 MLD SEWAGE

TREATMENT PLANT AT KANAKPUR KANSAD FOR NEWLY ADDED AREA

OF NEW SOUTH ZONE, SURAT MUNICIPAL CORPORATION. (INCLUDING

YEAR OF OPERATION AND MAINTENANCE)”

1. Department Name Drainage Department, Surat Municipal

2. Tender Type Engineering Procurement and Construction

3. Tender Notice No DMC/Drainage/03 /2026-27, Work No.20

Name of Project: Design, Supply, Installation, Testing, and

4. Commissioning of a Sewerage Treatment

Plant (open technology)

Name of Work: BID DOCUMENTS FOR "DESIGN,

5. CONSTRUCTION, ERECTION, TESTING

AND COMMISSIONING OF 53 MLD

SEWAGE TREATMENT PLANT AT

KANAKPUR KANSAD FOR NEWLY ADDED

AREA OF NEW SOUTH ZONE, SURAT

MUNICIPAL CORPORATION. (INCLUDING

10 YEAR OF OPERATION AND

Estimated Contract Value (INR) Rs. 79,95,33,400 (Rs. 56,61,79,000 for

6. Construction and 23,33,54,400 for

Operation and Maintenance Period of

Period of completion of work (In Up to 10 Cr - 12 Months

7. Months) Above 10Cr and up to 25 Cr - 18 Months

Above 25Cr and up to 100Cr - 24 Months

Above 100 Cr - 30 Months

Time period includes Monsoon and Trial Run

(minimum of 3 months Trial Run)

Period of O & M (in Years) 10 (Ten) Years from the date of certification of

8. work completion.

3 (Three) Years Defect Liability Period from

the date of certification of work completion

9. Bidding Type Two Bid System

10. Bid Call (Nos.)

11. Tender Currency Type Single

12. Tender Currency Settings Indian Rupee (INR)

13. Joint Venture Not Applicable

14. Defect Liability Period Duration of 3 Year after certification of work

For Project Cost – Tender Fee (Non-Refundable)

15. Bid Document Fee / Bid From 0.5 Cr up to 1.0 Cr - Rs. 2,832/- (2,400/- +

Processing Fees / Tender Fee: 18% GST) (Minimum Tender Fee )

Above 1.0 Cr and up to 3.0 Cr - Rs. 4,248/- (3,600/-

Above 3.0 Cr and up to 5.0 Cr - Rs. 7,080/- (6,000/-

Above 5.0 Cr and upto 10.0 Cr - Rs. 14,160/-

Above 10.0 Cr and upto 25.0 Cr - Rs. 21,240/-

Above 25.0 Cr and upto 50.0 Cr - Rs. 28,320/-

16. Bid Document Fee Payable To: MUNICIPAL COMMISSIONER, Surat

Municipal Corporation

17. Bid Security / EMD / Proposal Rs. 79,96,000.00 /- (Rupees in words

Security (INR): Seventy Nine lac Ninety six thousand

18. Bid Security / EMD In Favour of: "The Commissioner, Surat Municipal

Corporation" payable at Surat

19. Security Deposit As per Contract Data

Tender Dates Note:

All Dates are in dd/mm/yyyy, hr: min as

per Indian Standard Time (IST)

20. Bid Document Downloading 10/08/2026

21. Site Visit To be conducted at convenience of

Contractor before the submission of the Bid

Contact Number 95107

Contact Address for Site Visit Executive Engineer, Drainage Department,

Old Rander Zone Office, Tadwadi, Rander

main road, Surat

22. Pre-Bid Meeting 25/08/2026

Bidders shall have to post their queries on

E-mail address ( Word Format only)

[email protected]

Address for pre-bid meeting _______

23. Bid Document Downloading 10/09/2026

24. Last Date & Time for Online 10/09/2026 up to 18:00:00 hrs

Receipt of Bids

25. Physical Submission of 11/09/2026 to 23/09/2026 up to 17:00:00

documents last Date & Time hrs

26. Bid Opening Date 11/09/2026 10:30 Hrs Onwards (If

27. Bid Validity Period 180 Days from the last date of submission

Physical submission of Tender Instrument of tender fee & EMD shall be

28. Fee, and Earnest Money submitted in electronic format only through

Deposit online (By scanning while uploading the

bid). This submission shall mean that

Tender Fee and EMD are received for

purpose of opening the bid. Accordingly

offer of only those who shall be opened

whose tender fee and EMD is received

electronically. However, for the purpose of

realization of instrument of tender fee &

EMD, bidder shall send the same in original

through RPAD/ Speed Post so as to reach

to "To Chief Accountant, "Shri Tapi

Bhawan - Surat Mahanagar Seva Sadan"

Gordhandas Chokhawala Marg, Shri

Tapipura, Surat - 395003, Gujarat," as

mentioned in point no. 25 above, during

Any document in supporting to tender bid

shall be submitted in electronic format only

through online (by scanning etc.) and

submission only in hard copy will not be

accepted separately.

• As per City Engineer Shri Note No. 61, Dt.

Penaltative action will be taken for not

submitting original Demand Draft in the

account department of Surat Municipal

Corporation Tapi Bhavan within 7 days from

the last date of online submission of the bid

for the first time as mentioned below.

Sr. Penalty Amount

1. Up to Rs. 1 Crore Rs. 10,000/-

More than Rs. 1 Rs. 20,000/-

2. Crore and Upto

More than Rs. 10 Rs. 30,000/-

3. Crore and Upto

More than Rs. 50 Rs. 70,000/-

4. Crore and Upto

More than Rs. Rs. 1,00,000/-

If bidder will not submit the penalty amount

within 10 days to Surat Municipal Corporation

and/or bidder will not submit the demand draft

in original for the second time and after,

Penaltative action shall be taken for abeyance

of registration and cancellation of E-tendering

code for 6 (six) months.

Payments details

1. Tender fee, Earnest money deposit,

PAN Card shall be uploaded online

2. Tender Fee (Document fee) As per

sr. no. 15 above in favour of "The

Commissioner, Surat Municipal

Corporation" payable at Surat in form

of Demand Draft shall be issued by

any nationalized bank or as per list

mentioned in latest GR of Finance

3. Earnest money Deposit amounting to

1% of the estimated tender cost in

form of Bank Guarantee in favour of

"The Commissioner, Surat

Municipal Corporation" payable at

Surat, valid up to 45 days from the date

of closure of the bid validity period of

180 days i.e. (180 days + 45 days=225

days), shall be issued by any

nationalized bank or as per list

mentioned in latest GR of Finance

Department (Enclosed).

30. Officer Inviting Bids: MUNICIPAL COMMISSIONER, SURAT

MUNICIPAL CORPORATION

31. Bid Opening Authority: MUNICIPAL COMMISSIONER, SURAT

MUNICIPAL CORPORATION

32. Address: Executive Engineer, Drainage Department,

Old Rander Zone Office, Tadwadi, Rander

main road, Surat

33. Contact Details of Officer +91-95107

The following documents shall be

uploaded while submitting the BID

• Scanned copy of Demand Draft as

• Scanned copy of BG as EMD

• Scanned copy of Contractor’s

registration certificate of with

Up to 1.0 Cr – Class D (minimum class)

Above 1.0 Cr and up to 1.5 Cr - Class C

Above 1.5 Cr and up to 3.0 Cr - Class B

Above 3.0 Cr and up to 7.0 Cr - Class A

Above 7.0 Cr – No limit – Class AA

The Contractor shall be duly registered in

accordance with the registration

requirements prescribed by the

34. Submission of tender Government of Gujarat (Roads &

Buildings Department / Water

Resources Department) for the

appropriate class of contractor.

Contractors who are presently

registered with CPWD, Indian Railways,

or any other State Government

Department, or who are registered with

Boards, Corporations, Government

Undertakings, Bodies, or Organizations

of State or Central Governments,

including all Public Sector Units (PSUs),

in categories equivalent to Class “AA/ A

/ B / C / D” or Class-I/II… (or such other

corresponding classifications), and who

otherwise meet the eligibility criteria

specified in the tender documents, shall

be considered eligible, subject to

compliance with the following conditions:

Such Contractors shall apply for

registration in the appropriate “AA /

A / B / C / D” class with the

Government of Gujarat (R&B / WRD)

on or before the last date of

submission of the tender documents.

The Contractor shall further ensure that

final registration in the applicable “AA /

A / B / C / D” class with the Government

of Gujarat (R&B / WRD) is obtained prior

to the date of finalization and issue of

the Work Order.

Proof of submission of application

for registration in the relevant “AA / A /

B / C / D” class shall be uploaded

along with the tender documents,

failing which the bid shall be liable to be

rejected and shall not be considered for

Scanned copy of Bidder’s solvency

certificate. (Minimum 20% of the

estimated tender cost of current

calendar Year i.e. 2026)

• Scanned copy of GSTIN

• Scanned copy of PAN card

• Scanned copies of Experience

certificates showing

successful completion of work

(certified by client)

• Scan copies of financial documents.

In addition to the documents

mentioned above, the documents

required as per attached Forms &

Annexure are also to be uploaded.

Bidder shall submit their offer i.e.,

technical bid as well as price bid in

electronic format on stipulated website

& date as mentioned in the tender

document. No offer in physical form will

If any uploaded scanned submissions

do not open, then such documents

shall not be considered as

“submitted”. And such unopen able

docs shall be treated as “Not

submitted” and shall not be taken into

consideration for evaluation.

35. General Terms & As Per Tender Document

36. Mode of Quoting Rates Online, in words and figures at the end of

MUNICIPAL COMMISSIONER,

SURAT MUNICIPAL CORPORATION

Sr. Section Description Page No

Invitation for Bid (IFB)

1 Section -1 Instructions to Bidders 13 -

2 Section -2 Qualification Information 39 -

3 Section -3 Conditions of Contract 47 -

4 Section -4 Contract Data 125 -

5 Section -5 Technical Specification 130 -

6 Section -6 Form of Bid 874 -

7 Section -7 Bill of Quantities 888 -

8 Section -8 Securities and Other Forms 930 -

9 Section -9 Attached

10 Section -10 Documents to be furnished 943 -

by Bidder / Qualification

11 Section -11 Special Condition 947 -

INVITATION FOR BID

NATIONAL COMPETITIVE BIDDING

1. The MUNICIPAL COMMISSIONER/ CHIEF OFFICER (SURAT MUNICIPAL

CORPORATION) invites bids for the construction of works detailed in the table. The

bidders may submit bids for any or all of the following works.

NOTICE INVITING TENDER

Pack Approximate Cost of

Bid security Period of Class of

age Name of work value of document

(Rs.) completion Registration

No. works (Rs.) (Rs.)

BID DOCUMENTS FOR

“Design, Construction,

Erection, Testing, and

Commissioning of a

MLD Sewage Treatment

Plant at Kanakpur Kansad 30,000 + 24 (Twenty Class “AA”

01 for Newly Added Area of 79,95,33,400 79,96,000.00 18% GST Four and above

New South Zone, Surat =35,400

Municipal Corporation.

(Including 10 Years of

Maintenance) (2nd

2. Prospective / Interested bidder may download the Bid Documents from website

https://tender.nprocure.com free of cost till the Time and Date as mentioned on

online NIT at website https://tender.nprocure.com.

3. However, Bidder who is submitting Bid Online will have to pay the Bid Document

Fee/ Tender Fee through Demand Draft only of any Schedule Bank payable at

SURAT and in favour of "The Commissioner, Surat Municipal Corporation".

Once the Bid is received online, Bid Document / Tender Fee will not be refundable.

The Demand Draft for Bid Document / Tender fee / Bank Guarantee against Bid

Security / EMD shall be submitted in electronic format through online (by

scanning) while uploading the bid, this submission shall mean that bid document /

tender fee and Bid Security / EMD has been received. Accordingly, the offer of

only those shall be opened whose Bid Document / Tender Fee and Bid Security /

EMD have been received electronically. However, for the purpose of realization of

Demand Draft / Bank Guarantee bidder shall send the same in original through

R.P.A.D. so as to reach To Chief Accountant, "Shri Tapi Bhawan - Surat

Mahanagar Seva Sadan" Gordhandas Chokhawala Marg, Shri Tapipura, Surat

• As per City Engineer Shri Note No. 61, Dt. 05/02/2025

Penaltative action will be taken for not submitting original Demand Draft in the account

department of Surat Municipal Corporation Tapi Bhavan within 7 days from the last date

of online submission of the bid for the first time as mentioned below.

Tender Amount Penalty Amount in Rs.

1. Up to Rs. 1 Crore Rs. 10,000/-

2. More than Rs. 1 Crore and Upto Rs. 10 Crore Rs. 20,000/-

3. More than Rs. 10 Crore and Upto Rs. 50 Crore Rs. 30,000/-

4. More than Rs. 50 Crore and Upto Rs. 100 Crore Rs. 70,000/-

5. More than Rs. 100 Crore Rs. 1,00,000/-

If bidder will not submit the penalty amount within 10 days to Surat Municipal Corporation

and/or bidder will not submit the demand draft in original for the second time and after,

Penaltative action shall be taken for abeyance of registration and cancellation of E-

tendering code for 6 (six) months.

4. Bids received online, will be opened on the time, date and place as specified in the

online NIT at website https://tender.nprocure.com in the presence of the bidders or

their authorized representatives, who wish to remain present.

If the office happens to be closed on the day of opening of the bids as specified, the

bids will be opened on the next working day at the same time and venue.

5. A pre bid meeting will be Date: 25/08/2026. Bidders shall have to post their queries

on E-mail address (Word Format only) [email protected] to clarify

the issues and to answer questions on any matter that may be raised at that stage

as stated in clause 9.2 of ‘instructions to Bidders’ of the bidding documents

6. Bid Security (EMD) is equal to 1% of Estimated Amount put to bid / tender and

should be rounded off to the next thousand rupees.

7. Other Information is as under:

A. Agencies can prepare and edit their offers a number of times before the end of the

tender submission date and time. After the tender submission date and time, the

bidder cannot modify / edit / withdraw their submitted offer in any case. No written

or online request in this regard shall be granted.

B. Offers in physical form will not be accepted in any case.

C. Demand Draft purchased by the other than bidder and issued after the last

date of submission of Bids, will not be considered or accepted.

D. The cost incurred by the contractor for this offer for clarification or attending

discussion, conferences or site visits will not be reimbursed by the Employer or

Engineer-in-Charge.

E. Conditional tender shall not be accepted.

F. Any changes, addition, alternation made in the prescribed form attached with

tender are liable to be rejected.

G. Any change in format or conditional Bank Guarantee will not be accepted, and the

bidder will be considered non-responsive.

H. All the bidders are instructed to fill in information strictly in accordance with the

format given in the checklist /qualification document / tender document.

I. It is mandatory for the bidders to supply each and every information as asked

strictly in electronic format at appropriate places only.

J. Blank / insufficient information shall be treated as nil information and shall

result in disqualification.

K. Even if the bidder has been qualified in a similar or larger project in the past, it

shall not be deemed to be a ground / reason for not giving required information

for this work / bid.

L. Information supplied for earlier projects shall not be considered while evaluating

this bid. The Government will not ask for any other information, unless it is found

necessary by the competent authority.

M. If found necessary, the contractor will be intimated for negotiation,

8. For the works costing up to Rs. 7.5 crore (WRD Works), Rs. 7.0 crore (ROAD/

BRIDGE/ BUILDING WORKS), Rs. 0.5 Crore (Electrical Works) kindly refer to

GoG NWRWS & K Department’s Circular No. Paracha/1097/1397(11)/pa.fa./

MICELL(k-1) dated 18/01/2018 and Dated 30/09/2022

For the works costing under Rs. 7.5 crore for Construction work of Water

Resources Department, Rs. 7.0 crore for Roads, Bridges and Building and Rs.

crore for Electrical work

9. Following documents shall be submitted in electronic format only through online

by scanning and the

(i) Bid Document Fee / Tender Fee

(ii) Bid Security or EMD should be sent in original to the Tender opening

authority through RPAD, so as to reach the MUNICIPAL COMMISSIONER/

CHIEF OFFICER within 7 days from last day of submission of Bid.

(iii) Registration Certificate of appropriate class or Above class

(iv) Registration Certificate of Special Category - Road / Bridge / Building

and Category I / II / III, if required

(vi) Work Order and work Experience certificate (3A) certified by the authority

(vii) Other tender forms and Documents, as required for completion of the bid.

(viii) Valid Bank Solvency Certificate for the Current Calendar year

(ix) All other documents mentioned in the bid checklist and requirement of bid.

INSTRUCTIONS TO BIDDERS(ITB)

Section1: Instructions to Bidders Table of Clauses

A. General 15 D. Submission of Bids

1. Scope of Bid 15 19. Sealing & Marking of Bids

2. Source of Funds 15 20. Deadline for Submission of Bids

3. Eligible Bidders 1 21. Late Bids

4. Qualification of the 15 22. Modification and Withdrawal of Bid

5. One Bid per Bidder

6. Cost of Bidding 23 E. Bid Opening and Evaluation

7. Site Visit 23 23. Bid Opening

B. Bidding Documents 24 25. Clarification of Financial Bids

8. Content of Bidding 24 26. Examination of Bids and

Documents Determination of Responsiveness

9. Clarification of Bidding 24 27. Correction of Errors

10. Amendment of Bidding 25 28. Deleted

29. Evaluation and Comparison of

C. Preparation of Bids 26 30. Deleted

11. Language of Bid

12. Documents Comprising 26 F. Preparation of Bids

13. Bid Prices 26 31. Award Criteria

14. Currencies of Bid and 27 32. Employer’s Right to Accept any

Payment Bid and to Reject any or all Bids

15. Bid Validity 27 33. Notification of Award and Signing

16. Bid Security 27 34. Performance Security

17. Alternative Proposals 28 35. Advance Payment and Security

18. Format and Signing of 28 36. Dispute Review Expert

37. Correct or Fraudulent Practices

1. Scope of Bid

1.1. The Employer (Named in Appendix to ITB) invites bids for the Construction of works

(as defined in these documents and referred to as ‘the works”) detailed in the table

given in IFB. The bidders may submit bids for any or all of the works detailed in the

table given in IFB.

1.2. The successful bidder will be expected to complete the works by the intended

completion date specified in the Contract data.

1.3. Throughout these bidding documents, the terms ‘bid’ and ‘tender,’ along with their

respective derivatives (such as bidder/tenderer, bid/tender, bidding/tendering), shall

be construed as synonymous.

2. Source of Funds

2.1. The expenditure on this project will be met from the budget of Govt. of Gujarat / Govt.

of India for centrally sponsored projects.

3. Eligible Bidders

3.1. This Invitation for Bids is open to all eligible bidders.

3.2. All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a

statement that the Bidder is neither associated, nor has been associated, directly or

indirectly, with the consultant or any other entity that has prepared the design,

specifications, and other documents for the Project or being proposed as Project

Manager for the Contract. A firm that has been engaged by the Employer to provide

consulting services for the preparation or supervision of the work, and any of its

affiliates, shall not be eligible to bid.

4. Qualification of the Bidder

4.1. All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a

preliminary description of the proposed work method and schedule, including

drawings and charts, as necessary. The proposed methodology should include a

program of construction backed with equipment planning and deployment duly

supported with broad calculations and quality assurance procedures proposed to be

adopted justifying their capability of execution and completion of work as per technical

specifications, within stipulated period of completion.

4.5. Memorandum of Understanding (MoU) with qualified technology provider shall be

submitted on ₹300/- non judicial stamp paper duly notarized and signed by the

respective authorized representatives clearly stating the terms & conditions of the

MoU as per Tender Form. Such MOU should be valid up to Operation and

Maintenance period and it shall not be amended or modified without prior consent

from Employer during the period of performance of contract; Employer shall not allow

such change except for special reasons. The MoU should also form as part of the

contract agreement.

#4.5 PHYSICAL CRITERIA:

4.5.1 MINIMUM PRE- QUALIFICATION CRITERIA:

If bidder fails to submit above documents or mandatory criteria are not fulfilled, bidder

shall be considered as not qualified and their financial bid shall not be open. To qualify,

each bidder in the same name and style should have achieved the following

List of Mandatory documents to be submitted

a. Registration

b. EMD / Bid Security /Tender Fee

c. Solvency Certificate

e. Bid Capacity

f. Document supporting similar nature of work & Financial and physical criteria.

a. Registration: As per Section: II, Instruction to Bidder, Clause

b. EMD/Bid Security and Tender Fees: As per tender notice.

4.5.2 TECHNICAL QUALIFICATION CRITERIA

4.5.2.1 Similar Nature of Work:

The bidder must have completed similar nature of work i.e., ‘Successfully Design,

Supply, Installation, Testing and Commissioning and Operation & Maintenance

for a minimum period of ONE year of Sewerage Treatment Plant based on SBR /

MBR / MBBR or Equivalent Technology complying with Effluent Discharge

Standards prescribed by the NGT (latest guideline)’ within last Seven (7) Financial

Years i.e., from FY 2019-20 to FY 2025-26 and up to one month prior to last date of

submission of the bid having,

One similar completed work with STP of capacity not less than 80% of Total capacity

Two similar completed works with STP of capacity not less than 50% of Total

Three similar completed works with STP of capacity not less than 40% of Total

Note under 4.5.2.1:

(i) Equivalent Technology shall mean any proven wastewater treatment technology,

other than Sequencing Batch Reactor (SBR), Moving Bed Biofilm Reactor

(MBBR), or Membrane Bioreactor (MBR), which is capable of consistently

achieving treated effluent quality prescribed by the National Green Tribunal

(NGT), CPCB, and the applicable State Pollution Control Board (SPCB).

(ii) Equivalent Technology shall exclude Oxidation Ponds, Oxidation Ditches

(facultative/anaerobic/aerobic), DEWATS, SBT, Waste stabilization pond,

Trickling filters, Oxidation Ditch, Rotating Biological Rotators (RBC), Up-flow

Anaerobic Sludge Blanket (UASB) Technology, Green Technology and Aerated

(iii) Any Equivalent Technology Proposed shall be certified by a

Government-Authorized Representative not below the rank of Executive

Engineer or equivalent.

(iv) NGT Discharge Norms Shall Be Applicable for the Discharge of Treated Effluent

into Natural Water Bodies and Drains.

(v) For establishing similar work experience, the Bidder shall submit an effluent

quality test certificate issued by a NABL-accredited laboratory, confirming that

the treated effluent complies with the NGT-prescribed quality standards. The

Bidder shall also furnish the completion certificate (Form 3A) for the similar

assignment, duly authenticated by an officer not below the rank of Executive

4.5.2.2 Experience Of Designing and Execution of Proposed Technology Provider

(As Applicable)

In case of open technology, plants will become technology driven. If the sole bidder/

lead partner is not a technology provider then the lead partner/ sole bidder must form

Memorandum of Understanding (MoU) with the technology provider (As

applicable depending on type of Technology Proposed) for design and performance

guarantee along with the performance credentials of the offered process, its

philosophy, process/design with calculations, drawing, layout, hydraulic flow diagram,

process flow diagram, P&I diagram, O&M manuals, control philosophy etc. The

technology provider must have a registered office in India fully equipped with

trained manpower to extend services as and when required. Documentary evidence

supporting the above requirements shall be submitted along with the bid. The

Employer reserves the right to verify and examine any or all such documents, as

deemed necessary. In the event that any ambiguity, inconsistency, or discrepancy is

identified in the submitted documents, the bid is liable to be rejected.

The Technology Provider may participate as a Bidder either as a sole bidder or as

a joint venture (JV) partner; however, the Technology Provider shall not be

permitted to participate in more than one bid in the capacity of a Bidder for this

tender. Notwithstanding this restriction, the Technology Provider is permitted to act

as a Technology Provider for more than one bidding entity.

The Technology provider or MoU Partner must have experience of designing

proposed Similar Technology for a minimum capacity of 30% of the maximum

proposed capacity of STP, in any single completed project. The STP as referred

should have been completed during last Seven (7) Financial Years i.e. FY 2019-20

to FY 2025-26 and up to one month prior to last date of submission of the bid and

shall have been in successful operation, for at least one year immediately preceding

one month prior to the last date of bid submission. The technical bid shall be

evaluated based on the facts and circumstances certified by the client not below the

rank of Executive Engineer or equivalent, fulfilling the above- required experience by

the technology provider as evidence.

Memorandum of Understanding (MoU) with qualified technology provider shall be

submitted on ₹300/- non-judicial stamp paper duly notarized and signed by the

respective authorized representatives clearly stating the terms & conditions of the

MoU as per Section-6. Such MOU should be valid up to Operation and Maintenance

period and it shall not be amended or modified without prior consent from Employer

during the period of performance of contract; SMC shall not allow such change except

for special reasons. Also, MoU between the technology provider/contractor shall be

made part of the bid/contract.

Technology provider shall be responsible to provide necessary supervision, support,

spare/replacement inventory on need basis for the performance of the plant. The

process design and drawings shall be vetted and signed by the technology provider

also. Technology provider shall enter into MOU as per Section-6.

In case of STP works where Technology Provider is not required for the proposed

Technology, Contractors shall submit CV/Credentials of Employees who is/are on

payroll of company and have 5 years’ experience of Design and Engineering of STP

based on proposed Technology. The bidder should substantiate such experience

along with relevant degree Certificate of such employee.

Notes under clause 4.5.2.2;

For Technology Provider, the experience of works executed in Government/ Semi

Government/ Public Sector Units of India shall be considered for evaluation. (The

experience of parent associate company of the bidder shall not be considered). Such

certificate shall be given in English language only. The experience of sublet work / in

house / private work shall not be considered in case of Technology Provider.

The experience of any work not supported by client certificate or in any form will not

be considered for qualification. The experience certificate from the client equivalent

to not below the rank of Executive Engineer shall only be considered. The bidder who

has already applied as a prime contractor for the same tender shall not be eligible to

apply under joint venture.

4.5.3 FINANCIAL QUALIFICATION CRITERIA

c. Solvency Certificate

The bidder shall submit a Bank Solvency Certificate indicating a minimum solvency

value of ₹ 20% of the estimated cost of work. The certificate must be issued in the

current calendar year (i.e., 2026) by a nationalized bank or a bank listed in the latest

Government Resolution (GR) of the Finance Department. The certificate must be

printed on the official letterhead of the issuing bank.

Bidder must have achieved minimum annual Financial Turnover (at current price

level) from contract receipt of works (in all classes of civil engineering construction

50% of the estimated cost of work upto ₹ 100 Cr or

65% of estimated cost of work exceeding ₹ 100Cr

in any One (1) Financial Year out of last Five (5) Financial Years i.e. from FY 2021-

Note: The details pertaining to turnover of last five financial years from FY 2021-22

to FY 2025-26 shall be certified by Chartered Accountant on his own letter head and

e. Available Bid Capacity.

Applicants who meet the minimum qualification criteria will be qualified only if their

available bid capacity at the expected time of bidding is more than the total estimated

cost of the work. The available bid capacity will be calculated as below:

Assessed Available Bid Capacity=(A*N*2-B), where

A = Maximum value of work executed in any one year during the last Seven Years

(updated to the price level of the year indicated in appendix) taking into account the

completed as well as works in Progress.

B = Value at current price level of the existing commitments and ongoing works to be

completed during the next (2 year) (period of completion of work for which bids are

Also, declaration of financial liabilities, work on hand / completed projects on Rs.300/-

non-Judicial stamp paper.

In the case of a Joint Venture (Not Applicable), parameters A and B shall be

determined based on details pertaining to such partners who propose to undertake

physical execution of work and in proportion to their participation / stake as specified

in respective clause in the tender documents.

N = Number of years prescribed for completion of the works for which the bids are

invited. (The value of N shall be considered as 1)

If the Tender has been invited as a Package/Slice Minimum aggregate required Bid

Capacity shall be considered and accordingly the Bidder may qualify for less number

of Packages/Slices. In case of individual Tenders (not invited in a single Basket) the

Bidder may qualify for a particular work (based on his Technical Bid), but at the time of

evaluation of Price Bid, if a greater number of such individual Bids are evaluated

simultaneously, aggregate Bid Capacity shall be considered. In such a case, if the

Bidder does not have adequate capacity for all the Bids in which his Bid is the lowest

responsive Bid, he may be considered for a smaller number of Bids. Decision of the

Employer based on the least cost combination as may be the most advantageous to

Nagarpalika shall be final and binding to all the Bidders.

4.5.4 Notes under Minimum Qualification Criteria

i. The statement showing the value and details of completed work, existing commitments

and ongoing work as well as the stipulated period of completion remaining for each of

the work listed should be certified and countersigned by the officer not below the rank

of an Executive Engineer.

ii. The certificate for past performance should be as prescribed Proforma in Section

iii. The Bidders are required to upload work order and latest client’s work experience

certificates (or in any format with yearly breakup) obtained from the respective

authorities/ Employers towards proof of their having executed contracts satisfactorily

along with their bids. The quantities involved should be certified by the top executive

of the firm in the prescribed Proforma as per Section 2 (or in any format with yearly

iv. Physical and financial performance of any work not supported by client certificate or in

any form will not be considered for qualification.

v. The Bidder should furnish information about technical capability (similar nature of work

satisfying Technical Qualification Criteria clause 4.5.2. Bidders are required to

substantiate the information by submission of appropriate client certificates.

vi. The Bidder must provide by uploading evidence of having adequate experience. The

bid should include supporting certificate or report relating to physical, financial,

technical and other capability of Bidder in their original language along with certified

translation of relevant portion of the certificate/ report in English. The Bidder should

furnish the information about financial capability in Rupees only.

vii. Depending upon the actual bid capacity assessed and other qualifying requirements,

the bidder will be qualified for the work.

viii. The bidder is required to submit the declaration of his financial liabilities, work on

hand/completed projects on Rs.300/- non-judicial stamp paper. In case of false

statement/ declaration the bidder shall be liable for penal action. Further, the details

furnished in the relevant form as per tender should be in line with the declaration by

ix. The criteria mentioned above shall be evaluated based on the details submitted with

the documents. Such bidder shall have to submit the details in the prescribed Proforma

which are applicable to them. Bidders should read the note under each Form/Annexure

carefully and submit the details accordingly.

x. Turnover of previous year shall be given additional weightage to bring them to FY

2026-27 Price level to account for price escalation as illustrated below:

Turnover at previous completed

Financial Year Turnover

financial year’s price level

2021-2022 (Base Year – 5yrs) F 1.61 x F

2022-2023 (Base Year – 4yrs) E 1.46 x E

2023-2024 (Base Year – 3yrs) D 1.33 x D

2024-2025 (Base Year – 2yrs) C 1.21 x C

2025-2026 (Base Year – 1yr) B 1.10 x B

2026-2027 (Base Year) A 1.00 x A

xi. Financial year means period beginning from the 1st April to 31st March of the next

xii. The details pertaining to Turnover from FY 2021-22 to FY 2025-26 and the details

pertaining to Net Cash Accrual, Net Worth and Net Working Capital for the from FY

2021-22 to FY 2025-26 shall be certified by Chartered Accountant on his own letter

head and duly attested. The cost of material supplied by the Government / Client shall

not be taken into account for experience against Turnover & Similar nature of work.

xiii. The cost of material supplied by the Government/ Client shall not be taken into account

for experience against Turnover and Similar nature of work.

xiv. The work for which bidder has not entered into contract agreement will not be

xv. The above experience shall be completed within last Seven (7) Financial Years i.e.,

FY 2019-20 to FY 2025-26 and up to one month prior to last date of submission of the

bid, for which Form -3A and 11 must be submitted.

xvi. Experience as sub-Contractor shall not be considered.

xvii. The work executed in Government (State/Central), Board, Corporation, and

Government Undertaking /Organizations of state & central government shall only be

considered for evaluation. The experience certificate from the client is equivalent to not

below the rank of Executive Engineer. The experience of sublet works shall not be

xviii. All MOUs shall be on a Non judicial stamp paper of appropriate value duly notarized

and signed by respective authorized representatives.

xix. The Bidder/ JV Member / MOU partners contract should not have been Terminated/

Blacklisted / Debarred in any State Govt/ Municipal Corporations/ Central Govt. / Any

state Govt Organization, Urban Local body and/or its undertaking company or its SPV,

Asian Development Bank/ World Bank or similar international funding agencies

organizations due to delay in projects during last Seven Years.

xx. The work for which bidder has not entered into contract agreement will not be

xxi. If the bidder claiming Technical / Physical Eligibility Criteria for the works has

completed any of the works in joint venture with any other company then, along with

the experience certificates, the firm shall submit the joint venture agreement for that

particular work. Experience certificates not accompanied by joint venture agreement

shall not be considered for evaluation. The credit for the bidder which has completed

work in joint venture is allocated as follows:

If the bidder has completed the work as a member in the project, then the bidder can

claim credit for the entire scope of the work in proportion to the stake. A statutory

auditor certificate specifying the payments received for the project should be

submitted. In the event of percentage participation in the project calculated through the

statutory auditor certificate differs from the percentage in the Joint Venture Agreement,

the percentage participation calculated through payments received shall be considered

for evaluation purposes.

4.5.4.1 Bidder should fulfil the overall criteria mentioned under Clause 4, Qualification

of the Bidder. If not fulfilled, he will be out rightly rejected.

4.5.5 Personnel Capabilities.

Availability for his work of personnel with adequate experience is required.

The Bidder must have adequate Technical Key staff for carrying out this contract in

accordance with approved work programme. Bidder should submit an undertaking on

₹100 non-judicial stamp paper and notarized mentioning the deployment of

manpower based on the requirement as per the approved project programme.

Eligible Degree with minimum

Sl.No. Key Staff required Requirement in

Master’s in environmental/ mechanical

engineering with 7 Years experience in

Wastewater Process design

1. Process Engineer or

Graduate in Environmental/ Mechanical

Engineering with 10 Years’ experience in

Wastewater Process design

Eligible Degree with minimum

Sl.No. Key Staff required Requirement in

Master’s in Instrumentation Engineering with

7 Years experience in Wastewater Process

Instrumentation

Graduate in Instrumentation Engineering

with 10 Years’ experience in Wastewater

Graduate/Master’s in Civil Engineering with

more than 10 Years experience and

3. Construction Engineer specifically minimum 5 years of experience

in execution of Sewerage Treatment Plants

of any technology.

Diploma/Graduate in Civil Engineering with

4. Site Supervisor

a minimum of 5 Year experience

Technical Assistant/ Degree in Diploma/ITI with a minimum of

Operator Year experience

4.5.6 Equipment Capabilities

Based on the studies carried out by the Engineer, the minimum suggested major

equipment to attain the completion of works in accordance with the prescribed

construction schedule are shown in the Appendix.

The bidders should, however, undertake their own studies and furnish with their bid, a

detailed construction planning and methodology supported with layout and necessary

drawings and calculations to allow the employer to review their proposals. The

numbers, types and capacities of each plant/equipment shall be shown in the

proposals along with the cycle time for each operation for the given production capacity

to match the requirements.

The Bidder must have adequate Plant, Equipment & Machinery for carrying out this

contract in accordance with approved work programme. Bidder should submit an

undertaking on ₹100 non-judicial stamp paper and notarized mentioning the

deployment of machinery based on the requirement as per the approved project

4.5.7 Financial Position Deleted

4.5.8 The audited balance sheets for the last Five Years should be submitted, which must

demonstrate the soundness of the applicant’s financial position, showing long – term

profitability including an estimated financial projection for the next two years, if

necessary, the employer will make inquiries with the applicant’s bankers.

4.5.9 Litigation History

The Applicant should provide accurate information on any litigation or arbitration

resulting from contracts completed or under execution by him over the last Five Years.

A consistent history of awards against the Applicant or any partner of a joint venture

may result in failure of the applicant.

4.5.10 Disqualification

Even though the applicants meet the above criteria, they are subject to be disqualified

Made misleading or false representation in the forms, statements submitted, and/or

Record of poor performance such as abandoning the work, rescinding of contract for

which the reasons are attributable to the non – performance of the contractor;

consistent history of litigation awarded against the applicant or financial failure due to

bankruptcy. The rescinding of contract of a joint venture on account of reasons other

than non – performance, such as Most Experienced partner of joint venture pulling out,

court directions leading to breaking up of a joint venture before the start of work, which

are not attributable to the poor performance of the contractor will, however, not affect

the qualification of the individual partners.

4.5.11 The bidder who has applied for corporate Debt Restructuring (CDR) / facing recovery

proceedings from financial institutions / facing winding up processing / those under BIFR in

the last 5 financial year shall be considered for bid qualification. However, if the bank /

financial institution has accepted the proposal of debt restructuring on or before the last

date of online submission, the same shall be considered for further evaluation. An affidavit

by bidder along with certificate from bank must be produced in such cases. In case of Joint

Venture agreement, this provision shall be applicable for both lead partner and JV partner.

# 4.6 JOINT VENTURE: Not Applicable

4.8 Even though the bidders meet the above qualifying criteria, they are subject to

be disqualified if they have:

- Made misleading or false representation in the forms, statements and

Attachments the submitted in proof the qualification requirements; and / or

- Record of poor performance such as abandoning the works, not properly completing

the contract, inordinate delay in completion, litigation history, or financial failures

- Participated in the previous bidding for the same work and had quoted unreasonably

high bid prices and could not furnish rational justification to the employer.

5. One bid per bidder

5.1. Each bidder shall submit only one bid for one package. A bidder who submits or

participates in more than one bid (other than as a subcontractor or in cases of

alternatives that have been permitted or requested) will cause all the proposals with

the bidder’s participation to be disqualified.

6. Cost of Bidding

6.1. The bidder shall bear all costs associated with the preparation and submission of his

Bid, and the Employer will in no case be responsible and liable for those costs.

7.1. The Bidder, at the Bidder’s own responsibility and risk, is encouraged to visit and

examine the Site of work and its surroundings and obtain all information that may be

necessary for preparing the Bid and entering into a contract for construction of the

The costs of visiting the site shall be at Bidder’s own expense.

SIGNATURE OF CONTRACTOR MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

B. BIDDING DOCUMENTS

8. Content of Bidding Documents

8.1. The set of bidding documents comprises the documents listed below, and

addenda issued in accordance with Clause 10:

Section Particulars Volume No.

- Invitation for Bids

1 Instructions to Bidders I

2 Qualification Information, and other forms

3 Conditions of Contract

4 Contract Data

5 Technical Specifications II

6 Form of Bid III

7 Bill of Quantities

8 Securities and other forms

10 Documents to be furnished by bidder V

8.2. Volumes I, II, III and IV are available online and documents to be furnished by

the bidder in compliance with Section 2 will be prepared by him and furnished

as in two parts (refer clause 12).

8.3. The bidder is expected to examine carefully all instructions, conditions of

contract, contract data, forms, terms, and technical specifications, bill of

quantities, forms, Annexes and drawings in the Bid Document. Failure to

comply with the requirements of Bid Documents shall be at the bidder’s own

risk. Pursuant to clause 26 hereof, bids which are not substantially responsive

to the requirements of the Bid Documents shall be rejected.

9. Clarification Bidding Documents

9.1. A prospective bidder requiring any clarification of the bidding documents may

notify the Employer in writing or through E-mail at the Employer’s address

indicated in the invitation to bid. The Employer will respond to any request for

clarification which he received earlier than 15 days prior to the deadline for

submission of bids. Employer’s response will be published on website including

a description of the enquiry but without identifying its source.

9.2. Pre-bid meeting

9.2.1. The bidder or his official representative is invited to attend a pre-bid meeting

which will take place at the address, venue, time and date as indicated in the

9.2.2. The purpose of the meeting will be to clarify issues and to answer

questions on any matter that may be raised at that stage.

9.2.3. The bidder shall be required to submit any questions in writing or e-mail to

reach the Employer not later than 03 days before the meeting.

9.2.4. Minutes of the meeting, including the question raised (Without identifying the

source of enquiry) and the responses given will be published without delay

on the tender website i.e. www.tender.nprocure.com. Any modification of the

bidding documents listed in sub- Clause 8.1 which may become necessary

as a result of the pre-bid meeting shall be made by the Employer

exclusively through the issue of an Addendum pursuant to Clause 10 and

not through the minutes of the pre-bid meeting.

9.2.5. Non-attendance at the pre-bid meeting will not be a cause for disqualification

10. Amendment of Bidding Documents

10.1. Before the deadline for submission of bids, the Employer may modify the bidding

documents by issuing addenda.

10.2. Any addendum thus issued shall be part of the bidding documents. The Employer

will assume no responsibility for the same.

10.3. To give prospective bidders reasonable time in which to take an addendum into

account in preparing their bids, the Employer may, at his discretion, extend as

necessary the deadline for submission of bids, in accordance with Sub-Clause

SIGNATURE OF CONTRACTOR MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

C. PREPARATION OF BIDS

11. Language of the Bid

11.1. All documents relating to the bid shall be in the English language.

12. Documents Comprising the Bid

12.1. The bid to be submitted by the bidder as Volume V of the bid document (refer

Clause 8.1) shall be in two separate parts:

Part I shall be named “Technical Bid” and shall comprise

(i) Bid Security in the form specified in Section

(ii) Qualification Information and supporting documents as specified in Section

(iii) Certificates, undertakings, affidavits as specified in Section

(iv) Any other information pursuant to Clause 4.5 of these instructions

(v) Undertaking that the bid shall remain valid for the period specified

Part II shall be named “Financial Bid” and shall comprise

(i) Form of Bid as specified in Section

(ii) Priced Bill of Quantities for items specified in Section

12.2. The Bidder shall submit the details / information pertaining to each part

i.e. technical as well as financial and must be submitted online only.

12.3. Following documents will be deemed to be part of the bid.

Particulars Section No. Volume No.

Instructions to Bidders (IFB) 1 I

Conditions of Contract 3 I

Contract Data 4 I

Scope of work & Technical Specifications 5 II

Form of Bid 6 III

Bill of Quantities 7 III

Securities and Other Forms 8 III

Documents to be furnished by bidder 10 V

13.1. The Contract shall be for the whole works as described in Sub-Clause 1.1, based

on the priced Bill of Quantities submitted by the Bidder.

13.2. The bidder should quote percentage above/below/at par with respect to total

amount put to tender in Bill of Quantities.

13.3. All duties, taxes, and other levies except GST payable by the contractor under

the contract, or for any other cause shall be included in the rates, prices and total

Bid Price submitted by the Bidder. (GST will be paid extra)

13.5. The rates and prices quoted by the bidder are subject to adjustment during the

performance of the Contract in accordance with the provisions of Clause 47 of

the Condition of Contract (Irrespective of the time limit and Bid Amount)

14. Currencies of Bid and Payment

14.1. The unit rates and the prices quoted by the bidder shall be entirely in Indian

Rupees. All payments shall be made in Indian Rupees.

15. Bid Validity

15.1. Bids shall remain valid for a period of not less than 180 days after the deadline

date for bid submission specified in Clause

15.2. In exceptional circumstances, prior to expiry of the original time limit, the

Employer may request that the bidders may extend the period of validity for a

specified period. A bidder may refuse the request without forfeiting his bid

security. A bidder agreeing to the request will not be required or permitted to

modify his bid, but will be required to extend the validity of his security for a period

of the extension, and in compliance with Clause 16 in all respects.

16. Bid Security

16.1. The Bidder shall furnish, as part of his Bid, a Bid security in the amount as shown

in column 4 of the table of IFB for this particular work. This Bid security shall be

in favor of Employer as named in Appendix and may be in one of the following

a. Bank Guarantee from any scheduled Indian bank, in the format given

in Volume III. (Bank Guarantee is applicable only for Bid Estimated

Amount of 01 Crore and above) and Bank Guarantee of Schedule and

Private Banks shall be considered as per latest GoG Finance

Department’s Circular or amendment.

b. Fixed Deposit Receipt issued by any Scheduled Indian Bank or a foreign

Bank approved by the Reserve Bank of India.

# A Valid Bid Security / EMD Exemption Certificate issued by (1) Road &

Building Department or (2) Narmada Water Resources, Water Supply and Kalpsar

Department of Govt. of Gujarat. Exemption Certificate is applicable only when

Registration Certificate of Appropriate Class and Category of Approved

Contractors is required as eligible criteria of bidder.

16.2. Bank guarantees (and other instruments having fixed validity) issued as surety

for the bid shall be valid for 45 days beyond the validity of the bid i.e. total validity

of 180+45 = 225 Days

16.3. Any bid not accompanied by an acceptable Bid Security and not secured as

indicated in Sub-Clauses 16.1 and 16.2 above shall be rejected by the Employer

as non-responsive.

16.4. The Bid Security of unsuccessful bidders will be returned within 28 days of the

end of the bid validity period specified in Sub-Clause

16.5. The Bid Security of the successful bidder will be discharged when the bidder has

signed the Agreement and furnished the required Performance Security.

16.6. The bid Security may be forfeited

(a) If the Bidder withdraws the bid after Bid opening during the period of

(b) If the Bidder does not accept the correction of the Bid Price, if any or

(c) In the case of a successful Bidders, if the Bidder fails the specified time

i) Sign the Agreement; or

ii) Furnish the required Performance Security.

(d) #If found necessary, the bidder will be intimated for negotiation, He will

be intimated maximum three times within the validity period for

negotiation, if contractor does not respond in time, his Bid Security

(EMD) will be forfeited and his tender will be rejected. Punitive action

will be taken on such contractors. (As per GoG R&B Dept’s Gr. No.

17. Alternative Proposals by Bidders.

17.1. Bidders shall submit offers that fully comply with the requirements of the bidding

documents, including the conditions of contract (including mobilization advance

or time for completion), basic technical design as indicated in the drawing and

specifications. Conditional offers or alternative offers will not be considered

further in the process of tender evaluation.

18. Format and Signing of Bid

18.1. The Bidder shall prepare documents comprising the bid as described in Clause

12 of these Instructions to bidder as the “Technical Bid “and “Financial Bid” in

separate parts to be uploaded.

SIGNATURE OF CONTRACTOR MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

D. SUBMISSION OF BIDS

20. Deadline for Submission of the Bids

20.1. Complete Bids must be received online by the Employer at the tender website

specified above not later than the date indicated in appendix.

20.2. The Employer may extend the deadline for submission of bids by issuing an

amendment in accordance with Clause 10, in which case all right and obligation

of the Employer and the bidders previously subject to the original deadline will

then be subject to the new deadline.

22. Modification and Withdrawal of Bids

22.1. Bidders may modify or withdraw their bids online before the deadline prescribed

in Clause 20 or pursuant to Clause

22.3. No bid shall be modified or withdrawn after the deadline for submission of Bid.

22.4. Withdrawal or modification of a bid between the deadline for submission of bids

and the expiration of the original period of bid validity specified in Clause

above or as extended pursuant to Clause 15.2 may result in the forfeiture of the

Bid security pursuant to Clause

SIGNATURE OF CONTRACTOR MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

E. BID OPENING AND EVALUATION

23. Bid Opening

23.1. The Employer will open all the Bids received including modifications made

pursuant to Clause 22, in the presence of the Bidders or their representatives

who choose to attend at time, date and the place specified in Appendix in the

manner specified in Clauses 20 and 23.3, In the event of the specified date of

Bid opening being declared a holiday for the Employer, the Bids will be opened

at the appointed time and location on the next working day.

23.3. The “Technical Bid” shall be opened. The amount, form and validity of the bid

security furnished with each bid will be announced. If the bid security furnished

does not conform to the amount and validity period as specified in the invitation

for bid (ref. Column 4 and paragraph 3) and has not been furnished in the form

specified in Clause 16, the technical bid will not be opened.

(i) Subject to confirmation of the bid security by the issuing Bank, the bids

accompanied with valid bid security will be taken up for evaluation with

respect to the Qualification information and other information furnished in part

I of the bid pursuant to Clause 12.1.

(ii) If required, the bidder will be asked in writing to clarify his Qualification

Documents with respect to any required clarification

(iii) The bidders will respond in not more than 7 days of issue of the clarification

(iv) Immediately (usually within 3 or 4 days), on receipt of this clarification the

Evaluation Committee will finalize the list of responsive bidders whose

financial bids are eligible for consideration.

23.6. At the time of opening of “Financial Bid”, the names of the bidders were found

responsive in accordance with Clause 23.4(iv) will be announced. The bids of

only these bidders will be opened. The responsive Bidders’ names, the Bid

prices, the total amount of each bid, any discount and such other details as the

prices, the total amount of each bid, any discount and such other details as the

Employer may consider appropriate, will be announced by the Employer at the

23.7. The time of opening of “Financial Bid”, the names of the bidders were found

responsive in accordance with Clause 23.4(iv) will be announced. The bids of

only these bidders will be opened. The responsive Bidders’ names, the Bid

prices, the total amount of each bid, any discount, and such other details as the

prices, the total amount of each bid, any discount, and such other details as the

Employer may consider appropriate, will be announced by the Employer at the

23.8. In case bids are invited for more than one package, the order for opening of the

“Financial Bid” shall be in order of estimated amount of Bids from highest to

23.9. The Employer shall prepare minutes of the Bid opening, including the

information disclosed to those present in accordance with Sub-Clause 23.6.

24.1. Information relating to the examination, clarification, evaluation, and

comparison of Bids and recommendations for the award of a contract shall not

be disclosed to Bidders or any other persons not officially concerned with such

process until the award to the successful Bidder has been announced. Any

effort by Bidder to influence the Employer’s processing of Bids or award

decisions may result in the rejection of his Bid.

25. Clarification of Financial Bids

25.1. To assist in the examination, evaluation, and comparison of Bids, the Employer

may, at his discretion, ask any Bidder for clarification of his Bid, including

breakdowns of unit rates. The request for clarification and the response shall

be in writing or by e- mail, but no change in the price or substances of the Bid

shall be sought, offered, or permitted except as required to confirm the

correction of arithmetic errors discovered by the Employer in the evaluation of

25.2. Subject to sub-clause 25.1, no Bidder shall contact the Employer on any matter

relating to his Bid opening to the contract is awarded. If the Bidder wishes to

bring additional information to the notice of the Employer, it should do so in

25.3. Any effort by the Bidder to influence the Employer in the Employer's bid

evaluation, bid comparison or contract award decision may result in the

rejection of the Bidders’ bid.

26. Examinations of Bids and Determination of Responsiveness

26.1. During the detail evaluation of "Technical Bid", the Employer will determine

whether each Bid (a) meets the eligibility criteria defined in Clause 3 and 4; (b)

has been properly signed; (c) is accompanied by the required securities and;

(d) is substantially responsive to the requirements of the Bidding document.

During the detailed evaluation of the “Financial Bid”, the responsiveness of the

bids will be further determined with respect to the remaining bid conditions, i.e.,

priced bill of quantities, technical specifications, and drawings.

26.2. A substantially responsive “Financial Bid” is one which confirms all the terms,

conditions and specifications of bidding documents, without material deviation

or reservation. A material deviation or reservation is one (a) which affects in any

substantial way the scope, quality, or performance of the Works; (b) which limits

in any substantial way, inconsistent with the Bidding documents, the Employer’s

rights or the Bidder’s obligations under the Contract; or (c) whose rectification

would affect unfairly the competitive position of other Bidders presenting

substantially responsive Bids.

26.3. If a “Financial Bid” is not substantially responsive, it will be rejected by the

Employer and may not subsequently be made responsive by correction or

withdrawal of the non-conforming deviation or reservation.

29. Evaluation and Comparison of Financial Bids

29.1. The Employer will evaluate and compare only the Bids determined to be

substantially responsive in accordance with Sub-Clause 26.2.

29.3. The Employer reserves the right to accept or reject any variation or deviation.

Variation and deviations and other factors, which are in excess of the

requirements of the Bidding documents or otherwise result in unsolicited

benefits for the Employer, shall not be taken into account in Bid evaluation.

29.4. The estimated effect of the price adjustment conditions under Clause 47 of the

Conditions of Contact, during the period of implementation of the Contract, will

not be taken into account in Bid evaluation.

29.5. If the Bid of the successful Bidder is seriously unbalanced in relation to the

Engineer’s estimate of the cost of work to be performed under the contract the

Employer may require the Bidder to produce detailed consistency of those

prices with the construction methods and schedule proposed. After evaluation

of the price analyses, the Employer may require that the amount of the

performance security set forth in Clause 34 be increased at the expense of the

successful /bidder to a level sufficient to protect the Employer against financial

loss in the event of default of the successful Bidder under the Contract.

29.6. A bid which contains several items in the bill of Quantities which are

unrealistically priced low and which cannot be substantiated satisfactorily by the

bidder may be rejected as non-responsive.

SIGNATURE OF CONTRACTOR MUNICIPAL COMMISSIONER

SURAT MUNICIPAL CORPORATION

F. AWARD OF CONTRACT

31. Award Criteria

31.1. Subject to Clause 32, the Employer will award the contract to the Bidder whose

Bid has been determined.

(i) to be substantially responsive to the Bidding documents and who

has offered the Lowest evaluated Bid Price, provided that such bidder has

been determined to be eligible and qualified in accordance with the

provisions mentioned under this Section

(ii) To be within the available bid capacity adjusted to account for his bid price

which is the lowest evaluation in any of the packages opened earlier than

the one consideration.

In no case, the contract shall be awarded to any bidder whose available

bid capacity is less than the evaluated bid price, even if the said bid is

the lowest evaluated bid.

32. Employer’s Right to Accept any Bid and to Reject any or all Bids

32.1. Not with standing Clause 31, the Employer reserves the right to accept or reject

any Bid, and to cancel the Bidding process and reject all Bids, at any time prior

to the award of contract, without thereby incurring any liability to the affected

bidder or Bidder or any obligation to inform the affected Bidder or Bidders of the

grounds for the Employer’s action.

33. Notification of Award and Signing of Agreement

33.1. The Bidder whose Bid has been accepted will be notified of the award by the

Employer prior to expiration of the Bid validity period by cable, telex or facsimile

confirmed by registered letter. This letter (hereinafter and in the condition of

contract called the “Letter of Acceptance”) will state the sum that the Employer

will pay the Contractor in consideration of the execution, completion, and

maintenance of the Works by the Contractor as prescribed by the Contract

(hereinafter and in the Contract called the “Contract Price”).

33.2. The notification of award will constitute the formation of the contract, subject

only to the furnishing of performance security in accordance with the provisions

33.3. The Agreement will incorporate all agreements between the Employer and the

successful Bidder. It will be signed by the Employer and to the successful

Bidder, within 28 days following the notification of award along with the Letter

of Acceptance. Within 21 days of receipt, the successful Bidder will sign the

Agreement and deliver it to the Employer.

33.4. Upon the furnishing by the successful Bidder of the Performance Security, the

Employer will promptly notify the other Bidders that their Bids have been

34. Performance Security

34.1. (A) Within 10 (Ten) days of receipt of Letter of Acceptance, the successful

Bidder shall furnish to the Employer an irrevocable and unconditional guarantee

from a Bank in the form set forth in Section 8 (the “Performance Security”) for

an amount equal to 5% (five percent) of its Contract Price. In case of bids

mentioned below, the successful Bidder, along with the Performance Security,

shall also furnish to the Authority an irrevocable and unconditional guarantee

from a Bank in the same form given at Section 8 towards an Additional

Performance Security (The “Additional Performance Security”) for an amount

calculated as under:

(a) If the Contract Price offered by the Selected Bidder is lower than 10% but

up to 20% of the Estimated Project Cost, then the Additional Performance

Security shall be calculated @ 20% of the difference in the (i) Estimated

Project Cost (as mentioned in Bid Document) - Minus 10% of the

Estimated Project Cost and (ii) Contract Price offered by the selected

(b) If the Contract Price offered by the Selected Bidder is lower than 20% of

the Estimated Project Cost, then the Additional Performance Security

shall be calculated 30% of the difference in the (i) Estimated Project Cost

(as mentioned in Bid Document) - Minus 10% of the Estimated Project

Cost and (ii) Contract Price offered by the selected Bidder.

(c) This Additional Performance Security shall be treated as part of the

Performance Security.

(d) The Performance Security shall be valid beyond 60(sixty) days of the

Defects Liability Period, and the Additional Performance Security shall be

valid beyond 28 (twenty-eight) days of Project Completion Date.

34.2. If the performance security is provided by the successful Bidder in the form of

a Bank Guarantee, it shall be issued either (a) at the Bidder’s option, by a

Nationalized/Scheduled Indian bank or (b) by a foreign bank located in India

and acceptable to the Employer, listed under GoG Finance Department’s latest

Circular or amendment.

34.3. Failure of the successful Bidder to comply with the requirement of Sub-Clause

34.1 shall constitute sufficient grounds for cancellation of the award and

forfeiture of the Bid Security.

35. Advance Payment and Security

35.1. The Employer will provide an Advance payment on the Contract Price as

stipulated in the Conditions of Contract, subject to maximum amount, as stated

in the Contract Data.

37. Corrupt or Fraudulent Practices

37.1. The Employer will reject a proposal if it determines that the Bidder

recommended for award has engaged in corrupt or fraudulent practices in

completing for the contract in question and will declare the firm ineligible, either

indefinitely or for a stated period of time, to be awarded a contract with National

Highways Authority of India/ State PWD and any other agencies, if it at any time

determines that the firm has engaged in corrupt or fraudulent practices in

completing for the contractor, or in execution.

37.2. Furthermore, Bidders shall be aware of the provision stated in Sub- Clause

of the Conditions of Contract.

APPENDIX TO ITB

Clause Reference with respect to Section –I

1. The Name of the Employer is MUNICIPAL COMMISSIONER, [Cl.1] IFB

SURAT MUNICIPAL CORPORATION.

2. The last Seven Years.

3. This Annual Financial Turnover Amount is ₹ ………………….. [Cl.4.5.3.2]

4. Value of Work is ₹ ………………….. [Cl.1] IFB

6. The cost of electric work is ₹ …………………..

7. The cost of water supply / sanitary works is ₹ ………………..

8. Liquid assets and / or availability of credit facilities is [Cl.4.5.6]

9. Price level of the Financial Year 2026-27 [Cl.4.5.3.4]

10. The pre-bid meeting will take place as indicated in the [Cl.9.2.1]

11. The technical Bid will be opened at the office of the Surat [Sr.no.26] NIT

Municipal Corporation as indicated in the appendix.

12. Address of the Employer : MUNICIPAL [Sr.no.32] NIT

COMMISSIONER, (Surat Municipal Corporation)

14. The bid should be submitted at the latest by as stated on [Cl. 20.1 & 20.2]

15. The bid will be opened at MUNICIPAL COMMISSIONER, [Cl. 23.1]

(Surat Municipal Corporation), as stated on online NIT as

indicated in the appendix.

16. The Bank Draft in favor of “MUNICIPAL COMMISSIONER, [Cl.3] IFB

(Surat Municipal Corporation)”.

18. Escalation factors (for the cost of work executed and financial

Year Financial Year Multiplying

Base year of 2026-2027

inviting tender

#LIST OF KEY PLANT & EQUIPMENT TO BE DEPLOYED ON

[Reference CL.4.5.6]

The contractors shall also give a list of machinery in their possession and which they

propose to use on the work.

Sr. Plant or Approximate

Location (maximum Make Capacity Remark

No. Machinery Value

List of Key Personnel to be deployed on Contract Work

(Reference Cl. 4.5.5)

#Employment of a qualified site Engineer by the Contractor.

The Contractor shall employ full-time technically qualified staff during the

execution of this work satisfying the minimum requirement under clause

4.5.5 and as specified hereunder.

1. Two graduate Civil Engineers and three diploma Civil Engineers when

cost of the work to be executed is more than Rs.50 lakhs.

2. One graduate & two Diploma, Civil Engineers when the cost of the

work to be executed is more than Rs.15 lakhs but less than Rs.50 lakhs.

3. Minimum two Diploma Civil Engineer when the cost of work is less than

Rs.15 lakhs but more than Rs.5 lakhs.

4. Minimum One Diploma Civil Engineer for the work when the cost of

work to be executed is less than Rs. 5 lakhs. The Engineer employed

for the Government work must have sufficient experience to handle

the work independently. Such an Engineer shall have to stay at the site

of work, and he shall not be entrusted with other duty except this work.

In case the contractor or partner of the contractor firm is a Civil Graduate

Engineer’ s Employment of a separate Engineer will not be

necessary provided that the Engineer partner himself attends the

execution of the work on the site.

Within 15 days of issue of work-order the Contractor will have to

furnish to the Deputy MUNICIPAL COMMISSIONER/ CHIEF OFFICER-

in-charge of the work the Name, Qualifications, copy of mark sheet,

Colour Photograph and the appointment order issued such engineers

engaged for this contract work. If 15 days after issue of work order such

designated Site Engineers do not resume or do not remain present on

site of work, the recovery at the rate of Rs.15,000-00 per month per

Engineer will be made from the bills/deposit/dues of the contractor. Such

recovery shall be non- refundable.

QUALIFICATION INFORMATION

QUALIFICATION INFORMATION

The information to be filled in by the Bidder in the following pages will be used for the

purpose of post qualification as provided in Clause 4 of the Instruction to Bidders. This

information will not be incorporated in the Contract.

1. For Individual Bidders

1.1 Constitution or legal status of

Bidder (Attach Copy)

Place of registration

Principal place of business

Power of attorney of signatory of Bid

1.2 Total value and capacity of Civil engineering construction Work performed in the

last Seven Years (in Rs. Lakhs)

1.2.1 Work performed as prime contractor in the past, involved in execution of all main

items of work described in the bid documents, provided further that all other

qualification criteria are satisfied (in the same name) on works of a similar nature

over the last Seven Years** and in current year before the submission of the bid.

Project Name of Description Contrac Value Date Stipulated Actual date Remark

Name the of work t No. of of period of of explaining

Employer contrac issue completio completion* reasons

t (Rs. of n for delay

Crore) Work & work

order Completed

*Attach certificate(s) from the Engineer(s)in-charge

**Immediately preceding the financial year in which bids are received.

1.3 Quantities of work executed as prime contractor, involved in execution of all

main items of work described in the bid document, provided, further that all

other qualification criteria are called (in the same name and style) in the last

Seven Years** and in current year before the submission of the bid.

*To be modified as per the nature and scope of work

Year Name of Name of Quantity of work performed (Cum/MT)

the the STP Pumping CETP/STP Storage

work Employer Constructio machinery works structures,

n & Pumping Commissio equalization

experience station n works tanks and

ITEM 1 ITEM 2 ITEM 3 ITEM

1.4 Information on Bid Capacity (works for which bids have been submitted and works

which are yet to be completed) as on the date of this bid.

(A) Existing commitments and on-going work:

Description Place Contract Name Value Stipulated Value of Anticipated

of works & No. &Address Contrac Period of Works* of

State of t (Rs. Completio remaining completion

Employer Cr) n to be

*Attach certificate(s) from the Engineer(s)in-charge

**Immediately preceding the financial year in which bids are received.

1.5 Availability of key items of Contractors Equipment for carrying out the works (Ref.

Clause 4.5.6). The Bidder should list all the information requested below.

Item of Requirement Availability Proposals Remarks

Equipment NO Capacity Owned/ Leased to be Nos./ Age/ (From whom to

procured Capacity Conditions be purchased

1.6 Qualifications and experience of key personnel required for administration and

execution of the contract. Attach biographical data. Refer also to Sub Clause 9.1 of

the Conditions of Contract.

Position Name Qualification Year of Year of experience

Experience in the proposed

(General) position

Project Manager

1.7 Proposed sub-contract and firms involved – Not Applicable

Sections of the Value of Sub- Sub-Contractor Experience in

works Contractor (Name & similar work

1.8 Attach copies of certificates on possession of valid license for executing water

supply/ sanitary work/ electrical works. Financial reports for the last Seven Years:

balance sheets, profit and loss statements, auditors’ reports (in case of

companies/corporations), etc. List them below and attach copies.

1.9 Evidence of access to financial resources to meet the qualification requirements:

cash in hand, lines of credit, etc. List them below and attach copied documents.

1.10 Name, address, telephone, telex, and fax numbers of the Bidders bankers who may

provide references if contacted by the Employer.

1.11 Information on Litigation history in which the Bidder is involved.

Other Party Employer Cause of Amount Remarks

(ies) Dispute Involved showing

1.12. Statement of compliance under the requirements of Sub Clause 3.2 of the

instruction to Bidders. (Name of Consultant engaged for project preparations is *

1.13 Proposed work method and schedule. The Bidder should attach descriptions,

drawings and charts as necessary to comply with the requirements of the Bidding

documents. (Refer ITB Clause 4.1)

1.14 Programme Schedule

1.15 Quality Assurance Plan

3. Additional Requirements

3.1 Bidders should provide any additional information required to fulfill the

requirements of Clause 4 of the Instructions to the Bidders, if applicable.

(i) Affidavit &

(ii) Undertaking

SAMPLE FORMAT FOR EVIDENCE OF ACCESSTOOR

AVAILABILITY OF CREDIT FACILITIES

(CLAUSE 4.5.7 OF ITB)

BANK CERTIFICATE

This is to certify that M/s. is a reputed company

with good financial standing.

If the contract for the work, namely, is awarded to the

above firm, we shall be able to provide overdraft/credit facilities to the extent of Rs.

working capital requirements for executing the above during the contract period.

Senior Bank Manager

Address of the Bank

1. I, the undersigned, do hereby certify that all the statements made in the required

attachments are true and correct.

2. The undersigned also here by certifies that neither our firm M/s.

have not abandoned any work of Government of Gujarat/Government of India/any

Board or Corporation under Government of Gujarat/Government of India nor any

contract awarded to us for such works have been rescinded, during last Seven Years

prior to the date of this bid.

3. The undersigned hereby authorize(s) and request (s) any bank, person, firm, or

corporation to furnish pertinent information deemed necessary and requested by the

Department to verify this statement or regarding any (our) competence and general

4. The Undersigned understands and agrees that further qualifying information may be

requested and agrees to furnish any such information at the request of the

Department/ Project implementing agency.

(Signed by an Authorized Officer of the Firm)

Title of Officer

I, the undersigned do here by undertake...........................................that our firm

upto 25% of the value of the work during implementation of the contract.

(Signed by an Authorized officer of the firm)

Title of officer

CONDITIONS OF CONTRACT

Conditions of Contract

Table of Contents

A General Page D. Cost Control Page

1 Definitions 37 Bill of Quantities

2 Interpretation 38 Changes in the Quantities

3 Language and Law 39 Variations

4 Engineer’s Decisions 40 Payments for Variations

5 Delegations 41 Cash Flow Forecasts

6 Communications 42 Payment Certificates

7 Sub-Contractors 43 Payments

8 Other Contractors 44 Compensations Events

9 Personnel 45 Tax

10 Employer’s & Contractor Risk 46 Currencies

11 Employers Risks 47 Price Adjustment

12 Contractor’s Risk 48 Retention

13 Insurance 49 Liquidated damages

14 Site Investigations Reports 50 Bonus

15 Queries about the Contract 51 Advance Payment

16 Contractors to Construct the 52 Securities

17 The Works to be Completed By 53 Deleted

the Intended Completion

18 Date Approval by the 54 Cost of Repair

20 Discoveries E. Finishing the Contract

21 Possession of the Site 55 Completion

22 Access to the Site 56 Taking Over

23 Instructions 57 Final Account

24 Disputes 58 Operating and Maintenance

manuals Terminations

25 Procedure for Disputes

26 Deleted 60 Payment upon Terminations

B. 62 Release from Performance

27 F. Special Conditions of

Programme Contract

28 Extensions of the Intended 63 Labour

completion date

29 Deleted 64 Compliance with labour

Delays Ordered by The

Engineer 65 Arbitration

31 Management Meetings

32 Early Warning

C. Quality Control

33 Identifying Defects

35 Correction of Defects

36 Uncorrected Defects

CONDITIONS OF CONTRACT

1.1 Terms which are defined in the Contract Data are not also defined in the

Conditions of Contract but keep their defined meaning.

Bill of Quantities means the priced and completed Bill of Quantities forming

part of the Bid

Compensation Events are those defined in Clause 44 hereunder

The Completion Date is the date of completion of the Works as certified by the

Engineer in accordance with Sub Clause

The Contract is the contract between the Employer and Contractor to execute,

complete and maintain the Works till the completion of Defects Liability

Period. It consists of the documents listed in Clause 2.3 below.

The Contract data defines the documents and other information which comprise

The Contractor is a person or corporate body whose Bid to carry out the Work

has been accepted by the Employer.

The Contractor’s Bid is the complete Bidding document submitted by the

Contractor to the Employer and includes Technical and Financial Bids.

The Contract Price is the price stated in the Letter of Acceptance and

thereafter as adjusted in accordance with the provisions of the Contract.

Days are calendar days: months are calendar months.

The Defects Liability Period is the period named in the Contract Data and

calculated from the Completion Date.

The Employer is the party who will employ the Contractor to carry out the

The Engineer is the person named in the Contract Data (or any other competent

person appointed and notified to the contractor to act in replacement of the

Engineer) who is responsible for supervising the Contractor, administering the

Contract, certifying payments due to the Contractor, issuing and valuing

Variations to the Contract, awarding extensions of time, and valuing the

Compensations Events.

Equipment is Contractor’s machinery and vehicles brought temporarily to the

site to construct the Works.

The Initial Contract Price is the Contract Price listed in the Employer’s

Letter of Acceptance.

The Intended Completion Date is the date on which it is intended that the

Contractor shall complete the Works. The Intended Completion Date is specified

in the Contract Data. The Intended Completion Date may be revised only by the

Engineer by issuing an extension of time.

Materials are all supplies, including consumables, used by the contractor for

incorporation in the works.

Plant is any integral part of the work which is to have mechanical, electrical,

electronic or chemical or biological functions.

The Site is the area defined as such in the Contract Data.

Site Investigation Reports are those which were included in the Bidding

documents and are factual interpretive reports about the surface and subsurface

conditions at the site.

Specifications means the Specifications of the works included in the Contract and

any modification or addition made or approved by the Engineer.

The Start Date is given in the Contract Data. It is the date when the Contractor

shall commence execution of the works. It does not necessarily coincide with any

of the Site Possession Dates.

A Subcontractor is a person or corporate body who has a Contract with the

Contractor to carry out a part of the work in the Contract which includes work on

Temporary Works are works designed, constructed, installed, and removed by

the Contractor which are needed for construction or installation of the Works.

A Variation is an instruction given by the Engineer, which varies the Works. The

Works are what the Contract requires the Contractor to construct, install, and

turn over to the Employer, as defined in the Contract Data.

2. Interpretation

2.1 In interpreting these Conditions of Contract, singular also means plural, male

also means female or neuter and the other way around. Heading have no

significance. Words have their normal meaning under the language of the

Contract unless specifically defined. The Engineer will provide instructions

clarifying queries about Conditions of Contract.

2.2 If sectional completion is specified in the Contract Data, references in the

Conditions of Contract to the Works, the Completion date, and Intended

Completion Date apply to any Section of the Works (other than references to

the Completion Date and Intended Completion date for the whole works)

2.3 The documents forming the Contract shall be interpreted in the following

order of priority

(2) Letter of Acceptance, notice to proceed with works

(3) Contractor’s Bid

(4) Contract Data

(5) Conditions of Contract including Conditions of Contract

(6) Specifications

(8) Bills of quantities and

(9) Any other document listed in the Contract Data as forming part of

3. Language and Law

3.1 The language of the Contract and the law governing the Contract are stated

in the Contract Data.

4. Engineers Decisions

4.1 Except where otherwise specifically stated, the Engineer will decide

contractual matters between the Employer and the Contractor in the role

representing the Employer.

5.1 The Engineer may delegate any of his duties and responsibilities to other

people after notifying the Contractor and may cancel any delegation after

notifying the Contractor.

6. Communications

6.1 Communications between parties which are referred to in the conditions

are effective only when in writing. A notice shall be effective only when it

is delivered (in terms of Indian Contract Act).

7. Sub-Contracting

8. Other Contractors

8.1 The Contractor shall cooperate and share the Site with other contractors,

public authorities, utilities and the Employer between the dates given in

the Schedule of other Contractor. The Contractors shall as refer to in the

Contract Data, also provide facilities and services for them as described in

the Schedule. The employer may modify the schedule of other contractors

and shall notify the contractor of any such modifications.

9.1 The Contractor shall employ the key personnel named in the Schedule of

Key Personnel as referred to in the Contract Data to carry out the functions

stated in the Schedule or other personnel approved by the Engineer. The

Engineer will approve any proposed replacement of key personnel only if

their qualifications, abilities, and relevant experience are substantially

equal to or better than those of the personnel listed in the Schedule.

9.2 If the engineer asks the Contractor to remove a person who is a member

of the Contractor Staff or his work force stating the reasons the Contractor

shall ensure that the person leaves the Site within seven days and has no

further connection with the work in the Contract.

10. Employer’s and Contractors Risks

10.1 The Employer carries the risk which these Contract states are Employer’s

risks, and the Contractor carries the risks which these Contracts states are

Contractor’s risk.

11. Employer’s Risks

11.1 The employer is responsible for the excepted risks which are (a) in so far

as they directly affect the execution of the Works, the risks of war,

hostilities, invasion, act of foreign enemies, rebellion, revolution,

insurrection or military or usurped power, civil war, riot commotion or

disorder (unless restricted to the Contractor’s employees), and

contamination from any nuclear fuel or nuclear waste or radioactive toxic

12. Contractor’s Risks

12.1 All risks of loss of or damages to physical property and of personal injury

and death which arise during and in consequence of the performance of

the Contract other than the excepted risks are the responsibility of the

13.1 The Contractor shall provide, in the joint names of the Employer and the

Contractor, insurance cover from the Start date to the end of the Defects

Liability Period, in the amounts and deductibles stated in the Contract data

for the following events which are due to the Contractor’s risks:

(a) Loss of or damage to the works, Plant and materials,

(b) Loss of or damage to Equipment

(c) Loss of or damages of property (expect the Works, Plant, Materials

and Equipment) in connection with the Contract; and

(d) Personal injury or death.

13.2 Policies and certificates for insurance shall be delivered by the Contractor

to the Engineer for the Engineer’s approval before the Start Date. All such

insurance shall provide for compensation to be payable in the types and

proportions of currencies required to rectify the loss or damage incurred.

13.3 If the Contractor does not provide any of the policies and certificates

required, the Employer may affect the insurance which the Contractor

should have provided and recover the premiums the Employer has paid

from payments otherwise due to the Contractor or, if no payment is due,

the payment of the premiums shall be a debt due.

13.4 Alterations to the terms of insurance shall not be made without the

approval of the Engineer.

13.5 Both parties shall comply with any conditions of the insurance policies.

14. Site Investigation Report

14.1 The Contractor in preparing the Bid shall rely on any site Investigation

reports referred to in the Contract Data, supplemented by any information

available to the Bidder.

15. Queries about the Contract data

15.1 The engineer will clarify queries on the Contract Data

16. Contractor to Construct the Works

16.1 The Contractor shall construct and install the works in accordance with the

specification and Drawings.

17. The Works to be completed by the Intended Completion Date

17.1 The Contractor may commence execution of the Works on the Start Date

and shall carry out the Works in accordance with the programme submitted

by the Contractor, as updated with the approval of the Engineer, and

complete them by the Intended Completion date

18. Approval by the Engineer

18.1 The Contractor shall submit Specifications and Drawings showing the

proposed Temporary works to the Engineer, who is to approve them if they

comply with the Specifications and drawings.

18.2 The Contractor shall be responsible for design of temporary works.

18.3 The Engineer’s approval shall not alter the contractor responsibility for

design of the Temporary works.

18.4 The Contractor shall obtain approval of third parties to the design of the

Temporary works where required.

18.5 All Drawings prepared by the Contractors for the execution of the

temporary or permanent work are subject to prior approval by the Engineer

before their use.

19.1 The Contractor shall be responsible for the safety of all activities on the Site.

20. Discoveries

20.1 Anything of historical or other interest or of significant value unexpectedly

discovered on the site is the property of the Employer. The contractor is

to notify the engineer of such discoveries and carry out the Engineer’s

instructions for dealing with them.

21. Possession of the Site

21.1 The Employer shall provide the Contractor with possession of the Site,

whether in part or in full. If possession of a part is not given by the date

stated in the Contract Data, the Employer is deemed to have delayed the

start of the relevant activities, and this will be a Compensation Event.

22. Access to the Site

22.1 The Contractor shall allow the Engineer and any person authorized by the

Engineer access to the Site, to any place where work in connection with

the Contract is being carried out or is intended to be carried out and to

any place where materials or plants are being manufactured/ fabricated/

assembled for the works.

23. Instructions

23.1 The Contractor shall carry out all instructions of the Engineer pertaining

to works which comply with the applicable laws where the site is located.

23.2 The Contractor shall permit the Employer to inspect the Contractor’s

accounts and records relating to the performance of the Contractor and to

have them audited by auditors appointed by the Employer, if so required

by the Employer.

24.1 If the Contractor is of the view that a decision taken by the Engineer was

either outside the authority given to the Engineer by the Contract or that

the decision was wrongly taken, the decision shall be referred to #Divisional

Head. , (SMC) (Higher Authority) within 14 days of the notification of the

Engineer's decision. If the issue is not resolved, any party can refer to the

matter for conciliation within 15 days from the decision given by the

#Divisional Head.

(a) For the work up to Rs.100 Cr., if any of the parties is not satisfied

with the decision of the #Divisional Head, (SMC), both the parties

have to refer to the Divisional Head concerned for the conciliation

(b) For the work more than Rs.100 Cr., if any of the parties is not satisfied

with the decision of the #Divisional Head, both the parties have to

refer to the Municipal Commissioner, (SMC), Government of

Gujarat for the conciliation process.

If the dispute is not resolved through the conciliation process, he may refer

the dispute to Gujarat Public Works Contract Dispute Arbitration Tribunal. If

the Contractor fails to refer a claim / dispute to the Higher Authority within

14 days of the notification of the Engineer's decision, the Contractor shall not

be entitled to any additional payment/claim if he doesn’t follow the above

sequence in stipulated time. However, during such period, he would not stop

the work in any case.

25. Procedure for Disputers

25.1 The arbitration shall be conducted in accordance with the arbitration

procedure stated in the Special Conditions of Contract.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

B. TIME CONTROL

27.1 Within the time stated in the Contract Data the Contractor shall submit to

the Engineer for approval a Programme showing the general methods,

arrangements orders, and timing for all the activities in the works along

with monthly cash flow forecast.

27.2 An update of the Programme shall be a programme showing the actual

progress achieved on each activity and the effect of the progress achieved

on the timing of the remaining work including any changes to the sequence

of the activities.

27.3 The Contractor shall submit to the Engineer, for approval an updated

programme at intervals no longer than the period stated in the Contract

data. If the Contractor does not submit an updated programme within this

period, the Engineer may withhold the amount stated in the Contract data

from the next payment after the date on which the overdue programme

has been submitted.

27.4 The Engineer’s approval of the programme shall not alter the Contractor’s

obligations. The Contractor may revise the programme and submit it to the

Engineer again at any time. A revised programme is to show the effect of

Variations and Compensations events.

28. Extension of the Intended Completion Date

28.1 The Engineer shall extend the Intended Completion Date if a compensation

Event occurs or a Variation is issued which makes it impossible for

completion to be achieved by the Intended Completion Date without the

Contractor taking steps to accelerate the remaining work and which would

cause the Contractor to incur additional cost.

28.2 The Engineer shall decide whether and by how much to extend the

Intended Completion Date within 35 days of the Contractor asking the

Engineer for a decision upon the effect of a compensation event or

Variation and submitting full supporting information. If the Contractor has

failed to give early warning of a delay or has failed to cooperate in dealing

with a delay, the delay by this failure shall not be considered in assessing

the new Intended Completion Date.

28.3 The Engineer shall within 14 days of receiving full justification from the

contractor for extension of Intended Completion Date refer to the

Employer his decision. The employer shall in not more than 21 days

communicate to the engineer the acceptance or otherwise of the

Engineer’s decision. If the employer fails to give his acceptance, the

Engineer shall not grant the extension, and the contractor may refer the

matter under Clause

30. Delays Ordered by the Engineer

30.1 The Engineer may instruct the Contractor to delay the start or progress of

any activity within the works.

31. Management Meetings

31.1 Either the Engineer or the Contractor may require the other to attend a

management meeting. The business of a management meeting shall be to

review the plans for remaining work and to deal with matters raised in

accordance with the early warning procedure.

31.2 The Engineer shall record the business of management meetings and is to

provide copies of his record to those attending the meeting and to the

Employer. The responsibility of the parties for actions to be taken is to be

decided by the Engineer either at the management meeting or after the

management meeting and stated in writing to all who attended the

32. Early Warning

32.1 The Contractor is to warn the Engineer at the earliest opportunity of

specific likely future events or circumstances that may adversely affect

the quality of the work, increase the Contract price or delay the execution

of works. The Engineer may require the contractor to provide an estimate

of the expected effect of the future event or circumstance on the contract

price and completion date. The estimate is to be provided by the

Contractor as soon as reasonably possible.

32.2 The Contractor shall cooperate with the Engineer in making and

considering proposals for how the effect of such an event or circumstance

can be avoided or reduced by anyone involved in the work and in carrying

out any resulting instruction of the Engineer.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

C. QUALITY CONTROL

# 33. Identifying Defects/ Defect liability period

33.1 : Defect liability period: The contractor shall be responsible for making good

and remedy at his own expense any defect which may develop or may be

noticed before the period mentioned hereunder from the certified date of

completion. The Engineer in charge shall give the contractor a notice in

writing about the defects and the contractor shall make the same good

within 15 days of receipt of the notice. In the case of failure on the part

of the contractor, the Engineer- in-charge may rectify or remove or re-

execute the work at the risk & cost of the contractor. The Engineer-in-

charge shall be entitled to appropriate the whole or any part of the amount

of security deposit towards the expenses, if any, Incurred by him in

rectification, removal or re-execution. The Defects Liability period shall

(a) For all works costing up to Rs. 50,000 (amount put to tender), the period

shall be 3 Months from the certified date of completion.

(b) For all works costing more than RS. 50,000 and up to Rs. 1 crore (amount

put tender), the period shall be 10 (Ten) months from the certified date

of completion or one monsoon, whichever is later.

(c) For major projects costing more than Rs. 1 crore, the period shall be

Months from the certified date of completion which should include three

(d) For original building works the defect liability period will be 4 years or

elapse of 4 monsoon period following date of possession of building taken

over by user agency following the certified date of completion, whichever

is later. For the purpose of deciding the monsoon period, the 30th

September shall be treated as the last date.

Modified vide R & B D Circular No. PAC-11-102008-2076-N dated

31/8/2009, PRCH/102013(2976) 2759-N, Dated 27/05/2013 and Circular

No. TNC/10/2016/Clause 17A (Correction/(1)C Dated 12/05/2016]

33.2 Free maintenance guarantee period for works of Road/Bridge construction

(a) For resurfacing work of road free maintenance guarantee period one

year from the date of completion.

(b) In case of widening of the road/strengthening of the road/bridge, the

contractor shall have to give four years free maintenance guarantee

from the certified date of completion. During this period the contractor

shall visit the site every six months along with the concerned Section

Officer / Deputy MUNICIPAL COMMISSIONER/ CHIEF OFFICER and will

examine the work already carried out in this contract like road work,

jungle cutting, side shoulders, side gutter, road furniture, patta etc.

and will prepare Km. wise inspection report duly signed by all

concerned and any defect observed shall be done within 15 days by the

contractor at his risk and cost as per the direction of Engineer in charge.

The contractor needs to do videography of these visits and require to

submit at the time of release of FMG. If B.T. the surface during the

maintenance period of 4 years is worn out then agency shall have to

provide renewal coating as per tender item as directed by the Engineer-

in- charge. The amount equivalent to 5% of each running bill shall be

withheld and will be released after the free maintenance guarantee

period (i.e. 4 years) is over.

However, this amount shall be released against fixed deposit or bank

guarantee pledged in the name of MUNICIPAL COMMISSIONER/ CHIEF

OFFICER after completion certificate of work is issued.

(1) The flakiness and elongation index (combined) for coarse aggregates

under no circumstances shall exceed the allowable limit set forth in the

relevant clause for the material in question.

(2) 2% of the amount eligible for the payment of bituminous items shall be

withheld till the miscellaneous items like earthwork in embankment /

cutting for side shoulders, side gutters, kilometer / indicator / guard

stones, sign boards etc. are completed in all respect by the contractor.

After completion of the miscellaneous items, the above said 2%

withheld amount shall be released.

(Govt. of Gujarat's G.R. No.: TNC-10-2013-3(Part-3)/C, Dtd. 13/12/2013).

(3) Videography for the surface under Maintenance Guarantee is to be done

as per Govt. letter No.: SSR/10/2015-16/26/C, Dtd. 26/11/15 for the

work costing more than Rs. 5.00 Crore.

(4) Setting up of adequate laboratory & deployment of quality engineers.

The contractor shall have to set up the laboratory with adequate

equipment. Till the setting up of adequate laboratory is completed &

reported of this to the engineer (subject to due verification by

engineer’s representative) by contractor in writing, Rs.2,00,000/- shall

be withheld. The qualified quality Engineer shall be deployed

exclusively for this contract by the contractors. If quality Engineer is

not deployed by contractor within one month after the date of work

order, the amount equivalent to Rs.20,000 per month shall be

recovered till the actual deployment of quality engineer. The amount

so recovered towards the deployment of quality engineers shall not be

(5) Asphalt work will have to be cross checked as per G.R. No.:

RGN/60/2006/35/C, dtd.31/05/07 before final bill is paid.

(6) Maintenance during Construction Period

During the Construction Period, the Contractor shall maintain, at his

own risk and cost, the existing lane(s) of the road so that the traffic

worthiness and safety thereof are at no time materially inferior as

compared to their condition 10 (ten) days prior to the date of the

Agreement, and shall undertake the necessary repair and maintenance

works for this purpose; provided that the Contractor may, at his cost,

interrupt and divert the flow of traffic if such interruption and diversion

is necessary for the efficient progress of works and conforms to Good

Industry Practice; provided further that such interruption and diversion

shall be undertaken by the Contractor only with the prior written

approval of the MUNICIPAL COMMISSIONER/ CHIEF OFFICER which

approval shall not be unreasonably withheld. For the avoidance of

doubt, it is agreed that the Contractor shall at all times be responsible

for ensuring safe operation of the road.

33.3 The Engineer shall check the Contractor’s work and notify the Contractor

of any defects that are found. Such checking shall not affect the

Contractor’s responsibilities the Engineer may instruct the Contractor to

search for a Defect and to uncover and test any work that the Engineer

considers may have a Defect.

34.1 If the engineer instructs the Contractor to carry out a test not specified in

the Specification to check whether any work has a Defect and the test

shows that it does, the Contractor shall pay for the test and any samples.

If there is no defect the test shall be a Compensation Event.

34.2 #1% of the amount of work done should be deducted from R.A. Bill of the

contractor for testing the quality of material workmanship, irrespective of

actual charges.

34.3 Agency has to establish testing laboratory on site for the various test to be

carried out in the work for this purpose agency shall construct a pukka

laboratory building with all facility on site at location specified by the

engineer in charge.

35. Correction of defects

35.1 The engineer shall give notice to the Contractor of any defects before the

end of the defects Liability Period, which begins at Completion and is

defined in the contract data. The Defects Liability Period shall be extended

for as long as Defects remain to be corrected.

35.2 Every time notice of a Defect is given, the Contractor shall correct the

notified defect within the length of time specified by the Engineer’s

36. Uncorrected Defects

36.1 If the Contractor has not corrected a defect within the time specified in

the Engineer’s notice, the Engineer will assess the cost of having the Defect

corrected, and the Contractor will pay this amount.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

D. COST CONTROL

37. Bill of Quantities

37.1 The bill of Quantities shall contain items for the constructions, installation,

testing and commissioning work to be done by the Contractor.

37.2 The bill of Quantities is used to calculate the Contract price. The

Contractor is paid for the quantity of the work done at the rate in the Bill

of Quantities for each item.

38. Change in Quantities

38.1 The Engineer shall have power to make any alterations in or addition to

the original specifications , drawings, designs and instructions that may

appear to him to be necessary or advisable during the progress of the work

and the contractor shall be bound to carry out the work in accordance with

any instruction in this connection which may be given to him in writing

signed by the Engineer and such alteration shall not invalidate the contract

and any additional work which the contractor may be directed to do in the

manner above specified as part of the work shall be carried out by the

contractor on the same conditions in all respects on which he agreed to do

the main work and at the same rate as are specified in the tender for the

Except that when the quantity of any item exceeds the quantity as in the

tender by more than 130%, the contractor will be paid for the quantity in

excess of 130%, at the rate entered in the SOR of the year during which

the excess in quantity is first executed.

39.1 All Variations shall be included in updated programmers produced by

the Contractor.

40. Payments for Variations

40.1 If the additional or altered work includes any class of work for which no

rate is specified in this contract, then such class of work shall be carried

(i) At the rate derived from the item within the contract which is comparable

to the one involving additional or altered class of work; where there are

more than one comparable items, the item of the contract which is nearest

in comparison with regard to class or classes of the work involved shall be

selected and the decision of the Divisional Head as to the nearest

comparable item shall be final and binding on the contractor.

(ii) If the rate cannot be derived in accordance with (i) above, such class of

works shall be carried out at the rate entered in the Schedule of Rates of

the division for the year in which the tender was received, increased or

decreased by the percentage by which the tender amount is more or less

as compared to the amount arrived at the rates in the “Schedule of Rates”

of the Division in the year in which the tender was received. If the Schedule

of rates of the Division does not contain all the items, the percentage

increase or decrease of the tender shall be calculated considering such

items which were included in the “Scheduled Rates” of the division for the

year and for materials consumed on such item the rate to be charged would

be the basic rate taken into account for fixing the rate in S.O.R. referred

(iii) If it is not possible to arrive at the rate from (i) and (ii) above, such class

of work shall be carried out at the rate decided by the competent

authorities on the basis of detailed rate analysis after hearing the

contractor before a Committee of two Divisional Head stationed at the

same place or the nearest place.

40.2 If the additional or altered work, for which no rate is entered in the

“Schedule of Rates” of the Division is ordered to be carried out before the

rate is agreed upon, then the contractor shall within seven days of the date

of receipt by him of the order to carry out the work, inform the Engineer-

in-charge of the rate, which it is his intention to charge for such class of

work and if the Engineer in charge does not agree to this rates, he shall

by notice in writing be at liberty to cancel his order to carry out such class

of work and arrange to carry it out in such manner as he may consider it

advisable, provided always that if the contractor shall commence work or

incur any expenditure in regard thereof before the rates shall have been

determined as lastly herein before mentioned, then in such cases he shall

only be entitled to be paid in respect of the work carried out or

expenditure incurred by him prior to the date of the determination of the

rate as aforesaid according to such rate or rates as shall be fixed by the

Engineer-in-charge. In the event of the dispute, the decision of the

Divisional Head of the Circle shall be final.

Where, however, the work is to be executed according to the

designs, drawings and specifications recommended by the contractor and

accepted by the competent authority, the alternation above referred to

shall be within the scope of such designs, drawings and specifications

appended to the tenders.

The time limit for the completion of the work shall be extended in

the proportion that the increase in the cost occasioned by alterations bears

to the cost of the original work and the certificate of the Engineer-in-

charge as to such proportion shall be final and conclusive.

41. Cash Flow Forecasts

41.1 When the programme is updated, the contractor is to provide the engineer

with an updated cash flow forecast.

42. Payment certificates.

42.1 The Contractor shall submit to the Engineer monthly statements of the

estimated value of the work completed less the cumulative amount

certified previously.

42.2 The Engineer shall check the Contractor’s monthly statement within

days and certify the amount to be paid to the Contractor after taking in to

account any credit or debit for the month in question in respect of

materials for the works in the relevant amounts and under conditions set

forth in sub-clause 32.3 of the Contract Data (secured Advance).

42.3 The value of work executed shall be determined by the Engineer.

42.4 The value of work executed shall comprise the value of the quantities of

the items in the Bill of Quantities completed.

42.5 The value of work executed shall include the valuation of variations and

compensation events.

42.6 The Engineer may exclude any item certified in a previous certificate or

reduce the proportion of any item previously certified in any certificate in

the light of later information

43.1 Payments shall be adjusted for deductions for advance payments,

retention, other recoveries in terms of the contract and taxes at source,

as applicable under the law. The Employer shall pay the Contractor the

amounts certified by the Engineer within 28 days of the date of each

43.2 Payment of GST (prevailing rates) on the amount payable under the

contract to the Contractor will be made by the Employer. Hence, it is the

responsibility of the contractor to pay the GST to the concerned Authority.

43.3 Items of the works for which no rate or price has been entered in will not

be paid by the Employer and shall be deemed covered by other rates and

prices in the Contract.

44. Compensation events

44.1 The following are compensation Events unless they are caused by

the Contractor:

(a) The Employer does not give access to a part of the Site by the

site Possession date stated in Contract data to the Contractor

44.2 In case of compensation event occurs and it prevents the work being

completed beyond the Intended Completion Date then Authority will

approve EOT with eligible contractual price escalation.

45.1 The rates quoted by the Contractor must be inclusive of all other taxes

prevailing on due date of bid submission except GST. However, any

subsequent changes in the tax structure by Government after due date of

bid submission will be compensated (+/-) on availability or submission of

actual documentation. Contractor will have to intimate Engineer regarding

changes occurred in the tax structure after bid submission. If the

contractor fails to provide such information and if any financial obligation

may arise due to change in tax structure, same will be recovered from the

45.2 GST will be paid separately on the bills. Hence, it is the responsibility of

the contractor to pay the GST to the concerned Authority.

46. Currencies.

46.1 All payment shall be made in Indian Rupees.

47. Price Adjustment

47.1 Contract price shall be adjusted for increase or decrease in rates and price

of labour, materials, fuels and lubricants in accordance with the following

principles and procedures and as per formula given in the Contract Data:

(a) The price adjustment shall apply for the work done from the start date

given in the contract data up to end of the initial intended completion

date or extensions granted by the Engineer and shall not apply to the

work carried out beyond the stipulated time for reasons attributable to

the contractor.

(b) The price adjustment shall be determined during each month from the

formula given in the contract data.

(c) Following expressions and meanings during the work done during each

R = Total value of work done during the month. It would include the

amount of secured advance granted, if any, during the month less the

amount of secured advance recovered, if any during the month. It will

exclude value for works executed under variations for which price

adjustment will be worked separately based on the terms mutually

47.2 To the extent that full compensation for any rise or fall in costs to the

contractor is not covered by the provisions of this or other clause in the

contract, the unit rates and prices included in the contract shall be deemed

to include amounts to cover the contingency of such other rise or fall in

48.1 The Employer shall retain from each payment due to Contractor the

proportion stated in the Contract Data until Completion of the whole of

48.2 On Completion of the whole of the Works half the total amount retained is

48.2 On Completion of the whole of the Works half the total amount retained is

repaid to the Contractor and half when the Defects Liability Period has

passed and the Engineer has certified that all Defects notified by the

Engineer to the Contractor before the end of this period have been

48.3 On completion of the whole works, the contractor may substitute retention

money with an “on demand” Bank guarantee.

In case, Contractor requests for refund of the Retention Money

deducted by the Employer under the provision of this clause, Employer

shall consider the said request of the Contractor provided that the refund

hereunder shall be made in tranches of not less than 1% (One Percent) of

the Contract Price and Contractor furnishes an irrevocable and

unconditional Bank guarantee for an equal amount substantially in the

format of Bank Guarantee for Performance Guarantee enclosed with SBD

and valid up to 60 day beyond the scheduled / extended Defects Liability

Period. On completion of the whole works, the contractor has however an

option to submit a fresh irrevocable and unconditional Bank Guarantee for

an amount equal to 5% of the total value of work executed substantially in

the format of Bank Guarantee for Performance Guarantee enclosed with

SBD and valid up to 60 days beyond the Defect Liability Period and yet

refund the Retention Money Bank Guarantee submitted for refund of

Retention Money.

49. Liquidated Damages

49.1 The Contractor shall pay liquidated damages to the Employer at the rate

per day stated in the Contract Data for each day that the Completion Date

is later than the Intended Completion Date (for the whole works or the

milestone as stated in the contract data). The total amount of liquidated

milestone as stated in the contract data). The total amount of liquidated

damages shall not exceed the amount defined in the Contract Data. The

Employer may deduct liquidated damages from payment due to the

Contractor. Payment of liquidated damages does not affect the

Contractor’s liabilities.

49.2 If the Intended Completion Date is extended after liquidated damages have

been paid, the Engineer shall correct any overpayment of liquidated

damages by the Contractor by adjusting the next payment certificate. The

Contractor shall not be entitled for any interest on the over payment

calculated from the date of payment to the date of repayment.

49.3 If the contractor fails to comply with the time for completion as stipulated

in the tender, then the contractor shall pay to the employer the relevant

sum stated in the Contract Data as Liquidated damages for such default

and not as penalty for everyday or part of day which shall elapse between

relevant time for completion and the date stated in the taking over

certificate of the whole of the works on the relevant section, subject to

the limit stated in the contract data.

The employer may, without prejudice to any other method of

recovery deduct the amount of such damages from any monies due or to

become due to the contractor. The payment or deduction of such damages

shall not relieve the contractor from his obligation to complete the works

on from any other of his obligations and liabilities under the contract.

49.4 If, before the Time for Completion of the whole of the Works or, if

applicable any Section, a Taking Over Certificate has been issued for any

part of the Works or of a Section, the liquidated damages for delay in

completion of the remainder of the Works or of that Section shall, for any

period of delay after the date stated in such Taking-Over-Certificate, and

in the absence of alternative provisions in the Contract, be reduced in the

proportion which the value of the part so certified bears to the value of

the whole of the Works or Section, as applicable. The provisions of this

Sub-clause shall only apply to the rate of liquidated damages and shall not

affect the limit thereof.

50 Bonus – Not Applicable

50.1 If the contractor achieves completion of the whole of the works prior to

the intended Completion Date prescribed in Contract Data the Employer

shall pay to the contractor a sum stated in Contract Data as bonus for every

completed month but subjected to maximum amount as stated in

Contract Data; which shall elapse between the date of completion of all

items of works as stipulated in the contract, including variations ordered

by the Engineer and the time prescribed in Clause

50.2 Bonus shall be paid only to works amounting to above INR 5 crore with

time limit of the works is equal or more than 6 months. The bonus would

be paid as under

% of Initial Contract Price

% of Time Saved

entitled for Bonus

Less than 10% 0%

51. Advance Payment- Not Applicable

51.1 The Employer shall make advance payment (not to be paid less than two

installments except in special circumstances for which the reason to be

Recorded in writing) to the Contractor of the amounts stated in the

Contract Date by the date stated in the Contract Date, against provision

by the Contactor of an Unconditional Bank Guarantee in a form and by a

bank acceptable to the Employer in amounts and currencies equal to be at

least 110% of the advance payment. The guarantee shall remain effective

until the Advance payment has been repaid, but the amount of the

guarantee shall be progressively reduced by the amounts repaid by the

Contractor. The Mobilization advance would be deemed as interest bearing

advance at an interest rate of 10 % to be compounded, quarterly.

51.2 The Contractor is to use the advance payment only to pay for Equipment,

plant and Mobilization expenses required specifically for execution of the

Works. The Contractor shall demonstrate that advance payment has been

used in this way by supplying copies of invoices or other documents to the

51.3 The advance payment shall be repaid by deduction proportionate amount

from payments otherwise due to the Contractor, following the schedule of

completed percentages of the Works on a payment basis. No account shall

be taken of the advance payment or its repayment in assessing valuations

of work done, variations, price adjustments, Compensation Events, or

Liquidated damages.

52.1 The performance Security (including additional security for unbalanced

bids) shall be provided to the Employer no later than the date specified in

the Letter of Acceptance and shall be issued in an amount and form and

by a bank or surety acceptable to the Employer and denominated in Indian

Rupees. The performance Security shall be valid until a date 60 days from

the date of expiry of Defects Liability Period and the additional security

for unbalanced bids shall be valid until a date 28 days from the date of

issue of the certificate of completion.

54. Cost of Repairs.

54.1 Loss or damage to the Works or Materials to be incorporated in the Works

between the Start date and the end of Defects Correction periods shall be

remedied by the Contractor at the Contractor’s cost if the loss or damages

arises from the Contractor’s acts or omissions.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

E. FINISHING THE CONTRACT

55.1 The Contractor shall request the Engineer to issue a Certificate of

Completion of the works and the Engineer will do so upon deciding that

the work is completed.

56. Taking Over

56.1 The Employer shall take over the Site and the Works within seven days of

the Engineer issuing a certificate of Completion.

57. Final Account

57.1 The Contractor shall supply to the Engineer a detailed final account of the

total amount that the Contractor considers payable as full and final

total amount that the Contractor considers payable as full and final

settlement of all claims under the Contract for items before the end of the

Defects Liability Period. The Engineer shall issue a Defect Liability

Certificate and certify any final payment that is due to the Contractor

within 56 days of receiving the Contractor's account if it is correct and

complete. If it is not, the Engineer shall issue within 56 days a schedule

that states the scope of the corrections or additions that are necessary. If

the Final Account is still unsatisfactory after it has been resubmitted, the

Engineer shall decide on the amount payable to the Contractor and issue a

payment certificate within 56 days of receiving the Contractor’s revised

57.2 If reversal in characteristic of tender (L1 becoming L2) on account of

excesses and savings in final account is observed, the Engineer/Employer

shall be at liberty to restrict the final payment of BOQ items to the lowest

amount evaluated of the bids considering the final quantities and the rates

quoted including the rebates if any. Payment of variation items shall

however be made at the rates approved by the Employer, within 90 days

from the physical completion of work.

58. Operating and Maintenance Manuals

58.1 If “As built” drawings and/or operating and maintenance manuals are

required, the Contractor shall supply them by the dates stated in the

58.2 If the Contractor does not supply the Drawings and/or manuals by the dates

stated in the Contract data, or they do not receive the Engineer’s approval,

the Engineer shall withhold the amount stated in the Contract Data from

payments due to the Contractor.

59. Termination

59.1 The Employer or the Contractor may terminate the Contract if the other

party causes a fundamental breach of the Contract.

59.2 Fundamental breaches of Contract include, but shall not be limited to the

1. The contractor stops work for 28 days when no stoppage of work is shown

on the current programme and the stoppage has not been authorized by

2. The Engineer instructs the Contractor to delay the progress of the Works

and the instructions is not withdrawn within 28 days;

3. The Employer or the Contractor is made bankrupt or goes into liquidation

other than for a reconstruction or amalgamation

4. A payment certified by the Engineer is not paid by the Employer to the

Contractor within 56 days of the date of the Engineer’s certificate

5. The Engineer gives Notice that failure to correct a particular Defect is a

fundamental breach of Contract and the Contractor fails to correct it

within a reasonable period of time determined by the Engineer;

6. The Contractor does not maintain a security which is required;

7. The Contractor has delayed the completion of works by the number of days

for which the maximum amount of liquidated damages can be paid as

defined in the Contract data; and

8. If the Contractor, in the judgment of the Employer has engaged in corrupt

or fraudulent practices in competing for or in executing the Contract.

For the purpose of this paragraph: “corrupt practice” means the

offering, giving, receiving or soliciting of anything of value to influence the

action of a public official in the procurement process or in contract

execution. “Fraudulent practice” means a misrepresentation of facts in

order to influence a procurement process or the execution of a contract to

the detriment of the borrower and includes collusive practice among

Bidders (prior to or after bid submission) designed to establish bid prices at

artificial non-competitive levels and to deprive the Borrower of the

benefits of free and open competition.

59.3 When either party to the Contract gives notice of a breach of contract to

the Engineer for a cause other than those listed under Sub Clause

above, the Engineer shall decide whether the breach is fundamental or

59.4 Notwithstanding the above, the employer may terminate the Contract for

60. Payment upon Termination

60.1 If the Contract is terminated because of a fundamental breach of Contract

by the Contractor, the Engineer shall issue a Certificate for the value of

the work done less advance payments received up to the date of the

issue of the certificate, less other recoveries due in terms of the contract,

less taxes due to deducted at source as per applicable law and less the

percentage to apply to the work not completed as indicated in the Contract

data. Additional Liquidated Damages shall not apply. If the total amount

data. Additional Liquidated Damages shall not apply. If the total amount

due to the Employer exceeds any payment due to the Contractor the

difference shall be a debt payable to the Employer.

60.2 If the Contract is terminated at the Employer’s convenience or because of

a fundamental breach of Contract by the Employer, the Engineer shall issue

a certificate for the value of the work done, the cost of balance material

brought by the contractor and available at site, the reasonable cost of

removal of equipment, repatriation of the Contractor’s personnel

employed solely on the works, and the Contractor’s cost of protecting and

securing the Works and less advance payment received up to the date of

the certificate, less other recoveries due in terms of the contract and less

taxes due to deducted at source as per applicable law.

61.1 All materials on the Site, Plant Equipment’s, Temporary Works and Works

are deemed to be property of the Employer, if the Contract is terminated

because of a Contractor’s default.

62. Release from Performance

62.1 If the Contract is frustrated by the outbreak of war of by any other event

entirely outside the control of either the Employer or the Contractor the

Engineer shall certify that the Contract has been frustrated. The

Contractor shall make the Site safe and stop work as quickly as possible

after receiving this certificate and shall be paid for all work carried out

before receiving it and for any work carried out afterwards to which

commitment was made.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

F. SPECIAL CONDITIONS OF CONTRACT

The Contractor shall, unless otherwise provided in the Contract,

make his own arrangements for the engagement of all staff and labour,

local or other, and for their payment of housing, feeding and transport.

The Contractor shall, if required by the Engineer, deliver to the

Engineer a return in detail, in such form and at such intervals as the

Engineer may prescribe, showing the staff and the numbers of the several

classes of labour from time to time employed by the Contractor on the site

and such other information as the Engineer may require.

64. COMPLIANCE WITH LABOUR REGULATIONS

During continuance of the contact, the Contractor and his sub-

contractor shall abide at all times by all existing labour enactments and

rules made thereunder, regulations, notification and bye laws of the State

or central Government or local authority and any other labour law

(including rules), regulations, bye laws that may be passed or notifications

that may be issued under any labour law in future either by the State or

the Central Government or the local authority. Salient features of some of

the major labour laws that are applicable to the construction industry are

given below. The Contractor shall keep the Employer indemnified in case

any action is taken against the Employer by the competent authority on

account of contravention of any of the provisions of any Act or rules made

thereunder, regulations or notifications including amendments. If the

Employer is caused to pay or reimburse, such amounts as may be necessary

to cause or observe, or for observance of the provisions stipulated in the

notifications/bye laws/Acts/Rules/regulations including amendments, if

any, on the part of the Contractor, the Engineer/employer shall have the

right to deduct any money due to the Contractor including his amount of

performance security. The Employer/Engineer shall also have the right to

recover from the Contractor any sum required or estimated to be required

for making good the loss or damage suffered by the Employer.

The employees of the Contractor and the Sub-Contractor in no case shall

be treated as the employees of the Employer at any point to time.

SALIENT FEATURES OF SOME MAJOR LABOUR AND OTHER LAWS APPLICABLE

TO ESTABLISHMENTS ENGAGED IN BUILDING AND OTHER CONSTRUCTIONS

A) Workmen Compensation Act 1923:- The Act provides for compensation in

case of injury by accident arising out of and during the course of employment.

B) Payment of Gratuity Act. 1972:- Gratuity is payable to an employee under

the Act on satisfaction of certain conditions on separation if an employee has

completed 5 years’ service or more on death, the rate of 15 days wages for

every completed year of service. The Act is applicable to all establishments

employing 10 or more employees.

C) Employees P.F. and Miscellaneous Provision Act 1952:- The Act Provides for

monthly contributions by the employer plus workers @ 10% or 8.33% The

benefits payable under the Act are :

1. Pension or family pension on retirement or death, as the case may be.

2. Deposit linked insurance on the death in harness of the worker.

3. Payment of P.F. accumulation on retirement/death etc.

D) Maternity Benefit Act 1951:- The Act provides for leave and some other

benefits to women employees in case of confinement or miscarriage etc.

E) Contract Labour (Regulation & Abolition) Act 1970: The Act provides for

certain welfare measures to be provided by the Contractor to contract labour

and in case the Contractor fails to provide, the same are required to be

provided, by the Principal Employer by Law. The principal Employer is

required to take Certificate of Registration and the Contractor is required to

take license from the designated Officer. The Act is applicable to the

establishments or Contractor of Principal Employer, if they employ 20 or more

contract labour.

F) Minimum Wages Act 1948:- The Employer is supposed to pay not less than

the Minimum Wages fixed by appropriate Government as per provisions of the

Act, if the employment is a scheduled employment. Construction of Building,

Roads, Runways are scheduled employment.

G) Payments of wages Act 1936:- It lays down as to by what date the wages are

to be paid, when it will be paid and what deductions can be made from the

wages of the workers.

H) Equal remunerations Act 1979:- The Act provides for payment of equal

wages for work of equal nature to Male and Female workers and for not

making discrimination against female employees in the matter of transfer,

training and promotions etc.

I) Payments of Bonus Act 1965:- The Act is applicable to all establishments

employing 20 or more employees. The Act provides for payments of annual

bonus subject to a minimum of 8.33% of wages and maximum of 20 % of wages

to employees drawing Rs. 3500/- per month or less. The bonus to be paid to

employees getting Rs.2500/- per month or above Rs.3500/- per month shall

be worked out by taking wages as Rs.2500/- per month only. The Act does

not apply to certain establishments. The newly set-up establishments are

exempted for Seven Years in certain circumstances. Some of the State

Governments have reduced the employment size from 20 to 10 for the

purpose of applicability of this Act.

J) Industrial Disputes Act 1947:- The Act lays down the machinery and

procedure for resolutions of Industrial disputes, in what situations a strike or

lock-out becomes illegal and what are the requirements for laying off or

retrenching the employees or closing down the establishment.

K) Industrial employment (standing Orders) Act 1946:- It is applicable to all

establishments employing 100 or more workmen (employment size reduced

by some of the State and Central Government to 50). The Act provides for

laying down rules governing the conditions of employment by the Employer

on matters provided in the Act and get the same certified by the designated

L) Trade Unions Act 1926:- The Act lays the procedure for registration of trade

unions of workmen and employers. The Trade Unions registered under the

Act have given certain immunities from civil and criminal liabilities.

M) Child Labour (Prohibition & Regulation Act 1986:- The Act prohibits

employment of children below 14 years of age in certain occupations and

process and provides for regulation of employment of children in all other

occupations and processes. Employment of Child labour is prohibited in

Building and Construction Industry.

N) Inter – State Migrant workmen’s (Regulation of Employment & Conditions

of service) Act 1979:- The Act is applicable to an establishment which

employs 5 or more inter-state migrant workmen through an intermediary

(who has recruited workmen in one state for employment in the

establishment situated in another state).The inter-state migrant workmen, is

an establishment to which this Act becomes applicable, are required to be

provided certain facilities such as housing, medical aid, traveling expenses

from home up to the establishment and back, etc.

O) The Building and Other Construction workers (Regulation of employment

and Conditions of Service) Act 1996 and the Cess Act of 1996:- All the

establishments who carry on any building or other constructions work and

employ 10 or more workers are covered under this Act.

All such establishments are required to pay cess at the rate not exceeding 2%

of the cost of construction as may be modified by the government. The

Employer of the establishment is required to provide safety measures at the

Building or construction work and other welfare measures, such as canteens,

First Aid facilities, Ambulance, Housing accommodations for workers near the

workplace etc. The Employer to whom the Act applies has to obtain a

registration certificate from the Registering Officers appointed by the

P) Factories Act 1948:- The Act lays down the procedure for approval of plans

before setting up a factory, health and safety provisions, welfare provisions,

working hours, annual earned leave and rendering information regarding

accidents or dangerous occurrences to designated authorities. It is applicable

to premises employing 10 persons or more with aid of power or 20 or more

persons without the aid of power engaged in the manufacturing process.

Q) Royalty charges-The contractor shall pay the royalty to the competent

authority as per rule. The royalty charges paid shall be borne by the

contractor and shall not be reimbursed by the Employer.

R) Following Pollution control Acts and amendments made thereof from

time to time shall be applicable.

1. Water (Preservation and control of Pollution) Act,

2. Air (Prevention and Control of Pollution Act

3. Environmental (Protection) Act

The contractor must commit to adopting Environmental management

plan for best energy use, waste management, the reduction of pollution as in

EMS (Environmental Management system)ISO-14001-

65. ARBITRATION (GCC Clause 24)

The procedure for arbitration will be as follows: -

24.1 If the Contractor is of the view that a decision taken by the Engineer was

either outside the authority given to the Engineer by the Contract or that

the decision was wrongly taken, the decision shall be referred to

#Divisional Head (Higher Authority) within 14 days of the notification of

the Engineer's decision. If the issue is not resolved, any party can refer the

matter for conciliation within 15 days from the decision given by the

#Divisional Head.

(a) For the work up to Rs.100 Cr., if any of the parties is not satisfied with

the decision of the #Divisional Head, both the parties have to refer to

the #Divisional Head concerned for the conciliation process.

(b) For the work more than Rs.100 Cr., if any of the parties is not satisfied

with the decision of the Divisional Head, both parties have to refer to

the #Municipal commissioner, SMC, and Government of Gujarat for the

conciliation process.

If the dispute is not resolved through the conciliation process,

contractor may refer the dispute to Gujarat Public Works Contract

Dispute Arbitration Tribunal. If the Contractor fails to refer a claim /

dispute to the Higher Authority within 14 days of the notification of the

Engineer's decision, the Contractor shall not be entitled to any

additional payment/claim if he doesn’t follow the above sequence in

stipulated time. However, during such period, he would not stop the

work in any case.

Signature of Contractor MUNICIPAL COMMISSIONER/ CHIEF OFFICER

Section 3: Conditions of Contract for Operation & Model STP

Conditions of Contract for Operation & Maintenance

Section 3: Conditions of Contract for Operation & Model STP

CONDITIONS OF CONTRACT

FOR OPERATION AND MAINTENANCE

(ADMINISTRATIVE PROVISIONS)

The following additional clauses shall apply only during the Operation and Maintenance period.

1. DEFINITIONS A N D INTERPRETATION

1.1. Definitions: In these Conditions of Contract (“Conditions”) the following words and

expressions shall have the meanings hereby assigned to them, except where the context

otherwise requires.

1.1.1. “Applicable Law” means all national (or State) legislation, statutes, ordinances and

other Laws and regulations and by laws of any legally constituted public authority.

1.1.2. “Contract” means the contract agreement, these conditions, the Employer’s requirements,

the Tender and the further documents (if any) which are listed in the contract agreement.

1.1.3. “Contractor’s Equipment” shall mean all equipment, instruments, tools, machinery and

other appliances and things of the Contractor at the Site required for the fulfilment of the

obligations of the Contractor under these Conditions.

1.1.4. “Contractor’s Personnel” means the contractor’s representative and all personal whom the

contractor utilizes on site, who may include the staff, labour, & other employees of the

contractor and of each sub–contractor & any other personnel assisting the Contractor in

the execution of the work.

1.1.5. “Dispute” shall have the meaning given to it in Clause 15 of these Conditions.

1.1.6. “Employer’s Risk” shall include the risks mentioned as Employers risks in the General

Conditions and shall include any negligence or misconduct on the part of the Employer and

any event of Force Majeure as provided in Clause 12 of these Conditions.

1.1.7. “Employer’s Personnel” means the Employer’s Representative, the assistants and all other

staff, labour and other employees of the Employer and of the Employer’s representative,

and any other personnel notified to the contractor, by the Employer or the Employer’s

representative, as Employer’s personnel.

1.1.8. “Employer’s Requirements” means the document entitled Employer’s requirements, as

included in the contract, and any additions and modifications to such document in

accordance with the contract. Such document specifies the purpose, scope, and / or

design and / or other technical criteria, for the works.

1.1.9. “Facility” shall mean the entire system to be designed and constructed including the

equipments, buildings, structures, ramps, pits, pipes, fencing, lighting, testing and analysis

equipment, tools, computers, software programs, safety equipment, plant machinery,

supplies, instruments and inventory incorporated therein, as well as all open areas within

the Site, and including any additions, modifications, alterations, replacement and repairs as

may be made thereto from time to time.

1.1.10. “Force Majeure” shall mean those events mentioned in Clause 12 of these Conditions.

Section 3: Conditions of Contract for Operation & Model STP

1.1.11. “General Conditions” shall mean the conditions of tender issued by Employer EMPLOYER

for O&M works of projects.

1.1.12. “Good Operating Practices” means the standards, practices, methods and procedures as

practiced internationally and in India conforming to all Applicable Law and that degree of

skill, diligence, prudence and foresight which would reasonably be expected from a skilled

and experienced contractor engaged in India in the same type of undertaking under the

same or similar circumstances as the Contractor pursuant to these Conditions.

1.1.13. “O & M Contract” shall mean the contract or part of any other contract having scope of

Operation and Maintenance of facilities, entered in between the Employer and the

Contractor pursuant to these Conditions.

1.1.14. “O & M Completion Certificate” shall mean the certificate to be issued by the Employer on

the completion of all the obligations of the Contractor under these Conditions.

1.1.15. “O & M Services” shall mean those services specified in Schedule [1] which the Contractor

is obligated to perform under these Conditions.

1.1.16. “O & M Standard” shall mean the standards: As set forth in the tender documents

a) As required pursuant to Applicable Law;

b) Set out in the Performance Guarantee; and

c) For the functioning of the Facility as required in accordance with the Contract

including such requirements as may be mentioned in the Employer’s Requirements.

d) For the functioning of the Facilities set forth in these Conditions.

1.1.17. “O & M Manual” shall have the meaning for manual of Operation and Maintenance

prepared by the contractor.

1.1.18. “O & M Period” shall have the meaning set out in Clause.

1.1.19. “O & M Price” shall mean the amount of Operation & Maintenance as agreed upon

1.1.20. “Party” shall mean each of the Contractor and the Employer and Parties shall mean both

of them together.

1.1.21. “Performance Guarantees shall mean the guarantee that the Facility shall be operated

continually satisfying the minimum performance parameters set out in Schedule.

1.1.22. “Successor Contractor” shall have the meaning given to it in Clause.

1.1.23. “Site” shall means that specific area specified in the bid documents & shall include any

other places as may be specifically designed by the Employer from the time to time as

forming part of the site.

1.1.24. “Taking over Date” shall mean the date of issue of the taking over certificate at the end of

the Operation and Maintenance period.

1.1.25. “Taking over Certificate” means the certificate to be issued by EMPLOYER/ ULB to the

Contractor at the successful completion of the Operation and Maintenance period.

1.1.26. “Termination” shall have the meaning given to it in Clause [13] of these Conditions.

1.2. Interpretation: In these conditions, except where the context requires otherwise.

Section 3: Conditions of Contract for Operation & Model STP

1.2.1. words indicating one gender include all genders,

1.2.2. words indicating the singular also include the plural and words indicating the plural also

include the singular,

1.2.3. Provisions including the word ‘agree’, ‘agreed’ or ‘agreement’ require the agreement to be

recorded in writing;

1.2.4. ‘written’ or ‘in writing’ means hand‐written, type‐written, printed or electronically made, and

resulting in a permanent record;

1.2.5. The marginal words and other headings shall not be taken into consideration in the

interpretation of these Conditions;

1.2.6. The words ‘include,’ ‘includes’ and ‘including’ are not limiting;

1.2.7. As used in these Conditions, all defined terms include the plural as well as the singular;

1.2.8. Any agreement, document or drawing defined or referred to in these Conditions shall

include amendment, modification and supplement thereto and waiver thereof as may

become effective from time to time, except where otherwise indicated;

1.2.9. Any reference to any Clause or Sub – Clause shall unless specified otherwise mean a

Clause or Sub-Clause of these Conditions; and

1.2.10. Any rights of the Employer to make any inspections or to review any document shall not

create any obligation on the Employer to conduct such inspections or reviews to detect

any errors, inaccuracies, ambiguities or other potential problems. No inspection or approval

by or on behalf of the Employer shall operate as a waiver of any provision of these

Conditions, any obligation of Contractor under these Conditions, or any of the rights of the

Employer hereunder, except as expressly agreed in writing by the Employer.

1.3. Scope during Trial run and Defect Liability period:

1.3.1. The scope of work under this contract includes trial run and maintenance of the STP(s) as

a whole and its parts as an individual component as well. Under this the contractor has to

run the scheme completely and will have to prove performance of each component

individually and of whole scheme as per the standards laid down in contract. During this

period the contractor shall have to appoint necessary staff for running and maintenance of

scheme. The candidature of the staff being engaged by contractor shall have to be

approved by the Engineer-in-Charge. During this period Engineer-in-Charge/ULB will

appoint staff to check the performance of project and also get hands on training to run and

maintain the scheme. Contractor and his staff will arrange training for the staff to the

satisfaction of Engineer In-charge. The period of trial run, testing and commissioning will be

three (03) calendar months from the date of actual completion of the scheme as certified by

the Engineer In-charge. Defect liability period will start from successful commissioning of

1.4. Commencement and Duration of O & M part of contract

1.4.1. “The O & M Period” shall commence from the date of issue of ‘Certificate of successful

commissioning’ of the facilities including three calendar month trial run period or till

prescribed parameters are not attained & whichever is later of the two and shall

continue operation & maintenance of entire system for (As Mentioned in tender notice)

years including defect liability period there from.

1.5. Applicable Law

Section 3: Conditions of Contract for Operation & Model STP

1.5.1. The Contractor shall comply with all Applicable Law relevant to the Contractor’s

Personnel, including Applicable Law relating to their employment, health, safety,

welfare, immigration and emigration, and shall allow them all their legal rights.

1.5.2. The Contractor shall require his employees to obey all Applicable Laws, including those

concerning safety at work.

1.5.3. In the event Employer becomes liable to any Employer’s Personnel, any

Governmental authority (including but not limited to any fines or penalties levied by or

payable to such authority) or to any other third party under the provisions of any

Applicable Law resulting from Contractor’s failure to comply with such Applicable Law,

Contractor shall reimburse Employer for all payments required to be made by Employer to

such Employers Personnel, Governmental authority or any other third party, plus the actual

expenses that Employer may incur in investigating, settling or defending any litigation or

threatened litigation.

1.6. Assignment

1.6.1. The Contractor will not be entitled to sub-contract any part of his obligation under these

Conditions to any third party.

1.7.1. Emergencies

In the event of an emergency endangering any life or property, the Contractor shall

immediately take such action as may be necessary to prevent, avoid or mitigate

injury, damage or loss and shall, as soon as possible, report any such incidents,

including his response thereto to the Employer.

1.7.2. Contractor Action

The Contractor shall utilize his personnel to take such action as may be necessary in

accordance with Good Operating Practices in the event of an emergency.

Notwithstanding anything to the contrary herein, the Contractor may incur any

expenditure or take any other operating actions as the Contractor deems to be

necessary (in accordance with Good operating practices) in the case of emergencies

affecting the Facilities or the operation of the Facilities to counteract the effects where

the Contractor considers immediate action is required to safeguard lives or property. In

case such emergency was caused due to an Employer’s Risk then the Employer shall

reimburse such reasonable expenses that might have been incurred by the Contractor in

relation thereto acting in accordance with Good Industry Practices.

1.8. Notification

1.8.1. In the event of an emergency the Contractor shall forthwith notify the Employer of the

emergency, the expenditures made, and the operating actions taken.

1.8.2. If the Employer considers that an emergency has arisen in relation to the Facilities, the

Employer may give written notice to the Contractor specifying the nature of the emergency

which it has identified and the manner in which it requests such emergency to be rectified.

The Contractor shall rectify such defect with all due diligence. If such emergency is on

account of an Employer’s Risk, then the Contractor shall be reimbursed all costs and

expenses reasonably incurred by the Contractor for any actions taken by it pursuant to

such direction or notice. If the Contractor fails to comply with such direction or notice

promptly, the Employer shall be entitled to procure that it or any third party takes such

actions as may be necessary to remedy such breach by the Contractor. Any costs that may

Section 3: Conditions of Contract for Operation & Model STP

be incurred by the Employer in this regard shall be reimbursed to him in full by the

Contractor and shall be a debt due to him from the Contractor.

1.9. Inspections

Notwithstanding any provisions of these Conditions and without prejudice to any of the

other rights vested by the Contractor under these Conditions, The Employer shall have the

right at all times to inspect the Facilities and the Contractor shall co-operate in every

manner with the representatives of the Employer inspecting the Facilities and allow them

access to every part of the Facilities and produce any records requested.

2. OPERATION OF THE FACILITIES

2.1. Operation of the Facilities

2.1.1. On Employer appointing the Contractor to perform and undertake the O & M Services and

all other obligations set out and in accordance with these Conditions during the O&M

Period. The Contractor shall accept the appointment and acknowledges a duty to perform

such obligations.

2.1.2. The Contractor shall be in complete charge of and have custody and control over and

responsibility for the Facilities, and the Contractor shall perform or cause to be performed

on behalf of the Employer all O & M Services for the Facilities and shall supply or cause to

be supplied all materials required there for in accordance with the O & M Standard.

2.1.3. The Contractor shall also acknowledge that the Employer and the Employer’s Personnel

and other contractors may be carrying out work at the Facilities and shall endeavour to fully

co-operate and work in a manner so as not to cause any obstruction or hindrance to them.

2.1.4. The Contractor shall remain an independent Contractor and not an agent, employee and

nothing in these Conditions or the O & M part of contract shall be deemed to create a Joint

Venture between the Employer and the Contractor.

2.2. Responsibility of the Contractor- The Contractor shall be solely and exclusively

responsible for:

2.2.1. The contractor shall be responsible for smooth and satisfactory operation and maintenance

of the plant on round the clock basis for a period of (as mentioned in tender notice) years

from the date of completion of trial run and commissioning of Sewage Treatment Plant.

2.2.2. Obtaining all necessary permits and consents required by Applicable Law or any

Governmental authority for the Contractor to carry out the O & M Services.

2.2.3. The procurement of all goods and services necessary to ensure compliance with his

obligations under these Conditions,

2.2.4. Making available suitably qualified and trained personnel to perform the O & M Services.

2.2.5. Perform the O & M Services in accordance with the O & M Manuals prepared by the

Contractor and as approved by the Engineer in Charge and maintain the Facilities in good

repair and condition and ensure that the Facilities are well and suitably maintained at all

times in accordance with Good Operating Practices and in accordance with these

2.2.6. Procuring and administering all chemicals and other consumables, tools, equipment, spare

parts and other materials (which shall be of good quality and unused) necessary for the

operation and maintenance of the Facilities.

Section 3: Conditions of Contract for Operation & Model STP

2.2.7. Maintaining a system of records to identify all inventories related to the Facilities and

preparing and providing to the Employer a complete accounting of such inventory for every

fiscal quarter;

2.2.8. Arranging for the testing and recalibration of all scales, meters, gauges and other

measuring devices at the Facilities on an annual basis and maintain the Calibration

certificates as records unless otherwise stated in the O & M part of contract; and

2.2.9. For providing any and all relevant information required by the Employer.

2.2.10. Contractor shall ensure that the treatment plant is run on continuous basis and shut down if

any subject to obtaining prior permission / approval of the Employer. Generally major repair

encountered in any unit shall be attended as quickly as possible.

2.2.11. The contractor shall monitor the performance of the Sewage treatment plant; conduct the

analysis of the influent as well as effluent quality after treatment.

2.2.12. Contractor shall initiate and take adequate actions to ensure smooth and satisfactory

performance/ running of the plants on a 24 hours/ round the clock basis.

2.2.13. For the smooth running of the plant all the required equipment, machineries, accessories,

major and minor spares, consumables including chemicals, greases, lubricants, all

cleaning agents, packing, rubber sheet, laboratory reagents, all hardware, required quantity

of white wash, oil paint color, all types of epoxy paint, material required for house- keeping

and cleaning etc. are to be brought by the contractor. The quality of all consumable and

spare etc. i.e. technical requirements as per manufacture recommendation shall remain

2.2.14. A technical expert of the contractor shall visit the plant on every fortnight and will suggest if

required, to improve the efficiency and working of the plant. The visit must be recorded in

document and outcome of the visit/minutes of meeting should be got signed by Engineer

In-charge of works without which the visit shall not be considered.

2.2.15. In case, there is no inflow to the plant after completion of construction for a period of one

month and/ or more, payment during first fifteen days of O & M stage will be made without

any deduction. Payment for next fifteen days of the first month shall be made at rate of

50% of O & M price quoted by him. Contractor shall also be paid for 15 days of the second

month at rate of 50% of O & M price quoted by him. Thereafter, payment towards security

watchmen and minimum power requirement will only be made (i.e. after 45 days of