Tender for Increasing the Vertical Clearance of existing 66kV Overhead EHT line crossings at Railway km No. Three (Eight hundred to Nine hundred Double circuit between Channasandra CSDR to Yelahanka YNK Railway station in Hoody Division Bengaluru in the jurisdiction of Transmission pertaining Circle South KPTCL on total turn key basis on percentage tender basis

The Bidder shall have adequate knowledge of Sub-stations and Transmission lines, design, procedure including quality control and shall have infrastructure and errection facilities and capacitiy to execute the works

The bidder should have satisfactorily completed in the last five years at least one work of Construction of Stations/Transmission Lines/Errection of Towers/Maintenance or rectification work of EHV Transmission lines/One Terminal Bay of 66 KV class or above voltage class on Total Turn key, Partial Turnkey basis for the last five financial years in KPTCL/PGCIL/NHPC/NTPC/any Govt.,or public sector undertakings & produce experience and performance certificate duly signed by competent authorities not below the rank of the Executive Engineer Electrical which shall be in satisfactory service for a period of One year prior to date of submission of the Bid. Scanned copy of the supporting original documents shall be uploaded

The Bidder should possess valid Super Grade Electrical Contractors License issued by the Government of Karnataka as on the date of Bid Submission

Notwithstanding the above, if it is found that the performance vis a vis works awarded to the Bidder by KPTCL is either behind schedule or not satisfactory, KPTCL is either behind schedule or not satisfactory, KPTCL will be at liberty to disqualify the Bidder and reject its Bid at techno-commercial evaluation/any stage of processing of the bid

The Bidder must not have black listed by KPTCL/ESCOMS/other electrical utilities/who are in the business of distribution of power

The bidder should provide detailed information on any litigation or arbitration arising out of contracts completed or under execution by it over the preceding five years. A consistent history of awards involving litigation against the Bidder may result in rejection of bid

Notwithstanding anything stated above, the KPTCL reserves the right to assess the bidders capability to perform the work, should the circumstances warrant such assessment in the overall interest of the KPTCL

For executing the above works, the contractor should have the necessary skilled men with tools and tackles. List of technical staff, tools & tackles to be uploaded in Technocommercial sheets

Bidder shall note that KPTCL may not award the work to successful bidder, even if it is lowest quoted offer (L1) if in opinion of KPTCL based on its experience, the firm may not perform well in execution of work and may delay in execution because of its existing works on hand

A Bidder shall submit only one tender in the same tendering process

Goods and Service tax registration certificate issued by GOI

Any other relevant documents mentioned in tender document

Pan Certificate

No deviation Certificate

The Bidder shall upload Certificate regarding restrictions on procurement from a Bidder of a Country which shares a land border with India in the format as specified in the clause No. 1.5 of Annexure XVIII of the tender documents

Bidders shall submit audited financial reports for last five years preceding the date of bid submission duly certified by Registered Chartered Accountant, Minimum Average Annual Turnover MAAT of the bidder for best three years out of last five financial years ending on March or December as the case may be shall not be less than 1.5 times amount put to tender

Bidder shall be financially sound. Bidder shall submit audited financial reports for last five financial years preceding the date of bid submission, duly certified by the registered chartered Accountant