Tender ID

Karnataka

Retender

Works

Lift Irrigation Scheme

Supply of Manpower & Consummables to Kurni LIS Ist stage at Ingali Village for the year 2024-25

Karnataka Neeravari Nigam Limited

KNNL Division GRBCC Div No 2 Hidkal Dam | Karnataka

Amount: ₹12.7 LCloses: 6 Jan 2025Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published21 Dec 2024
Closed6 Jan 2025
Retendered21 Dec 2024

Cancellation Details

Retendered

RetenderedRetenderedReason: Retendered

Published 21 Dec 2024

Tender Value

₹12.7 L

EMD Value

₹19,000

Closing Date

6 Jan 2025, 11:00 pmClosed

Tender Inviting Authority

Office Inviting Bids

Karnataka Neeravari Nigam Limited

Contact Person

RAVI TALUR

Office Number

Mobile Number

Work Description

Supply of Manpower & Consummables to Kurni LIS Ist stage at Ingali Village for the year 2024-25.

Tender Information

Tender ID

KNNL/2024-25/LI/WORK_INDENT2136/CALL-2

Reference Number

KNNL/2024-25/LI/WORK_INDENT2136/CALL-2

Tender Type

Reserved

Product Category

Lift Irrigation Scheme

Form of Contract

Electronic Documents, First(One Cover)

Location

KNNL Division GRBCC Div No 2 Hidkal Dam

Source Website

Subscribe to view

Documents Required

8 documents required · 8 mandatory

Technical Bid

RequiredA copy of the valid Karnataka PWD Class-IV & above Registration Certificate

RequiredCopy of Valid Employees Provident Fund Registration Certificate

RequiredEPF paid Challan of previous month with reference to the date of publishing of the present Tender Notification in e-procurement portal

RequiredValid GST Registration Certificate and the Authorized person should be enclosed specimen signature.

RequiredIncome Tax PAN card and Income Tax returns filed for the Financial year 2023-24 Assessment year 2024-25

RequiredFor the works which are reserved for the bidders / contractor belonging to Scheduled Tribe the bidders should enclose the recent Caste Certificate obtained from the concerned taluka Tahasildars

RequiredFor the works which are reserved for the bidders / contractor belonging to Scheduled Tribe the bidders should enclose the recent Domicile Certificate Proof of minimum of 10 years resident of Karnataka obtained from the concerned taluka Tahasildars

RequiredThe contractor should attach their recent correct portal address Phone No. & mail address.

Eligibility Criteria

Tenders from Joint ventures are not acceptable.

The amount put to tender is Exclusive of GST.The Contractor should quote the rate Exclusive GST.Increase in GST shall not be paid in the extended period of contract for which the contractor is responsible for delay in determined by the authority while granting extension of time

Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by any State Government / Government of India /Union Territory

It shall be the responsibility of the Bidder to ensure credit of Tender Processing Fee and EMD into the respective receiving bank accounts of e-Procurement on or before the last date and time of bid submission.

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection.

The bidder is required to ensure browser compatibility of the computer well in advance to the last date and time for receipt of tenders. The departments shall not be responsible for non-accessibility of e-Procurement portal due to internet connectivity issues and technical glitches at bidders end

EMD Payments through e-Payment mode shall be made as one single transaction and payments made in part are liable for rejection

Bidder shall pay Contract Management Module processing fees of 0.025% of the contact value (Min Rs.500/- & Max Rs.7500/-) soon after contract has been issued to bidder

Contractors can request for E-tendering documents on Payment (non refundable) for each work towards the tender processing fee. While applying the contractors can pay the tender processing in the e-procurement portal using modes-viz. through ICICI bank / credit card / direct debit / National Electronic Fund Transfer (NEFT)/ Over The Counter (OTC)

The contractor should pay Earnest Money Deposit (EMD) in the E-procurement portal using any of the payment modes viz., credit card / direct debit / National Electronic Fund Transfer (NEFT) / Over the Counter (OTC). The validity of the EMD shall be for a period of 180 days from the date of opening of the tender. The EMD amount accepted in the form of electronic cash (not through DD) will be maintained in the Government Central Pooling Account at ICICI Bank until the contract is closed. The EMD amount to be paid through Electronic Cash only

The following certified copies duly attested shall be scanned and attached to E-procurement tender

A copy of the valid Karnataka PWD Class-IV & above Registration Certificate

Copy of Valid Employees Provident Fund Registration Certificate

EPF paid Challan of previous month with reference to the date of publishing of the present Tender Notification in e-procurement portal

Valid GST Registration Certificate and the Authorized person should be enclosed specimen signature.

Income Tax PAN card and Income Tax returns filed for the Financial year 2023-24 Assessment year 2024-25

For the works which are reserved for the bidders / contractor belonging to Scheduled Tribe the bidders should enclose the recent Caste Certificate obtained from the concerned taluka Tahasildars

For the works which are reserved for the bidders / contractor belonging to Scheduled Tribe the bidders should enclose the recent Domicile Certificate Proof of minimum of 10 years resident of Karnataka obtained from the concerned taluka Tahasildars

Tender has to quote service charges for supplying of man power for individual service and service charge shall not be negative.

The bidder should submit the declaration regarding payment of wages of the man power according to sanction estimate

While the time of agreement The bidder should submit the COURT AFFIDIT regarding payment of wages of the man power according to sanction estimate

The contractor should attach their recent correct portal address Phone No. & mail address.

For Construction of transmission line/Substation Works,the Contractor shall engage only those agencies who are licensed to do the power line construction works in Karnataka .They should have constructed at least one similar single power line for the equal to 80% of the length of power line for the work tendered in a single contract .The details of the transmission line construction contractor with registration certificate and certificates of experience signed by an officer of not below rank Executive Engineer of KPTCL shall be submitted for KNNLs verification post award of the Work

The Work of the construction of transmission line should be got done through a government licensed ,Super Grade Electrical Contractor CEIG Approved ,who have the experience of carrying out such works.

Corrigendum / Addendum will be published in the E- Procurement website for all modifications / Corrections if any

The intending contractors should note that, if any of the lands (either in part / parts or in whole) required for the work is not yet acquired by the Department, it shall be the responsibility of the contractor to take possession of such land and start the work by consent of the owners before commencement of work at no extra cost to the Department and no claims whatsoever relating to non availability of land would be entertained

If any of the dates mentioned above happens to be a General Holiday, the next working day will holds good

Conditional tenders are liable to be rejected. The officer competent to accept the tenders shall have the right to reject any or all the tenders without assigning any reason whatsoever

The intending bidders are advised to visit the site of work before submitting their tenders

As per the Government order No. LT/300/LET/2006 Bangalore Dt:-18-01-2007 a sum amounting to 1% of the bill amount of the contractor will be deducted towards cess and will be credited to the Karnataka building and other Constructions labour welfare fund

Any bidder who is otherwise technically qualified withdraws from the bidding process at any stage before a final decision is taken on the tender, the EMD of such bidder shall be forfeited, the name of such bidder shall be removed from the category list of contractors at least for a minimum period of one year in DEPARTMENT/KPWD, besides making such bidders liable for blacklisting

The detailed tender notification can be had from the website https://kppp.karnataka.gov.in And linking to e-tender or in the office of the undersigned Ph No. 918046010000

The payment of bills for these works will be made as and when letter of credit received under the same Head of Account from Govt. of Karnataka

Typo-graphical errors if any will not be the ground for any claims by the contractor

If many bidders quoted lowest same price to the work and the award of work will be done by toss/ lottery system or by obtaining no objection certificate in this regard by other contractors who have quoted the same price

The work shall be tackled and completed within prescribed tender period

The bidder should adhere all terms and conditions as mentioned in the tender notification and bid documents

No interest will be paid by Karnataka Neeravari Nigam Limited on the Earnest Money deposited

The contractor is responsible for any damages due to natural calamity the government or Nigam will not give any compensation for until the completion of maintenance period

The currency period of the tender shall be 180 days from the date of opening the tender/tenders. If delay in deciding the tender is inevitable, the consent of the tenderer agreeing to keep open his offer for a minimum further period should be obtained in advance. The minimum further period for which the tenderer is required to keep his offer open should invariably be specified before his consent is obtained.

During technical evaluation, if the employer finds that any certificates / information furnished is false, such bidders will be disqualified and barred from participation in the bid

If any bidder fails to satisfy the conditions mentioned above, such bids will be rejected and their financial bids will not be opened

The Bidder shall be responsible for successful performance of the contract

The Bidder to participate in the tender under single bid basis only. Any violation will attract disqualification of the bid

Further information can be had from the undersigned during office hours on telephone No.08333 263241

If the percentage quoted by the contractor for the work is below ninety percent of the updated recast estimated amount put to tender, then the contractor shall furnish an additional performance security in the form of Bank Guarantee for an amount equivalent to the difference between the cost as per quoted percentage and 90% of the updated cost put to tender. In case of contractor quoting above 125% of updated cost put to tender, then the over and above 125% of the updated cost put to tender will be withheld during the progress of work. The additional performance will be released proportionately to the bill amount till the contractor achieves progress of the entire cost of the work as per agreement. The withheld amount in the later case will be released only after entire work contracted is fully completed and so certified by the Executive Engineer. (If BG submitted while issuing fresh BG or extending any existing BG, claim period of a minimum one year from the date of expiry of validity period of BG is to be specified invariably)

The intending bidders are advised to visit the site of work, make themselves familiar with local situation about the availability of construction materials, work men, land required for construction activities, etc and shall upload along with bid with details of references for visit of different parts of the scheme in the form of photographs of site

The contractor whom tender is accepted shall execute the agreement within 20 of receipt of letter of acceptance. The successful tender will sign the agreement and deliver it to the employer

The tender processing charges paid by the bidder/firm/company are not refundable even if the tender is cancelled

The bidder/firm/company shall send the authorization letter for their representation duly attending their signature

The Employer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected

Maintenance period or the Defect liability period for this work is 12 months from the date of completion of work

If the Employer instructs the Contractor to carry out a test not specified in the Specification to check whether any work has a Defect and the test shows that it does, the Contractor shall pay for the test and any samples. If there is no Defect the test shall be a Compensation Event

The materials used for electrical works shall confirm to relevant ISI specification

Other terms and conditions as per Bid document & Tender Notification

Time allowed for completion of the work from the date of Agreement to the contractor is 3 (Three) months including monsoon period

Karnataka Neeravari Nigam Ltd., Reserves the right to verify the correctness of the statements and documents furnished and inspect the jobs executed by the agency/ firm, if found necessary

Further information can be had from the Office of the Executive Engineer, KNNL GRBCC DIVISION No.2, Hidkal Dam, Belagavi District during office hours

As per as Royalty charges is concerned, contractor should submit MDPs for each material issued from Mines and geology Department, GOK. Otherwise Penalty charges will be recovered as per Nigam circular No. 8708 dated: 26.12.2023

Fee & Financial Details

Tender Fee Amount

₹500

EMD Fee Amount

₹19,000

Important Dates

Last Activity

21 Dec 2024

Published

21 Dec 2024

Download Ends

23 Dec 2024

BOQ Preview

•

Supply of Manpower & Consummables to Kurni LIS Ist stage at Ingali Village for the year 2024-25

•

Providing round the clock Electrician, for Kurni LIS 1st stage at Ingalagi village by deploying Electrician in a day spreaded over in 2 shift of 8 hours each shift to prevent entry of miscreant and to...

•

Providing round the clock Pump Operator, for Kurni LIS 1st stage at Ingalagi village by deploying Pump Operator in a day spreaded over in 2 shift of 8 hours each shift to prevent entry of miscreant an...

•

Providing round the clock Helper for Kurni LIS 1st stage at Ingalagi village, by deploying Helper in a day spreaded over in 2 shift of 8 hours each shift to prevent entry of miscreant and to prevent t...

•

Providing round the clock Watchman for Kurni LIS 1st stage at Ingalagi village, by deploying Watchman in a day spreaded over in 2 shift of 8 hours each shift to prevent entry of miscreant and to preve...

•

Grease GEM-RR 3

•

Supplying and fixing HRC fuse link on existing switch fuse base with W loss as per IS-13703. (5.10.4 Above 315 A to 425 )

•

EHV Grade Transformer Oil - New , Transformer Oil as per IS-335:1993

Documents

Tap a document below to read it instantly. You can also download everything as a ZIP if you prefer.

NIT Documents

KW-1 2135.doc

Tender Document • 2.63 MB

New Doc 2022-08.pdf

Others - circular • 0.65 MB

NEW CIRCULAR.pdf

Others - circular • 2.81 MB

TENDER NOTIFICATION.docx

Instructions to Tenderers • 0.05 MB

New Doc 01-17-2022 13-11.pdf

Others - circular • 0.45 MB

EST2136.pdf

Others - EST • 1.58 MB

Ready to Participate?

Download all tender documents and submit your bid

Disclaimer: TenderKart has made every reasonable effort to ensure that the information on this page is accurate and authentic, however it cannot be held liable for any third-party claims or losses or any damages. TenderKart makes no warranty, expressed or implied, as to the results obtained from the use of this information. If you notice any error or omission, please let us know at .

Loading…

Tender ID

Karnataka

Retender

Works

Lift Irrigation Scheme

Supply of Manpower & Consummables to Kurni LIS Ist stage at Ingali Village for the year 2024-25

Karnataka Neeravari Nigam Limited

KNNL Division GRBCC Div No 2 Hidkal Dam | Karnataka

Amount: ₹12.7 LCloses: 6 Jan 2025Closed

Tenderkart AI

Reads all tender documents

Eligibility, documents, scope and key termsEligibility, required documents, scope of work and key terms of this tender, in one click.

Timeline

Published21 Dec 2024
Closed6 Jan 2025
Retendered21 Dec 2024